Loading...
Res No 179-22-15932RESOLUTION NO: 179-22-15932 A Resolution authorizing the City Manager to purchase and enter into a multi- year maintenance and service agreement with ADS Technology for the South Miami Parking Garage security system. WHEREAS, the City recently obtained the rights to operate the South Miami Municipal Garage and, in an effort, to improve the safety for patrons of the parking garage, the City is proposing to replace the current inoperable security camera system and; WHEREAS, the City issued Request for Qualifications, RFQ #FN2022-18 for the Design and Install of a Parking Garage Security System on August 3, 2022 which closed on September 1, 2022, and the City received six (6) submittals from the following Respondents and; 1. ADS Technology 2. Alfie Electronics 3. Bryant Integrated Technologies 4. Eyecast 5. Integrated Security Systems 6. Snappy Internet & Telecom WHEREAS, in accordance with the Evaluation Selection Criteria published in the solicitation, a Selection Committee comprised of Chairperson Alfredo Riverol, Chief Financial Officer; Captain Larry Corbin, South Miami PD; Carlos Marenco, Parking Enforcement Manager; and Atef Ali, Senior Telecommunications Technician met virtually via Zoom on September 13, 2022 to review, score and rank each proposal and; WHEREAS, the Selection Committee, decided to create a Short List of three (3) Respondents for further review and Oral Presentations and the Short List Respondents were: ADS Technology, Alfie Electronics and Integrated Security and; WHEREAS, Oral Presentations were scheduled virtually via Zoom on September 21, 2022 and at the completion of the interviews, the Selection Committee decided to complete Final Scores and Rank and recommended ADS Technology for the next phase of the Evaluation & Selection Process, Competitive Negotiations; and WHEREAS, in accordance with Selection Criteria, the Lowest Ranked Score is recommended for Competitive Negotiations; the scores are listed below: Page I of 3 Res. No. 179-22-15932 Respondent Ranking Order AVG BIDDER A.ALI A. RIVEROL LCORBIN C.MARENCO RANK RANK TOTAL ADS 1 1 3 1 1.50 1 TECHNOLOGY ALFIE 2 3 1 3 2.25 2 ELECTROINICS INTEGRATED 3 2 2 2 2.25 2 SECURITY WHEREAS, ADS Technology has been in business for twenty-four years and has extensive IT technical business and project management experience and has designed and installed garage areas camera and security systems at various condominium associations in South Florida and; WHEREAS, the design submitted by ADS Technology includes the purchase, permitting, installation, configuring, and the setting up of a fully operational state-of-the art CCTV IP Video Surveillance Solution which includes deployment of state-of-the-art POE (Power Over Ethernet) technology utilizing the latest 4K state-of-the-art CCTV technology, security cameras, License Plate Readers (LPR), Facial Recognition and, video camera coverage of the complete garage, including stairwells and elevators, emergency call boxes at a minimum on every floor, as well as all related and necessary materials at the City Municipal Garage and; WHEREAS, the system will employ a secure cloud system for remote device management, the ability to archive and share video clips and access multiple sites from anywhere and on any smart device with the cameras provided by Turing Vision video smart cameras who recently took the top prize in the 8th annual Security Sales & Integration Conference in March 2022 for the "Most Valuable Product Award-Video Surveillance Category" as the award recognizes exceptional products in video surveillance, access control, and those that make a substantial impact on integrators and; WHEREAS, the cost for the security system is $129,978 and a 5% contingency of $6,500 is recommended for any unforeseen circumstances for a not to exceed cost of $136,478 and shall be charged to account no. 301-1410-513-6430 with a balance of $279,302 before this request was made and; WHEREAS, a recurring annual cost of $22,810 will apply for a service and maintenance agreement for five (5) years beginning at the end of the one (1) year parts and labor warranty and will be reflected in the City's Adopted Budget for Fiscal Year 2023 -2024 and subsequent fiscal years for as long as the service and maintenance agreement is required. NOW THEREFORE BE IT RESOLVED BY THE MAYOR AND CITY COMMISSION OF THE CITY OF SOUTH MIAMI, FLORIDA. Page 2 of 3 Res. No. 179-22-15932 Section 1. The foregoing recitals are hereby ratified and confirmed as being true and correct and are hereby made a specific part of this resolution upon adoption hereof. Section 2. The City Manager is authorized to purchase and enter in to a multi-year maintenance and service agreement with ADS Technology for the South Miami Parking Garage security system for a not exceed cost of $136,978 including a five percent (5%) contingency ($6,500) and a recurring annual cost of $22,810 for a service and maintenance agreement five (5) years beginning at the end of the one (1) year parts and labo r warranty and will be reflected in the City's Adopted Budget for Fiscal Vear 2023 - 2024 and subsequent fiscal years for as long as the service and maintenance agreement is required. A copy of the proposal and maintenance agreement is attached. Section 3. Corrections. Conforming langu age or technical scrivener-type corrections may be made by the City Attorney for any conforming amendments to be incorporated into the final resolution for signature. Section 4. Severability. If any section clause, sentence, or phrase of this resolution is for any reason held invalid or unconstitutional by a court of competent jurisdiction, the ho ldi ng will not affect the validity of the remaining portions of this resolution. Section 5. Effective Date. This resolution will become effective immediately upon adoption. PASSED AND ADOPTED this 20 th day of December, 2022 ATTEST: READ AND APPROVED AS TO FORM, LANGUAGE, LEGALITY AND EXECUTION EX~CUTIO;~ A Page 3 of 3 APPROVED: COMMISSION VOTE: 5-0 Mayor Fernandez: Vice Mayor Bonich: Commissioner Liebman: Commissioner Corey: Commissioner Calle: Yea Yea Vea Yea Vea Agenda Item No:12. City Commission Agenda Item Report Meeting Date: December 20, 2022 Submitted by: Steven Kulick Submitting Department: Finance Department Item Type: Resolution Agenda Section: Subject: A Resolution authorizing the City Manager to purchase and enter into a multi-year maintenance and service agreement with ADS Technology for the South Miami Parking Garage security system. 3/5 (City Manager) Suggested Action: Attachments: CM Memo Parking Garage Security System.docx Resolution_Parking_Garage_Security_Sytem_12.12.22.docx FINAL RFQ DESIGN AND INSTALL PARKING GARAGE SECURITY SYSTEM 8.3.22CArev.pdf Proposals Received Report RFQ FN2022-18 9.1.22.pdf Proposal Parking Garage Cameras.pdf Parking Garage Service Agreement.pdf EXHIBIT 3 Evaluation & Selection Criteria.pdf Short List Scores and Rank RFQ FN2022-18 9.13.22.pdf FINAL Avg Rank Order and Scores 9.21.22.pdf Demand Star RFQ FN2022-18 9.1.22.pdf DRB AD RFQ FN2022-18.pdf SunBiz ADS TEchnology 12.9.22.pdf MDBR Ad.pdf MH Ad.pdf Parking Garage Schematics.pdf 1 Parking Garage Stairs Schematics.pdf 2 and the "City"). EXHIBIT 4 CONTRACT DESlGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 ~~~~~7r-".::::::-......,__-..J.J•~20~::::! jDecember I 1227 ,,., day of .=-=====~-, 20.i::..._py and (hereafter referred to as "Contractor'). wner"), through its City Manager (hereafter referred to as Contractor, for the consideration set forth herein, hereby agrees with Owner as follows: I. Contractor must furnish all labor, materials, equipment. machinery. tools, apparaws, transportation, and any other items necessary to perform all of the work shown on and described in the Contract Documents and must do everything required by this Contract and the other Contract Documents hereinafter referred to as the Work. l. The Contract Documents must include this Contract, General Conditions t.o the Contra.er.. if any, the drawings, plans, specifications and project manual, if any, any supplementary or special cond iti ons, other documents referring to this contract and signed by the parties, the solicitation documents ("hereinafter referred to as "Bid Documents") and any documents to which those documents refer which are used by Owner as well as any attachments or exhibits that are made a part of any of the documents described herein. 3. Contractor must commence the Work to be performed under this Contract on a date to be specified in a Notice to Proceed and must complete a.II Work hereunder within the length of time set forth in the Contract Documents. 4. Owner hereby agrees to pay to Contractor for the faithful performance of this Contracr.. subject to additions and deductions as provided in the Contract Documents and any properly approved, written change orders. in lawful money of the United States, the Lump Sum amount of. One-hundred twenty-nine thou sand nine hundred and seventy-eight (129 ,978.00 ) dollars ~ o.n.,-.. 11,o,.l ("Contract Price"). 5. The expenses of performing Work after regu lar working hours, and on Sunday and legal holidays must be included in the Contract Price. The City may demand, at any point in time, that any part. or all, of the Work be performed after regular working hours. In such event. the Respondent will have no right to additional compensation for such work. However, nothing contained here in authorizes work on days and during hours that are otherwise prohibited by ordinance unless specifically authorized or instructed in writing by the City. 6. If the Work is expected to require more than one month, Owner will make monthly partial payments to Contractor on the basis of a duly certified and approved schedule of values for the Work performed during ea.ch calendar month by Contractor, less the retainage (all as provided for in the Contract Documents), which is to be withheld by Owner until completion and acceptance of the complete project in accordance with this Contract and the other Contract Documents and until such Work has been accepted by the City. ,, 7. Upon submission by Contractor of evidence satisfactory to Owner that all labor, material, and other costs incurred by Contractor in connection with the construction of the Work have been paid in full. and after compliance with the terms for payment provided for in the Contract Documents. final payment on account of this Contract must be made within sixty (60) calendar days after the completion by Contractor of all Work covered by this Contract and the acceptance of such Work by Owner. 8. The Work must be completed in 60 calendar days. In the event that Contractor fails to complete the Work within the time limit stipulated in the Contract Documents, or the extended time limit agreed upon. in accordance with the procedure as more particularly set forth in the Contract Documents, liquidated damages must be paid by Contractor at the rate of S l ,S00,00 dollars per day, 9. It is further mutually agreed between the parties hereto that if a Payment and/or Performance Bond ("Bond") is required and if, at any time after the execution of this Contract and the Bond for its faithful performance and payment. the City deems the Surety or Sureties upon such bond(s) to be unsatisfactory, or if, for any reason such bond ceases to be adequate to cover the performance of the Work or payment to subcontractors and suppliers, Contractor muse. at its expense within five (5) business days after the receipt of notice from the City so to do, furnish an additional bond or bonds In such form and amount and with such Surety or Sureties as are satisfactory to the City. In such event. no further payment to Contractor will be deemed co be due under this Contract until such new or additional security for the faithful performance of the Work is furnished in the manner and in the form satisfactory to the City . 131 of 162 10. No additional Work or extras may be done unless the same is duly authorized In writing. and in advance of the work. by appropriate action by the City and in accordance with the Contract Documents. 11. The date that this contract was "made and entered into" and its effective date is the dace that the contract is the signed by the City or, if the contract is required to be approved by resolution of the City Commission. then the Effective Date is the date of the resolution approving the Contract whichever is the later date. 12. All provisions, conditions and restrictions contained in the bid document entided Instructions to Respondents are made a part of this agreement by reference. Any conflict between that document and this contract or the exhibits to this contract are to be resolved by the City Manager in the managers sole and absolute discretion. IN WITNESS WHEREOF, the parties hereto have executed this Contract on the day and date set forth next to their name below and may be signed in one or more counterparts, each of which will, without proof or accounting for the other counterpart. be deemed an original Contract. ATTESTED: s.,,w,~ tJ ~cL /J Nken A. Payn ~ Oty Clerk CONTRACTOI< ~p.,h. /l•' ""Y S1gnature:D-~~-~-~----------'. Pr int Signatory's Name: D Irv ID C s u 1r!,,e z__ Tide of Signatory: ?re~; Lr t Read and Approved as to Form, Language, Legality, and Execution Thereof: 132 of 162 EXHIBIT 5 CONSTRUCTION CONTRACT GENERAL CONDITIONS DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 ARTICLE I -DEFINITIONS Whenever used In these General Condldons or In the other Contract Documents. the foHowing terms have the meaning Indicated. These definitions always apply when the section of the Contract specifically refers to this Artide for the purpose of interpretlng a word or group of words In that sectlon of the Contract Document. However. when the section of the Contract. where the word to be defined is used. does not specifically refer to this Article to define the word or group of words, the definitions contained in this Article will not apply unless the word or group of words. in the context of It or their use In the Contract Document in question, ls/are ambiguous and open for Interpretation. In addition, these definitions do not apply to interpret terms in a specific provision of a Contract Document if that specific provision contains a definition of the term In question: Addenda; Written or graphic documents Issued prior to the Bid Opening which modify or interpret the Contract Documents. Drawings and Specificadons. by addition, deletions, clarificadons. or correction. APl)flgtion for Pa,yment: A form approved by the City's consultant (CONSUL TANT), If any. or the City Manager which is to be used by CONTRACTOR in requesting progress payments. ~ The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices and other terms for the Work to be performed. ~ Any person, firm or corpondon submitting a response to OWNER's solicitation for proposals or bids for Work. Bid Documents: The solldtatlon for bids or proposals and all documents that make up the solicitation including the instrUctions. form of documents and affidavits. Bomli; Bid bond, performance and payment bonds and other Instruments of security, furnished by CONTRACTOR and its surety In accordance with the Contract Documents and in accordance with the laws of the State of Florida. Chanie Order; A written order to CONTRACTOR signed by the City Manager authorizing an addition, deletion or revision In the Work. or an adjustment in the Contract Price or the Contract Time issued after execution of the Contract. Work Order Proposals: Written proposals from CONTRACTOR in response to orders or request for work based on the Scope of the Work provided by OWNER to CONTRACTOR. The proposal indudes line-item pricing. where there are multlp!e locations. and the timeframe for completing the work. ~ The City Manager for the Oty of South Miami, 6130 Sunset Drive. South Miami, Fl 33143, or manager's designee. unless the context wherein the word is used should more appropriately mean the City of South Miami. Qty Manager; Includes the Oty Manager's deslgnee. Construgion Observer; An authorized representative of CONSULT ANT. if any, or otherwise a representative of OWNER assigned to observe the Work performed and materials furnished by CONTRACTOR. CONTRACTOR will be notified in writing of the identity of this representative. Convag Documents: The Contract Documents include the Contract between OWNER and CONTRACTOR. other documents listed in the Contract and modifications issued after execution of the Contraa as well as all Bid Documents including but not limited to the solicitation for Bid, CONTRACTOR'S Bid, the Bonds. Insurance endorsements, Insurance CertificateS and policies, the Notice of Award, the Notice to Proceed. the General Conditions, Special Conditions. if any, any Supplementary Conditions. the Technical Specifications. Drawings. including any Incorporated specifications, addenda to the drawings Issued prior to execution of the Contract. Change Orders. Conwuction Change Directives and any written order for a minor change in the Work. and written modifications to any of the Contract Documents. Conmg Price· The total moneys payable to CONTRACTOR pursuant to the terms of the Contract Documents. Conmg Dme; The number of calendar days stated in the Contract for the completion of the Work. ConqagJne Officer; The Individual who Is authorized to sign the contraa documents on behalf of OWNER. CONTRACTOR; The person, firm, or corporation with whom OWNER has executed the Contract. CONSULTANT; The person Identified as CONSUL TANT in the Supplementary Conditions or. if none. then OWNER's designated representative as identified In the Supplementary Conditions. ~ A period of twenty-four hours measured from the beginning of the day at 12.-0 I a.m. and it will be presumed to be a calendar day unless specifically designated as a business day . .Qan: The number of twenty-four (24) hour periods following the event to which the word .. days" refers commencing at 12:0 I a.m. at the start of the next day. Therefore. in computing any period of time prescribed or 133 of 162 0oo atlowed by the Contract Documents, the day of the act. event, or default from which the designated period of time begins to run will not be lnduded. The last day of the period so computed will be Included unless it is a SaUJrday, Sunday, or legal holiday, in which event the period will run until the end of the next business day that is not a Saturday. Sunday or legal holiday. Defective Work; Work that Is unsadsfactery, faulty, or deficient In that It does not conform to the Contract Documents. or does not meet the requirements of any applicable Inspection, reference standard, teSt. or approval referred to In the Contract Documents. or has been damaged prior to CONSUL TANrS recommendation of final payment (unless responsibility for the protection thereof has been delegated to OWNER): substitutions that are not properly approved and authorized. any deficiency in the Work. materiaJs and equipment: materials and equipment furnished under the Contract that are not good quality and new unless otherwise required or permitted by the Contract Documents. Pcawings; The drawings which show the charaaer and Scope of the Work to be performed and which have been prepared or approved by CONSULT ANT. or if none, then by an architect or engineer hired by Oty Manager and are referred to in the Contract Documents. Fjeld Ordec A written order issued by CONSULTANT which clarifies or Interprets the Contract Documents in accordance with Paragraph 9.3 or orders minor changes in the Work in accordance with paragraph I 0.2. Moqrfjcation; (a) A written amendment of the Contract Documents signed by both parties. (b) a Change Order signed by both parties. ( c) a written clarification or interpretation if Issued by CONSULT ANT In accordance with paragraph 9.3 or {d) a written order for minor change or alteration in the Work Issued by CONSULTANT pursuant to Paragraph I 0.2. A modification may only be issued after execution of the Contract. it must be in writing and signed by the party against whom the modification is sought to be enforced. Non-conformin& Work means work that does not conform to the Contraa Documents and indudes work that is unsatisfaaory, faulty, or deficient or that does not meet the requirements of any applicable Inspection, reference standard, test. or that does not meet any approval required by, or referred to in, the Contraa Documents. or work that has been damaged prior to CONSUL TANrs recommendation of final payment (unless responsibility for the protection thereof has been assumed In writing by OWNER). Notice of Award; The written notice by Oty Manager to the apparent successful Bidder stating that upon compliance with the conditions precedent to be fulfilled by it within the time specified, City Manager will execute and deliver the Contract to him. Notice to Proceed; A written notice given by City Manager to CONTRACTOR (with copy to CONSUL TANT) fixing the date on which the Contract Time will commence to run and on which CONTRACTOR must start to perform its obligadons under the Contract Documents. ~ The Oty of South Miami. fmon: An Individual or legal entity. ~ The entire consuuction operation being performed as delineated in the Contraa Documents. ~ The term "policy'' as used In the Contraa Documents means the Insurance binder, If it Is Issued, the declaration page of the policy and the body of the policy, Including all endorsements • .8fQ: Request for Qualifications. Scope of Services, This phrase refers to the scope of the services or work to be performed and it has the same meaning as Scope of the Work unless the context In which the phase is used dearly means otherwise. Shop Pcawlnp; All drawings, diagrams, Illustrations, brochures, schedules. and other data which are prepared by CONTRACTOR, a Subcontractor, manufacturer, supplier, or distributor, and which Illustrate the equipment. material or some portion of the work and as required by the Contract Documents. ~ Physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. Spec;jfigtjons; Those portions of the Contract Documents consisting of written technical descriptions of materials. equipment. construction systems. standards and workmanship as applied to the Work. Subconuaaoc An lndMdual, firm or corporation having a direct contract with CONTRACTOR or with any other Subcontraaor for the performance of a part of the Work at the construction site. Subsrantjal Completion; The date, as certified by CONSUL TANT, when the construction of the Project or a certified part thereof is sufficiently completed, In accordance with the Contraa Documents, so that the Project, or a substandal part. can be utilized for the purposes for which It was Intended without restriction or limiadon to any degree. other than for the repair of minor "punch list" Items: or if there be no such certificatJon, the date when final payment is due In accordance with paragraph 14.9. However, in no event will the project or portion thereof, be deemed to be substantially completed until a certificate of occupancy or certificate of use Is lawfully Issued by the applicable governmental agency. A certificate of Substantial Completion, Issued by CONSULTANT, will be null and void If It Is based on false. misleading. or Inaccurate Information, from any source. or when it would not have been Issue but for the consideration of Work that is thereafter found to be defective to a degree greater than that which would normally to be considered by City Manager to be minor "punch list" work. 134ofl62 alieG Any person or organization who supplies materials or equipment for the Work. induding the fabriation of an item. but who does not perform labor at the site of the Work. ~ The individual or entity who is an oblfgor on a Bond and who Is bound with CONTRACTOR for the full and faithful performance of the Contraa and for the payment of all labor, services and materials used on the project. ~ Any and all obligations. dudes. and responsibilities necessary for the successful performance and completion of the Contract. ~ The term "Notice" as used herein means and Includes all written notices, demands, instructions. claims. approvals. and disapprovals required to obtain compliance with Contraa requirements. Written notice will be deemed to have been duly served if deUvered in person to the lncfividual or to a member of the firm or to an officer of the corporation for whom It Is intended, or to an authorited representative of such incfrlidual, firm, or corporation, or if def1Vered at or sent by registered mall to the last known business address. Unless otherwise stated in wridng. any notice to or demand upon OWNER under this Contraa must be delivered to Qty Manager and CONSULTANT. ARTICLE 2 -PRELIMINARY MATTERS ~ 2.1 The City Manager reserves the right to reject any and all Bids, at its sole discretion. Bids will be awarded by OWNER to the lowest responsive and responsible Bidder. No Notice of Award will be given until the City Manager has conduded its investigation. as it deems necessary, to establish, to the satisfaction of the Oty Manager, which Bidder is the most responsive and responsible of all the Bidders to complete the Work within the time prescribed and in accordance with the Contraa Documents. The Oty Manager reserves the right to rejea the Bid of any Bidder who is not believed to be. in the sole cf15cretJon and sadsfaction of Qty Manager, to be sufficiently responsible. quafHied. and finandal able to perform the work. In analyzing a Bid, the City Manager may also take into consideration alternate and unit prices. if requested by the Bid forms. If the Contraa is awarded, the Qty Manager will issue the Notice of Award and give the successful Bidder a Contraa for execution within ninety (90) day after opening of Bids. Execution of Contract; 2.2 At least four counterparts of the Contract. the Performance and Payment Bond, the Certifiates of Insurance. the Binder of Insurance if Issued, the Insurance Declaration Page if not induded in the Policy of Insurance. the Poficy of Insurance required by the Contraa Documents. the written notice of designated supervisor or superintendent as provided in Section 6.1 of the General Conditions and such other Documents as required by the Contraa Documents must be executed and delivered by CONTRACTOR to the Oty Manager within ten ( I 0) aJendar days of receipt of the Notice of Award. A Contraa Document that requires the signature of a party may be executed in counterparts separately by each of the parties and, In such evenr. each counterpart separately executed wil~ without proof or accounting for the other counterpart be deemed an original Contraa Document. fodeiture of Bid Secuci~Pedormance and Payment Bond if any are ceguiced by the applicable RFO; 2.3 Within ten ( I 0) aJendar days of being notified of the Award, CONTRACTOR must furnish a Performance Bond and a Payment Bond containing all the provisions of the Performance Bond and Payment Bond attached. 2.3.1 Each Bond must be in the amount of one hundred percent ( I 00%) of the Contraa Price guaranteeing to OWNER the completion and performance of the Work covered in such Conuaa as well as full payment of all suppliers. material man, laborers, or Subcontractor employed pursuant to this Projea. Each Bond must be with a Surety company whose qualifications meet the requirements of Sections 2.3.4. 2.3.5, and 2.3.6. 2.3.2 Each Bond must continue In effea for five years after final completion and acceptance of the Work with the liabifity equal to one hundred percent ( I 00%) of the Contraa Sum. 2.3.3 Pursuant to the requirements of Section 255.05( I), Florida Statutes. CONTRACTOR must ensure that the Bond(s) referenced above are recorded in the public records of Miami-Dade County and provide City Manager with evidence of such recording. 2.3.4 Each Bond must be executed by a surety company authorized to do business in the State of Florida as a surety, having a resident agent in the State of Florida and having been in business with a record of successful continuous operation for a least five (5) years. 13S ofl62 2.3.S The surety company must hold a current certificate of authority as acceptable surety on federal bonds In accordance with the United States Department of Treasury Circular S70, current revisions. 2.3.6 OWNER will only be required to accept a surety bond from a company with a rating A VII or better. 2.3.7 Failure of the successful Bidder to execute and deliver the Contract and deliver the required bonds and Insurance documents will be cause for the City Manager to annul the Notice of Award and declare the Bid and any security therefore forfeited. Conrragor's Pre-Sqrt Representation; 2.4 CONTRACTOR represents that it has familiarized itself with and assumes full responsibifity for having familiarized Itself with the nature and extent of the Contract Documents. Work. locality, and with all local conditions and federal, state, and local laws, ordinance. rules. and regulations that may in any manner affect performance of the Work and represents that it has correlated Its study and observations with the requirements of the Contract Documents. CONTRACTOR also represents that It has studied all surveys and investigadons. reports of subsurface and latent physical conditions referred to in the specifications and made such additional surveys and investigations as It deems necessary for the performance of the Work reflected In the Contract Documents and that he has correlated the results of all such data with the requirements of the Contract Documents. Commencement of Contract Dme; 2.S The Contract Time will commence to run on the date stated in the Notice to Proceed. Startinr the Proiea; 2.6 CONTRACTOR must start to perform its obligations under the Contract Documents on the date the Contract Time commences to run. No Work may be done at the site (as defined in Article I), prior to the date on which the Contract Time commences to run, except with the written consent of the City Manager. Before Sqrtinr Construction: 2.7 Before undertaking each part of the Work. CONTRACTOR must carefully study and compare the Contract Documents and check and verify pertinent figures shown thereon and all applicable field measurements and conditions. It must at once report in writing to CONSULT ANT any conflict. error. or disaepancy which it may discover. Neither OWNER nor CONSULT ANT will be liable for any harm, damage or loss suffered by CONTRACTOR as a result of Its failure to discover any conflict. error, or disaepancy in the Drawings or Specifications nor will CONTRACTOR be entided to any compensation for any hann, damage or loss suffered by CONTRACTOR due to any conflict. error, or discrepancy in the Contract Documents. Schedule of Completlon; 2.8 Within Ave (5) business days after delivery of the Notice to Proceed by City Manager to CONTRACTOR. CONTRACTOR must submit to CONSUL TANT for approval, an estimated construction schedule Indicating the starting and completion dates of the various sages of the Work. and a preliminary schedule of Shop Drawing submissions. CONSUL TANT will approve this schedule or require revisions thereto within seven (7) calendar days of Its submittal. If there is more than one CONTRACTOR involved In the Project. the responsibility for coordinating the Work of all CONTRACTORS will be provided in the Special Conditions. l 9 Within five (5) business days after delivery of the executed Contract by City Manager to CONTRACTOR. but before starting the Work at the site, a pre.construction conference will be held to review the above schedules, to establish procedures for handling Shop Drawings and other submissions. and for processing Applications for Payment, and to establish a working understanding between the parties as to the Project. Present at the conference will be OWNER'S representative. CONSUL TANT, Resident Project Representatives. CONTRACTOR. and Its Superintendent. QuaUfications of Subconrragoa, Maceda! men and Su12pUers; 2.10 Within five (S) business days after bid opening. the apparent lowest responsive and responsible Bidder must submit to the City Manager and CONSUL TANT for acceptance a list of the names of Subcontractors and such other persons and organizations (Including those who are to furnish principal items of materials or equipment) proposed for those portions of the Work as to which the Identity of 136 of 162 Subcontractors and ether persons and organizations must be submitted as specified in the Contract Documents. Within thirty (30) alendar days after receiving the list. CONSUL TANT will notify CONTRACTOR In writing if either the City Manager or CONSUL TANT has reasonable objection to any Subcontractor, person, or organization on such list. The fanure of the City Manager or CONSULTANT to make oblecdon to any Subcontractor, person, or organization on the 11st within thirty (30) calendar days of the receipt wlll constitute an acceptance of such Subcontractor, person, or organlzadon. Acceptance of any such Subcontractor, person or organization will not constitute a waiver of any right of OWNER or CONSULT ANT to reject defective Work. material or equipment. or any Work. materia~ or equipment not In conformance with the requirements of the Contract Documents. 2.11 If, prior to the Notice of Award, the Oty Manager or CONSULT ANT has reasonable objection to any Subcontractor, person or organlzadon listed, the apparent low Bidder may, prior to Notice of Award, submit an acceptable substitute without an lnaease In its bid price. 2.12 The apparent silence of the Contract Documents as to any detail, or the apparent omission from them of a detailed description concerning any Work to be done and materials to be furnished, will be regarded as meaning that only best pracdces are to prevail a.nd only materials and workmanship of the best quality are to be used in the performance of the Work. ARTICLE l-CORRELATION. INTERPRETATION. AND INTENT OF CONTRACT DOCUMENTS 3.1 It is the Intent of the Specifications and Drawings to describe a complete Project to be constructed in accordance with the Contract Documents. The Contract Documents comprise the entire Contract between OWNER and CONTRACTOR. They may be altered only by a modifiation as defined In An:ide I. 3.2 The Contract Documents are complementary; what ls called for by one Is as binding as if called for by all the documents. If CONTRACTOR finds a conflict. error, or disaepancy in the Contract Documents. it must. before proceeding with the Work affected thereby, immediately all it to CONSULT ANrs attention In writing. The various Contract Documents are complementary; in ase of conflict. error or disaepancy. the more saingent interpretation a.nd requirement that will provide the maximum benefit to OWNER will apply 3.3 The words .. furnish" and "furnish and install", .. install", and "provide" or words with similar meaning will be interpreted. unless otherwise specifically stated, to mean "furnish and Install complete in place and ready for service". 3.4 Miscellaneous items and accessories which are not specifically mentioned, but which are essential to produce a complete and properly operating Installation. or usable structure. providing the indiated funaions. must be furnished, and Installed without change In the Contract Price. Such miscellaneous items and accessories must be of the same quality standards. lnduding material. style. finish, strength. dass, weight. and other appliable characteristia, as specified for the major component of which the mlscellaneous Item or accessory Is an essential part. and will be approved by CONSULT ANT before installation. The above requirement ls not Intended to lndude major components not covered by or inferable from the Drawings and Specifications. 3.5 The Work of all trades under this Contract must be coordinated by CONTRACTOR In such a manner as obtaln the best workmanship possible for the entire Pro}ect. and all components of the Work must be Installed or erected In accordance with the best practices of the particular trade. 3.6 CONTRACTOR wlll be responsible for making the construcdon of habitable Structures under this Contract rain proof, and for making equipment and utility Installations properly perform the specified funaion. If CONTRACTOR is prevented from complying with this provision due to the Drawings or Spedfladons. CONTRACTOR must Immediately nodfy CONSUL TANT in writing of such limitations before proceeding with constrUction In the area where the problem exists. 3.7 Manufacturer's literawre. when referenced. must be dated, and numbered and is Intended to establish the minimum requirements acceptable. Whenever reference is given to codes. or standard specifications or other data published by regulating agencies or accepted organizations, induding but not limited to National 8ectrical Code. applicable State Building Code. Aorida Building Code. Federal Specifications. ASTM Specifiadons, various institute specifications. and the like, it will be understood that such reference is to the latest edition lnduding addenda In effect on the date of the Bid. 3.8 Brand names. where used in the technial specifications, are Intended to denote the standard or quality required for the particular material or product. The term •equal• or •equivalent•, when used in connection with brand names. will be Interpreted to mean a material or product that Is similar and equal In type, quality, size, capacity, composition. finish, color and other applicable characteristics to the material or product specified by trade name, and that Is suitable for the same use capable of performing the same function, in the opinion of CONSUL TANT, as the materlal or produet so specified. Proposed equivalent 137 of 162 items must be approved by CONSULTANT before they are purchased or incorporated In the Work. (When a brand name, catalog number, model number, or other ldentiflcatJon, is used without the phrase •or equal•, CONTRACTOR must use the brand, make and model specified). 3.9 Throughout this agreement the male pronoun may be substituted for female and neuter and vice versa and the singular words substituted for plural and plural words substituted for singular wherever applicable. 3.10 All technical interpretations will be made by CONSULTANT as set fonh in Section 9.3 below. 3.11 CONTRACTOR must advise CONSULT ANT, prior to performing any work involving a contlia in the Contract Documents and CONSUL TANT will make the final decision as to which of the documents will take precedence. If there is a conflia between or among the Contract Documents. only the latest version will apply and the latest version of the Contraa Documents. CONSULT ANT must use the following list of Contraa Documents as a guide. These documents are set forth below in the order of their precedence so that all the documents listed above a given document should have precedence over all the documents listed below It. (a) Change Orders (b) Amendments/addenda to Contract (c) Supplementary Conditions, if any (d) Contraa with all Exhibits thereto (e) General ConditJons (f) Written or figured dimensions (g) Scaled dimensions (h) Drawings of a larger scale (i) Drawings of a smaller scale 0) Drawings and Specifications are to be considered complementary to each other ARTICLE 4 -AVAILABILITY OF LANDS SUBSURFACE CONDITIONS REFERENCE POINTS Avalfabilitt of Lands; 4.1 OWNER will furnish, as Indicated in the Contract Documents. the lands upon which the Work is to be done. rights-of-way for access thereto, and such other lands which are designed for the use of CONTRACTOR. Easements for permanent struaures or permanent changes in existing facilities will be obtained and paid for by OWNER. unless otherwise specified In the Contract Documents. Other access to such lands or rights-of-way for CONTRACTOR'S convenience will be the responsibility of CONTRACTOR. CONTRACTOR must provide for all additional lands and access thereto that may be required for temporary construction fadlldes or storage of material and equipment. 4.2 The Oty Manager will, upon request. furnish to the Bidders. copies of all available boundary surveys and subsurface tests at no cost. Subsurface Condidons; 4.3 CONTRACTOR acknowledges that he has investigated prior to bidding and satisfied himself as to the conditions affecting the Work. induding but not limited to those bearing upon transportation. disposal, handling and storage of materials. availability of labor, water, electric power, roads and uncertainties of weather, river stages, tides, water rabies or similar physical conditions at the site. the conformation and conditions of the ground, the charaaer of equipment and facilities needed preliminary to and during prosecution of the Work. CONTRACTOR funher acknowledges that he has satisfied himself as to the charaaer, quality and quantity of surface and subsurface materials or obstades to be encountered insofar as this information is reasonably ascertainable from an inspection of the site. including all exploratory work done by OWNER/ CONSULTANT on the site or any contiguous site, as well as from information presented by the Drawings and Specifladons made part of this Contract. or any other information made available to it prior to receipt of bids. Any failure by CONTRACTOR to acquaint itself with the available information will not relieve it from responsibility for estimating properly the difficulty or cost of successfully performing Work. OWNER assumes no responsibility for any conclusions or interpretations made by CONTRACTOR on the basis of the information made available by OWNER/ CONSUL TANT. Differing Site Conditions; 4.4 CONTRACTOR must within forty-eight (48) hours of its discovery, and before such conditions are distUrbed, notify the Oty Manager in writing_ of: 4.4.1 Subsurface or latent physical conditions at the site differing materially from those indicated in the Contract Documents, and 138 of 162 4.4.2 Unknown physical conditions at the site. of an unusual nature, differing materially from those ordinarily encountered and generally inherent in Work of the character provided for in this Contract. The Oty Manager will promptly investigate the conditions. and if it finds that such conditions do materially differ to the extent as to cause an increase or decrease in CONTRACTOR'S cost of, or the time required for, performance of any part of the Work under this Contract. an equitable adjustment will be made and the Contract modified in writing accordingly. 4.5 No claim of CONTRACTOR under this dause will be allowed unless CONTRACTOR has given the notice required in 4.4 above; provided, however, the time prescribed therefore may be extended by the Oty Manager, but only if done in wridng signed by the Oty Manager or CONSUL TANT. ARTICLE 5 -INSURANCE Contractor must comply with the insurance requirements set forth in the Supplementary Conditions to the Contract. ARTICLE 6 • CONTRACTOR'S RESPONSIBILITIES Superyjsjon and Superintendence; 6.1 CONTRACTOR must supervise and direct the Work. It will be solely responsible for the means. methods. teehniques. sequences. and procedures of consuuction. CONTRACTOR must employ and maintain a qualified supervisor or superintendent (hereinafter referred to as "Supervisor" at the Work site who must be designated in writing by CONTRACTOR. before CONTRACTOR commences the Work and within the time required by the Contract. as CONTRACTOR'S representative at the site. The Supervisor or the person designated will have full authority to aa on behalf of CONTRACTOR and all communications given to the Supervisor will be as binding as if given to CONTRACTOR. The Supervisor(s) will always be present at each site as required to perform adequate supervision and coordination of the Worlc. (Copies of written communications given to the Supervisor will be mailed to CONTRACTOR'S home office). 6.1.1 CONTRACTOR must keep one record copy of all Specifications. Drawings, Addenda. Moamcations and Shop Drawings at the site at all times and in good order and annotated to show all changes made during the construction process. These must be available to CONSULT ANT and any OWNER Representative at all reasonable times. A set of "As-Built .. drawings. as well as the original Specificadons, Drawings. Addenda. Modifications and Shop Drawings with annotations. will be made available to City Manager at all times and It must be delivered to the City Manager upon completion of the Project. Labor, Materials and Egujpment; 6.2 CONTRACTOR must provide competent. suitably qualified personnel to lay out the Work and perform construction as required by the Contract Documents. It must always maintain good discipline and order at the site. 6.3 CONTRACTOR must furnish all materials. equipment. labor, transportation, construction equipment and machinery, tools. appliances, fuel, power, light. heat. local telephone, water and sanitary facilities and all other facilities and incidentals necessary for the execution, testing, initial operation, and completion of the Werle. 6.4 All materials and equipment must be new, except as otherwise provided in the Contract Documents. When special makes or grades of material which are normally packaged by the supplier or manufacturer are specified or approved, such materials must be delivered to the site in their original packages or containers with seals unbroken and labels intact. 6.S All materials and equipment must be applied, installed, conneaed, ereaed. used, cleaned. and conditioned in accordance with the Instructions of the applicable manufaaurer, fabricator, or processors, except as otherwise provided in the Contract Documents. Work, Mueri;lls, Equipment Products and Substitutions; 6.6 Materials, equipment and products incorporated In the Work must be approved for use before being purchased by CONTRACTOR. CONTRACTOR must submit to CONSULTANT a list of proposed materials, equipment. or products. together with such samples as may be necessary for them to determine their acceptability and obtain their approval, within ninety (90) calendar days after award of Contract unless otherwise stipulated in the Special Conditions. No request for payment for "or equat• equipment will be approved until this list has been received and approved by CONSULTANT. 6.6.1 Whenever a material. ardde or piece of equipment is identified on the Drawings or Specifications by reference to brand name or catalog number, it is understood that this is referenced for the 139 of 162 purpose of defining the performance or other salient requirements and that other products of equal capacities, quality and function must be considered. CONTRACTOR may recommend the substitution of a material, article. or piece of equipment of equal substance and function for those referred to in the Contract Documents by reference to brand name or catalog number, and if, in the opinion of CONSUL TANT. such material, anide. or piece of equipment is of equal substance and function to that specified. CONSULT ANT may approve its substitution and use by CONTRACTOR. Incidental changes or extra component parts required to accommodate the substitute will be made by CONTRACTOR without a change In the Contract Price or the Contract Time. 6.6.2 No substitute may be ordered or installed without the wriaen approval of CONSUL TANT who will be the Judge of quality. 6.6J Delay caused by obtaining approvals for substitute materials will not be considered justifiable grounds for an extension of construction dme. 6.6.4 Should any Work or materials. equipment or products not conform to requirements of the Drawings and Specifications or become damaged during the progress of the Work. such Work or materials must be removed and replaced, together with any Work disarranged by such alteratlons. at any time before completion and acceptance of the Project. AD such Work must be done at the expense of CONTRACTOR. 6.6.5 No materials or supplies for the Work may be purchased by CONTRACTOR or any Subcontractor that are subject to any chaael mortgage or under a conditional sale or other agreement by which an interest is retained by the Seller. CONTRACTOR warrants that they have good tide to all materials and supplies used by them in the Work. 6.6.6 NorH:onfonning Worlc The Oty of South Miami may withhold acceptance of, or reject items which are found upon examination. not to meet the specification requirements or conform to the plans and drawings. Upon written notification of re)ealon, items must be removed or uninstalled within five (S) business days by CONTRACTOR at his own expense and redelivered and/or reinstalled at his expense. Rejected goods left longer than thirty (30) calendar days will be regarded as abandoned and OWNER will have the right to dispose of them as its own property and CONTRACTOR thereby waives any daim to the good or to compensation of any kind for said goods. Rejection for non-conformance or failure to meet delivery schedules may result in CONTRACTOR being found in default. 6.6.7 In case of default by CONTRACTOR. the City of South Miami may procure the articles or services from other sources and hold CONTRACTOR responsible for any excess costs occasioned or incurred thereby. 6.6.8 OWNER reserves the right. In the event CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested. to obtain the good and/or services from other sources and deducting the cost from the Contraa Price without violating the Intent of the Contract. ConcemJng Subconrraaors; 6.7 CONTRACTOR may not employ any Subcontractor, against whom the Oty Manager or CONSULTANT may have reasonable objection, nor will CONTRACTOR be required to employ any Subconu-aaor who has been accepted by the Oty Manager and CONSULTANT, unless CONSULTANT determines that there Is good cause for doing so. 6.8 CONTRACTOR Is fully responsible for all acts and omissions of its Subcontraaors and of persons and organizations directly or indirectly employed by it and of persons and organizations for whose acts any of them may be liable to the same extent that they are responsible for the aas and omissions of penons directly employed by them. Nothing in the Contraa Documents create any contractual relationship between OWNER or CONSUL TANT and any Subcontraaor or other person or organization having a direct contract with CONTRACTOR. nor may it create any obligation on the pan of OWNER or CONSULTANT to pay or to see to payment of any subcontractor or other person or organization, except as may otherwise be required by law. Oty Manager or CONSULTANT may furnish to any Subcontractor or other person or organization, to the extent practicable, evidence of amounts paid to CONTRACTOR on account of specified Work done In accordance with the schedule values. 6.9 The divisions and sections of the Specifications and the identifications of any Drawings does not control CONTRACTOR in dividing the Work among Subcontractors or delineating the Work performed by any specific trade. 6.10 CONTRACTOR agrees to bind specifically every Subcontractor to the applicable terms and condidons of the Contract Documents for the benefit of OWNER. 140 of 162 6.11 All Work perfonned for CONTRACTOR by a Subcontractor must be pursuant to an appropriate agreement between CONTRACTOR and the Subcontraaor. 6.12 CONTRACTOR is responsible for the coordinition of the trades. subcontractors. material, and men engaged upon their Work. 6.1 l I CONTRACTOR must insert in all subcontracu reladve to the Work appropriate provisions to bind Subcontraaors to CONTRACTOR by the terms of these General Concfltions and other Contraa Documents Insofar as applicab!e to the Work of Subcontractors and give CONTRACTOR the same power as regards to terminating any subconuaa chat Oty Manager may exercise over CONTRACTOR under any provisions of the Contraa Documents. 6.lll The Oty Manager or CONSULTANT will not undertake to settle any differences between CONTRACTOR and their Subcontractors or between Subcontractors. 6.123 If In the opinion of CONSULT ANT, any Subcontractor on the Project proves to be incompetent or otherwise unsatisfactory, they must be promptly replaced by CONTRACTOR when directed by CONSULT ANT In wridng. 6.12A Disaimtnadon: No aalon may be taken by the any subcontractor with regard to the fulfilment of the terms of the subcontract. induding the hiring and retention of employees for the performance of Work that would disaimlnate against any person on the basis of race. color, aeed, religion. national origin, sex. age, sexual orientation, familial status, or disability. This paragraph must be made a pan of the subcontraaor's contraa with CONTRACTOR. Patent Fees and Rqyakies; 6.13 CONTRACTOR must pay all license fees and royalties and assume all costs incident to the use of any invention, design, process. or device which is the subjea of patent rights or copyrights held by others. CONTRACTOR must indemnify and hold harmless OWNER and CONSULTANT and anyone directly or indirectly employed by either of them from against all dalms, damages. losses. and expenses (induding attorney's fees) arising out of any infringement of such rights during or aher the completion of the Work and must defend all such claims in connection with any alleged infringement of such rights. 6.14 CONTRACTOR is responsible for determining the application of patent and/or royalty rights as to any materials. appliances. artides. or systems prior to bidding. However, he Is not responsible for such determination on-syswns which do not Involve purchase by them of materials. appriances. and anides. fmm: 6.1 S CONTRACTOR must secure and pay for all construction permits and licenses and must pay for all governmental charges and inspection fees necessary for the prosecution of the Work. which are applicable at the time of his Bid. When such charges are normally made by OWNER and when so stated in the Special Conditions, there will be no charges to CONTRACTOR. The City Manager will assist CONTRACTOR. when necessary. in obtaining such permits and licenses. CONTRACTOR must also pay all public utility charges. Electrigl Power and Ud>tJog; 6.16 Bectrical power required during construction must be provided by each prime CONTRACTOR as required by it. This service must be Installed by a qualified elearlcal Contraaor approved by CONSULT ANT. Ughtlng must be provided by CONTRACTOR In all spaces at all dmes where necessary for good and proper workmanship, for Inspection or for safety. No temporary power may be used off temporary lighting lines without specific approval of CONTRACTOR. Laws and Beiululons; 6.17 CONTRACTOR must comply with all notices, laws. ordinances. rules. and regulations apprsc:able to the Work. If CONTRACTOR observes that the Specifications or Drawings are at variance therewith. it must give CONSULT ANT prompt written notice thereof, and any necessary changes must be adjusted by an appropriate modification. If CONTRACTOR performs any Worlc knowing it to be contrary to such laws. ordinances. rules, and regulations. and without such notice to CONSULTANT, it must bear all costs arising there from: however, It will not be its primary responsiblllty to make certain that the Drawings and Specifications are in accordance with such laws. ordinances. rules. and regulations. Pisqimination: 6.17 A No action may be taken by CONTRACTOR with regard to the fulfilment of the terms of the Contract. induding the hiring and retention of employees for the performance of Work that would discriminate against any person on the basis of race. color, creed. religion, national origin. sex. age. sexual orientation. familial status. or disabtnty. 14'1 ofl62 ~ 6.18 Cost of all applicable sales, consumer use. and other taxes for which CONTRACTOR Is liable under the Contract must be included In the Contract Price stated by CONTRACTOR. Safeey and Prpregion; 6.19 CONTRACTOR is responsible for initiating. maintaining, and supervising all safety precautlons and programs In connection with the Work. They must take all necessary precaudons for the safety of, and must provide the necessary proteetion to prevent damage. Injury, or loss to: 6.19.1 All employees and other persons. who may be affected thereby, 6.19.2 All the Work and all materials or equipment to be Incorporated therein, whether in storage on or off the site. and 6.19.3 Other property at the site or adjacent thereto, induding uees. shrubs. lawns. walks. pavements. roadways. structures. and utilities not designated for removal, relocation, or replacement in the course of construcdon. 6.20 CONTRACTOR must designate a responsible member of their organization at the site whose duty must be the prevendon of accidents. This person must be CONTRACTOR'S Superintendent unless otherwise designated in writing by CONTRACTOR to the City Manager. Emecundes; 6.21 In emergencies affecting the safety of persons or the Work or property at the site or adjacent thereto, CONTRACTOR, without special Instruction or authorization from CONSUL TANT or City Manager, is obligated to aa. at his discretion. to prevent threatened damage. injury, or loss. He must give CONSULT ANT prompt written notice of any significant changes In the Work or deviations from the Contract Documents caused thereby. If CONTRACTOR believes that additional Work done by him in an emergency which arose from auses beyond his control entitles him to an inaease In the Contract Price or an extension of the Contract Time, he may make a claim therefore as provided in Artides 11 and 12. The Oty Manager reserves the right In the City Manager's sole and absolute discretion and when in the best Interest of the Oty, to suspend the work or services or cancel this contract in the event of an emergency that effects the Oty of South Miami, its residents or businesses and that has been declared an emergency by the Governor, Mayor of Miami-Dade County or by the City Manager pursuant to the City Manager"s Emergency Management powers set forth In Ch. 14 of the City's Code of Ordinances. In such event. the CONTRACTOR Is only be entided to be paid for the reasonable value of the work performed and any casts advanced that cannot be mitigated by CONTRACTOR. Shgp PcawJoa and Samples; 6.22 After checking and verifying all field measurements. CONTRACTOR must submit to CONSULT ANT for review, in accordance with the accepted schedule of shop drawing submissions. six (6) copies (or at CONSULT ANT option, one reprodudble copy) of all Shop Drawings. which must have been checked by and stamped with the approval of CONTRACTOR. The Shop Drawings must be numbered and identified as CONSULT ANT may require. The data shown on the Shop Drawings must be complete with respect to dimensions. design criteria, materials of construction and the like to enable CONSULTANT to review the informadon without any unnecessary investigation. 6.23 CONTRACTOR must also submit to CONSULTANT for review, with such promptness as to cause no delay In Work. all samples required by the Contract Documents. All samples must have been checked by and stamped with the approval of CONTRACTOR. Identified clearly as to material, manufaaurer, any pertinent-catalog numbers. and the use for which intended. 6.24 At the time of each submission, CONTRACTOR must notify CONSUL TANT, in writing, of any deviadons between the Shop Drawings or samples and the requirements of the Contract Documents. 6.25 CONSUL TANT must review with responsible promptness Shop Drawings and Samples. but his review is only for confonnance with the design concept of the Project and for compliance with the infonnation given in the Contract Documents. The review of a separate item as such will not indicate review of the assembly in which the Items functions. CONTRACTOR must make any corrections required by CONSULTANT and must return the required number of correaed copies of Shop Drawings and resubmit new samples until the review is satisfaaory to CONSULT ANT. CONTRACTOR must notify CONSULT ANT, in writing. of any prior Shop Drawing or revisions to Shop Drawings that are in conffict with each submission or re-submission. CONTRACTOR'S stamp of approval on any Shop Drawings or sample will constiwte representation to OWNER and CONSUL TANT that CONTRACTOR has either determined and/or verified all quantities, dimension, field construction criteria. materials. catalog numbers 142 ofl62 and similar data or they assume full responsibility for doing so. and that they have reviewed or coordinated each Shop Drawing or sample with the requirements of the Work and the Conuaa Documents. 6.26 No Work requiring a submittal of a Shop Drawing or sample may be commenced until the submission has been reviewed and approved in writing by CONSULTANT. A copy of each Shop Drawing and each approved sample must be kept In good order. In a book or binder. in chronological order or in such other order required by CONSULT ANT in writing, by CONTRACTOR at the site and must be available to CONSULTANT. 6.27 CONSUL TANrs review of Shop Drawings or samples will not relieve CONTRACTOR from his responsibility for any deviations from the requirements of the Contraa Documents unless CONTRACTOR has Informed CONSUL TANT. in writing. to each deviation at the time of submission and CONSUL TANT has given written approval to the specific deviation. nor may any review by CONSUL TANT relieve CONTRACTOR from responsibility for errors or omlssions in the Shop Drawings or samples. 6.27 A CONTRACTOR Is liable to OWNER for any adaltional cost or delay that is caused by its failure to notify CONSULT ANT of any of said deviations or conflicts between Shop Drawings or due to errors in the Shop Drawings or samples. Qeaoln&Up; 6.28 CONTRACTOR must dean up behind the Work as much as is reasonably possible as the Work progresses. Upon completion of the Work. and before acceptance of final payment for the Projea by OWNER. CONTRACTOR must remove all his surplus and discarded materials. excavated material and rubbish as well as all other material and equipment that does not form a part of the Work. from the property. roadways. sidewalks. parking areas. lawn. and all aa,acent property. In addition. CONTRACTOR must clean his portion of Work involved in any building under this Contract. so that no further cleaning by OWNER is necessary prior to its occupancy and he must restore all property. both public and private. which has been disturbed or damaged during the prosecution of the Work so as to leave the whole Work and Work Site in a neat and presentable condition. 6.29 If CONTRACTOR does not dean the Work site. OWNER may dean the Work Site of the materials referred to in paragraph 6.28 and charge the cost to CONTRACTOR. fubllc Convenjence and Sa{AY; 6.30 CONTRACTOR must. at all times. condua the Work In such a manner as to ensure the least practicable obstnJcdon to public travel. The convenience of the general pubnc and of the residents along and adjacent to the area of Work must be provided for in a satisfactory manner, consistent with the operation and local conditions. "Street Cosed" signs must be placed immediately adjacent to the Work. in a conspicuous position. at such locations as traffic demands. At any time that streets are required to be dosed. CONTRACTOR must notify law enforcement agencies and in particular. the City of South Miami Police Department before the street Is dosed and again as soon as it is opened. Access to fire hydrants and other fire extinguishing equipment must be provided and maintained at all times. SaoiRO' Proyjsfons; 6.31 CONTRACTOR must provide on-site office. and necessary toilet facilities. seduded from public observation, for use of all personnel on the Work Site. whether or not in his employ. They must be kept in a clean and saniwy condition and must comply with the requirements and regulations of the Pubfic Authorities having jurisdiction. They may not commit a public nuisance. Temporary field office and sanitary fadlitfes must be removed upon completion of the Work and the premises must be leh dean. Indemnification· 6.32 Contractor must comply with the indemnification requirements set forth In the RFQ and in EXHIBIT 2 of the Supplementary Conditions (Insurance and indemnification requirements). 6.33 In the event that any action or proceeding is brought against OWNER or CONSUL TANT by reason of any such daim or demand. CONTRACTOR. upon written notice from the Oty Manager, must defend such action or proceeding by counsel sadsfaaory to the City Manager. The indemnification provided above obligates CONTRACTOR to defend at Its own expense or to provide for such defense. at OWNER •s opdon. any and all claims of liability and all suits and actions of every name and description that may be brought against OWNER or CONSUL TANT. exduding only those claims that allege that the injuries arose out of the sole negligence of OWNER or CONSUL TANT. 143 ofl62 6.34 The obligadons of CONTRACTOR under paragraph 6.33 will not extend to the liability of CONSULT ANT, its agents or employees arising out of (a) the preparation or approval of maps. drawings. opinions. reports. surveys. Change Orders. designs. or spedficadons or (b) the giving of or the failure to give directions or Instructions by CONSULT ANT, its agents or employees provided such act or omission Is the primary cause of Injury or damage. 6.34A All of the forgoing lndemniftcadon provisions will survive the term of the Contract to which these General Cond°itions are a part. Indemnification may not exceed an amount equal to the total value of all Insurance coverage required by Section 5.1 of this document. Indemnification is limited to damages caused In whole or in part by any aa. omission. or default of CONTRACTOR. CONTRACTOR's subcontractors. sub-subcontraaors. materialmen. or agents of any tier or their respective employees to the extent caused by the negligence. recklessness. or intentional wrongful misconduct of the indemnifying party and persons employed or utilized by the Indemnifying pany In the performance of the consuucdon contract. Besponstbility toe Connection to Eximnr Work; 6.35 CONTRACTOR must connect Its Work to each part of the existing Work. existing building or structUre or Work previously Installed u required by the Drawings and Specifications to provide a complete installation. 6.36 Excavations. grading, fill, storm drainage. paving and any other consuuction or Installations in rights-of- ways of streets. highways. public carrier lines. utility lines. either aerial. surface or subsurface. etc.. must be done In accordance with requirements of the special conditions. OWNER will be responsible for obtaining all permits necessary for the Work desaibed in this paragraph 6.36. Upon completion of the Work. CONTRACTOR must present to CONSULTANT certificates. In triplicate. from the proper authorities. stating that the Work has been done In accordance with their requirements. 6.36.1 OWNER will cooperate with CONTRACTOR in obtaining action from any utilities or public authorities Involved in the above requirements. 6.36.2 CONSUL TANT Is responsible for obtaining elevations of curbs and gutters. pavement. storm drainage suuaures. and other items which must be established by governmental departments as soon as grading operations are begun on the slte and. in any case. sufficiently early In the constrUctlon period to prevent any adverse effect on the Project. Coopeorlon witb Governmental Pepamneng. Publjc;; Utilities, Ett,; 6.37 CONTRACTOR Is responsible for making all necessary arrangements with governmental departments. public utilities. public carriers. service companies and corporations (hereinafter referred to u "third parties'1 owning or controlling roadways. railways. water. sewer. gas. electrical conduits. telephone. and telegraph facilides such as pavements. tracks. piping. wires. cables, conduits. poles. guys. etc.. Including lnddentaJ suucwres connected therewith. that are encountered in the Work in order that such itemS a.re properly shored, supported and proteaed, that their location Is identified and to obtain authority from these third parties for relocadon If CONTRACTOR desires to relocate the Item. CONTRACTOR must give all proper notices. must comply with all requirements of such third parties In the performance of his Work. must permit entrance of such third parties on the Project in order that they may perform their necessary work. and must pay all charges and fees made by such third parties for their work. 6.37.1 CONTRACTOR'S attention ls called to the fact that there may be delays on the Project due to work to be done by governmental departments. publlc utilides. and others in repairing or moving poles. conduits. etc. CONTRACTOR must cooperate with the above parties in every way possible, so that the constntction can be completed in the least possible time. 6.37.2 CONTRACTOR must be familiar with all codes, laws. ordinances. and reguladons which In any manner affect those engaged or employed In the Work. or materials and equipment use In or upon the Work. or In any way affect the conduct of the Work. and no plea of misunderstanding will be considered on account of damage or delay caused by his Ignorance thereof. Use P,;emises; 6.38 CONTRACTOR must confine Its apparatus, storage of materials, and operations of its workmen to the limits Indicated by law, ordinances, permits and directions of CONSULTANT and Oty Manager. and may not unnecessarily encumber any part of the site or any areas off site. 6J8. I CONTRACTOR may not overload or permit any part of any suuaure to be loaded with such weight u will endanger its safety, nor may It subject any work to stresses or pressures that will endangerit. 6.38.2 CONTRACTOR must enforce the rules and regulation promulgated by CONSULT ANT and OWNER u well u their insuuctlons with regard to signs. advertisements. fires. and smoking. 144 of 162 6.38.3 CONTRACTOR must arrange and cooperate with the Caty Manager in routing and parking of automobiles of its employees, subcontraaors. and other personnel, as well as that of the material delivery trUdcs and other vehldes that come to the Projea site. 638.4 The Oty Manager wil1 designate specific areas on the site for storage. parking. ete. and the Job site must be fenced to protect the job site and the general public. 6.38.S CONTRACTOR must furnish, lnstal1, and maintafn adequate construction office facilities for all worken employed by it or by its Subcontracton. Temporary offices must be provided and located where directed and approved by CONSULT ANT. All such facilides must be furnished in saia accordance with existing governing regulations. Aeld offices must indude telephone facilities. Protection of Existing Pmpem lmprpyemeoa; 6.38 Any existing surface or subsurface improvements. such as pavements. curbs. sidewalks. pipes or utilities. footings. or stn1aures ftnduding portions thereof), trees and shrubbery, not Indicated on the Drawings or noted in the Specifications as being removed or altered must be proteeted from damage during consuuction of the Project. Any such Improvements damaged during construction of the Project must be restored at the expense of CONTRACTOR to a condition equal to that existing at the time of award of Connet. ARTICLE Z -WORK BY OTHERS, 7.1 OWNER may perform additional Work related to the Project or may let other direct contraas therefor which must contain General Conditions similar to these. CONTRACTOR must afford the other connctors who are parties to such direct contracts (or OWNER. if it is performing the additional Work itself), reasonable opportunity for the inuoduction and storage of materials and equipment and the execudon of Work and must properly connea and coordinate Its Work with thein. 7.2 If any part of CONTRACTOR'S Work depends upon proper execution or results of the Work of any other connaor or OWNER. CONTRACTOR must prompdy report to CONSULTANT in writing any defeas or defidendes in such Work that render it unsuitable for CONTRACTOR's Work. 7.3 CONTRACTOR must do all cutting, fitting, and patching of the Work that may be required to make its several pans come together property and fit to receive or be received by such other Work. CONTRACTOR may not endanger any Work of others by cutting, excavating. or otherwise altering their Work and may only cut or alter their Work with the written consent of CONSULT ANT and of the other contraaor whose work will be affected. 7.4 If the performance of additional Work by other contraaors or OWNER is not noted in the Conna Documents prior to the execution of the Contract. written notice thereof will be given to CONTRACTOR prior to starting any such additional Work. If CONTRACTOR believes that the performance of such additional Work by OWNER or othen will cause CONTRACTOR additional expense or enddes him to an extension of the Conna Time. he may make a daim therefore as provided In Artides 11 and 12. 7.5 Where praaicable. CONTRACTOR must build around the work of other separate connctors or must leave chases. slots and holes as required to receive and to conceal within the general constn1ction Work the work of such other separate contracton as directed by them. Where such chases. slots. etc., are tmpracdcab!e., the Work will require specific approval of CONSULT ANT. 7.6 Necessary chases. slots. and holes not built or left by CONTRACTOR must be cut by the separate conuaaor requiring such alteradons after approval of CONTRACTOR. CONTRACTOR must do all patching and finishing of the work of other conuaaors where it Is cut by them and such patching and finishing will be at the expense of CONTRACTOR 7.7 Cooperation is required in the use of site facilities and in the detalled execution of the Work. Each connaor must coordinate their operation with those of the other Conuaaors for the best interest of the Work in order to prevent delay in the execution thereof. 7.8 Each of several contraaors working on the Projea Site must keep themselves informed of the progress of the work of other contraaors. Should lack of progress or defective workmanshlp on the pan of other contraaors Interfere with CONTRACTOR's operations, CONTRACTOR must notify CONSULTANT immediately and in wridng. lack of such notice to CONSULTANT will be construed as acceptance by CONTRACTOR of the status of the work of other contractors as being satisfactory for proper coordination of CONTRACTOR's own Work. 7.9 The cost of extra Work resuldng from lack of notice. untimely notice. failure to respond to notice. Defective Work or rack of coordination will be CONTRACTOR's cost. 145 of 162 7.10 The Oty Manager reserves the right In the event CONTRACTOR cannot provide an item(s) or service(s) In a timely manner as requested. to obtain the good and/or services from other sources and deducting the co5t from the Contraa Price without violating the Intent of the Contraa. ARTICLE B -CIJY'S RESPONSIBILITIES, 8.1 The City Manager will Issue all communications to CONTRACTOR through CONSULT ANT. 8.2 In cases of termlnadon of employment of CONSULT ANT, the City Manager will appoint a CONSULT ANT whose status under the Contraa Documents will be that of the former CONSULT ANT. 8.3 The Oty Manager will prompdy furnish the data required of them under the Contract Ooannents. 8.4 OWNER'S duties In respect to providing lands and easements are set forth in Paragraphs 4.1 and 4.2. 8.5 OWNER will have the right to take possession of and use any completed or partially completed portions of the Work. notwithstanding the fact that the time for completing the entire Work or any portion thereof may not have expired: but such taking possession and use will not be deemed an acceptance of any Work not completed In accordance with the Contract Documents. ARTICLE 9 -CONSULTANTS' STATUS DURING CONSTRUCTION, Olis Represenqtiye; 9.1 CONSULT ANT will be OWNER'S representative during the construction period. The dudes and responsibilities and the limitations of authority of CONSUL TANT as OWNER'S representative during consuuaion are set forth In Artides I through 16 of these General Condidons and will not be extended without wriaen consent of the Oty Manager and CONSULT ANT. 9.1.1 CONSUL TANT's decision. In matters relating to aesthetia, will be final, if within the terms of the Contract Documents. 9.1.2 Except as may be otherwise provided in this contract. all dalms. counterclaims. disputes. and other maaers In question between OWNER and CONSUL TANT arising out of or relating to this Contract or the breach thereof. will be decided in a court of competent jurisdiction within the State of Aorida. Yisia to SJte; 9.2 CONSUL TANT must provide an inspector to make periodic visits to the site at each phase of construction to observe the progress and quality of the executed Work and to determine if the Work is proceeding In accordance with the Contract Documents. His efforts must be direaed toward providing assurance for OWNER and all applicable regulatory agencies that construction is In compliance with the Construction Documents and applicable laws. rules. and regulations. On the basis of these on site- observations as an experienced and qualified design professional, he must keep the City Manager informed of the progress of the Work and must guard OWNER against defects and deficiendes in the Work of CONTRACTOR. Qarifications and lorer:preradons; 9.3 CONSULT ANT wlll lssu~ with reasonable promptness. such written clarifications. or Interpretations of the Contract Documents (In the form of Drawings or otherwise) as it may detennine necessary, which will be consistent with. or reasonably Inferable from. the overall Intent of the Contract Documents. If CONTRACTOR seeks an increase In the Contraa Price or extension of Contract Time based on a written clarification and/or Interpretation, It will be required to submit a timely claim as provided in Articles 11 and 12. Measurement of Ouantides; 9.4 AU Work completed under the Contract will be measured by CONSUL TANT according to the United States Standard Measures. All linear surface measurements will be made horizontally or vertically as required by the item measured. Bs:Jecdnr Pefectiye Work; 9.S CONSULTANT will have authority to disapprove or reject Work that is •oefeaive Work• as defined in Article I. It will also have authority to require special inspection or testing of the Work including Work fabricated on or off site. installed or completed as provided. If CONSUL TANT requires testing of completed Work. the cost of such inspections and/or testing must be approved in writing by the City Manager. AH consequential cost of such Inspections and testing. Including but not limited to the cost of testing and inspection. the cost of repairing any of the Work. or the work of others. the cost to move 146 of 162 furniture and equlpment and/or the cost to provide alternative facilities untll the repair work can be completed. must paid by CONTRACTOR if the Work ls found to be Defective Work. Shgp Pcawinp, Cban&e Pesters and Payments; 9.6 In connection with CONSULTANT responsibility as to Shop Drawings and samples. see paragraphs 6.2S through 6.2& Inclusive. 9.7 In connection with CONSULTANT's responsibility for Change Orders see Artides 10. 11, and 12. 9.8 In connection with CONSULTANT responsibilides with respect to the Application for Payment. etc., see Artidel4. Pecisions on Pisa&J:ttrnents; 9.10 CONSULTANT will be the Initial interpreter of the Construaion Documents. LimJqtions on Consulqnt's ResponsJbUities; 9.11 CONSULT ANT will not be responsible for the construction means, methods. techniques, sequences or procedures. or the safety precautions and programs incident thereto. 9.12 CONSULTANT will not be responsible for the acts or omissions of CONTRACTOR. or any Subcontractors, or any of their agent. servants or employees. or any other person performing any of the Work under or through them. ARTICLE Io· CHANGES IN THE WORK, I 0.1 Without Invalidating the Contraet. the Oty Manager may, at any time or from dme to time. order additions. deletions. or revisions in or to the Work which will only be authorized by a written Change Orders. Upon receipt of a Change Order, CONTRACTOR must proceed with the Work involved. All such Work must be performed under the applicable conditions of the Contraa Documents. If any authorized written Change Order causes an inaease or decrease in the Contract Price or an extension or shortening of the Contraa Time. an equitable adjustment will be made as provided In Article 11 or Article 12. A written Change Order signed by the City Manager and CONTRACTOR indicates their agreement to the terms of the Change Order. All Change Orders must be certified by CONSULT ANT as to the appropriateness and value of the change in the Work as well as to any change In the dme to complete the Work under the circumstances. The failure to include a time extension in the Change Order or in the request for a change order will result In a waiver of any extension of time due to the change in the work as refleaed in the Change Order. I 0.2 CONSUL TANT may authorize minor changes or alterations in the Work not involving extra cost and not inconsistent with the overall intent of the Contract Documents without the need for a fonnal written Change Order provided CONTRACTOR does not request additional time or additional compensadon. These may be accomplished by a written Field Order. If CONTRACTOR believes that any change or alteration authorized by CONSULTANT's Reid Order would entides CONTRACTOR to an increase In the Contraa Price or extension of Contract Time. it must submit a written notice of Intent to demand a Change Order within twenty-four (24) hours of the Issuance of the Field Order and submit a written proposal for Change Order within four (◄) days thereafter. otherwise CONTRACTOR will be deemed to have waived such claim. I 0.3 Additional Work performed by CONTRACTOR without authorization of a written Change Order will not entitle it to an Increase In the Contract Price or an extension of the Contract Time. except In the case of an emergency as provided In paragraph 6.21 and except as provided in paragraph I 0.2. I 0.4 The City Manager will execute appropriate Change Orders prepared by CONSUL TANT covering changes In the Work. to be performed as provided In paragraph 4.4, and Work performed In an emergency as provided In paragraph 6.21 and any other claim of CONTRACTOR for a change in the Contraa Time or the Contraa Price which Is approved by CONSULT ANT. 10.5 It is CONTRACTOR'S responsibility to notify its Surety of any changes affecting the general Scope of the Work or change In the Contraa Price or Contraa Time and the amount of the applicable bonds will be adjusted accordingty. CONTRACTOR must furnish proof of such an adjustment to the City Manager before commencement of the Change Order Work. The Work will be stopped until CONTRACTOR provides such proof of adjustment in the Bond amount and any such delay will be charged to CONTRACTOR. 147 of 162 ARTICLE 11 -CHANGE OF CONTRACT PRICE. 11.1 The Contraa Price constitutes the total compensation payable t0 CONTRACTOR for Performing the Work. All duties. responsibifides and obligations assigned t0 or undertaken by CONTRACTOR will be at its expense without changing the Contract Price. 11.2 The City Manager may, at any drne. without written notice to the sureties. by wriaen order designated or lndlated to be a Change Order, make any change in the Work within the general scope of the Contraa. lnduding but not limited t0 changes t0 or In: 11.2.1 Specifiadons 0nduding drawings and designs): 11.2.2 Method or manner of performance of the Work. 11.2.3 OWNER-furnished facilities. equipment. materials. services. or site; or 11.2.4 Acceleration In the performance of the Work. 11.3 Except as provided in this section, or sections referred to In this section. no order, statement. or condua of the City Manager will be treated as a Change Order or entide CONTRACTOR to an equitable adjustment unless and undl the change in the Work is specifialfy and expressly provided for in a written Change Order, or as otherwise provided in another section of the Contract Documents. 11.◄ When a Change Order ls issued by CONSULT ANT and signed by the City Manager or issued by the City Manager in writing. CONTRACTOR must perform the Work even if CONTRACTOR does not agree with the dollar amount of the Change Order. If any Change Order auses an lnaease or decrease in CONTRACTOR'S cost of, or the time required for, the performance of any part of the Work under this Contract. for which the Oty Manager and CONTRACTOR cannot reach a timely agreement. an equitable adjustment based on the cost of the Work will be made and the Contract modified accordingly. 11.S If CONTRACTOR intends tO assert a daim for an equitable adjusanent or contest the equitable adjusanent made by CONSUL TANT. it must. within ten (I 0) calendar days after receipt of a written Change Order, submit tO the Oty Manager and CONSULT ANT a written notJce induding a scatement setting forth the general nature and monetary extent of such claim for equitable adjusanent. time extension requested and supporting data. In determining the cost of the Change Order, the cosu will be limJted tO those listed In section 11.7 and 11.8. 11.6 No daim by CONTRACTOR. for an equitab!e adjustment hereunder will be allowed if not submitted in accordance with this section or If asserted aher final payment under this Contract. 11.7 The value of any Work covered by a Change Order or of any dalm for an inaease or decrease in the Contract Price will be determined In one of the following ways: 11.7.1 By negotiated lump sum. 11.7.2 On the basis of the reasonable cost and savings that resulu from the change In the Work plus a mutually agreed upon fee to CONTRACTOR to cover overhead and profit not t0 exceed 15%. If CONTRACTOR disagrees with CONSULTANrs determination of reasonab!e costs. the CONTRACT must provide a list of all cosu together with backup documentation 11.8 The term cost of the Work means the sum of all direct extra costs necessarily incurred and paid by CONTRACTOR in the proper performance of the Change Order. Except as otherwise may be agreed t0 in writing by Oty Manager, such cosu must be in amounts no higher than those prevailing In Miami• Dade County and may only Include the following items: 11.8.1 Payroll costs for employees In the dlrea employ of CONTRACTOR In the performance of the Work described In the Change Order under schedules of Job classifications agreed upon by Oty Manager and CONTRACTOR. Payroll costS for employees not employed full time on the Work must be apportioned on the basis of their time spent on the Work. Payroll cosu must be limited to salaries and wages. plus the cosu of fringe benefiu which may lndude social security contributions, unemployment. exdse and payroll raxes. workers' compensation, health and redrement benefits. sick leave, vacation, and holiday pay applicable thereto. Such employees may indude superintendents and foremen at the site. The expenses of performing Work after regular working hours. on Sunday or legal holidays will be lnduded In the above only If authorized by OWNER and provided It was not In any way, whether in whole or in part the result of the fault of CONTRACTOR due to negligence of CONTRACTOR or those acting by or through him or due In whole or In part t0 Defective Work of CONTRACTOR. 11.8.2 Cost of all materials and equipment furnished and incorporated In the Work. including costs of transportation and storage, and manufacturers' field services required in connection therewith. CONTRACTOR. must notify the City Manager of all cash discounts that are available and offer OWNER the opportunity tO deposit funds with CONTRACTOR for the payment for Items that offer a discount. Cash discounu will accrue to CONTRACTOR. unless CONTRACTOR falls t0 timely notify the City Manager of the discounts or if OWNER deposits funds with CONTRACTOR with which to make payments in which cases the cash discounts will 148 of 162 accrue to OWNER. All trade discounts. rebates and refunds. and all returns from sale of surplus materials and equipment will accrue to OWNER. and CONTRACTOR must make provisions so that they may be obtained. 11.83 Payments made by CONTRACTOR to the Subcontractors for Work performed by Subcontractors. If required by City Manager, CONTRACTOR must obtain compedtive bids from Subcontractors acceptable to him and must deliver such bids to Oty Manager who will then determine. with the advice of CONSULT ANT, which Bids will be accepted. No subcontract may be a cost-plus contract unless approved in wridng by the City Manager. If a Subcontract provides that the Subcontractor Is t0 be paid on the basis of Cost of Work plus a fee. the cost of the Work will be determined in accordance this section 11.8 and in such case the word '-Subcontractor" will be substituted for the word .. CONTRACTOR". 11.8.4 Renals of all construction equipment and machinery, except hand to0ls. and che parts thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by Oty Manager with the advice of CONSULT ANT, and the com of transportation, loading, unloacf'ing. installation, dismanding and removal thereof • all In accordance with tenns of said rental agreements. The rental of any such equipment. machinery or pans must cease when the use chereof is no longer necessary for the Work. 11.8.S Sales. use or similar axes related to the Work. and for which CONTRACTOR is liable. imposed by any governmental authority. 11.8.6 Payments and fees for permits and licenses. Costs for permits and licenses must be shown as a separate item. 11.8.7 The cost of ut11ities. fuel. and sanitary facilities at the site. 11.8.8 Minor expenses such as telegru15. long distance telephone calls. telephone service at the site. expressage. and similar petty ash items in connection with the Work. 11.8.9 Cost of premiums for additional Bonds and Insurance required solely because of changes in the Work. not to exceed two percent (2%) of the lnaease In the Cost of the Work. 11.9 The term '"Cost of the Wo~• does NOT Include any of the following: 11.9.1 Payroll com and other compensation of CONTRACTOR1S officers. executives. prindpals (of partnership and sole proprietorships), general managers, engineers. architects. estimators, lawyers. agents. expediters. timekeepers, derks, and other personnel employed by CONTRACTOR whether at the site or In its principal or a branch office for general adminlscration of the Work and not specifically Included In the schedule referred to In Subparagraph 11.S. 11.9.2 Expenses of CONTRACTOR'S principal and branch offices other than its office at the site. 11.9.3 Any part of CONTRACTOR'S capital expenses. Including interest on CONTRACTOR'S capital employed for the Work and charges against CONTRACTOR for delinquent payments. 11.9.4 Cost of premiums for all bonds and for all Insurance polides whether or not CONTRACTOR is required by the Contract Documents to purchase and maintain the same (except as otherwise provided In Subparagraph 11.8.9). 11.9.5 Cosu due to the negligence of CONTRACTOR. any Subcontractor, or anyone directly or Indirectly employed by any of them or for whose acts any of them may be liable. induding but not limited to. the correction of defective work. disposal of materials or equipment wrongly suppHed and making good any damage to property. 11.9.6 Other overhead or general expense costs of any kind and the cosu of any item not specifically and expressly Included In Paragraph 11.8. 11.10 CONTRACTOR1S fee which will be allowed to CONTRACTOR for its overhead and profit will be determined as follows: 11.10.1 A mutually acceptable firm fixed price: or if none can be agreed upon. 11.10.2 A mutually acceptable fixed percentage (not to exceed I 5%). 11.11 The amount of credit to be allowed by CONTRACTOR to OWNER for any such change which results in a net decrease In cost will be the amount of the aaual net decrease in costs calculated In the same manner as provided In 11.8. When both addidons and aedits are Involved in any one change. the net will be computed to indude overhead and profit. identified separately, for both additions and credit. provided however. CONTRACTOR will not be entided to claim lost profits for any Work not performed. ARTICLE 11. TIME FOR COMPLETION. LIQUIDATED DAMAGES AND CHANGE OF THE CONTRACT TIME. 12.1 lime is of the essence to this contraa and the date of beginning and the time for completion of the Work are essential conditions of the Contract. Therefore. the Work must be commenced on the date specified in the Nodce to Proceed and completed within the time specified for completion of the work. 149 of 162 11.2 CONTRACTOR must proceed with the Work at such rate of progress to ensure full completion within the Contract Time. It Is expressly undemood and agreed, by and between CONTRACTOR and City Manager. that the Contract Time for the comp1edon of the Work desaibed herein is a reasonable time. taking Into consideration the average dimadc and economic conditions and other factors prevailing in che locality of the Work. No extension of time will be granted due condidons that CONTRACTOR knew of or should have known of before bidding on the project or due to indement weacher, except as provided in section 12.7. 12.3 If CONTRACTOR fails to complete the Work within the Contract Time. or extenSion of time granted by che City Manager, then CONTRACTOR must pay to OWNER the amount of Uquldated damages as specified In the Contract Documents for each calendar day after the scheduled date for completion as adjusted by written Change Orders that extended the compledon date. 12.3. I These amounts are not penaldes but are liquidated damages incurred by OWNER for Its inability to obtain full use of the Project. Liquidated damages are hereby fixed and agreed upon between the parties. recognizing the Impossibility of predsely ascertaining the amount of damages that will be sustained as a consequence of such delay, and both parties desiring to obviate any question or dispute concerning the amount of said damages and the cost and effect of the failure of CONTRACTOR to complete the Contract on time. The above.stated Hquidated damages will apply separately to each phase of the Pro)ea for which a time for completion Is given. 12.3.2 Oty Manager is authorized to dedua the liquidated damages from monies due to CONTRACTOR for the Work under this Contract. 12.4 The Contract Time may only be changed by a written Change Order. Any daim for an extension in the CONTRACT TIME will be based on written notice delivered to the Oty Manager and CONSULT ANT within five (S) business days of the occurrence of the event giving rise to the claim and stating the general nature of the claJm Including supporting data. All daims for adjustment In the Contract Time will be evaluated and recommended by CONSULT ANT, with final approval by the Oty Manager. Any change in the Contract Time resulting from any such dalm must be incorporated In a written Change Order. 12.S All time Hmia mted in the Contract Documents are of the essence of the Contract. 12.6 No damage daim for delay is allowed and CONTRACTOR"s sole remedy for delay caused by OWNER will be an extension of time for the period of delay. 12.7 Extensions to the Contract Time for delays caused by the effeas of indement weather will not be granted unless the weather was unusual for South Rortda and could not have been anticipated. the abnormal weather ls doaJmented by records from the nadonal weather service and the abnormal weather is documented to have had a substandal affected on the construction schedule. 12.8 No Damages for Delay: CONTRACTOR agrees that he will not have any dalm for damages due to delay unless the delay exceeds 6 months. whether lndMdually or cumulatively, and then the damages will be limited to inaeased cost of materials that were unanddpated and that would not have been incurred but for the delay. Other than as set forth above, the only remedy for any delay will be limited to an extension of dme as provided for In Section 12.4 which will be the sole and exclusive remedy for such resuldng delay. Other than as set forth above. CONTRACTOR will not be entitled to an increase In the Contract Price or payment or compensation of any kind from OWNER for direct. indirect. consequential, impact or other costs. expenses or damages. lnduding but not Umited to, costs of accelention or inefficiency, overhead or lost profits, arising beause of delay, disruption, Interference or hindrance from any cause whatsoever, whether such delay, disruption. Interference or hindrance be reasonable or unreasonable. foreseeable or unforeseeable. or avoidable or unavoidable. 12.9 CONTRACTOR waives all daims that are not presented to City Manager in writing on or before the 21st day following the date of the event upon which the claim Is based. 12.10 Dispute Resolution: If any dispute concerning a question of fact arises under the Contract. other than termination for default or convenience. CONTRACTOR. and the city department responsible for the administration of the Contract will make a good faith effort to resolve the dispute. If the dispute cannot be resolved by agreement. then the department with the advice of the City Attorney and CONSULTANT will rule on the disputed issue and send a written copy of Its decision to CONTRACTOR. CONTRACTOR must comply with such decision and may not delay the proiect. ARTICLE 13 -GUARANTEE. 13.1 CONTRACTOR guarantees and unconditionally warrants through either the manufaaurer or CONTRACTOR directly, all materials and equipment furnished and Work performed for patent Defective Work for a period of one (I) year from the date of Anal Acceptance as Indicated in CONSULT ANT letter of Recommendation of Acceptance. if Issued. the Certificate of Occupancy, if issued. or the Certificate of Compledon, if issued by Oty Manager, whichever is applicable and if more than one is applicable. the one 150ofl62 that is Issued last. for patent Defective Work.. CONTRACTOR guarantees and unconditionally warrants through either the manufaaurer or CONTRACTOR directly, all materials and equipment furnished and Work performed for three (3) years from the date of Rnal Acceptance as lnarcated In CONSULTANT Letter of Recommencbtion of Accepance. If Issued. the Certificate of Occupancy, if issued. or the Certificate of Completion. if issued by Oty Manager, whichever is applicab!e and if more than one is applicable. the one that is Issued last. for lltent Defective Work. The City Manager will give notice of observed defects with reasonable promptness. In the event that CONTRACTOR should fail to corrmence to correct such Defeaive Work within ten (10) calendar days after having received written notice of the defect or should CONTRACTOR commence the corrective work. but fail to prosecute the C0rT'eCtive wort< continuously and diligently and in accordance with the Contraa Documents. applicable law, rules and regutadons. the City Manager may declare an event of default. terminate the Contraa In whole or In part and cause dle Defective Work to be removed or correaed and to complete the Work at CONTRACTOR's expense. and the City Ma~er will charge CONTRACTOR the cost thereby incurred. The Performance Bond will remain In full force and effect through the guarantee period. 13.2 The specific warranty periods listed in the Conuaa Documents. If different from the period of time listed in Section 13.1, wi0 take precedence over Section 13.1. I 3J CONTRACTOR must aa as agent. on a limited basis for OWNER. at the Caty Manager's option, solely for the follow-up concerning warranty compfiance for all items under manufaaurer·s Warranty/Guarantee and for the purpose of completing all fonns for Warranty/Guarantee coverage under this Contract. 13.4 In ase of default by CONTRACTOR. the City of South Miami may procure the anides or services from other sources and hold CONTRACTOR responsible for any excess costs occasioned or Incurred thereby. 13.S The Oty Manager may withhold acceptance of. or reject items which are found upon examination. not to meet the specification requirements. Upon wriaen notifiation of rejection, items must be removed within five (S) business days by CONTRACTOR at his own expense and redelivered at his expense. ReJected goods left longer than thirty (30) alendar days will be regarded as abandoned and Ctty Manager will have dle right to dispose of them as its own property and CONTRACTOR thereby waives any daim to the good or to compensation of any kind. ReJection for Non-Conforming Work or failure to meet delivery schedules may result In the Contraet being found in default. 13.6 If equipment is being provided. the standard manufaaurer•s warranty Information must be dersvered to OWNER for all equipment being proposed and. If required by the warranty. such equipment must be Installed by an authorized Installer before final payment Is made. If the manufacturer's warranty is issued to the respondent/contraaor, Respondent/Contraaor must assign it to the Oty. ARTICLE 14 -PAYMENTS AND COMPLETION, hxroeog w Coovacroc I ◄. I CONTRACTOR will not be entided to any money for any work performed before the Issuance of a Notice to Proceed on the form desaibed In the Contnct Documents and the issuance by Oty Manager of a "purchase order". or any other document. does not and will not authorize the commencement of the Work. At least ten (10) alendar days before each progress payment falls due (but not more often than once a month). CONTRACTOR must submit to CONSULTANT a partial payment esdmate filled out and signed by CONTRACTOR covering the Work performed during the period covered by the partial payment estimate and supported by such dat2 as CONSULT ANT may reasonably require. All progress payment applications after the fim progress payment must be accompanied by partial releases of lien executed by all persons, firms and corporations who have furnished labor, services or materials Incorporated into the work during the period of time for which the previous progress payment was made. releasing such claims and lien rights. if any, of those persons. If payment Is requested on the basis of materials and equipment not Incorporated In the Worlc but delivered and suitably stored at or near site. the partial payment estimate must also be accompanied by such supporting data, satisfactory to the Oty Manager, which estabUshes OWNER's tide to the material and equipment as well as certificaces of insurance providing coverage for I 00% of the value of said material and equipment covering the material and equipment from all casualties as well as theft. vandalism. fire and flood. CONTRACTOR must replace at Its expense any stored materials paid for which are either damaged or st0len before installation. CONSULTANT will within ten (10) calendar days after receipt of each panial payment estimate. either certifying in writing its approval of payment and present the partial payment estimate to the City Manager. or return the partial payment estimate to CONTRACTOR. Indicating in writing his ISi ofl62 reasons for refusing to approve payment. In the latter case. CONTRACTOR may make the necessary correaions and resubmit the partial payment estimate. OWNER. will within thirty (30) calendar days of presentation to It of any approved partial payment estimate. pay CONTRACTOR a progress payment on the basis of the approved partial payment estimate. City Manager may retain five (5%) percent of the amount of each payment until Rnal Completion and Acceptance of all Work covered by the Contract Documents. Any interest earned on the retalnage will accrue to the benefit of OWNER. 14.2 CONTRACTOR, before it receives final payment. must deliver to the City Manager a Contractor's Final Payment Affidavit as set fonh In the Aorida Consuuction Uen Statute as well as final releases of lien executed by all persons who have performed er furnished labor, services. or materials. directly or indirectly, which was Incorporated Into the Work. If any person refuses to provide such a release or provides a conditional release, the Oty Manager will have the right to Issue a joint check made payable to CONTRACTOR and such person. 14J Punch list Oty Manager and CONTRACTOR will develop a single list of items required to render complete, satisfactory. and acceptable the constrUctlon services purchased by the local govemmenQI entity. Within 30 calendar days after reaching substantial completion of the Project. City Manager will prepare a punch list of items that need to be completed and, within S days after the list of items has been developed and reviewed. the Oty Manager will deliver the punch list to CONTRACTOR. If the ProJea relates to more than one building or suucture. or involves a multiphase prefect. the Oty Manager will prepare a separate punch hst for each building and suuaure and If it is a multiphase project. for each phase. within 30 days of substantial completion of such building, suucture. and phase. [See Sec. 255.07, Aa. Stat.] The final contract completion date may not be less than 30 days after the delivery of the fiSt of items. If the fist is not timely detivered to CONTRACTOR. the contract time for completion must be extended by the number of days OWNER exceeded the required delivery date. Contractor's Warraotv of TttJe 14.3 CONTRACTOR warrants and guarantees that title to all Work. materials and equipment covered by an Application for Payment whether the Work. material or equipment Is incorporated In the Project or not. will have passed to OWNER prior to the making of the Application for Payment. free and dear of all Hens. daims, security lncerest and encumbrances (hereafter in these General Conditions referred to as •uensj: and that no Work. materials or equipment. covered by an Application for Payment. wall have been acquired by CONTRACTOR or by any other person performing the Work at the site or furnishing materials and equipment for the Project. under or pursuant to an agreement under which an interest therein or encumbrance thereon ls retained by the seller or otherwise imposed by CONTRACTOR or such other person. Apprpyal of Payment 14.4 CONSULT ANTs approval of any payment requested In an Appllcadon for Payment will constitute a representation by him to OWNER. based on CONSULTANrs on site observations of the Work in progress as an experienced professional and on his review of the Application for Payment and supporting data. chat the Work has progressed to the point indicated In the Application for Payment: that. to the best his knowledge. information and belief. the quality of the Work is In ac:cordance with the Contract Documents (subject to an evaluation of the Work as a functioning Project upon substantial completion as defined in Artlde I, to the results of any subsequent tests called for In the Contract Documents and any qualifrcadons stated in his approval): and that CONTRACTOR is entitled to payment of the amount approved. However, the approval of such payment does not mean and may not imply that CONSULT ANT made exhausdve or continuous on-site observations to check the quality or the quantity of the Work. or that he has reviewed the means, methods. techniques, sequences and procedures of construction or that he has made any examination to ascertain how or for what purpose CONTRACTOR has used the moneys paid or to be paid to him, or that tide to any Work. materials. or equipment has passed to OWNER free and dear of any liens. 14.S CONTRACTOR will not be endded to be paid unless: (a) the labor and materials listed on a payment application have been used in the construction of this Work or, as to materials included In the request for payment chat have not yet been Incorporated into the construction, such materials are on the site or stored at an approved location. and (b) payment received from the last payment application has been used to fully pay for all the laborers. subcontractors and materials reflected In chat request. other than amounts that are In dispute and that are listed In the payment application with reasonable darity as to the reason for withholding payment with 152 of 162 the name. addresses and telephone number of the person whose request is being withheld. The payment application must contain the forgoing statement and the statement must be certified by CONTRACTOR as being true. In the event that CONTRACTOR withholds payment from a Subcontraaor or Supplier, dle same amount of money will be withheld from CONTRACTOR's payment untll the issue is resolved by written a,eement between them and then a Joint check will be made payable to the person in question and CONTRACTOR In accordance with the settlement agreement. otherwise the money will be held by OWNER unn1 a judgment is entered in favor of CONTRACTOR or the person. in which case the money wm be paid according with said judgment. Nothing contained herein will indicate an intent to benefit any third persons who are not signatories to the Contract. 14.6 CONSULTANT may refuse to approve the whole or any part of any payment if, In its opinion. it is unable to make such representadons to OWNER as required this Section 14. It may also refuse to approve any payment. or It may void any prior payment application cerdficadon because of subsequently discovered evidence or the results of subsequent inspection or tests to such extent as may be necessary in its opinion to protect OWNER from loss because: 14.6.1 of Defective Work. or completed Work has been damaged requiring correction or replacement. 14.6.2 the Work for whlch payment Is requested cannot be verified. 14.6.3 dalms of Uens have been filed or received. or there ls reasonable evidence indicating the probable fifing or receipt thereof. 14.6.4 the Contna Price has been reduced because of modifications. 14.6.5 OWNER has corrected Defective Work or completed the Work In accordance with Artide 13. 14.6.6 of unsadsfaaory prosecution of the Work. induding failure to dean up as required by paragraphs 6.29 and 6.30. 14.6.7 of persistent failure to coopente with other contractors on the Projea and persistent failure to arry out the Work in accordance with the Contraa Documents. 14.6.8 of liquidated damages pa~e by CONTRACTOR. or 14.6.9 of any other Yiolation o~ or failure to comply with provisions of the Contract Documents. 14.7 Prior to Final Acceptance. City Manager, with the approval of CONSULT ANT, may use any completed or substanda(ly completed pordons of the Work provided such use does not interfere with CONTRACTOR's compledon of the Work. Such use will not constitute an acceprance of such portions of the Work. 14.8 The Oty Manager has the right to enter the premises where the Work Is being performed for the purpose of doing Work not covered by the Contract Documents. This provision may not be construed as relieving CONTRACTOR of the sole responsibility for the are and proteetion of the Work. or the restoration of any damaged Work except such as may be aused by agents or employees of OWNER. 14.9 Upon completion and acceptance of the Work CONSULT ANT will issue a Certificate attached to the Anal Appllcatlon for Payment that the Work has been accepted by it under the conditions of the Conuaa Documents. The entire balance found to be due CONTRACTOR. Including the reained percencages. but except such sums as may be lawfully retained by OWNER. will be paid to CONTRACTOR within thirty (30) calendar days of completion and acceptance of the Work. 14.10 Upon The awarded CONTRACTOR will be strongly encouraged to register as an ePayables Vendor with OWNER. The Bank of America ePayables Solution is an automated card payment process that shifts accounts payable disbursements to corporate purchasfng cards. ePayables. streamline the process of making payments to your organization going forward. City Manager will provide CONTRACTOR with a credit arcl account number to keep on file. This card has unique security features. with SO of available funds until an Invoice is approved for payment. After an Invoice has received proper and complete approval. an elearonlc remittance advice will be sent via e-maf~ or fax. which notifies CONTRACTOR that the funds have been transferred into the account linked to the card for the amount listed on the Invoice and/or remittance email. Please refer to the ePayables Questions & Answers Form contained in this RFQ or cont.act OWNER's Rnance department at (305) 663-6343 with any questions. Acceptance of Boal Payment as Belease 14.11 The Acceptance by CONTRACTOR of Final Payment will be and will operate as a release to OWNER and a waiver of all daims and all liability to CONTRACTOR other than claims previously filed and unresolved. The waiver Includes all things done or furnished in connection with the Work and for every aa and negfea of OWNER and others relating to or arising out of this Work. Any payment. however, 153 ofl62 final, or otherwise. will not release CONTRACTOR or its suredes from any obligations under the Contraa Documents or the Performance Bond and Payment Bonds. 14.12 CONSULT ANT may void any cenifiation of Subnantial Completion or Final Compledon of the Work as may be necessary 1n hls opinion to protect OWNER from loss if he determines. beause of subsequendy discovered evidence or the results of subsequent inspection or tests. that: 14.12.1 the Work Is defective. or that the completed Work has been damaged due t0 the fault of CONTRACTOR or any incfividual or entity operating under or through it requiring correction or replacement to the extent that the project is no longer Substantially Completed, or in the case of final Completion certifiadon, is no longer Finally Competed. 14.12.2 the Work necessary to be completed for the purpose of certifying the work as being Subst1ntially Completed or Anally Completed cannot be verified, 14.12.3 claims or Uens have been filed or received. or there Is reasonable evidence indicating the probable filing or receipt thereof that. if valid and paid, would reduce the amount owing t0 CONTRACTOR by 20% in the case of Substantial Completion and 5% in the case of Final Completion. 14.12.4 there Is Defective Work the value of which. if deduaed from the contna price would reduce the amount owing tO CONTRACTOR by 20% In the case of Substantial Completion and 5% in the ase of Anal Completion. 14.13 If CONSUL TANT de-certifies any portion of the Work that was certified f'lnitial Certifiation'1 by CONSULT ANT, CONTRACTOR must repay to OWNER any money paid as a result of said Initial Certifiadon being issued which will be paid only when the decertified work is re-certified. ARTICLE Is -SUSPENSION Of WORK AND TERMINATION, I 5.1 The Oty Manager may, at any time and without cause. suspend the Work or any portion thereof for a period of not more than ninety (90) calendar days by notice ln writing to CONTRACTOR and CONSULT ANT. which will fix the date on which Work win be resumed. Except for the Oty Manager's exercising his right to suspend or terminate the contraa pursuant to Article 6. Section 6.21 due to a state of emergenty, CONTRACTOR will be allowed an inaease in the Conuaa Price or an extension of the Contract Time. or both, directly attributable to any suspension and If a dalm is timely made and if It is allowed under the tenns of Artides 11 or Artide 12. Qty May Tenn;nate I 5.2 If CONTRACTOR is adjudged bankrupt or Insolvent. or if he makes a general assignment for the benefit of Its creditors. or if a tnJStee or receiver Is appointed for CONTRACTOR or for any its property. or if he files a petition to ake advantage of any debtor's act. or to reorganize under bankruptcy or similar laws. or if he repeatedly fails to supply suffident sldlled workmen or suitable materials or equipment. or if he repeatedly fails to make prompt payments to Subcontractors or for labor, materials or equipment or he disregards laws. ordinances. rules. regulations or orders of any public body having Jurisdiction. or if he disregards the authority of CONSULT ANT. or if he otherwise violates any provision of, the Contraa Documents. then the City Manager may, without preJudice to any other right or remedy and after giving CONTRACTOR and the Surety seven (7) alendar days written notice. terminate the services of CONTRACTOR and take possession of the Project and of all materials. equipment. toels. constrUaion equipment and machinery thereon owned by CONTRACTOR. and finish the Work by whateYer method It may deem expedient. In such case CONTRACTOR will not be entided to receive any further payment until the Work Is finished. If the unpaid balance of the Contract Price exceeds the direct and indirect costs of completing the Pro)eet. lnduding compensation for additional professional services, such excess will be pald to CONTRACTOR. If such cosa exceed such unpaid balance. CONTRACTOR or the Surety on the Performance Bond must pay the difference to OWNER. Such cosu Incurred by OWNER wi11 be determined by CONSULT ANT and Incorporated in a Change Order. If after termination of CONTRACTOR under this Section. it Is detennlned by a court of competent jurisdiction for any reason that CONTRACTOR was not in default. the rights and obligations of OWNER and CONTRACTOR will be the same as if the termination had been issued pursuant to Section 15.5 I 5.3 Where CONTRACTOR'S services have been so terminated by the City Manager said termination will not affect any rights of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys by OWNER due CONTRACTOR will not release CONTRACTOR from liability. 154 ofl61 IS.4 Upon seven (7) calendar days' written notice to CONTRACTOR and CONSULTANT, the City Manager may, without cause and without prejudice to any other right or remedy, elea to terminate the Contraa for the convenience of OWNER. In such case, CONTRACTOR will be paid for all Work executed and accepted by the Oty Manager as of the date of the termination. minus any deduction for damage or Defective Work. No payment will be made for profit for Work which has not been performed. I 5.4A OWNER reserves the right In the event CONTRACTOR cannot provide an 1tem(s) or service(s) in a timely manner as requested, to obtain the good and/or services from other sources and deducting the cost from the Conuaa Price without violating the intent of the Contraa. Remoya,I 0 ( Equipment I S.S In the case of termination of this Contraa before completion for any cause whateVer, CONTRACTOR. if notified to do so by the City Manager, must prompdy remove any part or all of its equipment and supplies from the property of OWNER. Should CONTRACTOR not remove such equipment and suppfies. the Oty Manager will have the right to remove them at the expense of CONTRACTOR and CONTRACTOR agrees that OWNER will not be liable for loss or damage to such equipment or supplies. Equipment and supplies will not be construed to Include such items for which CONTRACTOR has been paid In whole or in part. Coonaoc May Stop Work or Terminate I 5.6 If. through no aa or fault of CONTRACTOR. the Work Is suspended for a period of more than ninety (90) calendar days by the City Manager or by order of other public authority. or under an order of court or CONSULT ANT falls to act on any Application for Payment within thirty (30) calendar days after it is submitted, or OWNER falls to pay CONTRACTOR any sum approved by CONSULTANT. within thirty (30) calendar days of its approval, and presentation, then CONTRACTOR may, upon twenty (20) calendar days written notice to the Oty Manager and CONSUL TANT. terminate the Contract. The Oty Manager may remedy the delay or neglea within the twenty (20) calendar days. If timely remedied by OWNER. the Contraa will not be considered terminated. In lieu of terminating the Contract. if CONSULTANT has failed to aa on an Application for Payment or OWNER has failed to make any payment as afore said, CONTRACTOR may upon ten ( I 0) calendar days' notice to the City Manager and CONSULTANT stop the Werle until it has been paid all amounts then due. lndemnJficatJon of lndgpendent Consultant, I 5.7 CONTRACTOR and the City Manager hereby acknowledges that if CONSULT ANT is an independent contraetor of OWNER. CONSULT ANT may be reluctant to rule on any disputes concerning the Contract Documents or on the performance of CONTRACTOR or OWNER pursuant to the terms of the Contraa Documents. Therefore. OWNER. at CONSULTANTs request. agrees to provide CONSUL TANT with a wriaen Indemnification and hold harmless agreement to Indemnify and hold CONSULTANT harm!ess as to any decision in this regard before CONSULTANT makes an Interpretation, de-certifies a payment application, decertifies Substantial Completion. decertifies Final Completion, certifies an event of default. or approves any action which requires the approval of CONSULTANT. ARTICLE 16 -MISCELLANEOUS. 16. I Whenever any provision of the Contraa Documents requires the giving of written notice it will be deemed to have been validly given If delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended. or If delivered at or sent by registered or certified mal~ postage prepaid. to the last known business address. l 6.2 The Contract Documents are the property of OWNER. CONTRACTOR and CONSULT ANT will have the right to keep one record set of the Contraa Documents upon completion of the Project. 16.3 The duties and obligations imposed by these General Conditions, Special Conditions and Supplementary Conditions. if any, and the rights and remedies available hereunder, and. in particular but without Umiiation, the warranties, guarantees and obligations imposed upon CONTRACTOR by the Contraa Documents and the rights and remedies available to OWNER and CONSUL TANT thereunder. will be in addition to, and will not be construed in any way as a limitation of, any rights and remedies available by raw, by special guarantee or by other provisions of the Contraa Documents. 16.4 Should OWNER or CONTRACTOR suffer Injury or damage to its person or property because of any error, omission, or act of the other or of any of their employees or agents or others for whose acts they are legally liable. daim must be made In writing to the other party within twenty-one (21) calendar days of the first observance of such Injury or damage. ISS of 162 ARTICLE 17 • WAIVER Of JURY TRIAL. 17.1 OWNER and CONTRACTOR knowingly, Irrevocably voluntarily and lntendonally waive any right either may have to a trial by Iury In State or Federal Court proceedings in respect to any action. proceeding. lawsuit or counterclaim arising out of the Contract Documents or the performance of the Work thereunder. ARTICLE 18 • ATTORNEY$ FEES IURISDICJION I VENUE I GOVERNING LAW, 18.1 The Contract will be conscrued In accordance with and governed by the law of the State of Florida. 18.2 The parties submit to the I urisdlctlon of any court of competent jurisdiction in Florida regarding any claim or action arising out of or reladng to the Contract or Contract Documents. The parties agree that venue of any action to enforce the Contract is in Miami-Dade County, Florida. 18.3 Except as may be otherwise provided In the Contract Documents, all claims, counterclaims, disputes. and other matters in question between OWNER and CONTRACTOR arising out of or relating to this Contract or the breach thereof, will be decided in a court of competent Jurisdiction within the State of Florida. ARTICLE 19 • PROIECT RECORDS. 19.1 The City Manager has the right to inspect and copy during regular business hours at OWNER'S expense. the books and records and accounts of CONTRACTOR which relate In any way to the Project. and to any claim for additional compensation made by CONTRACTOR, and to conduct an audit of the financial and accounting records of CONTRACTOR which relate to the Project. CONTRACTOR will retain and make available to City Manager all such books and records and accounts. financial or otherwise. which relate to the Project and to any claim for a period of three (3) years following final completion of the Project. During the Project and the three (3) year period following final completion of the Project. CONTRACTOR must provide City Manager access to Its books and records upon five (5) business day's written nodce. 19.2 CONTRACTOR and all of its subcontraaors are required to comply with the public records law (s.119.0701) while providing services on behalf of OWNER and CONTRACTOR. under such conditions, must incorporate this paragraph in all of its subcontracts for this Project. CONTRACTOR and its subcontractors are specifically required to: (a) Keep and maintain public records required by the public agency to perform the service: (b) Upon request from the public agency's custodian of public records. provide the public agency with a copy of the requested records or allow the records to be inspeaed or copied within a reasonable time at a cost that does not exceed the cost provided In this chapter or as otherwise provided by law: (c) Ensure that public records that are exempt or confidential and exempt from public records disdosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract If the contractor does not transfer the records to the public agency; and (d) Upon completion of the contract. transfer, at no cost. to the public agency all public records in possession of the contractor or keep and maintain public records required by the public agency to perform the service. If the contractor transfers all public records to the public agency upon completion of the contract. the contractor must destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the contractor keeps and maintains public records upon completion of the contract. the contractor must meet all applicable requirements for retaJning public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records. in a format that is compatible with the Information technology systems of the public agency. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT 305-663-6340; E-mail: npayne@southmiamifl.gov; 6130 Sunset Drive, South Miami, FL 33143. 19.3 If CONTRACTOR or its subcontractor does not comply with a public records request, the City Manager has the right to enforce this contract provision by specific performance and the person who violateS this provision Is liable to OWNER for its costs of enforcing this provision. including attorney fees incurred in all proceedings, whether administrative or civil court and in all appellate proceedings. 156 of 162 ARTICLE 20 -SFfERABILIIY, 20.1 If any provision of the Contract or the applicadon thereof to any person or situation is. to any extent. held Invalid or unenforceable. the remainder of the Contract. and the application of such provisions to persons or situations other than those as to which it is held invalid or unenforceable will not be affected thereby, and will continue In full force and effect. and be enforced to the fullest extent permitted by law. ARTICLE 21 -INDEPENDENT CONTRACTOR, 21.1 CONTRACTOR Is an independent CONTRACTOR under the Contract. Services provided by CONTRACTOR must be by employees of CONTRACTOR and subject to supervision by CONTRACTOR, and not as officers. employees. or agents of OWNER. Personnel policies. tax responsibilities. social security and health Insurance, employee benefits. purchasing policies and other similar administrative procedures, applicable to services rendered under the Contract must be those of CONTRACTOR. AUICLE 22 -ASSIGNMENT, 22.1 CONTRACTOR may not transfer or assign any of its rights or duties. obligations and responsibilities arising under the terms. condidons. and provisions of this Contract without prior written consent of the Oty Manager. The City Manager will not unreasonably withhold and/or delay OWNER'S consent to the assignment of CONTRACTOR's rights. The City Manager may, in the manager's sole and absolute discretion, refuse to allow CONTRACTOR to assign Its duties, obligations and responsibilities. In any event. OWNER is not obligated to consent to such assignment unless CONTRACTOR remains joindy and severally liable for any breach of the Agreement by the assignee. the assignee meets all of OWNER's requirements to the City Manager's sole satisfaction and the assignee executes all of the Contract Documents that were required to be executed by CONTRACTOR. ARTICLE 23 -FORCE MAIEURE. 23.1 Neither party may hold the other responsible for damages or for delays in performance caused by force majeure. acts of God, or other acts or circumstances beyond the control of a party or that could not have been reasonably foreseen. prevented or avoided. For this purpose. such aas or drcurnst3nces indude. but not limited to, weather conditions affecting performance. floods. epidemics. war. riots, strikes. lockouts. or other Industrial disturbances. or protest demonstrations. Should such aas or circumstances occur, the parties will use their best efforts to overcome the difficulties and to resume the work as soon as reasonably possible. ARTICLE 24-E-YERIFY(448,095(2) 24.1 As a condition precedent to entering into this Agreement. and in compliance with Section 448.09S, Ra. Stat.. Contractor, and its subcontractors must register with and use the E-Verify system to verify work authorization status of all employees hired after January I, 2021. 24.1.1 Contractor must require each of its subcontractors to provide Contractor with an affidavit stating that the subcontractor does not employ, contraa with, or subcontract with an unauthorized alien. Contractor must maintain a copy of the subcontraaor's affidavit as part of and pursuant to the records retention requirements of this Agreement. 24.1.2 The City, Contractor, or any subcontraaor who has a good faith belief that a person or entity with which It is contracting has knowingly violated Section 448.09(1), Fla. Stat. or the provisions of this section must terminate the contract with the person or entity. 24.1.3 The Oty, upon good faith belief that a subcontractor knowingly violated the provisions of this section, but that the Contractor otherwise compiled, must prompdy notify Contractor and Contractor must immediately terminate the contraa with the subcontractor. 24.1 .4 A contra.a terminated under the provisions of this Section Is not a breach of contract and may not be considered such. 24.1.5 Any contraa termination under the provisions of this Section may be challenged no later than 20 calendar days after the date on which this Agreement is terminated pursuant to paragraph b. or c. above. 24.1.6 Contractor acknowledges that upon termination of this Agreement by the Oty for a violation of this Section by Contractor, Contraaor may not be awarded a public contract for at least one (I) year. Contractor further acknowledges that Contraaor Is liable for any additional costs incurred by the City as a result of termination of any contract for a violation of this Section. 157 of 162 24.l.7 SubcontractS. Contractor or subcontnctor must insert In any subcontractS the clauses set forth in this Section, Including this Subsection, requiring the subcontractors to Include these clauses in any lower tier subcontractS. Contractor Is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in this Section and Contnctor's failure to enforce compliance is a substantial and nnateriill breach of this Agreement. ARTICLE 25-ANTI DISCRINIMATION 25 .1 Contractor and all of its employees. subcontractors and subconsuh:ants, while performing work for the City, includ ing the hiring and retention of employees for the performance of Work. are prohibited from discriminating against anyone on the basis of race. colo r, religion , family status. sex (including sexuill orienation, gender identity and intersexuality). height. weight. domestic partnership st:2tus. labor organization membership, political affiliation. national origin, age. disability or any other classification that is federally defined as a "protected class" and Contractor mu st ake all steps necessary to prevent such discrimination by all of Its employees, subcontractors and subconsultants who are performing work for the City and must ensure nondiscrimination in all programs. services and activities that are part of the Scope of Services. A violation of this paragraph is a substantial, material breach of this Contract. 25.l Contractor must include in all of its subcontraru the following clause: "Subcontractors and all of their employees, subcontractors and subconsultants, while performing work for the City, including the hiring and retention of employees for the performance of Work. are prohibited from discriminating against anyone on the basis of race. color, religion, family status, sex (including sexual orientation, gender identity and intersexuality), height. weight. domestic partnership status, labor organization membership, politicill affiliation. national origin, age. disabil ity or any other classification that is federally defined as a "protected class". Subco ntractors must take all steps necessary to prevent such discrimination by all of their employees. subcontractors and subconsultan ts who are performing work for the Oty and must ensure nond iscrimination in all programs. services and activities that are put of the Scope of Services. A violation of this paragraph is a substantial, material breach of this Subcontract." IN WITNESS WHEREOF, the parties hereto have executed the General Conditions to acknowledge their inclusion as part of the Contract Documents on this __ day of , 20_. ATTESTED: Read and Approved as to Form. Language, Legality, and Execution Thereof: ~ONTRA~R: ~D~JµA()o/ AA 1 Signature: ..µ-i;_=:::..._-~__,'-+L_:...._ ______ _ Print Signatory's Name: {)w1() f... Sya:,-,6 ~ Title of Signatory: r M.l ~ Not OWNER: CITY OF SOUTH MIAMI Signuure: '~"~4~ City Attorney END OF SECTION 158 of 162 EXHIBIT 6 Supplementary Conditions CONSTRUCTION CONTRACT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 A. Consultanc In accordance with ARTICLE I of the General Conditions the consultant (CONSULT ANT) is defined as the person Identified as the consultant in the Supplementary Conditions or if none. then OWNER's designated representative as Identified In the Supplementary Conditions. CONSULTANrs. if any. and OWNER's Designated Represenrauve•s name. address, telephone number and facsimile number are as follows: Consultant: NIA B. T ennination or Substitution of Consultant: Nothing herein will prevent the Oty Manager from terminating the services of CONSULTANT or from substituting another 0 person" to aa as CONSULTANT. C. Plans for Construction: CONTRACTOR will be furnished 9mt(ll seu of Contraa Documents without charge. Any additional copies required will be furnished to CONTRACTOR at a cost to CONTRACTOR equaJ to the reproduction cost. D. The Scope of Services. also referred to as the Work in the contraa doaiments. Is as set forth In the RFQ and in the attached EXHIBIT I, Attachments A, B. C & P to the RFO and if there is a conftia the attached Exhibit will take precedence. E. Contractor must comply with the Insurance and Indemnification requirements is set forth in the RFQ and in the document set forth in the attached EXHIBIT 2 to the RFQ and if there is a conftia the attached Exhibit will take precedence. F. The Work must be completed in 60 mlcndar clap unless a shorter time is set forth In the Contraa and In such event the Conuaa will rake precedent notwithstanding any provision in the General Conditions to the Contract that may be to the contrary. G. CONTRACTOR has reviewed and checked aJI information and data with respea to existing Underground Facilities or conditions at or contiguous to the site and assumes responsibility for the accurate location of all Underground Facilities and conaltlons that may affea the Work. It is agreed by the parties that no additional examinations. lnvesdgatlons, explorations. tests. reports or similar Information or data in respect to any Underground Facilldes or conditions are. or will be. required by CONTRACTOR to perform and furnish the Work at the Contraa Price. within the Contract Time and in accordance with the other terms and conditions of the Contraa Documents. H. CONTRACTOR has given the City Manager written notice of all conflicts. errors or disaepancies that it has discovered In the Contraa Documents and, if any conflicts. errors or dlscrepandes have been found and notice given, CONTRACTOR represents. by submitting its proposaJ to the Oty Manager, that CONTRACTOR has received sufficient notice of the resolution thereof from the City Manager. that such resolution is acceptable to CONTRACTOR and that CONTRACTOR waives any daim regarding the conflicts. errors or discrepancies. IN WITNESS WHEREOF, the parties hereto have executed the Supplementary Conditions to acknowledge their inclusion as part of the Contraa on this __ day of ______ , 20_. co S'agnature:-F-....;;........;;.~;..,..~------ Prlnt Signatory's Name:._O_/µ_/ ____ .....;... ___ _ Tide of Signatory: }r-e l ~ ~ n,:\:: 159 or 162 ATTESTED: OWNER: CITY OF SOUTH MIAMI S~runs hJ~~ Nken;).. Payne Ocy Clerk 1 Read and Approved u to Form. Language. :~:;~ OtyAnomey END OF SECTION 160 of 162 EXHIBIT I SCOPE OF SERVICES Attachment A DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 I. General Requirements: The City of South Miami recently obtained the rights to operate the South Miami Municipal Parking Garage located at SW 73 rd Street between 58th Court and 58 th Avenue, South Miami, FL 33143. The garage currently includes approximately thirty-four (34) existing CCTV predominantly utilizing small dome cameras mounted vertically on the walls. The current security system is inadequate and does not meet the needs of the City. The City is soliciting turnkey services, including but not limited to the design, purchase, installation, configuring and permitting, for a state-of-the art CCTV IP Video Surveillance Solution by a qualified and licensed CCTV IP Video Surveillance Solution installer for commercial properties. The work specified in this Request for Qualifications (RFQ) consists of furnishing all goods, materials, supplies and services necessary to provide a completed project that meets all of the needs described in this Scope of Services and as otherwise described in this RFQ (the "Work"). The Work is to be performed per specifications and the contract documents. The Work is to be performed in accordance with the specifications and the contract documents (as defined in the Instructions for Respondents) that are required to be produced by the Contractor and that are approved by the City. This includes, but is not limited to keeping the project site clean and safe, the furnishing all labor of the Contractor and the labor of all allowable subcontractors, the cost of dumpster(s) and the disposal of materials as well as all necessary engineering and architectural plans, drawings and technical specifications and permits; all necessary equipment, including rental equipment, machinery, tools, means of transportation, the coordination with any other City contractor, subcontractors and utility companies (i.e. power, gas, water): erecting construction safety measures, including fencing, and cones, and ensuring that the safety measure are in place at the end of each working day, cleaning the construction site at the end of each working day; maintenance of traffic and hiring of off duty City police officer, if required by the City; and any other goods and services necessary to perform all of the Work. Permit fees are waived for permits required to be issued directly by the City of South Miami. Permit fees charged by other government entities, if required, are the responsibility of the Respondent/Contractor; however, in all cases; it is the responsibility of Respondent/Contractor to secure any and all permits that may be required for this project. All of the Work must be reflected in the Respondent's proposal and EXHIBIT I, SCOPE OF SERVICES, ATTACHMENTS A, B, C & D. II. Scope of Work: Scope of work is a turnkey project for the design, purchase, perm1ttmg, installation, configuring, and the setting up of a fully operational state-of-the art CCTV IP Video Surveillance Solution which includes deployment of state-of-the-art POE (Power Over Ethernet) technology utilizing the latest 4K state-of-the-art CCTV technology, security 38 of 162 cameras, License Plate Readers (LPR), Facial Recognition and, video camera coverage of the complete garage, including stairwells and elevators, emergency call boxes at a minimum on every floor, as well as all related and necessary materials at the City Municipal Garage identified in Exhibit I, Scope of Services "Site Location,,, listed below. The Respondent may leverage as much of the existing Parking Garage infrastructure as possible, without compromising the new design and functions. Given the License Plate Readers and Facial Recognition, some interface of a higher-level databases or police/security agencies would be anticipated. The new design must allow remote access to the camera system over the internet. The Respondent shall provide electrical diagrams, system design layout and structural diagrams and calculations as required. In addition, the Respondent shall provide on- going maintenance & service, and 24-7 technical support over a five (5) year term. Work activity is limited to the hours from 7:00 a.m. through 6:00 p.m., on weekdays from Monday through Friday and Saturday as provide in Section 7- 15 and 7-16 of the City's Code of Ordinances. Ill. Site Location: The project is located at • City of South Miami Municipal Parking Garage SW 73 rd Street between 58 th Court and 58 th Avenue South Miami, FL 33 143 The awarded contractor will be provided an extensive site visit of the Municipal Parking Garage facility to assist in the preparation of a cost/design proposal. IV. Construction Plans & Drawings: South Miami Municipal Parking Garage Construction Plans are located as Exhibit I, Attachment B. Parking Garage Plans are located as Exhibit I, Attachment C and a Boundary Survey is located as Exhibit I, Attachment D. V. Project Duration: The Work must be completed within 60 calendar days from the Commencement Date set forth in the Notice to Proceed/Purchase Order/Email Notification. VI. Evaluation and Selection of a Consultants: Selection of Consultants/Respondents shall be in accordance with Florida Statute 287.055, 11 Consultants Competitive Negotiation Act," and, the qualifications listed in Exhibit 3, "Evaluation and Selection Criteria.,, While the "Consultants Competitive Negotiation Act," does not legislatively apply for this project, the City will utilize the format and process for the Selection of Consultants/Respondents. It is the intention of the City to award a contract to the highest ranked Consultant/Respondent in accordance with the Exhibit 3 "Evaluation and Selection Criteria.,, 39 of 162 VII. Warranty: Respondent/Contractor must include the following with their proposal: Applicable warranty and/or guarantees of all material and labor, including: • any conditions; and • guaranteed response time for repair; and • guaranteed replacement during the warranty period; and • life expectancy of LED lighting under normal use; and • Failures during the warranty period must be repaired or replaced to the satisfaction of the City; and • the term of the warranty. At a minimum, Respondent/Contractor must warrant their Work to be free of significant defects in workmanship and materials for a period of one (I) year and if General Conditions are made part of the contract documents for this project, at a minimum, Respondent/Contractor must warrant their Work in accordance with the warranty requirements found in the General Conditions to the Contract. City Manager will be the final arbiter in determining whether the defect is significant. If equipment is being provided, the standard manufacturer's warranty information must be provided in writing for all equipment being proposed and, if required by the warranty, such equipment must be installed by an authorized installer before final payment is made. If the manufacturer's warranty is issued to the respondent/contractor, Respondent/Contractor must assign it to the City before final payment. SPECIAL NOTE BID & PERFORMANCE AND PAYMENT BONDS ARE (NOT) REQUIRED FOR THIS PROJECT. END OF SECTION 40 of 162 EXHIBIT No. I SCOPE OF SERVICES ATTACHMENT B Request for Qualifications for the Design and Install Parking Garage Security System RFQ #FN2022-18 "CONSTRUCTION PLANS, CITY OF SOUTH MIAMI MUNICIPAL PARKING GARAGE" 41 of 162 Fll,1 Ill { I South Miami Municipal Parl(ing Facility S.W. 73rd Street between 58th Court & 58th Avenue South Miami, Florida 33143 IND EX OF DRAW INGS DESI GN TEAM Civil C-t Dtmc,l.'D'!Pla., e-2 w,• .. ,&s.-,f'lan c.2 JJ~"911,.0r-~0vri." Architacluml A,0 ~Jll~MI A,i S'.o'"•n :i'•U11!1 Al r~I L'l~clM:111 A-2t1 r1rs t Low I l•lo $••tty /\:l s..ia'll'dllr~I P'M /\-la Second leyq/ L ftt S•ltly A-4 n-/dl9',II P'JJ1 A-4:i Tl-«ilM"~l l-o lllar.t, A-5 f ourt.'1 l.,.1'1 P;m A--5a J'(Mtflt,.-..11 1o ::io'111 1 Aa fd!:IL ... ~11toor)l 1.w, A-Ill rJt:t l...,111t.~ $.W17 Af £~"r,c,,£1t,3I Ol'K Al E••e-,o,E11io ,..tOni A-9 8•.-.'Cl "'1 $fc'Cf'_. /1,.9.al ~""il~- A ~(I r1c.'-'alW•S-alY't1 A-!Ill f ~1)GII W• S..-1 fll'l:'I A-!Otl f yt..<41WJIS.,.,• rttt:--:;:;~; ~ Arch 1tcctural cont. A.12 ,_~L.-, .. H,t'«t«tC1111"""9~ A-17,, ~L.-... llll''~Ctt--J f'\3"' A.-\JU fl\td l t!,01 Ro"«t«J Cl'' r,g 1~.,., /l,17c FOl,ll\i'1 t,.,.,.1 R•"kl«I C411c;~ ~ (!:''-~ Ila S!ofolrQr,t P.al'l:MI~ ~:\4. 131) 5:0,~r,:,n\P,1,v,,o'~ ~~ 111!$ Dr-'11 ', 1\-10 De l.I 11 111 7 O,,lnh ~ Sltuctural S I tlv'os. 5CJ'~JCl.l'. Ol'iJ:h 52 FOUl"~~'Ol'1Pla<l S-1 Stcc,,IILirMlftsr""Jl'l!"I 5:4 fh,,O~F~11'1L~F",-.'ff"'Jr'"MI S-.5 r 1t1Lr.1IF•~f"llllPlln 56 04ltatsSdlOCl.'n s-, rw..an: ... Or .... g-~& Mect1nnic.:1 I •,• 1 0 H.i:e1. 5,tf,q,J,,., DeU1 s v .11 1iv,u;r"1rlo')ot~n 4 •71 Wh\C58CCl>"dF'OO'P\,I !.I ll IIV,\C:,t,:1,41f'!ilt>~ 1;1,1 s,...-,,o~ 1.151 INM:Su~n '.4 61 u.,,,., M •1 I U(I~·, I,! 8 I 11'1'.11••'' Eloctrlca l (. I O r.1«1,c,1 No!it,. ()cl.1 :, St~•Ul ll'OJ t: I 1l tl«tt!c.1• li91l!Jl'l{l PL!'l c., IP ei«w;1 PQ<Mtr PW' t-1 7V E'4'11'Ctll Roon, C7H, l'dCl<:Jll,Gn-:u-,Plan E; 111> E'f("l r-(."IJPc,.~rP'...v, C:-3 1l C:'«1rr..,l l gt,: "'J Pr.-.,, r J H• rittt,.oW 1>o-.. o,l"'.,11n C-4 \l £111(.1,.r..1l l "'.h'~PL-.. (IIP(lolk.lf'CilllP_..P'..,.. r$1L £liKl/1Cia!L 1iiit,0•"'0PIMI E, 'f' E!Kiral r-· rian Pluo1binu ,. \ 1 rttttt .. .-P-.!111iif10 Po., P1 I ~t..<ll!~"M}Pb\ 1> J I f,-I\SL...,CIJJl:.,r.,-t,r,gP.1n P.A I l'"CIU'ttl rm' Plurrta'IQ F'l.1'"1 1•51 r,,i.noc,J~~ ra , P'UT1b1WJlto"ltltr1a1 1•~7 8"ort!I0,41Mr,o Fi ro Protcct1on i:p I !fo,t;l;f)llt 11' 1 1·,m l (ltnl !JJ"'111•1tu l nyo,I 11'-J ll«ona I 6""' S11 • 11'o t,i,, l a )Ol.t f ll ,\ It Id L6"oo1 l$'1t~J..:~-r la)·01-I fP.~ Fc1111n tt1 ,&' Sc~• U1101.t G)l~l. Cloent: M r. Mark mchman City or South Miam, M.R. Properties Inc . 6tJOSun,-,uen. ,6 ~r.r~11 ,.,.,.._ &,,.it11 •.•.-'" "k"1.11llPJ •.l ltff'l,F~■ C1v1I Engineer: Slc1JCl_ural En incer: Consul•Toch Eng1ncer1ng Hor shell G ill Consulting 1O5ro1r,•111mS!tN11s..,111101 Engineers, Inc. , •• ..,,.n.,·<!.-.:»11"1 4eD1 ~deleon8 ,4 S...-• ":JO Pt<~!ol'lJ1,&I ,.....,._~'d;IJ,.J1411 F,, JOS 5 Jt.11 t', Jl»-M7-J8ll Fa , 3%66~~ Architect: Bhtslcin Oes1gn Associates 18) :;.-, 'ii A,fl"-• CcmllO■~H lk.•i :1JJ13-t Ph ~ ,U,& 4-4)) ru :J0!>>1>1 1 01111 M .E P. Enqineer: W1lllam A . Borry & Associates Inc. 1(1100f,,"12~1hS!•ut 51.■."JI 111 0,-..11 Flh •,)l117 1•t1 ,,,....,IJ.100IJ , •• JM-513 9100 General Contr actor: KVC Constructors ln C. \t~,..j rffl1,1::1:n 1\II PT"! JCG-1',f-1101 fg , ;)05 l5f 1101 Fire Pr otection fngi~ecr: Simplex Grinnell l~'!l'IC".or"ITto«IIII>.,-._.,.,~ ···•-•l"'~jJlYJY., l'h fl,S..CJt.JIOO • •• 95-1 -1 35[65() I nr:cmvw I 11,1.P, l 9 10~1 l\V CCc:n11f1.Lllet 1,lM ;; ISSUED: 3-19-C\"11 BLITSTEIN DESIGN ASSOCIATES ARCHITECTS 285 SEV I LLA AVENUE ~. ~•·.f C OR A L GA BL ES , FL OR ID A 3 3 1 f {~ ! 1 ';) ;_ ~ . ·. ,!1\1 11 ,- "!~---··-••11p, •••••• n•I••• S3lON 1W3N3P ______ ,.,.,._,,. s,,~-_.....,.-:i,,, • .-. .... ,~.,,...,;.,...IIO) --.-a--•--"":~~":"=,...~ .,_, __ , ""'--l,tll\-lLIQU _ _...,,.dN'Q:l~,W-,_~- 11.wt•»-t,,..,.-..iu ~--....... ,..--.., .... 1....,.-.~...,.._ .. ,--~£~~-~==:.:::= .,;w-c., toilllc.Gk•1'W'\a._ ,.,_,. ... _. __ _, ... __. ... _.,,_.,:.-.n .... Al!l!08.:::I DU!)IJ8d 1edp1unl,l\j !WB!V\I l,nnos __ , ____ ...... _ .. __ -~'TII.C..I•-••------... u_,,....~».1-i~ ... --... r ... ~·.iaw,~~·=.:::r.= -~ ~~ti.::~~ ..__ ......... _. ___ .,. ___ _.,. -~••.::~=~.:.=..-:: _..,.-_. ... ,, .. _ _.I .. _......._ ... M----•••---... --.. ----1 .,._ .. ....._ _____ ..::-::::-.:-..:..-==. ------·-------_ ..._. __ ....... _ .. _._,._ ... -. ._ __ . ....._ ____ _ .. ~---::..::..r---:-.=.: =4~..::: ::..= .. ...._._...._~,·---..... -. -~-.......... _ ........ _ ... __ '"' ------~ .. --=-~.!"' .. -:t:~= ___ ......,. .. ll----·-N-..... -•-••-•IOI .. _ --=:...~~--:--:.:-:-..=::-.:= --·--------·-~ -----.......... ------·.:=--.:--z-:: -·---... .._ .... _.. _____ _ _____ , __ ...... _ .... __ _ ____ _, ___ .,._ __ .. , ........ -..... _. ____ ....,." _...,_ .... __ ,.,,._, ..... ....,. ... _,,,, __ ..,,.,.._.,. "-•--.,.....,._._, . .....,..,.w,-a_..""' -----.. -·----.. --... ... ..-. ...... ----~-=~= -........ -........... --.. -----.... ----.. --........ --... _....,......_. ________ ,... __ "'_.,,. ___ ..,, ... _ .. __ .... , ______ ,,_ .. _ .. ~,:_-:.,-,...:; .....,.. __ _.. .. _ ..... ...,.,_.. --·--....... --. ---•---.a .. .....:=..":"~~~i:::::: ..._. ___ .. ___ ,..__._,,,._~ ·------=:---:.::-.. ·== _ ... ,,_, __ .. __ :,:.•..:..:::.::: --~-... ------ ~OJd MBN pesod0Jd ---.. -------"""·-----·----· ...... .:~~::--==.:-.:.:=:..~~ ~-~--.. ..., . .-.. ... -.... ~-~~..E=~.:&:;$1:5::~ --·---..... .:::..="".:-.::.:-..:--...::::::~-= --.. -.. ,,-... ---... -----.-.. ,. __ ,._ .. , __ _,...,..,._ -·---... ~--·-·-.. ·-·-___ .. _ '".-:.:.--=--.:.='!Ti!/ .. ':'::.=--=--:.::-: --~-.----...... --... 11: =:--.. -=-~ -::...-..::. i::..--:-.:.' .. -.::..:::: Kl"'t, ,,. ___ .., ___ " ...... --...... ·-.... ,..._ _______ , .... __ ..... _...._.,. ___ .. _ _...., . ., -..-.................. -.....,.._ .... _ ·~ :~ ...... :r:·..;.-:..=i -:.-..::. ::-i. =-....:!?: ... __ .... _____ .,..,... __ .~ .. ------....... 1a.--------··--••-.-----.. ----.. --:.::.=::-.::---~~._::-.r;:;:::-.;:.;:;;. .:..:.o;:.:=:.r=s .. ~ .. -::.:::.-::-.. -:..:---=: --------.--•-··--·· ... --........ -...... --... --........ ....-..... -.......... --.. -....... .. _,... _ _....._. ...... _ ,............,.__..__,._ ......... ~ .. """" ,,._ ... , .... -:~r:..-:..: . .:-:::=.-=:~~ ,.., __ ...... .. !"-:..:' & ~~~.:s .. :; = ~ -..=.--..--.:--.:_-i..-:-:=£-..S--'1 ~F.= _.._ ______ _ ·---· -__ .. __ ,_,.__-. ~:.=~-J~'"E:$ ?r*~ -_,._,. _______ ,, __ _ .. ___ ............ _ ..... ........, ... _.._,...._.., -_ ...... =-=-~-::.-.:;-..::.i:--...~= ____ .., ____ ... _ ··- -..-i.. .. --•llfl-..---.. ,. .. oo=::..~~~...:t==-~ .. --::.::.=.-:-:; --...:---;;...-:.:::.-::-:.....--~ _ .. ____ ........ ------------.. --... --.. ..... :.-=:-..-:t""~~~-=== ...... -~;:s..-.:~-~·=:i:.~-= --------.. ...:::.--:::-~-::.~-= ---__ .... _____ .,.....,._...._ _ _ ... ,,,·-·----....... , __ .,.._,. _ _.,.._.,........,. KO_\,....t--•--fl• ..... _......-___ .............. _ ,11,--~1,-11-.. __ ...,_. __ .....,, _____ , ___ __ •·=--..~ .. ~.:.---=:.=~...r._:j5 ----==-~.=--r-:= ~...! = ___ ., __ ___ ..~=.,~-~...:=£==::~~ ...,._.__._....,. ....... ,.,..., ... ....,...._..,. _._. __ ·------.... . ..,..._...,._..,. ___ .. __ ·- ...:--...::.:::==1~-===-=:::ii'== --=-=--::-:::=...-:=.-:::.--:=..,;: .=-:; _,.._..__ .. ....,.....,.... __ ......_"' S31.0N 7'7'~3N3E> """::.. .. .:::.:-.:.~-=..-... :-:.:=-·.::.:"5 .,. :..::-.::: .j"'-=:!::: ~-=-..:: ::-.:: t': ......... _"' ___ .. _ _.~ .. --·---... .,.'ir..o:..'-:::~-:........_~=-S:-~ ..... -_.,_.,. __ ,,,_ ..... -- -:.::.::·.:-~-::. =: !":.::':.":..'";..: -----... ·-·------___ ,.. -·---··--.. -~ --... -•-... ...._ ... ___ .., -r-=-.r::-n::::.=::SE:5 ---~~-=-=--~--.:.:=-=-=-= -~': • .':":'!.:":S.=' ... ~==--~':.!:'-= .... ---r.~~-::::..::-:::.= __ ...,.._ -------... -· ---------.... -_ ,._, ___ .. ____ ... -·" .. -,.----·-------=-~~---: ~-:.....-= =-~.-.:::: --...... ·--·---· -:.:-:::-.. ·=~-~--...::=.~ ......... -........ -~:::-.:;:~ __ ,.,.. __ ... ___ .,._,, __ .., --... -Cl-... •--... -H-• _ ....... -.~---,.--. ... -11---w• ___ _.._ .. :=:-..::::::.-;-..=:.-::-~....::::; .=.~--:SE~-~~=~~ __ .. _ .... -.......... _.._ .,. ___ .. _ _,. ------ ~a-~~f~~~it~ ...., .. _ -.....-... --,-.. _ • :--:-::--'1:" .. ,aF""..::?:!--.:f"=:~=a .=.-.... --: = ~~ --=,:-..: ::.-:...-= ..... -.. -·,-~ .... ----.. -· ------·--........ _____ .,. •,::::.,~..::.i:-:. ..... =:. .. .:::::.-.:..-: -----.. --'ot ... 1,11,, .......... ,,._._ ---·---------_____ ....... _........,_, .... _j _...,.. .. _____ ,. -·---·--,.--:!:::..""""''= _..,. ____ , ___ ..... _., ..,_..,.. ____ ... ___ _ _ .._._,...,,_.._... ___ .. _,. -·- .. .......... ,.-~--... -... "'° _., ____ ""lo ,,, ... __ .... _ .. _..,...._,,. ___ "'° ---···--.,,.. ... __ ..,,_,t __ ,,. __ .,.. ___ ._ .. -o -... ,,..,.._....., _____ ~ .. :;. ... :1::-..::.=:i..-==ri"~l~~ ---..,.A ..................... __, __ , __ _...,,._ .... ,., ... ____ ..,. .. ,. --..... ..::;..";':;..--:t.:::..-:::: =-== ---::. ::-=:::.-:..=-':c:...-::..:~-= ... _ ... ....,_._.....,,. ......... _ .. _..,_ ..,_..,. __ .. _ .. ..___ .. ____ .,.._ .. ,,, ___ _ -... ~ Kltttl"NfCll:>IUO IIIIIMY..-Sffl N01510 IIOIIW.NI illlru:>llllOllV OOlOODllV ~ suvi:iossv · · · N'.)ISJO NIJ151l18 <:', · :: ·. --...... ---·--... N,.::.:. =~-=~HI-:..~.::. t::,=:. -=-= -----::'::-=-..... =·-.::.."L...o.:::::.=:.-: _....:::-.:.:::..~ .... ~~..:~ ______ _. ..... -...... ._ __ --... --....... ~~---·--,,_ .... ,,, ___ ,,_ .. ___ ........... --..... --=----=-:..=---=~~='== ............ --·-.. --.... .... ·-... .. ....... __ .......... ____ ... , ____ _ ,. ........ _ .. _____ ... __ ._ __ ...__.. .... -.... -----..-· --•.--____ ., ~--------·-.. ___ , ____ ~-.----.-------~-~----·-... -_ .. __ _ ._ ... _.....,_ ___ ... _______ _ ---... --.... --....... -........ --··-----... -.-•-&.e--.. __ ,,._._, __ ,__.._ .................... ... c:-. .==.i:::::::: ..:.=--~=-...:: :..= --... ----------·· )t ------·-..... _..,_w-... -------... -----·-·, ........ ,._,. ___ __ ··~---:.:.=::.-:..:::.--=...~--=--"'=='= "":.e: .. ~-=:::: ~,: .:::::.::.'"':.~:..:::: ~---...... --.. __ ,.. __ =-:-..:.:.::-::-.~.r.::-:-..t:....:::.= ----·-.. ..:.:E!::~..:.=::=.~~ ...... __ -----"t"""...=:=-::::.:..-.!t.': ____ ._._. ....... , .... -... -... -e:::::::.:.---::.-"~--=-=-==-==..=-: _____ .. ___ , __ ... .:=:.-:..-:.·.:::::-:..-:~=-:::::-~~·=:: -----...-.·-------........ __ ----_..._... ____ _ ---... -------...,.,.~=--=.:. ....,.. _____ ......, __ ...,. .... -=.!'".:. _..,.,_.,. ____ .. ____ .,..,,,._ .... -.... -----.:;:..':..:;-~.:: .... ""'-... -.._...., "Al•--"--"-.. :=-_.....:::-.. :::::::: ;.:::.:5.~ --.. .._ __ .. __ _::.:.:,.":.: ___ .., .... __ .. .. _. __ ....,.... _____ _ ______ ., __ _ ___ .. _____ _,..,,....._ .. __ ___ .......... _,,,._ .. _...,_., ... _,. __ ......._ _______ _.... .. _.._ .. )t ___ ..... ...._ ...... __ -= ·== :-~-=-= === ~ =-~.!:-S:.:~'"=--= ---... ..._ ........ -·-.,.,._ =~~=:'~:§ --==~'="=-=-= =-=-=::; =:,. ______ ........... ____ ._,.._ .. __ ,.. ,...,.,_ . ._ ___ ... ~t)~---===.-;.::.:: :-..:.::...--: .::;: s.:: ::.i:...-=::.:---..-:.-:-..:: :-.::: := -- ··-·· ·---··-···----------...... =---------------------------------~=---------~=~--------~~--' '.111111 I I I I. ~---, ! __ , ·-;, I ' _ _j • I ' ~ ---.. •, ,, . ~t • " I f ~ ;· !! 'I Ii !ii ,1 ~. :1 wt ' '.\ \\ ',\ \\11111 -,. ---~----\' J ,, -~ I • r ~\ I I: .,r-BOLLARO .,.....,. - -,-8UTST£1N DESIGN Client: wont -~ A s s o C I A r f 5 Mr. Mark Richman City of Soulh Miami ~ AR0007S10 M.R. Properties fnc. G130Su1111110rw AR.CHRECJURE INTERIOR DESIGN 1eoot.ESlh~• Souttt\l'i.m,,r1citd1t:'314l :zu,.,,...~ Q:nt~f1.DIM l,ti11M1,fbrw ~- ,10111 --------~~--...... ------....__..,..----------------- t i'1~re·· 1 !, l ~ ~I i\ ,f : .. ~ 1 .;;:: ~ ... ~, .. _ ,.. Proposed New Project South Miami Municipal Parking Facility SITE DATA. ...... ~~ ~"""-· tOfAlDtlU>,r.DNlf.A taTLhrllff'rA.'I. t&flf\ll'l.PAIIKNG\CC'VIAIO) IMllvt'l PAllll N01C~tll:tcl) JRIU.t\'tLl'AMll'Ml{CllYUl!DI •fMllVfLl"Nlfl-«llCwttllD► "Mlt'4LPNlftMJ!ROOF, I--- ·a.0t,- 1,.N1.-i .. , ..... »m.., S,.HlloQ"t >UWtltl JO.OOlto't tutlll..P--.Ol'IICIV'IXO US 1SfU.:'fUl'MCl'IIO U lf4»ll\'tlPAN<l:«<I •I.I J.ftl>ll'o'tlH.lll'11Q tCI 4"4ll\lfUWICtr,0 •C( -~-'"""'" lltAllll•l" ~'OIO_~ ~~-:Jr•L'_~-1~:•c....-.:-_~----- LEGAL DiSCRIPTION· trGAI.Olf:IC1tPt1UN lll'U 1r<1H,...."VJWl'llaU8 _.,_,, ...... 41-IO..IIWA lNloUttSIUOO,V1SD't_..., • ..._.,.,.._ . ..,, .. ---.1 ~----3,i~!Molv-e.,,,_e.._,..,olDedaC~ r~ 'DGtll•E•WIIM L"')l.lfUt-.,_.,,11,JWl•~lf!$5•,..,_.,~-1-ll ~f\., .... .... ., .......... -w.r.,...,_c1w11. t.,\MIU,oSSIAO.,,..,,·~ _,. • ..,.,. ..-~,..._, ____ ,P.-h•l_.P_,.,tecf.,..P,lill·,cllt-.-,0-,.,,,.. , ..... LEGEND ..... , 1111, SITE PLAN -,;;1•u 11111•1111 -.,..;.-.,--o ... --- 11•TlHf.VATOil ••.ll,O'o1!SJ4lt"Vf< it I ' , .. t Ii· ,I, •" 0~) ~--~ •t • ;! ,, I •i ' I 5 S O C I A TE 5 Mr. Mark Rk:hman llllfU City of South Miami ~ UTSTflN Dl51GN Cllenl: ' . .•· •. R0007570 M.R. Properties Inc. fll305'inMtDrnoo ARCHITlCIUIIEINIIRIOR DU101 ,.. __ Qnl.,._n...,. ~fu- SOut11 M ,...., flor><M 33143 itlll817 ~l!lfllUCf_,'AAl.~oeclS'Ol'S.,.,._.AM' n-N!_Ol',all"'VC'l\ll'W.fll.,.otll [ ..... ::-... _..,_., .... ~ ......... ,_,;-,;,..; ., I '"·-•-"-~···-·""'" ··--· Proposed New Project N ED l'IRSl'LEVEL South Miami Municipal Parking Facility .. ,, ···-----· -----··--·-----·r- /1/~. .:-.=·.::-:·.~ .... ~20.2005 ••nt IUlt 1st LEVEL Sult: lm" ·••et ••• __ -_,, ... _if, I iflflH I I I " EB ~lRST LEVEL UfE SAtl:TY L...,,;,iL,.,,;: : DllfSlElN DESIGN -..... ,., ASSOC I A TES ... : .. : AR0007570 AROIITECTIJRE INTERIOR DESIGN 2ass..,a.A.,._ 0:.C&blel,flll'U4 Proposed New Project South Miami Municipal Parking Facility •uhl•• 1st LEVEL LIFE SAFETY PLAN frO,Jtet ,._,,.,., ~--""-d,1.-1 _,, D'-1 CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM TO:The Honorable Mayor & Members of the City Commission FROM: Shari Kamali, City Manager DATE: December 20, 2022 SUBJECT:A Resolution authorizing the City Manager to purchase and enter into a multi-year maintenance and service agreement with ADS Technology for the South Miami Parking Garage security system. BACKGROUND:The City recently obtained the rights to operate the South Miami Municipal Garage and, in an effort, to improve the safety for patrons of the parking garage, the City is proposing to replace the current inoperable security camera system. Therefore, the City issued Request for Qualifications, RFQ #FN2022-18 for the Design and Install of a Parking Garage Security System on August 3, 2022. The solicitation closed on September 1, 2022, and the City received six (6) submittals from the following Respondents: 1. ADS Technology 2. Alfie Electronics 3. Bryant Integrated Technologies 4. Eyecast 5. Integrated Security Systems 6. Snappy Internet & Telecom In accordance with the Evaluation Selection Criteria published in the solicitation, a Selection Committee comprised of Chairperson Alfredo Riverol, Chief Financial Officer; Captain Larry Corbin, South Miami PD; Carlos Marenco, Parking Enforcement Manager; and Atef Ali, Senior Telecommunications Technician met virtually via Zoom on September 13, 2022 to review, score and rank each proposal. The Selection Committee, decided to create a Short List of three (3) Respondents for further review and Oral Presentations. The Short List Respondents were: 1. ADS Technology 2. Alfie Electronics 3. Integrated Security 3 THE CITY OF PLEASANT LIVING CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM The Oral Presentations were scheduled virtually via Zoom on September 21, 2022. At the completion of the interviews, the Selection Committee decided to complete Final Scores and Rank and recommended ADS Technology for the next phase of the Evaluation & Selection Process, Competitive Negotiations. The Selection Criteria was comprised of a weighted criteria with a maximum total score of 100 for each Respondent. Each Evaluation Selection Committee member rankedeach Respondent based on the total score for each Respondent; #1 (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The Lowest Average Rank Score is recommended for Competitive Negotiations.The results of the Final Average Rank Score are listed below: Respondent Ranking Order BIDDER A. ALI A. RIVEROL L. CORBIN C. MARENCO AVG RANK TOTAL RANK ADS TECHNOLOGY 1 1 3 1 1.50 1 ALFIE ELECTROINICS 2 3 1 3 2.25 2 INTEGRATED SECURITY 3 2 2 2 2.25 2 ADS Technology has been in business for twenty-four years and has extensive IT technical business and project management experience and has designed and installed garage areas camera and security systems at various condominium associations in South Florida. The design submitted by ADS Technology includes the purchase, permitting, installation, configuring, and the setting up of a fully operational state-of-the art CCTV IP Video Surveillance Solution which includes deployment of state-of-the-art POE (Power Over Ethernet) technology utilizing the latest 4K state-of-the-art CCTV technology, security cameras, License Plate Readers (LPR), Facial Recognition and, video camera coverage of the complete garage, including stairwells and elevators, emergency call boxes at a minimum on every floor, as well as all related and necessary materials at the City Municipal Garage. The system will employ a secure cloud system for remote device management, the ability to archive and share video clips and access multiple sites from anywhere and on any smart device. The cameras provided are Turing Vision video smart cameras who recently took the top 4 THE CITY OF PLEASANT LIVING CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM prize in the 8th annual Security Sales & Integration Conference in March 2022 forthe “Most Valuable Product Award-Video Surveillance Category.” The award recognizes exceptional products in video surveillance, access control, and those that make a substantial impact on integrators. Furthermore, the South Miami PD reviewed and approved the design as it pertains to the deployment and placement of cameras for maximum coverage and security. FUNDING:The cost for the security system is $129,978. A 5% contingency of $6,500 is recommended for any unforeseen circumstances for a not to exceed cost of $136,478 and shall be charged to account no. 301-1410-513-6430 with a balance of $279,302 before this request was made. A recurring annual cost of $22,810will applyfor a service and maintenance agreement for five (5) years beginning at the end of the one (1) year parts and labor warranty and will be reflected in the City’s Adopted Budget for Fiscal Year 2023 – 2024 and subsequent fiscal years for as long as the service and maintenance agreement is required. ATTACHMENTS:Resolution RFQ #FN2022-18 Bid Tabulation Proposal ADS Technology Parking Garage Camera Deployment Schematics Five (5) Year Service & Maintenance Agreement Evaluation Selection Criteria Short List Scores and Average Ranking Order Final Selection Committee Scores and Average Ranking Order Demand Star Results DBR Advertisement Sun Biz Registration 5 THE CITY OF PLEASANT LIVING CITY OF SOUTH MIAMI DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 SUBMITTAL DUE DATE: September 1, 2022 at 10 AM Solicitation Cover Letter The City of South Miami, Florida (hereinafter referred to as “Owner”) through its chief executive officer (City Manager) hereby solicits sealed proposals responsive to the City’s request (hereinafter referred to as “Request for Qualifications”, “RFQ” or “E-Bidding”) All references in this Solicitation (also referred to as an “Invitation for Proposals” or “Invitation to E-bid) to “City” will be a reference to the City Manager, or the manager’s designee, for the City of South Miami unless otherwise specifically defined or unless the context in which the word is used requires it to mean the City of South Miami. The City is hereby requesting sealed proposals in response to this RFQ#2022-18, DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM. The purpose of this Solicitation is to contract for the services necessary for the completion of the project in accordance with the Scope of Services, (EXHIBIT 1, Attachments A, B C & D) and the plans and/or specifications, if any, described in this Solicitation (hereinafter referred to as “the Project” or “Project”). Interested persons who wish to respond to this Solicitation can obtain the complete Solicitation package by accessing the following webpage: http://www.southmiamifl.gov/ which is the City of South Miami’s web address for solicitation information. Proposals are subject to the Standard Terms and Conditions contained in the complete Solicitation Package, including all documents listed in the Solicitation. The City will only receive submittals electronically through the DemandStar Electronic Bid System (E-Bidding). To register as a business, go to https://network.demandstar.com/ See directions for registering and signing into your DemandStar user account on the next page following this Solicitation Cover Letter. Proposals must be received electronically through DemandStar, no later than 10:00 A.M. local time (the “Closing Date”) on September 1, 2022 and any Proposal received by the City through DemandStar after 10:00 a.m. local time on said date will not be accepted under any circumstances. Hand delivery will not be accepted. E-BID OPENING VIA VIDEO CONFERENCING: The opening of E-Bids for this solicitation will occur at 10:30 A.M. local time on (the Closing Date, September 1, 2022. The City Clerk will conduct the E-Bid Opening through video conferencing using the Zoom platform. Members of the public may view the meeting via Zoom at https://zoom.us/j/3056636339 ,or listen to the meeting on a dedicated phone line by dialing +1-786-635-1003 Meeting ID: 3056636339. The City reserves the right to award the Project to the person with the lowest, most responsive and responsible Proposal, as determined by the City, subject to the right of the City, or the City Commission, to reject any and all proposals, and the right of the City to waive any irregularity in the Proposals or Solicitation procedure and subject also to the right of the City to award the Project, and execute a contract with a Respondent or Respondents, other than to the one who provided the lowest Proposal Price and, if the Scope o f the Work is divided into distinct subdivisions, to award each subdivision to a separate Respondent. Nkenga A. Payne, CMC City Clerk, City of South Miami 1 of 162 9 THE CITY OF PLEASANT LIVING DemandStar Registration and User Account Sign-in Directions The following is an example of the procedure on April 3, 2020 and it is subject to change after that date. Go to https://network.demandstar.com/ which on April 3, 2020 brings up the following message. If you do not have an account with DemandStar, click on “Create Your Account” otherwise, if you have an account, click on the “x” in the upper right-hand corner of this message and it will bring you to the following user sign in page. 2 of 162 10 COVID-19 (Coronavirus) Emergency Response From DemandStar DemandStar is committed to help i ng all government agencies source qualified suppliers for COVID-19 emergency response. Governments If you are a governme nt agency who needs Ebidding capa bility t o receive supp li er responses on line, ple ase fill out this form and we will get back to you i mmediately. Ebidd i ng is offered at no charge to governments. Broadcast Bids on DemandStar Suppliers If yo u are a bus in ess who can help respond to t he many emergency response bids on the Dema n dStar ne t wo r k, please click here to create your account and get not ifie d of bi ddi ng o p portuniti es. Create Your Account ➔:~ DEMANDSTAR ~:~ DEMANDSTAR r.or Business For Government Sisnln SiJn Up SCOPE OF SERVICES and SCHEDULE OF VALUES DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 The Scope of Services and the Schedule of Values, if any, are set forth in the attached EXHIBIT 1, ATTACHMENTS A, B C & D. 3 of 162 11 SCHEDULE OF EVENTS DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 TENTATIVE SCHEDULE No Event Date* Time* (EST) 1 Advertisement/ Distribution of Solicitation & Cone of Silence begins 8/3/2022 11:00 AM 2 PRE-PROPOSAL MEETING: NONE SCHEDULED NONE SCHEDULED 3 Deadline to Submit Questions 8/23/2022 10:00 AM 4 Deadline to City Responses to Questions 8/26/2022 10:00 AM 5 DEADLINE TO SUBMIT RFQ RESPONSE: The City will only receive submittals electronically through the DemandStar Electronic Bid System (E-Bidding). To register as a business, go to https://network.demandstar.com/ 9/1/2022 10:00 AM 6 E-BID OPENING VIA VIDEO CONFERENCING VIA THE ZOOM PLATFORM at https://zoom.us/j/3056636339 ,or listen to the meeting on a dedicated phone line by dialing +1-786-635-1003 Meeting ID: 3056636339. 9/1/2022 10:30 AM 7 Projected Announcement of selected Contractor/Cone of Silence ends 9/20/2022 7:00 PM END OF SECTION 4 of 162 12 INSTRUCTIONS for RESPONDENT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 IT IS THE RESPONSIBILITY OF THE RESPONDENT TO THE SOLICITATION TO ENSURE THAT THE RESPONSE TO THE SOLICITATION (HEREINAFTER ALSO REFERRED TO AS THE “PROPOSAL” THROUGHOUT THE CONTRACT DOCUMENTS) REACHES THE CITY CLERK ON OR BEFORE THE CLOSING HOUR AND DATE STATED ON THE SOLICITATION FORM. THE RESPONDENT MAY BE REFERRED TO AS “CONTRACTOR” OR AS “CONSULTANT”. 1. Purpose of Solicitation. The City of South Miami is requesting a response with the lowest and most responsive and responsible Proposal, as determined by the City. The City reserves the right to award the contract to the Respondent whose proposal is found to be in the best interests of the City. 2. Qualification of Proposing Firm. Response submittals to this Solicitation will be considered from firms normally engaged in providing the services requested. The proposing firm must demonstrate adequate experience, organization, offices, equipment, and personnel to ensure prompt and efficient service to the City of South Miami. The City reserves the right, before recommending any award, to inspect the offices and organization or to take any other action necessary to determine ability to perform in accordance with the specifications, terms and conditions. The City of South Miami will determine whether the evidence of abilit y to perform is satisfactory and reserves the right to reject all response submittals to this Solicitation where evidence submitted, or investigation and evaluation, indicates inability of a firm to perform. 3. Deviations from Specifications. The awarded firm must clearly indicate, as applicable, all areas in which the services proposed do not fully comply with the requirements of this Solicitation. The decision as to whether an item fully complies with the stated requirements rests solely with the City of So uth Miami. 4. Designated Contact. The awarded firm must appoint a person to act as a primary contact with the City of South Miami. This person or back-up must be readily available during normal work hours by phone, email, or in person, and must be knowledgeable of the terms of the contract. 5. Precedence of Conditions. The proposing firm, by virtue of submitting a response, agrees that City’s General Provisions, Terms and Conditions herein will take precedence over any terms and conditions submitted with the response, either appearing separately as an attachment or included within the Proposal. The Contract Documents have been listed below in order of precedence, with the one having the most precedence being at the top of the list and the remaining documents in descending order of precedence. This order of precedence will apply, unless clearly contrary to the specific terms of the Contract or General Conditions to the Contract: a) Addenda to Solicitation b) Attachments/Exhibits to the Solicitation c) Solicitation d) Attachment/Exhibits to Supplementary Conditions e) Supplementary Conditions to Contract, if any f) Attachment/Exhibits to Contract g) Contract h) General Conditions to Contract, if any i) Respondent’s Proposal 6. Response Withdrawal. After Proposals are opened, corrections or modifications to Proposals are not permitted, but the City may allow the proposing firm to withdraw an erroneous Proposal prior to the confirmation of the proposal award by City Commission, if all of the following is established: a) The proposing firm acted in good faith in submitting the response; b) The error was not the result of gross negligence or willful inattention on the part of the firm; c) The error was discovered and communicated to the City within twenty-four (24) hours (not including Saturday, Sunday, or a legal holiday) of opening the proposals received, along with a request for permission to withdraw the firm’s Proposal; and d) The firm submits an explanation in writing, signed under penalties of perjury, stating how the error was made and delivers adequate documentation to the City to support the explanation and to show that the error was not the result of gross negligence or willful inattention nor made in bad faith . 7. The terms, provisions, conditions, and definitions contained in the Solicitation Cover Letter will apply to these instructions to Respondents and they are hereby adopted and made a part hereof by reference. If there is a conflict between the Cover Letter and these instructions, or any other provision of this Solicitation, the Cover Letter will govern and take precedence over the conflicting provision(s) in the Solicitation. 5 of 162 13 8. Any questions concerning the Solicitation or any required need for cl arification must be made in writing, by 10:00 AM August 23, 2022 to the attention of Steven P. Kulick, Chief Procurement Officer at skulick@southmiamifl.gov or via facsimile at (305) 669-2636. 9. The issuance of a written addendum is the only official method whereby interpretation and/or clarification of information can be given. Interpretations or clarifications, considered necessary by the City in response to such questions, will be issued by a written addendum to the Solicitation Package (also known as “Solicitation Specifications” or “Solicitation”) by U.S. mail, e-mail, or other delivery method convenient to the City and the City will notify all prospective firms via the City’s website. It is the responsibility of the Respondent to keep apprised of the publishing of addenda on the City’s website. 10. Verbal interpretations or clarifications will not have any legal effect. No plea by a Respondent of ignorance or the need for additional information will exempt a Respondent from submitting the Proposal on the required date and time as set forth in the public notice. 11. Cone of Silence: You are hereby advised that this Request for Proposals is subject to the “Cone of Silence,” in accordance with Section 8A-7, of the City’s Code of Ordinance. From the time of advertising until the City Manager issues his recommendation, there is a prohibition on verbal communication with the City’s professional staff, including the City Manager and his staff and members of the City Commission. The Cone of Silence ordinance, Section 8A-7, has been duplicated at the end of these instructions. 12. Violation of these provisions by any particular Respondent or proposer will render any recommendation for the award of the contract or the contract awarded to said Respondent or proposer voidable, and, in such event, said Respondent or proposer will not be considered for any Solicitation including but not limited to one that requests any of the following a proposal, qualifications, a letter of interest or a bid concerning any contract for the provision of goods or services for a period of one year. Contact will only be made through regularly scheduled Commission meetings, or meetings scheduled through the Purchasing Division, which are for the purposes of obtaining additional or clarifying information. 13. Lobbying. "Lobbyist" means all persons (including officers and managers of a legal entity), firms, or legal entities such as a corporation, partnership or limited liability company, employed or retained by a principal (including an officer of the principal or an employee of the principal whose duties include marketing , or soliciting business, for the principal) who seeks to encourage the passage, defeat, or modifications of (1) ordinance, resolution, action or decision of the City Commission; (2) any action, decision, recommendation of the City Manager or any City board or committee; or (3) any action, decision or recommendation of City personnel during the time period of the entire decision-making process on such action, decision or recommendation which foreseeably will be heard or reviewed by the City Commission, or a City board or committee. All firms and their agents who intend to submit, or who submitted, E-bids or responses for this Solicitation, are hereby placed on formal notice that neither City Commissioners, candidates for City Commissioner or any employee of the City of South Miami are to be lobbied either individually or collectively concerning this Solicitation. Contact may only be made through regularly scheduled Commission meetings, or meetings scheduled through the Purchasing Division, which are for the purposes of obtaining additional or clarifying information or as otherwise provided for in the City’s Cone of Silence. Any presentation before a selection committee is considered to be lobbying; however, the presentation team may avoid formal registration by complying with section 8A-5 (c) (9), of the City’s Code of Ordinances. A presentation team affidavit is provided with this solicitation that may be used to comply with presentations, if applicable. Anyone who submits a proposal, whether solicited or u nsolicited, on behalf of his or her principal or his or her employer is considered to be a lobbyist and must register. An officer or manager of a legal entity who is submitting a proposal, whether solicited or unsolicited, is considered to be a lobbyist. See section 8A-5 of the City’s Code of Ordinances for further information and contact the City Clerk to register as a lobbyist. 14. Reservation of Right. The City anticipates awarding one contract for services as a result of this Solicitation and the successful firm will be requested to enter into negotiations to produce a contract for the Project. The City, however, reserves the right, in its sole discretion, to do any of the following: a) to reject any and all submitted Responses and to further define or limit the scope of the award. b) to waive minor irregularities in the responses or in the procedure required by the Solicitation documents. c) to request additional information from firms as deemed necessary. d) to make an award without discussion or after limited negotiations. It is, therefore, important that all the parts of the Request for Proposal be completed in all respects. e) to negotiate modifications to the Proposal that it deems acceptable. f) to terminate negotiations in the event the City deems progress towards a contract to be insufficient and to proceed to negotiate with the Respondent who made the next best Proposal. The City reserves the right to proceed in this manner until it has negotiated a contract that is satisfactory to the City. 6 of 162 14 g) To modify the Contract Documents. The terms of the Contract Documents are general and not necessarily specific to the Solicitation. It is therefore anticipated that the City may modify these documents to fit the specific project or work in question and the Respondent, by making a Proposal, agrees to such modifications and to be bound by such modified documents. h) to cancel, in whole or part, any invitation for Proposals when it is in the best interest of the City. i) to award the Project to the person with the most responsive, responsible Proposal, as determined by the City. j) to award the Project, and execute a contract with a Respondent or Respondents, other than to one who provided the lowest Proposal Price. k) if the Scope of the Work is divided into distinct subdivisions, to award each subdivision to a separate Respondent. 15. Contingent Fees Prohibited. The proposing firm, by submitting a proposal, warrants that it has not employed or retained a company or person, other than a bona fide employee, contractor or sub-contractor/sub- consultant, working in its employ, to solicit or secure a contract with the City, and that it has not paid or agreed to pay any person, company, corporation, individual or firm other than a bona fide employee, contractor or sub - contractor/sub-consultant, working in its employ, any fee, commission, percentage, gift or other consideration contingent upon or resulting from the award or making of a contract with the City. 16. Public Entity Crimes. A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit an E-bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit an E-bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit E-bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. 17. Respondents must use the Proposal Form(s) furnished by the City. All erasures and corrections must have the initials of the Respondent’s au thorized representative in blue ink at the location of each and every erasure and correction. Proposals must be signed using blue ink; all quotations must be typewritten or printed with blue ink. All spaces must be filled in with the requested information or the phrase “not applicable” or “NA”. The proposal must be delivered on or before the date and time, and at the place and in such manner as set forth in the Solicitation Cover Letter. Failure to do so may cause the Proposal to be rejected. Failure to include any of the Proposal Forms may invalidate the Proposal. Respondent must deliver to the City, as part of its Proposal, the following documents: a) The Invitation for Proposal and Instructions to Respondents. b) A copy of all issued addenda. c) The completed Proposal Form fully executed. d) Proposal/E-bid Bond, (Bond or cashier’s check), if required, attached to the Proposal Form. e) Certificates of Competency as well as all applicable State, County and City Licenses held by Respondent f) Certificate of Insurance and/or Letter of Insurability. 18. Goods: If goods are to be provided pursuant to this Solicitation the following applies: a) Brand Names: If a brand name, make, manufacturer’s trade name, or vendor catalog number is mentioned in this Solicitation, whether or not followed by the words “approved equal”, it is for the purpose of establishing a grade or quality of material only. Respondent may offer goods that are equal to the goods described in this Solicitation with appropriate identification, samples and/or specifications for such item(s). The City will be the sole judge concerning the merits of items proposed as equals. b) Pricing: Prices should be stated in units of quantity specified in the Proposal Form. In case of a discrepancy, the City reserves the right to make the final determination at the lowest net cost to the City. c) Mistake: In the event that unit prices are part of the Proposal and if there is a discrepancy between the unit price(s) and the extended price(s), the unit price(s) will prevail and the extended price(s) will be adjusted to coincide. Respondents are responsible for checking their calculations. Failure to do so will be at the Respondent’s risk, and errors will not release the Respondent from his/her or its responsibility as noted herein. d) Samples: Samples of items, when required, must be furnished by the Respondent free of charge to the City. Each individual sample must be labeled with the Respondent’s name and manufacturer’s brand name and delivered by it within ten (10) calendar days of the Proposal opening unless schedule indicates a different time. If samples are requested after the Proposal opening, they must be delivered within ten (10) calendar days of the request. The City will not be responsible for the return of samples. 7 of 162 15 e) Respondent warrants by signature on the Proposal Form that prices quoted therein are in conformity with the latest Federal Price Guidelines. f) Governmental Restrictions: In the event any governmental restrictions may be imposed which would necessitate alteration of the material quality, workmanship, or performance of the items offered on this Proposal prior to their delivery, it will be the responsibility of the successful Respondent to notify the City at once, indicating in its letter the specific regulation which required an alteration. The City of South Miami reserves the right to accept any such alteration, including any price adjustments occasioned thereby, or to cancel all or any portion of the Contract, at the sole discretion of the City and at no further expense to the City with thirty (30) days advanced notice. g) Respondent warrants that the prices, terms, and conditions quoted in the Proposal will be firm for a period of one hundred eighty (180) calendar days from the date of the Proposal opening unless otherwise stated in the Proposal Form. Incomplete, unresponsive, irresponsible, vague, or ambiguous responses to the Solicitation will be cause for rejection, as determined by the City. h) Safety Standards: The Respondent warrants that the product(s) to be supplied to the City conform in all respects to the standards set forth in the Occupational Safety and Healt h Act (OSHA) and its amendments. Proposals must be accompanied by a Materials Data Safety Sheet (M.S.D.S) when applicable. 19. Liability, Licenses & Permits: The successful Respondent must assume the full duty, obligation, and expense of obtaining all necessary licenses, permits, and inspections required by this Solicitation and as required by law. The Respondent will be liable for any damages or loss to the City occasioned by the negligence of the Respondent (or its agent or employees) or any person acting for or through the Respondent. Respondents must furnish a certified copy of all licenses, Certificates of Competency, or other licensing requirement necessary to practice their profession and applicable to the work to be performed as required by Florida S tatutes, the Florida Building Code, Miami-Dade County Code or City of South Miami Code. These documents must be furnished to the City as part of the Proposal. Failure to have obtained the required licenses and certifications or to furnish these documents will be grounds for rejecting the Proposal and forfeiture of the Proposal /E-bid Bond, if required for this Project. 20. Respondent must comply with the City’s Insurance Requirements as set forth in the attached EXHIBIT 2, prior to issuance of any Contract(s) or Award(s) If a recommendation for award of the contract, or an award of the contract is made before compliance with this provision, the failure to fully and satisfactorily comply with the City’s bonding, if required for this project, and insurance requirements as set forth herein will authorize the City to implement a rescission of the Proposal Award or rescission of the recommendatio n for award of contract without further City action. The Respondent, by submitting a Proposal, thereby agrees to hold the City harmless and agrees to indemnify the City and covenants not to sue the City by virtue of such rescission. 21. Copyrights and/or Patent Rights: Respondent warrants that as to the manufacturing, producing, or selling of goods intended to be shipped or ordered by the Respondent pursuant to this Proposal, there has not been, nor will there be, any infringement of copyrights or patent righ ts. The Respondent agrees to indemnify City from any and all liability, loss or expense occasioned by any such violation or infringement. 22. Execution of Contract: A response to this Solicitation will not be responsive unless the Respondent signs the form of contract that is a part of the Solicitation package. The Respondent to this Solicitation acknowledges that by submitting a response or a proposal, Respondent agrees to the terms of the form contract and to the terms of the general conditions to the contract, both of which are part of this Solicitation package. The Respondent agrees that Respondent’s signature on the E-bid Form and/or the form of contract that is a part of the Solicitation package and/or response to this Solicitation, grants to the City the authority, on the Respondent’s behalf, to inserted, into any blank spaces in the contract documents, information obtained from the proposal and, at the City’s sole and absolute discretion, the City may treat the Respondent’s signature on any of those documents as the Respondent’s signature on the contract, after the appropriate information has been inserted, as well as for any and all purposes, including the enforcement of all of the terms and conditions of the contract. 23. Evaluation of Proposals: The City, at its sole discretion, reserves the right to inspect the facilities of any or all Respondents to determine its capability to meet the requirements of the Contract. In addition, the price, responsibility and responsiveness of the Respondent, the financial position, experience, staffing, equipment, materials, references, and past history of service to the City and/or with other units of state, and/or local governments in Florida, or comparable private entities, will be taken into consideration in the Award of the Contract. 24. Drug Free Workplace: Failure to provide proof of compliance with Florida Statute Section 287.087, as amended, when requested will be cause for rejection of the Proposal as determined by the City. 25. Hold Harmless: A Respondent who submits a proposal in response to this solicitation does so with the understanding and agreement to indemnify and hold harmless, to the fullest extent permitted by law, the City 8 of 162 16 of South Miami and its officers and employees from liabilities, damages, losses and costs, including, but not limited to reasonable attorney’s fees, to the extent caused by the negligence, recklessness , willfulness, wantonness or intentional acts or omissions of the contractor and persons employed or utilized by the contactor in the performance of its contractual obligations to the City. This indemnification will survive the termination of the Respondent’s contractual obligations to the City. Nothing contained in this solicitation is intended to imply, nor will it constitute a right, to sue the City in reference to its decisions to reject, award, or not award a contract, as applicable, unless the claim is based solely on allegations of fraud and/or collusion. The submission of a proposal will act as an agreement by the Respondent that the Proposal/Bid Bond, if required for this project, will not be released until and unless the Respondent waives any and all claims that the Respondent may have against the City that arise out of this Solicitation process or until a judgment is entered in the Respondent’s favor in any suit filed which concerns this Solicitation process. If a judgment is entered in favor of the City in any litigation for damages, interest, costs, or expenses associated with the litigation, the Proposal/Bid Bond, if required for this project, will be applied to the payment of those amounts awarded by the court and any balance due the City will be paid by the Respondent. Notwithstanding anything contained in this paragraph to the contrary, a design professional’s indemnification obligations are limited by the provisions of paragraph F of the City’s Insurance and Indemnification Requirements, Exhibit 2 of this Solicitation. 26. Cancellation: Failure on the part of the Respondent to comply with the conditions, specifications, requirements, and terms as determined by the City, will be just cause for cancellation of the Award or termination of the contract. 27. Bonding Requirements: The Respondent, when submitting the Proposal, must include a Proposal/Bid Bond, if required for this project, in the amount of 5% of the total amount of the base Proposal on the Proposal/Bid Bond Form included herein. A company or personal check will not be deemed a valid Proposal Security. 28. Performance and Payment Bond: The City of South Miami may require the successful Respondent to furnish a Performance Bond and Payment Bond, each in the amount of 100% of the total Proposal Price, including Alternates if any, naming the City of South Miami, and the entity that may be providing a source of funding for the Work, as the obligee, as security for the faithful performance of the Contract and for the payment of all persons or entities performing labor, services and/or furnishing materials in connection herewith. In addition, if the Respondent’s employees will be working in secure or sensitive areas of the City, the City may require that the Respondent provides employee bonding, naming the City of South Miami as the obligee on the bond. The bonds must be with a surety company authorized to do business in the State of Florida. 28.1. Each Performance Bond must be in the amount of one hundred percent (100%) of the Contract Price guaranteeing to City the completion and performance of the Work covered in the Contract Documents. 28.2. Each Performance Bond must continue in effect for five years after final completion and acceptance of the Work with the liability equal to one hundred percent (100%) of the Contract Sum. 28.3. Each Payment bond must guarantee the full payment of all suppliers, material man, laborers, or sub-contractor/sub-consultant employed pursuant to this Project. 28.4. Each Bond must be with a Surety company whose qualifications meet the requirements of insurance companies as set forth in the insurance requirements of this solicitation. 28.5. Pursuant to the requirements of Section 255.05, Florida Statutes, Respondent must ensure that the Bond(s) referenced above must be recorded in the public records of Miami-Dade County and provide CITY with evidence of such recording. 28.6. The surety company must hold a current certificate of authority as acceptable surety on federal bonds in accordance with the United States Department of Treasury Circular 570, current revisions. 29. Proposal Guarantee: Notwithstanding the fact that the Respondent, in submitting a proposal, agrees to the terms contained in the form of contract that is part of this Solicitation package, the successful Respondent, within ten (10) calendar days of Notice of Award by the City, must deliver, to the City, the executed Contract and other Contract Documents that provide for the Respondent’s signature, and deliver to the City the r equired insurance documentation as well as a Performance and Payment Bond if these bonds are required. The Respondent who has the Contract awarded to it and who fails to execute the Contract and furnish the required Bonds and Insurance Documents within the specified time will, at the City’s option, forfeit the Proposal/Bid Bond/Security that accompanied the Proposal, and the Proposal/Bid Bond/Security will be retained as liquidated damages by the City. It is agreed that if the City accepts payment from the Proposal/Bid Bond, that this sum is a fair estimate of the amount of damages the City will sustain in case the Respondent fails to sign the Contract Documents or fails to furnish the required Bonds and Insurance documentation. If the City does not accept the Proposal/Bid Bond, the City may proceed to sue for breach of contract if the Respondent fails to perform in accordance with the Contract Documents. Proposal/Bid Bond/Security deposited in the form of a cashier’s check drawn on a local bank in good standing must comply with the same requirements as a Proposal/Bid Bond. 9 of 162 17 30. Pre-proposal Conference Site Visits: If a Mandatory Pre-proposal conference is scheduled for this project, all Respondents must attend the conference and tour all areas referenced in the Solicitation Documents. It will be grounds for rejecting a Proposal from a Respondent who did not attend the mandatory pre-proposal conference. No pleas of ignorance by the Respondent of conditions that exist, or that may hereinafter exist, as a Solicitation result of failure to make the necessary examinations or investigations, or failure to complete any part of the Solicitation Package, will be accepted as basis for varying the requirements of the Contract with the City of South Miami or the compensation of the Respondent. The Respondent, following receipt of a survey of the property, if applicable, is bound by knowledge that can be seen or surmised f rom the survey and will not be entitled to any change order due to any such condition. If the survey is provided before the proposal is submitted, the contract price, or negotiation in a request for qualifications, must include the Work necessitated by those conditions. If the survey is provided subsequent to the submission of the proposal or negotiation in a request for qualifications, the Respondent will have five calendar days to notify the City of any additional costs required by such conditions and the City will have the right to reject the proposal, or in the case of an RFQ, the negotiated price, and award the contract to, or begin negotiations with, the second most responsive, responsible E- bidder with the lowest price, or in the case of an RFQ, with the next best qualifications, or to reject all E-bids. 31. Time of Completion: The time is of the essence with regard to the completion of the Work to be performed under the Contract to be awarded. Delays and extensions of time may be allowed only in accordance with the provisions stated in the appropriate section of the Contract Documents, including the Proposal Form. No change orders will be allowed for delays caused by the City, other than for extensions of time to complete the Work. 32. Submittal Requirements: All Proposals must comply with the requirements set forth herein and must include a fully completed Respondent’s E-Bid Form, if any, and a Respondent’s Cost and Technical Proposal if it is included with this Solicitation Package. 33. Cancellation of E-Bid Solicitation: The City reserves the right to cancel, in whole or part, any request for proposal when it is in the best interest of the City. 34. Respondent may not discriminate in its hiring of employees or sub-contractor/sub-consultants or in its purchase of materials or in any way in the performance of its contract, if one is awarded, based on race, color, religion, national origin, sex, age, sexual orientation, disability, or familial status. 35. All respondents, at the time of E-bid opening, must have fulfilled all prior obligations and commitments to the City in order to have their E-bid considered, including all financial obligations. Prior to the acceptance of any E- bid proposal, qualifications or quotation, the City's Finance Department will certify that there are no outstanding fines, monies, fees, taxes, liens, or other charges owed to the City by the Respondent, any of the Respondent’s principal, partners, members or stockholders (collectively referred to as “Respondent Deb tors”). An E-bid, proposal or quotation will not be accepted until all outstanding debts of all Respondent Debtors owed to the city are paid in full. No E-bidder who is in default of any prior contract with the City may have their E-bid considered until the default is cured to the satisfaction of the City Manager. 36. E-bid Protest Procedure. See attached EXHIBIT 7. 37. Evaluation Criteria: If this project is to be evaluated by an Evaluation Committee, the evaluation criteria is attached as EXHBIT 3. 38. Availability of Contract - Any Governmental or quasi-governmental entity, in this or in any other state, or any federal governmental agency, may avail itself of this solicitation and the contract that is awarded pursuant to this solicitation and purchase any and all goods/services specified herein from the successful E-bidder(s)/proposer(s) at the contract price(s) established herein, when any federal, state, and/or local laws, rules, and regulations allows the piggybacking off said contract and provided that the successful E-bidder(s)/proposer(s) is/are in agreement. Each Governmental or quasi-governmental entity which uses this formal solicitation and resulting E-bid contract or agreement will establish its own contract/agreement, place its own orders, issue its own purchase orders, be invoiced there from, and make its own payments, determine shipping terms and issue its own exemption certificates as required by the successful E-bidder(s)/proposer(s). 39. Non-Appropriation of Funds. In the event that no funds or insufficient funds are appropriated and budgeted or are otherwise unavailable in any fiscal period for payments due under any contract awarded pursuant to this solicitation, then the City, upon written notice to Successful E-bidder or their assignee of such occurrence, will have the unqualified right to terminate the contract without any penalty or expense. No guarantee, warranty or representation is made that any particular project(s) will be awarded to any Respondent(s). 40. Most Favored Public Entity. Respondent represents that the prices charged to City in the proposal do not exceed existing prices to other customers for the same or substantially similar items or services for comparable quantities under similar terms, conditions, wages, benefits, insurance coverage and any other material cost factors. If respondent’s prices decline, or should respondent, at any time during the term of a contract entered into with City, provide the same goods or services with the same comparable quantities under similar terms, 10 of 162 18 conditions, wages, benefits, insurance coverage and any other material cost factors, Respondent must immediately extend the same prices to City. 41. Confidential and Proprietary Information. Respondents may assert that some trade secrets, financial records, and proprietary or other confidential information in their unsolicited proposal are confidential information that they claim to be exempt from disclosure under applicable Florida pu blic records laws. Such information may be included in the unsolicited proposal, but submitted in a separate, sealed binder, designated on the cover as CONFIDENTIAL MATERIALS. A Respondent submitting materials claimed to be confidential must include a cover letter listing all material designated as confidential and clearly mark each page of any material believed to be a trade secret or other confidential information/document in all capital letters and bold font as CONFIDENTIAL MATERIALS. If a document is not totally confidential but contains non-confidential and confidential information, the Respondent must provide a redacted copy of the document and an unredacted copy. In addition, the Respondent must prepare a list of all the documents claimed to be confidential or containing confidential information and on the next line under the description of each document the Respondent must cite the statutory provision that provides the basis for the Respondent’s claim that the document or a portion of the document is confidential and below the citation the Respondent must copy and paste the applicable statutory provision (this listing requirement will hereinafter be referred to as “properly list” or “properly listed” confidential document). The failure to properl y list a confidential document or the failure to redact a confidential document that is only partially confidential will result in the waiver of any claim that the document is confidential or that the unredacted document contains confidential information. If any person or entity requests that the City produce or disclose any of said purported confidential information or documents, the City will advise the Respondent and afford the Respondent an opportunity to protect its assertion that said confidential information is exempt from production. If Respondent fails to timely authorize the production of the information or document and/or fails to timely seek a protective order, and/or is unsuccessful in obtaining a protective order, the City will produce the requested information or document. The City will not actively contest any request to disclose such alleged confidential information or document and the City cannot guarantee that the alleged confidential document or information may not be disclosed should i t ultimately be determined not to be confidential under applicable Florida public records laws. The Respondent must indemnify the City for any damages and costs the City may incur due to the Respondent’s claim that its document or information is confidential. The City can only agree to advise the Respondent of such request and give the Respondent an opportunity, at Respondent’s sole and exclusive cost, to defend the request for disclosure of the confidential information or document in a Court of competent jurisdiction or other applicable forum. 42. Definitions. The following definitions will govern the interpretation of this RFQ: “Certify”, including all of its tenses, such as “certifies”, “certifying” and “certified”, means the act of swearing or affirming under penalties of perjury that the facts that are being “certified” are true and correct and it must be accomplished either by swearing (or affirming) to the truth of the statement before a notary public, or by a declaration, under penalties of perjury, as to the truth of the statement pursuant to Florida Statutes, Section 92.525. 43. Tie E-bids (not applicable to an RFQ). In the event of tie E-bids, Respondents will be directed to submit sealed Best and Final Offers and deliver to the Office of the City Clerk located at South Miami City Hall, 6130 Sunset Drive, South Miami, Florida 33143. The “Best and Final Offers” must be enclosed in a sealed envelope or container and must have the following Information clearly printed or written on the exterior of the envelope or container in which the sealed proposal is delivered: “Best and Final Offers”. On the second line of the envelope insert the Project Name and Solicitation Number. On the third line of the envelope insert the nam e of the person or entity who is going to be legally bound to perform the contractual obligations if awarded the contract. 44. Tie Selection. In the event of a tie by an Evaluation Selection Committee after they have scored each submittal, the meeting facilitator of the Selection Committee meeting, usually the City’s Procurement Manager, will tabulate the Selection Committee’s scores and advise the Committee there is a tie score; without advising the Committee the scores or the Respondents involved. The meeting facilitator will direct the Selection Committee to re-score the Respondents submittals and, will continue the re-scoring until the tie is broken, and a clear winner for the award recommendation has been determined. If the tie is not broken after three attempts to break the tie, all responses will be rejected, and the item will be re -advertised. 45. Rescind the Award. The City reserves the right to rescind the award recommendation, even after the award recommendation has been conditionally approved by the City Commission but before execution of the Contract by the City Manager and, by responding to this RFQ, Respondent agrees to waive any contractual rights or equitable claims that Respondent may have accrued following the initial award recommendation by the City Manager under these conditions. 11 of 162 19 46. State of Emergency. The City reserves the right, in its so le and absolute discretion, to suspend the work or services or cancel the contract in the event of an emergency that effects the City of South Miami, its residents or businesses and that has been declared by the Governor, Mayor of Miami -Dade County or the City Manager. 47. Force majeure. Neither party may hold the other responsible for damages or for delays in performance caused by force majeure, acts of God, or other acts or circumstances beyond the control of a party or that could not have been reasonably foreseen, prevented or avoided. For this purpose, such acts or circumstances include, but not limited to, weather conditions affecting performance, floods, epidemics, war, riots, strikes, lockouts, or other industrial disturbances, or protest demonstrations. Should such acts or circumstances occur, the parties will use their best efforts to overcome the difficulties and to resume the work as soon as reasonably possible. 48. Proprietary Rights 48.1 The Respondent hereby acknowledges and agrees that the City retains all rights, title and interests in and to all materials, data, documentation and copies thereof furnished by the City to the Respondent hereunder or furnished by the Respondent to the City and/or created by the Respondent for delivery to the City, even if unfinished or in process, as a result of the Services the Respondent performs in connection with this Agreement, including all copyright and other proprietary rights therein, which the Respondent as well as its employees, agents, subcontractors and suppliers may use only in connection of the performance of Services under this Agreement. The Respondent shall not, without the prior written consent of the City, use such documentation on any other project in which the Respondent or its employees, agents, subcontractors or suppliers are or may become engaged. Submission or distribution by the Respondent to meet official regulatory requirements or for other purposes in connection with the performance of Services under this Agreement shall not be construed as publication in derogation of the City's copyrights or other proprietary rights. 48.2All rights, title, and interest in and to certain inventions, ideas, designs and methods, specifications and other documentation related thereto developed by the Responde nt and its subcontractors specifically for the City, hereinafter referred to as "Developed Works" shall become the property of the City. 48.3 Accordingly, neither the Respondent nor its employees, agents, subcontractors, or suppliers shall have any proprietary interest in such Developed Works. The Developed Works may not be utilized, reproduced or distributed by or on behalf of the Respondent, or any employee, agent, subcontractor or supplier thereof, without the prior written consent of the City, except as required for the Respondent's performance hereunder. 48.4 Except as otherwise provided in subsections a, b, and c above, or elsewhere herein, the Respondent and its subcontractors and suppliers hereunder shall retain all proprietary rights in and to all L icensed Software, if any is provided hereunder, that have not been customized to satisfy the performance criteria set forth in the Scope of Services. Notwithstanding the foregoing, the Respondent hereby grants, and shall require that its subcontractors and suppliers grant, if the City so desires, a perpetual, irrevocable and unrestricted right and license to use, duplicate, disclose and/or permit any other person(s) or entity(ies) to use all such Licensed Software and the associated specifications, technical data and other Documentation for the operations of the City or entities controlling, controlled by, under common control with, or affiliated with the City, or organizations which may hereafter be formed by or become affiliated with the City. Such license specifically includes, but is not limited to, the right of the City to use and/or disclose, in whole or in part, the technical documentation and Licensed Software, including source code provided hereunder, to any person or entity outside the City for such person's or entity's use in furnishing any and/or all of the Deliverables provided hereunder exclusively for the City or entities controlling, controlled by, under common control with, or affiliated with the City, or organizations which may hereafter be formed by or become affiliated with the City. No such License Software, specifications, data, documentation or related information shall be deemed to have been given in confidence and any statement or legend to the contrary shall be void and of no effect. 49. Anti-Discrimination. Contractor and all of its employees, subcontractors and subconsultants, while performing work for the City, are prohibited from discriminating against anyone on the basis of race, color, religion, family status, sex (including sexual orientation, gender identity and intersexuality), height, weight, domestic partnership status, labor organization membership, political affiliation, national origin, age, disability or any other classification that is federally defined as a “protected class” and Contractor must take all steps necessary to prevent such discrimination by all of its employees, subcontractors and subconsultants who are performing work for the City and must ensure nondiscrimination in all programs, services and activities that are part of the Scope of Services. A violation of this paragraph is a substantial and material breach of this Contract. END OF SECTION 12 of 162 20 SUPPLEMENTAL INSTRUCTIONS AND RESPONSE TO THE SOLICITATION FORMAT FOR RESPONDENT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 FORMAT AND CONTENT OF RFQ RESPONSE: Firms responding to the Solicitation must disclose their qualifications to complete the project as described in Exhibit 1, Scope of Services, Attachments A, B, C & D for the City in the format set forth below. Failure to provide requested information may result in your Response to the Solicitation being deemed non-responsive and therefore eliminated from further consideration. A. Title Page Show the name of Respondent’s agency/firm, address, telephone number, name of contact person, date and the subject: REQUEST FOR QUALIFICATIONS For “DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM, RFQ #2022 - 18. B. Table of Contents Include a clear identification of the material by section and by page number. C. Cover Letter and Executive Summary This letter should be signed by the person in your firm who is authorized to negotiate terms, render binding decisions, and commit the firm’s resources. Summarize your firm’s qualifications and experience to serve as the Parking Garage Security System provider, and your firm’s understanding of the work to be done and include a commitment to perform the work in accordance with the terms of the Response to the Solicitation being submitted. This response should emphasize the strength of the firm in any relevant areas which you feel the City should weigh in its selection process. Response to the Solicitation: This section should summarize the key points of your submittal. Limit to one (1) to TEN (10) pages. Includes the Cover Letter and Executive Summary. Response to the Solicitation must include the following. 1. Respondent’s qualifications to perform the services detailed in Exhibit 1, “Scope of Services, Attachments A, B C & D” 2. Detailed work plan/project approach to accomplish the objectives of the proposed project, as described in Exhibit 1, Scope of Services, to complete the project in a timely manner. 3. A list of the executive and professional personnel that will be employed in this engagement and their experience with similar engagements, including the percentage of project time projected to be spent by each person. 4. In addition to submission of the “RESPONDENTS QUALIFICATION STATEMENT” found in the RFQ detailing Respondent’s experience with engagements of a similar scope including a summary of prior work experience and competence in undertaking engagements of this type. Experience shown should be of the lead project personnel who will be assigned to the City’s project and will routinely be interfacing with the City. 13 of 162 21 D. Firm Overview State the full legal name and organizational structure of the firm. Describe the ownership structure of your firm. State the location of the office that will be serving the City including mailing address and telephone numbers. a. Name of Firm submitting responding to the Solicitation. b. Name and title of individual responsible for the submittal. c. Mailing and e-mail addresses. d. Telephone and facsimile numbers. E. Personnel and References Identify the primary individuals who will provide services to the City with regard to the day- to-day relationship with the City and include a brief resume for each of the primary individuals including licenses and certifications held by those individuals. Provide a list of five clients the firm has worked with in the last 5-years. Indicate the firm’s experience with clients within the State of Florida and provide a brief description of the type of services provided as well as the names, titles, addresses and telephone numbers of those primarily responsible for the account. In addition to the day-to-day relationship, please provide information regarding the firm’s and individual’s experience with engagements which are similar to the project contemplated by the City. Finally, provide specific services required to complete this engagement that are provided by your firm, through subcontractors or subconsultants. F. Other Relevant Experience Provide a description of your proposed primary individuals’ relevant experience over the last three years with other cities and counties that you believe are relevant to this proposed engagement. Include three case studies, if available, that illustrate experience with relevant services where the proposed primary individuals have served for similar engagements as proposed by the City detailed in the Scope of Services in this RFQ. Please limit your response in the Sections, “D,” “E,” & “F.” to SEVEN (7) pages. END OF SECTION 14 of 162 22 CONE OF SILENCE ORDINANCE, SECTION 8A-7 DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 Chapter 8A of the City of South Miami Code of Ordinances is hereby amended in pertinent part to add a new section 8A-7 which is to read as follows: Sec. 8A-7. Cone of Silence: (A) Definitions. (1) "Cone of silence", as used herein, means a prohibition of any communication regarding competitive solicitations such as a request for proposal ("RFP"), request for qualification ("RFQ"), request for information (“RFI”) or request for bid (“RFB”), between: (a) A potential vendor, service provider, proposer or bidder (hereinafter referred to as the “Potential Bidder”), or agent, representative, lobbyist or consultant for the Potential Bidder; (hereinafter referred to as the “Bidder’s Representative”) and (i) Members of the City Commission or (ii) City's professional staff or (iii) Any member of the City's selection, evaluation or negotiation committee. (b) Members of the City Commission shall not communicate with professional staff or members of the selection, evaluation and negotiation committees at any point in the competitive process except as provided in paragraph D (3) below. (2) “City’s professional staff” means City Department Heads and their staff and the City Manager and Deputy City Manager and their staff including consultants involved in the solicitation, evaluation and negotiation process. (B) Restriction; notice. A cone of silence shall be imposed upon each competitive solicitation, commencing with the date that the advertisement of said solicitation is published and the requirements of this section shall be included in the solicitation. At the time of imposition of the cone of silence, the City Manager or Manager’s designee shall: (a) provide for public notice of the cone of silence by posting a notice at City Hall; (b) issue a written notice thereof to the affected Departments; (c) file a copy of such notice with the City Clerk; and (d) serve a copy thereof on each City Commissioner. (C) Termination of Cone of Silence. The Cone of Silence shall terminate at the beginning of the City Commission meeting at which the City Manager makes his or her written recommendation to the City Commission or at the time that the solicitation process is terminated by the City Manager. However, if the City Commission refers the Manager's recommendation back to the Manager or staff for further review, the cone of silence shall be reimposed until the beginning of the City Commission meeting at which the City Manager makes a subsequent written recommendation. (D) Exceptions to applicability. The provisions of this section shall not apply to: (1) Communications at a duly noticed pre-bid conferences or at any duly noticed public Selection or Negotiation Committee meeting or duly noticed public City Commission meeting at which the City Manager has placed the subject of the solicitation on the Agenda; (2) Communication regarding the solicitation at recorded contract negotiations, recorded oral presentation or recorded oral question and answer session and recorded contract negotiation strategy sessions in compliance with the exemption in Florida Statutes Section 286.0113; 15 of 162 23 - (3) Briefings made by the City Manager or his designee to the City Commissioners during a meeting following the completion of the Selection or Negotiation Committee meetings; (4) Written communication at any time with any City professional staff (not including selection, evaluation or negotiation committee members), unless specifically prohibited by the applicable competitive solicitation documents. This section shall not be construed to prevent written communication between City professional staff and any City selection, evaluation or negotiation committee. A copy of any written communication made during the cone of silence shall be contemporaneously filed with the City Clerk by the Potential Bidder or Bidder’s Representative. The City Clerk shall make copies available to any person upon request; (5) Communication that is strictly limited to matters of those processes or procedures that are contained in the corresponding solicitation document and which communication is between any person and the City's Purchasing Agent or the City employee who is designated as being responsible for administering the procurement process for such solicitation; (6) Communications with the City Attorney and his or her staff; (7) Communications during any duly noticed site visits to determine the competency and responsibleness of bidders regarding a particular bid during the time period between the opening of bids and the time the City Manager makes a written recommendation; (8) Any emergency procurement of goods or services pursuant to City Code; (9) Responses to a request made by the City's Purchasing Agent, or the City employee who is designated as being responsible for administering the procurement process for such solicitation, for clarification or additional information; (10) Communications prior to bid opening between City’s professional staff and Potential Bidders and/or Bidder’s Representatives to enable City staff to seek and obtain industry comment or perform market research, provided all communications related thereto between a Potential Bidders and/or Bidder’s Representatives and any member of the City's professional staff including, but not limited to the City Manager and his or her staff, are in writing or are made at a duly noticed public meeting. (F) Penalties. Violation of this section by a particular bidder or proposer, or their representative, shall render any award to said bidder or proposer voidable by the City Commission and/or City Manager. Any person who violates a provision of this section may be prohibited from serving on a City selection or evaluation committee. In addition to any other penalty provided herein, violation of any provision of this section by a City employee may subject said employee to disciplinary action at the discretion of the City Manager. END OF SECTION 16 of 162 24 PROPOSAL SUBMITTAL CHECKLIST FORM DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 This checklist indicates the forms and documents required to be submitted for this solicitation and to be presented by the deadline set for within the solicitation. Fulfillment of all solicitation requirements listed is mandatory for consideration of response to the solicitation. Additional documents may be required and, if so, they will be identified in an addendum to this Solicitation. The response must include the following items: Attachments and Other Documents described below to be Completed IF MARKED WITH AN “X”: Check Completed. X The City will only receive submittals online and electronically through the Demand Star Electronic Bid System (E-Bidding). To register as a business, go to https://network.demandstar.com/ The City, at its discretion, may request hard copies of proposals received from a specific Respondent or all Respondents. X SUPPLEMENTAL INSTRUCTIONS found prior to the PROPOSAL SUBMITTAL CHECKLIST FORM. X Indemnification and Insurance Documents EXHIBIT 2 X Signed Contract Documents EXHIBIT 4, 5 & 6 X Respondents Qualification Statement X List of Proposed Subcontractors and Subconsultants and Principal Suppliers X Non-Collusion Affidavit X Public Entity Crimes and Conflicts of Interest X Drug Free Workplace X Acknowledgement of Conformance with OSHA Standards X Affidavit Concerning Federal & State Vendor Listings X Related Party Transaction Verification Form X Presentation Team Declaration/Affidavit of Representation Submit this checklist along with your proposal indicating the completion and submission of each required forms and/or documents. END OF SECTION 17 of 162 25 RESPONDENT QUALIFICATION STATEMENT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 The response to this questionnaire will be utilized as part of the CITY’S overall Proposal Evaluation and RESPONDENT selection. 1. Number of similar projects completed, a) In the past 5 years b) In the past 10 years 2. List the last five (5) completed similar projects. a) Project Name: Owner Name: Owner Address: Owner Telephone: Actual Final Contract Price: b) Project Name: Owner Name: Owner Address: Owner Telephone: Actual Final Contract Price c) Project Name: Owner Name: Owner Address: Owner Telephone: Actual Final Contract Price: d) Project Name: Owner Name: Owner Address: Owner Telephone: Actual Final Contract Price: e) Project Name: Owner Name: Owner Address: Owner Telephone: Original Contract Price: Actual Final Contract Price: 18 of 162 26 3. Current workload Project Name Owner Name Telephone Number Contract Price 4. The following information must be attached to the proposal. a) RESPONDENT’s home office organization chart. b) RESPONDENT’s proposed project organizational chart. c) Resumes of proposed key project personnel, including on-site Superintendent. 5. List and describe any: a) Bankruptcy petitions filed by or against the Respondent or any predecessor organizations, b) Any arbitration or civil or criminal proceedings, or c) Suspension of contracts or debarring from Bidding or Responding by any public agency brought against the Respondent in the last five (5) years 6. Government References: List other Government Agencies or Quasi-Government Agencies for which you have done business within the past five (5) years. Name of Agency: Address: Telephone No.: Contact Person: Type of Project: 19 of 162 27 END OF SECTION Name of Agency: Address: Telephone No.: Contact Person: Type of Project: Name of Agency: Address: Telephone No.: Contact Person: Type of Project: 20 of 162 28 LIST OF PROPOSED SUBCONTRACTORS, SUBCONSULTANTS AND PRINCIPAL SUPPLIERS DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 Respondent must list all proposed subcontractors and subconsultant, if subcontractors and subconsultants are allowed by the terms of this Solicitation to be used on this project if they are awarded the Contract. Classification of Work Subcontractor/Subconsultant Name Address Telephone, Fax & Email Other: This list must be provided as a part of Respondents submittal to the City of South Miami and in response to this RFQ. END OF SECTION 21 of 162 29 NON-COLLUSION AFFIDAVIT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 STATE OF FLORIDA ) ) COUNTY OF MIAMI-DADE ) ___________________________________________ being first duly sworn, deposes and states that: (1) He/She/They is/are the ______________________________________________________ (Owner, Partner, Officer, Representative or Agent) of __________________________________________ the Respondent that has submitted the attached Proposal; (2) He/She/They is/are fully informed concerning the preparation and contents of the attached Proposal and of all pertinent circumstances concerning such Proposal; (3) Such Proposal is genuine and is not a collusive or sham Proposal; (4) Neither the said Respondent nor any of its officers, partners, owners, agents, representatives, employees or parties in interest, including this affiant, have in any way colluded, conspired, connived or agreed, directly or indirectly, with any other Respondent, firm, or person to submit a collusive or sham Proposal in connection with the Work for which the attached Proposal has been submitted; or to refrain from Bidding or proposing in connection with such Work; or have in any manner, directly or indirectly, sought by agreement or collusion, or communication, or conference with any Respondent, firm, or person to fix any overhead, profit, or cost elements of the Proposal or of any other Respondent, or to fix any overhead, profit, or cost elements of the Pr oposal Price or the Proposal Price of any other Respondent, or to secure through any collusion, conspiracy, connivance, or unlawful agreement any advantage against (Recipient), or any person interested in the proposed Work; (5) The price or prices quoted in the attached Proposal are fair and proper and are not tainted by any collusion, conspiracy, connivance, or unlawful agreement on the part of the Respondent or any other of its agents, representatives, owners, employees or parties of interest, including this affiant. Signed, sealed and delivered in the presence of: _________________________________ By: ___________________________________ Witness Signature _________________________________ ___________________________________ Witness Print Name and Title ___________________________________ Date ACKNOWLEDGEMENT STATE OF FLORIDA ) ) COUNTY OF MIAMI-DADE ) On this the _______ day of ______________, 20_____, before me, the undersigned Notary Public of the State of Florida, personally appeared (Name(s) of individual(s) who appeared before notary) ______________________________________________ and whose name(s) is/are Subscribed to the within instrument, and he/she/they acknowledge that he/she/they executed it. 22 of 162 30 WITNESS my hand and official seal. _______________________________________ Notary Public, State of Florida NOTARY PUBLIC: SEAL OF OFFICE: ______________________________________ (Name of Notary Public: Print, Stamp or type as commissioned.) ____ Personally known to me, or ____ Personal identification: _________________________ Type of Identification Produced ____ Did take an oath, or ____ Did Not take an oath. 23 of 162 31 PUBLIC ENTITY CRIMES AND CONFLICTS OF INTEREST DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 Pursuant to the provisions of Paragraph (2) (a) of Section 287.133, Florida State Statutes – “A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a Proposal or bid on a Contract to provide any goods or services to a public entity, may not submit a Bid or proposal for a Contract with a public entity for the construction of repair of a public building or public work, may not submit bids or proposals on leases or real property to a public entity, may not be awarded to perform Work as a RESPONDENT, Sub-contractor, supplier, Sub-consultant, or Consultant under a Contract with any public entity, and may not transact business with any public entity in excess of the threshold amount C ategory Two of Section 287.017, Florida Statutes, for thirty six (36) months from the date of being placed on the convicted vendor list”. The award of any contract hereunder is subject to the provisions of Chapter 112, Florida State Statutes. Respondents must disclose with their Proposals, the name of any officer, director, partner, associate or agent who is also an officer or employee of the City of South Miami or its agencies. SWORN STATEMENT PURSUANT TO SECTION 287.133 (3) (a), FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. 1. This sworn statement is submitted to ____________________________________________________________________________ [print name of the public entity] by ____________________________________________________________________________ [print individual’s name and title] for___________________________________________________________________________ [print name of entity submitting sworn statement] whose business address is and (if applicable) its Federal Employer Iden tification Number (FEIN) is ____________________ (If the entity has no FEIN, include the Social Security Number of the individual signing this sworn statement: ___________________________________________________.) 2. I understand that a “public entity crime” as defined in Paragraph 287.133 (1)(g), Florida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to , any bid, proposal or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation. 3. I understand that “convicted” or “conviction” as defined in Paragraph 287.133 (1) (b), Florida Statutes, means a finding of guilt or a conviction of a public entity crime, with or without an adjudication of guilt, in any federal or state trial court of record relating to charges brought by indictment or information after July 1, 1989, as a result of a jury verdict, non-jury trial, or entry of a plea of guilty or nolo contendere. 4. I understand that an “affiliate” as defined in Paragraph 287.133 (1) (a), Florida Statutes, means: (a) A predecessor or successor of a person convicted of a public entity crime; or (b) An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term “affiliate” includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in any person, or a pooling of equipment or income among persons when not for fair market value under an arm’s length agreement, will be a prima facie case that one person controls 24 of 162 32 another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months will be considered an affiliate. 5. I understand that a “person” as defined in Paragraph 287.133 (1) (e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or proposal or applies to bid or proposal on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term “person” includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. 6. Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this sworn statement. [Indicate which statement applies.] _____ Neither the entity submitting this sworn statement, nor any of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and con victed of a public entity crime subsequent to July 1, 1989. _____ The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. _____ The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent of July 1, 1989. However, there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it was not in the public interest to place the entity submitting this sworn statement on the convicted ven dor list. [attach a copy of the final order.] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FOR THE PUBLIC ENTITY IDENTIFIED IN PARAGRAPH 1 (ONE) ABOVE IS FOR THAT PUBLIC ENTITY ONLY, AND THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017, FLORIDA STATUTES, FOR CATEGORY TWO OF ANY CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. ____________________________________ [Signature] Sworn to and subscribed before me this __________ day of ___________________________, 20____. Personally known ________________________ ___________________________________ OR Produced identification _________________ Notary Public – State of ________________ _______________________________________ My commission expires ________________ (Type of identification) (Printed, typed or stamped commissioned Form PUR 7068 (Rev.06/11/92) name of notary public) 25 of 162 33 DRUG FREE WORKPLACE DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 Whenever two or more responses to a solicitation which are equal with respect to price, quality and service are received by the State or by any political subdivisions for the procurement of commodities or contractual services, a response to the solicitation received from a business that certifies that it has implemented a drug-free workplace program will be given preference in the award process. Established procedures for processing tie responses to solicitations will be followed if none of the tied vendors have a drug-free workplace program. In order to have a drug-free workplace program, a business must: 1) Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. 2) Inform employees about the dangers of drug abuse in the workplace, the business’s policy of maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be imposed upon employees for drug abuse violations. 3) Give each employee engaged in providing the commodities or contractual services that are under Bid a copy of the statement specified in paragraph (1) above. 4) In the statement specified in paragraph (1) above, notify the employees, that, as a condition to their working for the employer with regard to the matters that are the subject of the response to the solicitation including those involving the procurement of commodities or contractual services that are under Bid, the employee must abide by the terms of the statement and must notify the employer of any conviction of, or plea of guilty or nolo contendere to, any violation of Chapter 893 or of any controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5) days after such conviction. 5) Impose a sanction on or require the satisfactory participation in a drug abuse assistance or rehabilitation program, if such is available in the employee’s community, by any employee who is so convicted. 6) Make a good faith effort to continue to maintain a drug-free workplace through implementation of this section. As the person authorized to sign this statement, and under penalties of perjury, I declare that I have read the foregoing statement and that the facts stated in it are true and that this firm is in full compliance with the above requirements. RESPONDENT’s Signature: ___________________________________ Print Name: _________________________________________ Date: ______________________________________________ 26 of 162 34 ACKNOWLEDGEMENT OF CONFORMANCE WITH OSHA STANDARDS DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 TO THE CITY OF SOUTH MIAMI We, _____________________________, (Name of RESPONDENT), hereby acknowledge and agree that as CONTRACTOR for the DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 as specified have the sole responsibility for compliance with all the requirements of the Federal Occupational Safety and Health Act of 1970, and all State and local safety and health regulations, and agree to indemnify and hold harmless the City of South Miami and N/A (Consulting Engineer if any) against any and all liability, claims, damages, losses and expenses they may incur due to the failure of Whenever two or more responses to a solicitation which are equal with respect to price, quality and service are received by the State or by any political subdivisions for the procurement of commodities or contractual services, a response to the solicitation received from a business that certifies that it has implemented a drug-free workplace program will be given preference in the award process. Established procedures for processing tie responses to solicitations will be followed if none of the tied vendors have a drug-free workplace program. In order to have a drug-free workplace program, a business must: 1) Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. 2) Inform employees about the dangers of drug abuse in the workplace, the business’s policy of maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be imposed upon employees for drug abuse violations. 3) Give each employee engaged in providing the commodities or contractual services that are under E-bid a copy of the statement specified in Section (1). 4) In the statement specified in Section (1), notify the employees, that, as a condition to their working for the employer with regard to the matters that are the subject of the response to the solicitation including those involving the procurement of commodities or contractual services that are under E-bid, the employee must abide by the terms of the statement and must notify the employer of any conviction of, or plea of guilty or nolo contendere to, any violation of Chapter 893 or of any controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5) days after such conviction. 5) Impose a sanction on or require the satisfactory participation in a drug abuse assistance or rehabilitation program, if such is available in the employee’s community, by any employee who is so convicted. 6) Make a good faith effort to continue to maintain a drug-free workplace through implementation of this section. As the person authorized to sign this statement, and under penalties of perjury, I declare that I have read the foregoing statement and that the facts stated in it are true and that this firm and its subcontractors, if any, who are listed below, are in full compliance with the above requirements: CONTRACTOR _____________________________________ ________________________________ Witness BY: __________________________________ Name __________________________________ Title 27 of 162 35 AFFIDAVIT CONCERNING FEDERAL AND STATE VENDOR LISTINGS DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 The person, or entity, who is responding to the City’s solicitation, hereinafter referred to as “Respondent”, must certify that the Respondent’s name Does Not appear on the State of Florida, Department of Management Services, “CONVICTED, SUSPENDED, DISCRIMINATORY FEDERAL EXCLUDED PARTIES and COMPLAINTS VENDOR LISTINGS”. If the Respondent’s name appears on one or all the “Listings” summarized below, Respondents must “Check if Applies” next to the applicable “Listing.” The “Listings” can be accessed through the following link to the Florida Department of Management Services website: http://www.dms.myflorida.com/business_operations/state_purchasing/vendor_i nformation/convicted_suspended_di scriminatory_complaints_vendor_lists DECLARATION UNDER PENALTY OF PERJURY I, _____________________ (hereinafter referred to as the “Declarant”) state, that the following facts are true and correct: (1) I represent the Respondent whose name is ______________________________. (2) I have the following relationship with the Respondent __________________ (Owner (if Respondent is a sole proprietor), President (if Respondent is a corporation) Partner (if Respondent is a partnership), General Partner (if Respondent is a Limited Partnership) or Managing Member> (if Respondent is a Limited Liability Company). (3) I have reviewed the Florida Department of Management Services website at the following URL address: http://www.dms.myflorida.com/business_operations/state_purchasing/vendor_information/convicted_suspended_di scriminatory_complaints_vendor_lists (4) I have entered an “x” or a check mark beside each listing/category set forth below if the Respondent’s name appears in the list found on the Florida Department of Management Services website for that category or listing. If I did not enter a mark beside a listing/category, it means that I am attesting to the fact that the Respondent’s name does not appear on the listing for that category in the Florida Department of Management Services website as of the date of this affidavit. Check the following categories if Applicable ___ Convicted Vendor List ___ Suspended Vendor List ___ Discriminatory Vendor List ___ Federal Excluded Parties List ___ Vendor Complaint List Under penalties of perjury, and as the person authorized to sign this statement, I declare that I have read the foregoing statement and that the facts stated in it are true and that this firm is in full compliance with the above requirements. By: ___________________________ (Signature of Declarant) ___________________________ (Print name of Declarant) ACKNOWLEDGEMENT STATE OF FLORIDA ) COUNTY OF MIAMI-DADE ) On this the ____ day of ______________, 20_____, before me, the undersigned authority, personally appeared ____________________________________ who is personally know to me or who provided the following identification ______________ and who took an oath or affirmed that that he/she/they executed the foregoing Affidavit as the Declarant. WITNESS my hand and official seal. ____________________________ Notary Public, State of Florida NOTARY PUBLIC: SEAL ____________________________ (Name of Notary Public: Print, Stamp or type as commissioned.) 28 of 162 36 RELATED PARTY TRANSACTION VERIFICATION FORM DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 I ______________________________, individually and on behalf of ______________________________ (“Firm”) have Name of Representative Company/Vendor/Entity read the City of South Miami (“City”)’s Code of Ethics, Section 8A-1 of the City’s Code of Ordinances and I hereby certify, under penalties of perjury that to the best of my knowledge, information and belief: (1) neither I nor the Firm have any conflict of interest (as defined in section 8A-1) with regard to the contract or business that I, and/or the Firm, am(are) about to perform for, or to transact with, the City, and (2) neither I nor any employees, officers, directors of the Firm, nor anyone who has a financial interest greater than 5% in the Firm, has any relative(s), as defined in section 8A-1, who is an employee of the City or who is(are) an appointed or elected official of the City, or who is(are) a member of any public body created by the City Commission, i.e., a board or committee of the City, [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (2) must be based solely on the signatory’s personal knowledge and he/she is not required to make an independent investigation as to the relationship of employees or those who have a financ ial interest in the Firm.]; and (3) neither I nor the Firm, nor anyone who has a financial interest greater than 5% in the Firm, nor any member of those persons’ immediate family (i.e., spouse, parents, children, brothers and sisters) has transacted or entered into any contract(s) with the City or has a financial interest, direct or indirect, in any business being transacted with the city, or with any person or agency acting for the city, other than as follows: ____________________________________________________________________________________ _ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (3) must be based solely on the signatory’s personal knowledge and he/she is not required to make an independent investigation as to the relationship of those who have a financial interest in the Firm.]; and (4) no elected and/or appointed official or employee of the City of South Miami, or any of their immediate family members (i.e., spouse, parents, children, brothers and sisters) has a financial interest, directly or indirectly, in the contract between you and/or your Firm and the City other than the following individuals whose interest is set forth following their names: _______________________________________________ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must refer, on the above line, to the additional sheet and the additional sheet must be signed under oath). The names of all City employees and that of all elected and/or appointed city officials or board members, who own, directly or indirectly, an interest of five percent (5%) or more of the total assets of capital stock in the firm are as follows: _______________________________________________________________________________ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must refer, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (4) must be based solely on the signatory’s personal knowledge and he/she is not required to make an independent investigation as to the financial interest in the Firm of city employees, appointed officials or the immediate family members of elected and/or appointed official or employee.] (5) I and the Firm further agree not to use or attempt to use any knowledge, property or resource which may come to us through our position of trust, or through our performance of our duties under the terms of the contract with the City, to secure a special privilege, benefit, or exemption for o urselves, or others. We agree that we may not disclose or use information, not available to members of the general public, for our personal gain or benefit or for the personal gain or benefit of any other person or business entity, outside of the normal ga in or benefit anticipated through the performance of the contract. (6) I and the Firm hereby acknowledge that we have not contracted or transacted any business with the City or any person or agency acting for the City, and that we have not appeared in representation of any third party before any board, commission or agency of the City within the past two years other than as 29 of 162 37 follows:____________________________________________________________________________ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). X:\Purchasing\Vendor Registration\12.28.12 RELATED PARTY TRANSACTION VERIFICATION FORM [3].docx (7) Neither I nor any employees, officers, or directors of the Firm, nor any of their immediate family (i.e., as a spouse, son, daughter, parent, brother or sister) is related by blood or marriage to: (i) any member of the City Commission; (ii) any city employee; or (iii) any member of any board or agency of the City other than as follows: ____________________________________________(if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (7) must be based solely on the signatory’s personal knowledge and he/she is not required to make an independent investigation as to the relationship by blood or marriage of employees, officers, or directors of the Firm, or of any of their immediate family to any appointed or elected officials of the City, or to their immediate family members]. (8) No Other Firm, nor any officers or directors of that Other Firm or anyone who has a financial interest greater than 5% in that Other Firm, nor any member of those persons’ immediate family (i.e., spouse, parents, children, brothers and sisters) nor any of my immediate family members (hereinafter referred to as “Related Parties”) has responded to a solicitation by the City in which I or the Firm that I represent or anyone who has a financial interest greater than 5% in the Firm, or any member of those persons’ immediate family (i.e. spouse, parents, children, brothers and sisters) have also responded, other than the following: ______________________________________________________________________________________ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must refer, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm wh ose stock is publicly traded, the statement in this section (8) must be based solely on the signatory’s personal knowledge and he/she is not required to make an independent investigation into the Other Firm, or the Firm he/she represents, as to their officers, directors or anyone having a financial interest in those Firms or any of their any member of those persons’ immediate family.] (9) I and the Firm agree that we are obligated to supplement this Verification Form and inform the City of any change in circumstances that would change our answers to this document. Specifically, after the opening of any responses to a solicitation, I and the Firm have an obligation to supplement this Verification Form with the name of all Related Parties who have also responded to the same solicitation and to disclose the relationship of those parties to me and the Firm. (10) A violation of the City’s Ethics Code, the giving of any false information or the failure to supplement this Verification Form, may subject me or the Firm to immediate termination of any agreement with the City, and the imposition of the maximum fine and/or any penalties allowed by law. Additionally, violations may be considered by and subject to action by the Miami-Dade County Commission on Ethics. Under penalties of perjury, and as the person authorized to sign this statement, I declare that I have read the foregoing statement, that I have made a diligent effort to investigate the matters to which I am attesting hereinabove and to the best of my knowledge, information, and belief the facts stated in it are true and this firm is in full compliance with the above requirements. Signature: ___________________________ Print Name & Title: ______________________________ Date: ________________________ 30 of 162 38 Sec. 8A-1. - Conflict of interest and code of ethics ordinance. (a) Designation. This section shall be designated and known as the "City of South Miami Conflict of Interest and Code of Ethics Ordinance." This section shall be applicable to all city personnel as defined below and shall also constitute a standard of ethical conduct and behavior for all autonomous personnel, quasi-judicial personnel, advisory personnel and departmental personnel. The provisions of this section shall be applied in a cumulative manner. By way of example, and not as a limitation, subsections (c) and (d) may be applied to the same contract or transaction. (b) Definitions. For the purposes of this section the following definitions shall be effective: (1) The term "commission members" shall refer to the mayor and the members of the city commission. (2) The term "autonomous personnel" shall refer to the members of autonomous authorities, boards and agencies, such as the city community redevelopment agency and the health facilities authority. (3) The term "quasi-judicial personnel" shall refer to the members of the planning board, the environmental review and preservation board, the code enforcement board and such other individuals, boards and agencies of the city as perform quasi-judicial functions. (4) The term "advisory personnel" shall refer to the members of those city advisory boards and agencies whose sole or primary responsibility is to recommend legislation or give advice to the city commission. (5) The term "departmental personnel" shall refer to the city clerk, the city manager, department heads, the city attorney, and all assistants to the city clerk, city manager and city attorney, however titled. (6) The term "employees" shall refer to all other personnel employed by the city. (7) The term "compensation" shall refer to any money, gift, favor, thing of value or financial benefit conferred, or to be conferred, in return for services rendered or to be rendered. (8) The term "controlling financial interest" shall refer to ownership, directly or indirectly, of ten percent or more of the outstanding capital stock in any corporation or a direct or indirect interest of ten percent or more in a firm, partnership, or other business entity at the time of transacting business with the city. (9) The term "immediate family" shall refer to the spouse, parents, children, b rothers and sisters of the person involved. (10) The term "transact any business" shall refer to the purchase or sale by the city of specific goods or services for consideration and to submitting a bid, a proposal in response to a Solicitation, a statement of qualifications in response to a request by the city, or entering into contract negotiations for the provision on any goods or services, whichever first occurs. (c) Prohibition on transacting business with the city. No person included in the terms defined in paragraphs (b)(1) through (6) and in paragraph (b)(9) shall enter into any contract or transact any business in which that person or a member of the immediate family has a financial interest, direct or indirect with the city or any person or agency acting for the city, and any such contract, agreement or business engagement entered in violation of this subsection shall render the transaction voidable. Willful violation of this subsection shall constitute malfeasance in office and shall affect forfeiture of office or position. Nothing in this subsection shall prohibit or make illegal: (1) The payment of taxes, special assessments or fees for services provided by the city government; (2) The purchase of bonds, anticipation notes or other securities that may be issued by the city through underwriters or directly from time to time. Waiver of prohibition. The requirements of this subsection may be waived for a particular transaction only by four affirmative votes of the city commission after public hearing upon finding that: (1) An open-to-all sealed competitive proposal has been submitted by a city person as defined in paragraphs (b)(2), (3) and (4); (2) The proposal has been submitted by a person or firm offering services within the scope of the practice o f architecture, professional engineering, or registered land surveying, as defined by the laws of the state and 31 of 162 39 pursuant to the provisions of the Consultants' Competitive Negotiation Act, and when the proposal has been submitted by a city person defined in paragraphs (b)(2), (3) and (4); (3) The property or services to be involved in the proposed transaction are unique and the city cannot avail itself of such property or services without entering a transaction which would violate this subsection but for waiver of its requirements; and (4) That the proposed transaction will be in the best interest of the city. This subsection shall be applicable only to prospective transactions, and the city commission may in no case ratify a transaction entered in violation of this subsection. Provisions cumulative. This subsection shall be taken to be cumulative and shall not be construed to amend or repeal any other law pertaining to the same subject matter. (d) Further prohibition on transacting business with the city. No person included in the terms defined in paragraphs (b)(1) through (6) and in paragraph (b)(9) shall enter into any contract or transact any business through a firm, corporation, partnership or business entity in which that person or any member of the immediate family has a controlling financial interest, direct or indirect, with the city or any person or agency acting for the city, and any such contract, agreement or business engagement entered in violation of this subsection shall render the transaction voidable. The remaining provisions of subse ction (c) will also be applicable to this subsection as though incorporated by recitation. Additionally, no person included in the term defined in paragraph (b)(1) shall vote on or participate in any way in any matter presented to the city commission if that person has any of the following relationships with any of the persons or entities which would be or might be directly or indirectly affected by any action of the city commission: (1) Officer, director, partner, of counsel, consultant, employee, fiduciary or beneficiary; or (2) Stockholder, bondholder, debtor, or creditor, if in any instance the transaction or matter would affect the person defined in paragraph (b)(1) in a manner distinct from the manner in which it would affect the public generally. Any person included in the term defined in paragraph (b)(1) who has any of the specified relationships or who would or might, directly or indirectly, realize a profit by the action of the city commission shall not vote on or participate in any way in the matter. (E) Gifts. (1) Definition. The term "gift" shall refer to the transfer of anything of economic value, whether in the form of money, service, loan, travel, entertainment, hospitality, item or promise, or in any other form, without adequate and lawful consideration. (2) Exceptions. The provisions of paragraph (e)(1) shall not apply to: a. Political contributions specifically authorized by state law; b. Gifts from relatives or members of one's household, unless the person is a conduit on behalf of a third party to the delivery of a gift that is prohibited under paragraph (3); c. Awards for professional or civic achievement; d. Material such as books, reports, periodicals or pamphlets which are solely informational or of an advertising nature. (3) Prohibitions. A person described in paragraphs (b)(1) through (6) shall neither solicit nor demand any gift. It is also unlawful for any person or entity to offer, give or agree to give to any person included in the terms defined in paragraphs (b)(1) through (6), or for any person included in the terms defined in paragraphs (b)(1) through (6) to accept or agree to accept from another person or entity, any gift for or because of: a. An official public action taken, or to be taken, or which could be taken, or an omission or failure to take a public action; b. A legal duty performed or to be performed, or which could be performed, or an omission or failure to perfor m a legal duty; c. A legal duty violated or to be violated, or which could be violated by any person included in the term defined in paragraph (b)(1); or d. Attendance or absence from a public meeting at which official action is to be taken. 32 of 162 40 (4) Disclosure. Any person included in the term defined in paragraphs (b)(1) through (6) shall disclose any gift, or series of gifts from anyone person or entity, having a value in excess of $25.00. The disclosure shall be made by filing a copy of the disclosure form required by chapter 112, Florida Statutes, for "local officers" with the city clerk simultaneously with the filing of the form with the clerk of the county and with the Florida Secretary of State. (f) Compulsory disclosure by employees of firms doing business with the city. Should any person included in the terms defined in paragraphs (b)(1) through (6) be employed by a corporation, firm, partnership or business entity in which that person or the immediate family does not have a controlling financial interest, and should the corporation, firm, partnership or business entity have substantial business commitments to or from the city or any city agency, or be subject to direct regulation by the city or a city agency, then the person shall file a sworn statement disclosing such employment and interest with the clerk of the city. (g) Exploitation of official position prohibited. No person included in the terms defined in paragraphs (b)(1) through (6) shall corruptly use or attempt to use an official position to secure special privileges or exemptions for that person or others. (h) Prohibition on use of confidential information. No person included in the terms defined in paragraphs (b)(1) through (6) shall accept employment or engage in any business or professional activity which one might reasonably expect would require or induce one to disclose confidential information acquired by reason of an official position, nor shall that person in fact ever disclose confidential information garnered or gained through an official position with the city, nor shall that person ever use such information, directly or indirectly, for personal gain or benefit. (i) Conflicting employment prohibited. No person included in the terms defined in paragraphs (b)(1) through (6) shall accept other employment which would impair independence of judgment in the performance of any public duties. (j) Prohibition on outside employment. (1) No person included in the terms defined in paragraphs (b)(6) shall receive any compensation for services as an officer or employee of the city from any source other than the city, except as may be permitted as follows: a. Generally prohibited. No full-time city employee shall accept outside employment, either incidental, occasional or otherwise, where city time, equipment or material is to be used or where such employment or any part thereof is to be performed on city time. b. When permitted. A full-time city employee may accept incidental or occasional outside employment so long as such employment is not contrary, detrimental or adverse to the interest of the city or any of its departments and the approval required in subparagraph c. is obtained. c. Approval of department head required. Any outside employment by any full-time city employee must first be approved in writing by the employee's department head who shall maintain a complete record of such employment. d. Penalty. Any person convicted of violating any provision of this subsection shall be punished as provided in section 1-11 of the Code of Miami-Dade County and, in addition shall be subject to dismissal by the appointing authority. The city may also assess against a violator a fine not to exceed $500.00 and the costs of investigation incurred by the city. (2) All full-time city employees engaged in any outside employment for any person, firm, corporation or entity other than the city, or any of its agencies or instrumentalities, shall file, under oath, an annual report indicating the source of the outside employment, the nature of the work being done and any amount of money or other consideration received by the employee from the outside employment. City employee reports shall be filed with the city clerk. The reports shall be available at a reasonable time and place for inspect ion by the public. The city manager may require monthly reports from individual employees or groups of employees for good cause. (k) Prohibited investments. No person included in the terms defined in paragraphs (b)(1) through (6) or a member of the immedi ate family shall have personal investments in any enterprise which will create a substantial conflict between private interests and the public interest. 33 of 162 41 (I) Certain appearances and payment prohibited. (1) No person included in the terms defined in paragraphs (b)(1), (5) and (6) shall appear before any city board or agency and make a presentation on behalf of a third person with respect to any matter, license, contract, certificate, ruling, decision, opinion, rate schedule, franchise, or other benefit sought by the third person. Nor shall the person receive any compensation or gift, directly or indirectly, for services rendered to a third person, who has applied for or is seeking some benefit from the city or a city agency, in connection with the particular b enefit sought by the third person. Nor shall the person appear in any court or before any administrative tribunal as counselor legal advisor to a party who seeks legal relief from the city or a city agency through the suit in question. (2) No person included in the terms defined in paragraphs (b)(2), (3) and (4) shall appear before the city commission or agency on which the person serves, either directly or through an associate, and make a presentation on behalf of a third person with respect to any matter, license, contract, certificate, ruling, decision, opinion, rate schedule, franchise, or other benefit sought by the third person. Nor shall such person receive any compensation or gift, directly or indirectly, for services rendered to a third party who ha s applied for or is seeking some benefit from the city commission or agency on which the person serves in connection with the particular benefit sought by the third party. Nor shall the person appear in any court or before any administrative tribunal as counselor legal advisor to a third party who seeks legal relief from the city commission or agency on which such person serves through the suit in question. (m) Actions prohibited when financial interests involved. No person included in the terms defined in paragraphs (b) (1) through (6) shall participate in any official action directly or indirectly affecting a business in which that person or any member of the immediate family has a financial interest. A financial interest is defined in this subsection to include, but not be limited to, any direct or indirect interest in any investment, equity, or debt. (n) Acquiring financial interests. No person included in the terms defined in paragraphs (b)(1) through (6) shall acquire a financial interest in a project, business entity or property at a time when the person believes or has reason to believe that the financial interest may be directly affected by official actions or by official actions by the city or city agency of which the person is an official, officer or employee. (0) Recommending professional services. No person included in the terms defined in paragraphs (b)(1) through (4) may recommend the services of any lawyer or law firm, architect or architectural firm, public relations firm, or any other perso n or firm, professional or otherwise, to assist in any transaction involving the city or any of its agencies, provided that a recommendation may properly be made when required to be made by the duties of office and in advance at a public meeting attended by other city officials, officers or employees. (p) Continuing application after city service. (1) No person included in the terms defined in paragraphs (b)(1), (5) and (6) shall, for a period of two years after his or her city service or employment has ceased, lobby any city official [as defined in paragraphs (b)(1) through (6)] in connection with any judicial or other proceeding, application, Solicitation, RFQ, bid, request for ruling or other determination, contract, claim, controversy, charge, accusation, arrest or other particular subject matter in which the city or one of its agencies is a party or has any interest whatever, whether direct or indirect. Nothing contained in this subsection shall prohibit any individual from submitting a routine administrative request or application to a city department or agency during the two -year period after his or her service has ceased. (2) The provisions of the subsection shall not apply to persons who become employed by governmental entities, 501(c)(3) non-profit entities or educational institutions or entities, and who lobby on behalf of those entities in their official capacities. (3) The provisions of this subsection shall apply to all persons described in paragraph (p)(1) whose city service or employment ceased after the effective date of the ordinance from which this section derives. (4) No person described in paragraph (p)(1) whose city service or employment ceased within two years prior to the effective date of this ordinance shall for a period of two years after his or her service or employment enter into a lobbying contract to lobby any city official in connection with any subject described in paragraph (p)(1) in which the city or one of its agencies is a party or has any direct and substant ial interest; and in which he or she participated directly or indirectly through decision, approval, disapproval, recommendation, the rendering of 34 of 162 42 advice, investigation, or otherwise, during his or her city service or employment. A person participated "directly" where he or she was substantially involved in the particular subject matter through decision, approval, disapproval, recommendation, the rendering of advice, investigation, or otherwise, during his or her city service or employment. A person participated "indirectly" where he or she knowingly participated in any way in the particular subject matter through decision, approval, disapproval, recommendation, the rendering of advice, investigation, or otherwise, during his or her city service or employment. All persons covered by this paragraph shall execute an affidavit on a form approved by the city attorney prior to lobbying any city official attesting that the requirements of this subsection do not preclude the person from lobbying city officials. (5) Any person who violates this subsection shall be subject to the penalties provided in section 8A -2(p). (q) City attorney to render opinions on request. Whenever any person included in the terms defined in paragraphs (b)(1) through (6) and paragraph (b)(9) is in doubt as to the proper interpretation or application of this conflict of interest and code of ethics ordinance, or whenever any person who renders services to the city is in doubt as to the applicability of the ordinance that person, may submit to the city attorney a full written statement of the facts and questions. The city attorney shall then render an opinion to such person and shall publish these opinions without use of the name of the person advised unless the person permits the use of a name. 35 of 162 43 PRESENTATION TEAM DECLARATION/AFFIDAVIT OF REPRESENTATION DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 This affidavit is not required for compliance with the City’s Solicitation; however, it may be used to avoid the need to register members of your presentation team as lobbyists. Pursuant to City Ordinance 28-14- 2206 (c)(9), any person who appears as a representative for an individual or firm for an oral presentation before a City certification, evaluation, selection, technical review or similar committee, must list on an affidavit provided by the City staff, all individuals who may make a presentation. The affidavit must be filed by staff with the Clerk's office at the time the committee's proposal is submitted to the City Manager. For the purpose of this subsection only, the listed members of the presentation team, with the exception of any person otherwise required to register as a lobbyist, must not be required to pay any registration fees. No person may appear before any committee on behalf of an anyone unless he or she has been listed as part of the firm's presentation team pursuant to this paragraph or unless he or she is registered with the City Clerk's office as a lobbyist and has paid all applicable lobbyist registration fees. Pursuant to '92.525(2), Florida Statutes, the undersigned, ________________, makes the following declaration under penalties of perjury: Listed below are all individuals who may make a presentation on behalf of the entity that the affiant represents. Please note; No person may appear before any committee on behalf of anyone unless he or she has been listed as part of the firm's presentation team pursuant to this paragraph or unless he or she is registered with the Clerk's office as a lobbyist and has paid all applicable lobbyist registration fees. NAME TITLE For the purpose of this Affidavit of Representation only, the listed members of the presentation team, with the exception of any person otherwise required to register as a lobbyist, will not be required to pay any registration fees. The Affidavit of Representation must be filed with the City Clerk's office at the time the committee's proposal is submitted to the City as part of the procurement process. Under penalties of perjury, I declare that I have read the foregoing declaration and that the facts stated in it are true and specifically that the persons listed above are the members of the presentation team of the entity listed below. Executed this ______ day of ___________________, 20 ___. ___________________________ Signature of Representative ___________________________ ______________________________ Print Name and Title Print name of entity being represented. END OF SECTION 36 of 162 44 NOTICE OF AWARD DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 The City has considered the Proposal submitted by your firm for the DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 in response to the City’s advertisement for Request for Proposal and Instructions to Respondents. You are hereby notified that your Proposal has been accepted for the DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 and the negotiated price is attached as Exhibit A to this Notice of Award. You are required by the Instructions to Respondents to execute the Contract Documents at the time of submittal of proposal and to furnish any required bonding, including a Performance Bond, Payment Bond, and insurance documents (see Proposal Submittal Checklist Form) within ten (10) day from the date of this notice to you. Notwithstanding the fact that you have agreed, by responding to the Solicitation, to the terms of the contract attached to the Solicitation package, if you fail to execute said Contract and to furnish said bonds, the required insurance documentation within ten (10) calendar days from the date of this notice, the CITY will have the right and be entitled, in its sole and absolute discretion, to disqualify the Proposal, revoke the award and retain the Proposal/Bid Bond/Security. Please be advised that if the contract price exceeds $5,000.00 or if it is a multi -year contract requiring payment out of more than one year’s appropriation, the award and the contract must be approved by the City Commission before it is binding on the City. Moreover, the award is subject to rescission if the City Manager determines that it is not in the best interest of the City. BY: __________________________________ Shari Kamali City Manager Dated this ____ day of ______________, 20____ ACCEPTANCE OF NOTICE Receipt of the above Notice of Award is hereby acknowledged by _______________________________ On this the ______ day of ____________________, 20____. BY: __________________________ TITLE: __________________________ You are required to return an acknowledged copy of this Notice of Award to the City Manager. END OF SECTION 37 of 162 45 EXHIBIT 1 SCOPE OF SERVICES Attachment A DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 I. General Requirements: The City of South Miami recently obtained the rights to operate the South Miami Municipal Parking Garage located at SW 73rd Street between 58th Court and 58th Avenue, South Miami, FL 33143. The garage currently includes approximately thirty-four (34) existing CCTV predominantly utilizing small dome cameras mounted vertically on the walls. The current security system is inadequate and does not meet the needs of the City. The City is soliciting turnkey services, including but not limited to the design, purchase, installation, configuring and permitting, for a state-of-the art CCTV IP Video Surveillance Solution by a qualified and licensed CCTV IP Video Surveillance Solution installer for commercial properties. The work specified in this Request for Qualifications (RFQ) consists of furnishing all goods, materials, supplies and services necessary to provide a completed project that meets all of the needs described in this Scope of Services and as otherwise described in this RFQ (the “Work”). The Work is to be performed per specifications and the contract documents. The Work is to be performed in accordance with the specifications and the contract documents (as defined in the Instructions for Respondents) that are required to be produced by the Contractor and that are approved by the City. This includes, but is not limited to keeping the project site clean and safe, the furnishing all labor of the Contractor and the labor of all allowable subcontractors, the cost of dumpster(s) and the disposal of materials as well as all necessary engineering and architectural plans, drawings and technical specifications and permits; all necessary equipment, including rental equipment, machinery, tools, means of transportation, the coordination with any other City contractor, subcontractors and utility companies (i.e. power, gas, water); erecting construction safety measures, including fencing, and cones, and ensuring that the safety measure are in place at the end of each working day, cleaning the construction site at the end of each working day; maintenance of traffic and hiring of off duty City police officer, if required by the City; and any other goods and services necessary to perform all of the Work. Permit fees are waived for permits required to be issued directly by the City of South Miami. Permit fees charged by other government entities, if required, are the responsibility of the Respondent/Contractor; however, in all cases; it is the responsibility of Respondent/Contractor to secure any and all permits that may be required for this project. All of the Work must be reflected in the Respondent’s proposal and EXHIBIT 1, SCOPE OF SERVICES, ATTACHMENTS A, B, C & D. II. Scope of Work: Scope of work is a turnkey project for the design, purchase, permitting, installation, configuring, and the setting up of a fully operational state-of-the art CCTV IP Video Surveillance Solution which includes deployment of state-of-the-art POE (Power Over Ethernet) technology utilizing the latest 4K state-of-the-art CCTV technology, security 38 of 162 46 cameras, License Plate Readers (LPR), Facial Recognition and, video camera coverage of the complete garage, including stairwells and elevators , emergency call boxes at a minimum on every floor, as well as all related and necessary materials at the City Municipal Garage identified in Exhibit 1, Scope of Services “Site Location,” listed below. The Respondent may leverage as much of the existing Parking Garage infrastructure as possible, without compromising the new design and functions. Given the License Plate Readers and Facial Recognition, some interface of a higher-level databases or police/security agencies would be anticipated. The new design must allow remote access to the camera system over the internet. The Respondent shall provide electrical diagrams, system design layout and structural diagrams and calculations as required. In addition, the Respondent shall provide on- going maintenance & service, and 24-7 technical support over a five (5) year term. Work activity is limited to the hours from 7:00 a.m. through 6:00 p.m., on weekdays from Monday through Friday and Saturday as provide in Section 7- 15 and 7-16 of the City’s Code of Ordinances. III. Site Location: The project is located at: • City of South Miami Municipal Parking Garage SW 73rd Street between 58th Court and 58th Avenue South Miami, FL 33143 The awarded contractor will be provided an extensive site visit of the Municipal Parking Garage facility to assist in the preparation of a cost/design proposal. IV. Construction Plans & Drawings: South Miami Municipal Parking Garage Construction Plans are located as Exhibit 1, Attachment B. Parking Garage Plans are located as Exhibit 1, Attachment C and a Boundary Survey is located as Exhibit 1, Attachment D. V. Project Duration: The Work must be completed within 60 calendar days from the Commencement Date set forth in the Notice to Proceed/Purchase Order/Email Notification. VI. Evaluation and Selection of a Consultants: Selection of Consultants/Respondents shall be in accordance with Florida Statute 287.055, “Consultants Competitive Negotiation Act,” and, the qualifications listed in Exhibit 3, “Evaluation and Selection Criteria.” While the “Consultants Competitive Negotiation Act,” does not legislatively apply for this project, the City will utilize the format and process for the Selection of Consultants/Respondents. It is the intention of the City to award a contract to the highest ranked Consultant/Respondent in accordance with the Exhibit 3 “Evaluation and Selection Criteria.” 39 of 162 47 VII. Warranty: Respondent/Contractor must include the following with their proposal: Applicable warranty and/or guarantees of all material and labor, including: • any conditions; and • guaranteed response time for repair; and • guaranteed replacement during the warranty period; and • life expectancy of LED lighting under normal use; and • Failures during the warranty period must be repaired or replaced to the satisfaction of the City; and • the term of the warranty. At a minimum, Respondent/Contractor must warrant their Work to be free of significant defects in workmanship and materials for a period of one (1) year and if General Conditions are made part of the contract documents for this project, at a minimum, Respondent/Contractor must warrant their Work in accordance with the warranty requirements found in the General Conditions to the Contract. City Manager will be the final arbiter in determining whether the defect is significant. If equipment is being provided, the standard manufacturer’s warranty information must be provided in writing for all equipment being proposed and, if required by the warranty, such equipment must be installed by an authorized installer before final payment is made. If the manufacturer’s warranty is issued to the respondent/contractor, Respondent/Contractor must assign it to the City before final payment. SPECIAL NOTE BID & PERFORMANCE AND PAYMENT BONDS ARE (NOT) REQUIRED FOR THIS PROJECT. END OF SECTION 40 of 162 48 EXHIBIT No. 1 SCOPE OF SERVICES ATTACHMENT B Request for Qualifications for the Design and Install Parking Garage Security System RFQ #FN2022- 18 “CONSTRUCTION PLANS, CITY OF SOUTH MIAMI MUNICIPAL PARKING GARAGE” 41 of 162 49 42 of 162 50 J: /: I l ~_..._~.~ ----_1 _____________________ ----_,_ ------~ • • • • • UlllCl S.W. 73rd Street between 58th Court & 58th Avenue South Miatni, Florida 33143 • • ac11 INDEX OF DRAWINGS DESIGN TEAM Survey Civil C-1 Demolition Plan C-2 Water & Sewer Plan C-2 Paving & Drainage Plan Architectural A-0 General Notes A-1 Site Plan -Site Data A-2 First Level Plan A-2a First Level Life Safety A-3 Second Level Plan A-3a Second Level Life Safety A-4 Third Level Plan A-4a Third Level Life Safety A-5 Fourth Level Plan A-5a Fourth Level Life Safety A-6 Fifth Level (Roof) Plan A-6a Fifth Level Life Safety A-7 Exterior Elevations A-8 Exterior Elevations A-9 Building Sections A-9a Building Sections A-10 Typical Wall Sections A-1 Oa Typical Wall Sections A-10b Typical Wall Sections A-11 a Elevator 1 Hoistway Architectural cont. A-12 First Level Reflected Ceiling Plan A-12a Second Level Reflected Ceiling Plan A-12b Third Level Reflected Ceiling Plan A-12c Fourth Level Reflected Ceiling Plan Storefront Pannels Storefront Pannels Cont 0 en Pannels ,-../'-_,,._. e a1 s Details Details Details Structural S-1 Notes, Schedules, Details S-2 Foundation Plan S-3 Second Level Framing Plan S-4 Third & Fourth Level Framing Plan S-5 Fifth Level Framing Plan S-6 Details, Schedules S-7 Details S-8 Details S-9 D s S-10 Details & S-11 Details Mechanical M-1.0 Notes, Schedules, Details M-1.1 HVAC First Floor Plan M-2.1 HVAC Second Floor Plan M-3.1 HVAC 3rd, 4th, 5th Plan M-4.1 Sections M-5.1 HVAC Schedules M-6.1 Details M-7.1 Details M-8.1 Details Electrical E-1.0 Electical Notes, Details, Schedules E-1.1 L Electrical Lighting Plan E-1.1 P Electrical Power Plan E-1.2P Electrical Room E-2.1 L Electrical Lighting Plan E-2.1 P Electrical Power Plan E-3.1 L Electrical Lighting Plan E-3.1 P Electrical Power Plan E-4.1 L Electrical Lighting Plan E-4.1 P Electrical Power Plan E-5.1 L Electrical Lighting Plan E-5.1 P Electrical Power Plan Plumbing P-1.1 First Level Plumbing Pain P-2.1 Second Level Plumbing Plan P-3.1 Third Level Plumbing Plan P-4.1 Fourth Floor Plumbing Plan P-5.1 Fifth Floor Plumbing Plan P-6.1 Plumbing Isometrics P-6.2 Storm Drainage Fire Protection FP-1 Sections FP-2 First Level Sprinkler Layout FP-3 Second Level Sprinkler Layout FP-4 Third Level Sprinkler Layout FP-5 Fourth Level Sprinkler Layout Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida Civil EnQineer: Consul-Tech Engineering 10570 NW 27th Street, Suite 101 Miami, Florida 33172 Ph: 305-599-3141 Fax: 305-599-3143 Client: City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Structural Engineer: Hershel! Gill Consulting Engineers, Inc. 4601 Ponce de Leon Blvd, Suite 350 Miami, Florida 33146 Ph: 305-667-3631 Fax: 305-665-9298 Architect: Blitstein Design Associates 285 Sevilla Avenue Coral Gables, Florida 33134 Ph: 305-444-4433 Fax: 305-444-0181 M.E.P. Engineer: William A. Berry & Associates Inc. 10200 NW 25th Street, Suite 111 Doral, Florida 33172 Ph: 305-513-9000 Fax: 305-513-9100 General Contractor: KVC Constructors Inc. 9499 NE 2nd Avenue, Suite 205 Miami, Florida 33138 Ph: 305-757-7707 Fax: 305-757-7701 Fire Protection Engineer: Simplex Grinnell 10550 Commerce Parkway Miramar, Florida 33025 Ph: 954-431-3700 Fax: 954-435-6650 BLITSTEIN DESIGN ASSOCIATES • ARCHITECTS • 285 SEVILLA AVENUE CORAL CABLES, FLORIDA . -----------l /i RECEIVED MAR 1 9 2007 KVC Constructors, Int 331~'/4 ·, icl 4: : -~---------------------------------------------------'-~,,--;-";', ._,,.,___ ,....~~ . / .-• ·,,;c.;c;.; . • ' . . . I ' i ..... o-• ' illM1Hllili1/;ir .. Ii 43 of 162 51 t r==================--============================-----=-----~=========== ....... =======-----------.... -==-----=--.... _---_--__ --_--__ -----====------==================---·-_··-_-_-=-_--·::-_••-=-----:i ,---------------------------------------------------------------------------------------------------------------------------------- F.. . • -. . - - . I-' ' ~ . - . • i -7 . : ! ARCHITECTURE 285 Sevilla Avenue Cootf,:ictor is to toke oore to protect adjacent areas from du:st and damage during the coMtruction process and shall clean up afte, themselves at the end of eoch workOO)'. All rubbish ond trash to be removed from the premises ond properly di,posed of each doy. No rubbish sh<JII be left in premises after each workday, (G.C. is responsible for all trash hauling.) All trodes sholl be responsible for reviewing their respective requireo'lents and coordinating their work with all other trade:,, G.C. to coordinate all wo~ of the 1torious subcontractors to assure efficient and orderly insto!lotion. Pnwide accommodation for item, installed at a later dote. Verify that erements of interrelated operating equipment are compatible. Coordinate work of v<:1rious sections that hove interdependent responsibilities for inst1Jllin9, connecting to, ond pl<:1cing in service such equipment. Coordinote space req1..1irements ond in:stol!ation of mechQnical on,j electrkol work that ore indicote-j, detoiled, or implied gn:immatieol1y on drawings. Unless specifically noted, provide and pay for labor, materials, and equipment, tools, con,tructioo equipment and mochioery, and other focilities and seNices necessary for proper execution and completion of work, inch.iding permits. G.C. shall purchase and maintain inst.nonce coverage in accordance with U,e requirements of the landlord and the tenant. Verify and coordin<1te with tenant's project mana..ier for any additional requirements. G.C. lo f1.1rnish all required temporary facilities ond temporary utilities immediotely after receipt of notice to proceed for use in corivenience of all those engog.ed in the project work. All contra-ctors to stay behind the barriers and mointain access to ,uch oreos cleon ond free of construction matetiols ond debris. Coordinote all construction ond scheduling with owner, reviewing all 11cheduted octivitie, ot 01Jtset of constrvction, Mowoble tolefances unles.s otherwise noted or indicated. The following tolen:mces shall apply to all work: -All verticol surfaces sholl be plumb or constructed to the exoct slopes or on9les indlcoted. -The maximum deviation from the true plone for vertical and horizontal surfaces shall not be more than 1 ;a• in 1 O' -o•os measured by a straight edge placed anywhere on the surface. -All horizontal surfo,:es shol1 be level or constructed to the exact angle indicated or intended. -Wo\l and soffit intenections shall bei 90 degrees or the exact angle indicoted or intended. -All cornera and edges shall be straight ond true without dentsi, WoJVes, bulges, or other blemishes. -All joints sholl be tight, stroi9ht, even, and smooth. -All operable items shall operots smoothly, without sticking or binding, and without excessive pla)' or looseness. The following materliols sho.11 bo !eft at the job site. They shall be takeo from the same material, lot or run used to construct and finish tha project: -One full quart of each i,>oint color in o clean, tighUy closed con, and cleorty morked. -One carton of restroom and flo04" tiles -One carton of eoch type of acousticol ceiling tile. Materials shall be left in one locotion upon owner's representoUves directiM ond approval. The o·wner or owner', subcontractors m,ay occupy portions of the project during the finol stoge of construction. Coordinote and cooperate with the owner to minimize conflict and facilitate the owner'!! operation. All dimensions and finishes :1hall be verified and coordinated with txisting conditio-ns ond constructio,i, fobricotion or purchasing. In cose of conflict betw,een the project requirements and / or exrsting conditions, the one hoving U,e mo$l $lringent requirements sholl govern os approved by the owner. Architect is to be notified of all discrepancies ond conflicb. Perform all wor'k in accordonce with occeptobfe trod& proctice to insure the highest quolity finished product expressed, or impUed. NI work to be performed by skilled personriel in occordol'tce with established standards of workmanship in each of the various trod-n. Coordinate blocking requirements with adjacent or related trodes, accessories, equipment. and fixture instollotion lhot require blockinq ot no odditionol cost to the contract, Repoir property dornoged by the instotters to a like new condition or replace dornoged surfaces ond moter!ol~ of previously instolled work by otl1er trades, in$tallers, end subcontroctors. Where requested by the owner to certify e<>nforrnMce to trode stondords or the project requiremer,ts, the contractor shall enlist a testing laborotory at the owner's e)(pense. If the requested test shows nonconformonce to generally accepted trade stondords or the project requirement,, the controctor shall correct the deficiency ot no odditronal cost to the owner and reimburse oll costs of the testing to tM.e oltfner, unless the contractor hos used products inearrectly lobefed by the monufocturer or has mode previously opproved changes. G.C. to provide security of tne work, including tools on.J uninsta11ed moterio1;1I~. Protect the WOfk, sf:Of"ed producb, construdJon equipment and owner's proiarty from theft and vandalism, and from entry by unauthorized personnel until final occeptan.i:e, IJainto;n o fully charged fire extin..iuisher at the project site at oll times. Do not use on)' material or equipment for On)' purpose other than that which it is speeifically designed or epecif1ed for. All materials and equipment thot ore similar shall be the same type, model, and style for the some use throughout the project, or they shall be rejected, When the project requirement, require thot tM in:stol1otion of work sho!I comply with manufacturer's instructions, perform thd worl< in strict accordonce with tlia most current written manufacturer's instructions. G.C. ti> supply owner with alt manufacturer's written material. AJI products and equipment to be delivered in on undamoged condition and stored in accordance with U,e manufacturer's in"Structions to ovoid disruption of the woric or damage to tMe items. Replace damaged or unfit materials at no cost to the owner. Notify the owner when the work is substantially e<>mplete and ready for inspection. Upon insp~tion, provide written operation end maintenance instructions and guarantees for all equipment ond mater!ols installed. Provide written guarenteesi for o p.eriod of one }'ecJr from the dote of fin-al occeptarice of the work. Provide finol clean up and damage repair kit at the proj~t conclusion. Leave premises neot, cleon, and clear of tools, equipment, ond surplus moterials. Un!ess reque:1ted by the owner, clean up shall include, but not b-s limited to: -Power vacu1.1ming the entire space, -Hand dusting and cleaning of al shelving, cabinetry, casework, gfo.ss and mirrors bath installed under this contract and existing walls ceilings, fixturu, etc. -Repoir or reple,:ement of property damoged during final completion of the project. The general controctor shall submit Dode County product approval for oll exterlof doors, windows, roofing, and glozing to the orchitl!lct for review ond oppro,..al. The owner, owner's representatives. and the architect m,ay visit the site periodically to condu-ct site inspections in order to insun• thot all work performed is in accordance to U,e plans and specifications. Photographs of the project moy be taken ot an~ time for documentation of the constructl'on progress. The general contractor, owner, and archite<:t moy post their corporate identification on the job site for the general public's interest The size of the signs must conform to locol code and si9noge spe<:ifications. BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Cota.I Gables, Fl 33134 J0.5..444-4433 fax 305 444-0181 EMAIL: bdamlamlObellsouthnet Site Work Contractor sMII verify the size ond location of alt stubs to the building os may be indlooted on the drawings. Contractor shall be required to bring all utility lines if required (water, sewer, gos, and electrical) into tha building from terminotion points os indicoted oo the pion:,, reody for s.elVlce. Owner shall submit soil reports pdor to construction of tMe foundation. The contractor sholl notify the orchitect of any discreponcy between the report and the plons prior to beginning worll;. All grading worl< shall conform to all city ond county reg1,.1lotions and ordinances. Contractor sholl protect odjocent properly during all groding r:,peretions. Contro(:tor !lholl field verify all elevation flow lines, existing condition, ond points of e<>nnections with adjoining properties. Ari)' discreponcies shol1 ba ca!led to the attention of the architect befon, proceeding with work. G.C. to verify all dimensions and elevations. Notify arctiitect of 01'1)' discrepancies, On all walking surfaces with a slopa o, less than 5,C provide o slip resistant finish, described as o medium so11ed finish. On all surfaces with o slope greater tharl 6,C, provide a slip resistant finish. Verify type with architect prior to worll;. Do not allow ony cross slopes to exceed 1/4• per foot or 2%. Coosmte Refer to stn.Jcturol drawinqs. Metal E'.obricatroo Provide all miscelloneous metal items including materials, fabrications, fastening, ond occessories, required for finished instollatiM os indicoted alid specified. Provide oil miscellaneous moterial occessor;u, tools, methods, and equipment required for fabrication ond instollotion of miscellonee-us metol items O!I indicated on drawings. All ferrous metol itl!lms shall be shop finished. TOi.lch up or repair damaged areas prior to installation with some material. Provide contoct surface:, with concrete,, mosonry, or other dissimilar materials with o minimum of one point zero (1,0) mil. df)' thickness of oo opprO\'ed zinc chromatic primer. Provide oll steel blockin9 ond bracing in metal stud fr<.imed partitions necessary for a complete installation 01 r9quired for support of oil w-oll-mounted equipment and fabrications os indicated on drawings. Provide supports ot doorjombs and elsewhere as required. f"obrlcate oil miscellaneous fromiog ond bracing items to detail of structural shopes, plates and bors. Weld joints where prodi,;,ol. Provide bolt9 and other connectlon devices as required. lndude anchor,, clip aii9les, sle8"o'es, oncho.- plate, and $imilor devices whether supplied or indicated. Set oc-curately in position os requir~ and anchor securely to building coristruction with fasteners appropriate, to the instollotion. Refer to structural drawings for more informaUon, Sealant and Cgytkjog Provide non-sog sealant camplyini with requirements of rederal specifications TTS-154.l of FS TT-S-230 Type 11•c1oss •g, Provide acoustical seofant which shall be non-hardening, non-drying synthetic n.bbef' sealing compo1.1nd with minimum 90 " solids. Use ot oil interior joints, at intersections between planes, around door and window frames. Primer shall be made or recommended by sealant manufochJrer fof' the specific conditioning and substrates. Provide backing moteriol by Dow -Ethafoam -or approved equol. Apply seolant over backing to uniform thiekr,ess in continuous be-od, filling all jo!nb and voids 90:lid. Superftciol pointing witti skim bood will not be ae<:epted. All s1.1rfaces shall be adequate:ly cleaned and prepared in occordonce with manufocturer?, written instructions' prior to installation. Wood ond Hollow Metal Doon, and frgma Prcwide welded metal doorframes at all G,C, provided doors, free fror,i scale and pitting 11nd otner surfoce defects, unless otherwise noted. Prov-ide hollow metal door as: required on plans constructed with the following material,: Minimum 18 gouge for faee sheets of interior doors. 16 gage for edge channels, Minimum 22 gouge for face stiffeners -Minimur,i 20 gouge for interior frames Provide doors of sizes afld types indicated on drawings, ftJlly welded seomless construction with no visible s~ms or joints on faces or >'e1ti'col edge,. Thickness Is os scheduled on drawings. race stiffener,, edges, ond hardware reinforcement sholl be of the Mighest quality workmanship and materials. P'ro..-ide in accordance with tha best trode practice ond monufact,;rer's written recommendations for tM& use intended, Provida custom mode welded units with integral trim, sizes ond shopes as indicoted on drawings. rabricete units square, true and free from defects. Hordw-ori, reinforcement ond anchors (erection, floor and jomb) shall be os required for seeure installation and shall be in accordance with trede requirements for the specified hordwore ond intended use. After fabrication, dress, fill, and sand exposed surfaces, Body putty holes and imperfection,. Apply uniform coot of monufocturer's standard prime c,o,ot to oll exposed ,urlaces. Leov& reody to receiva finish paint. Install frames accurately in loootion, indlcated on dr-awings. Install ridge plumb, level, and tl\le. Atign with adjacent constf\JCtion. Secure floor anchors to floor constructions with approved mechanical faster,ers. Anchor to odjoini~ walls with spedfied anchors. Broce frames to retain po:,ition on.J continually cheek olignment during construction of odjocent wads. Adjust frame loe<Jtian, os necessary using shims before fastening. Leo"we reody to re<:eive seolont where indicated on drawings. 1nstal1 wood doors, frames, and trim at sizes and thickness specified on drawings. Prepare doors for finish hordwore. Obtain templates from hard·wan, manufocturer Olid confirm type, location, ond ,pedal requirements of hordware for each door before cutting. Hong doors as scheduled on drawings in accurate locotions with 1/8' cleoronce at top~ and 3/a• cleoronce at bottom unless specifi-cal!y n.:ited for und.ercuts or other deviations in fit. Verify cleoronces required for floor finishes. Moke no •rit in• cuts on job site unloss approved. Hong pairs of doors as specified with 3/32• cleoranca ot meeting edges. Oemonstrot& t.hot doors open freely without binding, and latch properly when closed, Actess doors,, when, required, ore to be provided by general contractor. Doors to be by Milcor or equal. Use style DW at wall's 0nd ceilings, (at exterior stucco sofftt) and size 09 indicoted. Frorrie shall be galvanized steel. Ponel shall be 14- goge steel with sprint typa concealed hinges, opening to 175 degrees. Locks shall be f11,.1sh, screwdriver operated with metal CQn. Prime coot shall be factory applied. HordWQCO All finish hardwore fof' complete work shall ba furnished ond installed in accordance wiU, dro:win9s and sp-ecifications, Q1.1ontities listed in any instance ore for the controctor's convenience on~ ond ore not guaranteed. Items not specifically mentioned, bYt necessary to complete work shall be fumished, matching in finish and quolity of the items specified. Contractor to be responsible for proper operotion and fitting of hardware in locations specified. Contractor is to supply a room under lock and key to store all finish hardware. Store o, to description and lo,cation of installation in accordonce with approved plans. Exposed surfaces of hardware shall be covered and well protected during installation so as to ovoid any dom<:1ge, GENERAL NOTES Provide hardware for fire roted opening:! in compliance with requirements of Nf'P.'-80, These requirement, take pre<:edence over other requiremelits for such hardware. Hordw<Jre finish shall be as noted of specified. Use templates and other st.1pplles supplied by hordwars, manufacturer for proper instollation. Each item of hordwore Sholl b-e ~eked seporotely with all neces'SOry screH, fasteners, and tempkltes, Oell'Vor pockoge-s cleorly identified and labeled. tr-.,tall eoch hordj,::ire item in occ,ordonc• with monufacturer's written instructions otid reeommiandotions, and locate in accordon,:e wit~ re-commended locotions. Set items level, plumb, ond true to line and locotion, Mjusl and reinforce atto-chment substrot<l!I o'9 nectsS<ir')' for UCwre insto11otion. Space fasttntrs and anctiors as indlcat~ or in o¢¢¢rd-:inee with ind1.1stry standards. ~k.e finol ~ju~tfri~t at,d chetk 6f Mrdwor! ®rin~ 1.P'ie \\'eel\ immedi<itef)' prior to aoceptonce, Cle.:in and h.1brieote or,eroble items as n,e,cessary ta restore proper functioning and finish of h-:ircfware and doors. MQke final adjustment of locksets and closers to compe,nsote for operation of heotirig and ventikition sy,stem, under svpervi~on of manufadurer's repres-entotiveo. Lubrieote oil m<iving parts with graphite type lubricont unless otherwise re-commended by monufocturer. Replace all hardware that cannot be lubricated and adjusted to operate freely and smoothly. Partition Wotls Provide chonnel shaped rol1 formed steel members c9nforming to ASTM C640, hot dipped fini:,h where exposed to moisture, not less than 20 gage. Provide 16 goge at doorjomb,. Provide c:old rol!ej steel eMnnels not ress than 16 gouge. Provid1111 roll-ed roll hot stloped channels minimum 25 gouge, 7/a• dEep with 1;2• hemmed edges, hot dipped finish it'Mre noted. Provide galvonize-d l'lanqers of steel wire in accordonce with ASTM C754. Provide jock studs bet\til-een bottom track and winOOw ond / or relief sills, between lentils ond headers in top trocks. Provida blocking and framing for alt wall mounted finish hardwcra and equipment, incl\lding doorstoPS:. Provide double bead of butyl seolont at floor tracks, ceiling rock. ond studs abutting other construction. Provide chtlnnel shoped blockir'tg S\Jpport or gat-,cnit&d strip s1.1pport of wall-M,mg cabinet!!, eqU'ipment, fixt!Jra,, and a<:eessories of not less than 22-gauge rmterlol. Provide supl)Ort in wall or port.ition fromirtg system wherever woU hung cabinets and equipment are indieoted on droll'ings, ond where required for mounting miscelfaneo 1..1s items U,ot req•..1ire bocking. S~t floor tracks in O<Xurate locations ond securely onc.hor in accordance with AMST stolidords. Erect studs ot , 5• o.e. or as iridieoted, and secure to troek. Install heod track in oce0<donc::e to details. Install blocking, bradng. and anchor strips, Leave ready to receive finishes materials. Erect all comporients for ceilirrg and sof1it framing in accun:ite locations as indic1Jted, tl"IJ., to llne, level errd plumb, and in occordonc,s with opplicable ASTIA standards as reference.j obove. Use a loser level to odjust supports, sixins, or otherwise for !nstollotlon within specific tolerances. Provido kick bracir'lg in aceordance with industry standards for wall studs, ceilin9 member,, draft or smoke stops Qnd curtain walls. ~ Provide point finishn for buil.Jing and other surfaces for exterior and interior of b•.Jilding os speeified on drawings. Provide putty and or sealant ot aluminum windows. Prote<;t the work of other lra<Jes from domoge and defacement coused by this wor'k. Repair on:, dcimage coused by the work of tl'lis section. Remove e!ectr1cal 01.1tlet and switch plot-n, mecha~icol diffuser grilles, and oU,er s1,,1ch hardware, fitting,, and fastenings priar to e<>mmencing the worlr:. Store, cleon, and replace upon CQmpletron ofter finol point coot ho,a dried. Paint contractor to ootif:, general contractor if on:, surfoee to be pointed or stained is unS1.1itab!e to produce a proper finish. Apply no finish to the surface until it Ms t>Hn ~ sotltlfoctory, Finish work shan be uniform, of approved color, smooth, and free from n.ns and bru,h strokes. Maka ends of point adjoining other materials or colors sharp and clean. :.\'here nigh 9loss enomel is used, lightly sand under coot to obtain a smooth finish coot. Provide all newly pointed surfot;es with one coat tinted primer ond two coot, of final color unless otherwise retommended by point monufact1.1rer. Delfver all ixiint to job site In unopetied containers bearing the monufo-cturer's lab-el showing po;nt ty~. sheen, ond color. Paint types sholl be those specificolly recommended by tho monufocturer for the material for which U,ey are to be applied. Pointing contractor to follow monufectur-e-r's inslr\Jctions for proper application of the point. All s-urfoees to be pointed sholl be thorougMly cleane.J and p('epared for pointing prior to point appricotion. Provida ventilotora as required to prevent build up of fumes. Sandpaper all wood to a smooth ond even surface, and dust off, Apply primer coat, fill noil holes and other impertections with putty tinted with primer or stain to match wood color. Sand an wow'work between coots to o smooth surface, Bock !)rim all exterior ond interior wood ont trim to be pointed prior to installation. Thorou9hl)' cleon ond apply no finish unless S"Jrfoce in clean, dry, and reody for application. At completion, touch up and restore. ony do~ed surfoce. LeO\'e all surfaces in good cleon condition. Provide for multip{e site vis:it:t as required for to-ueh up and refinishin..i, Other pOlrit manufatturet!I may not be Sl.i~stit"Yt~ lfi~l'fout owner's opprovol. Finish all surfaces os specifie-d an dra·o'fings exce~t o, modified and supplemented hereinafter and 1,1pon written owner approvol. ~ Provid,s drywall panels manufoctured in accordonee with tMe requirements of ASTM JJ6 Provide type "X .. fire retardant drywoll panels as indicated on drawings 5/a• thick, tested and quolified for one-hour fire: rating. Toper and round ed,ges. Provide meto1 edg,s and corner beads ot el'lds, edges, ond corners. F'or -:oritrol joLnts, providis U.S. gypsum f09J or opp('oved equal. Install in locotions as reeommef'lded by industry sfondords and in complionee with U.S. gypsum wallboard standards. Provido fostener, in ae<:ordon,ce with ASTM C646 unless otherwise noted or indicated. Provtde t)'pe "s• bLJgla heed screws far ottachment of woll board ta metal framing, ond type •s• plain heod screws for attachment of froming to door frames, Provide all incidentol and acc-essoiy materials, tools, and equipment. Use methods required for sotisfoctory completion of drywoll cOn$truction including access doors ond panel!. Apply continoJous beod of sea1lont at all joints of drywall abutting adjacent construction including orOi.lnd all fromed openings ond otl1er protn.,stOns through drywall. Pro'l'ide Polly-sulfide s~lanl Where unexposed, provide acoustical seo/ant. Api;,ly pfG-fi~ compoi.ind to jOint, in O~e¢rdOl'IU WiU\ ii'\d'\,'1.t'j st<iMQrd9. Apply embedding compoynd or,d rei1nforeing tope centered over joinl App!)' skim coot after toping ond embedding compound is dry. Apply sKond coot, fillif"lg, and tapering flush with surfoee. Provtde final finish thot is smooth, without divots, bumps, bows, or ony other surface blemish, and 1read)' ta receive point. Proposed New Project Woll Bose Install cove bose in bathrooms. See drawings. Provide pre-molded in$ide and outside corner:!. Job mitering shall be permitted upon owner approval. Use odhes,'ves only os recommended by th,s monufoct1.1rer of the material to which it is applied. CorefuUy inspect oil sur1aces to receive base prior ta lnstoliotlon. Repair damaged surfaces prior to instol!otion. Upon completion, immediately remove oll surplusi adhesive from adjacent surfoces in accc,rdonce with the timing re-::ammended by the maiiufoct1,.1rer, using mote-rials ttiot they recommend for thot purpose. Glas, and Glazing Provide glass os sp.ecified on drowings. NI exposed glass edges sholl be grol.md smoath and polished. Genero! gloss shall be q.J in occordance with federol specificotions 00-6-451 and FGMA glazing monuol. Gloss shall be req1.1ired for the sizes and conditions detailed in the drowings. Refer to elevations for fromes. Frames shall hove o factory opplied finish. See drawings for type orid cofO(, Provide resilient reopfene blocks 70 to 90 shore a durometer hardness and resilient accessories designe-d for positioning gloss in rabbits. Pro~ide clips of non-wrrosl..,·e metal with rounded edges designed for contact blocks, not gloss. Provide standard p.-eform~ glazing tope, stonlocke 400 or oppt"ove<J equol. Pro..-ide non-shrink elastomen'c tope where required. Use siricon Daw 1795 or GE silpruf, clear or approved equal, Use only if required by local building code!. OtlierNise, all interior storefrorit glass shall hlJ'VIJ: a 1 /4• vertical cteor space between gloss panels, All edges, drilled holes, and notches sh-:111 be factory cut and / or foctof)' formed. lnstoll in accordan,ce with FGMA recommendotiori:, unless noted otherwise. Verify that from.es to receive gl-:iting are sq1.1ore and true, that perimeter c:learonces ore sufficient to prevent point loadin9, and that sur1aces ore clean and dry, and ready to receive glazing materiols. Remove all proteetive coatings from frame surfaces. Center glass in rabbits and position os to maintain creorol'lces on oll sides, indoor,, and outdoors in accordance with F'GMA recommendations. Shim as require<J to position agoinst fixed stops and frame bars. Set oll extrusion:, in correct locotions. They shall be level, flush, square, plumb in alignment with other work. Upon completion, remove all excess sealont and materials from s:urface!I. Wash and cte<in all gloss ond gloss framing members. Toilet Actes,oriM General contractor shall provide the foHoNing: -toilet paper dispenser -sonitory nopkin dispos-ol -liquid sioop di:!lpenser eleetric hand drier or poper towel dispenser with waste receptacle handicop grab b-ors -mirrof Deliver inserts ond rwgh in frome<J to job site ot oppropriat, time. F'osten toilet accessories with all required mounting devices, fastening,, ond occe,ssories as required for a finished installotion. Properly package and tog fixtures for reody identiftc:otion. Fosten all item'J with screws or bolts extending at !ecst one inch into solid bocking if no otl",er fastening is specified. lnstaltotion of toilet accessories sholl bt11 in ocoordonce with drawin9s, reviewed shop drawings, and tMe monufacturer's instructions on.J recommendations. General contractor shall st.1pply and install odequote bocking for secwe installation of oil occes"Sories. Locations and heights sholl be as shown on drawings ond in accordance with ADA ordinances. Fire extinguisher shall be furnished by G.C. See drawings for locotion, Fira extinguishers shall be 10 pound capocity, with UL labels, enamel steel col'ltainer and pressure gouge fl)( class A. B, or C fires. Provide additional fire extinguishers as directed by fire marshal. GENERAL REQUIREMENTS CONL ALL NE.W CONSTRUCTION SHALL COMPLY WITH ALL APPLICABLE COOES AND STANDARDS TO INCLUDE ALL STATE IJ>.'NS, LOCAL ORDINANCES, UTILITY COMPANY REGUIJ>.TIONS, AND ALL APPLICABLE REQUIREMENTS or THE SOUTH fl.ORIDA BUILDING CODE, NATIONAL ELECTRIC CODE, OCCUPATIONAL SAFETY ANO HEALTH ACT (OSHA), FIRE PROTECTION ASSOCIATION, ETC. THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR ALL PERMITS AND APPROVALS REQUIRED BY THE GOVERNING BODIES HAYING JURISDICTION. THE GENERAL CONTRACTOR AND ALL SUBCONTRACTORS SHALL BE REQUIRED TO flELD CHECK AND VERIFY ALL EXISTING CO!-ICMTIONS AND DIMENSIONS AND SHALL BE RESPONSIBLE FDR THE COORDINATION or SAME. IF, AT ANY TIME DURING CONSTRUCTION, DISCREPANCIES ARE FOUND, THE CONTRACTOR MUST NOTIFY THE ARCHITECT. AFTER SIGNING OF THE CONTRACT, NO EXTRAS WI LL BE ALLOWED FOR CONDITIONS THAT WERE NOT BROUGHT TO THE ATTENTION OF THE ARCHITECT OR OWNER. IX( CHANGES MADE BY THE GENERAL CONTRACTOR WHICH DEVIATE FROM THE CO!-ISTRUCTION DOCUMENTS MUST BE REPORTED TO THE ARCHITECT OR ENGINEER OF RECORD. THE ARCHITECT DOES NOT HAVE CONTROL OR CHARGE or' AND SHALL NOT BE HELD RESPO!-ISIBLE FOR CONSTRUCTION MEANS, METHODS, TECHNIQUES, SEQUENCES AND PROCEDURES OR FOR SAfrn' PRECAUTIONS OR PROGRAMS IN CO!-INECTION WITH THE WORK. THE ARCHITECT IS NOT RESPONSIBLE FOR IBE ACTS OR OMISSIONS or THE GENERAL CONTRACTOR, SUBCONTRACTORS OR ),N-1 OTHER PERSONS PERFORMING ANY or THE WORK, OR FOR THE FAILURE OF ANY or THEM TO CARRY OUT WORK IN ACCORDANCE WITH THE CONTRACT DOCUMENTS. ALL DETAILS AND SECTIONS IN THE CONSTRUCTION DOCUMENTS ARE INTENDED TO BE TYPICAL ANO SHALL BE CONSTRUED TO APPLY TO ANY SIMILAR CONDITION ELSEWHERE ON THE PROJECT EXCEPT WHERE A DIFFERENT DETAIL OR NOTE IS INDICATED. IT IS THE INTENT or THE CONSTRUCTION DOCUMENTS TO PRODUCt: A COMPLETE AND FlNISHED PROJECT. >N( ITEt.A REQUlRED TO COMPLETE THE PROJECT NOT SPEClflCALLY INDICATED, BUT GENERALLY UNDERSTOOD TD BE REQUIRED TO COMPLETE THE PROJECT, SHALL BE PART or THE CONSTRUCTION DOCUMENTS. DO NOT SCALE THE DRAWINGS! THE CONTRACTOR SHALL VERIFY ALL DRAWING DIMENSIONS, SHOULD THERE BE ANY INCONSISTENCIES NOTIPI' THE ARCHITECT. CONTRACTOR SHALL OBTAIN THE IJ>.TEST SET or DRAWlNGS, INCLUDING ANY REVlSIONS, BEFORE STARTING THE JOB. South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida flNISH MATERIALS, COLORS, PATTERNS AND TEXTIJRES SHALL BE COORDINATED WITH OWNER. CONTRACTOR TO VERIFY ALL UTILITY LOCATIONS BEFORE COMMENCING THE JOB. CONTRACTOR TO PROVIDE PROPER PRECAUTIONS TO PROTECT ALL UNDERGROUND UTILITY LINES ANO EXISTING l,O,NOSCAPE(IF ANY IS PART or THIS PROJECT). CONTRACTOR TO BE RESPONSIBLE FOR ALL DAMAGE DURING CONSTRUCTION TO VEGETATION, SITE WORK AND UTILITY LINES. EACH SUBCONTRACTOR SHALL COORDINATE THEIR WORK WITH THE OTHER TRADES ON THE JOB SITE AND SHALL CLEAN UP THE SITE AT THE END OF EACH PHASE. ALL WOOD THAT COMES IN CONTACT WITH CONCRETE Sl,>LL BE PRESSURE TREATED. ALL EXPOSED WOOD SHALL BE SQUAAE EOOE SELECT. NE.W ROOF TRUSSES SHALL BE PRE-ENGINEERED ANO PRE-WMIFIICTURED BY A TRUSS COMPANY. THE CONTRACTOR WILL SUBMIT SHOP DRAWINGS TO THE ARCHITECT / ENGINEER FOR HIS APPROVAL. ALL METAL SHALL HAVE A GALVAl-nED FINISH. CONTRACTOR TO VERIFY ROUGH MASONRY OPENINGS WITH WINOOW MANUFACTURER PRIOR TD FRAMING OUT WINDOW OPENINGS. CORNER BEADS ANO CASING BEADS SHALL BE APPLIED TO ALL CORNERS AND EDGES TO PRODUCE STR.'JGHT & TRUE LINE CORNERS. PROVIDE CONTINUOUS BEAD or SEAL>l,T/CAULKING AROUND EXTERIOR/INTERIOR PERIMETERS OF ALL DOORS AND WINDOWS. NEW INTERIOR TOP OF SlAB ELEVATION HAS BEEN REFERRED TO 1-:5 +0' -o• (UNLESS OTHERWISE NOTED), AND SHALL MATCH EXISTING INTERIOR TOP or SlAB ELEVATION, IF ANY. CONTRACTOR SHALL VERIFY EXISTING FIELD CONDITIONS. ALL RAINWATER AND OTHER LIQUID WASTES SHALL BE DISPOSED UPON PREVlOUS GROUND WITHIN THE PROJECT'S PROPERTY ~MITS, AND SHALL NOT fl.OW DR CROSS ANY AOJOiNING PUBLIC PROPERTY. ALL PLUMBING fl)(TIJRES SHALL MEET rnE REQUIREMENTS SET FORTH IN TABLE 46-R2 or 11,E SOOTH FLORIDA BUILDING CODE, THE CONTRACTOR SHALL LEAVE TI,E SITE IN A CLEAN ORDERLY MANNER BY REMOYING ALL DEBRIS, ETC. AT THE END OF THE PROJECT. CONTRACTOR SHALL COORDINATE THE A(C DUCTWORK ROUTES THROUGH SlABS ANO WALLS. PROVIDE ACCURATE OPENINGS FOR OUTSIDE DIMENSIONS OF ALL DUCTWORK. GENERAL CONTRACTOR SHALL COORDINATE ALL FILL MATERSIL, ALL EXISTING ANO NEW GRADE ELEVATIONS ANO ALL GRADE SLOPES. ROOF SUBCONTRACTOR SHALL PR0"'1DE ALL FlJ\SHING, COUNTER FlJ\SHING, TRIM PIECES, ROOF -,0,T FlJ\SHING AND ALL OTHER ACCESSORIES. CONTRACTOR TO PR0"'1DE ALL REQUIRED TESTS AND PRODUCT DOCUMENTATION FOR CERTiflCATE or OCCUPANCY. ALL MATERW.S TO BE DELr.'ERED TO THE SITE IN ORIGINAL SEALED CONTAINERS BEARING ORIGINAL MANUFA.CTURES LABELS. CONTRACTOR SHALL BE RESPONSIBLE FOR NOT ENCROACHING EASEMENTS AND SETBACKS. ALL CONTRACTORS' WORK SHALL BE PERFORMED IN A FIRST CLASS WORKMANUKE MANNER, MATCHING ANO ALIGNING ALL SURFACES WHERE .IPPLICABLE TO N'FORD A FINISHED, NEAT APPEARN<CE. CONTRACTOR SHALL CLEAN ALL SURFACES FREE or ALL DIRT ANO REFVSE CAUSED BY DEBRIS FROM INSTALLATION TECHNIQUES OF THE TRADE. ALL ADJACENT SURFACES SHALL BE PROTECTED OR PATCHED ANO REPAIRED IN IBE CONDITION PRIOR TO IBE COMMENCEMWT or THE CONTRACTORS WORK. ALL GlASS, IJGHT FIXTURES, FINISH SURFACES AND HARDWARE SHALL BE THOROUGHLY CLEANED IN A MANNER ACCEPTABLE TO THE OWNER, ALL EGRESS WINDOWS TO COMPLY WITH NFPA 101 or THE SOUTH FLORIDA BUILDING CODE AS FOLLOWS: AN OUTSIDE WINDOW OR DOOR MUST BE OPERABLE FROM IBE INSIDE WITHOUT THE USE OF TOOLS AND PR0"'1DING A MINIMUM CLEAR OPENING OF NOT LESS THAN 20· WlDE AND 24" HIGH AND 5.7 SQ. FT. IN AREA. IBE BOTTOM or THE OPENING SHALL NOT BE MORE THAN 44• ABOVE THE flNISH Fl.OOR . THE MODE or OPERATION MUST NOT REQUIRE THE USE or A KEY, TOOL. SPECL'>L KNOWLEDGE OR EFFORT TD I.W(E AVAIIJ>.BLE THE REQUIRED CLEAR OPENING, AND NO PART or THE OPERATION MECIWIISM SHALL BE P\ACED HIGHER THAN 54• ABOVE THE FINISH fl.OOR. ALL DRYWALL TO BE 1 /2" GYPSUM BOARD. ALL TILE TO BE INSTALLED ON "GREENBOARD". ALL WET AREAS TO HAVE ·ouROROCK". CONTRACTOR TO PROYIDE COMPLETE INTERIOR AND/ OR EXTERIOR PAINTING INCLUDING STAINING OR PAINTING OF ALL DOORS AND FRAMES. A SEPARATE PERMIT AND PRODUCT CONTROL APPROVAL, WHEN APPLICABLE, MAY BE REQUIRED FOR ITEMS SUCH 1-:5, BUT NOT LIMITED TO, THE FOLLOWING: STR\JCTURAL GIJ>.ZING, WOOD TRUSSES , ODORS, ROOFING, AWNINGS, RIDGE YENTIIJ>.TION, WINDOWS, PRECAST SYSTEMS, HANDRAJLS. R.'JLINGS, Gu.SS WALLS, STORM SHUTTERS, & BRICK PAYERS. CONTRACTOR SHALL SUBMIT CUT $HEPS OR SHOP DRAWINGS FOB REYJEW BY THE ARCHITECT FOR Il:1E FOlLOWING ITEMS· -ALL PRE-CAST CONCRETE STRUCTURAL MEMBERS, AND PANELS -DECORATIVE PRE-CAST ELEMENTS -ALL EXTERIOR ALUMINUM STOREFRONT, GIJ>.ZING, AND DOORS -DECORATII/E ALUMINUM RAJLINGS, GRILLES, ETC. -AWNINGS -SIGNAGE -PAINT COLORS & ALL 00. flNISHES -ALL INTERIOR DOORS -ALL R.'JLINGS -PRECAST CONCRETE STi>JRS -ELEVATOR AND 1-:SSOCIATED EQUIPMENT -A/C UNITS ANO GRILLES -LIGHTING -ELECTRICAL PANELS ISSUED: 3-19-07 date May 26, 2006 sheet title revision GENERAL NOTES project number dr-•wn by D.M. Scale: /' -s-;-h_e_e_t--.,-------n1...--,--1-A~ nu m b e r ) t,,',. '" , 1 u.l, • ,} v;, of,>, • ,:;:_-4, r>. .. 44 of 162 52 a• t • 2' CONC CAP "IEINF WI~ 11-5 :;ct,, 1' ii, J/.3 @f>" Ce. a· CMU WALL Kt.Jl>.IF 1wi1 115@ 32" 0/C VERT. IN FIL;_EC Cfl LAND 9 GA LAlJ':JER TYPE -IOF'!:Z. JOit,, T KEINF@ 16" 0 C. STUCCO FiNISH ---- BOT"i SIDES PAIIH TO MA-CH EXIST. PERIMi:TE.~ WALL PR0\1'01". B' )( 16" Of>E.Nl',GS :s i S!OE) @EA.CH3W/\I..LS 1/'J" JQlt,,T FILLER, SEALER 4• co~c. $L.\a R!:INF J w, ~F oc :O'.TT' E ~ --- ~. ~:~~~: VAPCR B.AMIE.:... CONT REJNF CONC. WAl.w FOOTl:--1'3 ~ E WALL SECTION @ SCALE·. 1/2" = 1 '-0" "' :t 5' "' N -- 4•. CONC FILLED 80\.LNt) -l ,.,. l l l F BOLLARD ~-SCALE:112'=1'-0" 8' •• • • 8' C.NI.U WALL CONC. SLAB 8'x20' lHASH - COMPACTOR ~ • BOLLA.qo 0 I i &, I _, N I "' ~-t--t------~ , I : :r I 'gi ~, L "'' I ~I I -r-~...,.__~, Ill ti ~J ' ----------- ~ ::, 0 01 .c -00 LI) ~I 1 I -f- 2a1'-5o/.e 280'-1" 128'-1" 23'-0" " i~ ,. '" ~ 0 ' ' ' u:sr OAK TREES (7) + 4• DIA. 1 RUNK q' ---;-__ ;_,'-O'SPR_= __ -'(-·''--,,OCCUPATIONAL" <t. S.W. 73rd STREET ---¼------+---+ ~=-=-==================r~============================================:J!!!jllllllJ~ \ I 25•.o" ' 1·~½· // ----------------------------------- _,_ ______ ,!'-------- N "SITEPLAN PLEASE SEE SHEET A-2 FOR FIRST (GROUND) LEVEL PLAN 28'·0" 27'--4" BOLLARD E STEEL GATES ' -1 • • •I ·-• ,. • • WHEEL STOP w " n ~ w ,_ r 3 SLOPE -118"=1' 4'-0" 5'-6~ l 9'-0" 1 ' • "' ' N WHEEL STOP w • ~ 'i' ~ "' if) -w c I 3 SLO ENOTTO - EXC ED 2% IN ALL iRECT ONS SEE DETAIL 'A' -1l,_ l 1 l 5'-0" l 12'-0" MIN, ~ ~l ~7,---- 13•-0· MAX. SCALE: 1" = 20'-0" ' w w f ~ ~ ~ ~ ~ ~ ~ 4" 6" 6' 4" DETAIL "A" "- STRIPE DETAIL N.T.S. NOTE: ALL PAVEMENT MARK.~GS SHALL BE PAiNTED IN WHI l E. --o~ ?Osnor-, SHALL I !AVE~-REFLE:";"'TV': BLlE BACKGROU~O WITH W'•IT! REFLEC-1V'I! S Y1"80_ A:\10 EIOR'J.f.R. F'-'J'!kl~Q BY 0ISAalEO PERMIT O~LY !. TOW-A'/IAY ZO~E 1,o··oMr'U-!TOl<i SHA.LL HAVEi\. KER.l:.c· 'YE «-,1-E BACKGROUND WITH BLACK CPAQI.IE LEOE.IIO 8. BO;wCR. -"" F'NE IJII TO 1250 00 PLEASE ',OTE ALL 9UILD,N<J,g SHALL HAV'E PRE-CONSl R.JCTON TREATMENT PROTECT10N A.GA.NS~ SUBTfR'¼NEAN rER.M--ESA-5 Prn · a1111.1, A C<a!nFICA TE OF COMP·JA'-ICE Sf-ALL BE ISSUE'.J-O Tt-,E 9UILDll',G DEPMT'~1ENT BY THE -ICENSEC PEST :::oNnOL COIIPMYTHAT c,:~•rAiNS THE FOLLOWNG s~A1D,IENT: '""."HE 8JILCING HAS RECEIVEl) A COMPLE: E TREATMU-.T FOR THE PREVE:!>-1-ION JI= suB-ERRA."JEA~ TERM1-e:s. IHEXM:C~f 1-S IN ACCORDA.1',CE 'Nlf:"1 TJ-,E "IULES AND LAl'VS ES",',BUSrE□ BY n:E FLORl!JA DEPA.~7.-iE!\ T QI= AGR.CUL i.JREA".ID CONSlilv<ER SERVICES' L ,. . • • • • • • ®TYPICAL PARKING SPAC~.r.s. ®HANDICAP PARKING SPAC~rs . @HANDICAP SIGNS & DETAILS N.T.S. 0 TRASH ENCLOSURE ® SCALE: 1/4" = 1'-0" BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305•444 4433 fax 305-444-0181 EMAll: bdamlamlObellsouth.net Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida VERIFY OPENING WI TRASH COMP. MAI\JUF. WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project date May 26, 2006 revision South Miami Municipal Parking Facility S.W, 73rd Street & 58th Avenue, South Miami, Florida -·~-------=---..-~;-=--i'-~ ... ~ • • • • • • • • • ~ . . ~ , SI TE DATA ZONING: SR -(SPECIAL Rfl Ail) -- TOTAL LOT AREA 43540 sqrt (0.9995 acres) --· TOTAL BUILDING AREA 163,647 sqft --1ST LEVEL RETAIL 27,687 sqft 1 ST LEVEL PARKING (COVERED) 4,741sqft 2ND LEVEL PARKING (COVERED) 30,739 sqft 3RD LEVEL PARKING (COVERED) 35,236 sqft 4TH LEVEL PARKING (COVERED) 35,236 sqft 5TH LEVEL PARKING (ROOF) 30,008 sqrt ALLOWED PROVIDED MAX. FAR. 1,60 0.64 MAX BUILD NG HEIGHT 4 STORIES -56' 4 STORIES -55'-3" LOT COVERAGE 90% 83% REQUIRED PROVIDED MIN. SETBACKS FRONT O' FRONT O' REAR 10' REAR 14'-2" SIDE O' SIDE O' TOTAL PARKING PROVIDED 435 1ST LEVEL PARKING 17 2ND LEVEL PARKING 122 3RD LEVEL PARKING 105 4TH LEVEL PARKING 104 5TH LEVEL PARKING (ROOF) 87 H.C. SPACES INCLUDED 9 LEGAL DESCRIPTION: LEGAL DESCRIPTION: Lot 35, and the North 11 2/3 feet of Lo136, and all of Lots 48, 49 and 50, of WA LARKINS SUBDIVISION, according to the Plat thereof, as recorded in Plat Book 3 at Page 198 of the Public Records of Dade County, Florida. TOGETHER WITH: Loi 36, LESS the North 11 2/3 feet and LESS the West 5 feet and Lo137, LESS the Sou'.h 10 feet and the West 5 fee1, of WA LARKINS SUBDIVISION, according to 1he Plat thereof, as rBCorded in Plat Book 3 at Page 198 of the Public Records of Dade County, Florida. SW70t'1 Slreet - -ED LOCATION SKETCH N.T.S. LEGEND SYMBOL DESCRIPTION SYMBOL DESCRIPTION ~---PROPERTY LINE OBJECTS -----OVERHEAD -4-----CENTER Ll~E ----------OBJECTS HIDDEN //// RETAIL AREA/ --- - EASEMENT MAINT. \,' GREEN AREA C.M.U. WALLS '\,~ SITE ELEVATION ·' FT. ABOVE SEA LEVEL ~5E..-"11CM Qt:SIGM110N == SHEET ,OC.t.llN ISSUED: 3-19-0 sheet title SITE PLAN project number drawn by D.M. Sc a I e: sheet 45 of 162 53 I l I I • l , l 1 i i '! • • I I I I I I ~I §I A )----+-,---+ I I~ ,@---h \ f-I l:'. :i ') ) ' ) ) I FACE o:: - COL. E "'~fiR:;;~ I I ~'<----++~1 I I r 6x20 TRAS! COMPACTOR SE:E SHEEl 1 0 . .. 12' C.M.U. r ~2.t-+t=---------R-E-T~1-,L~~~··4~---------~----+---___:"M~·~~---l-------"_+L-ff,~~,__,._,.,,,,~-~-~-~.~.~ .. ·-:-'--'- '--I I L,JTURECONC.StAB7 RETAIL 7 ~,.--~+ ~ r-'. 1375 sqft an,NANT(TYP.) ~ 1097 sqft ,MAINTENANC I ,t;f-,>-t-.tt+I -r'~,Htt_-. i-------+----------~1-----+------_,J STORAGE AR'-"'J" ~ I! <sJI -I , I I ' I ! t-----1-rNL- TD Wl/,,IETALG SEE PLUMB. D •O' C ,c SCI WAC. FURRO..T FdR. .. ;., ~ .. -:..;..;.......a.,.._. 24".:24" INT. c:o-.c COL. ~TYP) .. . . ,. . . .. •, • . . .. { ~11", . . .. • t, • / .. / .. 0 ,1 • .. . ., :i!J'--0" L,sPHAL T "' crv,/ • • ., •, ... • I ' CO,VERED PARKIN<'.3 A . .. . . ',. E"A . . . .. ! q ' "I ! • . .. 5• • • -----:--- 0 12" '.J.M U. -.. I,·~ •. EI ECT. . , •, . . . . UMP . '. . ' " .. •" . . . . .. . " '1 ., . 0 . . VE. lfY F,'\IAL .OCA ,.,a~ '/YI Wl'tER 'AA-1::!1' lol.U. • rt•e,i ~ ALLS., _._. e ~-. . . ' .. ·:· i : : . . I: 1· ' I , •, .. . . •, I CON~SLA.8 ON GAACE IN~•-'PEREMl!.TER A.R.0 1 1'.0 TENANT SPACE . COO IM'1:.W/OWl'IE.~ (SEE TR\JCT.) I SEC. CT 7'131 .,(FUTURE co~c. sv,.a7 BY TENN-. T (TYP.) . . : I 1!1----------'-'-'·1_1_' ----~ t---,-+-----------------'-'_'-5_' ,_ __ -+-----------l-·~·~· :-·~',.·--+'-'-'-O_· ___ I, ------_ , •' ~ 47' o· C ·I-' -• • I 1.28 - ; . '~ ~ ;Ii· T -LITSTEIN DESIGN f , ~;.,,__,__,_ \ S S O C I A T E S LLLL-.L.-LL-~~,~-R0007570 ARCHITECTUREINTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdaniam!Obuth.net L lYS 28"1.28" EX 1 CO'-IC. CORNER ~--,o, 24"x28' EXJ COt.C. COL \lYP) __ _ IMPACT "l:E:J STOOlf~i'iT 7 I I ~ flRE EXTlt-.GUISI-IERS It-. WALL MOUNTED CA31NET. \10U'ff ClPER.AT!NG MECHAN:SM 48' AFF MN( Client: SY~!lOl - &I@ Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida I RESTAU!NT 1 4761 Sqft I 79'-4' L S,M PRE-Ct.ST CONC, PAr-..EL "OCCUPATIONAL" DESCRJFT!()"II SYMBOL DlcSO!PT!C~ (.:(J .. (;IU.TE (~Ei PRE·CAS-OONC-~E-E ~n!LX::TLIIV,!.) [SCI; STRI.IC"1Jfl,A,..) .N~R PA.R-'T!CJl'i CMU 'NAl,S w=• WA,.L Mt.iJ FIRE EX.INGU1st<ER WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 T-0" -'t: LEGEND S...-\.!BOl [l!"SCRlP-!l'.l"II h SWING :,OOR ----- . . ' ... SYl.'GOL e -- 0 LurnRECONC BY TEl'WIIT 1n CC!'>IC. SLAB Oi'i GRADE ,N 5'·0" t'lRE:.MHER AROUND TE~'<' S?ACE OOOROII\ATE ,/YI OWNER. (S€E S"Rl,JCT I ·, . ' .) LAB7 .. RESTAURANT 2 5822 sqft 95'-4" . . ' S.W. 73rd STREET NOTE: SEE STRUCTURAL DRAWINGS FOR SIZING AND DESCRlf'T>CN SY'ltaol. J[SCR.P-'OS TYPE OF ALL STRUCTURAL ELEMENTS :JQQ.R r-lU!.BlaR -------C6JECT9 r100E.N "iOTE, ALL FUTURE TENANTS ARE TO SUBMI f rHEIR. OWN SE.PAHA 1 E " JSJEC:-CS OVERl-<E:AC ,. CONCR~ TE 9tAa ?LANS FOR SEPAP.A:E PERMITTING OF THEIR OWN RESPECTIVE TE.~'-H SPACES. STORE.FRONT PA.-.EL, WINDOW ::£S G,M.T>Q~ Proposed New Project .. . .. . . . t . . ..• . .· .. . ' N ED FIRST LEVEL South Miami Municipal Parking Facility S,W, 73rd Street & 58th Avenue, South Miami, Florida I RESTAURA~T 3 6740 sqft I 60'-0' .. .. ~ . '.• " . : .. . ., .. .. . . .. : ... . . }_f --+-~ ,· 1S"' COI\IC, SHEAR WA~~ ... ..,_ '. . . •' , ,L < . . . ' ,, .. -.- ·1 r ' 'a STAIR:• ' RETAIL 6 ~ 878 sqft FUTURE CONG. SlAB ---:f BY TENANT (TYP.) / I RETAIL b 1021 sqft I RETAIL~ 739 sqfl 1 RETAIL~ 704 sqft 1 / ELEV2 IMPACT RES. STOREfRO"T SIM 1/2" ,., . I Lu"".'UR.=:: coNc sLAB7 BY TENA'<T tTYP) RETAI 1 1041 ;rft ~ 22-0· M RETAIL 2 1041 sqft TY? SCALE: 3132" • 1'-0" date May 26, 2006 revision January 24, 2007 March 1 , 2007 sheet title 1st LEVEL project number l+--+---lt--t--FACE OF 7_, ---l---~--:_J COL. ~ ~'H.1--------1-''s------ 1'-1-i.l". r 1 ~ 1n • • . .. JI I ;· ! .. ' 4' ~?.',' . -' . +;,;:.>,"";, :"'.;•;:.. •;;_,~~~~/•l-l---l---•~ •-_._ rr-:.,··· . ' i • I I I •' 11h> : .i I r : . f. I -,""{"'J~?~/·~r'.••,,-..r-~• \ -'( ' ,.-, 5' I I-::;-;~ • .. r ~';'f[l,.f: .>,~ i .I, K ·roJ' ' 9 ' I -(; --.;.'.} ? ~ :f~ • ··J ",:,, ~I;~/ .. ,11. i • I I ~ I ! ~t--- _ _j " w :::) z W1 ~ I r March 22, 2007 drawn by D.M. OW"-IER REV ' . ~I 46 of 162 54 <! 'i J i 2--1-~· --- I I ' lHII I ) ©t-- ··1t--~, '·, I -r- @) r-1--------~'----------➔-----=C>-----+-- ---- ---- ----:---- ---- ---- - r I I I I I I : )'.--(' I -~ ............... I I '' L ·-.. ...., I 'I ..... ' ..... !if:; ' ' / AAIJIP :J? 5 5% ' I : I ( 0 I HORJZ. DIST' 30'-0" I ,'.; ---'> iZ-~ 0 I I \ \ \ \ \ \ \ S;>ED ~p UP TC PAAKl"IG \ I 95'-4' HORIZ. ),STANCE@ 10.1 % 0 0 0 \ \ \ II II II II II II II II lil II II II II II II 0 0 -~ l __/ [ <'Ji! ·'--'-'-,f..)'-·-·-·-·-fl ' -~~!]·-' ' I ~l=J=====/1 ' 11 ,, ' ' ' ' ' ' \ ' ' ' ' ' I ! ' 11 : I I --------------:----------+------T✓--➔----------i-.-------, I I \!. 1 I I I I I I I I I I I I ~~ I I I ' I I I I I I I I I / I / I I I I ·1 ' ~~ I '+ !'-I I l I .LJ r1===========±=======t=m-' I ~! ----------____ ,.._ I N I I I I I I I I I I / /i 1!}1 I I I I I I (D FIRST LEVEL Lire SAPETY I I I I I I I I I • I I SCALE: 3132" = 1 '-0" I I I I I I I I I I I I I I I I I I I I I I I I I I =_J~--tt- I --r ISSUED: 3-'19-07,i ~========B:::Ll:::T:::ST:::E:::l:::N==D:::E:::S:::IG:::N=====================;,_;;_--------------.;,.;;,:..;.:_,,;;.;.P;.;.r;.;.o;.;.p.;;,;,o;.;.s;.;.e;.;.d.;;,;,;.;.N_e_w_..;P_,..ro;.;.j_e_c_t ______ ~===========;;..;;;..;.;._-'=========d;;;;;a:::te=M:::a:::y:::26:::·:::2:::00:::6=~===!:::h:::e:::e:::t:::t:::lt:::l:::e========S:::c:::al:::e:::: :::3/3:::2:::"=:::1:::'-o:::•:L:::~;=-:~;;;;.~'fFf."':::f''1'(. ( Ass O CI ATE s revision 1st LEVEL -!h:-e_e_t_n_u_m..,.b-e,¥,;-,.c-~~d0 ARaaa?s?a South Miami Municipal Parking Facility LIFE sAFErv PLAN A.:: . ~ ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305-444-4433 fax 305-444-0181 E"-WL: bdamlamlobellsouthnet S.W. 73rd Street & 58th Avenue, South Miami, Florida project number drawn by D.M, Jr ' 47 of 162 55 I "' tl L E G E N D SYMBOL DE:SCR!PT10N -CCM;RJITf :sEE n!SUCT\l~ I I I I I I I I II CMl,,\O/ALL9 Pf<E Ci\ijT ::Ot.c:f£"'!l !8Ef $1RUC-l.fl,"-1 ,..-n;n,°"' o.,,.-r·;·ar, #~c.i- I\ SW'SG JOU< ~<;J==~W" e ---- ------- • .. DO,""'UNBcR 0!1.E'CT5 O..,,...UJ> Ol'UECTS tilDOC~ . ,. CO'fCRETI. alL.>.B - BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 265 Sevilla Avenue Coral Gables, Fl 33134 305 4 4 4 4 433 fax 305-444-0161 EMAIi; bdamlamlobellsouth.net q ~ ,cp ~------5r er 280'-1" p cp ~ --------r--- I I 1 I l:l _ , 7'-0" 1--26'-0" r 35'-0" 36'-0' 36'--0' I 24'--0" ----------t---36'-0" I --. ------·~--------,~-------=-=:__ ________ ,_ ______ _ I r 26'--0" I I --~ 228' 4" -~,---i--29' o· 18'--0" I:,' 14'-6" 112-0" ,_ __ 1_2•._o· __ ~,,_ ___ ._s•_.o· ____ ,~_a_·-<i_· -·,--.~:'_'_'-O"~~~:-rc_l ,_ I s•-a· r-o· TIP S'-6" _ r-~-4'--0" ~1~ 'ii 18'-0" 7'-0" ----;---,<---------'-+-----,I-- IZ-0" 6'-0' 12'·0" 1Z-O" 5'--0" I 1z--0· 12'--0" 18"--0' b ., '" - 9 ~ " ~ I I q ~ N ~ I !;,. i.-1" "----- ~ ~ '"'" '"' ,.,.,. ""'. i . I ....... ·• ., l ' ' -' ' _ .. _. c ' -· ' ~·--0; :. : .:-. J='.~~ ... w~.1.4" ........ ,. ,{ I ·~ , . • ·t t? E ij'):t -i, 24';i:;~41:1NJ •. CONC. CO~ t1YP} .[].__ /\ . :r v~ 4t--. "" ::,..$'4'( ·stA:'.'JO:ir.:: i:::~Ptt:~~~~tt-t 89~(2} ~ 4 • N ALUM. ORJU . .e (lY ) :ii~~~a~ it<!; (:;ON. Wt,., \TYP) 12'--0" CD SECOND LEVEL Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 E I 12'-0" r STR.fNO ll'YP} 9'-0"Tl'P '2'-0' .'i/WEPd'J r --1 I I ' ~"' ~~~ u:@4"0C . O,t_a~_.,WJ1$Jn9:~a~,,,...-11',S.~◊f 1!;1$$ thads.r~ prpytqo,_a ~i)):~srsJAOt fioftih;do$Gf'iboc:fa:S° a ,n·~rum aalted:fin~. i Oil ait' SIJrfaceiwhh a' sf greater than 6%, p(-ovide a $lip- re'6fstaiit finish. ilO.O.ot~ -P~F fu ht'J % I· , . ' 0 EN I l I f I 4'-D" TYP - -{- --------e--i---------- .i1·•.•.··········:•.··ii•.····' ... ·• .. ' . ' . 10" ME.-GA,$r Lltf-All .. -.-,--,-.. -- 100'-0" I 11~-<l-. ~~~~. .. . . . .. . .... ·. . . . .. I ! I ! I e.AR#.1i:RtABlt @· ••·o:c. t re. 4T NF fot.t..ow ~.t.Qi:>e: j)f Rfl,\1PJ}USS10e= r ! I ! I ! I PROVIDE WATE.R TIGHT -.....,_~~'-'--iMii,M!lAANE 11-1)$ (i:V'1~ ~""+----- ONLY, 12'-0" ---'-'_--O" ___ i-~'-'"-· _,_ ,.: ____ 18_·~--____ t_f __:IY_,;e_~_-~:_~_o"_'/_, ___ ,,_,"_· --l----"·_--o~ _____ ,,. --___ _!_2'_:?~_ NOTE: AREA W/ WATER I l TGl•TME.J..!SRANE. ~-~~ SCALE: 3132" = 1'-0" SEE STRUCTURAL DRAWINGS FOR SIZING AND TYPE OF ALL STRUCTURAL ELEMENTS Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida 5'--6" ELEV 2 ®-;:;~~·. I • \__ ECH R I:. 7'-4~ 2· ,. .. '' , .. ' ~ ,/ / ' 24'-3" ~ ,r . "· -: ◊ -if--,,F~~ ~-~ ., . , __ i, . I . ·.•· 1ifcciflc SH<AAWAU. cl ~ l 1 r $E-E /o;lf:;CH. OWGS , · f .-. FO:RTiifSAREA ,..../ I I 2·-0~ e·-o· TYP ,·~t -6'--0" ,2:--0· 12'-0' 12' -0" ~ ______ ,_ ___ ,._·.8)\_· __ J --18'-0' 4 • ------..-:. I E q ~ N -9 -"' I ~-... t.__ ~ ~ ,r ;..._._. ------~ . ' -----~--- ISSUED: 3- date May 26, 2006 revision & January 24, 2007 ffi February 13, 2007 sheet title 2nd LEVEL project number drawn by D.M. sheet numb(/ ,. W ··.1 ,-. A~,, 48 of 162 56 ®--- L EG E ND SYv13QI.. DESCRIPTIC"--DCN<,RlTI (ll<_: sm_,;;-,,,-, CM 'J '"""-LS 'RE-;JI~• OOM;ISF~ :SEE r'llJCn;FW.) ~-noo". ,,1,'tTrr,:;N 'MJ..1.3 r"'\ SWlNG x,;J~ IFEEl I ---➔ '"'™ OF S<;;RESI ----OB,~CTS ~ -------nBJEC-S ,moc~ ©----- OCCUPANCY OCCUPANT MAX TRAVEL DISTANCE GROUP LOAD SPRINKLERED UNSPRINKLERED GROUP M 30 sqft:/ person 200 ft 100 f'i PARKING GAAAGE 200 sqft/ pe•soo 400 fl 300ft ONE HOUR SEPARATION REQUIRED 8ElWEEN OCCt..:PANCIES Ml~ AILE WIDTH= 44 in. MIN QPEN1NG = 32 in. MIN STAIR WlDTH =44 in. BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305·444 4433 fax 305-444-0181 EMAIL: bdamlamlObellsouthnet cp I I I I I 1 I L----(-- r 1 r l A. I MAX EGRESS WIDTH I PERSON DEAD-END LEVEL STAIR 20~ 0.2 in. 0.3 in, 50 • 0,2 iri. 0.3in. 258'-6" ---------~, <~ --------------------AAMP UP TO LEVEL l iH~E 5. 7 ¾ .........._ _ 00-------------- N CD SECOND LEVEL LIPE SAPETY SCALE: 3132" • 1 '-0" Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida ~ I /'\ :[-// ?-i F -i . /LA .T IJ I -LL_ L____,,c___L__L_~ : I j I I ~ I • = = ISSUED: 3-19- date May 26, 2006 sheet title S c a I e : 3132" = 1 '-0" • ··• <: t-. revision 2nd LEVEL LIFE SAFETY PLAN project number drawn by D.M. 49 of 162 57 A'f---W--=~==---~~-~~ ~t -:-~ I ! ~ ~ ~ ~ 's-" j "<--- l 2e·-o• 5•-e· '· :1·--0· t--- 1 B'-0' '1 25'-0" -..- cp I 35' .o· I -~ I 4'-6" r--12·-o· 12'-0" 4'-8" , ' I I ' ___:___,__-.:. I 9' O" TYP ~ 280'-1" 36'--0" 36'-0' 36'--0" ,_ ______ _ I I ~220'-4' ~ -t---_ I 18'-0" I 5'-6" 7'-0" TYP 5'--6" ,-, ' ___ ,_ 1'-6" 4'-0" 1'--6" ,f-~>-,t- 11 I I I l- 8'-0" 12'-0" 12'-0" 3'-,J" >'-'---------,_ ___ ,____________ ____ , .. ---'-,------>---{ b· a-o· TYP ff f I I . 1a·-o· I r-o· 12'--0" ~ ---,---r----~r I !ll!l"A!l!l ' 1== 100'-0' 12·-0· 5'-0" I _,____ 12'-Q' 12'--0" I I ' S-0" 23'-0" 26'-Q' ~ ? -~-0~· t~ I I ~ --+~---'-~ N-0" ),"t ,., .,,. ~-----~~'------~·~ -j"-:;-® rf •.•• · 1111 EL i-:i.7'-9" T\-IIRD LEVEL 9'-0" . p--~ I / ELEV 2 - - . J ' -----·--·- 1 12'-0" ~:~~~~t:~ I 25'-0" -'T c::c, EXCi::E02% ~~ V r ~ ~ ~ D ~ n q ,, RAM? UP TO LEVEL FOUR 5 7},, ®--- - - - ------- - - ------__J_ - - - - - - - - - - - - _ __J ______ _ RAMP ~N ~.T'A, , -4--~,-------------L____------f---1----------- L E G E N D SYMBCL DESCRIPTION -CO'tCRlT'E \SE:1' s-ru,:,LRAL) I I I I I I I I 11 CIIL W/IJ.lS ~Hl:.e,<,ST~M;RE"'la :Sl.t 9,Tl\JCl',P,1,LJ ' I ':."TLIUO~ rART"TIC"I '1/l'J..U I\ S"'1N~ :n:::1R $=:SEClll:N oc:.cr.o.,~ -~ --· e ---- ------- . ,. XlCfl; WMl!E~ OM:CT1 :)V~u,.i 06.;lcVS~IOOD Xl!.<;'1r'l~ BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlamlObellsouthnet "' ~ ~ 'I ·---" . ' i I • I ~. I :---....--- ~ ·~· ,_ Client: ~ lg'-0• 1'-6" 6'-10" f~R~ OUT FOR REC. LT_ BOXES (3) ---,-,--18" CONG. Sr'EARW.b,LL 1'-t 18'-0" .2B"x2S" EXT. CONC CORNER COL. PRE-C>.ST PANEL PRE-CAST 18'-0" N I I I I I I __ 13'-Bh' 25'--0" 2'1")(26' EXT. CONC. COL (TYP) CD TI-IIRD LEVEL WITH Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Miami, Florida I 12·-0· i 111 ,a• PRE-C~ST uns-WiL STRlf'l'-13 (TYP) ~! __ I ~ RRICRCABLE@4' 1 C I 42' AFF FOLLOW SPoPE RAMP THIS SIDE I== I~;== o~ all walking surfaces ·it, a slope of less than 5 ¾ prov-de a slip res>s'.ant f isti, described as a medium salted fi,;ish On all surfaces with a sl a greater than 6 ¾, pmvice a sl;p 190,_0• ~ ----•-re-si~fr,is,tic.--~--------+----1----c----------· -----,---,------,;-0 --------------c------ Do not allcw any cross s\opes to exceed 1/4" per foot o, 2 %. 9'-0" TYP l 12'-0" 12·-o~ l ' SCALE: 3/32" = 1'-0" -\_ ~RE!G.'ST EVSBROW WI DECORATIVE AA!l1'-jG 12'--0° 18'..Q" •. 0'-6" NOTE: SEE STRUCTURAL DRAWINGS FOR SIZING AND TYPE OF ALL STRUCTURAL ELEMENTS Proposed New Project 12'-C" ,_ __ - 12'-0'" I ,r I 12'-0" South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida '2'-0" ~I V/ ~- / date May 26, 2006 revision ffi January 24, 2007 ffi February 13, 2007 -··-~ ~I sheet title 3rd LEVEL project number drawn by D.M. I 9 -==-'t:.:~t 5' ~ . ~ --~ .... --.,..-.'I,--'\ -o· ~~l ~1 ,_ I I - j q ~ t '1 ' ISSUED: 3-19-7 Scale: she et 50 of 162 58 L E SYM80l - I I I I I I I I 11 I\ !FEET I --➔ ---- ------- ®--- ®------- G E N D DESCRJPTIO"i OOW.l<L "E. \SL~ S =iu...,.,_; C-~-J 'l'/A..._S ~ .... .U.S. ="'.El""E \31:E ~HUC"JAAl.: INTcr'-.K:R rAR•'llO!, ~A!..S 3WIMO DC<;;/1 e,._r~ :;ll' CG"ESS O;J1aCTS C','t.R'(..1,:1 C!!JECl$ -ICCEN ©--- BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlamlObellsouth.net I I I I 1-· I ~ '-- 1 '~~ ® I cp ; : n 'L /Ji=:::'\. (Q'v , j .' ,,; . \ ' ! A I (, ,/ I .,, / I //, y' 1-_J m- I I .. ~ ~ -------------⇒-<-- - - - - - - - - + --'~~-- - - - - - - - - + -<-- - - - ~-- - ~ - - - -~ +-- - - ->-- - - - - - - - - - - - +-- - - - - - - - - - - +---~-->-----------------~ I '~ --t ~ ~- I ~ I : I ~s--- 1 ' I '✓ I ==I=,;=,,,, =-t ---=---s I I 1-== N CD TliIRD LEVEL LIPE SAPETY SCALE: 3132" = 1'-0" Proposed New Project date May 26, 2006 sheet title revision 3rd LEVEL South Miami Municipal Parking Facility LIFE SAFETY PLAN project number S.W. 73rd Street & 58th Avenue, South Miami, Florida drawn by D.M. '½ -~· ,, • , ,I , , I 9 , // ! ' I ' . I --- ISSUED: 3-·19-01 Sc a I e: 3132" ~ 1•-of;· , ," 51 of 162 59 iHlf Ii I ~ ~ ~- ' L E G E N D SYMBOl DESCRIPTION -00....:r.:ETI '.5C"E ~T~uCTU""'--:• I I I I I I I I 11 C.!<W. ,\'/•.US .. ~RE-U..ST CCNCAEE \SEESC~:CTJRAL) ~ I N ~ IN CR!l:Rl'""ll,1U~WA!..LS I~ 5Wl~GDXJR I I MtellON$=.SEJ:OOkll£S>.'IIITION ,= """" I e ---- ------- . ~~U'!tltl< 08.<tCrS 'JVU>J-<l.AD ce.Ecat -,oci.~ . .. CONCRE-E ~IAS BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, fl 33134 305 444 4433 fax 305 444 0181 EMAIi; bdamlamlObellsouth.net 9 ~. b °' 9 i;l · T Cf er 280'-1' er cp __ t_ ~ ---------- I I I I 26'-0" I 35 1 -0• 36'--C" 36'-0" 36'-0" I 24'0" ' 23'-0" I ·--r ELEV 2 i------__ ..,..___,,_ <== "5' I / ,,,.,. I (..L wo· ZNOSLCPETO~I <CJu0 . JI'' EXCEED~¾ ~ 9, \.,; ~ I 9,.______.__ .... ~t= ~ 9 ~L f--------'- _ __[ ______ _ \ , RAMP DN 5.7¾ • -+---------------1---------il--. --------- ~ N -1 ' 5' ,._,.,,__ • I 5' N ' I 1'-6~ 6'-10" ~ V"' r-~F STATIO~ . "' ~l~l= r ,J f t 18' o· r ~ ll ~ 2il"K28" EXT. CONC. l CORNERCOl 9 ~ 5' ~ ;. PRE:-cAST SPANDR£L -BEA'III ":"O 3'·8' A60VE DECK 9 ' .,...__._. I ·1· ---18'-0' J N f 24'-0" 24'K24' INT CONC COL (TW) FURR OUTfCR c{i:C. LT. BOXES (3) ~H--18'CONC. SHE.AR WAL- f '_J r L BARRIER ABLE@4' 0 C TO 42" AF I Or a!I walking surfaces wil'i a sl~pe ol less t"'a1 5 % provide a slip re.sistant finisf\ de➔cnbed as a Tredium sailed finish. On _all surfaces ...vit:i a slope gre er than 6%, pro'i'ide 3. slip i 10"i"RH~ST UTE WA:- ! 25'·0" res1sta1t finish, ·~ ~-~-~---+----t-----------c--~ Do not allow a~y cr::iss slopes tolexceed 114• ;)er foot or 2 % ALUM. GRILLE (lYli'l I , 24•~2sM Ex-r. coN I coL _ I (lYP) 1 r .d 12'-0" 12'..f.Y' 12·-0· = - 12' -0· 1 B' -0" -~I PRJ-CAST EYEBROV-. WI DE,10RATIVE RALNG i 10' -6' r 190'-0' - 12'-0" 12'-0" 12•-0· 12' -0" I I ,_ ______ ,__ ____ ,_ ____ ,__ ____ ,-____ ,_ ___________ ,~-------,f-----·-------,-----,,__ ____ ,__ ___ _ 280'-2" ED FOURTI-I LEVEL SCALE: 3132' = 1'-0" NOTE: SEE STRUCTURAL DRAWlr-..GS FOR SIZING ANO TYPE OF ALL STRUCTURAL ELEMENTS Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida r .- I I b I -6t 4'-0" ~'-6" ,-.-;-~ 5'-6" 7'--0' TYP 5'-6' I i 10' --6' 1B'·O' I ,-, 6'-0' I ' PRE;CAST SP~DREL BEAM rn l'·B' 1\30\IE DECK /- L 25'-0" ___________ ,__ __________ ~ I 12•-0• 12'-C" iJ = ;r u j ·. 8'-0" ~ ··-J G , Iii I J I ---i--,.. ' '.'I " '.9,._ I ---~,.. ' ' 9 --0" ill I • ~---~-~ ~ ,, ~ t 5' N - ~r 5' ' " ----------------~ date May 26, 2006 revision & January 24, 2007 ~ February 13, 2007 sheet title 4th LEVEL project number drawn by D.M. 52 of 162 60 ®--- L E G E N D SYMBOL DESCRIPTON -"'-!Mc..._,,~~~• ;·..,_c;,ul<AI.; I I I I I I I I II C llj U. WALLS -"<E•::,01<' ((;...c><lc E, ,S.CE !rlWCl'\.~ lf"l:RIOR r,.;ru; IOI< >'lAJ....S h ~wtt.G:>OOR jfE.ETI ---➔ >~n-c, E~f!:ES9 ---- ------- oe.ccn=~ ~e.ECT$ rl,:,COSM ©---- BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamlamlObellsouthnet cp er I I I L----(-- l I e-------t l N 9 • I ------------.. ·--- (_ _ __:_ ___ ~ == 9 -7 <== l @---------------- RAMP J? TO LEVEL f!VE 5 7% _ _j_ _______________ _J_ _______ +-, '+ RAM!-' DN 5.7% I 1 ----------------------------'---------- I ~ ~ A 2 - : - - - - - - - - - - - -..:-=--.:. --<----------+ ----~ ------ - + -<---- I i ! ~ I ~7 I ; , ' ' t-r-~- 1\ / V I I I "' ~I -1=== I I LJ + ln•'I r !164'1 ~ j -----... -----~ ----)---- ---------~ -----------~ --~-- -----, ---- - ------~ 1 -h r I L_ I I l I I l I I ''i-----~ I ~ I I ~""~ "' I~~ I :1 ~I ~"----------,~ I · t----1 ------,~ I I I I I I 1'~ I I I I ________________ -<-_________ l _________________ l-<-_ ~-__ y ~ _____ l ~-_ ->-____________ l ___________ l __ ~~~ ____________ J: I I I I I i I I I ~ I I I I I I I I I --~------------ ¾[I CD FOURTii LEVEL LIFE SAFETY SCALE: 3132" = 1'-0" Proposed New Project date May 26, 2006 sheet title revision 4th LEVEL South Miami Municipal Parking Facility LIFE SAFETY PLAN project number S.W, 73rd Street & 58th Avenue, South Miami, Florida drawn by D.M. ISSUED: 3-·19-07 Scale: 3/32"=1'.:0'';~~-.\~ s h e e t n u m li~''i. --~ tl-1-\.\'rn,--"f. , .... ' ~-.,)'-., . ; ... :-A~r5~:~' ,,,,,, .. .,. '"➔,,<; ., 1 R 53 of 162 61 i[!!:1111. LEGEND SYM30L DESCRIPTION j I I I I j I I : j CnlU. ','W..LS 0'1E-:;N:T :x,M;Rl,I;: •,$Sil ~'''-'C~JR.'.i..; ----ctl.ECTS Ol'Ecll<l....:: ... /c'\ v::!,/ ·'- I I I i ' BLIT5TEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlamlObellsouthnet 6 i l Client: 4'-0" ,f--~ "l ELEV 1 - A ., 4" D.S. ------1- C STAIR 1 ROOF PLAN I ' ' == \__ STRIPING (1"PI ==I •· ::i.s. ELEV. 1 ROOF PLAN !j e'OU: MCUf..TED LIGHT - FIXTURE SEE ~IGHT flXT SCHD TYPJ + er : ~~~" 11 ·-,_ •~~~ I I I ,a• PRE ST LITE WAL TO l l FOLLO# $LOPE OF RAMP @ 3'-6" A.30'fl:: RA l.tP DECK e,•. • I ""...:-f--+---~--------I I I' I I I I O:1 all walking surfa.P8s wi1.l'1 a slope of les9 tr.an 5 % provide a slip resist!nt finish, descr bed as a .-,e,:!ium sal1ed finish. , 1 • , 8·-o· 25'-0' H----'-'---~t-' -----~----,-------------t-Onall--surtaces-wAAa-slopegr~--thaf1.&%,pro,,,ide-a-sl<>-+----1>---~-~- ! I N CD Plffli LEVEL (ROOP) WITH City of South Miami resista 11 finish. I I Do 1ot allow any c~ss slopes to exceed 1!4" per foot or 2 %, I I 60-0" ,a· o· NOTE: SCALE: 3/32" = 1 '-0" SEE STRUCTURAL DRAWINGS FOR SIZING AND TYPE OF ALL STRUCTURAL ELEMENTS Proposed New Project ® 280'-1" ,----t-j I == !-"" ! 66'-0" I 230'-2" 1D" pqc::..cAST LITE-WALL TO 3'-8" A8r' E DECK Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility Miami, Florida S.W. 73rd Street & 58th Avenue, South Miami, Florida I I r I 61'--d" I t_,CAST I SPANOREL BEAf,4 TO ~•--3• A3(NE DEC,( I date May 26, 2006 revision STAIR 2 ROOF PLA'.sl o, C -1. 25'--0" IROOFAAEA 2~3 sq/I 4' 0 s. sheet title 5th LEVEL (ROOF) project number J I t- i -~~ -18-'-0" __ "__,' I I I _,' _____ J_j -~~--~ 1 ISSUED: 3-·I 9-?~ ; .: \. 5 ca I e: 3132" = 1'-Q'I,'. ~. , I✓ " ,. ) ~ ' -~· <(', 'f-'~i!ri-rl,~· .. sheet numbeff•.lf \' ' ., ;, 0 . ~ ju>' ·,, Aj6 \t.; ' > !~ • . '\-. ... & January 24, 2007 ~ February 13, 2007 drawn by D.M. 54 of 162 62 rili ,f i ill I L E $Y\1BOL - I I I I I I I I 11 " - I\ IFtET I .--➔ ---- ------- ®------- ®-- G E N D DESC~IPTi,ON com:'IETE \SH. ST~(:"'~"-"<.) c"~ ,w11.1s '!'.E C-',ST C0~~!1F"E .sEEr=n.AAL.i •~,:-,,,o~ ~AATIT·ON W.-Ll.S SWMl~ P~TI< OF E'.lRE:SS O~EO-CS 0'.tl\lv.D 09.·EO--S ·◄•DCC~ ©--- BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305 4 4 4 4 433 fax 305-444-0181 EMAIi.! bdamiamlobellsouth.net [ - L - cp r r ~ ~ -- - iJ ~ ~ 'l a s ' V, ··::···.:··:: ,:·::::·.::: I r ' t _h I I I ~-~ N ED Plffli LEVEL LIPE SAFETY SCALE: 3/32" = 1'-0" Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida er __J I date May 26, 2006 revision I I sheet title 5th LEVEL - I I I ~-~ ISSUED: 3-19-07 - Scale: 3132"= 1·-0·, ~ -., . . sheet number,;__ .0 LIFE SAFETY PLAN "' A~6.-~ project number drawn by D.M. • ' 55 of 162 63 1 ...... ., 'i '* rr=====-------,===----===========================-------===================================--======================---====-'-=-=---=--=~--··-··--··- ARCHITECTURE 28S Sevilla Avenue a-.. EL + 49"-::l" , . .,,. FIFTH LEVEL "ARKING - EL + 38'-<l" ~ FOURTH LEVEL PA..,i<IN~ EL + 27'-9" ~ THIRD L..EV1:LPAR~JNG - $ EL t 0'-0" ORO UNO LEVEL RE'l' All ' \ \ \ BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Gables, F1 33134 305•444·4433 fax 305-444-0181 EMAIL: bdamlamlobellsouthnet 2 I Lin~ Entertainment .. n, 1t · heater Grand Sl 1 L ;~ 'ITSIG~ LCA.'4\'ASA\t'INII\IG • -E.R SEPARATE uNDLR SEPARATE P[3MlT iD'.Pl LS6M!I 3 ' PLEASE NOTE: UNLESS OTHERWISE NOTED, SIGNAGE IS BY FUTURE TENANTS AND NOT A PART OF THIS PERMIT G.C. TO PROVIDE SHOP DRAWINGS FOR ALL AWNINGS NOTE OMITTED FUTURE TENANTS TO PROVIDE THERM/\L 1NSULATION AS REQUIRED FOR THEIR RESPECTIVE SPACES .,,,,, lONE P~ ZOr-<E P6 .. CESIC'I WINC LOADS I ASCE 7 ,' 02'" "' ,., ,. ~20 , " " . ,,. WIND VELOCilY = 146 MPH 20 · 50 + 71 ' EX?OSURE CAT • C .. ' BUILO,-.G CAT ~ 2 50 -100 • " " I• 1 O:i '0 □-200 .,, " " '" HEICHT• 65'-0" 200•500 .,, " P-4 ■ CEr-. -ER PORTION Of WALL ' . " 51 P-5 = PORTION Of l',:.LL ''l-7' FR<lM • 50 □ ' EACH OUTSl□E COR'iER . ZONE AAEA POS. P~ESSLJRE NEG PRE3:0URE • SEE ."iLSO STR'JC-JRAL CALC1.JLAT1QNS 4 5 /, ·.; ~i / ,y,•:;; f:c .-,i -! l,_ ___ +-1-____ ru,;;;;,,,,,.~_,. ______ ,__,__,_ ___ .......... --~ :~~c1 I "., f ,f' 0(;) 0 '"YP I 1,.·') 4() ,q~ +71,,i;t 1-77 pat' --·- 0 :, ,'I 0 0 .,) 1£:,,. 0 Lt\)l.RABBA'S- L. WALL scot.cEs SW 73rd STREET ELEVATION (SOUTH) ::::o::~\ LINE '\\ \ A CAWl'IS Al"INI .. Q B 1--LINE Of RA.VP BE"YO..,D II Ir-PRE·C,,.S.,. EYEBROW r "''"" ~oo, -,o, ~ I /~ PRE-CAST FACE P,O,'IEL ~\ / ,---OPEN METAL ,-, r-METALCROSS \ I / MULUON.! 1 I MD,mm \ I (OO GLAZING) '!.EVEAL LINE / I OPEN METAL~ Q BV.! SICr-. Y 07,,!ERS LNOE"</ 1 ,OL\iERED PMEL \ EL + 4;,•.3• (', FIFTH LE:.\l''El PAR1c;1NG ~:;-I SEP, TE p .:.:MIT I +-------_c·c::;;=::l=i==~~;:,~::a~,L--l-------1-,==11=/=~'-.l---'i=;,====r-l-=t====t-l---/-'-/_::::::~::~:~l-=====ia/=i::o-l------'t--l--•c::::;:=~=::;:=L--; o I o o EL ._ 38'-5' $ FOURTi, LE:VEL PARKJNO - CCL ~ 27'-9' ~ TH!R) LEVEL PAAKJNG EL + 17'-0' i$l SECOND Lt:.VEL PAA.c;JNG - CNNAS AWNING_ P',QVIDE '"°" (P-5) < sqft H7p ·125 ~ OSAW."'8 _t N"I •"',-,Eccl =i'ci0-i'·O'~~=~ ? GR.OUND LEVE .. RETA.IL \ I - \ ' 3'./l" Li' _I - I r PANEL_) JOl'IT L (?-5) 29 aqH ~-,------< +11 psi -·125pst DON E TE,9 ENTRANCE 8'-CLEAR (P-~:-44aqn \1 1/ l-++---< •77 :,sf ·Hpst ·L n-----.\----{' -----L-...r-1 -Ct,NV,A.S AWN NG UNCER SEPARA"."E ~ , ,I_ PVC ruBE SK;t-.S WI RED LEll:RS I - CHAlh MOLh-E:i SW 58th COURT ELEVATION (WEST) CAWAS A'NN,NG UNCE't StPMATE PEC("'11~ 6 B ,., ~ w:.~ ¾ ,,,;/ ,r;) •l(P-4) 1 S ~c.n --~77psf - .77 ;,sf 0 \ __ P\.At-CER BOX BY OTHEKS \IQTE OM TTED 7 0 OUTBACK \ 8 TE:-iN-,T s1or-. GNOERSEl'~iE PERM.T (TYPJ Elel'afo, lobb 9 ~0~ i'f.-, ~j r;:;, I\ : ' s-"J..,ED wooo s101r-.o l (OUTMCl<"S COl:lR \.._ SQ-iEME) BY :)T-ERS L CAN\IA-S A~lNG Ji'<DER SEPA.~-,: PERMIT-- 10 _,I ;P-5) •5 sq~ +77 psf ·125 psf _,,-,tJ-:'.lPEi'o MET.AL MULL!Ot,.;S (',CGLAZ,1,0) FOA.IA MOLD,NG F''..AT CASVAS •+-~-~~~\~~ SHOP DRl'Wlr.G."l METAL CANOPY\"// GABI.I: ,----SGPPORTS eROV<>e:---·- StiOP DWGS -T'ENA-.TSIG"j UNCi(R&:PN'.A': PE.'!.MIT 1~P) SCALE: 3132" • 1'-0" SCALE: 3132" a 1 '-0" ~ SEE um--FlXT .3CHED 1-\ ~ I 5'r ~ ~ ------ . ' 'I' ~i Client: WITH Proposed New Project date May 26, 2006 sheet title •• S c a I e : 3/32" ~ 1.>0'' Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W, 73rd Street & 58th Avenue, South Miami, Florida revision February 21, 2007 OW\IER REV March 1, 2007 OWNt.R. REV March 22, 2007 OW~ER~EV ELEVATIONS project number drawn by D.M. ~ , sheet n um.if,, T ; 0 , N ' 56 of 162 64 I I /-!---.. --H!:.V~ / ) K!:.V. CHANNEL / 1f L1NEI / METAL LET'."E.''IS ~y I I / // OTHERS j /i '-,. .. -~------------- ARCHITECTURE 285 Sevilla Avenue BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Cables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlamlobellsouthnet ALLEY ELEVATION (NORTH) (TOP PORTION VISIBLE FROM SUNSET DRIVE) Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project fljE'l'Ac. i:'.IJ.<OPYNI OABlE - SU,'PQRTS--, I B A-9 C 1--PRE-C/IST FACE PA.NE:..-\ / METAL CR~-~ \ I ~!EMBER \ i I' \\ \ , -JPE.-. ME:" AL rr"----,------i ~,_ i _Oi.,VERECPA.'1EL - I (P-5) 44 ,qft +77 psl' -125 puf (P-4; 50 :aqll •72 D5f -74 p:,f ,:P-4) 40 ,,.ft ~77 pr,/ -77 psi . r/~I~ I ' ; \ I I (P--4)2hql! •Hp$! -Hp,sf SW 58th AVENUE ELEVATION (EAST) South Miami Municipal Parking Facility S,W, 73rd Street & 58th Avenue, South Miami, Florida B I P•,NEL JO!'ff ~ REVS'\....JNE I 0 0 C ,, A I ,· ,<\( <6 1=1==::i1 I I ,f I I /! I I REVEAi.. LIN!': r EL ~ 3B'-6" I ~ FOURTrl lE~'H PAR~G- $l EL + 27'-9' 2 THIRD -EVEL "'AR-<ir-..G - r~~~i_, H----++'A~-----'-.__________.__ 1---i------. l _ f ,_ r-F-~?.--..--0 o .... ' -+-+-~.,P I\_,,, $ EL -+'7-0" J._ SE:.CONC 'I:EVEL PAR!f'-10- c..... U.NOE.RS!:?M'<IE PERMIT ( I Gt-.i flXT ' 3'--0" , •--•---'•--•---•'c '""ENA~TSIG,_ UNDtR SEPA.:«TE PERMIT fJ':'?) -(P4)24,~I! +77 psi -Ppst -t>'-s: 40 ,q~ '77 p,r/ -12S ~sf date May 26, 2006 revision & ffi August 18, 2006 owt-.ER REV. I G C .. R.F I March 1, 2007 3 ;P,4) 48 s~ .. ,r pd' n,,i / .. 1 S"TE.l,,IMQU>j,.EQ ·'<------ R V. CMA."lNE~ t.'(;:l AJ,. Li:TTI:HS 6Y o,-i-,ns 0 1::..'i METAL L U'VFRFD P"-NE_ \ ' SCALE: 3132" = 1 '-0• I -Si,\iR 1 01.k.~ I --REVE.o\J.. -.._~ // ;/ L,NE _",MUNl61~AL. PARK NG rt' META_ , , AASOR I . r~ - "-- -->---t--t--1 I -1----------- 1 SCALE: 3132" = 1'-0" ,r, El -2r-c.• -'I THl-'<-D LEvi'"""1. .-AAANa I ~ EL + ,r-o· -' S[CO~D LCV£L ~ING ISSUED: 3-19 O"Z . . . -. ~ ...... . ..... . -,.:> . ' sheet title ;· ~ S c a I e : 3/32" = )'·Q:• , -~ '~ ELEVATIONS project number drawn by D,M, 57 of 162 65 I ' BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlamlObelbouth.net ffl u T I I , • I 9' :,: I i J y I y T ffl j_ I ij ij I U @BUILDING SECTION Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 II ij IL @) I 6", EL + 49'-J" .._~~ LtVEL PARKING ,,, I b - Proposed New Project C @BUILDING SECTION A A-9 T - South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida T , POLE VW!><TU ..__ LICHT FIXTURES G C TO SUBMIT SI-IOl"~RAl'/1 '-lO<i B A-9 T ' I I I U I r=~ !· ~ \D 11 IJ ' fj / I Ii ' I / \-P::1.0VIOE -~-~-I __ / lt.SU..A-IQN ~-22 1 d a I e May 26, 2006 revl1lon I ' sheet lltle BUILDING SECTIONS / project number C ,, A /'3'\ ~ SIM SCALE: 3132" -1'-0" I\ I/ ---~I.----' ;=,= : I ;.., ! "l~,-.. t .,.__~N ~ '--' I I I SCALE: 3132" = 1 '-0" ISSUED: 3- ;f~ S c a I e : 3/32" = U-' ~ drawn by D.M. 58 of 162 66 111 I I j FUTURE TENANTS TO PROVIDE THERMAL INSULATION AS REQU,RED FOR TI--iEIR RESPECTIVE SPACES ~ I ' "' " . ,..,. =~{-------- : '1' FOU H LEVEL PARKl'IIG~t---° ~ 1-27'·'r THIR LEVEL PARKING ~ '--- ~1 ~I ~-.-·r.i:t' SEC NO LEVE~ PARl<l'IG~ <':,I_,..__..,.._.__ J;:: --'Ir- ~ I T S3 T ........_ PO...E '.1OU~TED LIGl'<T Fl.11.'1J.-(E;$ •~.C. TO SU8MIT SHOI' DRA'Nl.'iGS T ~I (V @ ·---1,!··---N-+l-~-~=-.... -__ -_-.. ~\rlr1 r---------+----..!--------,-;..t..------.JJ ____ "-_''_•_55_'·'_· __ lJ ................... ~-• 3 S1 T \_ pqo\l'QE l~SU'..AT,QN R 22 r I ;~ ,c.iiJ:l:cl ~'-~~~~;Kl-,-,,-,--~It--, , r -r-r-f f11J--J i~ j[_::::::1,:,: .. :c_~-c~ __ t_-_~, ~~=~=1=,~=~-=--.=~-=-,=:;--=:_=_"'.'=:=t=1r= ___ =_~=~=--~=..,.=,-==:_Jii I I J ' ~T ' . I I ~ _{---.. ~ !9 ~~c ~g~~LRETAIL L ..... -....1. ...... ______ ...J..U,. __________ .JJ:1.1.. ________ _j.11 _________ ...l'l!JjL_ll ____ J.,====~I ===d.---4---------====Jc:..tM~lli ______ ~1 ___ Jt:~':"':u~J=~o:,:"·~-----------------~--~-~--=-=·-1--~-~-=--=-~--=-=--~-:-·=·=-·:.:·::.-·:::-:.:.··:.:-:·:··:.:·:-·:.:-:·-±l.::--:.:-.:.··;,;-~--;;.;-;.;;.·;.;·--------...:.JI w __ L_LL BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305 111 1433 fax 305-444-0181 EMAIi.; bdamlamlobellsouthnet @BUILDING SECTION Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project /a'\ ~,I SIM -- A @BUILDING SECTION South Miami Municipal Parking Facility S.W, 73rd Street & 58th Avenue, South Miami, Florida T ?OLE 'wlOU'f'.""'EC ,I clGl,T FIXn1"tE9 ----' G C. TOSU:l~T &10P DRAW,!\ICS SLOPE 2'/i, ! SLOPE2% date May 26, 2006 revision ~ August 18,2006 OWNER REV i G C -RF.I I ' ' ! 1i i -' ' I sheet title BUILDING SECTIONS SCALE: 3132' 0 1'-0" C ' SCALE: 3132" = 1'-0" ISSUED: 3-- S c a I e : 3132" = project number drawn by D.M. '}_,i J~ \;. "" i\-. 59 of 162 67 · il i. iihll l CANT W/ COUNTER I I '--•f--FACiA =-,'---_/ -VENTIL.AT!ON LOUVERS I'-----ALUM. ---~I STOREFRONT ~--IMPACT ----' GLASS !$\EXT. ELEV. & ELEVATOR SCALE: 114', 1'-0" ENCLOSURE@ R F -.-r---FLASHING r 3UIL T-UP qOQftNG OVER LT WT CONC. ·. I : " ., .. - I i I •. . · .. ' ·~ SLOPE H4' PER FT. - "' ' I 0 ~ VER CORRIGATED ETAL DECK!t-..G F LASHING F ACIA V ENTllATION OUVERS \ L \_A ' ~ s LUM, -oREFRONT ,~ PACT G LASS s TL. COL. " . .. , . •. . FAC:A --------- VENTILATION_..,.,., LOUVERS ENCLOSUKE@ ROOF ~i I l - ELEV. • SCALE: 1/4" • 1 '-0" 'f ! "' ' . - ! <...; -/----12'--0" ---------+- A"'\ 2·-0· 8'-0""' 2'-0" j,. ./ ,, I ~3/ ~;_g) I . ----· . 5' • "' ' / PHE-CAST • EYEBROW 'I' "' / ,_ C 0 '.'I N ~c ,_ "" / ~ / V 1....---....-.~-ALUM. i ' MULLIONS ' / 1,0 / ~ / "" GLAZING) I~ (H\ ~ • ~ " . ' "' \ • \ E ~ I,_ HEV. ll~E ~ -16 I APPLIED N II ~::--... DECO!~ nor•• ·~ ' ~ ~ ' ALUM. -, -~ io GRILLE ' / u ' "' / • T "" / I"' / ~ ~~c ~ ' N ~ / ~ / ". ·--·' • "' ' • ;.. ~ " • ' "' PRE-CAST ' PANEL 'A' 1--s" ALUM TUBE ~{ ----' ~ ~ "/ . ' "' "' "' i :; I V V V V ~ • ' " i ,__ "' / "' / • L i 9' "'· PRE-CAST ' "' ~ I -' PANEL 'B' / " / " I '? 11 ' ;.. ~ ' ., .. JI_ . ' "' . 0 ' "' -------------'\,----- 0. 0 1o u . ' N --------------• -----·--TE:~ANT "I "' SIGN SAND N ~ /~ TE~ANT STOREFRT WALL I/ I / B \/ SCOt-.CE ' SEEL T. FIXT \A-1,;,/J )+' SCHE:.D -,h.. -I V V V . . . . . . ."7 -- ~ --L.tJ-----_..._..._ & ' . :r re\ M \ I •.or.a· ' \ ! " ~ ~ ~ \ I I i f-t- I ! ' ~ I 0' ' "' lo\ I ~ ' I I ' -- @ENLARGED ELEVATION SCALE: 1/4" a 1'-0" - I I I i ' i '" i7'~i_£_' i PRE.CAST""' ·r-c ·r PA\IEL "' ' f------------Sc- PRE-CAST ---, EYEBROW \ \ PRE-CAST ,, ·1 1.--SPANDREL i---. EL + 49'-3" 'JI' FIFTH LEVEL PARKING,___ ~ ~I I ~ ~ EL + 38'-6" { ~! PRE-CAST-- SPMDREL -FOURTH LEVEL PARKIIG I "' ----- EL + 27'-9" El • 17'-0" I ~SECONU LEVEL PARKF ' ~ N 8" ALU TUBE •·~u::) : .. TUBE PRE-CAST - CONG TEN,4J,.;T "' -PRE-CAST D.T. ~ "' CONC COL BEYOND ' ' ---·- ----,-· --- SEE STOREFRONT SHOP DRAWl!\G th S!GN BAND _ ~ @:;;,;:;:::;: :::., ' 1---'i wt~ I I DCdURS ----fl~/ / REVEAL / CSANNEL I ' I I STIJCCO CEILING ---1,~ I TENANT ----,-1 STOR.EF-RT ' 0 6 ' $ EL + 0'-0" GROUND LEVEL RET AA11r_.,~-----r7, ~.-;:;~±:=::1,µ,.z~ '? ' io ' " • ti ~ EL + 49'-3'' FIFTH LEVEL PARKIN +- !;_ EL + 38'-6" ~ &-iOURTH LEVEL PARKl~G ' ' ' '!I q " b ~ I I EL + 27'-9" $ THI-RD LEVEL PARKIN ~ EL + 17'-0" ~-~ SECOND LEVEL PARKI G EL + o·-o· ~ GROU~D LEVEL RETA/ i ~ PRE-CAST \ EYEBROW \ " .. ' \ , .. ' c':::: ' ALUM.~ :1 GRLLE ~ PHE-CAST --- SPANDR.EL PRE-CAST-~ ;,, ' 'le-"' ' "? "' ~ • ~l N ' -PRE-C AST D.T. PANEL ' -1 I -'z. ~G:::;J-1 ~r-- REV. Ll:-.IE ~ REV LINE -( ;' \ I ' , io ' "' ' N ' :r "' i,, '\--"' ' ~l ' .a> ISSUED: 3-·J 9- ~\-~========;;._---=========================================;;._====================;;:::c..;..___..:;.:===========;;._---.c:.;::::========::::......;.;_;__....:;;.;::======;;:;::,,~ ...... ~=,:i~ 1: .... ,,.. "- sheet title ARCHITECTURE 285 Sevilla Avenue BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Cables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlaniobellsouthnet Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida date May 26, 2006 revision July 17, 2006 :3.C.-FUI, ENLARGED ELEVATIONS project number drawn by D.M. .,.,,,:-,:-·, ;:-~-- 1/4" a,'i''Cf ':. .. s ,,: ,:;_, ,, Sc a I e: sheet 60 of 162 68 11 I :r "' N " I ' . I 18'--0" i f -------t------------,'- 1 9'-0" 9'-0" rs· ------~~-----3_•--~-1 _3'-_6"_,__ __ 5'-_6"_-_-_ -_: I 1 • 6" 2·-0· 2'-0" 1 '-6" . - I -~ I ,,__ ! PRE-CAST--• PMEL PRE-CAST EYEBROW I ' I ' I 1 '-6" 1'-6" I • r-e i ~ ! ' _,l_.__ ALLM. I a,l~· MULLIONS ----------------;--' ~,'-" ------ IND -------k. ---'L r-----_ GLAZING) I ------i ' -.., F--i i ' f.--~ r-,;..=== -ij-= = -=,v..-r---,== -, Ir, --,-,, ' r I", I / 11 \ ' , " I ' I \ I -' II :/ " I r,\1<: I ',I-/ II ,, ;, i1 ,, c r•---,,<----F ,, "' ' },< I I' ¾, II ,, I ,, ' I ,, \ II ' ' ,, I ' I I' , II ' ' ,, " ' I/ '-, 111 ' "I • --L \&'____ -_>JV_ ~J C ,, ' ' I • DECORATIVE --~-----------N MOLDING --------------·' "' ......_ __________ ' • • i \ . DECORATIVE "~ ALU\t i RA L1NG F--I ' _,._: f.-PRE-CAST -----.-: -------------, PRE-CAST "--,-.,..,---T---;11';:-7--,,, ! ' I I " PANEL 'C' I ,, ~ I ' " ' II I ,, PANEL 'C' REV : ',,II,,/ '• I , ,, '.I' ' ' Ct---i~t--ri1· ,, r· i-;-,< H, ' ,< ,, "' ! , I : I / :1 '-.,, II I ' ,, ' , I ' ,, ! , I t.v.:: JL ,~~ I '" I!. -==~ J ,, -'<------- ;-! , I I . ' ~ • I 0, :;-i ~' ~ PRE-CAST r?\ PRE-CAST PANEL 'D' \_A-\6,I PANEL 'D' REV . "' • -s.-1-0' ------'"-= I"---L ' c+ t--' f.--~r-, ----------------..... ,== :11 -..,..----,-----'11'i,-UP LIGHT ( 1 '-, I ,/I' I SEE:_ T. FIXT ,, I , I ,1 i ' REV.LINE 7 I ',I/ I ,. ' , SCHED. i~ ' -s' -+----j:~-F-}1{_ 3'-3" '° ' 1,/]' I _, ,-{., I ~\ I ·~ I ,1 I , I ' I , I , I ' I \I/ I ', I 1 ' =============---========================================================-----=------------=---============-----•-•-··-----· ...... _,. __ "' :8"'i.8"1 -rl, f PRE-CAST-I PANEL PRE-CAST -, EYEBROW \ ', \ , " ,~ PRE-CAS r !----SPANDREL --I.------- :r 2'-0" PRE-CAST _/ '1 '-0 EYEBROW -r- DECORATIVE ALLoM. RAILING~\ \ .I J: ---.: .. 11 \ill J\jl .,J : .. ,_ ' '. ' -~ ,. --t--'-c-- 0:, '° • N -'-c- ~; N 1 i ---I L Pr{E-CASTj O.T • ~ CONG. C BEYOND ~l • "' ' • ~ ~ ~ ·' N "' :r "' N q, 0 • :; • '!I "' 18 1-0~ I 9'-0" ff' ~1---5.--6-.. -----3--_-5•---r-:::. 5'-6" 1 '-6" i 2·-0 11 l 2·-0.. 1 '-6" r---~_,,_____,___, -,'------------, ! -/----,f---,~------1' ,,_ P~E-CAST--• PANEL PRE-CAST --~---t--~~ EYEBSOW ~ I t---- i I 2'-6· I i $ EL +4 9:'-3" FIFTH LE VELPARKI~ ' i z1 _,,__ _______ ,_ _____ _ -~- . Ll ' • 0 ~ ' ;.. _, _____ • ~ ~ ' "' -..,____ - 0:, I ·' "' ' ALU"-1. ---r-- MULL ONS ----------------...____...______ \NO ......_ I---..._ GLAZING) PRE-CAST PANEL 'C' PRE-CAST PANEL 'D' C2:),-,A~:1"'6 ~-tt ---_c ...__..,, --r- {I ... . ,.,, -____ _L_ "----Jc ===t======~~ --- UP LIGHT SEELT.FXT. SCHED ____ ,, __ ----:! __Ji 1. >-----PRE-CAST PANEL 'C' REV ½-;.. ., EL + 27'-9" " THIRD LEV~EL~P~A~RK~-j),fa~:;: PRE-CAST llr---1 PANEL 'D' REV 9' 0 P'1c CAST - PANEL P~E-CAST --, E:YE.13'-?.0W \ ' ALUM. MULLIONS (NO Gl..J\ZING) \ I 1 " ii \ ~,_,...,---..J,I i @/ 1i I ,_ _______ " __ ,__ P~-CAST SPANDREL -'-c- -Pl~E-CASl' D.T. '.7 I "' CONc.ctjL BEYOND I _l ~l ~-"' ' ---'<-- I Ji I . . f1 ' , ,. __ , _\l,' ____ ..1.. ____ -.11( _ J EL + 1 . ~ ,----7'-0" LEVEL PMKINGl - i ' r-_3_'-3_"_,.. _/ !r' • ~ • ~l & I I 'r. TENANT - SIGN BAND TENANT ~ -~ ' STOREFRT e, ' ' ;.. WA"....L I N sco~cs "I_ "-s SEE 1:;.LEV.& ~ ~ ~--I i LT.FIXT. ! SCHED. -'-c---<>-' --- A A ... A M & / = ~ ~ ! & I • k O• _, i ro , 3'-0" .L°iµ_ l\!2'-0· L ~ \ I\ I ' - ~ ENLARGED ELEVATION ARCHITECTURE 285 Sevilla Avenue BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Cables, F1 33134 305 444 4433 fax 30.5-444-0181 EMAIL: bdamlamlobellsouthnet SECOND --------r I I :t: " '-c-- J + M ' 0 ' 0 ~ 3'-0" ---~ $ EL + O' GROUND SCALE: '/4" = 1'-0" 5' r-- I • ! °r ; N . ,..,;.- I ------------- • N :r " ' I pqe_CAST CONG. TE."l:ANT SIGN BAND ! ' A A-16 ~ SEE STO~EFRONT ~ SHOP DR.A.WING &@ 1 ,: -19 '"' ---1--1-'r--'i If/HERE J:::';====1~\,}'··.--,--.,J -'-c- OCCURS I • REVEAL-- CHAN'"L f;1 STUCCO r 1 CEILING /. TENANT S_,..OREFRT FLOOR SLAB - SEE STRUCT. /I I I I I I I @ '.I' -., I - 91 ol -~~VEL REtAJL "'--------,.:::::;:;~=='J=.z~ Proposed New Project l ' • ~ ~ <D N I ' I ' lE:.NA'H ' SIGN 3AND ---+-----I----- TE/'\A'H • STOREFRT "I ;.. WAC 't N SCONCE "I_ "-s SEE ELEV.& ~ LT. FIXT. SCHED ( -1----0' -- M . & 1 '-6" 1 '-6" . . \ \ ' ,__,,__ ' ' 0 ' 00 3'-0" I 12 ◊" i \ I / \ ' ii ~ I ! I - ~'l ~ ~ . ! & I ' I ' ' ) I I ' ----•---'-c- ---1---'-c- 14- M 3'·0" • 9 f.. ING ;} '',• PRE-CAST//~ , CONG // , & IE't:1L ' ffi SIGf,D ~/ -- -r REVEAL -- CHANNEL STUCCO CEILING TENANT STOREFRT FLOOR SI.AB -' SEE STRUCT I \ I ''-==== ---~ /,,,_ __ I t--I EL + o·-o· ·'<----~~--'I<-, -----~,~-'>------..L.---..1..-------.....:----l,..._ ___ ....I ___ ....JL-~-'-c-'.', GROU~D LEVEL RE Al'"L..,_ ______ _ - @ENLARGED ELEVATION SCALE: \ /4" = 1 '-0" date May 26, 2006 sheet title revision South Miami Municipal Parking Facility ffi August 18, 2006 OWN~Rl:V, /G C.-R.F I. ENLARGED ELEVATIONS project number S.W. 73rd Street & 58th Avenue, South Miami, Florida drawn by D.M. • N ' ~~ " ~- ~ 0 .. -----'-c-. ISSUED: 3-19-0 61 of 162 69 · i I I I 12'-0" r 2·-0.. 8'-0" I 2·-0· l ,~1------r---r PRE-CAST ~ EYEBROW "' AU.iM VULUONS (NO GLAZING} K -----------t----- 1 r-------1 '-c:::========t=:i------ 1 Io 1---r---- APP·,JED -~ -------r--- , DECORATION I --,--:r I 0 I ! ~--1-=------~!s--11 ~* ">--><i=:- PRE-CAST 1---{[) PANEL 'E' I I ' PRE-CAST f---jfll~---t=:::::::----~.i(___~ ~ r--- PANEL 'F' -------------------_:><Cl -"'~-----J -------,. :--------- I I v7------i--1"--------------- PR.E-CAST / ~ SPAt,;DRAL BEHIND -- @ENLARGED ELEVATION SCALE: 1/4" = 1'-0'1 PRE-CAST PANEL PRE-CAST -1 E:.YH!ROW \ \ \ \ •, · 1----PRE-CAST t; .. SPANDREL EL + 49'-3" $ FIFTH LEVfL PARKl~G . ':I .,. ' EL + 38'"6" ~ FOURTH LEVEL PA, ING 1'-0' .,__ ALUM ~ MULLIONS \ (NO GLAZl~G) \o::: PRE-GAST PANEL 3" _,, ~ - 3" .,, ~ ~ EL + 27'-9" •-·-'l.c------- ' THIRD LEVEL PARKI G J ~ "' co EL + O'-ON ~ GROUND LEVEL RE Al'"L _... _ _., ____ _ • I N I ' Lt? : :, . i ~· t- i I ! ~I I ~ I I N -PRE-CAST 0.T. I ,,,~ CONC. CC> I/L BEYOND ~ -+--''s-- ' - • N ! I ' I i--'.- Pl-{E-CAST PAAEL --------------- FIFTH LEVEL PARKI I G EL ... 38'-6" ~ FOURTH LEVEL PARKING EL + 27'-9" ~RD LEVEL PARKING EL + 17'-0" • ~COND ,EVEL PARKING C/1 w ~ ---------L---- ',. ---PRE-cAST SPANDREL 1 ' .,., I_ '.I' N • N _ _,___,.__ I 1-. I • I ':I .,. L PRE-CAsr D T. ..---,--CONC. COL / BEYOND ~ --· k-- '.I' N '.'i' "' -'<-----"<-----_l ! ,, ' Pl~E-CAST ~ , CONG. , '"" C/l w i I ti"', EL + o·-o· I ., '" GROUND LEVEL REfAILL➔---~---~ur,'."". ,:;-=·· =====·='=' :::;:::::.~--',--~'<.-- 18'--0" I 9'-0" t ,,______~r-->-----~.,- 5'-6" 3'-6" I 3'-6'' 1 5'-6" ,,_ _______ ,. _____ ,,__ _____ ,,___ _______ ,_ I 1 ·-e· I 2'-0" 2'-0" 1 '-6" I PRE-CAST --· • PANEL PRE CAST ---le--~ EYEBROW ,_1,___,,___,f- ~ ----- _ _._ '--r=-""'·==--:-_,-_----.,,..---'' t1·6" --f-.--1·-w----T-- ' I -',----------!---------f--- -~ • I ':I I "I ALUM. ------~"""--~............___-___ _ MULLIONS - (NO -----..._--.....___ GLAZ1r...G) - -----------.--------- • I 0 I ~ I PRE-CAST PANEL 'C' ------- ' PRE-CAST PANEL 'D' ---------I---© UPUGHT--'---, SEE LT. ftXf. ~I SCH ED -'s---<J-L----L -',-------------- -·s---,,~---'\;--·----·-· -·--- - I , -r----r-- ' • I "? ' :, I I I I :, i "'I I I PRE-CAST (})--1 PANEL 'C' REV 1 PRE-CAST -'l----1<---_(}}----1 PANEL 'D' REV I I I I 1'-6" :711 _,.,.._______._F-- "' I @ENLARGED ELEVATION SCALE: 1/4'' = 11-0• • . i I ISSUED: 3-19-0,f 1 ~==============================~===============-=-.;..........;;; ·...;...;;..__;_;_;;;._.;.::_;·----=--=================~~\~-~{~Lt=-t~:;) 114" • 1·-i:0:~: ~$ ~ 'it"',<~ J ARCHITECTURE 285 Sevilla Avenue BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Gables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlamlobellsouthnet Propose9 New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida date May 8, 2006 revision sheet title ENLARGED ELEVATIONS project number drawn by D.M. Scale: -' T" .. . 'lg, .... , sheet 62 of 162 70 W:111 r,==============================================================================================================--------==================================================----------------------------•-•_• """""-._ .. ====~--~---.,,.. • • 'i 0 b _, ~ 0, 20'-0" 1 ·-0~ ' ,_ --+---~ \ st \ / ,'---',c----------------------_,1-----j'- @ SRAI R 1 5th LEVEL SCALE 1/4'=1'-0" . -',-------- ~ ~~ ~-----k,t---~c-- \ DN ---e-- 1·-0·• t-,_ \v / / / 5'-3" 4'-6" 8'-3" (9 TREDS@ 11") 18'-8" 20'-0" 9'·2" (10 TR EDS @ 11 ") ' ' I / --+-----+----------:- / 5'-2'' 5'- -,UP 1'-11" i,_ / / / · 8"' .f-...-... I 7 f / 4'-6" 9'-2" (10 TREDS@ 11") 5'-0" , 8;,.,,_ ~ 8'-8" 1s .. i _,,_,,_-+----------2-0-'-0-"---------+-t-t f l'i ..J (J ~ 4 ,q <l ,,-n,, / I ! 1 '-0" _,,__,_ \ I ~ , -----K-+--__ J----- ' 1'-11· I ,_ I 8'-3" (9 TREDS@ 11") / ____ ,,,_ ·' ., 1 3'·6" CLR f l~_-__ -_~ ,-~ 4'-1 0" ROUGH l l 5'-3" 8" a~4 , a· i ,f-\------,_ ___________ 1,,_ _____ ,.____,_,__~ __________ ,_f- ! 8" 18'-8" 9'-8" _,,_,,___>------------------------t--;<---------------~,f- ' 29'-0" -1'--"C:::;:::~-;:::;c.~~~~-::::::;;;::::~~;,=--fl~----~t- SRAIR 2 5th LEVEL 5'-2" 8'-3" (9 TREDS @ 11 ") 1 '-11" --;<- UP DN 1'-0'' _,_ / /L J 5"-3" _,,_,_ ____ ~~------------- 18'-8" • ~ SCALE: 114" = 1'-0" / I 3'-6" CLR ,_ 4'-10" ROUGH ,,_ ______ ,,_ 8" 8'-4" --~ ,_ __________ _ 9"-8'' 8" / / -----,)~-,'--------------,'- 29'-0" '-0" 9'-2" (10 TREDS @ 11 ") 4'-6" ,'I+---',--_,_ ____________ "' ________ ---------r- ' f--- / 5'..0" 9'-2" (10 TREDS@ 11") 8" SCALE: 114" = 1'-0" HOLLESS HYO ULIC ELEVAT~""''--' RA 1 E: 3500 Ii BY SCH I NO LEI~ ~ ELEVAT ORP. OR EQUAL ~~ PROVIDE VANDAL ~ESISTANT I INT. FINISl1ES & f·AR!JWARE I 3'-6" CLR ,,_ ____ ,_ 4'-10" ROUGH 1 8'-4" ,F---,------,r----------------,r------,~-,_,-__________ _ 8" 18'-8" 9'-8" _,,_'1--f------------------ / / / 29'-0" -1'----~::;:;:::::::;;::::::::;::::::::;:-::7=-"=',s;::;;,,;;;::,-s::::;,s;::;:;,s;;:::;,s:::7<:::;,s='-------------------- @STAIR 21st LEVEL A-ff: ,'f(E..{;AST OO"IC H/,,IRCl\5!: SCE ST'IUCT\JRE SCALE: 1/4" -11-0 1 J TYPICAL STAIR TRED ARCHITECTURE 285 Sevilla Avenue A-11 SCALE: 1-1/2" = 1'-0" I I -,- -• "' :;; c6 @ 12 UJ CJ) ii'. ~ ' 9 f.. ~ -~----... -,-..-- / / / / / / / / / / / / / / / / / / / _,.__ PRE-CAS~ STAIRCASE & LA"JDI\IG 1-112• MEfAL PIP RAIL @42" A.F.F. 1-112" METAL--)_ HANDRAIL@34"\ A.FF. \ TO REJEC..,. 6" DA SPHERE @STAIR 1 SECTION INTERIOR DESIGN CoraJ Gables, Fl 33134 305 444 4433 fax J0.5..4.44-0181 S,W, 73rd Street & 58th Avenue, South Miami, Florida EMAIL: bdamlamlobellsouthnet / / / ..--. EL + 17'·0' 'I' SECOND LEV > 12•0.C.ATTACf'W/ I 2-112"x:318"STL 1 > BRACKETS ;"OP & BOT. 5'-0" O.C. ~IN. COORDINATE W/ MANUF 2 @STAIR 2 SECTION SCALE: 114" = "-0" ISSUED: 3-·I 9-7 drawn by D,M. 63 of 162 71 Li BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305-444-0161 EMAIL: bdamlamlobellsouthnet Proposed New Project TYP. VERIFY ALL ROUGH OPE~1NGS WI MA"IUF HOLLESS HYDRAULIC ELEVATOR RATED 3500 1:, BY SCH1NDLER ELEVATOR CORP. OR EQUAL PROVIDE VANDAL RESISTANT INT. FINISHES & HARDWARE L 3'-6" CLR 1 c_--:l f'--__, I 4'-10" ROUGH 8'A" 9'-0" South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida -}-----.---1.---------~ ' ~ ~'!,-----~ L + 49'·3" ~ FTH LEVEL PARKING ~ L + 38'-6" ,,.--, URTH LEVEL PARK1N L + 27'-9" ~-T -iR □ LEVEL PARKl~G E.L + 17'.,(J" ~SECOND LEVEL PARKIN '$ I;),_ +0'-0" _,__ GROUND LEVEL RETAIL date May 17, 2006 revision 1/, / & January 24, 2007 G.C. -'l..F \ STL. DOOR RAIL _J S.S. ELEV. 1~ DOOR ,--------\----------------, ' r==I====;-: I ELEV. PIT METAL LAODER WI - 2-1,'2" x 3/8" STL STRINGERS & 3/4' DIA STL RUNGS 12• O.C. ATTACH WI 2-112" x 3/8• STL BRACKETS TOP & BOT. 5'-0" 0 C \11N COORDINATE WI ~ANUF, sheet title 1/, / 1/ -/, 1/ HOISTWAY ELEVATOR project number drawn by ISSUED: 3-19- Scale: sheet n u <,;a -< Ai~• D.M. I I 64 of 162 72 1 i I 'I 1 ' I I j l - i ' @- ®- STUCCO C.H. +10'--0" ~ ~ A j ';<; CANOPY 6 F , AWNING ~ A CA.'IOPY ' ti ' ~--- 5·--0· 0 J-B X 0 I I DRYWAL~ f---i-----+'"Rc<-c C.H. +1 □•-0• ~{--,,,_~-=--=--~ STUCCO c-->-- C.H. -1-1 □'-0" F , A'Nl',JiNG A 0 M 5'--0' ---- ' " i! ,, 1; ~' "J. N,~:; . tl A , CANOPY ~-...,_ ST'JCCO CH, +10'--0"' ! I I ~ I i BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE , INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444·4433 fax 305·444·0181 EMAIL: bdamlamlcbellsouth.net t:.H + 4'-6' C I I C , C.H.'1-14' i CANOPY 16'-0" B 11 11 , I I ' I I cp 12'--0" ,,___ ____ ,, I I' 23'-8½' I ,, 33'--8" ,f--------'-------) 11 I I I I I ii I M STUCCO C.H +10'·0' 22'·0' I -//- I DROP C.H. 1 l.CANOPY) & 11 '-0" I ,, FIRST LEVEL REFLECTED CEILING PLAN SCALE: 3/32" = 1'-0" N 1- G : i i; ED ED ED [gf n 1· +'---Jli 11 LI' n :: I I " II;[ LI ,1 --+--+-wfciDRRpi,::!=li-1-1+--E-w; II - 11, I ' ED D 11 dl::::;;;l;oiiiillll ! i C LI ' ! : --++- X ' I I I I I I ~r---N----------~--------, ;:;;=:;:;:;;:;=;:::;;~=,;:;'.:;:;:;:;:~-;;-=;I 1-1- ////' / -c7/ ;7 ' ,/ /W, /' 1/ / /, : /"! / ' . // / . ,· . - "I )t _,/ I , /llf/ I / lJ / / --- i I ¢ I ~ I I I ! Ix I! i1 11 i I ' ' i' ¢ i' I I I I ' I ;i Ii i1 i 11 ' I ¢ / i' i I I I ' C.H. t 4'-6' I, ' I! *~ I I I ' M • I 0 ,. ' 'A ~-0 F AW'NING STUCCO , AWNING C.H. +'O' • I CANOP'f AWNING STUC ~ CANOPY G.H +10' I i 15'-0" 46'-6" _,, 8'--0' A' 10'--6" A' I 18'-0" A' SY'v1i30t. DESCRIPTION SY!vl90L DESCRJI' l ION 181 A.'C GRl!_LE (SQUARE) = -'Luo;;.:sscE.NT STRI? L1GrT AlC GRILLE (LINEAR) 0 RECESSED LIGHTING 0 ~GE LIGHT F\XT (j Et-.lERGE:.NCY LIGl·T e> C:.IAERGl::.NCY LIGHT [::.ii EMERGE.NCY LIG-H CJ LAY-!N FLI..ORESCENT WGHT FIXT1.JRE ~ E)(:i-SIGN f -t-.,-WALL MOUN-ED L ·GHT FIXTURE Proposed New Project South Miami Municipal Parking Facility S.W, 73rd Street & 58th Avenue, South Miami, Florida 29'-0" j I CANOPY 15'-0" ~ I I, AWNING i I I, I I 1T-0' I STUCC C.H. +10' • ® I 12'-0" I 12·~· 4•-0• J'-----r-" I~~ -',; ~ / ! I I' C I I X D ! I I,___ _ _, ; I ¢ I ~ I ' I I I ' '' I X ! C .. +I '-3" I I ' X 5'-0" I ' : I I i I I' '' 11 I I I: C I ~ ~ I j C C +1 -6" DM I ' I i' 5'--0" I §>" 0 M ~--~----~---'-I~-~ _ _,__ ___ _,_, CANOPY AWNING 8'-0" , 9'-6Y;i" ,, date May 26, 2006 revision February 21, 2007 OWNER REV March 1, 2007 March 22, 2007 OWNER REV STUCCO C.H. +10'-0" CANOPY 16'-0" ,_ __ --- sheet title 1st LEVEL REF. CEILING project number drawn by D,M, A , ,, io C.'\-.OPY STUCCO C.H. +1ci'=cf' ,.._ A , CA,\jQf'Y F AWNI\IG t 1' STUCCO ~ C.H.t'D'--0" ~ l 1< CANO,:,Y ~1 STUCCO CH +10'--0' l ',; '; il F AWNING ',; ',; I A ~ CMOi;Y 65 of 162 73 ®-- 4< ©------ BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444•4433 fax 305·444•0181 EMAIL: bdamiamiobellsouth.net B ,- n II II ~ 1 I I I I I I I I I I~ ~ --1----1 r : ___ J_ --- ~: Oh I ~ ~/ I /L/ / / :b I ,f ! II II LI ------1! I. t --11 i I 0-fl I . ' ' L N X -, ,7 I\ V ,L J ,, ,--,-,- 11 c·=: ~ I 1 1 I •I I 11 I 11 I I /1.1 I I I I I I I I I I I I I I I I I I : t ' I , ;;;;;;;7 : i;;;;;;;; ;;:a I _L __ :f __ _L ---, ;;;;;; ;;;;;; ,I ---f- r --\ SECOND LEVEL REFLECTED CEILING PLAN SCALE, 3132" = 1'--0" L Proposed New Project r -, _J C - I"" :11 : __ E, __ ,I jll I I A/ Q A [ _"'_"'_ _i;;;;i"' ' I I I I I C.H .. +8'-3 : I' l i ~ "'"''"' i;;;; "'"' -...1..---+-------i - t.oiufocturer ood Cato Number ''° 1 ,I ,1. ii i ;;;;;;!~ .;;;;; ;;;;; 7 ----r----- 277 1 42\f T 13ft.-P-I.IW-32P-1-277-EL-SR 277 1 2W PLT WAl.L WAl.L WAl.L WAl.L 277 • 400W hi-I PULSE STAAT 277 • <OOW ~ F'VL.SE STAAT f'( ro..E t.mGTH REIAM'. 10 F1.00ft 4C-.'OJ.1AWS-400N:·H~li-P 277 • 400W htl PULSE START P"°""' LOT LX:HT>IO (1t-•• ro..£ t.mG1H RE1>JM: TO FLOOR 277 • 400W hi-I PULS£ SfART T TO BE SlllCTED ll<!l PRQ.'100) 6'I 0,,00, X THERWOPI.ASTIC LED EXlT LIGHT LEO'S INCLUDED WITH BATTERY BIJILOIN¢ STAADAAO 277 XI 'llrAThf¼'ROOr EXIT SK;N WITH mRV ROOnOP LOO. ENAU. l.ltro:-t.lW-R-DT-El--CW 277 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida i' ,1 I I I I I I I I I • ;;;;;;;;;;;;;;;. ··l . ;;;;;;r-~ i I ; DAAWNlS ---f-,- 'Mfil Mfil .,.,m: ITA8l£ FOR DAMP LOC,,.TJON lJBEL REQUiRED m:w.-RESISTANT & WEAn-lErf'ROOF EXIT 9GN date May 26, 2006 revision I I I I . I : I i V C.H. +8'-3 I ____ J II :r-7 7-r ✓-r 7 / / / / / / I I ~ _t _____ ---1 I ~ __ 1 ___ 1 __ _ I I L t sheet title 2nd LEVEL REF. CEILING project number drawn by D.M. L L ISSUED: 3-1976' _\/_ 66 of 162 74 rr=====================~---""'.'.--~--""'.'.._~ __ ""'.'._""'.'. __ ""'.'. __ =============-=------------========================-----------------------------~.....--------:----~--===-:1 7 ®---- ©-----~ BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305•444•0181 EMAIL: bdamiamiobellsouth.net n II II ~ n I' I B 0 K L i r I I ~~ I I L n II II LI , I __ __j --~-- ' I 0 N 1 __ _J -7 I I I I I I 1· I ' I i' I I r1 V I l==='- Lh----,, C.H. +8'-3 ' r\ iL J I I I -+- ' 1-~---, I E:::: ==i I I I I I I I 1: I, I TI-IIRD LEVEL REFLECTED CEILING PLAN SCALE: 3132" = 1'-0" ei== i A I' -,,-,-- 'I \ ~ =-:::1 ' ~==>= >-g ~i ~-~ ~: "' ~ ~: 0 ~ c.11.; f-8'-3" 1: I I 1' I I A I I '? I I I cp A1 1 _;;i,_·"'_ "'= "' "' 1 -I 1 "'"' I "'1"'"' :: "" "';;a F' -"'"' "":'" "' , i <;;j -----~-tt---t--L---l---~ r · -r-L- ~~~~~~ ~~~~~~ Proposed New Project South Miami Municipal Parking Facility S.W, 73rd Street & 58th Avenue, South Miami, Florida ~ d a t e May 26, 2006 revision February 21, 2007 Ol'VNE:R REV B V LJ C.H.1+8'-3 sheet tltle X r- 1 I I I (v I I I I I L 3rd LEVEL REF. CEILING project number drawn by D.M, n II II IJ n II II LI Scale: 3132"= 1'-0" sheet number 67 of 162 75 r='======~-~·-~-~--·--------~-----------======================-=====~===============-----==================================-=-~--=~~--=-~-=-=~~~·~~-==~ ®--- ®----- ©--- BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305•444·4433 fax 305·444·0181 EMAIL: bdamlamiCbellsouth.net er I i I: -------X I I ' I ~ ,~ II LI N I I I I ___ JJ ---li- , 0 I 11 --11 __ : I : I I I I I I I L C.H. t8'-31 ' ' I I I I I :I I I : f>. A1 : I I I I I I I I : i I I "' I 1"''1'"'"' I G "'F I "'"' --...Lr ---..l..-l-1---- ~~~~ FOURTii LEVEL REFLECTED CEILING PLAN SCALE: 3/32" • 1'-0" Cf ® I > Cl --::::;:·::3 _ _L __ _,__ Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida ' J;;;;;; ;;;;;;i ' -.- date May 8, 2006 revision February 21, 2007 OWNER REV B I\ V. LJ C.H +13•.3• sheet title 4th LEVEL REF. CEILING project number drawn by D.M. ~ I I I I I ISSUED: 3-19 -~ Sc ii I e: 3/32" • 1•:t)• 68 of 162 76 1 -~=----=====..,..-================-----==============================================--===-------==~=====.,,..---""-===-==-----=======._._. . .__ ........ =-==-·-=="';'I I ' -----------, I DOOR NO_ 1.2 , _3 LOCATION REST AU RANT 2 RESTAURANT 2 DOOR SCHEDULE DOOR WIDTH HEIGHT THICK MAT'L FRAME TYPE HARDWARE PL, DB, CL 1-J/4" AL AL 8 PL, 08, CL 1-314" J-L ____ ,__,_A=L ___ ,_=8 __ 1 PL, DB, CL l-'-1~4 ___ ,_~R=ES=T~A~U~RA=N~T23~----I2\3'-0" __ ,~B='·=O" ___ t-1~·=3/~4•_,__,_A=L ___ 1-A~L~--,~C~_,PL,OB,CL ___1_5 --R=ES=T=A~U=R=A=N=T~3~-----1-3=•--0=•---lr8='·=0_' __ ,_1-=3/~4_"_1=A=L~--1-~AL~--,rB~_,PA,PL.DB,CL -1-T=E=N~A=N~T~,~------,_,._3'2·0"~--1-"'8'~-o=·--l--'-1-=3/~4_" -t=A~L~--1-~AL~--l>--'B~_, PL, DB, CL l-'-1=7 ___ ,_T=E=N=AN=T~2~------o--=3•~-0="---1-=8~'-0="--l--'-1-=3~/4_"_,=A-L~--1-~AL~--t>--'B~_,PL,OB,CL 1 B TENAN=T~3~------t-=3•~-0~"---1-=8~'-0~•--,_1-=3~/4_'_,_A_L ___ ,__AL~--,,-B __ 1 PL, DB, CL , 9 TENANT4 3'--0" 8'-0' 1-3/4' ~A=L ___ ,_,A~L~--t=B~_,PL,DB,CL _1_JO _ TENANT~5~-------1-'3='-0="---l1--'8='·~0" ___ t-~1-=3/~4'_,__,_A=L ___ 1-A~L~--,~B~-, PL, DB, CL 11-'-1.~1=1 __ ~AN=T~B~-------1-3=•·=0'_' ---1-'B='·=O_' --1----'-1-=3/~4_" _ ,~A=L ____ o=cAL~--8 Pl, DB, CL J_J2 _ f-=EL~E~-✓~A~T=O~R~L=O=B=B~Y=2~---tl--'3~'-=0" ___ 11-B~'-=O_" --t-'-1-=3/~4_" _ ,~A=L~--1-A~L~--8 PL, CL -A .=_ho. 1.13 STAiR=2 ________ l-.,_3'c,-O,_" ___ ~i!-6'_:,~,)· ~='------1-'-1 ·:e3,:,/4,_' _ 1_,_H,c.M=., --1-'--'H,,,.M,,__ \J--'E~f--t PA, CL .....__,,. ...___..., ll-'-1.~1~4 __ 1-'-R=EA~TAURANT=3~-- 1.15 EM EXIT CORRIDOR 3'-0" 1-3/4" H.M. H.M A PA, CL ---- ELECT. [{QOM__ _ r3=•-o~·---1~7_•-=o· ___ i-~1-=3/~4'_' -,=H=.M=-~-11--'H=·=M~. --,~A~c-, LH1 , DB 1, CL ~ /), 11-'-1 -~1~7 __ 1-'-PU=M==P=R=O=O=M~-----1-"-3'_:,--0-_' ___ l--'-7'-"--0'-"-:--l--'1-"-3"'/4,_'_ll--'H'--'.'"M"-. __ 1--'-Hc,.M,c,~-lpE.J-'--I LH1, DB1, CL ............ 6. I'----""' 1.18 REST AU RANT 2 3'-0" 1.19 l-'-1.=2~0 __ ~R=ES=T~A~U~RA=N~T22~-----1-'3='·=0' ___ I,_7='--0=="--l-'-1-=3/~4_'_,~H=.M~. __ ,_~H=.M=·--irD~_,LH1,CL 1-3/4' H.M. ___ ,_H~-=M~. __ D LH2 REMARKS NOTE 1-f>JOTE 3. COORD,NATE WI O~VNER '>IOTE 1-NOTE 3, COORDINAII:. WI OWNER NOTE 1-NOTE 3, COORDINATE W/ OWNER NOTE 1-",JQTE 3, COORD·NATE W/ OW"IER NOTE 1-"lOTE 3, COORD,NATE W/ OW!'!ER NOTE 1-NOTE 3 NOTE 1-"IOTE 3 NO.,.!: 1-',iOT~ 3 NOTE 1 -NOTE 3 NOTE 1-NOTE 3 NOTE 1-NOTE 3 NOTE 1 · NOTE 3 NOlE 1-NQTE3 NOTE 1-NO~E 3 NOTE1-NO E3 DOOR SCHEDULE CONT. DOOR NO. 2_, 22 2-4 LOCATION WIDTH ELEV_ 1 MACHINE ROOM 3'-0'' STAIR 1 3'-0" ELEV 2 MACHINE ROOM 3'-o· 3.2 STAIR 2 3'-0' a-=~--1-==~-------,~~-- 4.1 STAIR 1 3'-0' DOOR HEIGHT THICK MAT'L FRAME TYPE HARDWARE --------------1---- 7'-Q"l 1-314" H_M_ 1-3/4" H_M_ E PA, CL E PA,CL 1-31°4" H.M HM _ A LH1, DB1 ,_ __ ,__,__ ___ ,_ ______ ,_ __ A PA,CL 6'-8" 1-31°4" H.M, _ __ H_.M=---1-=A~_ PA, CL "' 61-811 1-314' H.M. H.M. E PA.CL 1-'-'4.~2 --f-=ST.__./IJ=R=2 _______ f-=3•~-o~•--/1-8~'-~8'_,___ 1:_314~--H~-~M~_ H.M. E PA,CL 4.3 ELECT. ROOM 3'-o· 6'-8" LH1, 0B1, CL 1----5_.1 ___ ,__ST_AJ_R_1 ________ lr3~•=0• __ _,_ ,-6='-~8_" ·J--t--'-1-=3~/4_' _ ,~H=·=M~. -1--'--'H"".M'--_µE=',-~-PA, CL 52 STAIR 2 3'-0 .. 1-314' HM. E PA,CL 5.3 ELEVATOR 1 LOBBY T-o· 1-J/4' AL ,_A~L~--~-PL, CL 5.4 ELEVATOR 2 LOBBY 3'-0~ 7'-o· 1-314' AL ,_A~L~--1-=B __ PL, CL REMARKS NOTE'· NOTE 3 NOTE 1· NCTE 3 NOTE 1-NCTE 3 NOTE 1. NOTE 3 NOTE~-NOTE 3 NOTE 1. NOTE 3 NOTE 1-NOTE 3 NOTE 1-NOTE 3 NOTE 1-NOTE 3 NOTE 1-NOTE 3 NOTE 1-NOTE 3 NOTE:. 1-NOTE 3 HARDWARE LEGEND TYPE DESCRIPTION Cl DOOi~ CLOSE~ CB HEAVY .)llTY De.AD 3CL T L.OCK, KEY EXT, KEY .!\T DB1 HEAVY DUTY DE,\D 30L T LOCK, KEY EXT, T-T:Jq_/-,1 INT OS DOCR STOP HO DOOR HOlD OPEN LH LEV'ER HANDL'E (NC LOCK) LH1 HEAVY DUTY LEVER HANDLE WI LOCK SET, KEY EXT .. T-TUR',I INT LH2 LEVER KAND LE WI PRIVACY LOCK LHM HEAW DUTY LEVER HANDLES W/ LCCKS IJY DQO=!. MANUFACTURE.=!. PA PANIC HARDWARE PA1 r'ANIC HARDWARE (LCCKABU:! WI PANIC OVERRIDE) Pl DOOR. Pt.:LLS PH PIVOT HINGES TB 1-EAO &. FLOOR THqOW BOllS fO.,'{ PASSIVE LEAF Of !JOUBLE )OOKS V VERiFY WITH OWNER 'VER FY FINISHES WITH OWNER DOOR NOTES 1. TO BE DADE CO. APPROVED FOR IMPACT. G.C. TO PROVIDE SHOP DRAWINGS & N.O.A. No. 2. TYPICAL FDR ALL -VERIFY FINISHES WITH OWNER / V V v-,A 3. SEE ELEVATIONS FOR+ AND -PRESSURE VALUES. 1.23 MAINTENA.~CE 3'-0" 7'-o· 1-3/4' H.M H.M A LH1, DB, Cl 1.24 TENANT 7 ---,~ t:2J_3'--0" 8'-0" 1-3/4' AL AL C PL, DB, CL -A 1.25 STAIR 1 3'-0~ 6'-8' I'------' 1-3/4" H.M H.M E ,__ PA, Cl 1.27 ELEVATOR LOBBY 1 1-3/4' AL AL B PL, CL 1 .2B RESTAURANT 1 3'-0" 8'-0" ------ l-'-1=2~9 __ t--R~E~S=TA~U~RA=N=T==1 _____ ,-=3•~-o=·--.. a=·~-O_" __ t--'-1-~3~/4_"_,~A~L~--t-~A~L ___ l-'B~_, Pl, DB, CL I \ / 1 HR FIRE RATED HOLLOW METAL \ DADECOUNlY +---AP~ROVEDFOR LARGE & SMALL MISSILE IMPACT iMPACT RESISTANT DOOR DOOR TYPES ARCHITECTURE 285 Sevilla Avenue BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Gables, Fl 33134 305•444·4433 fax 305·444-0181 EMAIL: bdamlamiobellsouth.net 1-314" AL \ ,_A~L~ __ ,_B~_,PL,DB,CL \ -i--ALUMINUM STILES (NARROW) \ \ I / DADE COUNlY o-----APPRDVEDFOR LARGE & SMALL \ollSSILE IMPACT I ----+--i--1115• LM.,1, SAFElY GLASS /D.E\ '<:JI IMPACT ESISTANT STOREFRONT DOOR: I\olPACT SERIES 3000 BY ® ARCH ALUMINUM OR EQUAL B (N.OA 01-0919.02) NOTE 1-NCTE 3 I----~ ---------lf-----0----1-----1----t----0--- NOTE<. NOTE 3 NOTE'-NOTE 3 NOTE 1-t-.OTE 3 NOTE 1-NOTE 3, COORDINATE WI OWNER NOTE 1 • NOTE 3, COORDINAT: WI OWNER 'IOTE 1-NO IE 3 COORDINATE WI OWNE'R ------1------------- / / \ \ I I \ \ \ \ \ I ,~ II A-15 \ I \ \ I I /D.E\ \ / ~-+-----'< I'-------' \/ IMPACT RE I STANT STORE FRONT DOOR IMPACT SERIES 3000 BY ARCH ALUMINUM OR EQLAL (N.O.A. 01-0919.02) © --1-----1---1----1----1--- --t-----1----0----t----l---- __ ,_ __ -0---0----t----+--- / \ / I 1 HR FIRE RATED HOLLOW METAL \ @ SCALE: 1 /2" = 1 '-0" Proposed New Project I ) > > > > > > -. I f.5 HR FIRE /RATED "B-LABLE" / HOLLOW METAL \ ® I \ South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida 4. TYPICAL, VERIFY ALL ROUGH OPENING SIZES W/ DOOR MANUFACTURER. -- < • I DADE COUNlY -+--APPROVED FOR < LARGE & SMALL \ollSSILE IMPACT . ---- • ' ' ' • ' -' / date May 26, 2006 revision January 24, 2007 G.C, -R.F.I sheet title DOOR SCHED. project numbe1 drawn by D.M. 69 of 162 77 ! I I r-===============================------============--=-=-=--========~----===============================:;::::::::::==---;-;----•==·· ~=---:, I, ---~ . 12'-0" / / 2' 2'-8" or 6'-0" 2" 2'-8" 21· -,,_-•. ----~--, ,,, '"1 ,.,,.,_,I ---------1----,,F------1~ 5' 0 - 5' 0 -' ., ·' r-- I i ~:r--. -'s-- I 11· ~n- ----. _, :==="!,;;:.,=======~ i ' I'\,.~--~ I / \ I I V / ' 0 ·' \ a, 1\ \ \ \ \ I ',i/ - @ A'\ ~~ 13'-0" 4'-1 Xs" 4'·1X," \ I \ \ I I I \ . I\ - I/, I - 2" Jj. 11 // I ' < -o.;:::=- I ' ' !-< 5' ' "' 0 - ' ! ' I I <-,.~ .i co.1 ,- ' -@ A ~o/ I 6"~4" 11· r 6'-0" 2" -1~ /,'- I I 3'-6" /// l'1..1 .. ' -- .1'·1"_J._ / ,-, /2 --/ / - ' ! I '\ ' ' ' I ', i I ' ~ ' ' L I j ' ' ' ! ~ ! ~ -® STOREFRONT BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305•444·0181 EMAi L: bdamiamiobellsouth.net ---------- ' ' ' 4'-11/,s" --:s--N~ ' "' -·' -· --:s--N~ ' ' ~I ), JJ i I NOT USED ® -'\.--'\.-- ' I ! ~ - - 9 "' -'s--- ~ -'s--tO ; - I 11'·10" ·,: Jt 3'-81Y,s" iL 3'-B 1Y,6· ,·1 ii I i I I I - ' -© _...___.,..,.____ r:::::::::::::::::::::::::::--1::::::::;--;::::::::::::::::::::::::::::::::::::::::::-;:::::::::::::::::::::::::::::::::::::::::;-i bl' i -• I ~ -·------·--~ ·------------_1 _--_-------, --------=--- ' ' ' ' ' I l'=====I=:-:::' ' -® A"'\ /s-\ ';~ ""'Y 8'-0' 4•.om ' ' 1· r ~f 3•_9• ~]"~ 3'-9" 2" 3'-8" -/2' //- I I ----<-,.~ -'s-i-.~ ~ b • b N ~ ' ' ~ "' ;;. (n . ' -., ' ' I -·~ -"s-1-,_~ ~~N~ I ' i ' b b I ' ~ I "' j ' --@ ® - l ---7-1'- ' ' i --------- 11'-9" -----------•-----~ 21' 3'-0" ----------{{- . 2" /,'- I Ll c-========1 :=\==='='~--- 3'-11½" 2" 3'-11½" I , -__ ,,,,,___ _____ ,fl I\ \ \ \ / I 'r1-----/ @ - A ~1.,,REV , 8'-0" I r2-,-------4'--6-.. -------2-r ____ 3_•_0---2f. _,,,,,_j'-------------~,,_--______ 'f1' \ \ - \ \ • ~ ~ I I I NOT USED I '/ il1 - CD 0 - A'\ ~ 9'-6½" I , l ·2" 4'-6¼'' 2' 4'-6¼' /2' /( {,( -, I, I _..,___"_ ., ---_,. ~ • 0 ·' ' (\j i -r-- ' • '.? 0 -'° ' f.. I 11 -~[ ---~-----. -· I -@ SCALE: 3/8" = 1 '-0" Proposed New Project rt\. "<(17 8'-0" -----------/- 2" 4'-6" 2+ 7,,,___ ______ /f I • I > 7'-0" t ·· 3'-0' 21' 3'-6" : -{/---l-----1,,_• ______ r ) < i I i LLL --) I \ ~/ I; • 71 / I I I ' < / > I I I ' ) b ·' "' / • 0 \ &, \ \ > \ ' -=1\ \ \ \ .i \ \ \ \ \ " .I ' -® -@ A - 5 8'-0" I 2' 3'-9" 21' 3•.9• _,.;,_., _________ , ____ ,.,,_-, __________ _ 11 1f ,1'- -'s-----'\.-- ' '.? 0 - . 9 "' ~ -'-.-- '° '' 6'-0" Jt -1-~ 2'-9" ?)~ 2'-9" -1·1 ========== ========== -',-~&-N'!s--- b ' !-< ·' ---;- "' " -® - STOREFRONT & GLAZING NOTES LARGE MISSILE IMPACT RESISTANT PRODUCTS: GENERAL CONTRACTOR TO PROVIDE SHOP DRAWINGS All Storefront 1. SERIES L-3000 ALUMINUM WINDOW WALL SYSTEM BY ARCH ALUMINUM & GLASS L.C . IMPACT RESISTANT, GLAZED WI 9/16' OVERALL LA\< COMPOSED OF: 114" GLASS HS+ 0.09 lfl,NER LAYER 'SE~TRY GLASS PLUS'.,. •14• GLASS HS NOA #0' -0619.01 All Storefront Doors 2. SERIES MEDIUM STILE ALUMINUM STOREFRONT DOORS BY ARCH ALL.Ml~UM & GLASS L.C. IMPACT RESISTANT, DOOR LEAF GLAZED W/ 3/16" hS + 0.09 INNER LAYER+ 3116" GLASS HS NOAl!<J1-0919.02 3, ANCHORS SHALL BE OF lYPE, & SPACED AS Sf,OWN ON MANUF, SHOP DRAWINGS EMBEDMENT INTO BLDG SUBSTRATE BEYOND WALL Fl~ISHES OR STUCCO, 4. ALL STEEL 1N CONTACT WITH ALUMINUM IS TO BE PAl~TED WITH A COATl~G OF A HEAVY BODIED BITUMINOUS PAINT OR APPLY A NON-ABSORPT VE TAPE OR GASKET. 5. EXISTING STRUCTURE MUST SUPPORT THE LOADS IMPOSE.J BY G:...AllNG SYSTE~ 6. VE.HIF-Y All OIME.NSIOt-.S Pl{IOH. TO FAl3R.ICATI0'-' 7. STOREFRONT GlASS TO BE CLEAR date May 26, 2006 sheet title / revision STOREFRONT _,,__ I - -'s-N~-- ' ' !-< 0 . ' ---;- "' " i South Miami Municipal Parking Facility September 27, 2006 project number S.W. 73rd Street & 58th Avenue, South Miami, Florida March 1, 2007 drawn by D,M, : . . . . .... , . . ' 8'-0" ' 0 I -' ;.. • "" - - - - -__ i ' I I\ 2'-0" \ / / \ \ \ ' \ I VALET - -t= - 3'-0" 2f 2·..a~ /f --- @ -,;, -S c a I e: as showi;;: /,_ ' ' . sheet numb,)H, -·' ' ' / l I I I 70 of 162 78 Iii! A ~ 8'-0" I , J ' 2' 2'-2' ]'. 3'-0" 2" 2'-2' -h·, ,v I ·1 -'s-------'s--- ' " • , I I q "' ' ;:. i N, -',--~'-;: ' i ' ;( i I I I ~7. I I b l I I ·' V 0 ~ ~ /1 b F---i\ 1o I\ ' I i \ i I I i\, I \ NOT USED i i I \ -------.-'-.- i ~.i \ " ' -® ® A"'\ ~:7 12'-8" , --/-, 2" 4'-D" },!'. 4'-0" 2" 4'-0" 2' -/,'j ,,.;· /)'-- " 11 -~ i • 0 ' I 1'J I --' ---· I I ! b ' 11 b ~ '.'I ! " I I .-',.---- ' <D, " - STOREFRONT-CONT. BOT. OF DECK _J I I BOT.OFTEE ~ I INTERIOR I ALUM. S.F. FRAME PROV. SHOP DWGS 9/16" LAM. IMPACT GLASS srucco ~------ BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305·444-4433 fax 305•444-0181 EMAIL: bdamiamiobellsouth.net . ,___ EXT. PRE-CAST CONC. PA~EL EL 14'-4" $ B.O. SPANDRAL .,_,, _ _,_ __ PRE-CASTCONC. CLOSURE SPANDRAL / TENANT SIGN BAND ,---·--· .. ~,.... • I , I I EL 1 0'-0' T.O. STOREFRONT '----1" REVEAL ~ · STUCCO CEILING EL s·-o· $ DOORHT EL 0'-0" LEVEL ONE ~ ~:7 ,I-2'-5Y," I' 2" 2'-1½" 2'' -/I' ----·-/)'-- I ' - ·l -\L 7 5' N -'s--1, ' b ' b U) ~ ~! ' F---F--- U)~ ' _\ -..----, ,I <O ' I - I, 1. -;,' 4'-21.Xe" 2\' ,,·, 4'-2'½," ' , I i J: ! I i I ' . ,l __ A A ~REV "'.'.:7 I 12'-0" :f 6"-4" 11· I' )r 4'-2' ~t 3'-0 11 2" 4'-2" J,..._ 2'-11" 2r 2'-11" 2" ._,.; ,,.; ~' -rr /f 11 n ' I .. --.. . _.,____':,. ' I I ~ L:l l_ b ·' N ' I I ,, / ' 7( I I ' I / I / I I • 0 ' [\ i:o \ ' \ \ I LL. ' I ~ \ @ - A ~~ 33'-0" rt--4'-4'X," 2" ,,-6'-0" 1 l 7 . - , I, __ / i\ I \ I \ I I ' ' ' ~ I ' I ' ! \ \ I i ·, ! \ I I ' \ ' / ! \ I/ --\,; - SCALE: 318" ~ 1'-0" \ / -',.---- ! ! I I ! I 5' 0 -• <O ' F--- I .L . 4•.41,:'5" 1 2" ,,- I I ' I -- ! i ' I \ I /; I I I I I I _I EXT. PRE-CAST CONC PANEL I I EL 14'-4" $ B.O. SPAN ORAL PRE-CASTCONC. __ j__ CLOSURE SPANDRAL / TENAN f SIGN BMD i < . ALUM. S.F. FRAME ----., • • PROV. SHOP DWGS '\ -• EL 10'-0" $ T 0. STOREFRONT \ I ' 91'6~LAM. IMPACT ----H GLASS EL 8'-0" ~-DOOR lff [EXTERIOR! LEVEL ONE Proposed New Project -. - 4•.2 1X," '. . 71 11 ' -- ff I I I ! 4'-211/,," I ! \ BOT. OF DECK _j 1~ BOT. OF TEE \ I INTERIOR I I ·'\.-"'~- ! , • 5' "i O'> 0 ~ -' I , r-"' . ' .. /- 2" /)'-- i ' I ! A A"'\ } ~ 14'-0" ~:.:Y I 1r 3'-C 3'-4" 3•.4• 2" 3•.4• ·1,----2"111,2" -111 J, n -11 lJ1 I 11 ' " ,----I I I I I I I ~/I ~ I\ \ I I I' I ! \ \ -- A"'\ ~ {. if ~\ 2'-7" i'J ----11 f{ -'-.--'s--- • 6 - i ~L □CJ I " I • 'I' F--- .l "' i ... - - I ' . PRE-CAST CONG I CLOSURE SPANO~ • · / TENANT SIGN BAND I ' [EXTERIOR I 8" CM U. ---~lf-H 5/8" STU CC~--Ul+-IH ! I ' I ! i I !INTERIOR I ,f 2" /)'-- I ' .. date May 26, 2006 revision South Miami Municipal Parking Facility £ ~eptember 27, 2006 ..,.C .• R.F.I. S.W. 73rd Street & 58th Avenue, South Miami, Florida ' '. , 2" 3'-8" //--- -'\.-~:\ I ! I b • :t ' b 0, ~ ' i ~~ ,. ' sheet title STOREFRONT CONT. project number drawn by D.M. 2" ,,.;· ! i' / I ,, I ' A ~ 11 ·-o· ' ····---~ 3•.o· 21' 3'-8' f' -/~---------/;'- 11 " I , '9 ;.. 1-.. .. ---1 ----7?1 I Ir I b ·' "' I ·, Ll I I "'\ -... - ISSUED: 3-19 0 Scale: ASSHO\'V sheet i 71 of 162 79 r====================---------=============================~'."'.===----------===========-~---------------================----=-=-----=================-"'-=-~----------:-----~-c--.,,--~,-,.,,_.,---, SIM DNS OPEN METAL MULLIONS (NO GLAZING) OPEN GRILLE 1 OPEN GRILLE 2 \_ / (D\ 7 I OPEN GRILLE 1D I ~ lYP ~1 13'-4" 41 1_ 1r ---3----1½-,.-. -,:--3-----1½_2' __ -,1--3----1½-,---3--.-1½-,-f~r_ I ~f §N GRILLE 18 I ® ~ 9 ! @ 9 16 SW 58th COURT ELEVATION (WEST) CFEN GRILLES I OPEN GRILLE 3 -"-.=-~ 1<l I ' -~@)--- ~I N [ I { ----- EQ I EQ EQ I EQ I EQ , EQ 11 'r"";--;--r---,--;--,!- .-....-= .... ~-----l_ t--r---------i I OPEN GqlLLE 4 lYP ~f 8'-'.0½" 41 { ----------/~ I I' 4'-2¼" 2" 4'-2¼" 2" ! ",~----,~----/)'--jj__ ______ _ -~ ~- f OPEN METAL MULLIONS (NO GLAZING) I - ' " I OPEN GRILLE 11 I I OPEN GRILLE 131 4' 12'-0" 41 _,,_ ___________ _,'] 1 ~f 3•9;1,, ~ _3_'-9_o/._, .. _2,,_·_,_•.9'i_x_,.·_,.._~ Cj) 2 ' © cp 9 9 9 Cf) ' i 4i 5'-0" 4' -,------+,c t 4'-8" 2r, <'------,If-: 11, I I OPEN GRILLE 20] cp 6 11 9 1 9 m I ta:~ti1rt+-~t-~-:,J~--+=+141~~~~~t-:;=,._~t7----I J,Q) i ' I SW 73rd STREET ELEVATION (SOUTH) OPEN GRl'.LES 4' I i 9 -~~ I~ I 0 ' "7 :--"r- ~ 0 -' ~ ..-_~ ,-~ 0 -' • ' I -' .----~ 0 -·' ' 4'-0" __ _,_r _2_· -0-.. --2---0-.. 1 _, t , __ , __ II __JL_ OPEN METAL r.-ULLIONS (NO Gu\ZING) - j c-_ ----.--.-,rl 4T 1~10~ 4~ f~~~-3--.-~-y-, .. -2-.-3-'-4-1X_10_·_2_[_3•.-1-X-1,-.. -f~r 11----•----1 .)_ ----4-. -T~ ·Rg;;;;;;;;::::::J~~;;;;;;~;;;::;;;;~ I I I 8'-0" 2'-7'/,," 2'-71/,5 f 2'-7'/,," t (01 ii ----l -'\,,-"¢. ,,.___ \ ,,/ -",;;--..-_'1== (D\ / I OPEN ;ILLE 7 ;.'.. i ~: I ~--~l~=-========l --:,.-----. i---,----------i (f) (D\ / -[ OPEN -;qlLLE 5 ~ TYP 4! 11'-2" 4' /l _ 3~6 .. _ 1,_: __ 3·_-6_" ----3'-_6_ .. _t . -r ~~ i~~:::::::;::;!s==::::;::::::::::g:::::::;::;~rs-1 '-J ~ I " "' I ---~ 1 lir=~s~~=~§::::~s~ -~~~ ' I-/ ~ -. ---, OPEN GRILLE 141 lYP ~ ~ C 9 13, 9 I OPEN GRILLE 6 ~ --I..-_..,___ . ' "-------1 ' I ~II~ 1' I "' "" I lYP ~1 11'•1" 4Y H_,_r ___ 5'--3½-,.-.-----5---3-½-, .. --;t I ""I !l-------I I ---~,___ l~n======~====:=1i::J @-/ I OPEN GRILLE 1 s I lYP ~ C!? ~ ------------· -· ·t -- - ---~ --·- 6l I ' ... ~ "' ! ---. . -.. , . ~ •~4• M _,,_2,_/'_3-,_-1-01-Y,-, .. -3i-,-3--.-10-,-y,-, .. -2-.-3-•.-10-1 X_16_"_2~f T fri -·--·--, ® er cp ® ' I GID 6 @J 9 9 9 w - - - ---·---I -I I I -----I .I---. . .. ---~ '-~~~ ·' •·· --. ··--·1 + .. = 1i =• ' -----.r-----. ' •. I ,. . . ~' 1 .. 11 -··-, ·-·---· .. ---L.. --. - • l-·-~ ' ' --·-· +----' . --, .. --·--------. lYP 4" 5'-BQ 4'' _,,_2" ___ 5_•_4-.---;t rr -r 1 I OPEN GRILLE 111 ® cy ' ! g I g 6 9 9 I I i I -------. --. ----. . ' ----·-.~ -. -. .. , . . I . .I I I -{r=r . ~ -!.&\.., --·---+------. . I " I I ' . --.. -. lti,.j = -----i -r _n_ i I I ··---mil I 71+1,-··, ' ;:- EEH--~ .,~ ----rt.ma.-} ~ - - ~ •· I . --.. . -·---. ----. ., _____ ''.:~;---:;--:--. . ' . 11 -+-' ~ I 'I ---t·----~-----' -~ ~i -------- i I; I ,, ! kl 111 ------------I I I l'.:1 I I I . Ii -- SCALE: 1' = 30'-0" SW 58th AVENUE ELEVATION (EAST) OPE:.N GRILLE:S --~-~--s~CAL~E:~,.-,.,~.o- ALLEY ELEVATION (NORTH) OPEfl.. GRJLLES I OPEN GRILLE 9 Cj) (fl rv ! ! I 6 20 ! ! ' ,'= ~, ;;:' ~ ' . ------------. I I ,j I ~ ".t-. --r . --. I It ~ ~ ! --, - II -~ • f_,_ ' . . . ! I I r I ti ;1 -- -- ;.J I' --' . ' , * •~ I l-=========----...::::=-----'-===============================::;_...::::=========================:.:.._--.:::c..:..__ _ ___;;====================~...::::=====================;;;;;_,~-~~'.!4t;;,;;:,;:.:-~-I~••~· ARCHITECTURE BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305·444-4433 fax 305-444·0181 EMAIL; bdamiamiCbellsouthnet Proposed New Project date May 26, 2006 revision South Miami Municipal Parking Facility ~ August16,2006 G.C,• R.F.I, S,W, 73rd Street & 58th Avenue, South Miami, Florida :-•· ~II 3/8''=1• .. 9i•~")~ -, \~-t' ,, L'-, • J.: sheet title Sc a I e: OPEN GRILLES sheet numb~t;_; : 2 project number drawn by D.M. 72 of 162 80 i i: I :1·1: Ii 1i i , l ~ ~r ~ st.OP'i: 5.7% 4'DC -,f- ,Yp METAL STAIRS ~---\AETALPPERAJLING42"H WI 3,'4' PICKElS @4' O.C MN< " +7'' r--~rALPIPEHANDRAIL@ 34' A,;:_;:_ 3W PICKETS TO REJECT 4" DIA. SPHERE ;_· -' _;_L.__,_ :3.C. TO PROV OE SHCP DRAW ,'<US SCALE: 112" = 1'-0" ~,-' _____ ,_ ... _. ___ _ _,..,,.-.,1~ _ _ 6 TREDS@1'" DN_l_ !/ I , NON--SLIP Fir.! SH -i__ (:YP) -....____ MET."-.L ~IPE RAILING d.,!' H WI 3/4" r':CKETS --~ @ 4' O.C. MAX. MET,'",.L .:,ll·'l::. ~ HANJRAIL@ 34"A.F.=, G A-14 DN If- I I, 'c \ METAL STAIRS G.C. TO ?'ROVIDI:: SHO~ DRAWINGS "-A-14_/ BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305·444-4433 fax 305•444-0181 EMAIL: bdamiamiobellsouth.net SCALE: 112" = 1'-0" C @ ,, ~ ·' ~ ~ ~ ' "' " -i ' METAL PIPE RAIL1NG 4;!' H --~ WI 3/4' ?ICJ<;ETS @4" 0 C MAX. @ METAL STAIRS 'f I' H ,_L~----c I ~ METAL s-AJRCASE ---ME~AL Sll~NGE.R SCALE: 112" = 1'-0" l " " 0 ~ ~ u " " ~ EL +3'-6' Af~ TOP OF RAIL ~--1 1/2" METAL PIPE RA IL -- ~--314" METAL PICKET 4 1--METAL STRINGER ' I r---3-1/2•DIA.x4"D / CORE DRILL W/ / QUICK-RETE ANCH. ~ i GEM (TYP) --1-,[ , l C • •" . . -, ® TYP. RAIL DET. A-14 ", BOTTOM OF C STRUCT. DEC-< 'OC -~ V: p- I I LJ // - I ' ' I I ,. MAX~ ~ -~ ~ ~ v----,, ~ ' \ \ . \' ' \ REJECT 4" SPHERE SCALE 1-·rZ',.1'-0" •~8" STL BRAC~ET WI EDGE \:ONG EL +3'.6" AFF ~r-----------1 1/2" METAL PIPE RAIL ;:;,·' ·,,.--::,> ,---3/4• METAL PICKET 4" OC ~--METAL STRl~GER ,[ I • . ";i-.;_ 3.1,12• DIA x 4" D CORE D~ILL WI QUICK-RETEA."<CH. CEM. (TYP.) . ~· . ' . ,--.------<"lo;- t/11~. --r. ' TYP. RAIL DET. SCALE 1-112"=1'--0" REINF. CONG. --, SEE STRUCT. \\\ CONSTRUCTION --, \ ADHESIVE \ ' \ \ I \ 3-112Nx3-112" STEEL \ CORNER GLARD \ 35• H!GH FROM ~ \ FINISH FL. \ \ EA. SIDE \ \ \ b 4 -',-- ------ METAL PICKET 4' OC / METALSTRINGER / ,-STRINGER / ,....STAIR TRED I / ' : ' I I TYP. RAIL □ET. SCALE 1-1r.2"=1'-0" 4 4 CONC, ANCHOR BOLTS ~ >------l -'-c---- ' ·' - r ' . ·' ~ ~ ------- ITWffl[illl STEEL TRED WI NO"'J-SLIP CRISS-CROSS TEXTURE STEEL RISER STEEL 'C' CHA."'JEL FRAM!NG -• ,: C i;j ii' ®STEEL STAIR DETAIL 11' t TRED I / ,1,1vTE: ALL EXPOSED STEEL SURFACES TO BE PRIMED R 1' & PAINTED TO PREVENT RUST SEE MANUF. SPECS. FOR DROP-IN STEEL S".,.AIR INSTALLAT!ON SCALE: 1.1,12• = ,·-0· ~ BOTTOM OF ~• STRUCT. TEE··~ ' • ' D A-17 ,•: ,(- I ~ FINISH SLAB Proposed New Project ' ' • ' a • • • a ' • • ' . ' ' ' cl ' ' • • ' • ' \-- ' ' \ -\ \.__1------COMPRESSIVE FILL MATERIAL ,_ __ CONC. TIE BEAM SEE STRUCT. SEE DET. 'D' SHEET A-17 FOR UL FIRE RATING DESIGN CONTINUOUS r HORIZ, JOINT '/ REINF.@ 16" 8" CMU 1----- FILL CELLS WI CONC. SEE STRUCT 318" MORTAR: HORIZ. JOINTS CONT. VERT, JOINTS STAGGERED -CONC, SLAB SEE STRUCT. NON-BEARING C.M.U. PARTITION SCALE 3"=1 '-0" South Miami Municipal Parking Facility S.W, 73rd Street & 58th Avenue, South Miami, Florida @CORNER GUARD SCALE1-112'"1'0" ~ BOTTOM OF STRUCT. DECK~·- I HEAD I c---'1--+--+-~---ONE LAYER OF 5/8"ryPE 'X' 1 DR"f'v\'ALL I PLAN ~ ~' FINISH SLAB ,. I I • I 1 FOR O\IE HOUR RATING BY 0 UTURE TENANT 3-6/B" 25ga MTL STUDS SPACED@ 16"o.c. TO UNDERSIDE OF STRJCT. DECK PROVIDE HORIZ. BRAC1NG AS REQUIRED f--+------TENANT LEASE LINE / \ I I ' I ___ 3~5/8" STEEL RUNNER CHANNEL TOP & BOTTOM 1~ FUTURE SLAB BY TENANT I DEMISING PARTITION SCALE 3"= 1 '-0" date May 26, 2006 revision 7K July 17, 2006 G.C. •R.F.I I HEAD I ALL ,.OlNTS & SCREW !-<EADS ON OUTER LAYER TO HAVE T\'VO COATS DRY OR PRE MIXED JOINT COMPOUND, 2" W PERF. PAPER TAPE OVER · 'l't / ~\:',:';:;;:;t,Mo~,,, . ·7 I / EL 2' •o"AFF ~..._.. TC'POr= RA~ '°-'>---~ I ~----= ---...____ ~:JCT AL \f.'f.LL PRACKFT ~ 49M Or.. ~(1) 3/S• x 3• ;<vVIK HIL Tl 80l,. II ........_ 3.)L T ---------------COSC WALL H ~YP. HANDRAIL DET. <l " ,,. 10· I I 5' 1 ,r----r--,C 5' ' SCALE 1-1/2'=1'-0" ,,.,,---i-i12• H CONC. DOME TOP 6" DIA. STL. BOLi.ARC .,,,-(TO BE PLUMB) _ STEEL PL. ON 114" NEOPH.E.NE PAD 1-CONT. SEALANT // 1 /,-FIN, FL ALL METAL TO L. BE GALVANIZED (4) 3/4" EXP ANCHORS a• DIA. STL. BOLLARD CONG, FILLED WELDED TO STL PL TYP. BOLLARD □ET. SC/ILE 1 · 1'2"•'1 '-0" METAL STUD BRACING @ CEILING LINE ALL JOINTS, EWBEDDED -..,.,,---,J•--.,,..,-- IN rnTCOAT. jPLAN SELF TAPP NG BLGLE HEAD SCREWS TYPE S-12@ 12' O.C .. 1' LONG 3-5/8" STEEL RUl>.JNER CHANNEL TOP & BOTTOM F1NISH BASE I UL DESIGN No. U425 I @1 HR. PARTITION (TYc~~ 3 .. = 1 ,_ 0 .. ISSUED: 3-19-d sheet title Sc a I e: DETAILS sheet project number drawn by D.M. . , . , , . . ~ 73 of 162 81 ' ! I I r---:-:-============================---==============-===========------------================--:-:._=-:-:_"."".' __ -:-:_===============-""~==-~=--::.-"': ==-=~ ' '<J ' <;, <J '<:J lc=i <;, ' A,1.jQ-IORS@ '2" O.C. AS REQ") BY CALCUlATIONS ---- 1 <1 £1 ' .......__---:__ • I ---..._:, SHIM'l4't./.AX7_ 4 <J SEALANT ,-----/ CONC, H=.ADER "' !EXTERIOR I - -- \ ' \ ' ' SEE STRUCT, '-ALUM. FRAME ~ 9116' L.AM1NATED / GLAS8 VINYL \ BLOCK INTERIOR I H-63 ~SETTING I ~ ' "',!,!==Iii-ALUM. FRANHO 5--IIM • 14" ~',AX ~ '"m L o o r--1 SEA!ANT I <1 CO~C. SILL~ SEE ELEYATIO"IS £1 <l <1 STOREFRONT @HEAD & SILL A SCALE 3"=1'-0" r-CONC, / SEE STRUCT / ALL..M. FRAME I/ /~ ANCHOR9@'2"0.C. , I I AS REQ'D BY I I CALCULATIONS '<:J <;, ' /;! -q - J " - ---ALUM. STILES -.. I \ IINTEcR!OR I / // l-v, 100 T/\?E --\ \\ / D.C. 795 I \ / /~ SILICONE --1 ', \ -q L -= '? <;, 17 <J I / / 7,'18" LAMINATED \ \ \ /. 1-GLAss ~ llr\====~1 H,3 wEATH~ 1/4' MAX. SH,"A Q. SEALANT ~l 1½" L ~- 1 f X• ' WEDGE I .,.. I ,A~~l·N~fLF ' I ,1.· I 3-¼" I s)\· ,;--f SCREW ;f---,(, ;- ' ·1 I EXTERIOR I -r E, ' \ 1 A-15 1 STOREFRONT DOOR IN MASONRY OPENING ' _, - --~~.--~ __ · ' . --; I --i C • . -. . .,-V" V ...,.- SE!;. STOS::EF~ONT--1 SHOP DAAW1NGS \ \ \ I ) FAS~ENERS ~ ASREQ SEE SHOP DWGS .. ,--_/'- ' !INTERIOR I I O C !EXTERIOR I I Jmr= \~AlUM FRAME 9.116' IJ\.M,NATED GLASS STOREFRONT @ HEAD SCALE3"=1'-0" BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 265 Sevilla Avenue Coral Gables, Fl 33134 305·444·4433 fax 305·444·0161 EMAIL; bdamlamiobellsouth.net SCALE 3"= 1 '--0" !EXTERIOR I -' - ~ 9i16" LAMINATED / GtASS Vt-.YL BLOC-< H-63 ~ SETTING -~ ~ -~,.....ALUM.FP.AME i...__ALUM. FRA.....,E ~--#10X11W F.H. SGR<:.W ~If-----ALUM. RAIL Jfflltll------Y:2100TA:,E ,,____ D.C.795 -----SILICO~E _IIIJ::------7i16" ul.MINATED GLASS WEDGE #e F.H SEL= --+--~ TAP?l"IG SCREW ALUM. THRESHOLD--+-~ \ \ ANCHORS-------; AS REGl'D 3 PER LEAF 1-1.'2" lvl,N Evl8ED (INTERIOR I STOREFRONT DOOR @HEAD & SILL SCALE 3"=1 '-0" STOREFRONT & GLAZING NOTES LARGE MISSILE IMPACT RESISTANT PRODUCTS: GENERAL CONTRACTOR TO PROVIDE SHOP DRAWINGS 1, All Storefront SERIES L-3000 ALUMINUM WINDOW WALL SYSTEM BY ARCH ALUMINUM & GLASS L.C, MPACT RESISTANT, GLAZED WI 9116' OVERALL LAM, COMPOSED OF 114" GLASS HS+ 0,09 l~NER LAYER 'SENTRY GLASS PLUS'+ 114' GLASS HS NOA #01-0619 )1 2. AH Storefront Doors SERIES MEDIUM STILE ALUMINUM STOREFRONT DOORS BY ARCH ALUMINUM & GLASS LC- IMPACT RESISTANT, DOOR LEAF GLAZED WI 3/16M HS+ 0.09 INNER LAYER+ 3/16" GLASS HS NOA#01-0919,02 3 ANCHORS SHALL BE OF TYPE, & SPACED AS SHOWN ON MANUF, SHOP DRAWINGS EMBEDMENT INTO BLDG SUBSTRATE BEYOND WALL FINISHES OR SlUCCO, 4, ALL STEEL IN CONTACT WITH ALUMINUM IS TO BE PAINTED WITH A COATING OF A HEAVY BODIED BITUMINOUS PA!NT OR APPLY A NON-ABSORPTIVE TAPE OR GASKET. 5, EX:STING STRUCTURE MUST SUPPORT THE LOADS IMPOSED BY GLAZING SYSTEM, ,;, <J <;, SE:E SlORHRONT SHOP DR.AWING3 [1NIERIOR I 18(1 E:RIOR I \_ PRECAST PANEL '-q STOREFRONT @JAMB SCALE3"=1'-0' Proposed New Project !INTERIOR I CONC SEE STRUCT - -q --,,l,LLJ\ol. f-HAME ;· AN Cr ORS@ ''Z' 0 C. <;, -q -q <;, 114"MAI(. SHIM !EXTERIOR I / ' ,-AS REQ''.J SY / CALCULA'IOr-.S / _L / ,-----91113' LAMINATED t r,:=;1;/ / GlASS I <J IN1E:KMCIJIA·E MULLIO~ WHERE OCCURES @ STOREFRONT JAMB A-15 IMPACT SERIES 3000 BY ARC ALUMINUM 71J~E STEEL --~ WELD TO S:"L PLATE \ ALI,.,~. BREAK ye-,u SCALE 3"=1'-0" -op & BOTTOM / ANCHOREDl'HOCONC, '\ ; TO MATCH STOREFRONT S[ESTRUC7JRALOWGS /.:4"MAX.+ '\ I SHM -~J'--- / j I #14 TEI( scR;;:vvs _______ F~=,=l!i!c=z=!l=i!l=i!i=i!i=!!!l='i't=:;1 ,... 9,116' LAWMTED @. '2' O.C, ~ , ~' -\ GLASS SEE SHOP DWGS ~ "'ti\ r-\ ', !EXTERIOR I !INTERIOR I - STOREFRONT 1ri=\@ STL. COL. JAMB SCALE 3"=1'-0" South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida -q 114" Wo4.X_ SHIM - A-15 <J ~ 80NC / SE:.ES.IRUCT / ~ ALU\4. FAAME / //,-_____ ANCHORS@12"0.C. V , ;· AS ~EQ'O 3Y / / CALCULATIOf\S I _/ ,-9/15' LAM,NATED i / GLASS ' -' -' ----ALUM STILES ~, I \ PNTERIOR I / ,------V21JQTA.r'-=: --\ \ / / \ I / DC795 \ 1 1-SILICONE ~ \ \ / 7 11!!' LAMINA1ED \ \ \\ ' ' \ \ ; , ,-GLASS -~\i_ -IHJ 'r'/EATIIE:C:1NG I ~/ , )s; F\"==,i\ ~ I I 'NEDGE 1113 F.H. SE:LF ""!"Af'PING SCREW ,y.• _,,__,_, ____ , !EXTERIOR I STOREFRONTDOORINSTOREFRONTSYSTEM IMPACT SERIES 3000 BY ARC ALUMINUM SEESTO~E~RoNr~ - S! !OP DU WINGS \ \ \ \ 1,----------ALUM. FRAME I I -9J1B' LAMINATED FA$1E:NE:.RS ---~ ASREQ -...._ SEE SHCP DWGS \\ GlASS ~ 10= !INTERIOR I D 1~xTER OR I I I lfJ-J _, - STOREFRONT @ JAMB SCALE 3"=1'-0" : l!I r-VERIFV Fl~ISH ~ni q <I 1/ I 1' ~--CONC. LINTEL SEE ~ S':RUCT. DWGS _\11 11 _,,.,,,, . I ------ANCHORS (2@ HEAD. 3 ,£1 , ' , , V DADE COUNTY 11 <1 'H I __,,,,,.-@EACHJAMB)ASPER 1~ REQUIREME.'•ns VER!FY 0 ,VSH_/ ~"'~-~-7'1-7"1 ;::7' . .,,...;-:;:t• -------"-~---~·,:~ !::...;._' -~ ·-. · ,.. · -.-. I _ ·. l ... ·-,: ~ -·~ ·· >i \\~f-i ', '. ~; ---------HOLLOW MET AL FRA\1E (FILL WI GROUl; HOLLOW l,IC:.TAL----1 DOOR IEXTCRIOR I A-15 ' -uir- H.M. DOOR HEAD/ JAMB sim. !INTERIOR I SCALE 3"= 1 '-0" SCALE 3"=1'-0" ISSUED: 3-19-' date May 26, 2006 sheet title revision DETAILS ill October 25, 2006 G.C, -R.F.I project number drawn by D.M, 74 of 162 82 n ) . . . .. •, .. .' . .. . r CONCStAa $EE ST~l,K;l . . .. . . ' . ' . ' V • V V . . . • .•c., •". . • ' . . ' \ \ L 1 ~E'/EAJ.. L_ 5111"-\Y'E'~ Ch,,_'INEL ST~CCO ~ . . I 1 REVEAL _J CHl\~Nfl a'Vl'.: . . V . 1 &E STORlfllONT DRA't,'1NGS < @ STUCCO CEIL~~~ 1112 .. = 1 __ 0 .. I I I ,I 8 ____ ...JflJr---....J..I NOTE: • • . ' • • • • ... ,,,,,,.----CONC. PANEL. .,,..,,..,.-, SEE STRUC1. _../ --ALUM. / STOREFROt,, T FRAME A.LUM. TUBE __J 6" ,di" A.LUM, C!-.ANNEL l SECTION AA G.C. TO PROV DE Sf-OP DRAWINGS. FRONT ELEVATION I -" 8'-3' AFF \.'1B.O.STEM DECORATIVE ALUM. FRAME -IN PRE-CAST PANEL OPENING \A-16., - I O I -- . . . .. .. ---- fEXIT~, ==== ~ 1 LLUMINATED EXIT SIGN FLEXIBLE PENl)AN f MOUNT. DO NOT OOUNT !N DRIVEWAYS. SEE LIGHT FIXTLRE SCHEDULE I SCALE 3"=1 '-0" / STRUCTURAL PRE-CAST /1 TEE UNITS. SEE STRUCT. I ' ~ :.□ ~GH~ FIXTURE, PENDANT MOUNTED WI BIRD SHROUD. SEE LIGHT FIXTIJRE SCHEDULE .. • • • . ' ® LIGHT FIXTURE MOUNTING SCALE: 3/4" = 1'-0" BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444·4433 fax 305-444-0181 EMAIL: bdamlamlobellsouth.net . . EDGE CONG\ - . ' • ~2CACAL'I. ST\. /-1-W.GE~ WIRE ,,/ WR.A.? 3 F'J•_L '.MES SPA,:E @4' 0 C . '1_ MAN RL,NNER / CEILING ___/ TILE VERIFY FINISH W/ OWNER r-3/4"ALU~.TUBE ---+-•I----'>-' WELDED ALl,M ~ ANGLEW/1/4' \ TAP CON SCREWS \ \ •, j' 3'' ROUND ALUM Pc.ATE -r--~~~~ l===I~ ,,,------rvETAL STRINGER •• / REQUIRED ~ A -~ ----✓ • • • --,£----k--\ f-------1' ./ I ) !,,i '-. !-.I ,...._~· ~• -•~/. ' :~ --'-'jf"-al.a~,o-T_E __ ..::.,i, ______ _J -· /'T\ DECORATIVE RAIL DET. ~ I G.C. TO PROVIDE SHOP DRAWINGS. I Ir · ."d THIS RAJL1NG IS DECORATIVE ONLY. IT IS LOCATED ONLY ALO'JG THF EXTERIOR FACE OF fHE i3UILD1NG THAT IS NOT ACCESSABLE TO - THE OCCUPANTS OF THIS STRUCTURE - IG'\ DECORATIVE RAIL DET. SCALE 1-112',.1'-0' \.A-16J6 -...._,,, SCALE 1-1!2""'1'-0" -r----·-,-,-r-------·ihr,,-----.'\-. -,-~- .r.:_; 6 I \ ?;=i;ECAST~ COIIIC. ~A.~EL 1'R!:VLJ\l.__', ChM!';~L "YC ., \ \_51!rl-A."E~ STJCCO ,@DETAIL . . . . . - " . -0 ., [INTERIOR I IEXTERJOR I • V V SCALE: 1 1/2" = 1•-~--J --- Proposed New Project #9 w:~E@4'--0' 0.C. TO _____ J ~ co,_o ROLLEO CHMjNELS / I... @4'--0"0C . STRUCTURE ~-,~-~-~~~~_L ~ -' 1 J\. I ./\.C. • ', ' \ 5/8"TYPE"X'l0 _j PREV!::r--T SAGGING \ I ''-4' O.C I 1 \ ,_ ____ -'-'-. ____ f _718"STEELHH-v\1S @16" O.C @DRYWALL CEILING ~c~~!-~~ .. <l <l <l ~ <l / -co;..,,c. PA."la / SEE STRUCT, / f-1 ,,,r-ALUM _.,/ S";OREFRQf,jT ',14" TAf'CO~S I/ @•2·0.c. DECORATIVE ALUM. FRAME , H \ IN PRE-CAST PANEL OPENING 1 A-16 1 JAMB/ HEAD SCALE 3"=1'-0" South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida . . ; . I ' I -: ' I , I ' ' . 4" • I l ' -SPANDREL bEAM "'. ~ ANCHO'.'l'3 IS ~ REQU,RED ~ I ~ ALUM ANGLE ------'~ ~ 2"x4'ALUMTUBE )======I i==f'::,--..___ 1' x 1' ALUM TUBE / ----SPANDREL BEAM ~ALUM ANGLE l)::n===:=·;;;;::~==t==::;z~~~~,'.::::j/' / ANCHORS AS -11 II , ' / _. " REQUIRED II II "· I( / . . 1,,-1 I I II. 'I·,, t · J •• • INOTE: I G C. TO PROVIDE SHCP DRAWINGS. @ALUM. GRIL~C~LE: 3/4"= 1'·0" I I . ' <l = <l <l =I / / CONC. PANEL SE.E STRUGT _ ALU~ STORErRONT ~ 1/4' .,.APC_ o_Ns / @'2"0G DECORATIVE ALUM. FRAME ,'J\ IN PRE-CAST PANEL OPENING \A-16/ JAMB/ HEAD SCALE 3"=1 '-0" date May 8, 2006 sheet title revision DETAILS October 25, 2006 G.C.·l·lFI March 1, 2007 project number d,awn by D.M. 75 of 162 83 j r;=---------==~===----=======-=============================-----==============--=====---------==-----============--=--------===============-----··=====--------=~ r-------------------------------------------------.--------------------------------------------------,-------------------------------------------------, ~1__________, MIN. 4" THK FIRE RATED CAULK IF IN WALL, ENCAPSULATE BET\A/EEN FORMING MATERIAL REINF. CONC. NOR.~. WEIGHT 6H THK MIN. WI MAX. ~o• DIA. OPENING 1 ..,-,--OPTIONAL STL PIPE SLEEVE 10" DIA NOM. SCHEDULE 40 CAST OR GROUTED INTO CONC '\"'-'•-_ll___sl\-___jL___. ---\-1AX_ 6" DIA GALV. STEEL CONDUIT, MIN. SCH, 40 SUPPORT HANGARS-~ GA. STL WIRE BENT IN 'U' SHAPE ¼'\X.5"0.C. LOOSE CERAM!C FIBER FOR.rv!ING MATERIAL-1" THK BOARDS W i UL LABEL FRJCTION FIT IN OPENING MN. 4" BELOW FLOOR LEVEL IF I~ WALL, PLACE EQUALLY AT EACH SIDE OF WALL RATED PENETRATION SECTION 'A' lu.L. SYSTEM No CBJ1007 A CONDUIT THROUGH REINF. CONG. FLOOR OR WALL ASSEMBLY A-17 SCALE: 3" = 1 '-0" L._ I ' I I ! ! ' I ' I i !). - -, I I I CONC. BLOCKS ;;-CLASS D-2 (2HR) II BEARING 'UL' LABEL I ' ' / I ! ' ' I I I '. i ; : ' I ' MORTAR 3/8" THK. r-2-1/4 MIN. 3.•12 MAX PARTS SHARP I CLEAN SAND TO 1 PART PORTLAND / CEMENT. 50% MAX HYDRATED LIME / HORIZ. JOINTS CONTINUOUS, ! ! VERT. JO.~TS STAGGERED i I ' . ' I ' I I I ' I ' I ! I I I , I . I,.... ! 1 1 I 1 ' .., ' I I I J v/ I I ! I ! \,. I ! I I I I/' ! i : /' ! . I I / ------; I I LOOSE MASO~RY FILL; ____j,,- IF ALL CORE SPACES FILLED W/ LOOSE DRY EXPANDED SLAG, EXPANDED CLAY OR SHALE, WATER REPELLENT VERMICULITE MASONRY FILL INSULA~ION, OR SILICON TREATED PE.R.UTE LOOSE Fill INSULATION, ADD 2 HOURS TO CLASSIFICATION. ,, I¼ 1 ' I --- ' , I I I I I I I I I ! i i 11 I ' ' ' I , I ------T ---- ' PCRTLAND CEMENT STUCCO: ___/ IF USED ADO 1/2 HOUR TO CLASSIFICATION WHERE COMBUSTIBLE MEMBERS ARE FRAMED IN WALL, PLASTER OR STUCCO VIUST BE APPLIED TO FACE OPPOSITE FRAM.ING TO ACHIEVE A MAX CLASSIFICATION OF 1-1/2 HOURS. I U.L. DESIGN No. U905 D 2HR BEARING/ NON-BEARING WALL ' I " I I I i i I ' ! ',- --, '-- I ~ ! ' ' i ' i i i - - --- A-17 SCALE: 3" = 1'-0" I U L. SYSTEM No. Wl5028 5/8" TY"PE 'X' DRYWALL (U.l. CLASSIFIED U300 OR U400) {ONE OR lWO HR RATING) (2 HOUR SHOWN) HIL Tl FS-ONE INTIJMESCENT FIRESTOP SEALANT MIN. 5/13" DEPTH FOR ONE HOUR RATING MIN. 1-1/4" DEPTH FOR lWO HOUR RATING TO BE ONE OF THE FOLLOWING· a.) MAX 4" DIA. NOMINAL STL. PIPE (SCHEDULE 40 OR HEAVIER) -r+---+----t b.) MAX 2" DIA. NOMINAL COPPE.R PIPE c.) MAX 4" DtA. NOMINAL EMT. d.) MAX 4" DlA. NOMINAL STL. CONDUIT MAX1MUM 314• THICK AB1PVC FLEXHLE FOA.M PIPE INSULATION NOTES MAX1MLM DIAMETER OF OPENING= 7-1/2" ANNULAR SPACE:= o• MIN.: 1-1.12" MAX F RATING= 1 I-.ROR2 HR T RATl~G = 1 hR OR 2 HR INSULATED METAL PIPE @THROUGH ONE HR. OR TWO HR. DRYWALL ASSEMBLY A-17 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444·4433 fax 305-444-0181 EMAIL: bdamiamiobellsouth.net SECTION 'A' .. ,,,,,,.,, ,,,,,,.,,. ......... ., ... ., . .,.,,.,.,, .. ,.,.,, - MINIMUM 1/2" CROWN HILTI FS-ONE FIRESTOP SEALANT AT POINT OF CONTACT. E:3" = 1 '-0" MAX. 6" JIA STEEL PIPE ~--MIN. SCH. 40 ' ______ 1 __ -f--~~/~/--r-,-FYRE-SHIELD 1·112~ MIN. SEALANT APPUED WITHIN OPENING FLUSH W/ TOP OF FLOOR OR BOTH SIDES OF WA.LL. _,,---PRE-RATED CONG, FLOOR OR WALL ASSEMBLY. 6N MIN. !--,=!eeJ--PIPE COVERING NOM. 1" THK. MAX. FIBERGLASS INSL.LATION ANNULAR SPACE 11/15" W1THIN FIRE STOP SYSTE'v1 MIN, 3" PACK1NG MATER:AL CERABLAN:<ET-FS OR CER. FIBER INSULATION FIRMLY PACKED INTO OPENING AS PERMANENT FORM. JU L. SYSTEM No. CBJ5005 --..,____ SECTION 'A' ----------~ /"C- • . ' ... ,. ,.,.,. """'!, . • ' < · .. ,. •,• RATED PENETRATION -INSULATED METAL 8 PIPE THROUGH REINF. CONG. FLOOR OR WALL ASSEMBLY . :• • A-17 SCALE: 3" = 1 '-0" J U.L. SYSTEM No. WL2098 518" TYPE 'X: DRYWALL (U L. CLASSlf: ED U300 OR U40C) (ONE OR MO HR RAT.'.\IG) (2 HOUR SHOWN) MAX. 2" DIA. :-.IOMlNAL .--+---+----PVC OR CPVC PLASTIC P!PE (CLOSED PIPING SYSTEM) ---HILT1 FS-ONE NTUMESCE.NT FIRESTOP SEALANT MIN. 5/8" DEPTH FOR ONE HOUR RATING MIN. 1-1/4" DEPTH FOR T'f.'O HOUR RATING NO-ES: MAXIMUM DlAMETER OF O?ENl~G = 4-318" ANNULAR SPACE= 3/4" M1N.: 1-114" MAX. F RATING= 1 HROR2 HR T RATING= 1 HR OR 2 HR L RATING @AMBIENT= LESS 1HAN 1 CF\lisq~ L RATING@ 40QA F = 4 CFM/sqft. CLOSED PVC/CPVC PLASTIC PIPE SECTION 'A' E A-17 THROUGH ONE HR. OR TWO HR. DRYWALL ASSEMBLY SAND CEMENT GROUT, 3500psi, ------. ALONG FULL LENGTH OF JOINT '\ UNLESS CONC. TOPPING IS , USED. WELD TIE PLATES MAY \ BE USED IN CONJIJNCTION W/ \ GROUT \ \ ' ' \ 4'-0" MIN 15'-0" MAX SCACE:3" = 1 '-0" \ ~r,..------.-. -.-, -. -----.,-. --. -------1 q -:-:- I RESTRAINED END I -I / NORMAL WEIGHT CONC. Slfl.GLE OR DOUBLE__/ TEE STEMMED UNITS (BEARING 'UL' - 3" MIN / CLASSIFICATION MARKING). OPENINGS MAY BE PROVIDED FOR PIPING, DUCTS, AND SIMILAR SERVICES AND SHOULD BE SUITABLY PROTECTED WITH EQUAL FIRE RESISTANCE I UNRESTRAINED END I H PRECAST TEE A-17 RESTRAINED 1 HR/ UNRESTRAINED 1 HR I UL Design No. J942 Ratin - 1 hr. Scale : N.T.S. Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida JOINT TREATMENT MATERIAL FLUSH TO TOP OF SLAB. CHEMIE LINZ-IN TU MEX SOR EQUAL. MUST HAVE "UL" LABLE 'JIN. 4" MINERAL WOOL INSULATION W/ 4 pcf. MIN. DENSITY, TIGHTLY PACKED INTO JOINT. d d STEEL REINF, STRUCTURAL co~c. SLAB, SEE STUCTURAL DRAWINGS FOR DETAIL ;:l •· .. 1 b4- C EXPANSION JOINT "' <I, d, ;:l ;:l "' d "' d' " .. ' ,1 "' .. d "1 4· ., I UL Design No. J900R I A-17 Scale : 3" = 1 '=0" I U.L. SYSTEM No. WL 1085 5/8" TYPE 'X' DRYWALL (U.L, CLASSIFIED U300 OR U400) (ONE OH rwo r<R RATING) (2 r'OUR SHOWN) TO BE ONE OF THE FOLLOWING: a.) MAX' 2• DIA. NOMINAL STc., PIPE (SCI-EOULE 10 OR HEAVIER) \\t---t-----1 b.) MAX '2" DIA. NOMINAL CAST IRON PIPE METAL PIPE c.) MAX 6" DIA. NOMINAL COPPER PIPE d.) MAX 6" DIA. NOMINAL EMT, e.) MAX 6" DIA. NOMINAL STL CONDU1T ....___ HILTI FS-ONE INTUMESCE'H FIRESTOP SEALANT FORCED INTO ANNULAR SPACE TO MAX. EXTENT POSS BLE NOTES MAXIMUM DIAMETER OF OPENING= 13--~/4" ANNl,;LAR SPACE= ow MIN.: '/4" MAX. F RAT1NG = 1 HR OR 2 HR T RATING= 0 HR L RATING@ AMBIENT= LESS THAN 1 c~M/sqft. L RATING@ 400" F = 4 CFWsqft. ~---- -z • i "' ' N -~ ' :!, -~ F THROUGH ONE HR. OR TWO HR. DRYWALL ASSEMBLY A-17 SAND CEMENT GROUT, 3500psi, ---, ALONG FULL LENGTH OF JOINT \ UNLESS CONC. TOPPING IS \ USED. WELD TIE PLATES MAY \ BE USED IN CONJUNCTION WI \ -, GROUT \ ~/~ \ 4'-0" MIN 15'·0' MAX w:%'1% ___ --l \ -. ' ,---,,--.. ------.--,-, ..... -,------------, ■ 3"MIN_,_ : / / 1/, ~ml ;fff;::)i "~ /?!ff%_// ~/$;:?';/!;, ! ! I ! ! I I ! I II SECTION 'A' RESTRAINED END I NORMAL WEIGHT CONC. SINGLE OR DOUBLE __J TEE STE~MED UNITS (BEARING 'UL' CLASSIFICATION MARKING). OPENINGS MAY BE PROVIDED FOR PIPING, DUCTS, AND SIMILAR SERVICES AND SHOULD BE SUITABLY PROTECTED WITH EQUAL FIRE RESISTANCE !_ 3/4" FIBER, SPRAYEO, WI UL MARK, SPRAY W/ WATER IN ONE OR ~ORE COATS TO FINAL UNTAMPED THICKNESS TO CONC. SURF. FREE OF DIRT & OIL. TAMPING IS OPTIONAL. MIN. AVERAGE UN TAMPED DENSITY IS 13pcf W/ MIN IND UNTAMPED DENSITY OF 11 pcf. A-17 PRECAST TEE RESTRAINED 2 HR/ UNRESTRAINED 2 HR I UL Design No. J804 3" MIN r- I UNRESTRAINED END I Ratin -2hr. Scale: N.T.S. ISSUED: 3-·19 date May 26, 2006 sheet title Scale: revision DETAILS sheet --r.:::-July 14, 2006 ~ BLDG OE.P. COMME:.'HS project number drawn by D.M. 76 of 162 84 -========~=========================----=-----========================----,--==========================''~"" -=c.."===~=== -------_,., ·---w :zc::_ • • ,----------------------------------------------------------------r-----------------------------------------------------------------.---------------------------------------------------''c,,-,,-,,~--------~-~--+,--, BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305•444•4433 fax 305·444·0181 EMAi L: bdamiamiobellsouth.net Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida SLCPE l/S" CONG. WAL_ SEE ~ .'<J STRJCnJR",L DRAWiNGS TYPICAL <l /,-METALCO-'ING I !~ 3-PLY BASE FLAS<"ING SYSll:::M (2-Pl.Y, 1 / • \i!OP 3ITUMOUS) GAF X M I . I I / / .-2"x5-5.'B"PREMA"JUFACTJREDFIBER I / I CANT STRP SET IN FU_L BE:.D HOT ' / ASPHALT I I I I I I I I 1 <J 3UILT-UP C::.00;-ING \1EMBRANE FINISH NOT S,--iOW',j ·-STRUCTURAL REINFORCED CO._C, SLAB. SEE STRUCTURAL DRAWINGS @PARAPET DETAIL SCALE: 1-112" = 1'-0" I 2·-0· 2'-0" I BLILT-UPROOFING s SYSTE\1 \ 111 I I NOTES: 36" X 36 LEAD SHEE-ROOFING FELTS IN MASTIC, PRIME -;-op SURF,~CE BEFORE STRIPPING ME:MB~E i>UES, ME~A-FLASHING AND FlAS.--1-1'1 r'Llt.S E:.XlE:NU Ji'<Wt.R. CLAVIPl"JC. RJNC. 1/0frll:..E ,t..SPHAULT IS STILL HOT. STRIPPl,"IG FEL -rs EXTE.'ID 4" A.-.!) s· BEYDND EDGE OF FLASH1NG SHEET. STRAINER /,-METAL Fl.ASHING I r SLCPE RIDGID I-..SULATION , i 112• PR FOOT TC DRAIN ,NA / / 'Z-0'" SQU,!,RE MOUND DRAJN I I 1 I I I 111 I I -' ' '-RElr..iF. STR..tCTURA.L CO'IC. SlAB SEE sr;;:ucruRAL DRAW,NGS ....... ~ .................. .....___ MN. 6" PVC AA.N WATER LEADER. TO CATCH BASIN BELOW. SEE ?LU\!BING C~WINGS @ROOF DRAIN SCALE: 1-112" = 1'-0" r ~ASTIC & ME.M3RANE SEA.A.NT@ / SIDESOFMETAl.LINER ·o- // -4'lo:24"x22git GA~V META~ SCU?PER LIN:CR W/ 4' ROOF SIDE FLANGE: & I GUSSETS@8'0C FU~L'I' / SOLOE:.RED SET 4' ~IN ,NTO I I PRE-CAS-SCUP"'ER MOD, B: n .. MEN / HASHING 3t.'l'ONO / , BASE FlASHl'.'<G BEYOND TRIM@ MET AL LINER ON / / / CPE\IING & FOLD FLAP l'ITO SCUPP€R Bor-oM ~ SLOPE 1-a;L I/ / :30TTOM Uf" SCUPPER ~ / <- ~BQTTOMOs,SCUPPEBYAR,ES i '~,. , >~ ~-• ~~ S ~ t I ~c_---• ,rt',;\(Y>Ji( '.:: ; ~ ~,...,.l~:""'"i'leT' .. 1"1 .. 1, ... 1 .. 1-11~1 I ,/ ' <J .~---SlRUC-URJ.l. RE.INl'-CRCED .-, , CONG. SlAB. SEE II _. .-,4 S1RUC""URAL CR.AWINGS PRE-CASTCCNCKc1ESCUPPES _// / SEALAST & "lA8 I IC BEAO / AROJN D OVERFLOW SCUPPER @ OVERFLOW SCUPPER SCALE: 1-112" = 1'-0" date May 26, 2006 sheet title revision DETAILS July 17, 2006 a.c.-R.F1 project number drawn by D.M. • • / . J 77 of 162 85 j ~============---===============================------=====--~---------------,,-==----:-========================--=-=·-=~=·=··=· ==i r---------------------------------,---------------------------------.---------------------------------..-------------------.---.------------.--------------------------------, FUTURE SIGNAGE BY OT~ERS (NOTTO EXCEED 151bs PER LINEAR FOOT). EXTERIOR FACE OF ~ PRE-CAST CONG. PANEL I ROUND ) HANGER ROD ~ / 11 W/ SILVER \ / / FINISH y / I{ I I, 1' I \ I I 5'-0" / / I I I I / I ~ IOR FACE O -·, / / P E-CAST CONC. I I PANDRAL / l I CONT. CAULK ;If' / / "IB' PE.R FT I • ' l C • • ,i C,0 I ,:....,_ _______ ============================== -=='=== $ 10·-0· AFF lt=T===::lt==========;::::;z=±f , __ - B.O. CA\!OPY , \ ANCHORS AS $ B'-0" AFF "--- \ REQUIRED \_ ALUMINUM CANOPY Wt DARK BRO~ZE TEXTURED FIN. G.C. TO PROVIDE SHOP DRAWINGS. CANVAS AWNING FRAMES TO BE 1.5" ROUND TUBING PAINTED TO MACH AWNING COLOR (BY OTHERS UNDER SEPARATE PERMIT) EXTERIOR FACE OF ~ PRE-CAST CONG. PANEL -...., EXTERIOR FACE OF ~'- PRE-CAST CONC. "-..... SPAN ORAL ,,_ _______ 5_'-_0'_' -------+ •' ' A . . . 4,.. <f • . . SCALE: 314" = 1'-0" PROVIDE - EPOXY PLYWOOD PAINT BACKING FOR H.C. GRAB BARS " 3'-0" TYPICAL S.S. H,C, --k--GRAB BAR ' ':---',. ' b ---k-b ~~ 0) ' .- M F-. ' ' N N ' .- -/ 1 '-6" t Ft ~ "" .,, ,_ ,i: ~ z Q ~ w w w (/) ' 5' ,, ~ 8'-0" AFF EPOXY PAINT 3'-6" S.S.H.C. GRAB BAR 61~p~~~ i---1 z _I ~ .- /1\ Int. Elevation A1ot. Elevation H.C. BATHRM SCALE: 3/8"=1'-0' BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305·444·4433 fax 305·444·0181 E/v\AIL: bdamiami@bellsouth.net H C. BATHRM SCALE: 318"=1'-0' fil fil CA~NAS AWN NG FRAf.<ES TO BE 1 5" ROUND TUBING PAINTED TO MACH AWNl~G COLOR (BY OTHERS UNDER SEPARATE PERMIT) EQ " EQ EPOXY PAINT --',-- '-.-- ~ ,' I b M ' "--fo !~ .-~ r,.... , I 1:::E .. 1 -•---~·N N .- 8" D:A. L.GHT WEIGHT ~ MEDALIAN "-. SUR~ACE , APPUED BY PINEAPPLE GROVE OR EQUAL SEE MANUF. FOR INSTALLATION Aiot. Elevation H.C. BATHRM SCALE: 3/8"=1'·0" ' 0 in . I •• . ' -s..----- 1 = 0 ' OC) ~P"'""c/="",,,<-C:::,--._,.-, ' • VERIFY W/ ARCHITECT L ANCHORS AS REQUIRED SCALE: 3/4" = 1'-0" S.S. FRAME'--. LEVEL INDICATOR [ POSITION "-.SIGN INDICATOR S.S. ELEV. -------1---• DOORS '□ USE VANDAL RESISTANT HARDWARE& FINISHES SEE ELEVATOR MANUF. FOR DIMENSIONS / CONFIGURATION OF HARWARE Proposed New Project b .- ·' co -'>c-- -',----- .. -',----- I CANVAS AWNING FRAMES TO BE 1.5" ROUND TUBING PAINTED-:-0 MACH AWN'NG COLOR (BY OTHERS UNDER SEl'ARA!E PERMIT} .,-_ . -r ! ----~•~-t-t----'s- 4'-0" t Jr .. ~l ===========~JL I> • • @ARBOR t, I> I> I> PRECAS~_j COW.: WAL,. I> 6 6 i> I> t' t, > I> \ ' I I R=__.I ci-w,NELP\IC . · ..... d ----~ ALUM ANGLE 1.S-x1SALUM TUBE WELD ALL METAL CONNECTIONS -CONC. ANCHORS AS REQUIRED ALLM ANGLE CONC. WALL ~OTE: G.C. TO PROVIDE SHOP DRAWINGS. SCALE: 314" = 1'-0" L..,OjH7lQ);, S<!Pf'\.JCD IIY ~El'I lYP· ~F!CMCE MOjSTUR!! BARRIER 3£:V,'EEN t,E•AL\CONC ~-O:.T. GRADE P".YWJ lfl1LJ..'l'IGAGE ~E•Af_Sl1J05@ Hr' JC. CORNERaul.D LIGHTBOX BUILD-OUT @PLAN -END ~~;~1~~=1._0 .. date May 26, 2006 reYiilon South Miami Municipal Parking Facility ffi ffi March 19 2007 OWNER Cf.EV S.W. 73rd Street & 58th Avenue, South Miami, Florida March 22, 2007 OWNER REV CANVAS AWN1NG FRAMES TO BE 1.5' ROUND TUBING PAIN fEO TO MACH AWNING COLOR (BY OTHERS UNDER SEPARATE PE.RMIT) 2'-0" /-------/- I> b c>D i> t, > /:; i> I> tp D I> I> > 6 / >t /L > / L " / // -- i 6 i> '> b '> i> t, i> i> D '> i> > " D > t, 6 '-PREGJIST CO'IC OCCK ~~, ~-i•U.W GA<l!: ~E':"AL STL-DS@ woe L.C:n,90X il'JPP'.'ED 8"\'0.,.-'-ER G,'ll'J,,V,:f:1 s-ucco Ml' O.T. GRA:lE "'"' 6"1•CA','l''.i,\GC t,l~l/lJ.S-J?S@ 18'" JC TV)" ''H(JV'"1E t,ICISTJR~ 0A.~IER &c.T'NlE!< t,1ET,•.L-!.C0'1C CALL( > _I PRECAST CUNC UEC,O: LIGHTBOX BUILD-OUT @SECTION DE~~~:~112 .. =1'-o" 1heet tltle Scale: DETAILS ,heet project number drawn by D.M. 78 of 162 86 , I • ! 1---~-- HVAC GENERAL NOTES SYMBOL LEGEND 1. THE DRAWINGS ARE TO BE CONSIDERED DIAGRAMMATIC, NOT NECESSARY SHOWING IN DETAIL OR TO SCALE ALL OF THE MINOR ITEMS, UNLESS SPECIFIC DIMENSIONS ARE SHOWN, THE STRUCTURAL, ARCHITECTURAL AND SITE CONDITIONS SHALL GOVERN THE EXACT LOCATIONS, CONTRACTOR SHALL FOLLOW DRAWINGS IN LAYING OUT WORK, CHECK DRAWINGS OF ALL TRADES TO VERIFY SPACES IN WHICH WORK WILL BE INSTALLED AND MAINTAIN MAXIMUM HEAD ROOM, AND SPACE CONDITlONS AT ALL POINTS. WHERE HEAD ROOM, OR SPACE CONDITIONS APPEAR INADEQUATE, ARCHITECT OR ENGINEER SHALL BE NOTIFIED ON WRITING BEFORE PROCEEDING WITH INSTALLATION, THIS CONTRACTOR SHALL, WITHOUT EXTRA CHARGE, MAKE FIELD MODIFICATION IN LAYOUT AS NEEDED TO PREVENT CONFLICT WORK OF VARIOUS TRADES FOR PROPER EXECUTION OF THE WORK. 2. EXAMINE ALL DRAWINGS CAREFULLY AND VERIFY EXISTING CONDITION IN FIELD PRIOR TO SUBMITTING A BID. CONTRACTORS WILL BE REQUIRED TO FURNISH, INSTALL AND/OR CONNECT WITH APPROPRIATE SERVICES ALL AIR CONDITIONING ITEMS SHOWN ON ANY OF THE ARCHITECTURAL, PLUMBING, ELECTRICAL AND SPRINKLER DRAWINGS WITHOUT ADDITIONAL EXPENSE TO THE OWNER IF DISCREPANCIES, CONFLICTS, INTERFERENCE OR OMISSIONS OCCUR BETWEEN DRAWINGS, NOTIFY IN WRITING THE ARCHITECT /ENGINEER IN AMPLE TIME TO PERMIT REVISIONS BEFORE THE BIDS ARE SUBMITTED. 3. INSTALL MATERIALS AND EQUIPMENT IN A NEAT AND FIRST CLASS WORKMANLIKE MANNER. THE OWNER RESERVES THE RIGHT TO DIRECT REMOVAL AND REPLACEMENT OF ITEMS WHICH, IN HIS OPINION, DO NOT PRESENT A NEAT AND WORKMANLIKE APPEARANCE, REMOVAL AND REPLACEMENT IS TO BE DONE IMMEDIATELY WHEN DIRECTED BY THE OWNER IN WRITING, AT THE SOLE EXPENSE OF CONTRACTOR. 4. START OF WORK BY CONTRACTOR SHALL BE CONSIDERED AS ACCEPTANCE BY HIM OF ALL CLAIMS OR QUESTIONS AS TO SUITABLE OF THE WORK OF OTHER TRADES OR OTHER CONTRACTORS TO RECEIVE HIS WORK. THIS CONTRACTOR SHALL REMOVE AND REPLACE, AT HIS EXPENSE, ALL AIR CONDITIONING WORK WHICH MAY HAVE TO BE REMOVED BECAUSE OF INTERFERENCE WITH OTHER TRADES. 5. START OF WORK BY CONTRACTOR SHALL BE CONSIDERED AS ACCEPTANCE BY HIM TO COMPLY WITH ALL THE SPECIFICATIONS AND NOTES INCLUDED ON THE SET OF CONTRACT DRAWINGS, AS WELL AS THE INSTRUCTIONS SUPPLY IN WRITING BY THE ENGINEER OFFICE THROUGH RFl'S OR SIMILARS. 6. THIS CONTRACTOR SHALL OBTAIN AND PAY ALL INSURANCE, FEES, PERMITS ASSOCIATION DUES, ROYALTIES, AND TAXES OF WHATEVER NATURE SHALL APPLY TO THIS WORK. HE SHALL ALSO PAY ALL INSPECTlON FEES AS MAY BE REQUIRED BY LAW OR ORDINANCE AND SHALL KEEP THE OWNER HARMLESS FROM ANY DAMAGE AND EXPENSE ARISING FROM ANY VIOLATION OF THE LAWS, RULES OR ORDINANCES. 7. THE WORD "AIR CONDITIONING" MEANS HEATING, VENTILATION, AIR CONDITIONING, DUCT WORK, PIPING REFRIGERANT LINES, CONTROLS, SMOKE AND FIRE/SMOKE DAMPERS ETC. 8. PROVIDE MEANS "FURNISH AND INSTALL". 9. DO A COMPLETE JOB, EVERYTHING CONNECTED, READY FOR USE. 11. AT COMPLETION OF JOB THE HVAC CONTRACTOR SHALL GIVE THE OWNER AN AS-BUILT SET OF DRAWINGS SHOWING THE AIR CONDITIONING SYSTEM AS INSTALLED IN THE FIELD. 12. ALL DUCT SIZES ARE CLEAR INSIDE DIMENSIONS. 13. THE HVAC CONTRACTOR SHALL WARRANT ALL WORKMANSHIP AND MATERIALS FOR ONE FROM THE DATE OF FINAL WORK ACCEPTANCE BY OWNER, ANY BREAKDOWN OCCURRING IN FIRST YEAR SHALL BE REPAIRED AT NO EXPENSE TO THE OWNER. THE COMPRESSOR(S) SHALL HAVE A FIVE YEAR GUARANTEE. 14. MOUNT ALL EQUIPMENT FOR WIND LOADS AND MOUNTING HEIGHTS AS REQUIRED BY LOCAL CODES. 15. ALL SHEET METAL DUCTWORK TO BE CONSTRUCTED IN ACCORDANCE WITH SMACNA'S STANDARDS. ALL JOINTS AND SEAMS OF INTERIOR DUCTS TO BE SEALED WITH 4" TAPE APPLIED WITH ADHESIVE TO MAKE JOINTS AIRTIGHT. BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305-444-4433 fax 305-444-0181 EMAi I.: bdamiami0bellsouthnet wa WILLIAM A. BERRY & ASSOCIATES CONSULTING ENGINEERS 10200 NW 25th STREET, SUITE 111 DORAL, FL 33172 TELEPHONE: 305-513-9000 FAX: 305-513-9100 EB 0006543 16. BRANCH TAKEOFFS MUST BE PROVIDED WITH APPROVED, ADJUSTABLE AND ACCESSIBLE AIR VOLUME DAMPERS. 17. FURNISH SMOKE DETECTORS, FIRE STATS AS REQUIRED BY NFPA. 18. THIS CONTRACTOR SHALL FURNISH ALL MOTOR STARTERS REQUIRED FOR ALL EQUIPMENT FURNISHED UNDER THIS CONTRACT AND SHALL BE INSTALLED BY THE ELECTRICAL CONTRACTOR. 19. VIBRATION ISOLATION: ALL EQUIPMENT AS PER MANUFACTURER SPECIFICATIONS DIV 15 TO ELIMINATE ANY EQUIPMENT NOISE FROM BEING HEARD. 20. PROVIDE NECESSARY CONTROLS FOR THE OPERATION OF THE A/C SYSTEM. 21. EQUIPMENT BY MANUFACTURERS OTHER THAN THOSE SPECIFIED MAY BE ACCEPTABLE. HOWEVER, THE COORDINATION WITH ALL TRADES FOR INSTALLING ACCEPTABLE AL TERNA Tl VE INCLUDING AUXILIARY EQUIPMENT (I.E. CONTROLS, STARTERS, SPACE AVAILABILITY, INTERFERENCE WITH OTHER TRADES, ETC.) SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR. PROVIDE SHOP DRAWINGS FOR ALL TRADES INVOLVED IN THE ALTERNATE. SEND AL TERNA TlVES TO THE ARCHITECT /ENGINEER IN AMPLE TIME TO PERMIT REVIEW. 22. ALL RFl'S OR SIMILARS TO THE ENGINEER'S OFFICE SHALL BE SUBMITTED IN WRITING THROUGH THE ARCHITECT'S OFFICE. 23. IF SPACE ABOVE CEILING IS USED AS RETURN AIR PLENUM. PVC OR ANY OTHER EXPOSED COMBUSTIBLE MATERIAL WILL NOT BE ALLOWED TO USE ABOVE CEILING. 24. IF PROPER CONDENSATE DRAIN SLOPE TO DISPOSAL POINT IS NOT POSSIBLE TO ACHIEVE, PROVIDE CONDENSATE PUMP AND ALL ELECTRICAL AND MECHANICAL CONNECTIONS FOR PROPER OPERATION. SYMBOL VD ---, (S) @ <D ® --rs "FD ABB. AD E/A CD CFM EF-X ET F/A MOD N/A 0/A R/A S/A VD FD BD DRAWING NUMBER M1.0 M1.0 M1 .1 M1.2 M1.3 M2.1 M3.1 M4.1 M5.1 M6.1 M7.1 M8.1 DESIGNATION VOLUME DAMPER DUCT MOUNTED SMOKE DETECTOR CARBON MONOXIDE SENSOR T}I ER MOST AT TEMPERATURE SENSOR FIRE STOPPING FIRE DAMPER ---------- ABBREVIATIONS DESIGNATION ACCESS DOOR EXHAUST AIR SERVICE CONDENSATE DRAIN PIPING CUBIC FEET PER MINUTE EXHAUST FAN, NUMBER-X EXPANSION TANK FROM ABOVE MOTOR OPERATED DAMPER NOT APPLICABLE OUTSIDE AIR SUPPLY SERVICE SPACE RETIJRN AIR SERVICE COOLING SUPPLY AIR SERVICE VOLUME DAMPER FIRE DAMPER BACKDRAFT DAMPER HVAC DRAWING INDEX DRA'MNG TITLE HVAC LEGEND, INDEX AND GENERAL NOTES HVAC OVERALL FIRST FLOOR PLAN HVAC FIRST FLOOR PLAN HVAC FIRST FLOOR PLAN HVAC FIRST FLOOR PLAN HVAC SECOND FLOOR PLAN HVAC THIRD FLOOR PLAN HVAC FOURTH FLOOR PLAN HVAC FIFTH FLOOR PLAN HVAC DETAILS HVAC DETAILS HVAC SCHEDULES HVAC LEGEND, INDEX AND GENERAL NOTES SCALE: N.T.S. Client: WITH Proposed New Project City of South Miami - - - --------~• - Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida I ; • • . • • • • '0 DUCTWORK LEGEND DUCTWORK SYMBOL DOUBLE LINE SINGLE LINE DESIGNATION 4 + , J ' , 4 AXB + , AXB , J , 4 A"~ + , A•" , J J ~ ~ 0 0 + 0 ~ + D<i , J !El + P4 ~ + D<J ' J !El {IR 1+ , B J r , {ID 1+ c D J ' , 41 □A □I+ , 0 AD, J , 011110 ',-----, Ill----', t=I:r=i ',-----~ t=rr:-1 < ► , ' , ~OR~ 7 tI 1 4 'id + ',-----r ~ ~ ® (1) date September 01, 2006 revision DIRECTION OF FLOW DUCT SIZE (CLEAR INSIDE DIMENSION) FIRST FIGURE INDICATES PLAN VIEW DIMENSION ROUND DUCT, A INCHES DIAMETER SIZE SUPPLY AIR DUCTWORK RETURN OR EXHAUST Al R DUCTWORK EXISTING DUCTWORK NEW DUCTWORK DUCTWORK TIJRNED UP DUCTWORK, TURNED DOWN SLOPING RISE IN DUCTWORK SLOPING DROP IN DUCTWORK ACCESS DOOR IN DUCTWORK FLEXIBLE CONNECTION DUCTWORK TRANSITION, CONCENTRIC DUCTWORK TRANSITION, ECCENTRIC ELBOW WITH TURNING VANES FLEXIBLE DUCTWORK CONNECTION TO RIGID DUCTWORK. MAKE 'MTH SPIN-IN FITTING. DUCT BRANCH CONNECTION TO MAIN DUCT RADIUS ELBOW WITH 1.5 TIMES HEEL RADIUS, UNLESS NOTED OTHER'MSE DUCT MOUNTED SMOKE DETECTOR NEW WORK START POINT sheet title HVAC LEGEND, INDEX AND GENERAL NOTES project number 20058':l drawn by J.L fRECEIVED MAR 1 9 2007 HVC Comtruaort, loo. SCALE : AS SHOWN sheet number M · 0. 1 79 of 162 87 I j r I -1 I I. A' I I I I , __ ./ ~ '[Jp 1 • . r-··· ·::i 0 ' ., 3 ---- l'?ET A,l; 7 1007 s,jft 4 T ,_ I . I - I I I 1 ··s. .,t .d~"~ ~11.,.---S-:,::::;:::::~~ ~:;!J . •I " -.. IMe,l<MMEfjf __ .• : . t . ... L .. . --~,r I , w, ~ ;{·i~;f~:ft~;"'::i"'."'i:_;;.:~:-~.i:;0+·-~;t~:r:=}?:''.?i.':·:_,., I I I I I I I '~-__ ,/ I /' ·-, :,Ci··+-- \ I I I I L BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305-444-4433 fax 305-444-0181 EMAIL; bdamiamiobellsouth.net · .., · FOH t~OOD . . l,.· •• Mh.1~ ... ·_••,,,.... n, I , l SL'B~fl mJm 1~'.il!Rj+ )'•l-1~: '-.,.;.--------' )2'121:1 18X& Ct;IS{ FOR Tf)i,\NT-1 LIQ. • 0---'11110 ~UN~11]t_P TO 2Nll I I I I I I .I ·. ·. • . . . .. )• SEE ENLARGED PLAN FOR THIS AREA ON SHEET M-1.1 I ······· ___ - Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 5 ---- / '' ' ,., , .. , .· .. r •. ; ; .. ,,..,, ....... -'>., .. , ''·'"· .,;, .... (: M . 0,1$§%,H ">'.. • N RESTAURANT 2 5822 sqlt • ! : j ~i~'?o~~=GH~ __ .7. ;2<~· ---r-· .· ' .; < ►5 : x . . "' tr:. ~ j • ()' '! ' .. ,, () i'"'" X tU .. - 4&48 WNJ. OPNG •T"~' ' .. ~ ' ' ' R3STAUf1ANT 11 6/40 sq't ·.• "/ . . ;, , ,,;, .. ,;.,,.:,;s:.·,,,.!:~l!llll-,::1t \.:.?..!:]·· . t, SEE ENLARGED PLAN FOR THIS AREA ON SHEET M-1.2 CD IiV AC OVERALL FIRST FLOOR PLAN SCALE: 3132" 0 1' O" WITH Proposed New Project City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida ---r . . I.!: j I I 1021. inft. 0/A LO!MRS; CAPP£0 FOR F\J11JRE CONNEC1)0N or TI;W,NT Rf;iTAiL 3 .,.,.,-----+-, 704 S it 0/A LOIMRS. i . :tN'!'IDFO~ FU11JRE' CONNEmlN 111 IDWfi 111,)(6 CII\SE f9R -4, 5 t· - LIil, 1110 SIJCllQN LINES lP TO 21(0 FLOOR LOO, { ' I I .. ~ l' ' i. " ii ' ••'• . ..,,.,,..,· t i.::ae,_;;_,r, ,_"_ ''''!''' ,.,;:,,,;Cf ..,, 11 ' ;;,, ••• ·,,sss r' '"'"""'· " I , r ' . ·-....; I p date September 01, 2006 revision ffi BLDG DP"MT COMMtNTS 11-2-06 & 2-20-07 -------- sheet title HVAC FIRST PLAN OVERALL FLOOR project number 20058':l drawn by ZM 7 ! I I I I I I I I I (!) I Cf_ I I I I I I I I I ,::..:J-l,,, ·;·· I SCALE : AS SHOWN sheet number M · 1. 0 80 of 162 88 ' ! I ' I . ' . ' I ,J ; 11 ' ' . I I I ' ' ! ~-~' ~--- BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305-444-0181 EMAIL: bdamiamiobellsouthJlet C > «'-.,> (/) /' /1/ ~ ! '' 1 1n6 C , E FOR n,;Nm_._ r_c1_1.o_ & ti µ-~-1 U9k:JiND( ~IJ(;JION u~~s 011 ,TO 2ND .i;lOOR l-£VEL RET "LS 1375 ~qft I, 0 fl LOUVERS. I CAPPE;Q FOR F\JTIJ ~E CONNEG~ON BY TEJW,T l 1BX6 C E FORT T-1 LIQ, □---n-iAND s ,noN uNEs/ µP rn 2ND FLOOR L£\ll;L ·1z,IJ, d _," ....... ,.,· , ·.,.,-. ,, 1 , -• -h·-· - I v,:l.i.u:-:· '.CC//! i ' \I l ~ i ~ ,>; ' . r . i • ! I :: ii:,i~~~~l:,I J:,-~;~ ·_-_-_ -·_·_, ½~:,-_-· .. -"·,·-}{~/ --. -3/4" _CONDENSATE DRAIN . TERl,ONAtE'. Ai CATCH BASIN N ED IiVAC p ARTIAL FIRST FLOOR PLAN SCALE: 1/8~ = 1'-0" Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida date September 01, 2006 revision sheet title HVAC PARTIAL FIRST FLOOR PLAN project number 2(Z)r2J!:,8'?, drawn by ZM • . . SCALE : AS SHOWN sheet number M · 1. 1 81 of 162 89 ' I i A / ~~~ " -·"""•· -. ' '1 4 B BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 265 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305-444•o-t81 EMAIL: bdamiamiobellsouth.net REiFAll 7 ' 1097sft REFRIGERAN i i ' / II . / •• A """ ';·' ,c;; ' ,., .. Client: I , .. _ "" •• w •• ··--·"- Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida \ ... ···•···•·· .... 1·.; .. ·"· · ..... · .. i +· ' : !,; ' ·r ·,ESTA F~ NT 2 i: ! I 11s22 s ·n . ' N ,48,17 OPN IBRO GH sija i\ST TO 2ND FLOO i i • ' i ' t 1. • I . . ' I ; ( ; j m'"""""'""" "'""" . -.... ED IiV AC p ARTIAL FIRST FLOOR PLAN SCALE: 118" = 1'-0" WITH Proposed New Project / J, "' .. -. (;, .-. +·· ... CH +1{-ff' . , I 4,llx 17 OPNG . HROVGH 1 ~T TO 2N D !lOO!l ' ! I a d H. ~--3'" ' R, Sf AU A T ,1 61 40 sqfl I ( 1 ••-' .............. ~-'" -.......... -~·-·· " -------~---~" ··~"·"'" ""''""""" ... '" -~"""''""'"" '"" cF :.,: ''s· "····"', date September 01, 2006 revision City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility ffi BLDG DPlM" COMMENTS & 01-08-07 S.W. 73rd Street & 58th Avenue, South Miami, Florida sheet title HVAC PARTIAL FIRST F L O OR P L AN 11 ·206 proJect number 20058~ drawn by ZM SCALE : AS SHOWN sheet number M · 1. 2 82 of 162 90 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevlla Awnue Coral C=bl•s, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamiamlObellsouthnet Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida N / ,,, .. , I REfte..1L 1 104~l sqrt I ' RE i-AIL 1 10, '1sqf;' ....................... ·-·········· ..... . I .. ,·· ·-----,-- I , '-·---·' I ; ! ...... .J ' ' HV C PARTIAL FIRST PLOOR p,,r,., WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 ' SCALE: 118" = 1'-0" Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida date September 0 1, 2006 revision sheet title HVAC PARTIAL FIRST FLOOR PLAN project number 200&8~ drawn by ZM. SCALE : AS SHOWN sheet number M · 1. 3 83 of 162 91 lHROUGH Sl,I • /,.. ..... __ ·····-·':,.,,.l. .. ;,,,-1-._\ ' ' ' I , I "'-.,/ !T ' " ii BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevlla Avenue Coral Gables, Fl 33134 305 444 4433 fax 305 444 0181 EMAIL: bdamlamiObellsouthnet /--~ ( 2) ~T,, i :',j \ I ' t-----+ ., 1-----lf r--.,,, .. j "" i WILLIAM A. BERRY & ASSOCIATES . CONSULTING ENGINEERS 10200 NW 25th STREET, SUITE 111 DORAL, FL 33172 TELEPHONE: 305-513-9000 FAX: 305-513-9100 EB0006543 i, I M. SAEED FA J•.E. #'40971 ELIZABETH T. PRIDA, P.E. #59464 (~31 (4'\ ' I \ ; \-.........,__,.,/ \:_r/ ' ' I I ,, !ii:i:ii:iiii:~~'.~.'.~~~~:~~=:lb~ ···········fr'C ---, ............. .; ........... -·---·~--t·fr·· . -' ........ r·~· --4:'f ..... . ,. ~-,!~ eit·::'""i' • i ~····· 1'=' ii ! ! I I MP UP TO 1:VEL, HRE · 5. 7% (.)-,, . ' ·1"· -,_ - j :~-.. .... ' ~--;_. ---\,.> ' ~,..,- i ' ' /,.~f\ \ 'Ii; I 'if,,/ i! Ii ,, c:: ~====i 1. " • ....... , •. 1 "~, ............... , .. ·1_,,,.,....-,/ ('5'\ I I \_I,/ .................... ············-i-················ m--~;/+'---1---fr··-1 j: E· ='F===ilic I ,! ......... ' I . ..... -............ ·······-·· ····-. ····-··•~j---········ .. ·-··-··-······ .... --~·-········- ' i I i I I 1, Ht---··lt----+---Ht---+-+--+--+ 1' ---,l.'e-' --t----!l! J __ -t,l1 .• ' ' ; 11 .. ---1· N \ \ t= \ \ \ I' ··1·· ! I'''''" i-:-.~.="'"1t'''"J !: '(1 j r " HV AC PARTIAL SECOND FLOOR PLAN SCALE: 1/8' = 1'-0' Client: WITH " l'k¥% . ~... .. ··¼_: . ~ I I I , j II ·1 I ~···-..... ,..... ·rl; ., .,,.+··· /!\ i ! i'i ' ..f-c+,-.. .. ,,·.·.·.·.·.·.l-t,¼,,.· .. ····'···••'i°-----··1 ,,. ...... , ...... ., .•.. ··r ·-··' t I . \ I· I ' ·1, n ' ' roposed New Project iL_ . ,-····· .. ,; ,it_, _;;;> ii i \ \ /,.. .... ~ ( 8 ) \,_r/ . I .. . ., 1 ~ .Bx17 OPNG . TO 2ND c'.:': . ' 1, !1 *== I, , .. ~ .......... ,1r .. .., ,[ ,, ~J.i,.-==-I ;: ill ... .l ! ' I i I I I I ,,--~ ( 9 l I ' '··--.··'/ / N ' I / I (10) \7_,1/ I \ \ '.1-.. I ' ~\"": __ ---+·I \ \1 - ·;, 00 00 00 ' ' 0 ' 0 0 0 " Pl i! . I " . ' '! , I j, ED HV AC P ARTJAL SECOND FLOOR s~~·-0· d a t e September 01, 2006 1heet title SCALE : AS SHOWN re"1!1lon sheet number Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida City of South Miami 6130 Sunset Drive South Miami, Florida 3314 South Miami Municipal Parking Facility _&_ ---=-0""'"2--=2=0_-=07'---_ HVAC PARTIAL SECOND FLOOR PLAN M · 2. 1 S.W. 73rd treat & 58th Avenue, South Miami, Florida project number 21'Z>05&~ drawn by ZM t 000 '. I ii 1JL :r. i ' : ! rt 84 of 162 92 I ~ .·1 I . ,, ii ii ,; ~ !I I c j I; . ' .. '''! !I •,·1; I ! !I .. • I. ii BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevll ■ Avenue Coral Cables, Fl 33134 305 444 4433 f■x 305-444-0181 EMAIL: bdami■mlObellsouthnet \ \ \ --------.---- 'Jr~ .L ~\ ' : JfJZO#'Ji Jff.Jll!J .... ... ---' . Wf~;~,.;,~..eli!l'i·~.,!!'llf!i ____ _.li'Wzl====,.= .... ::;1114.i ~ ..... ~ .... ,~,~. ::_::_:: _:: -=~ ~j-j_--'.".-+~-·!::_=~=,::. ::::::~~~-~~~-~!!i':i~~~~~~-,~~-;~•-':~-,::,~~---'~.-~-~~-~~-•~.,,t.~·i,z ~-. , -.. -... -,, ___ JTA •~•,,,,=====.,.,,-•ml,·-····· .,.•ri-----+!it-·-·--1,--------t+-:---H--+---+'-~--t,t-;: , --IF·'----;,::t--+----+~~ ~ ---., ··f.~ .. ----.,-·+r;-_: .-· i, ' ;,; il i c:lll=='J='·--l;l-----+jr-----v-~---~-f--..... E·:,_+······--··· ----·,····· l:!',-------•,, .. ••··~·--1+--E=:=:==:i'.f.5 ;kb i :! "'--= ·------¥i:--~"! F" ~--·----...+-cc-; -------·-''= ~. · --•--·-= "*~ ~-~ ~• ~ =,,,,,--,,,,,,.,,, '.1= 1 . i ; V "·-F"'"---1 ., 11 , .. ';'""''""""""""' ' _, . , ... ,...... '"'.J ,... ..,, ........ , f""•C'"-..... . , Ii " ./ ®--+ "" ------ i'"-....... ! •. r·, -' . !,/., li II n I RAM UP T• • LEV If FOUR 5 7% r---------1--+a ---------·--_,...., _ ---H ---~----1---1-k ----- . . • . I •. \ ····- ' I \ \ J. ...• L ... BAI RIER ~BLE @4" ( .t;. TO ~2" AF ' V ' ' . / ' i •••••••• 1 • ..-: ........... ~ ,I I I / ' I )n all Walking sur aces with q Slope of le s than 5% / ~rovide a slip res11lan! fi 1rish. rescnbed i ~ a mtJiurr / ¥11ted finish. , : / 9~_a11l~u~aces wit, a sltpe Jeater than %, p~vidf ~ slip/1 rps•st.Jmt f.msh. , I , , ' ' ; ' ; ; ! / [ o no 'allow any, \OSS ~lope: ta exceed ''4" p, r foo P0!%. --~--t+-----i·. y~-~ 1\\, ;' \ I i I \ ' \ N . I/ v . ...... , .. . \ ( / / ) / ::: •·············~, t-i'==···---··-9 ' r ' \ ttV) .C PARTIAL THIRD FLOOR p:._ A..N SCALE: 1/8" = 1'-0" Client: WITH Proposed New Project I / I I / I ' I I v ... 81',RRIEr ,CABLE @4" ... C. TQ42" AFF FOLLOW 1 ·:ope / I or RAM ITHIS SIDE ! ·''"'"'!' ,,.j;,,;J -I- I I ' I I I I I I ' I I I I I I I . I !:1 I F-"~~=~ . d at e September 01, 2006 revision Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida City of South Miar 1i 6130 Sunset Drive South Miami, Florida 3314: South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida i I ,ii ~-='-·'"-=---1 •• . ' I -:1 !: E ~ ------7 1! ' i I I I I I I ! / I V I I I / I sheet tltle HVAC PARTIAL TH I RD FLOORPLAN project number 200S~ drawn by ZM '! . ' j I / ·········:+ ····--~-- \ \ -···· .... -0 SCALE : AS SHOWN sheet number M · 3. 1 85 of 162 93 Ii ,I !------+·· .. ,., ....... . . \ii 1 i, \ ·······\~ ' ; \, ' . ' . ' . l--ll++-------l,o11 ~\'s-\Tt------ttt f ! ~!\ I ; / I ,i n ., I j l······++------•H·· .) ............. ··1----------'I ,,..' I ! BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevlla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305 114-0181 ~l: bdamlaml•bellsouthnet RAM ,<i~-t+---·-·--· -•-· !-·-·· ---··--·--f--·----~ -·---··-.. ---·---~ ---·· -'4 \ \ II I I I I . ' """••-···-· ......... """! .AB lll'ENI lS FOR E/, F1iJTU us FOR \ \ \ • ; , WILLIAM A, BERRY & ASSOCIATES ( CONSUL TING ENGINEERS , I 10200 NW25th STREET, SUITE 111' DORAL, FL 33172 TELEPHONE: 305-513-8000 FAX: 305-513-9100 M J!Mll!iWN;· 71 EB 0006S43 ELIZABE1!1 T. PRIDA'. P:E: ~ I 111 I, Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida I I· t'.'. ~~------,,~~·,= °".''.J , , I , , I I WITH City of South Mia 6130 Sunset Drive South Miami, Florida 331 I , I , , I / I ' N I , / , ! , • . I /· ., I/" V I ' . ..,,_::., __ ,--- ·····-......... -----------, ... , ....... ·-;-.......... ' .............. ---------··-r·· ·-··· .i -...., ,.·.•. t ,""" ·' I,! f, '. . . I !, / ' ' //.·1///i I I I ,I !' ii I ....... . , , !;;;;;;=,~""T ,,, .. ··._.,_,_ .. _._._:::~t~~-:, <~.:J c.: ... :, I \ ' \ \ I HVAC PARTIAL Ir'{JRTH FLOOR PLAN roposed New Project I I I V I / I SCALE: 1/8" = 1'-0' ' I '*'" ,,' ,,1. ' ,/ I South Miam Municipal Parking Facility ' ! S.W. 73rd !Street & 58th Avenue, South Miami, Florida I d ate September 01, 2006 revision ····· .. - I/ ·it--,,--= )'.i . ' I I ! I I I 1h11t tltle / / ' i/ if V ] HVAC PARTIAL FOURTH FLOOR PLAN project number 2~0&8~ i/ ,--1'' / «/ ~ /[ ' ✓/1 /' Ll . , '7, V:!i// !Y .d Yi !' ' I ' ' C SCALE : AS SHOWN 1heet number M · 4. 1 drawn by ZM 86 of 162 94 ! -!! ' '1 ! ______ J.L ---'---~------- (,1-) ' ,· ~r ! ':i&U4f'f'i'Jfi_ ~-L "l ; : : ii ~ ~ -··1 I l __ _ ' ...... , .... : TAIR I ! , ! I I I I I I i ; !/ !I l ;, I I BUTSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevlla Avenue Coral C2ble1, Fl 33134 305 444 4433 fax 305-444-0181 EMAIi; bdamlamlObellsouthnet I > -; fl . I 1 ~ --···· .. 1 [" .. ·---··-········1 i I ·rf-·li~t:·_-=·~~~~~~~~~~~;~=::::;:===:11ti:... __ ·!~~~~~~~--~;-··~:~~~:~~~~~~=--,~--=---·::;· .= .... =::::;:=:.:::...= __ = ___ -+,-=l __ L ti~ .... =.-=.,:..-i_-= __ ==r::I=:;:::=:::;::::::::== .. =, ___ -=_ =_l;::i _:::=::::;::=== ___ +=;=_r Lt ;!=: .. -:. ===+=;::'.:=:::;:.::=:::'.:::========+=rl:; ,::J =:::::===~,=.:;:::.=:::::===:;:::::::;:==-=i-----ijj>-_, _··:, _·_ -_ -_ -_ -_ -_ ++: =======~----_-_-_:_+J-tL ! ·:_:1 ~~~~~~~~~~~:~~~~i:::.,:_=:_=_=~-:_T·:t-·= i. 1-···-·... ~->-· ·-+,·"~\ ............................... 'j ,·········.+·=·-······=·-····-·· 1 .. ,,,,t.,.,,,, .,,,,,,.,~ . .J ;,,,,,,,,,,J,,,,,,,1 1 : r-"'="•+·"·'""··~· . ,,,.,,.~ •····~·.-:i ..... ·~· •. -· .... J_ ..... i ~, 1""" "*= i c~i ..... Ji .)->·--·--,~ e::.:·~'.~.:::.::.':.'.'.':.'J ! j e ............. '.'.'.'.i'-'.'J ·-·--L-·-·1 1"=·""'"=·" ' ,, ·····-"""··'·········· i 1---···~···-·······'-···~···-·, \ \\ \ "" IT e::--···-··r ··-,,-=!==' I 1 ' SLAB (lPENI FOR E/A FOR ! f1JTURE TENANT USE. vi~---;--+-----~ /\I ' ,/ 1 ; ,, 1\ :~/_.·\\ •, / \ t ' . \ \\ Client: \\ \ \, \\ \. \ ', ' ' , , Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Mianjli 6130 Sunset Drive ' South Miami, Florida 33143 • ' "f'lmi "i':.,r_~·, 1 __ Dk : · I I __ ,!;_ ' : ··-···J I I : .. 9 ... i ..., EL + 55'-3"' FIFTH LEVEL ... .. ............ ... ................... .. ................... ... -·········--···· ·-· ·····-····· ·-·· .............................................. ---I; c·---·~·.····'·••··•······:··1 ··-··-·-·~·-·-·--~ l I f·-'""'"!"""'"'-·i==•,,=·. N , CI) HV AC PARTIAL lmH PLOO~!~ Proposed New Project I I I I I I I I I I I I I I I I ' 1 : r··-·· -·-~···-··-·· ·-h I i South Miami Municipal Parking Facility S.W. 73rd S~reet & 58th Avenue, South Miami, Florida ! 6~-~,f~====~,,d;,J ! .......... ) .... . f····-·-·-·i··-·-·-····-:.·-· d a t e September 01, 2006 revision RAMI DN5.7% 1h11t tltle HVAC PARTIAL FIFTH FLOOR PLAN project number 2~&soa drawn by ZM. 'V: ',:,{) / ,✓A4.~ SCALE : AS SHOWN 1heet number M · 5. 1 Ii 87 of 162 95 -----------· -- r,;.;;:==============================================================================================================-=~==;;;;;;;,i 1..-----==lYPICAL EXTERIOR WALL. SEE ARCH. PLANS. ~-LOWER. SEE ARCHITECTURAL PLANS FOR lYPE, SIZE AND LOCATION. LOWER HAS A FULL HEIGHT AND WIDTH, 1 INCH THICK INSULATED METAL PANEL BACKING. 2 FEET PLENUM LENGTH, UNLESS ...-----INSULATED METAL PANEL, PART OF LOUVER OTHERWISE NOTED CONSTRUCTION. ON PLANS.---.... . r"'"F"--·---.. ---THREADED ROD WITH CONTINUOUS ANGLE AND BOLT "-THROUGH CONNECTION FOR OVERHEAD PLENUM MECHANICAL ROOM FLOOR------ 2-½ INCH x 2-½ INCH x 3/8 INCH ANGLE, FRAMING THE ENTIRE OPENING THROUGH THE INSULATED METAL PANEL. SECURE ANGLE FRAME TO THE PLENUM, AND SECURE THE FLAIRED PLENUM EDGES THROUGH THE INSULATED. METAL PANEL TO THE ANGLE FRAMING. ---~ SLOPE BOTTOM OF PLENUM A MINIMUM 4 INCHES PER FOOT SUPPORT. ROD SPACING SHALL BE 3' -o• ON CENTER, BUT NOT LESS THAN TWO PER LOUVER PLENUM. OUTSIDE AIR OR EXHAUST AIR DUCTWORK. """ SEE PLANS FOR SIZES. "-...,__ 1 INCH, HEAVY DENSllY FIBERGLASS BOARD INSULATION. PROVIDE ALL AROUND ON BACK OF COMPLETED PLENUM. A x B PLENUM SIZE, NOTED ON THE PLANS. CONSTRUCT PLENUM OF 18 GAUGE GALVANIZED SHEET METAL. EXTEND PLENUM THROUGH INSULATED METAL PANEL AND FLAIR THE EDGES TO FORM A PLENUM FLANGE ABOUT THE OPENING. PROVIDE ALL PLENUM JOINTS WITH DUCTWORK SEALANT. SUPPORT PLENUM FROM FLOOR AND/OR STRUCTURE ABOVE. OVERHEAD SUPPORT SHALL BE BY STRAPS WHEN CONCEALED ABOVE THE CEILING OR BY THREADED ROD WHEN EXPOSED IN MECHANICAL ROOMS. PROVIDE 1-½ INCH DIAMETER, SCHEDULE 40 BLACK STEEL PIPE, SECURED TO THE FLOOR WITH A FLAINGED END. MAKE LENGTH OF PIPE TO SUPPORT THE PLENUM FROM THE FLOOR BY WAY OF CONTINUOUS ANGLES. PROVIDE ALL MISCELLANEOUS METALS WITH A RUST PREVENTIVE FINISH. TO DRAIN.------------~ CUT AND REMOVE SECTION OF INSULATED METAL PANEL TO OBTAIN OPENING SIZE OF A (FEET AND INCHES) LENGTH BY B (FEET AND INCHES) HEIGHT. CLOSE OPEN END OF EXPOSED INSULATED METAL PANEL WITH ANGLES AND WEATHER-PROOF SEALANT AS RECOMMENDED BY THE APPROVED LOUVER MANUFACTURER. COORDINATE POINT OF LOUVER OPENING WITH ACTUAL BLADE POSITIONS. TYPICAL DUCTWORK CONNECTION TO LOUVER DETAIL N.T.S. BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, R 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamiamiObellsouthnet Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida SOUND INSULATED HOUSING----~ ADJUSTABLE MOUNTING FLANGE ___ _..,_ REMOVABLE ALUM. CEILING GRILLE---~ cu-1 & 2 i-----HURRICANE TIE-DOWN WIRE (lYPICAL.) '------VIBRATION ISOLATORS (lYPICAL.) ~-4 X 4 X 1 / 4" INCH GALVANIZED STEEL ANGLE. -------6 X 6 X 1/4" STEEL PLATE ANCHORED TO WALL CONDENSING UNIT MOUNTING DETAIL N.T.S. +AIR FLOW ~LOW "----EXHAUST DUCT .1....-----CENTRIFUGAL FAN INSIDE HOUSING TYP. CEILING TYPE EXH. FAN DETAIL N.T.S. WITH Proposed New Project City of South Miami INSULATION -~ 16 GA. STEEL SLEEVE / PACK ANNULAR SPACE WITH THERMALFIBER INSULATION PIPE ----.-\.-.,,__ - - - - - - - - - - - - ----,'"'I, ~6~~~~~-.. ~ .. •~. ~~i~~-~-~-~-~C~ALr,C:IUM SILICATE l" MIN. 1200' INSULATION FIRE SAFING OF PIPE PENETRATIONS OF WALLS AND PARTITIONS N.T.S. d a t e September 01, 2006 sheet title SCALE : AS SHOWN revision HVAC DETAILS sheet number 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility M · 6. 1 S.W. 73rd Street & 58th Avenue, South Miami, Florida project number 200S~ drawn by J.L 88 of 162 96 Ill -.--HANGER STRAPS ---11 __ 5o_"_M_A_XIM_U_M_,1i-UNLESS FOOT SCREWS MAY BE OMITTED IF HANGER LOOPS ____ .... OF STRAP IS PLACED UNDER A BOTTOM REINFORCEMENT 1• MIN. LOAD RATED FASTENERS-----,. BAND OF SAME SIZE / AS HANGER STRAP HANGERS MUST NOT DEFORM DUCT SHAPE BAND - HANGER RODS, WIRES OR STRAPS ONE HALF-ROUND MAY BE USED IF DUCT SHAPE IS MAINTAINED II-HANGER CLIP ANGLE 3/8" MIN. DIA. EXPANSION BOLTS OR INSERTS. USE EXISTING JOIST PRE-SET HOLES. COORDINATE WITH STRUCTURAL ENGINEER FOR ANY NEW PUNCHING OR PENETRATION IN A BEAM OR JOIST----~ NUTS & WASHERS 3/8" MIN. DIA. HANGER RODS 3/8" MIN. DIA. HANGER RODS. CONCRETE ANCHORS STEEL BEAMS TURNBUCKLE DUCT DIAMETER 10 DN 250 mm DN OPEN WEB JOIST 11" - 1 8" 460 mm 19" -24" 610 mm 25" -36" 900 mm 37" -50" 1270 mm MINIMUM HANGER SIZES FOR ROUND DUCTS -- MAXIMUM WIRE ROD STRAP SPACING DIAMETER 12' ONE 12 go. 1/4" 1" X 22 go 3.7 m ONE 2.75 mm. 6.4 mm 25.4 X 0.85 mm 12' TWO 12 ga. OR ONE 8 go. 1/4" 1" X 22 go 3.7 m ONE 4.27 mm. 6.4 mm 25.4 X 0.85 mm 1 2' TWO 10 go. 1/4" 1" X 22 go 3.7 m TWO 3.51 mm. 6.4 mm 25.4 X 0.85 mm 1 2' TWO 8 ga. 3/8" 1" X 20 ga 3.7 m TWO 2.7 mm. 9.5 mm 25.4 X 1 .00 mm 12' TWO 3/8" TWO 1" X 20 go. 3.7 m TWO 9.5 mm TWO 25.4 X 1.00 mm MANUFACTURED CONCRETE INSERTS 51" -60" 12' TWO 3/8" TWO 1" X 18 ga. 24" DIA. MAX. STRAP HANGERS HANGER STRAP 50" DIA. ~ MAX. RETAINING CLIP HANGER ROD 6a C-CLAMP W/ RETAINING CLIP 6a C-CLAMP W/ LOCK NUT (OPTIONAL) POWER ACTUATED STUDS INTO STEEL (STRUCTURAL OR DECK) WELDED STUDS AL TERNA TE --...c NU HANGER STRAP COUPLING 11--HANGER ROD TYPICAL METHOD OF SECURING HANGER RODS AND STRAPS N.T.S, RECTANGULAR DUCT HANGERS MINIMUM SIZE MAXIMUM HALF OF PAIR AT 10 FT. SPACING PAIR AT 8 FT. SPACING PAIR AT 5 FT. SPACING PAIR AT 4 FT. SPACING DUCT PERIMETER STRAP WIRE/ROD STRAP WIRE/ROD STRAP WIRE/ROD STRAP WIRE/ROD P/2 -30" 1" X 22 go 10 go. 1" X 22 go 10 ga. 1" X 22 ga 12 ga. 1" X 22 go. 12 ga. (0.135) (0.135) (0. 106) (0.106) P/2 -72" 1" X 18 go 3/8" 1" X 20 go 1/4" 1" X 22 ga 1 /4" 1" X 22 go. 1/4" P/2 -96" 1" X 16 ga 3/8" 1" X 18 ga. 3/8" 1" X 20 ga 3/8" 1" X 22 go. 1/4" P/2 -120" 1 1/2" X 16 go. 1 /2" 1" X 16 ga. 3/8" 1" X 18 ga 3/8" 1" X 20 go. 1/4" P/2 -168" 1 1/2" X 16 ga 1/2" 1 1/2" X 16 go. 1/2" 1" X 16 go 3/8" 1" X 18 go. 3/8" P/2 -192" NOT GIVEN 1/2" 1 1/2" X 16 ga 1/2" 1" X 16 ga 3/8" 1 1/2" X 16 ga. 3/8" P/2 = 193" UP SPECIAL ANALYSIS REQUIRED WHEN STRAPS ARE LAP JOINED THESE MINIMUM FASTENERS : USE SINGLE HANGER MAXIMUM ALLOWABLE LOAD STRAP WIRE OR ROD (DIA.) 1" X 18,20,22 go. -TWO #10 OR ONE 1/4" BOLT 1" X 22 ga. -260 lbs. 0.1 06" -80 lbs. 1" X 16 ga. -TWO 1/4" DIA. BOLT 1" X 20 ga. -320 lbs. 0.135" -120 lbs. 1 1 /2" X 16 go. -TWO 3/8" DIA. BOLT 1" X 18 ga. -420 lbs. 0.162" -160 lbs. PLACE FASTENERS IN SERIES, NOT SIDE BY SIDE 1" X 16 ga. -700 lbs. 1 / 4 11 -260 lbs. 1 1/2" X 16 go. -700 lbs. 3/8" -680 lbs. 1/2" -1250 lbs. 5/8" -2000 lbs. 3/4" -3000 lbs. NOTES : 1. DIMENSIONS OTHER THAN GAGES ARE IN INCHES. 2. TABLE ALLOWS FOR DUCT WEIGHT, 1 lb./ft2 INSULATION WEIGHT AND NORMAL REINFORCEMENT AND TRAPEZE WEIGHT, BUT NO EXTERNAL LOADS. 3. STRAPS ARE GALVANIZED STEEL; OTHER MATERIALS ARE UNCOATED STEEL. 4. ALLOWABLE LOADS FOR P/2 ASSUME THAT DUCTS ARE 16 GA. MAXIMUM, EXCEPT THAT WHEN MAXIMUM DUCT DIMENSION (W) IS OVER 60" THAN P /2 MAXIMUM IS 1.25 in. 5. 12. 10. 8 oo. WIRE IS STEEL OF BLACK ANNEALED. BRIGHT BASIC. OR GALVANIZED TYPE . ..... <--'''""""~""" ''' •• , ' ___ .. '•,, ~--•1, Client: WITH .· ',.,-f; ....... ~-":ll •, : ~ . ' City of South Miami 1520 mm 3.7 m TWO 9.5 mm TWO 25.4 X 1.31 mm 61" -84" 12' TWO 3/8" TWO 1" X 16 ga. 2130 mm 3.7 m TWO 9.5 mm TWO 25.4 X 1.61 mm NOTES . . 1. STRAPS ARE GALVANIZED STEEL; RODS ARE UNCOATED OR GALVANIZED STEEL; WIRE IS BLACK ANNEALED, BRIGHT BASIC, OR GALVANIZED STEEL. ALL ARE ALTERNATIVES. 2. TABLE ALLOWS FOR CONVENTIONAL WALL THICKNESS, AND JOINT SYSTEMS PLUS ONE LB/SF INSULATION WEIGHT. IF HEAVIER DUCTS ARE TO BE INSTALLED, ADJUST HANGER SIZES TO BE WITHIN THEIR LOAD LIMITS. HANGER SPACING MAY BE ADJUSTED BY SPECIAL ANALYSIS. RECTANGULAR DUCT REINFORCEMENT 2" W.G. STATIC NO REINFORCEMENT CODE FOR DUCT GAGE NO. POS. OR NEG. REINFORCEMENT REINFORCEMENT SPACING OPTIONS DUCT DIM. REQUIRED 1 o· 8' 6' 5' 4' 3' 2-1/2 2' 1 O" dn. 26 ga. NOT REQUIRED 11 ", 12" 24 ga. B-26 B-26 B-26 B-26 B-26 B-26 B-26 1 3", 14" 22 ga. B-24 B-26 B-26 B-26 B-26 B-26 B-26 15" • 16" 20 go . C-22 C-24 C-24 C-26 C-26 C-26 B-26 B-26 1 7", 18" 20 ga. C-22 C-24 C-24 C-26 C-26 C-26 C-26 B-26 19 ", 20· 18 ga. C-20 C-22 C-24 C-26 C-26 C-26 C-26 C-26 21" • 22" 16 go. D-20 D-22 D-24 D-26 C-26 C-26 C-26 C-26 23", 24" 16 ga. E-20 E-22 D-24 D-26 D-26 C-26 C-26 C-26 25", 26" E-20 E-22 E-24 D-26 D-26 C-26 C-26 C-26 27" • 28" F-18 E-20 E-22 E-24 D-26 D-26 C-26 C-26 29" • 30" F-18 F-20 E-22 E-24 E-26 D-26 D-26 C-26 31" -36" G-16 G-18 F-20 F-22 E-24 E-26 D-26 D-26 37" -42" H-16 G-18 G-20 F-24 E-24 E-26 E-26 43" -48" 1-16 H-18 H-20 G-22 F-24 F-24 E-24 49" -54" l-16G H-18G H-20G G-24 F-24 F-24 55" -60" l-16G l-18G H-18G G-22 G-24 F-24 61" -72" NOT J-16H l-18G H-22G H-22G H-24 73" -84" DESIGNED l-18G l-20G l-22G l-22G 85" -96" J-18H l-18H l-20H l-22H 97" -108" K-18H J-18H l-18H 109 11 -120" K-181 J-181 Proposed New Project date September 01, 2006 sheet title SCALE : AS SHOWN revision sheet number BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN wa WILLIAM A. BERRY & ASSOCIATES {I CONSUL TING ENGINEERS \ • 10200 NW251h STREET, SUITE 111\ .. Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility HVAC DETAILS AND SCHEDULES M · 7. 1 285 Sevlla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamlamlObellsouthnet DORAL, FL 33172 \ · TELEPHONE: 305-513-9000 '•, FAX: 305-513-9100 M.S E!!W.;P:E.#40971 EB 0006543 ELIZABElH T. PRIDA, P E. #69464 S.W. 73rd Street & 58th Avenue, South Miami, Florida project number 212>12>&8':I drawn by J.L 89 of 162 97 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevlla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bdamlamlObellsouthnet AIR DISTRIBUTION SCHEDULE PACKAGED AIC UNIT SCHEDULE SYMBOL USE lYPE ACCESSORIES MFG. & MODEL NO. REMARKS MARK No. PCK-1 PCK-2 ® EXHAUST THIN LINE GREENHECK ESU-130 REFER TO FLOOR PLAN FOR SIZE. AIR STATIONARY LOUVER -1 1 /2" FRAME. FLANGED UNIT lYPE PACKAGED A/C PACKAGED A/C ® OUTSIDE THIN LINE BIRD SCREEN GREENHECK ESU-130 REFER TO FLOOR PLAN FOR SIZE. AIR STATIONARY LOUVER 1 1/2" FRAME. FLANGED NOMINAL CAIPACllY, MBH 7200 12100 MAX. SUPPLY AIR, CFM 260 340 AMBIENT AIR TEMPERATURE 'F 95 95 NOTES: 1. ARROWS INDICATE DIRECTION OF AIR DISTRIBUTION. {SEE FLOOR PLANS). COOLING W 585 1090 2. MAXIMUM NOISE CRITERIA: 25/30. COOLING AMPS 2.4 4.2 3. MAXIMUM NECK VELOCllY: 500FPM. 4. DIFFUSERS AND GRILLES IN ALUMINUM CONSTRUCTION. HEATING KW 2.3 2.5 HEATING AMPS 9.2 9.4 EER 12.3 11.1 ELECTRICAL SERVICE fl /Hz/V 277/1/60 277/1/60 FAN MOTOR HP /FLA 0.075/0.46 0.125/0.71 MANUFAC. CARRIER CARRIER FAN SCHEDULE MODEL # 52PQ207-4 52PQ212-4 UNIT DESIGNATION EF-1 AREA SERVED MAINTENANCE RESTROOMS LOCATION CEILING FAN lYPE CENTRIF. CEILING LL.I TOTAL AIR CFl.1 75 (..) ~ TOTAL STATIC PRESSURE, IN. W.G. 0.45 a:: e FAN SPEED, RPM 950 a:: LL.I 0... DRIVE lYPE DIRECT MOTOR lYPE a:: MOTOR SIZE, (HP) ~ 15/140 0 ::Iii ELECTRICAL SERVICE AVAILABLE 120/1/60 COMPANION CURB (PREFAB) - HVAC DESIGN REOUIRES= YES NO DUCT SMOKE DETECTOR v FIRE DAMPER(S) v SMOKE DAMPER(S) v _J CURB HEIGHT -"' FIRE RATED ENCLOSURE v f:::J FIRESTATS u -y FIRE RATED ROOF CEILING ASSEMBLY v FIRE STOPING v OPERATING WEIGHT, LBS 10.0 SMOKE CONTROL v DESIGN MANUFACTURER & GREENHECK SP-B110 FLORIDA BUILDING CODE SECTION 4901.4(C) MODEL NUMBER EXCEPTION GROUP I ONLY HVAC SCHEDULES SCALE: NTS. Client: WITH Proposed New Project City of South Miami wa WILLIAM A. BERRY & ASSOCIATE CONSULTING ENGINEERS 10200 NW 25th STREET, SUITE 11 DORAL, FL 33172 TELEPHONE: 305-513-9000 Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida FAX: 305-513-9100 M. SAEE , .. #40971 EB 0006 543 ELIZABETH l PRIDA, PE #59464 I 1ilil SPLIT TYPE AIC UNIT SCHEDULE & ,,,r y . r UNIT lYPE CEILING SUSPENDED • WALL HUNG NOMINAL CAIPACllY, MBH 1B.O 9.3 MAX. SUPPLY AIR, RPl.1/CFM 862/500 350 AMBIENT AIR TEMPERATURE 'F 95 95 MARK No. SP-1 SP-2 WATTS 92 25 cc: 8 HP 1/16 -C ;;;:; ELECTRIC SERVICE -/Hz/V 208/1/60 1151/60 OPERATING WEIGHT LBS. 10B 1 B.7 MANUF./MODEL No. CARRIER 40QAB01B CARRIER 40BNC009 MARK No. COND-1 COND-2 SEER 12.0 ' 13.0 ' ' .,, TOTAL KW 1.7 840 WATTS :z "' :z 208/1/60 115/1/60 w ELECTRIC SERVICE -/Hz/V C :z 0 (.) MANUF./MODEL No. CARRIER 38HDC018-3 , CARRIER 38BNCOOJ / NOTES: THE 40QAB018 FANCOIL IS A 40QAB024 UNIT USING A DIFFERENT MOTOR SPEED FAN TAP. d a t e September O 1, 2006 on 2-20-07 ------ sheet tltle HVAC SCHEDULES proJect number 212>0&8~ drawn by Jl. SCALE : AS SHOWN sheet number M · 8. 1 " ' ' ' ' ' . ' ' ' ' ) ' • ' . I • ' ' • ' 90 of 162 98 Ill -CM. P1MS RIR Nil EX/,CI LOQffl0N) . ' 12" \ .. / i RETtl48 1375lsift > I 4"(920 Sf}-tf' BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevlla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305 444 0181 EMAIL: bdamiamlObellsouthnet WV wa WILLIAM A. BERRY & ASSOCIATES CONSULTING ENGINEERS 10200 NW 25th STREET, SUITE 111 DORAL, FL 33172 TELEPHONE: 305-513-9000 FAX: 305-513-9100 EB 0006543 IHASETIW' 12INIS) 1:IIIO CM. Eld! (Sjollr,1) Iii 1 1/4"CIMD II a.G. ••• SM:E RIR • ,,. 1 1/4"C'NPID N Cl.fl. ii, ,., SI\U RIR A/C -~'H-CXNJENSA1E ~ •· ' ,!! ____ , 4"Sltl. S1UIHP __ ..,,. ____ ..,. Fll1IIIE ,. O)P, RESTAURANT 1 4761 sqft : "OCCUPATIONAL" N 15'-'.)" ALLEY \ONE WAY) IIIIES. Ml.SIHTNl'INlllHASEIMSIE PIPNl2'AND SIMlllR Sllfll. SLOPE ,a 1/4'/FI ltll Ml. GR£ASE IIISIE Pl'M 3" Nil BEGER SIW.J. SLOPE /a 1/!'/FI Ull51i l«IIED OIIEl51IISE. FOR l'IIB«l Rm.IE SlflM.E RMR 1ll NICHl1ECl1M PIAN. CON1IW:1llR Sllfll. -PRIER 'IIU'ES AT tfNIST C.W. SOIR:E FOR FlOOI! llRMil -. SEE 11W' Rl5fJI. Dml ON SlfET 14.1 If . s.w. 73rd STREET ~ IIWJIIG Fill OPDIIG IN.IE N BOIi -------------- CD fIRST FLOOR PLUMBING PLAN SCALE: 3/32" = 1'-0' Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida RETAIL 1 1041 sqft ii! 7 RETAIi .. 2 1041sqft date September 01, 2006 revision 11-20-06 12-11-06 01-08-07 02-20-07 ' i ' i: .. , ··--·~-··· -::<,,l_;___, CATCH II/SIi . {SEE CML PUNS RI! bmLS NI) ElUll'I LOQffl0N) I Lo.-,,-'INV.ElIV.+8.52' f(NG'IDJ : ( PICK WATER ~t~ .~, w I zj i' > I !i < ~ I " . f; [; t, .;,: ii; 3: i (/) 1t fr/ I I ! ! sheet title FIRST FLOOR PLUMBING PLAN project number 200589 drawn by J.G, SCALE : AS SHOWN sheet number P · 1 . 1 91 of 162 99 i ,, ! l BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevlla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bclamlamiObellsouthnet I 4" V UP & DN ~r ... ,..,. .. ·7 ===::~=;:::= ·:·:::··· ....... ~,.""'"•~A¼Jii~· .-:-:=--::;-:=--:=--?:-~·~·--.F. =1~2====2~~~~~lll======~~~~ 43--~ ~······L 4' ' i ' \ \ ··········'\~--I ' \ \ . /' ~ \ . :.. \\.. \\ i ,/- ' ' // ... //~-~--··.l=i ·~ 1 i 1 / J1·"''~t2 \SF) .,,/ ....... ,' \ \ \ \ \ \ / \ I f---l __ r ri'.~ .. t .. )_ \ \ \ \ \ \ .. '' i \ \ \ \ \ ' \ \ \ • \ . \ • \ \ \ \ \ ' \ \;:;;;\;.,,:.;;.;;_;;;;;'.;;~ ...... '·::• ; .. ,r, .... ~~,,,,. ' 'C ' ! ;i Client: // .• / // // )'\z 7 '/: N -~·-... ·.' _/ I I ' . f-•=i!cll,1& !=\i~if'i'O'~., Itff ,~;~~: i f ; :3Sf),,~:r~~••••J,,::l::,,:-_lE\f;~;,0,,,,. i i • ' 4"G0 ; el T• -,-----~--\~:_ '-'--=---i-, -,_ J'.:'" .::.rr~~ -T ' '· ' \ ✓ \ / \ \ '. N I ' / • ' • . . , ; ,/ y " , . . . . . / , , ' . ' / / . / \ / / \, , , \ / ' \ / ,,/ \ . . \, / \ ,/ • I / I I • /' \ /( . / l \ / I /I I I ' / / / I / CD SECOND FLOOR PLUMBING PLAN SCALE: 3/32" = 1 '-0" WITH Proposed New Project \ \ \ \ \ ·--'"~ -~-- \ \ \ \ \ ' \ \ \ I ! / : . -----, .. ~ WILLIAM A. BERRY & ASSOCIATE$!~: { CONSULTING ENGINEERS c : 10200NW25lhSTREET,SUITE111j \'-$ I> wa Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility DORAL, FL 33172 ',,\I;";,•• , TELEPHONE: 305-513-9000 i,~, ~ r •· ,-•• •" _ r / FAX: 305-513-9100 ~.,_~§.J:o • EB 0006543 M. ~AT Ii._ ,.P.E:140971 ELIZABETH't'.lll\1DA, PE. #59464 Miami, Florida S.W. 73rd Street & 58th Avenue, South Miami, Florida \ \ \ \ ! ! i; ii / i ; I ! • I date September 01, 2006 revision 11-20-06 \ \ / ! i / / / ! \ \ \ \ t1 Q) ~T,/ . • / i / i / i / +------:/ .... / / -1 , I ' ' • j \ ! J.-- ··•·····-·····.·•·t::.,.,l.,~~·=····· ~ --r ,:;;;il&IE\L, sheet tltle SECOND FLOOR PLUMBING PLAN project number 200::>8~ drawn by j.G. SCALE : AS SHOWN sheet number P-2.1 92 of 162 100 I Ill I I_ /,·--., :_A:,-· ---.... ____ ,,, BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305 444 0181 EMAIL: bdamiarniObellsouthnet \ I j ' ' \ \ I I 4" V UP & llN ----i . ; , ~-.:.:·.:.::_J:.::·.·_·_:.:·.~:':'..':'., \ \ ' GOL 1-F'"i [ i ;\'GD ·····1·····+.----+-~.{2 ... GD / 1 \/ ,, t~ \SF) ' ' \ \ • \ \ ........... ::::~- \ \ \ \ \ ---_l__ '--1-'"""'al \ \ \ / R MPDN.5-?"."h ---t i !/" /i i=,:;;;:.::.;::.;:.::::.:.~ ;;.~-,------- ... -·---:~'.:~;:'.::::::.:2.::::::~'.~-+:::::::'.:::::3,:,-::.::::.::.;:.·_:'.::.:::::;=:::::r.:~:::: ·: i-T,1, ~":,~: ,. , ):~ r :\J~· ,Se . . .,. ;~·i!!!!.l·..i.--.-, ' \ ' \ \ ' \ ro·:ri<t'1 ; --/ \ l 1, / \ '\ _I \ \ I ' : ' \ V \l / i\ , ; \ / ,_ , ;' \ <"' \ '·,-................... . . , i ; I / ! :' y /! / l1/ ,/ l / / . ' , , ! / I , I / I ' '· \ \ / , ,-,,,',"'\"'I•,-~---:.-.. ·': '-. -. ,-. ···c_,-t,,[ .. ~~' ~--g-·~-!·· ~~~~~~±:;J1\\d/~{,~t,~~~~~§:22± ··i'""=""c"tCi"··="·'· ~~~;?~E='"";"'"''~''""~""~·~··""~·-~··'~~~\'ij;il~:- .. . -........ I "'··· ,,m.. . , .· .· .· -~~:;~·':::··=·· -·· . .;;-7• • • -•.. ""-'"· -====-2:;;;_.~-------. --------~-- ,, ....... ,_ ........... ,. ,m,,;,,,..,,_,=•1-••••' , Client: N ... ~'('<E ·CASf 'f.Y~:•.!:lf<.l)W •.;;; DECOP,n..nvE R,'\iUNC CD lliIRD FLOOR PLUMBING PLAN WITH City of South Miami SCALE: 3132" = 1'-0" Proposed New Project \ \ \ \ \ \ ' wa 1---- f WILLIAM A. BERRY & ASSOCIATES! 102~0N~~;;~~~::~~:il~~ 111 \\ ' , Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility DORAL, FL 33172 ,, TELEPHONE: 305-513-9000 \ FAX: 305-513-9100 '•,, · _ .• EB 0006543 M. SAEWFI\Ta.llMl;-1' .. #40971 ELIZABETH T. PRIDA, P.E. #59464 S.W. 73rd Street & 58th Avenue, South Miami, Florida i ! \ \ \ \ \ ! i • I ' I j / d a t e September 0 1, 2006 revision 11-20-06 \ \ \ \ ! ! ! \ \ \ \ '± . ----······ sheet title THIRD FLOOR PLUMBING PLAN project number 200&8':l drawn by J.G. SCALE : AS SHOWN sheet number P-3.1 93 of 162 101 I j ( c;';,_. ----,. ___ ,/ BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevlla Avenue Coral Gables, A 33134 305 444 4433 fax 305 444 0181 EMAIL: bdamiamiobellsouthnet \ ' \\ ' . \.\ ' ' \ \ \ Ii ;...I ___ _i_ ___ ·_\"::.:..i i I ' j' f \ ' ~-! \ L1 I .... L --~ :;;;~;:'51':.'!_i[:.i "" WILLIAM A. BERRY & ASSOCIAT . CONSULTING ENGINEERS 10200 NW 25th STREET, SUITE 111 DORAL, FL 33172 TELEPHONE: 305-513~000 Fl>:X: 305-513-9100 EB 0006543 . \ \ \ \ \ \ \ \ \ \ M. SAEED FATEMIAN, P.E. #40971 ELIZABETH T. PRIDA, P.E. #59464 Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida RAf,IP UP T1· lD:'E. HVE· i:,:.'% -- ... --+ .. ,. N \ \ ' ' r-< c:::::~, ,)~;\ .................... L .. _ -~ '~~----~~(· ....... \, ... \! \ \ \ \ \ ' I \ . \ / ' . ' I ~\ ' / \i i\ ' \ ,' i \ ' : "<,;-;,*··· :::::::; ~~~~2=§~;,~--~~~~2~~~ ,:;;,.,~,~~=•=,, ,;z : -~ ,::n,, . ,/ /i !' . / / // . j /I I . . . I I (I) FOURTH FLOOR PLUMBING PLAN SCALE: 3132" = 1 '-0" WITH Proposed New Project City of South Miami :· "'f&'.'"J. r . . -~·• ■-i \ ' j . I \ \ / ==== ---~-~--~~~-; ~~~=,.==,~l=,=j1=_= .. ~,i~~~, ' . -~w~~°R+1-ftf!.t1rc 1 . \ \ \ \ \ ' l=~,.L,.,.,...;,_.__, \ ' \ \. \ \ ,~~a·ac·•=·-··· ·····' ~ _ J I r J I ! ! / \ \ ' i/ ,; ! / d • t e September 01, 2006 revision 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility ,& 11-20-06 S.W. 73rd Street & 58th Avenue, South Miami, Florida \ I • ! / ' I ! ! Fc.EV2 \ / • I • / ! \ sheet title FOURTH FLOOR PLUMBING PLAN project number 200&89 drawn by J.G, SCALE : AS SHOWN sheet number P-4.1 94 of 162 102 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevlla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305 444 0181 EMAIL: bdamiamiObellsouthnet STAIR 1 ROOF ~-- ''-----,, __ (200 SF) ', ', ',, ,,_ ......., ; ·'"r·f- 4"X4" OOWNSPOl/T TAIR 4" VENT lE!lMl~TL 1-o• AFF i ... ······"· ' ,\ ';-~-----'-- -, "X4" OOWNspour . , l\ ' : ,+·'--+--f---- TO\DI~ ON SLAB 1 'l", P=,_,;,, ..:;,.-.;.,,.d,1·=,,,.;,:_,,. ___ -',-::.::.::.-;.:~.+/L,r-,:: .. -: ... -:,~i_;__ _ _.:___····.---_,---, -; ,-... -'-; .. -,-t-J --cc-.::::-1< ~\1-i ,--.. --.-------~-, -+---,-_-,,.-., .. -,._-, -1 ··-; -+-----,. -. ~ j,1': --,--~---- \ ! I i T I i ! : I \ \ \ \ \ \ \ \ f-------jl J. •. \ \ \ \ \ \ .... , .. , .. , ·=~-----,.-.. -~ ..... .J. \ ' Client: \ \ -\ -t ········'·= \, \\ -\ ' -' \ ' \ \ - \ ' \ ' ' \\ \ N ' \ \ \ \, \ \ -! I \ \ / f i , .... ,,.,,,-t, \ ' \ ED Flf Iii FLOOR PLUMBING PLAN WITH City of South Miami ' I I / / / / , ' / I ' I ' SCALE: 3132" = 1 '-0" Proposed New Project / I I , \ Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida I I / ! i / ! ! ; i / date September 01, 2006 revision 11-20-06 i ! ! '/ ; i ; ! STAIR 2 ROOF /' _,. ,-;·). ·~/ / ~~~:_;------,~--~'_-::_~~_t-.r-rf-, ---- ! ! ! sheet title \ \ \ - \ \ \ \ FIFTH FLOOR PLUMBING PLAN project number 200&09 drawn by J.C. , I 'l I SCALE : >S SHOWN sheet number P · 5. 1 95 of 162 103 ,,,.,,,,..,,,..-,,,1 ~- 4"(14 Fil ESIII.) I I I I i' I 4" 'IENf lP TO ROOF I I I I I )I TIE -IN TO SI.NIT, IATEIW. -_ /(SEE CIYI. PLANS FOR CONT,) _ ...... .,,,. .... • 1. .,,,, ', ✓3 V ,,,.,-_ ___ '', ~---' ,,,,. ., .,,,, .,,. ......... '...._ r (IWO WA~) ,,,,. ,,,,. -~', ''""'--.,.,-, ~llolLTIW'~ LtlflS) TIE-IN TO SI.NIT. 1AmW. _,,,,.,,,,.,' ./~~#~ f~,, ~ 1) /(SEE CM. PlANS FOR CONT.) ,--l -----~~!:::::::--COOG (!WO WAYS) •• , I / "(21 Fil ESTIM.) .......... ✓3•y ' ........... >✓,_rv "(21 Fil) -------CI) --~-v -r' I 4"(30 Fil ESTIM.) 4"GW. S1UII-OllT FllR P-2A I 4°(14 Fil ESTIM.) F\JllJRE USE{lYP,) I P-1A P-1A. AMERICAN STNnlRD 'MADERA" MOllEl J043.102 SLOIN FLUSH VALVE f 111 Nil SEAT f95 Ell OLSllNIIE. P-2A. MERICNI STNnlRD "I.IJcERI£" MODEL 0358.041, CHICAGO FAIICU J33-ISS5 Nil OfFSET GIIO DRl,IN 4"SNI. S1l.lB:-Olll FIJ1IJRE USE(TYP,) 4"(30 Fil ESTIii.) 4"GW. STUB-OUT FllR FIJ1IJRE USE{lYP.) llE-IN TO SI.NIT. IATBW. ;:SEE CML PLANS FOR CONT.) "(132 Fil ESTIii.) GR£ASE lRAP {2 LWIIS) 1.2lill. ll,IL fACH 4"(17 Fil ESIII.) \S1lflm 3) 4"(14 Fil ESTIM.) 4"(14 Fil ESTIM.) ~ ALL 5'.NITARY AND GREASE WASTE PIPING 2" AND SMIJJ.EII SHAil SlOPE AT 1/4"/FT AND ALL GREASE WASTE PIPING J" AND BIGGER SHALL SI.OPE AT 1/8" /FT UNLESS NOTED OTHERSWISE. FDR PWMBING FlXIIJRE SHEllULE REFER TO ARCHllEClURAI. PLAN. OON11lACTOR SHAU. PRO'llllE PRIMER V.11.VES AT NEMfST C.W. SOURCE FDR FL00ft CRAIN PRIMING. SEE 1RN' RESEAL DETAIL - I l ,,.-., I -.... ___ ,/ HESH REINF ' I (·-: I 4'-0" \ "-4, --1--.JJ , ........ I 1------1D'-5"'---+---I L _____ _ ____ :J f'RAHE & C□VER (TYP.) · TRAFFIC LID, 7" THICK i5 I!! 7• c.c I L:'---.=---_---''---::_----r--::_--'_ I GAL 1250 REINF. 6X6 10/10 C□NC, 3000 PSI, 28 DAY, GREASE TRAP DETAIL N.TB. 4" 'IENf UP TO ROOF i' I I GENERAL PWMBING NOTES: 1 • Al work lhall be done in accordance with tho Aorida a.lklng Cado and "1lh an appllcabll regulallono. 2. All horizontal oanilmy piping T or ..,. .. , ■hal elapo at 1/4" per foot (minimum). J" or la,v,r lholl lllope at a 1/8" per fool (ml~nun). J. The c:an,pletod inalallation lhall be fully guaranteed Q9Cllnol dolec:tlve mat.riolo and/or Improper warkmcllllhlp for a lrirll"""' ol one yoar for mat■rial and labor. ---. I ,,..,.,,,,. ' I 4. 1,11 autdaorl flaor -aut■ ■hall be terminated up lo grade and ■hon be marud. 5. MATERI.IIS: .,,...,,-.......... ) ,,,,. ' ,,,,.. .,,,,,. 4•(42 FU ESTllil.) '-.... .,,. .,,,,. a. Sall, 1alle Clld ..-rt, and ■larm: Cool Iron plpeo and :i.:r-~ ~ =~"\:':.:;..r'1u ■sl and In __.~1/T \11,1.'IED OOll£T FOR FIJ1IJRE USE SANITARY ISOMETRIC-PLUMBING &. um 4 "SAN. STUB-OUl_ f!)8 F\JllJRE TEIWIT (fl'P.) .,,,,. .,,,,, .,,,,, .,,.. .,,,. ,,,,. ..._,,,,. b. llomlslic watr. Clloo,r0 P.iPt, Type L with neat """"lhl cappor fltlilol. Type.,., Iii coric■olod -is DCG6jihml■. ldate piping fnm oancret,, with l...i.t.iv material CATtH BASIN (SEE CML PLANS FilR EXACT LOCAllON) 3"G.IS PIPE H.IHGIIIG IN CLG. SP,i:E (rnWIT 1J wco 1 1/4"Cli'PED IN CLG SPM:E FOR A/C CONDENSATE DRl,IN.IGE "--.....;z.lllll.EL N01E; THIS DETM. APPIDBLE FOR RESEAUNG OF ALL FLOOR DR,IINS Ell MrNIS DF A JOSNil 88210 PRIMER VALVE INSTAUED IN Tl£ l£AREST C.W. 5CJlllCE. ___,,,,.-JOSNil88210 ~ TRAP RESEAL UlllER IAVAlllffl' 1/2" C.W. 1H: TO IAVAlllffl' ~--1/2" TIW' RESEAL IN Mi TO FLOOR DRAIN 1/2" SUlPED TO THE FLOOR llRl,IN TRAP RESEAL DETAIL N.T.S. FLOOR DMIN TO "P" lRAP ......... J"GAS PIPE CAPPm IN CLG. SP/a: (rnWIT 2) NTS GAS=-REGUIATORS W IIT-oFF VALVE ( W/GAS CO.) "~~~HANOING IN ........... ......... ........... ~v~ ........... (IW,NT 2)---.. :-,..... 1 1/4"CAPPED IN CLG ~ .. ::..._ ......... A/C COlllENSATE DRMWlE -_,. ., :-,..... CAltH BASIN (SEE CML PLANS FilR EXACT LOCAllON) -4"SNI. STUB-IP J!i!!) ,,,,. ~ FIJ1IJRE TEIWIT ,, ". ..,,,,..,,,,".,,,,,.,,,,, \4■ V --~ ,,,,. 4 "SNI. STUB-IJP FOR 4" V STUB-OUT FOR F\JllJRE TEIWIT (TYP.) F\JllJRE TEIWIT GAS METER-REGULATOR W/SIIJT-oFF \/,II.VE (OOORD. W/GIS CD.) 4"(28 Fil ESTIii.) -.......:: .. ":-,..... -.......::,. ":-,..... DRIY LIG -.......:: .... :-,..... (TYP.) , , .. -.......:: .... .....__ ~• (2)1"CW CAPPED -----~CLG.SPM:E -........ -,,:;,· (lENNIT 8) ........... --... .. .. ~ .. .....__,___ __ ,1 1/2"CW HNONG IN .,~7 1 1/4~ IN CLG SPNi.N BOX ........... -... CLG. SPACE ~.,-FDR A/C CONDENS\TE DRAIIW:E 2"~" .... ~~ ~"CW CAPPm J"U/G .&. ffllBDL GD •· Conda,_ drain: DWC ~ 1,a:opt uoe rJfN Copper pipe and fltt!ng■ In a/c claooll. d. llomlslic -ai°"" _.,1,1y: Chrome flnloh luillnll with angle lhut all' volvu. PLUMBING LEGEND SINITARY LINE --GR£ASE WASTE --so--STORM DRAINMlE -co-COlllENSATE LINE ---COID WATER UNE ----HOT W.filR LINE -----HOT WATER RE!lllN LINE ---INllRECT WASTE ------'IENf LINE - G GAS LINE + PASS THRU SLAB --+HB HOOE IHI W/ SHUT-OFF VALVE AND VAllJUM BR!'Al<ER COOG CIEAN--OIIT ON GRMlE wco WALL QfAN OUT Fl)-SQ1 FLOOR DR,IIN -Sill/ME W/ lRAP ~ G.W.GE RIIIN WATER l£ADER DRAIN SCHEDULE DESCIIPIION MFR. I: IIOIJEL PARKING GNWlE DRAIN JOS.111 32100 ..... -i,a: 1"CW HNOHG IN CLG. SPM:E>, (rnWIT 6 ~'(b IN BOX BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 30S 444 4433 fax 305-444-0181 EMAIL: bdamlamiObellsouthnet WATER. GAS AND CONDENSATE ISOMETRICS-PLUMBING NTS Client: WITH , .....,...,, 1/4"t:IWED IN CLG < FIii A/C C0NDENSA1E DRMWll! 1 1/ 4 "CN'PED IN CLG SPACE FOR A/C CONDENSATE DRAIIWlE J"U/G Proposed New Project .. <> ~)1 "CW CAPPED ~S1'1l Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida J"U/G .&. "U/G .&. CATtH B.1SN (SEE CML PLANS FilR EX/Cr LOCAllON) d a t e September 0 1, 2006 revision P.,. BLDG DPTMT COMMEN15 Lil 11-2-06 _&. 11-20-06 & 01-08-07 & 02-20-07 sheet title ISOMETRICS· PLUMBING project number 2~~6'3 drawn by J.C. SCALE : AS SHOWN sheet number P-6.1 I' 96 of 162 104 Cl'R)H -{m CM.. PUNS Fill! DEIM.S Hfl ew:r L0CAlllN) c1a\1SF) 4• ~ (200 SF) 4"(2190 4"(2JIIO 10"(11BJ SF) 4"00 (2190 SF) (~SF) (7&"00 SF) 8" 4"00 (2oo SF) 4"(2Jllo SF) 4"(3150 SF) @ ~ 4'(ZIIO SF) 4"00 (2oo SF) &fl. .ma.: 4"00 (200 SF) 6"(7850 SF) 4"(33!!0 SF) 4"00 (2oo SF) 6'(2790 SF) B"(lll5o SF) JllllL 12" STORM DRAINAGE ISOMETRIC-PLUMBING NTS BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE · INTERIOR DESIGN 285 Sevlla A'Wnlfl Coral G:bles, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamlamlObellllOUth.net "" WILLIAM A. BE:RRY & ASSOCIATE:$ CONSULTING E:NGINEERS 10200 NW 25th SlREET, SUITE 111 DORAL, FL 33172 TELEPHONE: 305-513--8000 FAX: 305-513-9100 EB0006543 '• ,, M SAEED , ; . #40971 ELIZABETH T. PRIDA, P.E. #59484 Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 4"00 (2oo SF) 1"(4780 SF) 4"00 (200 SF) 1"(4IIIO SF) ' ' ! , I 4"00 (400 SF) 4"00 (400 SF) 6'(41 IIO SF) ® 6'(45110 SF) e'(4IIIIO SF\ D1/4" suJllE 4"00 (200 SF) 4"00 (200 SF) 4• 4"(2400 SF) 4"{2800 SF) 4• Jlll,fJ. 4"1300 SF) 4"1300 SF) - ~ "(2nO ~ 4'(1800 SF) 4 "(1800 SF}- ® 4"(1800 SF)-- 4'(1800 SF)--- .1111.fl,; 4"{2800 4'(2!IIO 4• ® 4"00 (2190 SF) 4• .¼DI.El. 4"(2490 SF) @ &fl. 4"00 (300 SF) 4'(2790 SF) 4"(2790 SF) 1o"(115IIO SF) .....__,,:::..... 12"{18740 SF) ____ .. Proposed New Project South Miami !Municipal Parking F;acility S.W. 73rd Sti:eet & 58th Avenue, South Miami, Florida i , I ; i ! date September 01, 2006 re,lslon sheet title STORM DRAINAGE ISOME TR IC•P LU MB ING project number 21Z>IZ>&0'3 drawn by J.C. SCALE : AS SHOWN sheet number P·6.2 .I 97 of 162 105 i 11· I " ,ll II ' I SYMBOL D [Z] f----+----1 H <ll @ II] $a $M 0-i O=j d1' en + GR 8:1 HNl ~ ~ ~ MN I~ KD Q) @> I-© [>l ~ [TI mm llllf"1lll -D .JI) 3 .JI) 3 20 0 [fil ELECTRICAL SYMBOL LEGEND DESCRIPTION RECESSED DOWN LJGm FllffiJRE. UPPER CASE LETTER DESIGNATES RXTURE "TYPE, ("TYPICAL). LOWER CASE LETTER DESIGNATES SWITCHING. lJGHT FIXTURE, -WALL BRACKET. lJGHT FlXTURE, -WALL BRACKET ON EMERGENCY. LIGHT FIXTURE, FLUORESCENT -<IB". LIGHT FIXTURE, FLUORESCENT -<IB" ON EMERGENCY. 2'x4' LAY-IN FLUORESCENT lJGHT FIXTURE. 2'x4' LAY-IN EMERGENCY FLUORESCENT LJGHT FIXTURE. FLUORESCENT STRIP LIGHT FIXTURE EMERGENCY LIGHT Will-I BATTERY PACK AND TWO HEAD LAMPS. EXIT LIGHT FIXTURE Will-I BATTERY BACK-UP. ARROWS INDICATE DIRECTIONS. MOTION (OCCUPANCY) SENSOR -360', CEILING MOUNTED IN OFFlCE AREA. LIGHTING CONTROL RELAY Will-I 4 POLES, 120 VOLTS COIL IN NEMA 1 ENCLOSURE. SINGLE POLE SWITCH, 20 AMP, 120/27N,,SPECIRCATION GRADE. LETTER DENOTES LIGH1S SWITCHED. MOUNT AT 48' A.F.F. UNLESS Ol1-IERWISE NOTED. MOTOR RATED SERVICE DISCONNECT SWITCH WITH OVERLOAD PROTECTION. SINGLE RECEPTACLE; 20A., 125 V.,GROUNDING TYPE. MOUNTED 18' A.F.F. (UNLESS 011-IERWISE NOTED). DUPUEX RECEPTACLE: 20A., 125 V.,GROUNDING TYPE. MOUNTED 18' A.F.F. (EXCEPT AS NOTED). ROOF MOUNTED RECEPTACLE -SAME AS ABOVE. MOUNTED TO BASE OF HVAC EQUIPMENT IN NEMA 3R ENCLOSURE. FLOOR BOX MODEL FSR FL540P OR EQUIVALENT. SHALL HAVE ACCESS FOR CATV A/1/ WIRING, CONTROL & DATA; SHALL INCLUDE TWO 1 ' CONDUl1S STIUBBED ABOVE CEILING GRID OF RESPECTM: CLASSROOM. DUPUEX GFI RECEPTACLE; 20A.,125 V.,GROUNDING TYPE. MOUNTED 18' A.F.F. EXCEPT IN TOILETS NEXT TO SINKS WHERE IT SHOULD BE MOUNTED AT 42". TELEVISION. ANT. OR CABLE OUTLET WITH SINGLE GANG. QUADRUPLE)( RECEPTACLE -18' A.F.F UNLESS 011-IERWISE NOTED. FLOOR BOX MODEL FSR FL540P OR EQUIVALENT.SHALL HAVE ACCESS FOR CATV A/1/ WIRING, CONTROL & DATA; SHAUL INCLUDE TWO 1' CONDUITS STIUBBED ABOVE CEILING GRID OF RESPECTIVE CLASSROOM. TYPICAL. SEE DETAIL 1 ON l1-IIS DRAWING SPECIAL PURPOSE RECEPTACLE -SEE FLOOR PLANS FOR NEMA CONFIGURATION. MULTI-OUTLET RACf)l(AY ASSEMBLY -WIREMOLD G-3000 WITH ALL ACCESSORIES. PROVIDE DUPLEX RECEPTACLES 24' O.C. COLOR AS SELECTED BY OWNER. WALL OR CEILING MOUNTED JUNCTION BOX. MINIMUM 4"x 4' x 1 ½' Will-I BWIK PLATE. J-BOX Will-I CONDUIT STIUB-UP CLOCK OUTLET WALL MOUNTED 7'-6' A.F.F r10' A.F.F. IN HIGH CEILING AREA). 4' SQUARE INFORMATION OUTLET BOX ("DATA") WIT\, SINGLE GANG RING FOR 1 JACK MOUNTED 18'AFF TO CENTER OF OUTLET. SEE NOTE #2. 4' SQUARE INFORMATION OUTLET BOX ("TELEPHONE/DATA") Will-I SINGLE GANG RING FOR 1 JACK MOUNTED 18"Aff TO CENTER OF OUTLET. SEE SHEET NOTE #2. 4" SQUARE INFORMATION OUTLET BOX ("TELEPHONE") WITH SINGLE GANG RING FOR 1 JACK MOUNTED 18'AFF TO CENTER OF OUTILET. SEE SHEET NOTE #2. 4" SQUARE INFORMATION OUTLET BOX ("TELEPHONE') W/SINGLE GANG RING FOR 1 JACK MOUNTED AT 56'A.F.F. TO CENTER OF OUTLET. SEE NOTE-2. CONDUIT RUN CONCEALED IN WALLS OR CEILINGS. CONDUIT RUN BELOW FLOOR SLAB OR BELOW GRADE. SEE SPECIFlCATIONS FOR REQUIREMENTS. TELEPHONE CONDUIT -RUN CONCEALED IN WALLS ONLY -3/4' DIA. MIN. STUB UP 6" AOOVE CEILING SPACE UNLESS 011-IERWISE NOTED. RUN EXPOSED IN OTHERS AREAS, SEE NOTES 1 &: 2 THIS SHEET. AAROW DESIGNATES "HOMERUN" TO PANEL, TICK MARKS DESIGNATE NUMBER OF WIRES. ( +-NEUTRAL. -w,-HOT LEGS, -\-BONDING WIRE) E)(POSED CONDUIT. TRANSFORMER -FOR DESCRIPTION SEE POWER RISER DIAGRAM. DISTRIBUTION PANEL (277 /4BOV.) LIGHTING OR A/C PANEL (277 /<IBOV) POWER/RECEPTACLE PANEL (120/2081/.) DISCONNECT SWITCH -HEAVY DUTY NEMA CLASS 'A' FUSED IN NEMA 1 ENCLOSURE, OUTDOOR TYPE NEMA 3R . DESIGNATES SWITCH RATING, 'J" DESIGNATES POLES; '20' DENOTES 20 AMP DUAL ELEMENTSTIME DELAY FUSE; •30• DENOTES JOA SWITCH; •o• DENOTES NON-FUSED SWITCH. MULTIPOLE LIGHTING CONTACTOR FUSE; •30• DENOTES JOA SWITCH; •o• DENOTES NON-FUSED SWITCH. SYMBOL @M<l WP (j) ELECTRICAL SYMBOL LEGEND DESCRIPTION ELECTRICAL 11-IERMOSTAT PROVIDED BY MECHANICAL CONTRACTOR AND INSTALLED BY ELECTRICAL CONTRACTOR .. VARIBLE FREQ. ORNE Will-I LINE SIDE BRAKER FURNISHED BY DIV. 15 MrD AND CONNECTED BY DI\/. 16 AIR-CONDITIONING VAV BOXES. CLOSED CIRCUIT TV CAMERA FOR SECURIT!' SYSTEM W.P. INDICATES CAMERA Wll1-I WEATIHERPRCOF HOUSING AND MOUNTING BRACKET. FURNISHED AND INSTALLED BY OTHERS. PROVIDE EMPT!' BOXES CONDUIT SYSTEM TO TELCOM ROOM. DOOR CONTACTS FOR SECURIT!' SYSTEM. OUTLET BOX ONLY. EMPT!' CONDUIT TO CABLETRAY. COORDINATE MOUNTING HEIGHT WIT\, SECURIT!' VENDOR. JUNCTION BOX FOR CCTV SYSTEM (SIGNAL) MOUNT UNDERSIDE OF STEEL JOIST OR WALL. JUNCTION BOX: WALL OR ABOVE CEILING FOR POWER INFEED TO THE MODULAR FURNITIURE ASSEMBLY. KI) Q) JUNCTION BOX: WALL OR ABOVE CEILING FOR TELEPHONE/DATA T/D T/D !NFEED TO Tl-IE MODULAR FURNITTJRE ASSEMBLY. l t l GROUND ROD-COPPER-Cl..,IJJ, FOR DESCRIPTION SEE P!AN. GROUND CABUE CONNECTION BETWEEN STEEL COLUMN FOR THE STRUCTURE AND GROUND ROD. INFORMATION OUTLET NOTES: 1. ALL TELEPHONE CONDUITS SHALL BE lERMINATE □ WIT\, INSULATE □ l1-IROAT BUSHINGS. LIGHTING FIXTURE SCHEDULE NOTES: 1. ALL FLUORESCENT IAMPS SHALL BE 3500'K AND 'ENVIRONMENTAL FRIENDLY' "TYPE AS MANUFACTIURED BY SYLVANIA OR APPROVED EQUAL. 2. ALL "HIGH FIREQUENCY ELECTRONIC BALLAS1S" SHALL BE t.tANUFACTIURED BY ADVANCE: MODEL #VOF-2532-TP, OR EQUAL BY MAGNATEK OR SYLVANIA. 3. ALL LIGHT FIXTURES SPECIFIED ABOVE, COULD BE SUBSTITIUTED WITH UGHT-FlXTURES OF EQUAL QUALIT!' PREVIOUSLY APPROVE□ BY 11-IE ENGINEER OF RECORD. 4. MOUNTING HEIGHT FOR EXIT-SIGNS SHALL BE AS FOLLOWS: WALL-MOUNTED IN OFFICE 6' ABOVE THE DOOR. PENDANT MOUNTED IN CORRIDOR (OFFlCE) 7'-6' A.F.F. 5. CONTRACTOR SHALL ORDER ALL LIGHT-FlXTIURES Will-I THE REQUIRED HARDWARE FOR A COMPUETE INSTALLATION. 11-11S INCLUDES WIRING ~IP, FUSES, ETC. 6. EMERGENCY BATTERY LIGHT SHALL BE CONNECTED TO l1-IE SAME BRANCH CIRCUIT FEEDING THE NORMAL UGHTS IN 11-IE AREA AND AHEAD OF ANY LOCAL SWITCH. 7. ALL FIXTURES PROVIDED WITH BATTERY PACKS SHALL BE ABLE TO PRCVIDE A MINll.4UM OF 80% Of TOTAL FIXTIURE LUMEN OUTPUT FOR 1.5 HOURS MINIMUM ABBREV/A TIONS ABBROOTION DESCRIPTION ABBRE'llATION DESCRIPTION ABBRE.'11ATION A.C.T. ABOVE COUNTER TOP K.VA Kl LOVOLT AMPERES HSG. A.F.F. ABOVE FINISHED FLOOR MAX. MAXIMUM GND. (TYP.) TYPICAL MIN. MINIMUM V. PNL PANEL (MFR) MANUF. MANUFACTURER AMP. LT. LIGHT GR. GROUND FAULT INTERRUPTER LTG. FIXT. FIXllJRE DiA. DIAMETER REC. H.I.D. HIGH INTENSIT!' DISCHARGE U.F. UNDER FLOOR SW. H.P.S. HIGH PRESSURE SCDUIM W/ Will-I DISC. SW. MH METAL HALIDE CKT. CIRCUIT HT. {HGT) -PHASE M.C.B. WJN CIRCUIT BREAKER H.P. PVC POLiv1NYL-CHLORIDE F/N FULL NEUTRAL J.B. RGS RIGID GALVANIZED STEEL SURF. SURFACE GRS. PWR. POWER MTD. MOUNTED COND. (C) MTG. MOUNTING CNTR. CENTER CONTR. ----~ .... -.... - LIGHTING FIXTURE SCHEDULE -- Lamp Information T~oe Luminaire Description Manufacturer and C<Jtalog Number Volt· No. Type Moun\inq Flnish Remarl<s HIU LUMl1'11'\1m. KIM PGL57 /1 OOPMHUN/A/WH-P-PB2 IUVff MH tu l / PROVIDE KIM PB2 IF REQUIRED A PARKING LEVELS 2T1 >ULSE START SURFACE WHITE I HIU LUMl1'11'\1~C KIM PGL57 /1 OOPMHUN/A/WH-P-PB2 OOW MH ED 17 ' .. "M ""' It ~E.QUIKtu A1 PARKING LEVELS 277 1 :>I II C'C" C:-T.lnT SURFACE WHITE l1-IROUGH INVERTER SYSTEM V/\IWI\C-11 !VALL Mvvi, I " SUITABLE ,vK 1101 LOCAT,v" ,JE B Will-I BATTERY STAIRWELLS LUN4-232EB8UNV-BDL500 277 2 F032 T8 SURFACE WHITE EMERGENCY BAfilRY PACK 0 t ' I ~J~,r KtleJC C AREA GROUND FLOOR COLUMBIA CS8-232-4EB8UNV 277 4 F032 TB SURFACE WHITE 0 t ' I ~IN, KtleJc m1H y --T T T T -~ - C1 BATTERY AREA GROUND FLOOR COLUMBIA CS8-232-4EB8UNV-B50 277 4 F032 TB SURFACE WHITE ~Ill-I BATTERY BACK-UP VANDAL-RESISTANT CORRIDOR D EXIT GROUND FLOOR COLUMBIA LUN8-232-4E88UNV 277 4 F032 T8 SURFACE GREY VANDAL-RESISTANT Will-I BATTERY ffi D1 CORRIDOR EXIT GROUND FLOOR COLUMBIA LUNB 232 4EB8UNV BDL500 277 4 F032 T8 SURFACE GREY WITl-1 BATTERY BACK-UP 't./.:/. , ... -... :11,; ip.vrtt.K , __ F032/U6 TB E FLOOR COLUMBIA JT822-232U6G-FSA12-E88UNV 277 2 RECESSED WHITE lAL , I\; IKUFet.K WIIH I E1 BATTERY GROUND FLOOR JT822-232U6G-FSA 12-EB8UNVB50 277 2 F032/U6 TB RECESSED WHITE Will-I BATTERY BACK-UP VANDAL RESISTANT WIT\, BATTERY --~--~~-~ ~ F STORAGE COLUMBIA LUN4-232EB8UNV 277 2 F032 T8 SURFACE GREY G WALL PACK KIM WD18D3-175MH-WH-P 277 1 250 MH WALL WHITE n,u -· 100W MH ED 7 H GARAGE RAMP 11.4 PGL51/100Pl.4HUN/WH P PB2 277 '0111 oc ~T,\RT SURFACE WHITE PROVIDE KIM PB2 IF REQUIRED HID GARAGE LUMINAIRE ,vvn Mn tU ·l / KIM r~, IF KEQUIKW H1 RAMP GROUND FL PARKING LEVEL KIM PGL51/100Pl.4HUN/WH-P-PB? 277 >ULSE STAAT SURFACE WHITE l1-IROUGH INVERTER SYSTEM 'IUt'I· ·Mc.fALLJt; " "' .. I PIT LIGHT ELEVATOR PIT HUBBELL NVQB184GHG 120 18W PL WALL GREY SUITABLE FOR WET LOCATION RECESSED FLUORESCENT J DOWNLIGHT LOBBY AREA ELITE HHSPL-1-42-E-6504-WT-1'111 277 1 42W PLT RECESSED WHITE SUITABLE FOR DAMP LOCATION K 13' SURFACE FllffiJRE KENALL MR1 JFL-P-MW-32P-1-277-EL-SR 277 1 32W PLT SURFACE WHITE L WALL SPOT LIGHT Kll.4 AFlL 16-175MHUN-WH-P/WM1-WH-P 277 1 175MH WALL WHITE M COLUMN l.40UNTED HUBBELL UMC-42F-E-4 277 1 42W PLT WALL WHITE N DECORATIVE WALL PACK ALLEY KIM WD14D4-175MH-WH-P 277 1 175MH WALL WHITE EM EMERGENCY LIGHT DUALITE EZ2-D 277 2 5'11 WALL WHITE S1 ROOFTOP PARKING LOT LIGHTING l20 -1 1 .. PVLt MIU ONE FllffiJRE TO GO l1-IROUGH INVERTER POLE1VERIFY POUE LENGll-1 RELATM TO FLOCR KIM 4C-ACA21AW5-400PMH-WH-P 277 4 400W MH PULSE START 21' MTG. HT. WHITE SYSTEM. POLE TO BE ROUND ALUMINUM. S2 ,vvFTvr-'""~INU LUI UU\'11,.,v ( 17 -4 KIM 4C-ACA21AW5-400PMH-WH-P 277 4 400W MH PULSE START 'OLE MIU WHITE ONE FllffiJRE TO GO l1-IROUGH INVERTER POLE)VERIFY POLE LENGT11 RELATM TO FLOOR 21' MTG. HT. SYSTEM. POLE TO BE ROUND ALUMINUM. SJ ,uuFTvr , LUI UU\'11,nv (17 -• KIM 4C-ACA21AW5-400PMH WH P 277 4 400W MH PULSE START WHITE 1u11c. ~1 ----IU YU ,,,. mVt..Klt.K POLElVERIFY POLE LENGll-1 RELATIVE TO FLOOR SYSTEM. POUE TO BE ROUND ALUMINUM. S4 ROOFTOP PARKING LOT LIGHTING (17'-4' KIM 4C-ACA21AW5-400PMH-WH-P 277 4 400W MH PULSE START POLE MTD WHITE ONE FllffiJRE TO uv l1-IROUGH INvu,TEH POLE)VERIFY POLE LENGll-1 RELATM TO FLOOR 21' MTG. HT. SYSTEM. POUE TO BE ROUND ALUMINUM. T TO BE SELECTED ,ANO PROVIDED BY OWNER X l1-IERMOPLASTIC LED EXIT LIGffi Will-I BATTERY BUILDING STANDARD DUAL-UTE CV3REW 277 RED LED'S INCLUDED UNIVERSAL WHITE DAMP LABEL REQUIRED X1 WEAll-lERPROOF EXIT SIGN WITH BAfilRY ROOFTOP LIEVEL KENALL METXX-M'II-R-DT-EL-CW 277 RED LED'S INCLUDED VANDAL-RESISTANT & SEE DRAWINGS WEATHERPROOF EXIT SIGN DESCRIPTION ABBREyJATION DESCRIPTION ABBREVIATION DESCRIPTION HOUSING DWG. DRAWING CLG. CEILING GROUND DISTR. DISTRIBUTION CCTV. CLOSED CIRCUIT TV VOLT DR. DOOR cu. COPPER AMP ELECT. El.ECTRICAL FU'D. FUSED LIGHTING E.F. EXHAUST FAN TV. TELEVISION RECEPTACLE E.C. EMPTY CONDUIT o.c. ON CENTER SWITCH EM. EMERGENCY OFF. OFFlCE DISCONNECT SWITCH EMT. El.ECTRICAL METALLIC TUBING (CONDUIT) W.P. WEAll-lER PROOF HEJGHT A.I.C. AMPERE INTERRUPTING CAPACIT!' XFMR. TRANSFORMER HORSEPOWER A. T.S. AUTOMATIC TRANSFER SWITCH f/N FULL SIZE NUETRAL JUNCTION BOX BRKR. BREAKER RIGID GALVANIZED STEEL 1/0 INFORMATION/OUTLET. CONDUIT GHHA. GROUND HAND HOLE 'A' CONTRACTOR FLOUR. FLUORESCENT ~==========================~=====~ •• ~.~~ ... ~·;"':..,'r'/·-~.4'~==============================================================================================================~ ,, <c•;.-' • ,, :·,,. Client: wITH ill ' ' . -, --·• t-,; _____ ..j. ____ -BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305-444-4433 fax 305-444·0181 EMAIi; bdamiamiobellsouthJ1et wa (}!;:::;~~~) Mr. Mark Richman wILuAM A BERRY & Assoc1ArEs! ~·r,,A~ c,, :,.: rr., M. R. Properties Inc. CONSULTING ENGINEERS '::, l., ~. , -.-✓.r;~ 18500 NE 5th Avenue 10200NW25thSTREET,SUITE111 ', ~-.(o Rio~-~-··~--Miami, Florida DORAL, FL 33172 ,,_" tSs,• .... ••••;,_,,, ... """' TELEPHONE: 305-513-9000 '•,,,!ONA\;'",,,,, FAX 305-513-9100 M. SAEED FAU~fttl.'p~ #40911 EB 000 5543 ELIZABETH fI1RIDA, PE #59464 Proposed New Project date September 01, 2006 City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility revision ffi PERMIT COMMENTS 07/10/06 S.W. 73rd Street & 58th Avenue, South Miami, Florida sheet title ELECTRICAL LEGEND AND NOTES project number 2eJeJ58':l drawn by ZM SCALE : AS SHOWN sheet number E-1.0 98 of 162 106 II \ / ARCHITECTURE 285 Sevilla Avenue L1-27 rAn \U :K ~-~ A. ! ~-. ,5'·'' ' ii· '-, i ,:J ,/" I ,,,: 1·,,· Ll-30 ►-il!ICJil::. z , Ll-29 ' ,,.,. ...... . .' J , ! , !~ , , rH J /"!"' 10 ~--·. . , ."f(: @ . : ,_ h ;;1,-'!~f1-~"''0oi.·: .: :::; BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Cables, Fl 33134 ,, ',;:,@ HU.,~►-->. ii . i ' !i ; Ji ~ . ·" .. !') ! '~ 305-444·4433 fax 305-444-0181 EMAIL; bdamiamiobellsouth.net 2 H.ETA!L i:l 1375 '?qft 5 © © 5 © f'<ES T At,Jf~ANT 1 4761 sc;ft © ' ' ®10 Client: ETAIL 7 1 Offi' sqft H1-9 (TIE) : ' ,t '; ,. .. . Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida , -·~ ,: < ;....~ :,~· ,> •·',<, .::-·',· N © © 5 5 5 " '! ' :i.,._..,.H 1-11 )Tie) , ' . Zi!."JitM!tM!C .... 'J ,·:&' " , -...,...-E1'.'..f 6 H 1-1,.___-'"---~-' -.;: CC /Ef~!£D , PA Kl\ill AREA C) 1__:..,..-----+--,.-;--..--,.-..L_ I .@ RFSTAUHANT 2 5/322 stjft f,f \2 , __ _ '-••··----- 5 C 5 5 'iii 7 / ,,8 9 © 9 © 9 © • f'<E:STAUHA~JT 1l 6740 sqfl r ' FIRST LEVEL ELECTRICAL LIGI-ITING PLAN I '- WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 SCALE 3132" = 1 '-0" Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida / . ,. © 9 © 9 9 9 i I 7 © © 10 / RETAIL fi 1021 sqft HSTAlL 4 739 sqf!. Ri;:T/,lL 3 704 sqft 9 , , ; ' 7 .-.L~~: '_,., 7 :F' / i ,.. ,. ,.r ./<,-••j _,}\:..:-- i> w ::) z lJJ ~ ,-.~ A,,,}. 0) !D lJ-.;___---'"--------~1<::;:::::::---.. s H ~ 7 '@I '' ·t .~~·~ 5 :=,,,c,_--',.',,, '"'Z ' ' H1- ,; date September 01, 2006 rel.'.\v .lslon / 'L \ OWNER CH.INGES _._.__.__ ---------08-18-06 & OWNER CHANGES 01-09-07 /5\ OWNER CH.INGES 02/21/07 ,, © © 2 101,1 ft .7 sheet title ELECTRICAL LIGHTING PLAN project number 20058~ drawn by ZM SCALE : AS SHOWN sheet number E-1.1L 99 of 162 107 r;;;;===============================================================================================;=======================;;:::::==================-----------;;;,;:,;--~-;;.;-===;;;;,-, Ir ___ ._. __ ...,, oc ::i o- 0, :r;! co: Lt') • 1 ~ '1' -\ ----_:_ - -- - ---- - --_: · ao SER'/ICE 24" MINIMUM . ;-"' SERVICE 24 MINIMUM BELOW BELOW GRADE TO BE _ -:. 1/ • GRADE TO NEW UTIUlY POLE CAPPED FOR F1JTURE .-< --,_-,"". _ PRCNIDED BY F.P.l. CONNECTION BY F.P.l. / _ \ i ;~8 ~NIZ 4 I ~$'.i ~, k16 d i " ~:~2Ct•~ , :_,-_,_-_--_-_-,,-=,,:,_ ________ ,cc: .. ilzr -•--·-•·· 7 5cd i_ i [Kl ... . . ..... -,.·--·· .. .. . . ........... / ··• . H1-20 .,..,,,....~---- llN 1-1" (R'.}-6) IIDJ OOi 'II l.CO'llCN lO 11-t: ~(Jfl(Em1C'l.. 5 ;---. f / / PROVIDE lWO (2) 3.5' E:i.l.T, EMPTY' CONDUIT FROM ELECTRICAL SER'/ICE A TO F1JTURE TENANT ill PROVIDE 2.0" EJ,f.T, EMPlY CONDUIT FROM TELEPHONE BOARD TO F1JTURE TENN-IT IBJ Client: / N103 •• 75cd l>ill / VERIFY ALL UNDERGROUND UTILITIES BEFORE DIGGING AND COMMENCING WORK COORDINATE ALL WORK TO BE DONE W/ ALL UTILITY REPRESENTATIVES TO T.T.B. IN ELECT. RM rei, 07 N106~ . 75cd PROVIOE lWO (2) 3.5" E.M.T. EMPlY CONDUIT FROM ELECTRICAL SEIMCE 4 TD F1JTURE TENANT 1..:,b. PROVIDE 2.0" E.M.T. EMPlY CONDUIT FROM TELEPHONE BOARD TO F1JTURE TENN-IT N1D5 [f]<l75cd / TENANT ID. SEE ESTIW.TEDi LOADS ON DRAWING E6.0. i. lYPICAL FOR ALL TENN-ITSi N104 ; 75cdl::{!f N . N108 7 5cd t::ill!) 1 D9 ~ NEW OVERHEAD-----+__,,.. SER'/ICE FOR EXISTING \ TENANT TO BE PR<MDED BY F.P.L ~ /7 : ~ N~UTIUJYPQE------ PRO'v1DED BY F.P.l. PROVIDE 3-2"C \\'ITH MIN/MUN' 24' AADIUS BENO UNDER Sl>B. I L1-32 R . PRQV1DE 2.0" E.M.T. EMPlY-- CONDLIT FROM TELEPHONE 80.';<D TO FUTURE TENANT PROVIDE lWO (2) 3,5" E.M.T. EMPTY CONDUIT FROM ELECTRICAL SERVICE A TO fUTURE TENANT ffi -• · N11D J™ 75cd N109 , 71ic<i [::{!] : OJ I' ' FIRST LEVEL ELECTRICAL POWER PLAN SCALE 3132' 0 1 '-0" WITH Proposed New Project City of South Miami ' ef <l' NEW OVERHEAD----=/f-- SER'/ICE FOR EXISTING TENANT TO BE PROVIDED BY F.P.l. / ;10 T PRO'v1DE ¾" EMPlY CONDUIT . FROM TELEPHONE BOAAD FOR DATA. TYPICAL FDR EACH METERING MACHINE. '-. N112 . ·-: 75cd F / PR<MDE 2.0" E.M.T. EMPl'I CONDUIT FROM ELECTRICAL' SERVICE TO F1JTURE TENANT o PR<MDE 1.0" E.M.T. EMPTt CONDUIT FROM TELEPHONE BOAAD TO F1JTURE TENANT l / PR<MDE 2.0" E.M.T. EMPJY CONDUIT FROM ELECTRICAL SER'/ICE TO F1JTURE TEN/>N,T o~--.,.1R0"1DE 1.o• E.M.T. EMPr/ CONDUIT FROM TELEPHONE' BOARD TO F1JTURE TENANr: IT] II] "v·· ... ·.. . PROVIDE 2.o• E.M.T. EMPl'I ,, , -_ CONDUIT FROM ELECTRICAL l SERVICE TO F1JTURE TENN-IT i,~---,-ROVIDE 1.o• E.M.T, EMPTY CONDUIT FROM TELEPHONE BOAAD TO F1JTURE TENN-IT ~--PROVIDE 2.0" E.M.T. EMPlY CONDUIT FROM ELECTRICAL SERVICE TO F1JTURE TENANT ~--PR<MDE 1.0" E.M.T. EMPlY CONDUIT FROM TELEPHONE BOAAD TO F1JTLRE TENANT N115 [ID'.)<175cd ,J 12 [ill 75cd .. ,-1 .. N116 __ _ .,. '1q, ,'., ., : ::: :::: '"'."'' ·x.__ ...... , . . Ll:c66. @] N119 ' 75cdt:,{Irn : 116 date September 01, 2006 sheet title rexlslon -' · BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility ---1Z::,__ GENERAL REVISION 09/05/06 Q\ COOROINAllON 11/15/06 /4\ OWNER CIWJGES 01/09/07 ,15\ OWNER CIWJGES 02/22/07 ELECTRICAL PO WE R PLAN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305-444•0181 EMAIL: bdamiamiObellsouth.net ---------· S.W. 73rd Street & 58th Avenue, South Miami, Florida ------------ project number 20058'9 drawn by ZM (fJ l C: t /( . ; i i SCALE : AS SHOWN sheet number E-1.1P 100 of 162 108 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305·444-4433 fax 305-444-0181 EMAIL: bdamiamiobellsouthnet Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 MULTIPOLE LIGHTING CONTACTOR AND TIME [ BELL SOUTH TELEPHONE POINT OF DEMARCATION. 2-3.0" PVC CONDUITS TD TELEPHONE POINT OF SERVICE. ~.,._,. ............. -.. 1.5" CONDUIT TO ROOF FOR SATEUTE. ~ ISXS::S:S:~ S S S S S S::S:s:::s:J 4'X4'X3/4' PLYWOOD BACKBOARD PAINTED W/ BLACK FIRE RETARDING PAINT FOR TELEPHONE SYSTEM. ' ' ' SWITCH -------;;_~~--.,,, 3P-400A-480V WITH 400A. FUSES IN NEMA 1 ENCLOSURE FOR TENANTS SERVICE ' ' ' ' : ' ' i Ml/LTIPOLE LIGHTING C()NTACTOR ANO Jj ME SWITCH : N II PANE ·u" PANEL "H1" T 75KVA-480/120/208V-3~-4WY-',:_j TRANSFORMER H NG F OM CEILING. FUTURE SPACE FOR TENANT METER AND OISCONNECT.(lYP,) LINE AND LOAD GUTTER 10" X 10• X 12FT. LONG SEE RISER ON SHEET E7-0~ ' LJ r-1 ELECTRICAL/TELEPHONE L' ROOM PANEL "HOP:N Orvss 600A. C.B. TENANT 3P-600A-480V WITH SOLID NEUTRAL I NEMA 1 ENCLOSURE (TYP. Of 3) rn 3P-600A. METER ENCLOSURE 3P-600A. METER ~_._n__,__~ ENCLOSURE 600A. i ________ 8 ~-T~_rr_B._~ 3P-600A. METER ENCLOSURE 600A. T~~T rn (DFIRST LEVEL ENLARGED ELECTRICAL Proposed New Project d a t e September 01, 2006 South Miami Municipal Parking Facility rev i'Xis.ion /Z\ 01\NER CfWaS 08-18--06 _,_......,_ & OWNER CH.INGES 0'2/22/07 S.W. 73rd Street & 58th Avenue, South Miami, Florida ROOM SCALE; 112" = 1•-0• sheet title FIRST LEVEL ENLARGED ELECTRICAL ROOM project number 200!;8~ drawn by ZM SCALE : AS SHOWN sheet number E-1.2P 101 of 162 109 (D 4 ,~---,"-. (B,:~-- '·-··' ... 2 (D BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 SeYllla Aven.ie Coral Cables, Fl 33134 305 444 4433 fax 305 444 0181 EMAIL: bdarriamiObellsouth.net Ir II !i !I, " .'.:'~: ____ : ____ .. ___ -' 2© Hll """"-~-----~-----'--' _: _________ _) Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida x·············•-=-r....-.,, ··::··:·-..·:···· .... ··-· .......... ·-·· :···7··,-/ .. -----------,..w... ... ,? --·1 • .. ::·_::" ... :""··) ,· ,f}'-.:· / ',' ! •. ;;z::;:: Vcc,'-_7 __ eci2:S:~c-; ! . / / : ' =~-----· ' .. ,., ....... , ........ . / ' ,/ 4(D 6 <P N EB SECOND LEVEL ELECTRICAL LIGHTING PLAN SCALE: 3/32' ~ 1'-0' WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project South Miami Municipal Parking Facility s.w. 73rd Street & 58th Avenue, South Miami, Florida L 6 2 L ~--+------, ' ;1/ /: ; . / :, / J / !1: ; 1 lli I ij 6 ' . ,/ i ·'' -~--/;,/-----:"-i! -I i r·· / 11 j ;Ii /\ :·1 · 1/ / 'I ' •1''J --,---,;-'-,;_· _ . ~-~L/ , ··ri· ··"'···/ ··i J • j r ·· 1;' \"'·····'·'··· jLc.L=""'-'~"'--,j I ! I I / ' ! j ' I ' ; ' I date September 01, 2006 revision ! ' ' / / / I / / I ' / I / / I I ! ;! \\ \ \ ---;-.\ \ \ \ \ sheet tltle ELECTRICAL LIGHTING PLAN project number 2~8':l drawn by ZM. 1P/2Qt, F\ISED DISCONIET FDR Elf.VliRIR Cllll LIGHTS SCALE : AS SHOWN sheet number E·2.1L 102 of 162 110 BLITSTEIN DESIGN ASSOCIATES AR0007570 I !I ' ~ / \ \ \ ' Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida • ,. i ·='~"'1'·" T . : . .:. ~. ;.:. ... ····· ···················7~·= == ..., ~~· . . ..... f' / t / h ;-······· ___ J '''-:,; ···----··-7 , ,/ ......... :·:·~- CXIN0-1 liM1 IIIIIIIED .. r_,, N ,, J/ ' i ~--IUI 1" ~ CONDUIT 10 IWW:ER'S OFFICE ON FIRST Fl.OOR. SEE TYPICAL RISER ON DRAWING E6.0. PR<MDE 1~" Elf'1Y CONOUT ALONG lHIS CENTER WM.I. ON EAClt F1.00R FROM lHE SECOND lHRU FOURTH, .. _,,,,,.-,, ,,,_ ....... =:.:...:::;:;:..:.::::::::.:.-_-,;J._ ,,_..., _____ __,_11',_'.0cd.,, ,•' •' ~ ' \ \ @ii!ii(.,. .•..•... .,, ......••... WWWiii • _,. .------.. ,,,..,.,...,•· ,,.,..-,, r-------., r:./ I . I I I I / ' / • I / ' ' ' I // I I I I I (I) SECOND LEVEL ELECTRICAL POWER PLAN SCALE: 3132" a 1 '-0" WITH Proposed New Project City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility ..... ·····················.-, .. , .. "'' ..... I ! I i I ' ! / I ! ' ! ! I N206 I ! I I ' I ! I I ! .- ! ! --,.---·· I I I I ! I .- ! ! / ! / \ \ .. \ I I ' ' / ' I ' \ \ \ !----······+·· .. \ .... ,11@4</M .... K..liiL •.... date September 01, 2006 rexlslon ...1£__ OWNER CHANGES 02/21/07 sheet title ELECTRICAL POWER PLAN I !j I j I I . ,ao ,,,., a AlffllM1ll IIDKEII ; ; N IEM 1 en CRPF int stUfT i i 111P IN IEIES 11111 1HE ,IF-UmrtR '. ' i !IDE:: 11--IIDIN FM: FEEi' 0f ·IJIIIIR.....C IP/100,, IEM' DUIY FUSED = r:;-:.;;,,ri: ~ SCALE : AS SHOWN sheet number E·2.1P 103 of 162 111 ARCHITECTURE 285 Sevlla Avenue L BLITSTEIN DESIGN ASSOCIATES AR0007570 INTERIOR DESIGN Coral Cables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamlamiobellsouthnet Iii 9 ', "" WILLIAM A. BERRY & ASSOCIATES CONSULTING ENGINEERS 10200 NW 25th STREET, SUITE 111 DORAL, FL 33172 TELEPHONE: 305-513-9000 FAX: 305-513-9100 EB0006543 i.,-··-········-··. ···-·- ~-----·• J!DiilW.'k>' c~·~-r.~;;;:~ H2-5 ;\ +------;' \ Ci'======at:;• :;;;~ ... ---·········•.l .. ~ .... \ \ \ ' ',,, •• "~ J M. SAEED j:~ P.E. #40!)71 ELIZABETH l PRIDA, P.E. #59464 • • • • • • . ' . -- ' / ® :,-0'7---t----t----_j_ _ _:r~®i•---i---+----t--©""/_v_· ---~--1-----t--....:t~:_--l---+--r--"t--~<i> 2-7 ,----' ,.,-., .... , ... ,.,, .... ,."'' l \ 1··-----~ ·------.,. __ 7 c-=-==== \ \ \ ' I , ' I / , ' ' ' ' ' / ; I On all w?.<ik!ng surfw .. -es 111df1 a slope oi la;;;s dlfUl 5'% l / pro'Ar.le .a slip resist.ant finish, d8!:l(Jfibed a~ a medium V ssltod 4Mh. , Or, all surfacer; with a 1,1(',,'){J gm mer than 6%. pmvicie a l'ilin .,/ rnsM;mt ~nk,t; 1 I Do n0t ~!inw ~ny c;mzis. :!tt1r,es m e-KtEed 1 i4~ per font~~%. ....... ,. /--, ....... \ \ \ / \ I I\ / ;:;;.:;;;;;;;;:;;;;;;;;;,, ~{'Tf:··:;;.;;J i ---~--~ ··················' ·····-··· ~ I N ' , I ' ' / ' / ' ' ' / I I ' ....... , ..... , ... , ......... , ...... ,. . 1¥.:. \i .•. --.-.• ., •.••••• :;;;;;;;i \ I htE·CAST E'.Yf.BROW W/ i.)l::COR!\Tl\,'E fZf&JNG / CTc-::c::=s ' b, ... ;;;;;;:;;:;::;; -···· (I) TiiIRD LEVEi. FI .F.CTRICAL LIGHTING PLAN SCALE: 3132" = 1'-0" Client: WITH Proposed New Project / I ,/ E2-2 Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida City of South Miami 6130 Sunset Drive South Miami. Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue. South Miami, Florida E2-J f::::::::············:·::; ---\·· .. -;,,'---- ',/ I ! ! I I I I ! i I / I ' I / 0 @ date September 01, 2006 revision / i j i ! ! I ! ! ! / I \ \ \ ' ............... \ \ \ \ l \ / ; I I 0 ~ •-+-----I__,_\\ __,l1,r I b.:: .. ·.::.·.:: ............ :: sheet title ELECTRICAL LIGHTING PLAN project number 200S89 \ \ \ \ drawn by ZM. \ \ SCALI : AS SHOWN sheet number E•3.1L 104 of 162 112 J BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 SeYlla Aveooe Coral Cables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamiamiobellsouth.net IT1 1:1 I i I. r , 75cd l2-25 : I~ '. l2-2 ----- L [ ',, --__ : ; J1 r.: EV iil ~- I !1 i ''······: ,. i ~/1 ~;l ~/! /,, I 11 / /! N.302 NJQ1 \ \ \,H_,_ :';TR:!PING '."1WJ Client: i Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida ''-··· ,,.,,,,,,,,,~>-Z,,,,, ... •.• .... ,, __ we __ i On all w,1lkhg st•tf~oos iv1th a s!or>o cf !am~ uian 5% · prr:nM.18'! a ':li1p resii>.tJrnt fihL<;~. des-:.·Mbml -"~ 8 med11;m , salted foish, ! On all surtooos with a Ai¢pe greater t!1an 6%. provide a slip ! re5is!.8.r1t fi,.,ish. ' i Oo not a!k,w any cross ~l◊pl"Ji'. to m«'.eed 114" per foot or 2tr~. . =;=•·••■§· .. ·•···=•=••··· § .. § .... ~·=•--·~··• .... ~, .. ~c.~~--· .... ~. ~= -l ........ ···""l!l, ... ,-... •· .•. ~.······. -;,:~_:_::_::_:_::····· .. ,.--.--.--''-""="S~•;;ss-;,\"'~ ' \ \ N ""'··········-····· ..... : ~RE·-C .. ST F.Yf:BRfl'N W: Oi:'.OORAJIVE H,MlJN0 CD TffiRD LEVEL FJ ECTRICAL POWER PLAN WITH Proposed New Project SCALE• 3132" = 1'-0" City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida --------- ·-·7 1z=,~=·:•·•·""""" N.306 N.305 x.=El /]~ .. / date September 01, 2006 rexlslon ...ill,_ OWNER CHANGES 'YJ./22/07 ' 4- sheet tltle ELECTRICAL POWER PLAN l2-10 project number 2tZJtZJ5~ drawn by ZM ..... , ~41 :i iii I! I l' ! ' ' I 1 l II 1· '. I SCALE : AS SHOWN sheet number E-3.1P 105 of 162 113 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305 444 4433 fax 305-444-0181 EMAIL: bclamlamlObellsouthnet ,_/·-1·\ . ' . . . / ~r ' ---"" WILLIAM A. BERRY & ASSOCIATES• CONSULTING ENGINEERS "l C-~-·.;· ,-.'#, '• • • \ \ 10200 NW 25th STREET, SUITE 111 ' DORAL, FL 33172 TELEPHONE: 305-513-9000 FAX: ~513-9100 EB0006543 . . . ~LS~~ . •ta L•' . M. t1UAI$. P.E. #40971 ELIZABETH T. PRIDA, P.E. #59464 \ • \ \ \ Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida :::c ' i ----'--- N ""''""""'ti,,,.I,,,., ··········-········~---··· / .... ·----. ,,. .. \ \ CD FOURTH LEVEL ELECTRICAL LIGHTING PLAN SCALE: 3132" = 1 '-0" WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida ' I I f I I ! I / ' ! ! I / ' f ' ! ! d It e September 01, 2006 revision ! ' ·I···· ... ·········i··· . -'1<'' i -.\!Y: • \ \ \ <-----1\---------. I \ \ • \ \ \ I I ,/ sheet title ELECTRICAL LIGHTING PLAN project number 21Z>0S6~ drawn by ZM SCALE : AS SHOWN sheet number E·4.1L 106 of 162 114-■l!1itl Ill llN1-1"~ ~ W l.CXllllCN 10 tltfCERSam: B'l1IRES 1l RlllE ~IDlftl!S l!fOlP. 1<15191tloERIERSSEII RIN:RUJ£ IE-~~ AIN3.. '12' ' / ! /,/ _____ _ '. \ $1Eill..FmlHS lff:A ~ lHS IH¥INl. \ \ ' \ I '· \ \ 1'181==#:.:L-UGlffiNG J / l ; l ·; FJECIBO\. ~ Slll.Ei\i\.i BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevllla Avenue Coral Gables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamlamobellsouthnet CONTICIORS I T/C. ; ! ( ' ' ! I ' ; L2-5 ' ' F= --. ··--,) .... . .... '.. Wt . ~ . ~ WILLIAM A. BERRY & ASSOCIATES'. ~ CONSULTING ENGINEERS : ·. 10200 NW 25111 STREET, SUITE 111 -, DORAL, FL 33172 . TELEPHONE: 305-513-9000 ·- FAX: 305-513-9100 M EB 0006543 · · 0971 ELIZABETH l PRIOA P.E. #59464 Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida N ' ' / ' ' ' / .::: .. ::.:.:r·· y ··~ii%>1H'"'" ............... ::r::::: \ \ \ \ \ \ Cl) IOURTH LEVEL FT F.ClRICAL POWER PLAN SCALE: 3132" = 1'-0" WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida \ , .. -i .. ···+ .. , i • I / I i ! I I I ' .! I ! ! ! ....... ··-······i·· .. .......... ·+-.... .( _ __;_-:'f' -'--· :'::·, ! \ \ ' . \ \ \ \ \ \ ' \ ! / ' i I I i ' \ \ \ \ \ \ \ \ I I i ! \, \ ! .i..._ I I I --.. -i .. --+s,.=.,~ -..... +-.r,~~J: ~•······i . ., date September 01, 2006 rexlslon __[£_ OWNER CHANGES 02/22/07 -·······'-" ·······-.~. . ~:::•;.; sheet title ELECTRICAL POWER PLAN project number 20058'3 drawn by ZM \ ' \ \ \ \ \ ' \ \ \ \ \ \ ~ i . i SCALE : AS SHOWN sheet number E·4.1P 107 of 162 115 ill ll rr============~=-c=================---==-·=-··-·-1 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305-444-0181 EMAIL: bdamiamiobellsouth.net 1 2 / 3 ' ' , ... ,---, Wh, E2-11 H2-3 / ,( /; [,/ // ' /' //" _/' ,,/ Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 4/ 5 6 ' '7 '·· -.. ,.~/ ---~~~-, ... ½'"'<'" --····· / :::; ·-£2-H ,, :·:.:: . ., ... ,: ·,' .T:.:. \ H2-1 f ' N Plffli LEVEL ELECTRICAL LIGiiTING PLAN SCALE• 3,32• = 1 '-0" WITH Proposed New Project City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida ,-·· /--··•,s. / 8 9. .. --,-----~•···~ -~·········--·----- date September 01, 2006 revision /'"'"•·- :10. ' ,, rM,~B··· '/&Wd'&~••~/ffe//@Yf l: I ... :L_::~~l--s h ' ' ' ' / ' . " ' /' / / 1/ ' /( / i / : / " ' , sheet title ELECTRICAL LIGHTING PLAN project number 21ZleJS8~ drawn by ZM 1 1 SCALE : AS SHOWN sheet number E-5.1L 108 of 162 116 m A ----. B C BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305•444-4433 fax 305-444-0181 EMAIL; bdamiamiObellsouthnet 1 '' '' r • ,i, , I'. 2' / " . -, ! ---' --, -,. -~-----, --,---,· r --I ·;··· --' - :---1-----·-----·' ·--------------···-------------·----·-·--------··· --~--·----·-.. --· --,----------... ----·----·--·---_, ____ _ 7 - . ---' ··---------~-----...... ---. ------------·--. -------------·--· · -· ~-------------, --"-·-· ---------, i -. · ., ' 8 9 -.10 .... ,.- •. c ·-"---l-- - •--~-~-~ .......... --------------·· ----, _________ ., __ ~--=·---~~, . ' >·.• -----____ L =---»'>...~= ·--' --...... . ,,..,.~li·•=•"< ---------~--~~,.-e..d.,_, --------t-- - . ----.. , , __ 1---·-. -------J .. \----' .. -· --. ---.-·--,------r ------'' ' --_-,.-•-7 ---~--z::_-~ i l -~-----...... -~:~¾-~ ~~~~: -·----·----~ ------·--·--",-~---~~-' [2--, 1 , .11\&d ! ·-_ ; . . . . .• . . .,. 11QcdJ.i~3 ~= --~--=,--, -==~_:;._;-_::._:_;,::: -----·----'-f.,;;~,::7 ,. .• ,,~~~"' ""~""'•''"'";"' :;,_=::.r=--:-_::.;;., "'-=..,__,,,.~.--"'-= ~~----~ i, ::;;,_~...,:~--;;:_:_::;_] ' ' ·---. --' Client: ·-.-,---.----., --t--·· --. , ·····------·-----+-------·--·-, .. -------·----· ------------------------------------- - ---------~ ----·------.. ----- ---·-· --·----------T-----~ ·--·-----··-·--- -------------• .. -i -.------~ ·---···--------_______ .. _, -----------------' ----' ____ ; _____ ._ -' __ ·- ' ' ' ··----... ..,--,----------·-·--- . . . ! N ' ---··--~ -~-- - . ,-. --~ - - ------' -·----·--------. c..--,,.·---•• ~-, -· -------___ .J (DFIFTH LEVEL ELECTRICAL POWER PLAN SCALE: 3/32" = 1'-0" WITH Proposed New Project ----, L:Z-3 , I \ ---L· ____ -< -----' -'---'--·'----' d a t e September 01, 2006 rex.ision Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility ~ OWNER CHN-IGES 0'2/22/07 Miami, Florida S. W. 73rd Street & 58th Avenue, South Miami, Florida / -~-' ------------~ ----I ---------' . sheet title ELECTRICAL POWER PLAN profect number 20058,S drawn by ZM j 'i ,, J 1 _..._,._,. .. 1 : ! ''' .-- 'i. SCALE : AS SHOWN sheet number E-5.1P 109 of 162 117 I ' ~=====================================================================================================~-c:::=-==:.1 BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305·444-4433 fax 305-444·0181 EMAIL: bdamiamiobellsouth.net (••)- EQUAL TO SQ. "D' PANEL -"EM" VOLTAGE· 27~480V., 3~ .• 4W. lYPE: NOOD MAJ NS. lO MOUNTING: SU~fACE TYPE MAINS: M.C.8. LOCATION: MAIN ELECTRICAL ROOM AIC RATING: 14KAIC 'A' "B• 'C" AMPS CIR CON-CON-CIR A.MPS "A" '8' "C' IDENTIFICATION VA VA VA TRIP POLES No. WIRE DUIT DUil WIRE No POLES TR1P VA VA VA IDENTIFICATION LCAC LOAD OAD C.8. CB LOAD LOAD LOAD SPARE 000 ?n 1 1 12 3 4· 1" N4 2 1 70 15000 INVERTER I 1 STAIR #1 LIGHTS BCO 20 1 3 12 3 4·, 4 1 20 000 SPARE STAIR #2 LIGHTS 800 20 1 5 12 3 4• 6 1 20 IMQ SPARE 7 8 9 10 11 12 000 800 ROO 15000 1000 1000 TOTAL VA 'N PHASE 1!lQOO TOTAL VA 'B" PHASE 1800 TOTAL VA "C' PHASE 1800 TOTAL CONNECTED .WA l ~.!l TOTAL DEMAND .WA 24.5 TOTAL AMPSIPHASE 29.5 EQUAL TO: SQ. 'D" PANEL -"E1" VOLTAGE: 277 / 4&N-1 ¢-3W TYPE: NQQD MAINS, 125 MOUNTING: Sl!BE~CE TYPE MAINs:M,LO. LOCATION: ELECTRICAL ROOM A!C RATING: 14KAIC "A" AMPS CIR. CON-CON-CIR AMPS "A' IDENTIFICATION VA TRIP POLES No WIRE DUIT DUIT WIRE No. POLES TRIP VA IDENTIFICATION LOA[ C.3. CB. LOAD FIRST FL LIGHTS 840 20 1 1 12 3 4· J 4· 10 2 1 20 600 SECOND fl LIGHTS SECOND fl LJGHTS 600 20 1 3 12 3 4• J 4 10 4 1 7n 360 SECOND IL LIGHTS SECOND fl LJGHTS 480 20 1 5 10 3 4· 3 4 10 6 f -20 500 ~.A.l .P. -. -¼ 7 8 9 10 11 12 920 11§Q TOTAL VA "A." PHASE 2880 TOTAL CONNECTED .WA J,1 TOTAL DEMAND .WA 1,l TOTAL AMPS/PHASE 14.8 EQUAL TO SQ, 'D" PANEL -"E2" VOLTAGE: 27;6_480\/-1¢-3W TYPE: NF MAINS. 12 MOUNTING· SU8EeCE TYPE MAINS: M.C.B. LOCATION: 4TH ELECTRICAL ROOM AIC RATl~G: 14KAIC "A" AJMPS CIR. CON-CON-CIR AMPS 'A' IDENTIFICATION VA TRIP POLES No. WIRE DUIT DUIT WIRE No POLES TRIP VA IDENTIFICATION LCAt CB. c.a. LOAD THIRD FL UGHTS 600 ,,, 1 1 10 3 4· 3 1 4 12 2 1 20 240 THIRD FL LIGHTS THIRD FL UGHTS 480 20 1 3 10 12 4 1 20 360 FOURlll Fl UGHTS THIRD FL LIGHTS 600 20 1 5 10 12 6 1 20 480 FOURlll Fl UGHTS FOURTH Fl UGHTS 600 20 1 7 12 10 8 1 20 960 FIFTH Fl UGH1S -(• FOURlll fl LJGHTS 480 20 1 9 ,2 10 10 1 30 2900 rMtL El FlfTH fl LJGHTS qsn 70 1 11 10 12 12 1 20 720 FA POWER SUPPLY SPACE 13 14 SPACE SPACE 15 16 SPACE orncc 17 18 SPACE ~ 5660 TOTAL CONNECTED .WA 9,313 TOTAL OEMANO .WA 11.5 TOTAL AMPS/PhASE 11.6 (")-fil EX!IRIOR AND SITE LIGHT SfWJ. BE llJRNED ON BY POOTOCELL N,D llJlffD Off W.. TI~E CLOCK. EQUAL ~D: SQ. D "HOP" VOL "Ti! 277 L:!llOV-3¢-!W TYPE: 1-LJNE MAINS: 4-00A LOCATION MAN ELECTRICAL ROOM TYPE ~AINS 1QOA M.Q,a, MOUNTING SURFACE AIC: 42KAIC CKT AREA SERVED LOAD DATA CIRCUIT SREAi<ER GND. CON-JUIT RE.MARKS NO. E WIRE WIR:= (INCH) VOLT 0 POLE FRAME K.A.1.C TRIP 1 ELE.VATOR #1 43.2 4J.2 ~ 3 3 100 42KA 90 3#6 8 1.25' 2 ELEVATOR 12 43.2 4J.2 480 3 3 100 42KA 90 3#6 8 1.25' 3 PANEL "H1' 82.90 88.5 277/480 3 3 225 42KA 200 4#3/0 6 2' 4 PANEL 'H2' 18.98 23.73 277/480 3 3 225 42KA 100 4#1 8 1.25' 5 SPARE 20.0 20.0 277/480 3 3 225 42KA 100 6 l'ISS 277/480 3 100 42KA 30 4#8 B 3/4' TOTAL Di!!!f.50: KV A. 268.9 AMPS. Client: WITH (•)- (••i-i•i-(** -* -. -. - EQUAL TO: SQ. "D' PANEL -"H1" TYPE· NF MOUNTING: Sll8EACE LOCATION: MAIN ELECTRICAL ROOM "A' "8," "C" AMPS CIR CON-CON-CIR IDENTIFICATION VA VA VA TRIP' POLES No, WIRE DUIT DUIT WIRE No, POLES LOA[ LOAD OAD C.8, SECOND FL LIGHTING 470 20 1 1 10 3/4" 3/4' 1110 2 1 SECOND FL LIGHTING 1680 3 10 4 1 ST.fl.TENANT LTS '850 5 12 6 1 ST.FL TENANT US 189 7 12 8 1 ST.FL TENANT LTS 1545 9 10 10 1 ST. FL LIGHTING 610 11 12 12 1ST.FLPARKING LTS. 900 13 12 2.0· 1 0 14 3 SPARE 500 20 3/ 15 16 500 / 17 1ll 250 / 19 3 4" 10 20 1 flfi 1 W£li RII PCK-1 300 21 M12 3/4" 3 4• 10 22 ll lV !l WU1 !(Ill ri.,fl-300 23 1112 3/4" 3 4 10 24 t SPA E 1001 25 3 4• 10 26 3 I 1uOt 27 28 j 000 29 30 SPACE 0 31 32 I 0 33 34 I 0 35 36 I 0 37 38 I u 39 40 ' 0 41 42 7760 9025 1260 TOTAL VA "A' PHASE 40713 TOTALVA'B"PHASE 40713 TOTAL CONNECTED ;0/A 125.9 TOT AL DEMAND KV A 133.5 (•)-CONNECT IB!i\J 10 POLIS LIGHTING CONTACTOR LGIOOO. EQUAL TO: SQ. 'D' PANEL -"H2" TYPE: NQOD MOUNTl~G SUBEACE LOCATION: ELECTRICAL ROOM 4TH FLOOR 'A" "B" "C" AMPS C:R. CON-CON-CIR IDENTIFICATION VA VA VA TR.JP POLES WIRE WIRE •OLES LOAD LOAD OAD CB No. DUIT DUIT No. srn. FL LIGHT POlfS '881 20 1 1 410 3/4" 3/4 10 2 1 5111. FL LIGHT POlfS 880 3 ' 3/4 10 4 3RO. Fl. IJGHTNG 470 5 I 1.0 4 6 3 3RD. Fl. UGHllNG 168( 7 I ' 8 9 10 11 12 13 14 15 16 17 18 ~ 1 8811471 TOTAL VA "A" PHASE 21240 TOT AL VA ''B" PHASE 19350 TOTAL CONNECIE.D !'C'✓A 5Z,Q TOTAL DE.MAI\IO KVA 60.0 (1)-{()NNECT IBRU 8 POLIS LIGHTING CONTACTOR LG800. (")-fil EX!IRIOR ANO SITE LIGHT SfWJ. BE llJRNl:O ON BY PHOTOCELL AND TIJRNED ITT \'IA TIME CLOCK. VOLTAGE: MAJ""S: 27"{J_480V-30-4W 20 TYPE MAINS: M.L.O. AIC RATING: 42KAIC AMPS 'A" 'B' ·c· TRIP VA VA VA IDENTIF1CAT\ON C.8. LOAD LOAD LOAD 20 2100 2ND. Fl. EX!IRIOR LTS. 100 2ND. Fl EX!IRIOR Li~- 2100 2ND. Fl. EXlIRIOR LTS. 1225 111, ll ~ u,. 960 1ST. FL OOfRIOR LTS. 960 b1. M OOfRIOH LI~. 150/ 25000 PANEL L1 \'IA , 25COO 75 K'IA XMER / lJWJ 20 2300 ELEV #1 PCK-1 I 230( ELEV #2 PCK-1 t Lnuu UFt 1"' r""' l 20 1328 JOCKEY PUMP 1328 132B I 1000 SPARE 0 ,PACE 0 32"-"-31688 33216 TOTAL VA "C" PHASE: 44476 TOTAL AMPS,'PHASE 160.6 VOLTAGE: ~:Wi0ov-~~-4W MAJ NS: TYPE MAINS: M.C.8. AIC RATING: 14KAIC AJMPS 'A' ··s· ·c· TRIP VA VA VA I DE.NTIF !CATION C.B. LOAD LOAD LOAD 20 168 41H. FL LOOlt«; 1470 41H. FL IJQfllNG 701 15000 PANEl L2 ~ / 1"" 45 K'IA XMER / 1501N 6680 1 ..,_70 15000 TOTAL VA •c• PHASE 16470 TOTAL AMPS/PHASE 72.2 I ~,--G-ER-'S---1------------------,..::;.--+, 1' RIGID GALVANIZED STEEL EMPlY CONOUIT TO MANAGER'S OFFlCE ON FIRST FLOOR. (lYPICAL) NOTE #1 I _J__ _ J ~-~ccTV TO BE PROVIDED ~'% BY OTHER 1" E.C. TO MANAGER'S OFFICE ON FlRST I FLOOR, (lYPICAL) FURNISH AND INSTALL NEW 4" x 4" x 2i° DEEP JUNCTION BOXES. COORDINATE EXACT MOUNTING HEIGHT AND LOCATION WITH OWNER AND CCTV VENDOR _ l INTERIOR CCN EMPTY CONDUIT SYSTEM RISER DIAGRAM INTERIOR AND EXTERIOR UNION N.T.S. NOTES; 1. FURNISH AND INSTALL NEW 4" x 4" x 2~" DEEP, WEATHER PROOF JUNCTION BOX. COORDINATE EXACT MOUNTING HEIGHT AND LOCATION WITH OWNER, AND CCTV SYSTEM VENDOR. 5 ,----ccTV TO BE PRO'l1DED WP BY OTHER l EXTERIOR Proposed New Project EQUAL TO: SQ. 'D' PANEL -"L 1" VOLTAGE: 12~208Y-, 3~ .• 4V,,. TYPE: NQOD MAINS: 207.. MOUNTIN(l: Sl!8£ACE SECTION I TYPE MAINS M.C.8. WITH FEED lhfsG LUGS 7 LOCATION: MAIN ELECTRICAL ROOM AIC RATING: 10KAJC "A' "B" "C" AMPS CIR. CON-CON-CIR. AMPS "A" "3" "C" IDENTIFICATION VA VA VA TRIP POLES No. WIRE DUIT DUIT WIRE No POLES TRIP VA VA VA IDENTIFICATION LO" LOAD OAD C.B. C.8, LOAD LOAD LOAD rnsT FL P ARKlt«; MffiR 200 20 1 M10 3/4" 3/4' ,10 2 1 20 1200 00 FL PAAl<tlG MffiR FlRST fl REIIPTAClfS 900 3 4 nuu Gf.L RECEJ'LILlE T.T.B. nOO 5 6 nOO lliWIR 2 111 LlS & III fil'l!!IR l 111 LlS UK 500 7 8 1200 ~ru ~L l\r ,,... " SECllNO FL PARKING ME1lR 200 9 10 ' 500 ~!~ IIW• ,CCU", ti.tel, "" cvou.-1 850 20 '/ 11 12 500 filVA!OO ROOW l RECIP. 850 / 13 14 1200 SECOND FL P/00,I; METER PUMP RM COOO. -1 DOU 20 ?/ 15 16 500 SECOND fl RECEPTIC!IS 850 / 11 18 100 ff_, 111>1<:U fflllll(J 50 20 1 19 20 ,,, 2 ~u EIIC1. RM SP-1 lV 180 21 22 / 50 SPARE 720 23 24 2/ 20 ~IJ PUMP RM SP-I FAC.P. 500 25 12 3 4· 26 / 50 PARKING SIGN 200 27 10 3 4· 28 1 20 1200 PARKING SIGN r1<~~INu ~lurt 1201 29 10 3 4· 30 1200 PARKING SIGN 2ND,3RD &4THFL LTS. 120( 31 10 3 4· 32 720 FlRSI FlOOR RE(ffl/ffi & 1AASH COMPACTOR 2501 35 :1 / 33 8 3 4· 34 1200 2N0.3RD MIBFL LTS 1 501 / 35 36 1200 SIGN .,,,, / 37 38 1 on, SIGN SIGN 1200 20 1 39 110 3/4" 40 1200 SIGN SIGN "" 20 1 41 410 3/4" 42 180 N 6800 R/\,o 7820 5620 5150 3730 EQUAL TO SQ. 'D" PANEL -"L 1" VOLTAGE: 120b208V., 3~ .• 4W. NOOD MAINS TYPE 20A MOUNTING: SU8FACE SECTION II lYPS MAINS: M.L.Q, LOCATION: MAIN ELECTRICAL ROOM AIC ~TING: 10KAIC SIGN ILUI 20 1 4..l 110 3,4· 3/4 &10 44 1 20 1200 SIGN SIGN 1200 45 46 1200 SIGN SIGN 1201 47 48 1?00 SIGN SiGN 120! 49 50 1200 SIGN SIGN 1200 51 52 1200 SIGN SIGN ;LC\ 53 54 1600 VALET ROOM SP-2 -(") -(**) RECEPTACLES 12u1 55 56 1500 DEDICA1ID RECEPTACI DEDICATED RECEPTACLE 150( 57 58 1500 DEDICA1ID RECEPTAC1 DEDICATED RECEPTACLE 1501 59 60 1000 EXTERIOR G.F.I. EXTERIOR G.F.I, 100( 61 62 1000 EXTERl'JR G.F.I. EXTERIOR G.F.I. 1000 63 64 1000 EXTERKJR G.F.I. EXlmOR G.F.I. 100( 65 68 1000 EXTERIOR G.F.I. VAlff ROOM CU-2 230 67 68 69 70 71 72 73 74 75 76 77 78 79 80 81 82 83 84 16'11 29' 272 10520 10051 8530 TOTAL VA 'A' PHASE 22150 TOTAL VA "B" PHASE 22980 TOTAL VA "C~ PHASE 21250 TOTAL CONNECTED .WA 6!l,1 TOTAL DEMAND .WA 66.6 TOTAL AMPS/PHASE 185. 1 (11)-IBESt SIGNS SIWl BE llJRNED ON BY POOTOCELL N,D llJRNED Off W.. TIME QOCK. EQUAL TO· SQ. 1,011 PANEL -"L2" VOLTAGE: 120 ~208V., 3~.. 4W. lYPE· NQOD MAINS: rn ! MOUNTING: SU8FACE TYPE MAINS: M.C.B. LOCATION: ELECTRICAL ROOM 4TH FLOOR AIC RATING: 10KAJC "A" '8" ·c· AMPS CIR CON-CON-CIR AMPS "A" 'B' ·c· IDENTIFICATION VA VA VA TRIP POLES No, WlRE DUIT DUIT WtRE ~0- POLES TRIP VA VA VA DENT.FICATIO~ LOAD LOAD ,-.OAD C.B. CB. LOA.D LOAD LOAD srn. Fl. RECEPTACLES ~40 20 1 1 110 3/4" 3/4 410 2 1 20 Uf\fl .mt fl. RECEPTACLES srn. Fl. RECEPTACLES 540 3 4 720 .mt fl. RECEPTACLES 411,. tL RECEPTn;u::, 720 5 6 1200 JTI,. PAAXING MITER 411,, Fl. RECEPTACLES ~w 7 8 1200 JTI,, PAAXING METER EFtJ 720 9 10 1200 4IB. PAAXING METER FA POW£R SI.IPftY 720 11 12 1200 411,. PAAKING METER EIICT. RM. COND. -1 850 20 2 13 14 2 20 50 EIIC. R~ SP-1 ('*)- I 850 15 16 50 I SIGN 1200 ?n 1 17 18 1 ?n 1200 SIGN S!iN 120( 20 1 19 20 1 20 1200 SIGN l«>N 1200 360 20 , 23 2~ 1 20 1200 1200 ~llil'I ~lbN 120( 2D 1 25 26 1 20 1200 SIGN SIGN 1200 20 27 28 1 20 120( SK;N SIGN 120( on 29 30 1 20 360 N SIGN 120( on 1 31 32 srn. PAAJ<~ METER 1200 on 1 33 34 35 36 37 38 39 40 41 42 5890 5710 ,200 4550 4370 5160 TOTAL VA "A" PHASE 10440 TOTAL VA ''B' PHASE 10080 TOTAL VA "C" PHASE 9360 TOTAL CONNECTED t<NA 299 TOTAL DEMAND .WA 29.9 TOTAL AMPS/PHASE 83.0 5 date September 01, 2006 sheet title SCALE : AS SHOWN rex.lslon ELECTRICAL PANELS. sheet number Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility ---1.I::;_ GENERAi. REVISION 09/05/06 D\ OWNER CI-W-IGES 02/22/07 E-6.0 S.W. 73rd Street & 58th Avenue, South Miami, Florida project number 200589 drawn by ZM 110 of 162 118 Ii 7 ALL WIRING SHAL BE AS PER MANUFACTURING SPECS. -- INVERTER INVERTER ,-EME '11' '11' ,---BATTERY UPS CABINET - -3#1/0 & 1#6(GJ-2.o·c. 11:,. &. 75 'r/NA TRAINSF. - I 2 ~4#3/o & 1#6(G)-2.o·c. 1#4 GND. ' _ IN_ 3/ 4 •c. .----:' . . ... ii-PANEL PANEL HOUSE 'l-11' ~ METER 'L 1' I f 0 PANEL PANEL : NEW Bx8 GUITTR ~ -'HDP' 'EM' 1 Ci: ~NOTEQ) I . \ 4 TO FPL TRANSFORMER PAD. REFER TO SHEET E-1P FOR LOCATION. ELECTRICAL ROOM ----·3114 &-f#B -GND. ·1N 1.25"C - 45 'r/NA 4#3 & 1#8 &. ' . -GND. IN 1.25"C -TRAINSf. . ' 1#6 GND. A IN 3/4 'C -. - - PANEL PANEL PANEL 'H2' -C 'L2' 'E2' IT/C - 8 {J) 600A/3 PHASE 600A/3 PHASE 1 ~00A/3 PHASE K-7 METER CAN K-7 METER CAN K-7 METER CAN 3P/600A. & 3P/600A. &, 3P/600A. &. CIRCUIT 0 CIRCUIT CIRCUIT 0 0 PANEL -BREAKER -BREAKER -BREAKER 'E1' DISCONNECT DISCONNECT DISCONNECT 100% RATED -100% RATED -100% RATED - 42K A.I.C. 42K A.I.C. 42K A.1,C. 277/4-&N 277/~r:N 277 /48r:N TEMNT I ' TENANT J TENANT K ' 9 @--, 9 9 10 10 ? I IMDWAAE STAINLESS STIT1. ~ / CN' SCREW Wlrn ST.lJNLESS / STEEL WASIIER, PVJN WASHER AND HEXNUT. / T' , THOMPSON SfW.l. DRILL / HOLE D~ AS REQUIRED FOR BOLT SHIPPED. / 24' V: FlOOR LML l / IDJI; I. PRO'nDE MOUNTNG INSULATORS WHERE REQUIRED. ELEVATION WALL m10 IS 1-1/2' STAND OFF STANDAAO MCDIFY TO BE 2' STANO-OFF OR PROVIDE l /2" FILLER AT R. HEAD IIACH. SCREWS. ~ INSERT SIZED AS REQUIRED. (PR0'/I0£ STAINLESS STEEL SCREW IN 'IIIXlO AND SWING WING TOGGLE llOl TS IN PIASTER/DRY WALL) NOTE! DRILL CONCRETE WAl..1/PROVIDE TN'-IN AS REQUIRED. PR<MDE STAINLESS STEEL ROUND HEAD IIACHINE SCREW AS REQUIRED (2 PIJ\CES) EACH WALL BAACKET. TYP. GROUND PLATE MT'G DETAIL N.T.S. cp . I 3100 j 80 ~ M ✓ ELEVATOR 1 ELECTRICAL ROOM -1-4"E.C. ~FU1U£ llN'Nf r.mR & ~N === I 12" X 12" X 12° LONG LINE GUTTER I I ~ lE 10 B.Jl!lN:) RlJ-0'00-I S!EEL 3P/600A CX1JJ W'lm Rf£ /ID EIBl\llR 107 107 107 107 107 107 107 101/ 9"ffl00t-G FUSED DISCONNECT WHR GUNJ El6 00 LJ LJ LJ LJ LJ LJ LJ LJ 12"x4'\c1/4"' lHO< WlJj Ff£..ffiUID 211/~ov -Kl.E O 1/r QC. ~ llNIL CN 17 17 17 17 17 17 17 i7 lHS Cl1'Wt-G IDWilS A-H I ' LJ LJ LJ LJ LJ LJ LJ LJ 3/0 CU -/ EXOTHERMIC WE1D I • e, GND 'MRE I 12·x12·x 12' LONG LOAD GUTTER h NOTE (D C.W.P. ,< 3 = -=-= L/8',t, X 10 FT. COPPER ClAD -~ ~ --~ @ @ @ @ @ @ @ DRIVEN GROUND ROD -TYPICAL FOR 2 RODS M:NIMUM 10 FT. APART. ELECTRICAL RISER DIAGRAM -100 AMP NON AUTOMATIC /_ BREAKER IN NEMA 1 ENCLOSURE WITH SHUNT TRIP. I cp i ~ ~ J31DO I a 80 ~ ~ I ) ',J v ELE.VATOR 2 I FIRE PUMP ROOM I I 6 I M FIRE PUMP I 4 '~ ELECTRICAL FEEDER SCHEDULE ALUMINUM N.T.S. TENANT LOAD CALCULATION 4-600KCM IN 4"C. 2 4-#3/0 & 1-#6(G)-2"C. 3 1-2"E.C. TO TENANT SPACES A THRU H 4 3-#6 & 1/18(G) IN 1.25"C. 5 4-#1 IN 2.o·c. 6 3-#12 & 1 l/12(G)-3/4"C, 7 2-#4 & 1-#B(G)-3/4"C 8 2-1/10 &: 1-l/12(G)-3/4"C. 9 2 SETS OF [ 4-350KCM IN 3.5"C.] 10 2-3.5"E.C. TO TENANT SPACES I THRU K & BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Cables, Fl 33134 305-444-4433 fax 305-444-0181 EMAIL: bdamlamlobellsouthJ1et wa WILLIAM A. BERRY & ASSOCIATES CONSUL TING ENGINEERS 10200 NW 25th STREET, SUITE 111 DORAL, FL 33172 TELEPHONE: 305-513-9000 FAX: 305-513-9' 00 EB 0006543 M SAEED FATEMIAN, PE #40971 ELIZABETH T. PRIDA, PE. 1159464 1 2 SETS OF 4-250KCM IN 2.5"C EACH. 2 4-1/250 KCM & 1-#6(G)-2.5"C. 3 1-2.5"E.C. TO TENANT SPACES A THRU H 4 3-#4 & 1 #8(G) IN 1.25"C. 5 4-1/2/0 IN 2.0"C. 6 3-#12 &: 1/112(G)-3/4"C. 7 2-/12 &: 1-/18(G)-1.25"C 8 2-#10 &: 1-lf12(G)-3/4"C. 9 2 SETS OF [ 4-500KCM IN 3.5"C.] 10 2-3.5"E.C. TO TENANT SPACES I THRU K & Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 MJru; 1, PROVIDE ONE (1) 4"x12"x1/4" THICK COPPER GROUND BUS WITH 1/4" QWjETER PRE-DRILLED HOLES, 1" O.C. MOUNTED TO WALL WITH INSULATED BRACKETS IN ELECT. ROOM. 2. PROVIDE SERVICE ENTRANCE SURGE PROTECTION DEVICE AS MANUFACTURED BY: ADVANCE TECHNOLOGIES, NEMA 1 U.L. LISTED "TE/XHP" SERIES OR APPROVED EQUAL. J. PROVIDE BONDING CONNECTOR WITH APPROVED U.L. LISTED GROUND CLAMPS TO THE MAIN METALLIC COLD WATER PIPE AS PER NEC-250. 4. REFER TO PANEL SCHEDULES ON SHEET E-6.0 FOR FEEDER SIZES NOT INDICATED ON THE RISER DIAGRAM. Proposed New Project TENANT AREA SQUARE DESIGNATION FOOT A 1295 B 1050 C 830 D 960 E 670 F 670 () 960 H 960 I 6495 J 5660 K 4660 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida LIGHTING AT RECEPTACLES MISCELlANOUS 3W/SQUARE @1W/SQUARE LOAD IN VA FOOT FOOT 3885 1295 25900 3150 1050 21000 2490 830 16600 2880 960 19200 2010 670 13400 2010 670 134{)0 3880 960 19200 3880 960 19200 19485 6495 194350 16980 5660 169800 13980 4660 139800 date September 01, 2006 rexlslon ~ GENERAL REVISION 09/05/06 J3\ COORDINATION 11/15/06 /5\ OWNER CAHNGES 02/22/07 HVAC LOAD IN TOTAL LOAD AMPS 0 VA. IN VA 480V-3~-4W 13200 44280 53 7248 32448 39 5952 25872 31 9120 32160 39 7248 23328 28 7248 23328 28 9120 32160 39 9120 32160 39 64950 285780 344 56600 249040 300 46600 205040 247 TOTAL: 962,268 sheet title ELECTRICAL RISER. project number 20r2)!;8~ drawn by ZM . . . . -' • . . 4TH FLOOR 2ND FLOOR ( .J. u FIRE PU~P CONTROL!.ER WITH 600A. 8 MAI~ DISCONNECT A!!)' JOCKEY PUMP , 1ST FLOOR 6 5 SERVICE SIZE 100 100 100 100 100 100 10D 100 600 600 600 SCALE : AS SHOWN sheet number E · 7 . 0 • . t ,.., T I I I I 111 of 162 119 rr====================;..;::::========================================================================='-----'-==::::-=----======. -- NOTE #2 ROOF A - p - PW- L - ST - CT - AHU - 286' WIRE SCHEDULE AU,RM LOOP, I W\IITE 1 IIUJE # 16 TTN (SOUO) POWER. 1 RED(+) 1 BLACK(-) #14 THHN (SlR/,NOEO) POWER, I RED(+) 1 BLACK(-) #14 lHHN (SlR/,NOED) LOOP, 1 PAIR TWISlID #16 JACl<UED NON-SHIELDED (FPL LOW-CN' CABLE ATLAS # 2I6-I6-1-ITP2) OR WP-099O HORN srnooE I OAANGE (+) I BROWN (-) # 12 lHHN (SlR/,NDED) CONTROL 1 ORANG£ 1 RED 1 l3UICK 1 'rillOW #16 fEN (SOUD) AIR HANDLER SHUTDOWN 1 PINK (+) 1 VIOLET (-) #14 THHN (SlR/,NDED) SPRINKLER HEAD (TYP) @) TAMPER SWITCH NOTE #4 k >-----+----------~ SECOND FLOOR LOBBY NOTE #3 135' PHASE II PHASE 1 NOTE #5 E RECALL RECALL t-+----------t---{CM1----<CM NOTE #5 ( TAMPER SWITCH FIRST FLOOR LOBBY ELEVATOR HOIST-WAY SPRINKLER HEAD ELEVATOR PIT ELEVATOR CONTROL CABINET ELEVATOR MACHINE RM. NOTE #4 TYPICAL ELEVATOR DIAGRAM filcS. NOTES: 1. WIRE COMPONENTS PER FLORIDA STATE FIRE MARSHALL CHAPTER 4A-47 "UNIFORM FIRE SAFETY STANDARDS FOR ELEVATORS" AND ANSI A17. 1. 2. SHUTOFF VALVE: RUN TAMPER SWITCH TO F.A.C.P. FOR SUPERVISION (TYP). 3. HEAT DETECTOR ACTIVATION POINT SHALL BE LOWER THAN THE 265'F SPRINKLIER HEAD ACTIVATION TEMPERATURE. HEAT DETECTOR IN PIT TD BE WITHIN 18" OF SPRINKLER HEAD. 4. HEAT DETECTOR (135~ F) LOCATE HEAT DETECTOR AT 18" TO THE SPRINKLER HEAD. CONNECT DETECTORS IN PARALLEL TD SHUNT-TRIP MECHANISM THRU AUXILIARY CONTACTS. HEAT DETECTOR TO AUTOMATICALLY DISCONNECT POWER TO THE ELEVATOR PRIOR TO THE APPLICATION OF WATER. 5. ELEVATOR RECALL REFER TO ELEVATOR CAPTURE SEQUENCE OF OPERATION ON THIS SHEET. NOTE #4 FIRE ALARM NOTES 1. ENTIRE LIFE SAFETY SYSTEM SHALL COMPLY WITH ALL REQUIREMENTS OF THE LOCAL FIRE DEPARTMENT, LATEST ISSUE OF N.F.P.A. 72 AND N.E.C. ARTICLE 760. 2. VERIFY THAT ANNUNCIATION DEVICES ARE CLEARLY AUDIBLE (15db) ABOVE AMBIENT NOISE LEVEL iN ALL NORMALLY OCCUPIED AREAS. ;i, ALL HORNS SHALL PROVIDE AT LEAST 15dbA ABOVE AMBIENT LEVELS IN ALL AREAS AND BE LOCATED AS PER NFPA 72-6-3, 4. ALL STROBES SHALL BE 75cd MINIMUM i\~D LOCATED AS PER NFPA 72-6-4 AND MOUNTED ao· AFF OR 6" BELOW CEILING WHICHEVER IS LOWER. 5. FIRE PENETRATIONS WHEN APPLICABLE SHALL MEET NFPA 70-760-3(0) AND FBC 104-2.3 6. MAXIMUM CONDUIT FlLL SHALL BE 40% PER N.E.C. INCREASE CONDUIT SIZE AS REQUIRED. 7. FIRE ALARM SYSTEM IS A 24V. DC POWER LIMITED WITH A CONTROL PANEL EQUAL TO NOTIFIER MODEL AFP-2DO WITH BUILT-IN 2-LINE DIALER. SLC SUPPORTS 99 ANALOG/ADDRESSABLE 8. CIRCUITS AND 99 CONTROL OR MONITOR MODULES. 9. UPON COMPLETION OF THE INSTALLATION AND WIRING WORK BY THE ELECTRICAL CONTRACTOR, A TEST SHALL BE PERFORMED BY A STATE LICENSED REPRESENTATIVE OF THE FIRE ALARM SYSTEM SUPPLIER TO DETERMINE THE CORRECTNESS OF INSTALLATION PRACTICES AND OPERATION OF THE SYSTEM "AS SPECIFIED" PRIOR TO ISSUANCE OF THE REQUIRED "FIRE ALARM CERTIFICATION AND DESCRIPTION' DOCUMENT AND ATTACHING OF FIRE ALARM SYSTEM CONTROL PANEL "TAG" AS MANDATED BY THE STATE OF FLORIDA 4A-4B REQUIREMENTS. 10. THE FIRE ALARM RISER IS A DIAGRAMMATIC GUIDE FOR THE INSTALLATION OF THE FIRE ALARM EQUIPMENT. THE CONTRACTOR SHALL PROVIDE A COMPLETE OPERABLE SYSTEM AS PER NFPA 72, 101 AND FLORIDA BUILDING CODE. 11. THE CONTRACTOR MUST CAREFULLY COORDINATE ALL WORK AND TERMINATION POINTS WITH THE FIRE ALARM EQUIPMENT SUPPLIER PRIOR TO COMMENCEMENT OF ANY WORK. 12. FURNISH AND INSTALL INTELLIGENT LOOPS, PLUS AUDIO VISUAL ANNUNCIATION CIRCUITS FOR A.D.A. COMPLIANT HORNS AND STROBES (40% MAXIMUM CONDUIT FlLL). FURNISH AND INSTALL SUPERVISED REMOTE POWER SUPPLIES AS REQUIRED. FOR WIRE AND CONDUIT SIZES SEE WIRING LEGEND THIS DRAWING. 13. THE ELECTRICAL CONTRACTOR SHALL SUBMIT DETAILED AND COMPLETE SHOP DRAWINGS TO THE ENGINEER, INCLUDING BATTERY CALCULATIONS FOR ENTIRE SYSTEM INCLUDING "NAC" EXPANDERS FOR APPROVAL BEFORE INSTALLATION IS STARTED. 14. CONTRACTOR SHALL PROGRAM FIRE ALARM PANEL TO RECEIVE FIRE ALARM SIGNAL FROM A/C UNITS DUCT DETECTORS TO SHUT DOWN UPON DETECTION OF SMOKE IN THE SUPPLY AIR DUCTS AND OR UPON ACTIVATION OF ANY AUTOMATIC FIRE DETECTION WITHIN THE BUILDING. 15. MINIMUN SIZE OF CONDUIT IS 3/4". 16. NOTIFICATION APPLIANCE CIRCUITS (NAC) IS CLASS B SffiE Y WITH A MAXIMUM 3A PER CIRCUIT OR A TOTAL OF 8 AMPS. 17. SMOKE DETECTORS SHALL BE NOT LESS THAT 3FT. FROM ANY SUPPLY AIR REGISTER. p 128 125 124 123 121 p p IN PUMP p IN ELEV. 127 126 ROOM 2 PIT SHUNTTRIP ~ filVATOR SIWT F F I E 116 p p p 9 117 116 F F F FIFTH FLOOR AT ELEVATOR Mr.A - J; ~ 75cd 75cd N510 N509 J; ~ 75cd 75cd N410 N409 J; M;; 75cd 75cd N310 N309 F ~ 75cd N508 ~ 75cd N408 1M 75cd N308 75cd 75cd 75cd 75cd N210 N209 N208 N207 p p p p p 115 114 113 112 111 F F F ~ 75cd N507 ~ 75cd N407 ~ 75cd N307 ~ 75cd N506 I&' 75cd N406 ~ 75cd N306 filVATOR SIWTf2 SIMI! TRIP p 503 TOP or SIWT 504 ~~ 75cd 75cd N505 N504 ~ 75cd N503 ~~~ 75cd 75cd 75cd N405 N404 N403 Mtr Mtr ~ 75cd 75cd 75cd N305 N304 N303 r F F F F EllVATDR SIWT #1 SHUNT TRIP p 502 p 501 TOP or SIWT ~..----~ 75cd 75cd N502 N501 ~ 75cd N402 ~ 75cd N302 Im 75cd N301 I I p p 1 I lll'olJOA IIEOO 1 I~ RM /1. (bl~ I 75cd 75cd 75cd 75cd 75cd 75cd JB N206 N205 N204 N203 N202 N201 M-t 101 I E 102 10;3 p p p p p p p IN ELEV. 110 109 108 107 106 105 104 PIT SHUNT TRIP~ filVATDR SIWT F F F r••,-,:, ~:~;;;;) 51H. FlOOR JB 41H. FlOOR JRIJ. FlOOR 2ND. flOOR NOTE #2 TS NOTE #2 75cd 75cd 110<:d 75cd 75cd 110cd 75cd 75cd 75cd 75cd 11 Ocd 75cd 75cd 75cd 75cd 75cd 75cd 75cd 75cd 75cd 75cd 75cd 75cd 75cd ~ 00 N124 N123 N122 N121 N120 N119 Nl 18 N117 N116 N115 CONTROL WIRES FACP FIRE ALARM LEGEND I FACPI INTELLIGENT FIRE DETECTION ALARM PANEL: NOTIFIER #AFP200 WITH MPS-18A POWER SUPPLY (INCLUDES BACK-UP BATTERIES & CHARGER). ~ MANUAL PULL STATION (ADDRESSABLE): NOTIFIER NBG12LX. SEMI-FLUSH MOUNTED AT 4a' ABOVE FlNISHEO FLOOR TO (I_ OF OUTLET BOX. © HEAT DETECTOR. 0 INTEWGENT SMOKE DETECTOR: NOTIFlER FSP-851 WITH B710LP BASE. 24 VOLT ADDRESSABLE CEILING MOUNTED PHOTOELECTRIC SMOKE DETECTOR. 0E 24 VOLT ADDRESSABLE CEILING MT'D PHOTOELECTRIC SMOKE DETECTOR FOR ELEVATOR RECALL. ~ 0 I NTEWGENT-ADD DUCT PHOTO WITH RElAY FSD-751RP WITH REMOTE TEST STATION RTS-451 AND S>MPUNG TUBE ST-3. [TI F.A. HORN. MOUNTED >S PER /.DA REQUIREMENTS. 80' A.F.F. TO BOTTOM OF OUTLET BOX OR 6' BELOW CEILING. WHICHEVER IS LOWER. [[]<l HORN/STROBE: NOTIFIER MULTICANDElA RED P1224MC MOUNTED >S PER NJA REQUIREMENTS. so· A.F.F. TO BOTTOM OF Ol/llET BOX OR 6' BELOW CEJUNG, WHICHEVER IS LOWER. @,~ F.A. STROBE LIGHT NOTIFIER MULTIC>NOElA RED S1224MC, MOUNTED >S PER ADA REQUIREMENTS. 80" A.F.F. TO BOTTOM OF 0Ull£T BOX. 6' BELOW CEILJNG WHICHEVER IS LOWER. NUUBffi ADJACENT TO SYMBOL INDICATES C.V.OElA LMl.. ~ FLOW SWITCH CONNECTION. (rlJRNISHEO &: MOUNTED BY DIV. 15 /CONNECTED BY DIV. 16.) ~ TAMPER SWITCH CONNECTION. (ruRNISHEO &: MOUNTED BY DIV. 15/CONNECTED BY OIV.16) ® ADDRESSABLE ELECTRON IC CONTROL MODULE. ® ADDRESS/IJlLE ELECTRONIC MONITOR MODULE. e F{.S COMBINATION FlRE SMOKE DA.~PER. e M{.D MORORIZED DAMPER (MEC~ICJ.J.) N114 N113 N112 N111 N110 N109 N108 N107 N106 N105 N104 N103 N102 N101 FlRE IIL\RM 01/ilR CONTROL PANEL 1ST. FlOOR FIRE ALARM RISER DIAGRAM #B GRD .. -P 20A, 120V DEDICATED CIRCUIT SEQUENCE OF OPERATION: UPON ACTIVATION OF ANY MANUAL STATION THE FOLLOWING SHALL OCCUR: 1. ALL AUDIBLES WILL SOUND UNTIL SYSTEM IS SILENCED. 2. ALL STROBES WILL FLASH UNTIL SYSTEM IS RESET. 3. AN ALARM SIGNAL SHALL BE SENT TO THE FACP 4. A SIGNAL SHALL BE SENT TO A REMOTE CENTRAL MONITORING SYSTEM UPON ACTIVATION OF ANY SMOKE DETECTOR THE FOLLOWING SHALL OCCUR: 1. ALL AUDIBLES WILL SOUND UNTIL SYSTEM IS SILENCED. 2. ALL STROBES WILL FLASH UNTIL SYSTEM IS RESET. 3. ALL AIR HANDLERS SHALL SHUT DOWN. IN THE AREA WHERE FIRE ORIG,NATES 4. AN ALARM SIGNAL SHALL BE SENT TO THE FACP 5. A SIGNAL SHALL BE SENT TO A REMOTE CENTRAL MONITORING SYSTEM UPON ACTIVATION OF ANY DUCT SMOKE DETECTOR THE FOLLOWING SHALL OCCUR: 1. A SUPERVISORY SIGNAL SHALL BE SENT TO THE FACP. 2. ALL AIR HANDLERS SHALL SHUT DOWN IN THE AREA WHERE FIRE ORIGINATES 4. A SIGNAL SHALL BE SENT TO A REMOTE CENTRAL MONITORING SYSTEM UPON ACTIVATION OF ANY WATERFLOW SWITCH THE FOLLOWING SHALL OCCUR: 1. ALL HORNS WILL SOUND UNTIL SYSTEM IS SILENCED. 2. ALL STROBES WILL FLASH UNTIL SYSTEM IS RESET. 3. ALL AIR HANDLERS SHALL SHUT DOWN. 4. AN ALARM SIGNAL SHALL BE SENT TO THE FACP & ANNUNCIATOR 5. A SIGNAL SHALL BE SENT TO A REMOTE CENTRAL MONITORING SYSTEM c~l tr,j UPON ACTIVATION OF ANY TAMPER SWITCH THE FOLLOWING SHALL OCCUR: 1. A SUPERVISORY SIGNAL SHALL BE SENT TO THE FACP & ANNUNCIATOR """ 2. A SIGNAL SHALL BE SENT TO A REMOTE CENTRAL MONITORING SYSTEM hllY>",s;J)., I 3#12 IN 3/4"C TOL1-25 SEQUENCE OF ELEVATOR CAPTURE-REFER TO ELEVATOR SAFETY CODE A17.1-1Qa,M,.,,,,a YJ INITIATION OF SMOKE DETECTOR AT MACHINE ROOM SHALL CAPTURE THE ELEVATOR -0 FIRST FLOr .· IN ADDITION THE FIRE HAT AND WARNING LIGHT AT ELEV. CAB SHALL BE ACTIVAT ''\ ~-,,,, INITIATION OF SMOKE DETECTOR AT ELEVATOR LOBBY FIRST FLOOR SHALL CAPTUR TH. "'wb'-vATOft T. SECOND FLOOR. k .-· J .. ,# J INITIATION OF SMOKE DETECTOR AT ELEVATOR LOBBY 1ST. FLOOR SHALL CAPTURE TIH~ELEVATOR~V SECOND FLOOR. ~""~ J' . HEAT DETECTOR IN PIT, ELEVATOR MACHINE ROOM OR SHAFT SHALL SHUNT TRIP EL~ATOR)'OWE~ AND INITIATIE FIRE ALARM. ''•«-•" !-'==================~====~-~-""'-~.========================================================================cf;~~~ I I I. BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305-444-0181 EMAIL: bdamiamiobellsouthnet Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 Proposed New Project date September 01, 2006 revision South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida sheet title FIRE ALARM RISER, LEGEND NOTES AND DETAILS. project number 2e>e>S8<a drawn by ZM SCALE : AS SHOWN sheet number E-8.0 112 of 162 120 Charlie Crist Governor Juan C. Muniz, P.E. Consul-tech Developmentt Services 10570 NW 27 th Street, Suite 101 Miami, FL 33172 Dear Mr. Muniz: Lillian Rivera, RN, MSN, Administrator March 2, 2007 Ana M. Viamonte Ros, M.D., M.P.H. Secretary of Health This will acknowledge receipt of general plans and related documents pertaining to installation of a Water Main and Back11ow Preventer(s) to sene South Miami Parking Garage at SW 73'd Street btwn 58 th Avenue & 58 th Court Miami, Florida. Effective March 2, 2007, the above project's plans and documents are approved under DOH Number 272313-047-DSGP with the following provisions: Flushing valves must be provided at all temporary dead ends, unless close to a fire hydrant. This Water Main Extension is not to be placed into service until such tin1e as final \\Titten notice of Clearance is obtained from this office. Clearance will be given only after ce1iification is received from the engineer of record ce1iif)'ing that the project has been consuucted in conformance with the approved plans, together with records of two (2) consecutive days of satisfacto1y bacteriological samples, analyzed and ce1iified by the State of Florida Department of Health laboratory, for drinking water analysis, and taken ,vithin 60 days from the date of clearance documents submittal. For projects and po1iions of projects where there is any substantial deviation from the constrnction permit and approved engineering plans and specifications, a copy of record drawings will be provided. If this permit includes any testable back.flow prevention device, an approved tester will certify the test results. A set of approved drawings was stamped "JOB SITE COPY". This set must be shO\vn to the state inspector at the job site before bacteriological samples can commence. This approval pe1iains only to the water utilities serving this development and it is not to be constrned as approval of s:ewage aspects any future service. All water main piping including fitiings, shall be color coded or marked as described in Section 62-555.320(21)(b) 3, Department of Environmental Protection Drinking Water Rules, Florida Administrative Code Effective August 28, 2003. All concerned are reminded that approval must be obtained from both water and sewage facilities prior to constrnction. The owner or permittee is advised that approval is given to the functional a~pects of this project on the basis of representation, and data furnished to this division. There may be County, Municipal or other Local Regulations to be complied with by the owner or permittee prior to constrnction of the facilities represented by the plans referred to above. We recommend that appropriate Local Agencies be consulted before starting constrnction. This permit shall be valid for (5) fiye years from the date of issuance. Reapproval of expired pemuts shall be considered upon written request accompanied by the appropriate application-processing fee. We are enclosing copies of the approved documents for your files. CC:DERM f ('Y tI1 ) w·s, l/~c: c, P.E. Samir Elmir, PhD, PE, DEE, CEHP, Director Environmental Health and Engineering Miami-Dade County Health Department 1725 N. W. 167th Street, Miami, Florida 33056 Tel: (305) 623-3500 Fax: (305) 623-3502 Email: Samir_Elmir@doh.state.11.us Website: www.dadehealth.org c ___ _ Public Health , .. , .... ,,~ ...... ,,oi.c1. fiEiiffiiiffiiiiffiiiiiii53il 113 of 162 121 Attention: Transmittal Letter March 13, 2007 KVC Constructors, Inc. 9499 N. E. 2nd Avenue Suite 205 Miami Shores, Florida 33138 Office: 305-757-7707 Fax: 305-757-7701 South Miami Building Department Sonia Lama X Attached D X Shop Drawings D D Copy of Letter D □ Brochure □ 2 2 □ For Approval X For Your Use □ As Requested □ For Review and Comment □ FOR BIDS DUE: File Project: City of South Miami Parking Garage For Division: Under Separate Cover via: the following: Prints □ Plans Other; Change Order □ Samples Reproducible □ Specifications □ □ □ □ 1s1gned and seal Civil Drawings Sheets C-3, C-3A and C-4 :approved by the Fire Department and the Health Oepartment. 1Department of health Approval Letter Approved as S1Ubmitted □ Resubmit copies for approval Approved as Noted □ Submit(#] copies for distribution Returned for Corrections □ Return [#] corrected prints Revise and Resubmit/Work May Not Proceed D PRINTS RETURNED AFTER LOAN Juan A. Mejfa 114 of 162 122 ( r I ~C)~ ~r _;s,> ' .:i ~ o. u-Z-~ EXHIBIT No. 1 SCOPE OF SERVICES ATTACHMENT C Request for Qualifications for the Design and Install Parking Garage Security System RFQ #FN2022- 18 “PARKING GARAGE PLANS” 115 of 162 123 116 of 162124(s) ---t---15'--0"ALLEY(ONEWAY)~------------------------------------1-------+-----------+----------------~--------+-----~--------I I -€'.}-Ht------!lt-'-..::..=~----.-'t--:'-1-,:--,.:----· ·,,. -..:_..,-....::,__:....,..,---jj.:.._,,Lr--7"'-+-,,Lfl-:-'-,+j:'_L_._,_'i'---cc'-,---_.:.......,-,it---:----,---....:..:..=;.::==r,:::::;~b i~'::~;· .. ,, _.· ~~!.e:-:::.~;:i-' I I ~ @ F >-' §I ~i "' 1 I ' I ' I ' I d ~ ; BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECJ\JRE · INnRIOR DESIGN 285 --.., C<nl Cable,, A 33134 -fax305#4-0181 EMAIL: bd•n•nobell1outhnet Client: 14 •• L,r,:,:::,;s.':"7' RESTAU!NT1 4761sqfl1 I WITH Mr. Mark Richman M.R. Properties Inc. City of South Miami 6130SunsetDrive 185D0NE5thAvenue South Miami, Florida33143 Miami, Florida RESTAURANT 2 5822sqft Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida ! _ _._ I ' I RESTAURANT 3 e14osqft I date May26,200B revilion KJuly14,2006co-n.,., ~ October25,2006 1haat title 1st LEVEL project number drawn by D.M. Stale: 3132" ~ 1'-0" 117 of 162125BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Averue Coral Gable5, Fl 33134 ~bdarriamk»bellsouthnet'ax 305-444-01&1 N 3. /2 I~------+-~ j CD SECOND LEVEL Client: Mr. Mark Richman M.R. Properties Inc. 18~00 NE 5th Avenue M1am1, Honda WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 4 .5 ----t-Proposed New Project South Miami Municipal Parking Facility SW. 73rd Street & 58th Avenue, South Miami, Florida date May 26, 2006 revision 11 l'j ~hut title 2nd LEVEL project number drawn by D.M _J Scale ,,' ,·\ s~eetnumbe,·--::-----~ t<) \_, i¼.· A-3'\Y 'A' 118 of 162126BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE -INTERIOR DESIGN 285 Sevlla AYel'IJe C.oral c.ables, A 33134 305-444-4433 fax 305-444-0181 EM'\IL: bdarnlarriObellsow\net N CD Tli!RD LEVEL Client: Mr. Mark Richman MR Properties Inc. 18500 NE 5lh Avenue M1,m1, Florido WITH City of South Miami 6130 Sunset Drve South M1am1, Florida 33143 ,4 5', 6 t-Proposed New Project South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami Florida '.7' 8 I ii ];I,~ +----] i ---~ ~ j __________ ... .,:, date May ?6, 2006 sheet title 3rd LEVEL Scale: 3.'32"=1·-o· \ '"'" """"" --c\ .\ ~~'l project number diawn by D.M 119 of 162127BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 SeoAla Aveooe Coral Gables, Fl 33134 3Q5.444.4433 fax305-444-0181 EMAIL: bdamiamlobellsouth.net N CD FOURT!i LEVEL Clie_n_t:_ Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami. Flor'1da WITH City of South Miami 6130 Sunset Drive South Miami, Florida 33143 I , I ' I I ~~--. --~~~*~~;!;~~~~~~1=~k~~~;;;;;;~~~~~~~~~;,:;;;;;;;;":;~;;;;;;;;;;;;~~~~==~'! ~==--. Proposed New Project date May 26, 2006 South Miami Municipal Parking Facility S.W 73rd Street & 58th Avenus, South Miami tlorida sheet title 4th LEVEL project number draw~ by D.M :::'.',,..,.,-<:}' A-5·· \\,} '\i-'_ 120 of 162128~ ~----"@ ! LEGEND I\ -··--$===· @ -·-. ' 1 IR1 ROOF PLAN ' . -cp ~ N '3) 'r I I CD FIFIH LEVEL (ROOP) ARCHITECTURE . INTERIOR DESIGN 18500 NE 5th Avenue South Miami, Florida 33143 285 Sewlla Aver11a Coral CatNs, fl 33134 M1am1, Florida -fax305a44+0181 --"' (4\ '( ' I '5' 'f ' ---I i ... ,,. 0~ I ' I ,one SEE STRUCTURAL DRAWINGS FOR SIZING AND TYPEOFALLSTRUGTURALELEMENTS ,,. Proposed New Project (fi) ;so,· l ·-------~-~-I ~ i o·-0· , . ..,. ,,. I ,---: L--=J South Miami Municipal Parking Facility S.W 73rd Street & 58th Avenue, South M1amI, Florida (j_) (8) ~ T @ ... ~ ' , .. ' »-ll" ' 2'-□• ' 17'--0" ' l I I I i i 12-0· ,_,. ,,..,. ,,. ,. ,.,-<r I I :1 I ' ' I ,-----, I date May26,20D6 1heet title Scale:3/32"=1'-0" revision 5th LEVEL fil August1B,_2006 (ROOF) -----project number drawn by D.M. 121 of 162129~---------BLITSTEIN DESIGN ASSOCIATES AR0007S70 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305-444-0181 EMAIL: bdarnluriObellsouthnet Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH City of South Miami 6130 Sunset Drive South Miami. Florida 33143 4 9· fo I I ' ~----------Proposed New Project da t II May 26, 2006 !heet tlth revision ELEVATIONS South Miami Municipal Parking Facility project ~umber S.W. 73rd Street & 58th Avenue, South Miam,. Florida drawh by D.M 122 of 162130BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sewlla A"9l'U8 Ccnl ~ Fl 3.3134 -... .........,,.,, EMAIL: ~ Mr. Mark Richman M .R. Properties Inc. 18500 NE 5th Avenue Miam1,Flonda Proposed New Project City of South Miami 6130Sunse!Drive South Miami, Florida33143 South Miami Municipal Parking Facility s.w. 73rd Street & 58th Avenue, South Miami, Florida date May26,2006 r1vhlon ~August1B,_2006 sheet title Scale:3132"=1'-0" \, J , {; ELEVATIONS project number drawn by D.M. EXHIBIT No. 1 SCOPE OF SERVICES ATTACHMENT D Request for Qualifications for the Design and Install Parking Garage Security System RFQ #FN2022- 18 “BOUNDARY SURVEY” 123 of 162 131 124 of 162132';:J."1f" 1.LNorth Une, NE 1/4, Section .36-54-40 Measured 2641_56, .. c ...... ,., ,,. Measured 652. 85' · ..,.., ,._,...,, S. W. 7 2 nd S T R E E T {S U N S E T D R I V E) ,j Calculated 652.85' --~ ----t w=-----· ......... -;ca, ..... , ......... 1 _ ---~ -----T-r ~~~, ~s ""\"-. -----7 !1 ~,;>'-,-,>.=::,:--ii \___ Arll> lh~l•d ID,-Rlqn1-,r-~y 1;:111 Dar Olllclal R~cird !lock ~Ull 111 Jl.i;, 2.la "f' 7 I I ~ ~J, I ... + I r' ~ I I I ~1[ 1 •. 1. f w ::, z w > < -0 C ~ <O ;:. vi I ;I l ~ ~ .. ,$ I I, I -I~ :5 I~ :, "' 0 ., ,-?' :,; -7 25.00" . -----~..--, ..... ........ , ~f:~~¼: -1--~-. ..., ... ., .... it~ s. w. J'ii S TR E -----, FOullCI HIii • , DIie /lo. 14f v,. s. w. 8 0 th S TR E /South Line, NE 1/4, Section E~ -~--------Measured 2640.34' s: vi I I I' 36-54-40 -, .. ,ff-~ on t;.,tr,#111■ SE Conier NE 1/♦ $fCUo,r Jl-s+-40 SYMBOL '&!_,,, ... _ ... c.n,Ollt ii PIii■ TRU" :!II ''" ~ no■ .r Trdnc ~ ,.....,,.. e Watw Hm9 !lob 1111 Cal~ Badn gt~~ -.e C4'f So• ,E-Glfr""'4:!lt'r 1M S.-,04' Vo .... I>,__.~-mlflflll!fls.-... ~•~•b • -Cd-(;i«, ...... E-,C.,.UPo~ ljjli.._,_ CCMl..,,._PGII 0 ~arHNa e,-S.-1,11Mtiol1 FjC.-.flle.,. LEGEND -~.;.d • .,,,..,.., X Grc!vndE:1 .... II .,. I -k-i,nF'1111c::e ,_ -...,.t-,e:. ~ ul!krMu --,...., _,,.,._,... a ........ _ ~ =; .. ~-A F",r• Hydrant CB --lil ......... G! Wal.Ir,-_,.., <Sa ---e ~Mel..-I[) DKtr'col -.~ ... (1 ,....,. . ...,.., ;~ ................ 5)5·--•Vat.. 0 llt,Lal PW. ,;;, CH VOM 0 v-•~ l.ECAL DESCRlPTIQ/1; Lol 35, end ,he North 11 2/3 laet of Lol 36, ond all or Lots 48, +9 ond 50, ol W.A. LARKINS sue0I111S10N, cccotdin9 to the Piel thoreof, os recorded in Plot Book 3 ct Po9a 198 o: lhe Public Rec0<ds of Dode County. Florldc . TOGETHER 111TH: Lot 36, LESS tl\e North 11 2/3 feet ond LESS the West 5 feet end Lot 37. LESS the Scutt, lO !eot and tho West 5 feet, of IY.A. LARKINS SUBDIVISION. occor<f,ng to the Plot thereof, as record«d i,, ?lat Booll 3 ot Page 198 of toe, Public Ree0<ds of Oo~e County, Florido. CITY OF SOUTH MIAMI SURVEY FDR: PARKING LOT SW 56TH A VENUE AND 7 3RD STREET MIAMI, FLa.lDA I HEREBY CERTIFY: Thal the SKETCH OF Sl!R~Y of the obo•e coptlon~d proporty we-., completed under my superYi5i0n «ad/Or d!r.~ction. to lhe best of my knowle.dge-ond belier. Thi• survey meet• or e,ceeds the Minimum Technlccl Slo~dordo oel forth by the Florido B0<>rd or Lond Surveyor!:I i1'I Chcpte.r OlG-17-6 Florido Adm·irii!ltrot;ve Code. Pursuor"l lo Secjon ~72.027. f1orldo Stclut"". ~UR~YO:~) DELTA SURVEYORS, INC.' d-I /J/7~ V 13052 SW 133RD COURT i ,.,,,,,.,_.1/,..U/, i. MIAMI, FLORIDA . 33186 ! WALDO F. PAEZ TE: ,; •//·&?',:;, PROFESSIONAL SURVE. ANO MAPPER NO. 328~' 305-253-0909 CERTIFICATE OF UTHORIZATION FAX: 305-253-0933 L.B. NO. 3386 STA TE OF FLORIDA 1 )FLOOD ZONE: X PANEL NO. 0266 J COMt.lUNITY NO. 120658 DATE OF i.AAP: 3-2-94 Z)~~Es1~'/~~\:tr°'~f~As'rR:05J~f::_0N~E~~1c~ER~griRg~o-:i ~s COUNTY. ' .l)E:XAi.AINATION 0. ABSTI!ACT OF llllE lli1Lt HA~ TO BE MAOE TO Ot'TERMJNr RECORDED INSTIIUMQITI?;· If 11,NY. ~FECTING PR01'E.RTY • .+)LOCATION• ANO IOENi1f'ICATION;Of',U)1t.JTILIE~, !~·ANY AAE-SHO\\N IN• ACCORDANCE 'MTH· RECOROUJ·, PLAT· . • • sJo,ONERSHtP 1s S\JBJECT. To·OP1Nl0f,I o, TITLE. 6)l"il'E Of SUR\11::Y; 80UNDA!IY ~URVEY' .' . . 7)lHE HEREJN CAPTIONED F'RCPERTY WAS SURI/EYED ANO OESCRIBEO BASED ON THE SHOWN t:.EG"'L DESCRIPTION:. ?ROVIOEO BY CLIENT B)lHJS SURVEY IS NOT VALID MlHOUT .THE .SIGNATURE AND lliE ORIGINAL RAISED SEAL .OF A Fl0R10A UC£NSEil S\JflVEYOR ANO MAPPER 9)TrilS P[/2N OF SURVEY, HAS BEEN PREPAf!ED FOR THE EXCWSIVE USE OF THE EN'TITIES NAMED HEREON. THE C€:RT1f1CATE DOES N01 ElCTENO TO ANY UNNAMED PARTIES ,o~~~~~I::~~oAi~~llf;~ ~F.Jo::oro 0$f6"t°sa~~R~i< cg:rACT THE CONSlRUCTION ON lHE PRCPERTY HEREIN OESCRISEO. SURVEYOR SHAll. BE NOTIFIED AS TO ANY DEVIATION FROM UTILITIES SHOWN HEREON. 11 )THE SURVEYOR Of RECOft0:00€S NOT DETERMINE OWNER.SHIP OF FENCES. MEASUREMENTS SllOWN HEREON DEPICT PHYSICAL LOCATION OF FENCE • 12}ACCURACY: ·THE ,EXPECTEO:usE OF LANO AS CLASSl,IEO IN THE'. MINli.AUM TECliNICAt. STANOAROS (&IGl7-FAC). IS "COMMERCIAL•. THE MINl'-IUM RELATI~ OJSTANCE ACCURACY l'OR !HE T'fl'E OF BOUNDARY SIJRVEY IS 1 roar IN 10.000 FEET. llj£ ACCURACY 08T.I\INEO SY MEASIJREMEN,T ANO CALCULATION •OF A CtOSEO GEOMETRIC FIGURE WAS FCUND TO EXCEED THIS REQUIREMENT 13)IN SOME INSTANCES, CR~HIC REPRESENTA TIDNS HAVE BEEN EXAGGERATED TO MORE CUARLY ILLUSTRATE RELATIONSHIPS BE"FWEEN PHYSICAL IMPROVEMENTS ANO/OR LOT LINES.. IN All. CASES. DIMENSIONS SHOWN SHAU CONTROL Tt-lE LOCATION OF' THE IMPROVEMENTS DVER SCAUD POSITIONS. 14)NO ATTEi.APT HAS BEEN MIDE TO LOCATE ANY FOUNDATION BENEATH lliE SURFACE OF THE GRll!NO, 1 S)CONTACT THE APPROPRIA rt AUTHORITY PRIOR TO AN OES1GN WORK ON THE HEREIN DESCRIBED PARCEL FOR BUILDING AND ZONING INFORMATION. 16)ALL RICHT-OJ'-V(AYS WERE OBTAINED B'!' ~ECOROED PLAT BOOKS AND FIELD MEASUREMENlS, ANO ·Sl'iAU eE VERIFIED BEFORE ANY DESIGN WORK WITH THE PROPER RIGHT-Of-WAY DEPARTMEHT . If EL.EVA TIONS ARE SH0\11',1, iHEY ARE BASED ON A CLOSED LEVt:L LOOP USJNG THIRD ORDER PROCEDURE AND ARE RELATiiE TO THE NATIONAL GEOOET1C VERTICAL DATUM OF 1929. 0.0 DENOTES EXISTING ELEVAnON ELEVATION REFERS TO THE NATIONAL GEODETIC VERTICAL DAlUM OF MEAN SEA LEVEL OF 1929 .. BENCHMARK: SOUTH MIA~ ELEVATION: 13.31' LDC ATOR INDEX: 4005 W FlELO SURVEY DATE: 3"-10-05 SCALE: 1" • 30' DRAWN BY: K.K. ORAWIN~ OAn'.: _3-14.:05 .FB:_ 167,( SKETCH PG; 13 ORAVnNC NO., 05-20~ z RE\/lSEO: 02-07-:-06 • RE-5\.RVEY ORA\'11NG No 06-0107 • REVISED:-04-10-6 ADDITIO~AL ··ELEVATIONS No 06-0314 >-w > a: ::» Cl) >-· a: <C 0 z: ::, O-m DATE: OHHl6 .. SCALE: r-~ DRAWING NO: 08-03142-SHEET0NO. 1 EXHIBIT 2 DESIGN AND INSTALL PARKING GARAGE SECURITY SYSTEM RFQ #FN2022- 18 Insurance & Indemnification Requirements Insurance A. Without limiting its liability, the contractor, consultant or consulting firm (hereinafter referred to as “FIRM” with regard to Insurance and Indemnification requirements) must procure and maintain at its own expense during the life of the Contract, insurance of the types and in the minimum amounts stated below as will protect the FIRM, from claims which may arise out of or result from the contract or the performance of the contract with the City of South Miami, whether such claim is against the FIRM or any sub-contractor/sub-consultant, or by anyone directly or indirectly employed by any of them or by anyone for whose acts any of them may be liable. B. No insurance required by the CITY may be issued or written by a surplus lines carrier unless authorized in writing by the CITY and such authorization is at the CITY’s sole and absolute discretion. The FIRM must purchase insurance from and must maintain the insurance with a company or companies lawfully authorized to sell insurance in the State of Florida, on forms approved by the State of Florida, as will protect the FIRM, at a minimum, from all claims as set forth below which may arise out of or result from the FIRM's operations under the Contract and for which the FIRM may be legally liable, whether such operations be by the FIRM or by a Sub-contractor/sub-consultant or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable: (a) claims under workers' compensation, disability benefit and other similar employee benefit acts which are applicable to the Work to be performed; (b) claims for damages because of bodily injury, occupational sickness or disease, or death of the FIRM's employees; (c) claims for damages because of bodily injury, sickness or disease, or death of any person other than the FIRM's employees; (d) claims for damages insured by usual personal injury liability coverage; (e) claims for damages, other than to the Work itself, because of injury to or destruction of tangible property, including loss of use resulting there from; (f) claims for damages because of bodily injury, death of a person or property damage arising out of ownership, maintenance or use of a motor vehicle; (g) claims for bodily injury or property damage arising out of completed operations; and (h) claims involving contractual liability insurance applicable to the FIRM's obligations under the Contract. Firm’s Insurance Generally. The FIRM must provide and maintain in force and effect until all the Work to be performed under this Contract has been completed and accepted by CITY (or for such duration as is otherwise specified hereinafter), the insurance coverage written on Florida approved forms and as set forth below: Workers’ Compensation Insurance at the statutory amount as to all employees in compliance with the "Workers' Compensation Law" of the State of Florida including Chapter 440, Florida Statutes, as presently written or hereafter amended, and all applicable federal laws. In addition, the policy (ies) must include Employers' Liability at the statutory coverage amount. The FIRM must further ensure that all of its Sub-contractor/sub-consultants maintain appropriate levels of Worker's Compensation Insurance. Commercial Comprehensive General Liability insurance with broad form endorsement, as well as automobile liability, completed operations and products liability, contractual liability, severability of interest with cross liability provision, and personal injury and property damage liability with limits of $1,000,000 combined single limit per occurrence and $2,000,000 aggregate, including: • Personal Injury: $1,000,000; • Medical Insurance: $5,000 per person; 125 of 162 133 • Property Damage: $500,000 each occurrence; Umbrella Commercial Comprehensive General Liability insurance must be written on a Florida approved form with the same coverage as the primary insurance policy but in the amount of $1,000,000 per claim and $2,000,000 Annual Aggregate. Coverage must be afforded on a form no more restrictive than the latest edition of the Comprehensive General Liability policy, without restrictive endorsements, as filed by the Insurance Services Office, and must include: • Premises and Operation • Independent Contractors • Products and/or Completed Operations Hazard • Explosion, Collapse and Underground Hazard Coverage • Broad Form Property Damage • Broad Form Contractual Coverage applicable to this specific Contract, including any hold harmless and/or indemnification agreement. • Personal Injury Coverage with Employee and Contractual Exclusions removed, with minimum limits of coverage equal to those required for Bodily Injury Liability and Property Damage Liability. Business Automobile Liability with minimum limits of One Million Dollars ($1,000,000.00) plus an additional One Million Dollar ($1,000,000.00) umbrella per occurrence combined single limit for Bodily Injury Liability and Property Damage Liability. Umbrella coverage must be afforded on a form no more restrictive than the latest edition of the Business Automobile Liability policy, without restrictive endorsements, as filed by with the state of Florida, and must include: • Owned Vehicles. • Hired and Non-Owned Vehicles • Employers' Non-Ownership Subcontracts: The FIRM agrees that if any part of the Work under the Contract is sublet, the subcontract must contain the same insurance provision as set forth in these insurance and indemnification requirements, other than the Fire and Extended Coverage Insurance and substituting the word Sub-contractor/sub-consultant for the word FIRM where applicable. Fire and Extended Coverage Insurance (Builders’ Risk), IF APPLICABLE: A. In the event that this contract involves the construction of a structure, FIRM must maintain, with an Insurance Company or Insurance Companies acceptable to the CITY, "Broad" form/All Risk Insurance on buildings and structures, including Vandalism & Malicious Mischief coverage, while in the course of construction, including foundations, additions, attachments, and all permanent fixtures belonging to and constituting a part of said buildings or structures. The policy or policies must also cover machinery, if the cost of machinery is included in the Contract, or if the machinery is located in a building that is being renovated by reason of this contract. The amount of insurance must, at all times, be at least equal to the replacement and actual cash value of the insured property. The policy must be in the name of the CITY and the CONTRACTOR, as their interest may appear, and must also cover the interests of all Sub- contractor/sub-consultants performing Work. B. All of the provisions set forth in the Miscellaneous section below apply to this coverage unless it would be clearly not applicable. 126 of 162 134 Miscellaneous: A. If any notice of cancellation of insurance or change in coverage is issued by the insurance company or should any insurance have an expiration date that will occur during the period of this contract, the FIRM Is responsible for securing other acceptable insurance prior to such cancellation, change, or expiration so as to provide continuous coverage as specified in this section and so as to maintain coverage during the life of this Contract. B. All deductibles must be declared by the FIRM and must be approved by the CITY. At the option of the CITY, either the FIRM must eliminate or reduce such deductible or the FIRM must procure a Bond, in a form satisfactory to the CITY covering the same. C. The policies must contain waiver of subrogation against CITY where applicable, must expressly provide that such policy or policies are primary over any other collectible insurance that CITY may have. The CITY reserves the right at any time to request a copy of the required policies for review. All policies must contain a “severability of interest” or “cross liability” clause without obligation for premium payment of the CITY as well as contractual liability provision covering FIRM’s duty to indemnify the City as provided in this Agreement. D. Before starting the Work, the FIRM must deliver to the CITY and CONSULTANT certificates of such insurance, acceptable to the CITY, as well as the insurance binder, if one is issued, the insurance policy, including the declaration page and all applicable endorsements and provide the name, address and telephone number of the insurance agent or broker through whom the policy was obtained. The insurer must be rated A.VII or better per A.M. Best’s Key Rating Guide, latest edition and authorized to issue insurance in the State of Florida. All insurance policies must be written on forms approved by the State of Florida and they must remain in full force and effect for the duration of the contract period with the CITY. The FIRM may be required by the CITY, at its sole discretion, to provide a “certified copy” of the Policy (as defined in Article 1 of this document) which must include the declaration page and all required endorsements. In addition, the FIRM must deliver, at the time of delivery of the insurance certificate, the following endorsements: (1) a policy provision or an endorsement with substantially similar provisions as follows: “The City of South Miami is an additional insured. The insurer must pay all sums that the City of South Miami becomes legally obligated to pay as damages because of ‘bodily injury”, ‘property damage’, or ”personal and advertising injury” and it will provide to the City all of the coverage that is typically provided under the standard Florida approved forms for commercial general liability coverage A and coverage B”; (2) a policy provision or an endorsement with substantially similar provisions as follows: “This policy must not be cancelled (including cancellation for non-payment of premium), terminated, or materially modified without first giving the City of South Miami ten (10) days advanced written notice of the intent to materially modify the policy or to cancel or terminate the policy for any reason. The notification must be delivered to the City by certified mail, with proof of delivery to the City.” E. If the FIRM is providing professional services, such as would be provided by an architect, engineer, attorney, or accountant, to name a few, then in such event and in addition to the above requirements, the FIRM must also provide Professional Liability Insurance on a Florida approved form in the amount of $1,000,000 with deductible per claim if any, not to exceed 5% of the limit of liability providing for all sums which the FIRM becomes legally obligated to pay as damages for claims arising out of the services or work performed by the FIRM its agents, representatives, Sub Contractors or assigns, or by any person employed or retained by him in connection with this Agreement. This insurance must be maintained for four years after completion of the construction and acceptance of any Project covered by this Agreement. However, the FIRM may purchase Specific Project Professional Liability Insurance, in the amount and under the terms specified above, which is also acceptable. No insurance may be 127 of 162 135 issued by a surplus lines carrier unless authorized in writing by the city at the city’s sole, absolute, and unfettered discretion. Indemnification Requirement A. FIRM accepts and voluntarily incurs all risks of any injuries, damages, or harm which might arise during the work or event that is occurring on the CITY's property due to the negligence or other fault of FIRM or anyone acting through or on behalf of FIRM. B. FIRM must indemnify, defend, save and hold CITY, its officers, affiliates, employees, successors and assigns, harmless from any and all damages, claims, liability, losses, claims, demands, suits, fines, judgments or cost and expenses, including reasonable attorney’s fees, paralegal fees and investigative costs incidental there to and incurred prior to, during or following any litigation, mediation, arbitration and at all appellate levels, which may be suffered by, or accrued against, charged to or recoverable from the City of South Miami, its officers, affiliates, employees, successors and assigns, by reason of any causes of actions or claim of any kind or nature, including claims for injury to, or death of any person or persons and for the loss or damage to any property arising out of a negligent error, omission, misconduct, or any gross negligence, intentional act or harmful conduct of FIRM, its contractor/sub-contractor/sub-consultant or any of their officers, directors, agents, representatives, employees, or assigns, or anyone acting through or on behalf of any of them, arising out of this Agreement, incident to it, or resulting from the performance or non-performance of FIRM's obligations under this AGREEMENT. C. FIRM must pay all claims, losses and expenses of any kind or nature whatsoever, in connection therewith, including the expense or loss of the CITY and/or its affected officers, affiliates, employees, successors and assigns, including their attorney’s fees, in the defense of any action in law or equity brought against them and arising from the negligent error, omission, or act of FIRM, its Sub- contractor/sub-consultant or any of their agents, representatives, employees, or assigns, and/or arising out of, or incident to, this Agreement, or incident to or resulting from the performance or non- performance of FIRM's obligations under this AGREEMENT. D. FIRM agrees and recognizes that neither the CITY nor its officers, affiliates, employees, successors and assigns are to be held liable or responsible for any claims, including the costs and expenses of defending such claims which may result from or arise out of actions or omissions of FIRM, its contractor/sub-contractor/sub-consultant or any of their agents, representatives, employees, or assigns, or anyone acting through or on behalf of the them, and arising out of or concerning the work or event that is occurring on the CITY's property. In reviewing, approving, or rejecting any submissions or acts of FIRM, CITY in no way assumes or shares responsibility or liability for the acts or omissions of FIRM, its contractor/sub-contractor/sub-consultant or any of their agents, representatives, employees, or assigns, or anyone acting through or on behalf of them. E. FIRM has the duty to provide a defense with an attorney or law firm approved by the City of South Miami, which approval will not be unreasonably withheld. F. However, as to design professional contracts, and pursuant to Section 725.08 (1), Florida Statutes, none of the provisions set forth herein above that are in conflict with this subparagraph apply and this subparagraph sets forth the responsibility of the design professional concerning the extent of, and the conditions under which, indemnification is required. Thus, the design professional’s obligations as to the City and its agencies, as well as to its officers and employees, is to indemnify and hold them harmless from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys’ fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the design professional and other persons employed or utilized by the design professional in the performance of the contract. END OF SECTION 128 of 162 136 EXHIBIT 3 EVALUATION AND SELECTION CRITERIA Design and Install a Parking Garage Security System RFQ #FN2022- 18 Scoring and Average Ranking Phase I - Competitive Selection-Ranking; maximum 100 points per committee member. Proposals will be evaluated by an Evaluation Selection Committee that will evaluate and rank proposals on the technical criteria listed below. The Evaluation Selection Committee will be comprised of appropriate City personnel and/or members of the community, as deemed necessary, with the appropriate experience and/or knowledge. Respondents deemed as best suited and qualified will be selected by The Evaluation Selection Committee for discussion and/or presentations, ranking and subsequent negotiations with the highest ranked Respondent. The criteria are itemized with their respective weights for a maximum total of one hundred (100) points per Evaluation Selection Committee member. The evaluation factors used for determining qualifications for scoring and ranking, including average ranking order, shall include: Technical Criteria: a) RESPONDENTS QUALIFICATIONS (Maximum Point Value – 50) i. Number of years of experience in the design and installation of security camera surveillance systems for residential and commercial applications. Company and/or predecessors must have at least five (5) years of experience in this field. ii. Background in handling similar size projects: company must have successfully completed a project involving the commercial design and installation of a security camera surveillance system within the past five (5) years. iii. Degree of experience in all areas of a security camera surveillance design and installation process. v. Proof of satisfactory or better performance on contracts of similar scope and size: references and letters of reference must verify successful completion of similar projects. vi. Number of similar projects: company and/or predecessors must have completed at least five (5) similar projects within the last 5 years. b) PROJECTS (Maximum Point Value – 50) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, managerial approach, environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. 129 of 162 137 Average Ranking Order: Each Evaluation Selection Committee member shall rank each Respondent; #1 (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters and the lowest number represents the most qualified firm. In the example below, Respondent B’s total Rank Score is 6, divided by the number of Raters (4) equals the lowest number of 1.50 and therefore Respondent B is considered the most qualified and eligible for the award of a contract, subject to satisfactory negotiations: Respondent B = 6 (Rank Score) Divided by the Number of Raters (4) = 1.50 Phase II - Oral Presentations Upon completion of the criteria evaluation indicated above by the Evaluation Selection Committee, including rating, and ranking, the Evaluation Selection Committee may choose to conduct an oral presentation and/or interviews with the Respondent (s) who the Evaluation Selection Committee deems to warrant further consideration based such things as scores in clusters; based on the preliminary rating and rankings, and/or maintaining competition. Upon completion of the oral presentation(s) and/or interviews, the Evaluation Selection Committee will perform a final review to re-evaluate, re-rate, and re-rank the Proposals, as described above, remaining in consideration based upon the written documents, combined with the oral presentation. Phase III – Competitive Negotiations A final ranking of all firms or short-listed firms will be submitted to the City Manager for review and approval. In order to fulfill the City’s needs and meet the requirements in accordance with Exhibit 1 “Scope of Services, Attachments A, B, C & D” the City intends to award a contract to complete the work as described in Exhibit 1, “Scope of Services Attachments A, B, C, & D.” The City Manager shall commence negotiations with the first ranked firm. If those negotiations are unsuccessful, negotiations will be opened with the next ranked firm, etc. Negotiations shall continue until the City Manager has successfully completed negotiations with a firm and shall execute a contract with the City in accordance with City Commission approval. The City reserves the right to reject all Respondents, to request clarification of information submitted or to request additional information from any Respondent, and to waive any irregularities in any submittal. END OF SECTION Respondent Ranking Order Rater #1 Rater #2 Rater #3 Rater #4 AVG RANK RESPONDENT A 4 2 1 3 2.50 RESPONDENT B 1 1 3 1 1.50 RESPONDENT C 2 3 2 2 2.25 RESPONDENT D 5 4 4 5 4.50 RESPONDENT E 3 5 3 4 3.75 130 of 162 138 EXHIBIT 4 CONTRACT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 THIS CONTRACT was made and entered into on this _________ day of _________________, 20____, by and between _________________________________________________ (hereafter referred to as “Contractor”), and the City of South Miami (hereafter referred to as “Owner”), through its City Manager (hereafter referred to as “City”). . Contractor, for the consideration set forth herein, hereby agrees with Owner as follows: 1. Contractor must furnish all labor, materials, equipment, machinery, tools, apparatus, transportation, and any other items necessary to perform all of the work shown on and described in the Contract Documents and must do everything required by this Contract and the other Contract Documents hereinafter referred to as the Work. 2. The Contract Documents must include this Contract, General Conditions to the Contract, if any, the drawings, plans, specifications and project manual, if any, any supplementary or special conditions, other documents referring to this contract and signed by the parties, the solicitation documents (“hereinafter referred to as “Bid Documents”) and any documents to which those documents refer which are used by Owner as well as any attachments or exhibits that are made a part of any of the documents described herein. 3. Contractor must commence the Work to be performed under this Contract on a date to be specified in a Notice to Proceed and must complete all Work hereunder within the length of time set forth in the Contract Documents. 4. Owner hereby agrees to pay to Contractor for the faithful performance of this Contract, subject to additions and deductions as provided in the Contract Documents and any properly approved, written change orders, in lawful money of the United States, the Lump Sum amount of: ______________________________________________________________Dollars ($_________________. __) (Spell Dollar Amount above) (“Contract Price”). 5. The expenses of performing Work after regular working hours, and on Sunday and legal holidays must be included in the Contract Price. The City may demand, at any point in time, that any part, or all, of the Work be performed after regular working hours. In such event, the Respondent will have no right to additional compensation for such work. However, nothing contained herein authorizes work on days and during hours that are otherwise prohibited by ordinance unless specifically authorized or instructed in writing by the City. 6. If the Work is expected to require more than one month, Owner will make monthly partial payments to Contractor on the basis of a duly certified and approved schedule of values for the Work performed during each calendar month by Contractor, less the retainage (all as provided for in the Contract Documents), which is to be withheld by Owner until completion and acceptance of the complete project in accordance with this Contract and the other Contract Documents and until such Work has been accepted by the City. 7. Upon submission by Contractor of evidence satisfactory to Owner that all labor, material, and other costs incurred by Contractor in connection with the construction of the Work have been paid in full, and after compliance with the terms for payment provided for in the Contract Documents, final payment on account of this Contract must be made within sixty (60) calendar days after the c ompletion by Contractor of all Work covered by this Contract and the acceptance of such Work by Owner. 8. The Work must be completed in 60 calendar days. In the event that Contractor fails to complete the Work within the time limit stipulated in the Contract Documents, or the extended time limit agreed upon, in accordance with the procedure as more particularly set forth in the Contract Documents, liquidated damages must be paid by Contractor at the rate of $1.500.00 dollars per day, 9. It is further mutually agreed between the parties hereto that if a Payment and/or Performance Bond (“Bond”) is required and if, at any time after the execution of this Contract and the Bond for its faithful performance and payment, the City deems the Surety or Sureties upon such bond(s) to be unsatisfactory, or if, for any reason such bond ceases to be adequate to cover the performance of the Work or payment to subcontractors and suppliers, Contractor must, at its expense within five (5) business days after the receipt of notice from the City so to do, furnish an additional bond or bonds in such form and amount and with such Surety or Sureties as are satisfactory to the City. In such event, no further payment to Contractor will be deemed to be due under this Contract until such ne w or additional security for the faithful performance of the Work is furnished in the manner and in the form satisfactory to the City. 131 of 162 139 10. No additional Work or extras may be done unless the same is duly authorized in writing, and in advance of the work, by appropriate action by the City and in accordance with the Contract Documents. 11. The date that this contract was “made and entered into” and its effective date is the date that the contract is the signed by the City or, if the contract is required to be approved by resolution of the City Commission, then the Effective Date is the date of the resolution approving the Contract whichever is the later date. 12. All provisions, conditions and restrictions contained in the bid document entitled Instructions to Respondents are made a part of this agreement by reference. Any conflict between that document and this contract or the exhibits to this contract are to be resolved by the City Manager in the managers sole and absolute discretion. IN WITNESS WHEREOF, the parties hereto have executed this Contract on the day and date set forth next to their name below and may be signed in one or more counterparts, each of which will, without proof or accounting for the other counterpart, be deemed an original Contract. CONTRACTOR: _______________________________ Signature: ________________________________ Print Signatory’s Name: ________________________________ Title of Signatory: ________________________________ ATTESTED: OWNER: CITY OF SOUTH MIAMI Signature: _______________________ Signature: ______________________ Nkenga A. Payne Shari Kamali City Clerk City Manager Read and Approved as to Form, Language, Legality, and Execution Thereof: Signature: ________________________ City Attorney 132 of 162 140 EXHIBIT 5 CONSTRUCTION CONTRACT GENERAL CONDITIONS DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 ARTICLE 1 – DEFINITIONS Whenever used in these General Conditions or in the other Contract Documents, the following terms have the meaning indicated. These definitions always apply when the section of the Contract specifically refers to this Article for the purpose of interpreting a word or group of words in that section of the Contract Documen t. However, when the section of the Contract, where the word to be defined is used, does not specifically refer to this Article to define the word or group of words, the definitions contained in this Article will not apply unless the word or group of words, in the context of it or their use in the Contract Document in question, is/are ambiguous and open for interpretation. In addition, these definitions do not apply to interpret terms in a specific provision of a Contract Document if that specific provision contains a definition of the term in question: Addenda: Written or graphic documents issued prior to the Bid Opening which modify or interpret the Contract Documents, Drawings and Specifications, by addition, deletions, clarifications, or correction. Application for Payment: A form approved by the City’s consultant (CONSULTANT), if any, or the City Manager which is to be used by CONTRACTOR in requesting progress payments. Bid: The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices and other terms for the Work to be performed. Bidder: Any person, firm or corporation submitting a response to OWNER’s solicitation for proposals or bids for Work. Bid Documents: The solicitation for bids or proposals and all documents that make up the solicitation including the instructions, form of documents and affidavits. Bonds: Bid bond, performance and payment bonds and other instruments of security, furnished by CONTRACTOR and its surety in accordance with the Contract Documents and in accordance with the laws of the State of Florida. Change Order: A written order to CONTRACTOR signed by the City Manager authorizing an addition, deletion or revision in the Work, or an adjustment in the Contract Price or the Contract Time i ssued after execution of the Contract. Work Order Proposals: Written proposals from CONTRACTOR in response to orders or request for work based on the Scope of the Work provided by OWNER to CONTRACTOR. The proposal includes line -item pricing, where there are multiple locations, and the timeframe for completing the work. City: The City Manager for the City of South Miami, 6130 Sunset Drive, South Miami, FL 33143, or manager’s designee, unless the context wherein the word is used should more appropriately me an the City of South Miami. City Manager: Includes the City Manager’s designee. Construction Observer: An authorized representative of CONSULTANT, if any, or otherwise a representative of OWNER assigned to observe the Work performed and materials furnish ed by CONTRACTOR. CONTRACTOR will be notified in writing of the identity of this representative. Contract Documents: The Contract Documents include the Contract between OWNER and CONTRACTOR, other documents listed in the Contract and modifications issued after execution of the Contract as well as all Bid Documents including but not limited to the solicitation for Bid, CONTRACTOR’S Bid, the Bonds, Insurance endorsements, Insurance Certificates and policies, the Notice of Award, the Notice to Proceed, the General Conditions, Special Conditions, if any, any Supplementary Conditions, the Technical Specifications, Drawings, including any incorporated specifications, addenda to the drawings issued prior to execution of the Contract, Change Orders, Construction Change Directives and any written order for a minor change in the Work, and written modifications to any of the Contract Documents. Contract Price: The total moneys payable to CONTRACTOR pursuant to the terms of the Contract Documents. Contract Time: The number of calendar days stated in the Contract for the completion of the Work. Contracting Officer: The individual who is authorized to sign the contract documents on behalf of OWNER. CONTRACTOR: The person, firm, or corporation with whom OWNER has executed the Contract. CONSULTANT: The person identified as CONSULTANT in the Supplementary Conditions or, if none, then OWNER’s designated representative as identified in the Supplementary Conditions. Day: A period of twenty-four hours measured from the beginning of the day at 12:01 a.m. and it will be presumed to be a calendar day unless specifically designated as a business day. Days: The number of twenty-four (24) hour periods following the event to which the word “days” refers commencing at 12:01 a.m. at the start of the next day. Therefore, in computing any period of time prescribed or 133 of 162 141 allowed by the Contract Documents, the day of the act, event, or default from which the designated period of time begins to run will not be included. The last day of the period so computed will be included unless it is a Saturday, Sunday, or legal holiday, in which event the period will run until the end of the next business day that is not a Saturday, Sunday or legal holiday. Defective Work: Work that is unsatisfactory, faulty, or deficient in that it does not conform to the Contract Documents, or does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents, or has been damaged prior to CONSULTANT’S recommendation of final payment (unless responsibility for the protection thereof has been delegated to OWNER); substitutions that are not properly approved and authorized, any deficiency in the Work, materials and equipment; materials and equipment furnished under the Contract that are not good quality and new unless otherwise required or permitted by the Contract Documents. Drawings: The drawings which show the character and Scope of the Work to be performed and which have been prepared or approved by CONSULTANT, or if none, then by an architect or engineer hired by City Manager and are referred to in the Contract Documents. Field Order: A written order issued by CONSULTANT which clarifies or interprets the Contract Documents in accordance with Paragraph 9.3 or orders minor changes in the Work in accordance with paragraph 10.2. Modification: (a) A written amendment of the Contract Documents signed by both parties, (b) a Chang e Order signed by both parties, (c) a written clarification or interpretation if issued by CONSULTANT in accordance with paragraph 9.3 or (d) a written order for minor change or alteration in the Work issued by CONSULTANT pursuant to Paragraph 10.2. A modification may only be issued after execution of the Contract, it must be in writing and signed by the party against whom the modification is sought to be enforced. Non-conforming Work means work that does not conform to the Contract Documents and includes work that is unsatisfactory, faulty, or deficient or that does not meet the requirements of any applicable inspection, reference standard, test, or that does not meet any approval required by, or referred to in, the Contract Documents, or work that has been damaged prior to CONSULTANT’s recommendation of final payment (unless responsibility for the protection thereof has been assumed in writing by OWNER). Notice of Award: The written notice by City Manager to the apparent successful Bidder stating that upon compliance with the conditions precedent to be fulfilled by it within the time specified, City Manager will execute and deliver the Contract to him. Notice to Proceed: A written notice given by City Manager to CONTRACTOR (with copy to CONSULTANT) fixing the date on which the Contract Time will commence to run and on which CONTRACTOR must start to perform its obligations under the Contract Documents. Owner. The City of South Miami. Person: An individual or legal entity. Project: The entire construction operation being performed as delineated in the Contract Documents. Policy: The term “policy” as used in the Contract Documents means the insurance binder, if it is issued, the declaration page of the policy and the body of the policy, including all endors ements. RFQ: Request for Qualifications. Scope of Services. This phrase refers to the scope of the services or work to be performed and it has the same meaning as Scope of the Work unless the context in which the phase is used clearly means otherwise. Shop Drawings: All drawings, diagrams, illustrations, brochures, schedules, and other data which are prepared by CONTRACTOR, a Subcontractor, manufacturer, supplier, or distributor, and which illustrate the equipment, material or some portion of the work and as required by the Contract Documents. Samples: Physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. Specifications: Those portions of the Contract Documents consisting of written technical descriptions of materials, equipment, construction systems, standards and workmanship as applied to the Work. Subcontractor: An individual, firm or corporation having a direct contract with CONTRACTOR or with any other Subcontractor for the performance of a part of the Work at the construction site. Substantial Completion: The date, as certified by CONSULTANT, when the construction of the Project or a certified part thereof is sufficiently completed, in accordance with the Contract Documents, so that the Project, or a substantial part, can be utilized for the purposes for which it was intended without restriction or limitation to any degree, other than for the repair of minor “punch list” items; or if there be no such certification, the date when final payment is due in accordance with paragraph 14.9. However, in no event will the project or portion thereof, be deemed to be substantially completed until a certificate of occupancy or certificate of use is lawfully issued by the applicable governmental agency. A certificate of Substantial Completion, issued by CONSULTANT, will be null and void if it is based on false, misleading, or inaccurate information, from any source, or when it would not have been issue but for the consideration of Work that is thereafter found to be defective to a degree greater than that which would normally to be considered by City Manager to be minor “punch list” work. 134 of 162 142 Supplier: Any person or organization who supplies materials or equipment for the Work, including the fabrication of an item, but who does not perform labor at the site of the Work. Surety: The individual or entity who is an obligor on a Bond and who is bound with CONTRACTOR for the full and faithful performance of the Contract and for the payme nt of all labor, services and materials used on the project. Work: Any and all obligations, duties, and responsibilities necessary for the successful performance and completion of the Contract. Notice: The term “Notice” as used herein means and includes all written notices, demands, instructions, claims, approvals, and disapprovals required to obtain compliance with Contract requirements. Written notice will be deemed to have been duly served if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or to an authorized representative of such individual, firm, or corporation, or if delivered at or sent by registered mail to the last known business address. Unless otherwise stated in writing, any notice to or demand upon OWNER under this Contract must be delivered to City Manager and CONSULTANT. ARTICLE 2 – PRELIMINARY MATTERS Award: 2.1 The City Manager reserves the right to reject any and all Bids, at its sole discretion. Bids will be awarded by OWNER to the lowest responsive and responsible Bidder. No Notice of Award will be given until the City Manager has concluded its investigation, as it deems necessary, to establish, to the satisfaction of the City Manager, which Bidder is the most responsive and responsible of all the Bidders to complete the Work within the time prescribed and in accordance with the Contract Documents. The City Manager reserves the right to reject the Bid of any Bidder who is not believed to be, in the sole discretion and satisfaction of City Manager, to be sufficiently responsible, qualified, and financial able to perform the work. In analyzing a Bid, the City Manager may also take into consideration alternate and unit prices, if requested by the Bid forms. If the Contract is awarded, the City Manager will issue the Notice of Award and give the successful Bidder a Contract for execution within ninety (90) day after opening of Bids. Execution of Contract: 2.2 At least four counterparts of the Contract, the Performance and Payment Bond, the Certificates of Insurance, the Binder of Insurance if issued, the Insurance Declaration Page if not included in the Policy of Insurance, the Policy of Insurance required by the Contract Documents, the written notice of designated supervisor or superintendent as provided in Section 6.1 of the General Conditions and such other Documents as required by the Contract Documents must be executed and delivered by CONTRACTOR to the City Manager within ten (10) calendar days of receipt of the Notice of Award. A Contract Document that requires the signature of a party may be executed in counterparts separately by each of the parties and, in such event, each counterpart separately executed will, with out proof or accounting for the other counterpart be deemed an original Contract Document. Forfeiture of Bid Security/Performance and Payment Bond if any are required by the applicable RFQ: 2.3 Within ten (10) calendar days of being notified of the Award, CONTRACTOR must furnish a Performance Bond and a Payment Bond containing all the provisions of the Performance Bond and Payment Bond attached. 2.3.1 Each Bond must be in the amount of one hundred percent (100%) of the Contract Price guaranteeing to OWNER the completion and performance of the Work covered in such Contract as well as full payment of all suppliers, material man, laborers, or Subcontractor employed pursuant to this Project. Each Bond must be with a Surety company whose qualifications meet the requirements of Sections 2.3.4, 2.3.5, and 2.3.6. 2.3.2 Each Bond must continue in effect for five years after final completion and acceptance of the Work with the liability equal to one hundred percent (100%) of the Contract Sum. 2.3.3 Pursuant to the requirements of Section 255.05(1), Florida Statutes, CONTRACTOR must ensure that the Bond(s) referenced above are recorded in the public records of Miami-Dade County and provide City Manager with evidence of such recording. 2.3.4 Each Bond must be executed by a surety company authorized to do business in the State of Florida as a surety, having a resident agent in the State of Florida and having been in business with a record of successful continuous operation for a least five (5) years. 135 of 162 143 2.3.5 The surety company must hold a current certificate of authority as acceptable surety on federal bonds in accordance with the United States Department of Treasury Circular 570, current revisions. 2.3.6 OWNER will only be required to accept a surety bond from a company w ith a rating A. VII or better. 2.3.7 Failure of the successful Bidder to execute and deliver the Contract and deliver the required bonds and Insurance documents will be cause for the City Manager to annul the Notice of Award and declare the Bid and any security therefore forfeited. Contractor’s Pre-Start Representation: 2.4 CONTRACTOR represents that it has familiarized itself with and assumes full responsibility for having familiarized itself with the nature and extent of the Contract Documents, Work, loc ality, and with all local conditions and federal, state, and local laws, ordinance, rules, and regulations that may in any manner affect performance of the Work and represents that it has correlated its study and observations with the requirements of the Contract Documents. CONTRACTOR also represents that it has studied all surveys and investigations, reports of subsurface and latent physical conditions referred to in the specifications and made such additional surveys and investigations as it deems necessary for the performance of the Work reflected in the Contract Documents and that he has correlated the results of all such data with the requirements of the Contract Documents. Commencement of Contract Time: 2.5 The Contract Time will commence to run on the date stated in the Notice to Proceed. Starting the Project: 2.6 CONTRACTOR must start to perform its obligations under the Contract Documents on the date the Contract Time commences to run. No Work may be done at the site (as defined in Article 1), prior to the date on which the Contract Time commences to run, except with the written consent of the City Manager. Before Starting Construction: 2.7 Before undertaking each part of the Work, CONTRACTOR must carefully study and compare the Contract Documents and check and verify pertinent figures shown thereon and all applicable field measurements and conditions. It must at once report in writing to CONSULTANT any conflict, error, or discrepancy which it may discover. Neither OWNER nor CONSULTANT will be liable for any harm, damage or loss suffered by CONTRACTOR as a result of its failure to discover any conflict, error, or discrepancy in the Drawings or Specifications nor will CONTRACTOR be entitled to any compensation for any harm, damage or loss suffered by CONTRACTOR due to any conflict, error, or discrepancy in the Contract Documents. Schedule of Completion: 2.8 Within Five (5) business days after delivery of the Notice to Proceed by City Manager to CONTRACTOR, CONTRACTOR must submit to CONSULTANT for approval, an estimated construction schedule indicating the starting and completion dates of the various stages of the Work, and a preliminary schedule of Shop Drawing submissions. CONSULTANT will approve this schedule or require revisions thereto within seven (7) calendar days of its submittal. If there is more than one CONTRACTOR involved in the Project, the responsibility for coordinating the Work of all CONTRACTORS will be provided in the Special Conditions. 2.9 Within five (5) business days after delivery of the executed Contract by City Manager to CONTRACTOR, but before starting the Work at the site, a pre-construction conference will be held to review the above schedules, to establish procedures for handling Shop Drawings and other submissions, and for processing Applications for Payment, and to establish a working understanding between the parties as to the Project. Present at the conference will be OWNER’S representative, CONSULTANT, Resident Project Representatives, CONTRACTOR, and its Superintendent. Qualifications of Subcontractors, Material men and Suppliers: 2.10 Within five (5) business days after bid opening, the apparent lowest respons ive and responsible Bidder must submit to the City Manager and CONSULTANT for acceptance a list of the names of Subcontractors and such other persons and organizations (including those who are to furnish principal items of materials or equipment) proposed for those portions of the Work as to which the identity of 136 of 162 144 Subcontractors and other persons and organizations must be submitted as specified in the Contract Documents. Within thirty (30) calendar days after receiving the list, CONSULTANT will notify CONTRACTOR in writing if either the City Manager or CONSULTANT has reasonable objection to any Subcontractor, person, or organization on such list. The failure of the City Manager or CONSULTANT to make objection to any Subcontractor, person, or organization on the list within thirty (30) calendar days of the receipt will constitute an acceptance of such Subcontractor, person, or organization. Acceptance of any such Subcontractor, person or organization will not constitute a waiver of any right of OWNER or CONSULTANT to reject defective Work, material or equipment, or any Work, material, or equipment not in conformance with the requirements of the Contract Documents. 2.11 If, prior to the Notice of Award, the City Manager or CONSULTANT has reasonable objection t o any Subcontractor, person or organization listed, the apparent low Bidder may, prior to Notice of Award, submit an acceptable substitute without an increase in its bid price. 2.12 The apparent silence of the Contract Documents as to any detail, or the a pparent omission from them of a detailed description concerning any Work to be done and materials to be furnished, will be regarded as meaning that only best practices are to prevail and only materials and workmanship of the best quality are to be used in the performance of the Work. ARTICLE 3–CORRELATION, INTERPRETATION, AND INTENT OF CONTRACT DOCUMENTS 3.1 It is the intent of the Specifications and Drawings to describe a complete Project to be constructed in accordance with the Contract Documents. The Contract Documents comprise the entire Contract between OWNER and CONTRACTOR. They may be altered only by a modification as defined in Article 1. 3.2 The Contract Documents are complementary; what is called for by one is as binding as if called for by all the documents. If CONTRACTOR finds a conflict, error, or discrepancy in the Contract Documents, it must, before proceeding with the Work affected thereby, immediately call it to CONSULTANT’s attention in writing. The various Contract Documents are compleme ntary; in case of conflict, error or discrepancy, the more stringent interpretation and requirement that will provide the maximum benefit to OWNER will apply 3.3 The words “furnish” and “furnish and install”, “install”, and “provide” or words with similar meaning will be interpreted, unless otherwise specifically stated, to mean “furnish and install complete in place and ready for service”. 3.4 Miscellaneous items and accessories which are not specifically mentioned, but which are essential to produce a complete and properly operating installation, or usable structure, providing the indicated functions, must be furnished, and installed without change in the Contract Price. Such miscellaneous items and accessories must be of the same quality standards, including material, style, finish, strength, class, weight, and other applicable characteristics, as specified for the major component of which the miscellaneous item or accessory is an essential part, and will be approved by CONSULTANT before installation. The above requirement is not intended to include major components not covered by or inferable from the Drawings and Specifications. 3.5 The Work of all trades under this Contract must be coordinated by CONTRACTOR in such a manner as obtain the best workmanship possible for the entire Project, and all components of the Work must be installed or erected in accordance with the best practices of the particular trade. 3.6 CONTRACTOR will be responsible for making the construction of habitable structures under this Contract rain proof, and for making equipment and utility installations properly perform the specified function. If CONTRACTOR is prevented from complying with this provision due to the Drawings or Specifications, CONTRACTOR must immediately notify CONSULTANT in writing of such limitations before proceeding with construction in the area where the problem exists. 3.7 Manufacturer’s literature, when referenced, must be dated, and numbered and is intended to establish the minimum requirements acceptable. Whenever reference is given to codes, or standard specifications or other data published by regulating agencies or accepted organizations, including but not limited to National Electrical Code, applicable State Building Code, Florida Building Code, Federal Specifications, ASTM Specifications, various institute specifications, and the like, it will be understood that such reference is to the latest edition including addenda in effect on the date of the Bid. 3.8 Brand names, where used in the technical specifications, are intended to denote the standard or quality required for the particular material or product. The term "equal" or "equivalent", when used in connection with brand names, will be interpreted to mean a material or product that is similar and equal in type, quality, size, capacity, composition, finish, color and other applicable characteristics to the material or product specified by trade name, and that is suitable for the same use capable of performing the same function, in the opinion of CONSULTANT, as the material or product so specified. Proposed equivalent 137 of 162 145 items must be approved by CONSULTANT before they are purchased or incorporated in the Work. (When a brand name, catalog number, model number, or other identification, is used without the phr ase "or equal", CONTRACTOR must use the brand, make and model specified). 3.9 Throughout this agreement the male pronoun may be substituted for female and neuter and vice versa and the singular words substituted for plural and plural words substituted for singular wherever applicable. 3.10 All technical interpretations will be made by CONSULTANT as set forth in Section 9.3 below. 3.11 CONTRACTOR must advise CONSULTANT, prior to performing any work involving a conflict in the Contract Documents and CONSULTANT will make the final decision as to which of the documents will take precedence. If there is a conflict between or among the Contract Documents, only the latest version will apply and the latest version of the Contract Documents. CONSULTANT must use the following list of Contract Documents as a guide. These documents are set forth below in the order of their precedence so that all the documents listed above a given document should have precedence over all the documents listed below it. (a) Change Orders (b) Amendments/addenda to Contract (c) Supplementary Conditions, if any (d) Contract with all Exhibits thereto (e) General Conditions (f) Written or figured dimensions (g) Scaled dimensions (h) Drawings of a larger scale (i) Drawings of a smaller scale (j) Drawings and Specifications are to be considered complementary to each other ARTICLE 4 – AVAILABILITY OF LANDS SUBSURFACE CONDITIONS REFERENCE POINTS Availability of Lands: 4.1 OWNER will furnish, as indicated in the Contract Documents, the lands upon which the Work is to be done, rights-of-way for access thereto, and such other lands which are designed for the use of CONTRACTOR. Easements for permanent structures or permanent changes in existing facilities will be obtained and paid for by OWNER, unless otherwise specified in the Contract Documents. Other access to such lands or rights-of-way for CONTRACTOR'S convenience will be the responsibility of CONTRACTOR. CONTRACTOR must provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of material and equipment. 4.2 The City Manager will, upon request, furnish to the Bidders, copies of all available boundary surveys and subsurface tests at no cost. Subsurface Conditions: 4.3 CONTRACTOR acknowledges that he has investigated prior to bidding and satisfied himself as to the conditions affecting the Work, including but not limited to those bearing upon transportation, disposal, handling and storage of materials, availability of labor, water, electric power, roads and uncertainties of weather, river stages, tides, water tables or similar physical conditions at the site, the conformation and conditions of the ground, the character of equipment and facilities needed preliminary to and during prosecution of the Work. CONTRACTOR further acknowledges that he has satisfied himself as to the character, quality and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by OWNER/ CONSULTANT on the site or any contiguous site, as well as from information presented by the Drawings and Specifications made part of this Contract, or any other information made available to it prior to receipt of bids. Any failure by CONTRACTOR to acquaint itself with the available information will not relieve it from responsibility for estimating properly the difficulty or cost of successfully performing Work. OWNER assumes no responsibility for any conclusions or interpretations made by CONTRACTOR on the basis of the information made available by OWNER/ CONSULTANT. Differing Site Conditions: 4.4 CONTRACTOR must within forty-eight (48) hours of its discovery, and before such conditions are disturbed, notify the City Manager in writing, of: 4.4.1 Subsurface or latent physical conditions at the site differing materially from those indicated in the Contract Documents, and 138 of 162 146 4.4.2 Unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally inherent in Work of the character provided for in this Contract. The City Manager will promptly investigate the conditions, and if it finds that such conditions do materially differ to the extent as to cause an increase or decrease in CONTRACTOR'S cost of, or the time required for, performance of any part of the Work under this Contract, an equitable adjustment will be made and the Contract modified in writing accordingly. 4.5 No claim of CONTRACTOR under this clause will be allowed unless CONTRACTOR has given the notice required in 4.4 above; provided, however, the time prescribed therefore may be extended by the City Manager, but only if done in writing signed by the City Manager or CONSULTANT. ARTICLE 5 – INSURANCE Contractor must comply with the insurance requirements set forth in the Supplementary Conditions to the Contract. ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES Supervision and Superintendence: 6.1 CONTRACTOR must supervise and direct the Work. It will be solely responsible for the means, methods, techniques, sequences, and procedures of construction. CONTRACTOR must employ and maintain a qualified supervisor or superintendent (hereinafter referred to as “Supe rvisor” at the Work site who must be designated in writing by CONTRACTOR, before CONTRACTOR commences the Work and within the time required by the Contract, as CONTRACTOR'S representative at the site. The Supervisor or the person designated will have full authority to act on behalf of CONTRACTOR and all communications given to the Supervisor will be as binding as if given to CONTRACTOR. The Supervisor(s) will always be present at each site as required to perform adequate supervision and coordination of the Work. (Copies of written communications given to the Supervisor will be mailed to CONTRACTOR'S home office). 6.1.1 CONTRACTOR must keep one record copy of all Specifications, Drawings, Addenda, Modifications and Shop Drawings at the site at all times and in good order and annotated to show all changes made during the construction process. These must be available to CONSULTANT and any OWNER Representative at all reasonable times. A set of “As-Built” drawings, as well as the original Specifications, Drawings, Addenda, Modifications and Shop Drawings with annotations, will be made available to City Manager at all times and it must be delivered to the City Manager upon completion of the Project. Labor, Materials and Equipment: 6.2 CONTRACTOR must provide competent, suitably qualified personnel to lay out the Work and perform construction as required by the Contract Documents. It must always maintain good discipline and order at the site. 6.3 CONTRACTOR must furnish all materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, local telephone, water and sanitary facilities and all other facilities and incidentals necessary for the execution, testing, initial operation, and completion of the Work. 6.4 All materials and equipment must be new, except as otherwise provided in the Contract Documents. When special makes or grades of material which are normally packaged by the supplier or manufacturer are specified or approved, such materials must be delivered to the site in their original packages or containers with seals unbroken and labels intact. 6.5 All materials and equipment must be applied, installed, connected, erected, used, cleaned, and conditioned in accordance with the instructions of the applicable manufacturer, fabricator, or processors, except as otherwise provided in the Contract Documents. Work, Materials, Equipment, Products and Substitutions: 6.6 Materials, equipment and products incorporated in the Work must be approved for use before being purchased by CONTRACTOR. CONTRACTOR must submit to CONSULTANT a list of proposed materials, equipment, or products, together with such samples as may be necessary for them to determine their acceptability and obtain their approval, within ninety (90) calendar days after award of Contract unless otherwise stipulated in the Special Conditions. No request for payment for "or equal" equipment will be approved until this list has been received and approved by CONSULTANT. 6.6.1 Whenever a material, article or piece of equipment is identified on the Drawings or Specifications by reference to brand name or catalog number, it is understood that this is referenced for the 139 of 162 147 purpose of defining the performance or other salient requirements and that other products of equal capacities, quality and function must be considered. CONTRACTOR may recommend the substitution of a material, article, or piece of equipment of equal substance and function for those referred to in the Contract Documents by reference to brand name or catalog number, and if, in the opinion of CONSULTANT, such material, article, or piece of equipment is of equal substance and function to that specified, CONSULTANT may approve its substitution and use by CONTRACTOR. Incidental changes or extra component parts required to accommodate the substitute will be made by CONTRACTOR without a change in the Contract Price or the Contract Time. 6.6.2 No substitute may be ordered or installed without the written approval of CONSULTANT who will be the judge of quality. 6.6.3 Delay caused by obtaining approvals for substitute materials will not be considered justifiable grounds for an extension of construction time. 6.6.4 Should any Work or materials, equipment or products not conform to requirements of th e Drawings and Specifications or become damaged during the progress of the Work, such Work or materials must be removed and replaced, together with any Work disarranged by such alterations, at any time before completion and acceptance of the Project. All such Work must be done at the expense of CONTRACTOR. 6.6.5 No materials or supplies for the Work may be purchased by CONTRACTOR or any Subcontractor that are subject to any chattel mortgage or under a conditional sale or other agreement by which an interest is retained by the Seller. CONTRACTOR warrants that they have good title to all materials and supplies used by them in the Work. 6.6.6 Non-conforming Work: The City of South Miami may withhold acceptance of, or reject items which are found upon examination, not to meet the specification requirements or conform to the plans and drawings. Upon written notification of rejection, items must be removed or uninstalled within five (5) business days by CONTRACTOR at his own expense and redelivered and/or reinstalled at his expense. Rejected goods left longer than thirty (30) calendar days will be regarded as abandoned and OWNER will have the right to dispose of them as its own property and CONTRACTOR thereby waives any claim to the good or to compensation of any kind for said goods. Rejection for non-conformance or failure to meet delivery schedules may result in CONTRACTOR being found in default. 6.6.7 In case of default by CONTRACTOR, the City of South Miami may procure the articles or services from other sources and hold CONTRACTOR responsible for any excess costs occasioned or incurred thereby. 6.6.8 OWNER reserves the right, in the event CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested, to obtain the good and/or services from other sources and deducting the cost from the Contract Price without violating the intent of the Contract. Concerning Subcontractors: 6.7 CONTRACTOR may not employ any Subcontractor, against whom the City Manager or CONSULTANT may have reasonable objection, nor will CONTRACTOR be required to employ any Subcontractor who has been accepted by the City Manager and CONSULTANT, unless CONSULTANT det ermines that there is good cause for doing so. 6.8 CONTRACTOR is fully responsible for all acts and omissions of its Subcontractors and of persons and organizations directly or indirectly employed by it and of persons and organizations for whose acts any of them may be liable to the same extent that they are responsible for the acts and omissions of persons directly employed by them. Nothing in the Contract Documents create any contractual relationship between OWNER or CONSULTANT and any Subcontractor or o ther person or organization having a direct contract with CONTRACTOR, nor may it create any obligation on the part of OWNER or CONSULTANT to pay or to see to payment of any subcontractor or other person or organization, except as may otherwise be required by law. City Manager or CONSULTANT may furnish to any Subcontractor or other person or organization, to the extent practicable, evidence of amounts paid to CONTRACTOR on account of specified Work done in accordance with the schedule values. 6.9 The divisions and sections of the Specifications and the identifications of any Drawings does not control CONTRACTOR in dividing the Work among Subcontractors or delineating the Work performed by any specific trade. 6.10 CONTRACTOR agrees to bind specifically every Subcontractor to the applicable terms and conditions of the Contract Documents for the benefit of OWNER. 140 of 162 148 6.11 All Work performed for CONTRACTOR by a Subcontractor must be pursuant to an appropriate agreement between CONTRACTOR and the Subcontractor. 6.12 CONTRACTOR is responsible for the coordination of the trades, subcontractors, material, and men engaged upon their Work. 6.12.1 CONTRACTOR must insert in all subcontracts relative to the Work appropriate provisions to bind Subcontractors to CONTRACTOR by the terms of these General Conditions and other Contract Documents insofar as applicable to the Work of Subcontractors and give CONTRACTOR the same power as regards to terminating any subcontract that City Manager may exercise over CONTRACTOR under any provisions of the Contract Documents. 6.12.2 The City Manager or CONSULTANT will not undertake to settle any differences between CONTRACTOR and their Subcontractors or between Subcontractors. 6.12.3 If in the opinion of CONSULTANT, any Subcontractor on the Proj ect proves to be incompetent or otherwise unsatisfactory, they must be promptly replaced by CONTRACTOR when directed by CONSULTANT in writing. 6.12A Discrimination: No action may be taken by the any subcontractor with regard to the fulfilment of the terms of the subcontract, including the hiring and retention of employees for the performance of Work that would discriminate against any person on the basis of race, color, creed, religion, national origin, sex, age, sexual orientation, familial status, or disability. This paragraph must be made a part of the subcontractor’s contract with CONTRACTOR. Patent Fees and Royalties: 6.13 CONTRACTOR must pay all license fees and royalties and assume all costs incident to the use of any invention, design, process, or device which is the subject of patent rights or copyrights held by others. CONTRACTOR must indemnify and hold harmless OWNER and CONSULTANT and anyone directly or indirectly employed by either of them from against all claims, damages, losses, and expenses (including attorney's fees) arising out of any infringement of such rights during or after the completion of the Work and must defend all such claims in connection with any alleged infringement of such rights. 6.14 CONTRACTOR is responsible for determining the application of patent and/or royalty rights as to any materials, appliances, articles, or systems prior to bidding. However, he is not responsible for such determination on systems which do not involve purchase by them of materials, appliances, and articles. Permits: 6.15 CONTRACTOR must secure and pay for all construction permits and licenses and must pay for all governmental charges and inspection fees necessary for the prosecution of the Work, which are applicable at the time of his Bid. When such charges are normally made by OWNER and when so stated in the Special Conditions, there will be no charges to CONTRACTOR. The City Manager will assist CONTRACTOR, when necessary, in obtaining such permits and licenses. CONTRACTOR must also pay all public utility charges. Electrical Power and Lighting: 6.16 Electrical power required during construction must be provided by each prime CONTRACTOR as required by it. This service must be installed by a qualified electrical Contractor approved by CONSULTANT. Lighting must be provided by CONTRACTOR in all spaces at all times where necessary for good and proper workmanship, for inspection or for safety. No temporary power may be used off temporary lighting lines without specific approval of CONTRACTOR. Laws and Regulations: 6.17 CONTRACTOR must comply with all notices, laws, ordinances, rules, and regulations applicable to the Work. If CONTRACTOR observes that the Specifications or Drawings are at variance therewith, it must give CONSULTANT prompt written notice thereof, and any necessary changes must be adjusted by an appropriate modification. If CONTRACTOR performs any Work knowing it to be contrary to such laws, ordinances, rules, and regulations, and without such notice to CONSULTANT, it must bear all costs arising there from; however, it will not be its primary responsibility to make certain that the Drawings and Specifications are in accordance with such laws, ordinances, rules, and regulations. Discrimination: 6.17A No action may be taken by CONTRACTOR with regard to the fulfilment of the terms of the Contra ct, including the hiring and retention of employees for the performance of Work that would discriminate against any person on the basis of race, color, creed, religion, national origin, sex, age, sexual orientation, familial status, or disability. 141 of 162 149 Taxes: 6.18 Cost of all applicable sales, consumer use, and other taxes for which CONTRACTOR is liable under the Contract must be included in the Contract Price stated by CONTRACTOR. Safety and Protection: 6.19 CONTRACTOR is responsible for initiating, maintaining, and supervising all safety precautions and programs in connection with the Work. They must take all necessary precautions for the safety of, and must provide the necessary protection to prevent damage, injury, or loss to: 6.19.1 All employees and other persons, who may be affected thereby, 6.19.2 All the Work and all materials or equipment to be incorporated therein, whether in storage on or off the site, and 6.19.3 Other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, and utilities not designated for removal, relocation, or replacement in the course of construction. 6.20 CONTRACTOR must designate a responsible member of their organization at the site whose duty must be the prevention of accidents. This person must be CONTRACTOR'S Superintendent unless otherwise designated in writing by CONTRACTOR to the City Manager. Emergencies: 6.21 In emergencies affecting the safety of persons or the Work or property at the site or adjacent thereto, CONTRACTOR, without special instruction or authorization from CONSULTANT or City Manager, is obligated to act, at his discretion, to prevent threatened damage, injury, or loss. He must give CONSULTANT prompt written notice of any significant changes in t he Work or deviations from the Contract Documents caused thereby. If CONTRACTOR believes that additional Work done by him in an emergency which arose from causes beyond his control entitles him to an increase in the Contract Price or an extension of the Contract Time, he may make a claim therefore as provided in Articles 11 and 12. The City Manager reserves the right, in the City Manager’s sole and absolute discretion and when in the best interest of the City, to suspend the work or services or cancel thi s contract in the event of an emergency that effects the City of South Miami, its residents or businesses and that has been declared an emergency by the Governor, Mayor of Miami-Dade County or by the City Manager pursuant to the City Manager’s Emergency Management powers set forth in Ch. 14 of the City’s Code of Ordinances. In such event, the CONTRACTOR is only be entitled to be paid for the reasonable value of the work performed and any costs advanced that cannot be mitigated by CONTRACTOR. Shop Drawings and Samples: 6.22 After checking and verifying all field measurements, CONTRACTOR must submit to CONSULTANT for review, in accordance with the accepted schedule of shop drawing submissions, six (6) copies (or at CONSULTANT option, one reproducible copy) of all Shop Drawings, which must have been checked by and stamped with the approval of CONTRACTOR. The Shop Drawings must be numbered and identified as CONSULTANT may require. The data shown on the Shop Drawings must be complete with respect to dimensions, design criteria, materials of construction and the like to enable CONSULTANT to review the information without any unnecessary investigation. 6.23 CONTRACTOR must also submit to CONSULTANT for review, with such promptness as to cause no delay in Work, all samples required by the Contract Documents. All samples must have been checked by and stamped with the approval of CONTRACTOR, identified clearly as to material, manufacturer, any pertinent catalog numbers, and the use for which inte nded. 6.24 At the time of each submission, CONTRACTOR must notify CONSULTANT, in writing, of any deviations between the Shop Drawings or samples and the requirements of the Contract Documents. 6.25 CONSULTANT must review with responsible promptness Shop Drawings and Samples, but his review is only for conformance with the design concept of the Project and for compliance with the information given in the Contract Documents. The review of a separate item as such will not indicate review of the assembly in which the items functions. CONTRACTOR must make any corrections required by CONSULTANT and must return the required number of corrected copies of Shop Drawings and resubmit new samples until the review is satisfactory to CONSULTANT. CONTRACTOR must notify CONSULTANT, in writing, of any prior Shop Drawing or revisions to Shop Drawings that are in conflict with each submission or re-submission. CONTRACTOR'S stamp of approval on any Shop Drawings or sample will constitute representation to OWNER and CONSULTANT that CONTRACTOR has either determined and/or verified all quantities, dimension, field construction criteria, materials, catalog numbers 142 of 162 150 and similar data or they assume full responsibility for doing so, and that they have reviewed or coordinated each Shop Drawing or sample with the requirements of the Work and the Contract Documents. 6.26 No Work requiring a submittal of a Shop Drawing or sample may be commenced until the submission has been reviewed and approved in writing by CONSULTANT. A copy of each Shop Drawing and each approved sample must be kept in good order, in a book or binder, in chronological order or in such other order required by CONSULTANT in writing, by CONTRACTOR at the site and must be available to CONSULTANT. 6.27 CONSULTANT’s review of Shop Drawings or samples will not relieve CONTRACTOR from his responsibility for any deviations from the requirements of the Contract Documents unless CONTRACTOR has informed CONSULTANT, in writing, to each deviation at the time of submission and CONSULTANT has given written approval to the specific deviation, nor may any review by CONSULTANT relieve CONTRACTOR from responsibility for errors or omissions in the Shop Drawings or samples. 6.27A CONTRACTOR is liable to OWNER for any additional cost or delay that is caused by its failure to notify CONSULTANT of any of said deviations or conflicts between Shop Drawings or due to errors in the Shop Drawings or samples. Cleaning Up: 6.28 CONTRACTOR must clean up behind the Work as much as is reasonably possible as the Work progresses. Upon completion of the Work, and before acceptance of final payment for the Project by OWNER, CONTRACTOR must remove all his surplus and discarded materials, excavated material and rubbish as well as all other material and equipment that does not form a part of the Work, from the property, roadways, sidewalks, parking areas, lawn, and all adjacent property. In addition, CONTRACTOR must clean his portion of Work involved in any building under this Contract, so that no further cleaning by OWNER is necessary prior to its occupancy and he must restore all property, both public and private, which has been disturbed or damaged during the prosecution of the Work so as to leave the whole Work and Work Site in a neat and presentable condition. 6.29 If CONTRACTOR does not clean the Work site, OWNER may clean the Work Site of the materials referred to in paragraph 6.28 and charge the cost to CONTRACTOR. Public Convenience and Safety: 6.30 CONTRACTOR must, at all times, conduct the Work in such a manner as to ensure the least practicable obstruction to public travel. The convenience of the general public and of the residents along and adjacent to the area of Work must be provided for in a satisfactory manner, consistent with the operation and local conditions. "Street Closed" signs must be placed immediately adjacent to the Work, in a conspicuous position, at such locations as traffic demands. At any time that streets are required to be closed, CONTRACTOR must notify law enforcement agencies and in particular, the City of South Miami Police Department before the street is closed and again as soon as it is opened. Access to fire hydrants and other fire extinguishing equipment must be provided and maintained at all times. Sanitary Provisions: 6.31 CONTRACTOR must provide on-site office, and necessary toilet facilities, secluded from public observation, for use of all personnel on the Work Site, whether or not in his employ. They must be kept in a clean and sanitary condition and must comply with the requirements and regulations of the Public Authorities having jurisdiction. They may not commit a public nuisance. Temporary field office and sanitary facilities must be removed upon completion of the Work and the premises must be left clean. Indemnification: 6.32 Contractor must comply with the indemnification requirements set forth in the RFQ and in EXHIBIT 2 of the Supplementary Conditions (Insurance and indemnification requirements). 6.33 In the event that any action or proceeding is brought against OWNER or CONSULTANT by reason of any such claim or demand, CONTRACTOR, upon written notice from the City Manager, must defend such action or proceeding by counsel satisfactory to the City Man ager. The indemnification provided above obligates CONTRACTOR to defend at its own expense or to provide for such defense, at OWNER’S option, any and all claims of liability and all suits and actions of every name and description that may be brought against OWNER or CONSULTANT, excluding only those claims that allege that the injuries arose out of the sole negligence of OWNER or CONSULTANT. 143 of 162 151 6.34 The obligations of CONTRACTOR under paragraph 6.33 will not extend to the liability of CONSULTANT, its agents or employees arising out of (a) the preparation or approval of maps, drawings, opinions, reports, surveys, Change Orders, designs, or specifications or (b) the giving of or the failure to give directions or instructions by CONSULTANT, its agents or employees provided such act or omission is the primary cause of injury or damage. 6.34A All of the forgoing indemnification provisions will survive the term of the Contract to which these General Conditions are a part. Indemnification may not exceed an amount equal to the total value of all insurance coverage required by Section 5.1 of this document. Indemnification is limited to damages caused in whole or in part by any act, omission, or default of CONTRACTOR, CONTRACTOR’s subcontractors, sub-subcontractors, materialmen, or agents of any tier or their respective employees to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of the indemnifying party and persons employed or utilized by the indemnifying party in the performance of the construction contract. Responsibility for Connection to Existing Work: 6.35 CONTRACTOR must connect its Work to each part of the existing Work, existing building or structure or Work previously installed as required by the Drawings and Specifications to provide a complete installation. 6.36 Excavations, grading, fill, storm drainage, paving and any other construction or installations in rights-of- ways of streets, highways, public carrier lines, utility lines, either aerial, surface or subsurface, etc., must be done in accordance with requirements of the special conditions. OWNER will be responsible for obtaining all permits necessary for the Work described in this paragraph 6.36. Upon completion of the Work, CONTRACTOR must present to CONSULTANT certificates, in triplicate, from the proper authorities, stating that the Work has been done in accordance with their requirements. 6.36.1 OWNER will cooperate with CONTRACTOR in obtaining action from any utilities or public authorities involved in the above requirements. 6.36.2 CONSULTANT is responsible for obtaining elevations of curbs and gutters, pavement, storm drainage structures, and other items which must be established by governmental departments as soon as grading operations are begun on the site and, in any case, sufficiently early in the construction period to prevent any adverse effect on the Project. Cooperation with Governmental Departments, Public Utilities, Etc.: 6.37 CONTRACTOR is responsible for making all necessary arrangements with governmental departments, public utilities, public carriers, service companies and corporations (hereinafter referred to as “third parties”) owning or controlling roadways, railways, water, sewer, gas, electrical conduits, telephone, and telegraph facilities such as pavements, tracks, piping, wires, cables, conduits, poles, guys, etc., i ncluding incidental structures connected therewith, that are encountered in the Work in order that such items are properly shored, supported and protected, that their location is identified and to obtain authority from these third parties for relocation if CONTRACTOR desires to relocate the item. CONTRACTOR must give all proper notices, must comply with all requirements of such third parties in the performance of his Work, must permit entrance of such third parties on the Project in order that they may perf orm their necessary work, and must pay all charges and fees made by such third parties for their work. 6.37.1 CONTRACTOR'S attention is called to the fact that there may be delays on the Project due to work to be done by governmental departments, public utilities, and others in repairing or moving poles, conduits, etc. CONTRACTOR must cooperate with the above parties in every way possible, so that the construction can be completed in the least possible time. 6.37.2 CONTRACTOR must be familiar with all codes, laws, ordinances, and regulations which in any manner affect those engaged or employed in the Work, or materials and equipment use in or upon the Work, or in any way affect the conduct of the Work, and no plea of misunderstanding will be considered on account of damage or delay caused by his ignorance thereof. Use Premises: 6.38 CONTRACTOR must confine its apparatus, storage of materials, and operations of its workmen to the limits indicated by law, ordinances, permits and directions of CONSULTANT and City Manager, and may not unnecessarily encumber any part of the site or any areas off site. 6.38.1 CONTRACTOR may not overload or permit any part of any structure to be loaded with such weight as will endanger its safety, nor may it subject any work to st resses or pressures that will endanger it. 6.38.2 CONTRACTOR must enforce the rules and regulation promulgated by CONSULTANT and OWNER as well as their instructions with regard to signs, advertisements, fires, and smoking. 144 of 162 152 6.38.3 CONTRACTOR must arrange and cooperate with the City Manager in routing and parking of automobiles of its employees, subcontractors, and other personnel, as well as that of the material delivery trucks and other vehicles that come to the Project site. 6.38.4 The City Manager will designate specific areas on the site for storage, parking, etc. and the job site must be fenced to protect the job site and the general public. 6.38.5 CONTRACTOR must furnish, install, and maintain adequate construction office facilities for all workers employed by it or by its Subcontractors. Temporary offices must be provided and located where directed and approved by CONSULTANT. All such facilities must be furnished in strict accordance with existing governing regulations. Field offices must include telephone facilities. Protection of Existing Property Improvements: 6.38 Any existing surface or subsurface improvements, such as pavements, curbs, sidewalks, pipes or utilities, footings, or structures (including portions thereof), trees and shrubbery, not indicated on the Drawings or noted in the Specifications as being removed or altered must be protected from damage during construction of the Project. Any such improvements damaged during construction of the Project must be restored at the expense of CONTRACTOR to a condition equal to that existing at the time of award of Contract. ARTICLE 7 - WORK BY OTHERS. 7.1 OWNER may perform additional Work related to the Project or may let other direct contracts therefor which must contain General Conditions similar to these. CONTRACTOR must afford the other contractors who are parties to such direct contracts (or OWNER, if it is performing the additional Work itself), reasonable opportunity for the introduction and storage of materials and equipment and the execution of Work and must properly connect and coordinate its Work with theirs. 7.2 If any part of CONTRACTOR'S Work depends upon proper execution or results of the Work of any other contractor or OWNER, CONTRACTOR must promptly report to CONSULTANT in writing a ny defects or deficiencies in such Work that render it unsuitable for CONTRACTOR’s Work. 7.3 CONTRACTOR must do all cutting, fitting, and patching of the Work that may be required to make its several parts come together properly and fit to receive or be received by such other Work. CONTRACTOR may not endanger any Work of others by cutting, excavating, or otherwise altering their Work and may only cut or alter their Work with the written consent of CONSULTANT and of the other contractor whose work will be affected. 7.4 If the performance of additional Work by other contractors or OWNER is not noted in the Contract Documents prior to the execution of the Contract, written notice thereof will be given to CONTRACTOR prior to starting any such additional Work. If CONTRACTOR believes that the performance of such additional Work by OWNER or others will cause CONTRACTOR additional expense or entitles him to an extension of the Contract Time, he may make a claim therefore as provided in Articles 11 and 12. 7.5 Where practicable, CONTRACTOR must build around the work of other separate contractors or must leave chases, slots and holes as required to receive and to conceal within the general construction Work the work of such other separate contractors as directed by them. Where such chases, slots, etc., are impracticable, the Work will require specific approval of CONSULTANT. 7.6 Necessary chases, slots, and holes not built or left by CONTRACTOR must be cut by the separate contractor requiring such alterations after approval of CONTRACTOR. CONTRACTOR must do all patching and finishing of the work of other contractors where it is cut by them and such patching and finishing will be at the expense of CONTRACTOR 7.7 Cooperation is required in the use of site facilities and in the detailed execution of the Work. Each contractor must coordinate their operation with those of the other Contractors for the best interest of the Work in order to prevent delay in the execution thereof. 7.8 Each of several contractors working on the Project Site must keep themselves informed of the progress of the work of other contractors. Should lack of progress or defective workmanship on the part of other contractors interfere with CONTRACTOR’s operations, CONTRACTOR must notify CONSULTANT immediately and in writing. Lack of such notice to CONSULTANT will be construed as acceptance by CONTRACTOR of the status of the work of other contractors as being satisfactory for proper coordination of CONTRACTOR’s own Work. 7.9 The cost of extra Work resulting from lack of notice, untimely notice, failure to respond to notice, Defective Work or lack of coordination will be CONTRACTOR’s cost. 145 of 162 153 7.10 The City Manager reserves the right in the event CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested, to obtain the good and/or services from other sources and deducting the cost from the Contract Price without violating the intent of the Contract. ARTICLE 8 – CITY’S RESPONSIBILITIES. 8.1 The City Manager will issue all communications to CONTRACTOR through CONSULTANT. 8.2 In cases of termination of employment of CONSULTANT, the City Manager will appoint a CONSULTANT whose status under the Contract Documents will be that of the former CONSULTANT. 8.3 The City Manager will promptly furnish the data required of them under the Contract Documents. 8.4 OWNER’S duties in respect to providing lands and easements are set forth in Paragraphs 4.1 and 4.2. 8.5 OWNER will have the right to take possession of and use any completed or partially completed portions of the Work, notwithstanding the fact that the time for completing the entire Work or any portion thereof may not have expired; but such taking possession and use will not be deemed an acceptance of any Work not completed in accordance with the Contract Documents. ARTICLE 9 – CONSULTANTS’ STATUS DURING CONSTRUCTION. City’s Representative: 9.1 CONSULTANT will be OWNER’S representative during the construction period. The duties and responsibilities and the limitations of authority of CONSULTANT as OWNER’S representative during construction are set forth in Articles 1 through 16 of these General Conditions and will not be extended without written consent of the City Manager and CONSULTANT. 9.1.1 CONSULTANT’s decision, in matters relating to aesthetics, will be final, if within the terms of the Contract Documents. 9.1.2 Except as may be otherwise provided in this contract, all claims, counterclaims, disputes, and other matters in question between OWNER and CONSULTANT arising out of or relating to this Contract or the breach thereof, will be decided in a court of competent jurisdiction within the State of Florida. Visits to Site: 9.2 CONSULTANT must provide an inspector to make periodic visits to the site at each phase of construction to observe the progress and quality of the executed Work and to determine if the Work is proceeding in accordance with the Contract Documents. His efforts must be directed toward providing assurance for OWNER and all applicable regulatory agencies that construction is in compliance with the Construction Documents and applicable laws, rules, and regulations. On the basis of these on site- observations as an experienced and qualified design professional, he must keep the City Manager informed of the progress of the Work and must guard OWNER against defects and deficiencies in the Work of CONTRACTOR. Clarifications and Interpretations: 9.3 CONSULTANT will issue, with reasonable promptness, such written clarifications, or interpretations of the Contract Documents (in the form of Drawings or otherwise) as it may determine necessary, which will be consistent with, or reasonably inferable from, the overall intent of the Contract Documents. If CONTRACTOR seeks an increase in the Contract Price or extension of Contract Time based on a written clarification and/or interpretation, it will be required to submit a timely claim as provided in Articles 11 and 12. Measurement of Quantities: 9.4 All Work completed under the Contract will be measured by CONSULTANT according to the United States Standard Measures. All linear surface measurements will be made horizontally or vertically as required by the item measured. Rejecting Defective Work: 9.5 CONSULTANT will have authority to disapprove or reject Work that is "Defective Work" as defined in Article 1. It will also have authority to require special inspection or testing of the Work including Work fabricated on or off site, installed or completed as provided. If CONSULTANT requires testing of completed Work, the cost of such inspections and/or testing must be approved in writing by the City Manager. All consequential cost of such inspections and testing, including but not limited to the cost of testing and inspection, the cost of repairing any of the Work, or the work of others, the cost to move 146 of 162 154 furniture and equipment and/or the cost to provide alternative facilities until the repair work can be completed, must paid by CONTRACTOR if the Work is found to be Defective Work. Shop Drawings, Change Orders and Payments: 9.6 In connection with CONSULTANT responsibility as to Shop Drawings and samples, see paragraphs 6.25 through 6.28, inclusive. 9.7 In connection with CONSULTANT’s responsibility for Change Orders see Articles 10, 11, and 12. 9.8 In connection with CONSULTANT responsibilities with respect to the Application for Payment, etc., see Article 14. Decisions on Disagreements: 9.10 CONSULTANT will be the initial interpreter of the Construction Documents. Limitations on Consultant's Responsibilities: 9.11 CONSULTANT will not be responsible for the construction means, methods, techniques, sequences or procedures, or the safety precautions and programs incident thereto. 9.12 CONSULTANT will not be responsible for the acts or omissions of CONTRACTOR, or any Subcontractors, or any of their agent, servants or employees, or any other person performing any of the Work under or through them. ARTICLE 10 - CHANGES IN THE WORK. 10.1 Without invalidating the Contract, the City Manager may, at any time or from time to time, order additions, deletions, or revisions in or to the Work which will only be authorized by a written Change Orders. Upon receipt of a Change Order, CONTRACTOR must proceed with the Work involved. All such Work must be performed under the applicable conditions of the Contract Documents. If any authorized written Change Order causes an increase or decrease in the Contract Price or an extension or shortening of the Contract Time, an equitable adjustment will be made as provided in Article 11 or Article 12. A written Change Order signed by the City Manager and CONTRACTOR indicates their agreement to the terms of the Change Order. All Change Orders must be certified by CONSULTANT as to the appropriateness and value of the change in the Work as well as to any change in the time to complete the Work under the circumstances. The failure to include a time extension in the Change Order or in the request for a change order will result in a waiver of any extension of time due to the change in the work as reflected in the Change Order. 10.2 CONSULTANT may authorize minor changes or alterations in the Work not involving extra cost and not inconsistent with the overall intent of the Contract Documents without the need for a formal written Change Order provided CONTRACTOR does not request additional time or additional compensation. These may be accomplished by a written Field Order. If CONTRACTOR believes that any change or alteration authorized by CONSULTANT’s Field Order would entitles CONTRACTOR to an increase in the Contract Price or extension of Contract Time, it must submit a written notice of intent to demand a Change Order within twenty-four (24) hours of the issuance of the Field Order and submit a written proposal for Change Order within four (4) days thereafter, otherwise CONTRACTOR will be deemed to have waived such claim. 10.3 Additional Work performed by CONTRACTOR without authorization of a written Change O rder will not entitle it to an increase in the Contract Price or an extension of the Contract Time, except in the case of an emergency as provided in paragraph 6.21 and except as provided in paragraph 10.2. 10.4 The City Manager will execute appropriate Change Orders prepared by CONSULTANT covering changes in the Work, to be performed as provided in paragraph 4.4, and Work performed in an emergency as provided in paragraph 6.21 and any other claim of CONTRACTOR for a change in the Contract Time or the Contract Price which is approved by CONSULTANT. 10.5 It is CONTRACTOR'S responsibility to notify its Surety of any changes affecting the general Scope of the Work or change in the Contract Price or Contract Time and the amount of the applicable bonds will be adjusted accordingly. CONTRACTOR must furnish proof of such an adjustment to the City Manager before commencement of the Change Order Work. The Work will be stopped until CONTRACTOR provides such proof of adjustment in the Bond amount and any such delay will be charged to CONTRACTOR. 147 of 162 155 ARTICLE 11 – CHANGE OF CONTRACT PRICE. 11.1 The Contract Price constitutes the total compensation payable to CONTRACTOR for Performing the Work. All duties, responsibilities and obligations assigned to or undertaken by CONTRACTOR will be at its expense without changing the Contract Price. 11.2 The City Manager may, at any time, without written notice to the sureties, by written order designated or indicated to be a Change Order, make any change in the Work within the general scope of the Contract, including but not limited to changes to or in: 11.2.1 Specifications (including drawings and designs); 11.2.2 Method or manner of performance of the Work. 11.2.3 OWNER-furnished facilities, equipment, materials, services, or site; or 11.2.4 Acceleration in the performance of the Work. 11.3 Except as provided in this section, or sections referred to in this section, no order, statement, or conduct of the City Manager will be treated as a Change Order or entitle CONTRACTOR to an equitable adjustment unless and until the change in the Work is specifically and expressly provided for in a written Change Order, or as otherwise provided in another section of the Contract Documents. 11.4 When a Change Order is issued by CONSULTANT and signed by the City Manager or issued by the City Manager in writing, CONTRACTOR must perform the Work even if CONTRACTOR does not agree with the dollar amount of the Change Order. If any Change Order causes an increase or decrease in CONTRACTOR'S cost of, or the time required for, the performance of any part of the Work under this Contract, for which the City Manager and CONTRACTOR cannot reach a timely agreement, an equitable adjustment based on the cost of the Work will be made and the Contract modified accord ingly. 11.5 If CONTRACTOR intends to assert a claim for an equitable adjustment or contest the equitable adjustment made by CONSULTANT, it must, within ten (10) calendar days after receipt of a written Change Order, submit to the City Manager and CONSULTANT a written notice including a statement setting forth the general nature and monetary extent of such claim for equitable adjustment, time extension requested and supporting data. In determining the cost of the Change Order, the costs will be limited to those listed in section 11.7 and 11.8. 11.6 No claim by CONTRACTOR for an equitable adjustment hereunder will be allowed if not submitted in accordance with this section or if asserted after final payment under this Contract. 11.7 The value of any Work covered by a Change Order or of any claim for an increase or decrease in the Contract Price will be determined in one of the following ways: 11.7.1 By negotiated lump sum. 11.7.2 On the basis of the reasonable cost and savings that results from the change in the Work plus a mutually agreed upon fee to CONTRACTOR to cover overhead and profit not to exceed 15%. If CONTRACTOR disagrees with CONSULTANT’s determination of reasonable costs, the CONTRACT must provide a list of all costs together with backup documentation 11.8 The term cost of the Work means the sum of all direct extra costs necessarily incurred and paid by CONTRACTOR in the proper performance of the Change Order. Except as otherwise may be agreed to in writing by City Manager, such costs must be in amounts no higher than those prevailing in Miami- Dade County and may only include the following items: 11.8.1 Payroll costs for employees in the direct employ of CONTRACTOR in the performance of the Work described in the Change Order under schedules of job classifications agreed upon by City Manager and CONTRACTOR. Payroll costs for employees not employed full time on the Work must be apportioned on the basis of their time spent on the Work. Payroll costs must be limited to salaries and wages, plus the costs of fringe benefits which may include social security contributions, unemployment, excise and payroll taxes, workers' compensation, health and retirement benefits, sick leave, vacation, and holiday pay applicable thereto. Such employees may include superintendents and foremen at the site. The expenses of performing Work after regular working hours, on Sunday or legal holidays will be included in the above only if authorized by OWNER and provided it was not in any way, whether in whole or in part the r esult of the fault of CONTRACTOR due to negligence of CONTRACTOR or those acting by or through him or due in whole or in part to Defective Work of CONTRACTOR. 11.8.2 Cost of all materials and equipment furnished and incorporated in the Work, including cost s of transportation and storage, and manufacturers' field services required in connection therewith. CONTRACTOR must notify the City Manager of all cash discounts that are available and offer OWNER the opportunity to deposit funds with CONTRACTOR for the payment for items that offer a discount. Cash discounts will accrue to CONTRACTOR unless CONTRACTOR fails to timely notify the City Manager of the discounts or if OWNER deposits funds with CONTRACTOR with which to make payments in which cases the cash disc ounts will 148 of 162 156 accrue to OWNER. All trade discounts, rebates and refunds, and all returns from sale of surplus materials and equipment will accrue to OWNER, and CONTRACTOR must make provisions so that they may be obtained. 11.8.3 Payments made by CONTRACTOR to the Subcontractors for Work performed by Subcontractors. If required by City Manager, CONTRACTOR must obtain competitive bids from Subcontractors acceptable to him and must deliver such bids to City Manager who will then determine, with the advice of CONSULTANT, which Bids will be accepted. No subcontract may be a cost-plus contract unless approved in writing by the City Manager. If a Subcontract provides that the Subcontractor is to be paid on the basis of Cost of Work plus a fee, the cost of the Work will be determined in accordance this section 11.8 and in such case the word “Subcontractor” will be substituted for the word “CONTRACTOR”. 11.8.4 Rentals of all construction equipment and machinery, except hand tools, and the parts thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by City Manager with the advice of CONSULTANT, and the costs of transportation, loading, unloading, installation, dismantling and removal thereof - all in accordance with terms of said rental agreements. The rental of any such equipment, machinery or parts must cease when the use thereof is no longer necessary for the Work. 11.8.5 Sales, use or similar taxes related to the Work, and for which CONTRACTOR is liable, imposed by any governmental authority. 11.8.6 Payments and fees for permits and licenses. Costs for permits and licenses must be shown as a separate item. 11.8.7 The cost of utilities, fuel, and sanitary facilities at the site. 11.8.8 Minor expenses such as telegrams, long distance telephone calls, telephone service at the site, expressage, and similar petty cash items in connection with the Work. 11.8.9 Cost of premiums for additional Bonds and insurance required solely because of changes in th e Work, not to exceed two percent (2%) of the increase in the Cost of the Work. 11.9 The term “Cost of the Work” does NOT include any of the following: 11.9.1 Payroll costs and other compensation of CONTRACTOR'S officers, executives, principals (of partnership and sole proprietorships), general managers, engineers, architects, estimators, lawyers, agents, expediters, timekeepers, clerks, and other personnel employed by CONTRACTOR whether at the site or in its principal or a branch office for general administration of the Work and not specifically included in the schedule referred to in Subparagraph 11.5. 11.9.2 Expenses of CONTRACTOR'S principal and branch offices other than its office at the site. 11.9.3 Any part of CONTRACTOR'S capital expenses, including interest on CONTRACTOR'S capital employed for the Work and charges against CONTRACTOR for delinquent payments. 11.9.4 Cost of premiums for all bonds and for all insurance policies whether or not CONTRACTOR is required by the Contract Documents to purchase and maintain the same (except as otherwise provided in Subparagraph 11.8.9). 11.9.5 Costs due to the negligence of CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, includ ing but not limited to, the correction of defective work, disposal of materials or equipment wrongly supplied and making good any damage to property. 11.9.6 Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraph 11.8. 11.10 CONTRACTOR'S fee which will be allowed to CONTRACTOR for its overhead and profit will be determined as follows: 11.10.1 A mutually acceptable firm fixed price; or if none can be agreed upon. 11.10.2 A mutually acceptable fixed percentage (not to exceed 15%). 11.11 The amount of credit to be allowed by CONTRACTOR to OWNER for any such change which results in a net decrease in cost will be the amount of the actual net decrease in costs calculated in the same manner as provided in 11.8. When both additions and credits are involved in any one change, the net will be computed to include overhead and profit, identified separately, for both additions and credit, provided however, CONTRACTOR will not be entitled to claim lost profits for any Work not performed. ARTICLE 12 - TIME FOR COMPLETION, LIQUIDATED DAMAGES AND CHANGE OF THE CONTRACT TIME. 12.1 Time is of the essence to this contract and the date of beginning and the time for completion of the Work are essential conditions of the Contract. Therefore, the Work must be commenced on the date specified in the Notice to Proceed and completed within the time specified for completion of the work. 149 of 162 157 12.2 CONTRACTOR must proceed with the Work at such rate of progress to ensure full completion within the Contract Time. It is expressly understood and agreed, by and between CONTRACTOR and City Manager, that the Contract Time for the completion of the Work described herein is a reasonable time, taking into consideration the average climatic and economic conditions and other factors prevailing in the locality of the Work. No extension of time will be granted due conditions that CONTRACTOR knew of or should have known of before bidding on the project or due to inclement weather, except as provided in section 12.7. 12.3 If CONTRACTOR fails to complete the Work within the Contract Time, or extension of time granted by the City Manager, then CONTRACTOR must pay to OWNER the amount of liquidated damages as specified in the Contract Documents for each calendar day after the scheduled date for completion as adjusted by written Change Orders that extended the completion date. 12.3.1 These amounts are not penalties but are liquidated damages incurred by OWNER for its inability to obtain full use of the Project. Liquidated damages are hereby fixed and agreed upon between the parties, recognizing the impossibility of precisely ascertaining the amount of damages that will be sustained as a consequence of such delay, and both parties desiring to obviate any question or dispute concerning the amount of said damages and the cost and effect of the failure of CONTRACTOR to complete the Contract on time. The above-stated liquidated damages will apply separately to each phase of the Project for which a time for completion is given. 12.3.2 City Manager is authorized to deduct the liquidated damages from monies due to CONTRACTOR for the Work under this Contract. 12.4 The Contract Time may only be changed by a written Change Order. Any claim for an extension in the CONTRACT TIME will be based on written notice delivered to the City Manager and CONSULTANT within five (5) business days of the occurrence of the event giving rise to the claim and stating the general nature of the claim including supporting data. All claims for adjustment in the Contract Time will be evaluated and recommended by CONSULTANT, with final approval by the City Manager. Any change in the Contract Time resulting from any such claim must be incorporated in a written Change Order. 12.5 All time limits stated in the Contract Documents are of the essence of the Contract. 12.6 No damage claim for delay is allowed and CONTRACTOR’s sole remedy for delay caused by OWNER will be an extension of time for the period of delay. 12.7 Extensions to the Contract Time for delays caused by the effects of inclement weather will not be granted unless the weather was unusual for South Florida and could not have been anticipated, the abnormal weather is documented by records from the national weather service and the abnormal weather is documented to have had a substantial affected on the construction schedule. 12.8 No Damages for Delay: CONTRACTOR agrees that he will not have any claim for damages due to delay unless the delay exceeds 6 months, whether individually or cumulatively, and then the damages will be limited to increased cost of materials that were unanticipated and that would not have been incurred but for the delay. Other than as set forth above, the only remedy for any delay will be limited to an extension of time as provided for in Section 12.4 which will be the sole and exclusive remedy for such resulting delay. Other than as set forth above, CONTRACTOR will not be entitled to an increase in the Contract Price or payment or compensation of any kind from OWNER for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to, costs of accelerat ion or inefficiency, overhead or lost profits, arising because of delay, disruption, interference or hindrance from any cause whatsoever, whether such delay, disruption, interference or hindrance be reasonable or unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable. 12.9 CONTRACTOR waives all claims that are not presented to City Manager in writing on or before the 21st day following the date of the event upon which the claim is based. 12.10 Dispute Resolution: If any dispute concerning a question of fact arises under the Contract, other than termination for default or convenience, CONTRACTOR, and the city department responsible for the administration of the Contract will make a good faith effort to resolve the dispute. If the dispute ca nnot be resolved by agreement, then the department with the advice of the City Attorney and CONSULTANT will rule on the disputed issue and send a written copy of its decision to CONTRACTOR. CONTRACTOR must comply with such decision and may not delay the p roject. ARTICLE 13 – GUARANTEE. 13.1 CONTRACTOR guarantees and unconditionally warrants through either the manufacturer or CONTRACTOR directly, all materials and equipment furnished and Work performed for patent Defective Work for a period of one (1) year from the date of Final Acceptance as indicated in CONSULTANT Letter of Recommendation of Acceptance, if issued, the Certificate of Occupancy, if issued, or the Certificate of Completion, if issued by City Manager, whichever is applicable and if more than one is applicable, the one 150 of 162 158 that is issued last, for patent Defective Work,. CONTRACTOR guarantees and unconditionally warrants through either the manufacturer or CONTRACTOR directly, all materials and equipment furnished and Work performed for three (3) years from the date of Final Acceptance as indicated in CONSULTANT Letter of Recommendation of Acceptance, if issued, the Certificate of Occupancy, if issued, or the Certificate of Completion, if issued by City Manager, whichever is applicable and if more than one is applicable, the one that is issued last, for latent Defective Work. The City Manager will give notice of observed defects with reasonable promptness. In the event that CONTRACTOR should fail to commence to correct such Defective Work within ten (10) calendar days after having rece ived written notice of the defect, or should CONTRACTOR commence the corrective work, but fail to prosecute the corrective work continuously and diligently and in accordance with the Contract Documents, applicable law, rules and regulations, the City Manager may declare an event of default, terminate the Contract in whole or in part and cause the Defective Work to be removed or corrected and to complete the Work at CONTRACTOR's expense, and the City Manager will charge CONTRACTOR the cost thereby incurred. The Performance Bond will remain in full force and effect through the guarantee period. 13.2 The specific warranty periods listed in the Contract Documents, if different from the period of time listed in Section 13.1, will take precedence over Section 13.1. 13.3 CONTRACTOR must act as agent, on a limited basis for OWNER, at the City Manager’s option, solely for the follow-up concerning warranty compliance for all items under manufacturer’s Warranty/Guarantee and for the purpose of completing all forms for Warranty/Guarantee coverage under this Contract. 13.4 In case of default by CONTRACTOR, the City of South Miami may procure the articles or services from other sources and hold CONTRACTOR responsible for any excess costs occasioned or incurred thereby. 13.5 The City Manager may withhold acceptance of, or reject items which are found upon examination, not to meet the specification requirements. Upon written notification of rejection, items must be removed within five (5) business days by CONTRACTOR at his own expense and redelivered at his expense. Rejected goods left longer than thirty (30) calendar days will be regarded as abandoned and City Manager will have the right to dispose of them as its own property and CONTRACTOR thereby waives any claim to the good or to compensation of any kind. Rejection for Non-Conforming Work or failure to meet delivery schedules may result in the Contract being found in default. 13.6 If equipment is being provided, the standard manufacturer’s warranty information must be delivered to OWNER for all equipment being proposed and, if required by the warranty, such equipment must be installed by an authorized installer before final payment is made. If the manufacturer’s warranty is issued to the respondent/contractor, Respondent/Contractor must assign it to the City. ARTICLE 14 - PAYMENTS AND COMPLETION. Payments to Contractor 14.1 CONTRACTOR will not be entitled to any money for any work performed before the issuance of a Notice to Proceed on the form described in the Contract Documents and the issuance by City Manager of a “purchase order”, or any other document, does not and will not authorize the commencement of the Work. At least ten (10) calendar days before each progress payment falls due (but not more often than once a month), CONTRACTOR must submit to CONSULTANT a partial payment estimate filled out and signed by CONTRACTOR covering the Work performed during the period covered by the partial payment estimate and supported by such data as CONSULTANT may reasonably require. All progress payment applications after the first progress payment must be accompanied by partial releases of lien executed by all persons, firms and corporations who have furnished labor, services or materials incorporated into the work during the period of time for which the previous progress payment was made, releasing such claims and lien rights, if any, of those persons. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at or near site, the partial payment estimate must also be accompanied by such supporting data, satisfactory to the City Manager, which establishes OWNER’s title to the material and equipment as well as certificates of insurance providing coverage for 100% of the value of said material and equipment covering the material and equipment from all casualties as well as theft, vandalism, fire and flood. CONTRACTOR must replace at its expense any stored materials paid for which are either damaged or stolen before installation. CONSULTANT will within ten (10) calendar days after receipt of each partial payment estimate, either certifying in writing its approval of payment and present the partial payment estimate to the City Manager, or return the partial payment estimate to CONTRACTOR, indicating in writing his 151 of 162 159 reasons for refusing to approve payment. In the latter case, CONTRACTOR may make the necessary corrections and resubmit the partial payment estimate. OWNER, will within thirty (30) calendar days of presentation to it of any approved partial payment estimate, pay CONTRACTOR a progress payment on the basis of the approved partial payment estimate. City Manager may retain five (5%) percent of the amount of each payment until Final Completion and Acceptance of all Work covered by the Contract Documents. Any interest earned on the retainage will accrue to the benefit of OWNER. 14.2 CONTRACTOR, before it receives final payment, must deliver to the City Manager a Contractor’s Final Payment Affidavit as set forth in the Florida Construction Lien Statute as well as final releases of lien executed by all persons who have performed or furnished labor, services, or materials, directly or indirectly, which was incorporated into the Work. If any person refuses to provide such a release or provides a conditional release, the City Manager will have the right to issue a joint check made payable to CONTRACTOR and such person. 14.3 Punch list City Manager and CONTRACTOR will develop a single list of items required to render complete, satisfactory, and acceptable the construction services purchased by the local governmental entity. Within 30 calendar days after reaching substantial completion of the Project, City Manager will prepare a punch list of items that need to be completed and, within 5 days after the list of items has been developed and reviewed, the City Manager will deliver the punch list to CONTRACTOR. If the Project relates to more than one building or structure, or involves a multiphase project, the City Manager will prepare a separate punch list for each building and structure and if it is a multiphase project, for each phase, within 30 days of substantial completion of such building, structure, and phase . [See Sec. 255.07, Fla. Stat.] The final contract completion date may not be less than 30 days after the delivery of the list of items. If the list is not timely delivered to CONTRACTOR, the contract time for completion must be extended by the number of days OWNER exceeded the required delivery date. Contractor's Warranty of Title 14.3 CONTRACTOR warrants and guarantees that title to all Work, materials and equipment covered by an Application for Payment whether the Work, material or equipment is incorporated in the Project or not, will have passed to OWNER prior to the making of the Application for Payment, free and clear of all liens, claims, security interest and encumbrances (hereafter in these General Conditions referred to as "Liens"); and that no Work, materials or equipment, covered by an Application for Payment, will have been acquired by CONTRACTOR or by any other person performing the Work at the site or fu rnishing materials and equipment for the Project, under or pursuant to an agreement under which an interest therein or encumbrance thereon is retained by the seller or otherwise imposed by CONTRACTOR or such other person. Approval of Payment 14.4 CONSULTANT’s approval of any payment requested in an Application for Payment will constitute a representation by him to OWNER, based on CONSULTANT’s on site observations of the Work in progress as an experienced professional and on his review of the Application fo r Payment and supporting data, that the Work has progressed to the point indicated in the Application for Payment; that, to the best his knowledge, information and belief, the quality of the Work is in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning Project upon substantial completion as defined in Article 1, to the results of any subsequent tests called for in the Contract Documents and any qualifications stated in his approval); and that CONTRACTOR is entitle d to payment of the amount approved. However, the approval of such payment does not mean and may not imply that CONSULTANT made exhaustive or continuous on-site observations to check the quality or the quantity of the Work, or that he has reviewed the means, methods, techniques, sequences and procedures of construction or that he has made any examination to ascertain how or for what purpose CONTRACTOR has used the moneys paid or to be paid to him, or that title to any Work, materials, or equipment has passed to OWNER free and clear of any liens. 14.5 CONTRACTOR will not be entitled to be paid unless: (a) the labor and materials listed on a payment application have been used in the construction of this Work or, as to materials included in the request for payment that have not yet been incorporated into the construction, such materials are on the site or stored at an approved location, and (b) payment received from the last payment application has been used to fully pay for all the laborers, subcontractors and materials reflected in that request, other than amounts that are in dispute and that are listed in the payment application with reasonable clarity as to the reason for withholding payment with 152 of 162 160 the name, addresses and telephone number of the person whos e request is being withheld. The payment application must contain the forgoing statement and the statement must be certified by CONTRACTOR as being true. In the event that CONTRACTOR withholds payment from a Subcontractor or Supplier, the same amount of money will be withheld from CONTRACTOR’s payment until the issue is resolved by written agreement between them and then a joint check will be made payable to the person in question and CONTRACTOR in accordance with the settlement agreement, otherwise the money will be held by OWNER until a judgment is entered in favor of CONTRACTOR or the person, in which case the money will be paid according with said judgment. Nothing contained herein will indicate an intent to benefit any third persons who are not signatories to the Contract. 14.6 CONSULTANT may refuse to approve the whole or any part of any payment if, in its opinion, it is unable to make such representations to OWNER as required this Section 14. It may also refuse to approve any payment, or it may void any prior payment application certification because of subsequently discovered evidence or the results of subsequent inspection or tests to such extent as may be necessary in its opinion to protect OWNER from loss because: 14.6.1 of Defective Work, or completed Work has been damaged requiring correction or replacement, 14.6.2 the Work for which payment is requested cannot be verified, 14.6.3 claims of Liens have been filed or received, or there is reasonable evidence indicating the probable filing or receipt thereof, 14.6.4 the Contract Price has been reduced because of modifications, 14.6.5 OWNER has corrected Defective Work or completed the Work in accordance with Article 13. 14.6.6 of unsatisfactory prosecution of the Work, including failure to clean up as required by paragraphs 6.29 and 6.30, 14.6.7 of persistent failure to cooperate with other contractors on the Project and persistent failure to carry out the Work in accordance with the Contract Documents, 14.6.8 of liquidated damages payable by CONTRACTOR, or 14.6.9 of any other violation of, or failure to comply with provisions of the Contract Documents. 14.7 Prior to Final Acceptance, City Manager, with the approval of CONSULTANT, may use any completed or substantially completed portions of the Work provided such use does not interfere with CONTRACTOR’s completion of the Work. Such use will not constitute an acceptance of such portions of the Work. 14.8 The City Manager has the right to enter the premises where the Work is being performed for the purpose of doing Work not covered by the Contract Documents. This provision may not be construed as relieving CONTRACTOR of the sole responsibility for the care and protection of the Work, or the restoration of any damaged Work except such as may be caused by agents or employees of OWNER. 14.9 Upon completion and acceptance of the Work CONSULTANT will issue a Certificate attached to the Final Application for Payment that the Work has been accepted by it under the conditions of the Contract Documents. The entire balance found to be due CONTRACTOR, including the retained percentages, but except such sums as may be lawfully retained by OWNER, will be paid to CONTRACTOR within thirty (30) calendar days of completion and acceptance of the Work. 14.10 Upon The awarded CONTRACTOR will be strongly encouraged to register as an ePayables Vendor with OWNER. The Bank of America ePayables Solution is an automated card payment process that shifts accounts payable disbursements to corporate purchasing cards. ePayab les, streamline the process of making payments to your organization going forward, City Manager will provide CONTRACTOR with a credit card account number to keep on file. This card has unique security features, with $0 of available funds until an invoice is approved for payment. After an invoice has received proper and complete approval, an electronic remittance advice will be sent via e-mail, or fax, which notifies CONTRACTOR that the funds have been transferred into the account linked to the card for the amount listed on the invoice and/or remittance email. Please refer to the ePayables Questions & Answers Form contained in this RFQ or contact OWNER’s Finance department at (305) 663-6343 with any questions. Acceptance of Final Payment as Release 14.11 The Acceptance by CONTRACTOR of Final Payment will be and will operate as a release to OWNER and a waiver of all claims and all liability to CONTRACTOR other than claims previously filed and unresolved. The waiver includes all things done or furnished in connection with the Work and for every act and neglect of OWNER and others relating to or arising out of this Work. Any payment, however, 153 of 162 161 final, or otherwise, will not release CONTRACTOR or its sureties from any obligations under the Contract Documents or the Performance Bond and Payment Bonds. 14.12 CONSULTANT may void any certification of Substantial Completion or Final Completion of the Work as may be necessary in his opinion to protect OWNER from loss if he determines, because of subsequently discovered evidence or the results of subsequent inspection or tests, that: 14.12.1 the Work is defective, or that the completed Work has been damaged due to the fault of CONTRACTOR or any individual or entity operating under or through it requiring correction or replacement to the extent that the project is no longer Substantially Completed, or in the case of Final Completion certification, is no longer Finally Competed. 14.12.2 the Work necessary to be completed for the purpose of certifying the work as being Substantially Completed or Finally Completed cannot be verified, 14.12.3 claims or Liens have been filed or received, or there is reasonable evidence indicating the probable filing or receipt thereof that, if valid and paid, would reduce the amount owing to CONTRACTOR by 20% in the case of Substantial Completion and 5% in the case of Final Completion. 14.12.4 there is Defective Work the value of which, if deducted from the contract price would reduce the amount owing to CONTRACTOR by 20% in the case of Substantial Completion and 5% in the case of Final Completion. 14.13 If CONSULTANT de-certifies any portion of the Work that was certified (“Initial Certification”) by CONSULTANT, CONTRACTOR must repay to OWNER any money paid as a result of said Initial Certification being issued which will be paid only when the decertified work is re -certified. ARTICLE 15 – SUSPENSION OF WORK AND TERMINATION. 15.1 The City Manager may, at any time and without cause, suspend the Work or any portion thereof for a period of not more than ninety (90) calendar days by notice in writing to CONTRACTOR and CONSULTANT, which will fix the date on which Work will be resumed. Except for the City Manager’s exercising his right to suspend or terminate the contract pursuant to Article 6, Section 6.21 due to a state of emergency, CONTRACTOR will be allowed an increase in the Contract Price or an extension of the Contract Time, or both, directly attributable to any suspension and if a claim is timely made and if it is allowed under the terms of Articles 11 or Article 12. City May Terminate 15.2 If CONTRACTOR is adjudged bankrupt or insolvent, or if he makes a general assignment for the benefit of its creditors, or if a trustee or receiver is appointed for CONTRACTOR or for any its property, or if he files a petition to take advantage of any debtor's act, or to reorganize under bankruptcy or similar laws, or if he repeatedly fails to supply sufficient skilled workmen or suitable materials or equipment, or if he repeatedly fails to make prompt payments to Subcontractors or for labor, materials or equipment or he disregards laws, ordinances, rules, regulations or orders of any public body having jurisdiction, or if he disregards the authority of CONSULTANT, or if he otherwise violates any provision of, the Contract Documents, then the City Manager may, without prejudice to any other right or remedy and after giving CONTRACTOR and the Surety seven (7) calendar days written notice, terminate the services of CONTRACTOR and take possession of the Project and of all materials, equipment, tools, construction equipment and machinery thereon owned by CONTRACTOR, and finish the Work by whatever method it may deem expedient. In such case CONTRACTOR will not be entitled to receive any further paymen t until the Work is finished. If the unpaid balance of the Contract Price exceeds the direct and indirect costs of completing the Project, including compensation for additional professional services, such excess will be paid to CONTRACTOR. If such costs exceed such unpaid balance, CONTRACTOR or the Surety on the Performance Bond must pay the difference to OWNER. Such costs incurred by OWNER will be determined by CONSULTANT and incorporated in a Change Order. If after termination of CONTRACTOR under this Section, it is determined by a court of competent jurisdiction for any reason that CONTRACTOR was not in default, the rights and obligations of OWNER and CONTRACTOR will be the same as if the termination had been issued pursuant to Section 15.5 15.3 Where CONTRACTOR'S services have been so terminated by the City Manager said termination will not affect any rights of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys by OWNER due CONTRACTOR will not release CONTRACTOR from liability. 154 of 162 162 15.4 Upon seven (7) calendar days’ written notice to CONTRACTOR and CONSULTANT, the City Manager may, without cause and without prejudice to any other right or remedy, elect to terminate the Contract for the convenience of OWNER. In such case, CONTRACTOR will be paid for all Work executed and accepted by the City Manager as of the date of the termination, minus any deduction for damage or Defective Work. No payment will be made for profit for Work which has not been performed. 15.4A OWNER reserves the right in the event CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested, to obtain the good and/or services from other sources and deducting the cost from the Contract Price without violating the intent of the Contract. Removal of Equipment 15.5 In the case of termination of this Contract before completion for any cause whatever, CONTRACTOR, if notified to do so by the City Manager, must promptly remove any part or all of its equipment and supplies from the property of OWNER. Should CONTRACTOR not remove such equipment and supplies, the City Manager will have the right to remove them at the expense of CONTRACTOR and CONTRACTOR agrees that OWNER will not be liable for loss or damage to such equipme nt or supplies. Equipment and supplies will not be construed to include such items for which CONTRACTOR has been paid in whole or in part. Contractor May Stop Work or Terminate 15.6 If, through no act or fault of CONTRACTOR, the Work is suspended for a p eriod of more than ninety (90) calendar days by the City Manager or by order of other public authority, or under an order of court or CONSULTANT fails to act on any Application for Payment within thirty (30) calendar days after it is submitted, or OWNER fails to pay CONTRACTOR any sum approved by CONSULTANT, within thirty (30) calendar days of its approval, and presentation, then CONTRACTOR may, upon twenty (20) calendar days written notice to the City Manager and CONSULTANT, terminate the Contract. The City Manager may remedy the delay or neglect within the twenty (20) calendar days. If timely remedied by OWNER, the Contract will not be considered terminated. In lieu of terminating the Contract, if CONSULTANT has failed to act on an Application for Payment or OWNER has failed to make any payment as afore said, CONTRACTOR may upon ten (10) calendar days’ notice to the City Manager and CONSULTANT stop the Work until it has been paid all amounts then due. Indemnification of Independent Consultant. 15.7 CONTRACTOR and the City Manager hereby acknowledges that if CONSULTANT is an independent contractor of OWNER, CONSULTANT may be reluctant to rule on any disputes concerning the Contract Documents or on the performance of CONTRACTOR or OWNER pursuant to the ter ms of the Contract Documents. Therefore, OWNER, at CONSULTANT’s request, agrees to provide CONSULTANT with a written indemnification and hold harmless agreement to indemnify and hold CONSULTANT harmless as to any decision in this regard before CONSULTANT makes an interpretation, de-certifies a payment application, decertifies Substantial Completion, decertifies Final Completion, certifies an event of default, or approves any action which requires the approval of CONSULTANT. ARTICLE 16 – MISCELLANEOUS. 16.1 Whenever any provision of the Contract Documents requires the giving of written notice it will be deemed to have been validly given if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or if delivered at or sent by registered or certified mail, postage prepaid, to the last known business address. 16.2 The Contract Documents are the property of OWNER. CONTRACTOR and CONSULTANT will have the right to keep one record set of the Contract Documents upon completion of the Project. 16.3 The duties and obligations imposed by these General Conditions, Special Conditions and Supplementary Conditions, if any, and the rights and remedies available hereunder, and, in particul ar but without limitation, the warranties, guarantees and obligations imposed upon CONTRACTOR by the Contract Documents and the rights and remedies available to OWNER and CONSULTANT thereunder, will be in addition to, and will not be construed in any way as a limitation of, any rights and remedies available by law, by special guarantee or by other provisions of the Contract Documents. 16.4 Should OWNER or CONTRACTOR suffer injury or damage to its person or property because of any error, omission, or act of the other or of any of their employees or agents or others for whose acts they are legally liable, claim must be made in writing to the other party within twenty-one (21) calendar days of the first observance of such injury or damage. 155 of 162 163 ARTICLE 17 - WAIVER OF JURY TRIAL. 17.1 OWNER and CONTRACTOR knowingly, irrevocably voluntarily and intentionally waive any right either may have to a trial by jury in State or Federal Court proceedings in respect to any action, proceeding, lawsuit or counterclaim arising out of the Contract Documents or the performance of the Work thereunder. ARTICLE 18 - ATTORNEYS FEES JURISDICTION / VENUE / GOVERNING LAW. 18.1 The Contract will be construed in accordance with and governed by the law of the State of Florida. 18.2 The parties submit to the jurisdiction of any court of competent jurisdiction in Florida regarding any claim or action arising out of or relating to the Contract or Contract Documents. The parties agree that venue of any action to enforce the Contract is in Miami-Dade County, Florida. 18.3 Except as may be otherwise provided in the Contract Documents, all claims, counterclaims, disputes, and other matters in question between OWNER and CONTRACTOR arising out of or relating to this Contract or the breach thereof, will be decided in a court of competent jurisdiction within the State of Florida. ARTICLE 19 - PROJECT RECORDS. 19.1 The City Manager has the right to inspect and copy during regular business hours at OWNER’S expense, the books and records and accounts of CONTRACTOR which relate in any way to the Project, and to any claim for additional compensation made by CONTRACTOR, and to conduct an audit of the financial and accounting records of CONTRACTOR which relate to the Project. CONTRACTOR will retain and make available to City Manager all such books and records and accounts, financial or otherwise, which relate to the Project and to any claim for a period of three (3) years following final completion of the Project. During the Project and the three (3) year period following final completion of the Project, CONTRACTOR must provide City Manager access to its books and records upon five (5) business day’s written notice. 19.2 CONTRACTOR and all of its subcontractors are required to comply with the public records law (s.119.0701) while providing services on behalf of OWNER and CONTRACTOR, under such conditions, must incorporate this paragraph in all of its subcontracts for this Project. CONTRACTOR and its subcontractors are specifically required to: (a) Keep and maintain public records required by the public agency to perform the service; (b) Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law; (c) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the contractor does not transfer the records to the public agency; and (d) Upon completion of the contract, transfer, at no cost, to th e public agency all public records in possession of the contractor or keep and maintain public records required by the public agency to perform the service. If the contractor transfers all public records to the public agency upon completion of the contract, the contractor must destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the contractor keeps and maintains public records upon completion of the contract, the contractor must meet all applicable requirements for retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records, in a format that is compatible with the information technology systems of the public agency. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT 305-663-6340; E-mail: npayne@southmiamifl.gov; 6130 Sunset Drive, South Miami, FL 33143. 19.3 If CONTRACTOR or its subcontractor does not comply with a public records request, the City Manager has the right to enforce this contract provision by specific performance and the person who violates this provision is liable to OWNER for its costs of enforcing this provision, including attorney fees incurred in all proceedings, whether administrative or civil court and in all appellate proceedings. 156 of 162 164 ARTICLE 20 – SEVERABILITY. 20.1 If any provision of the Contract or the application thereof to any person or situation is, to any extent, held invalid or unenforceable, the remainder of the Contract, and the application of such provisions to persons or situations other than those as to which it is held invalid or unenforceable will not be affected thereby, and will continue in full force and effect, and be enforced to the fullest extent permitted by law. ARTICLE 21 – INDEPENDENT CONTRACTOR. 21.1 CONTRACTOR is an independent CONTRACTOR under the Contract. Services provided by CONTRACTOR must be by employees of CONTRACTOR and subject to supervision by CONTRACTOR, and not as officers, employees, or agents of OWNER. Personnel policies, tax responsibilities, social security and health insurance, employee benefits, purchasing policies and other similar administrative procedures, applicable to services rendered under the Contract must be those of CONTRACTOR. ARTICLE 22 – ASSIGNMENT. 22.1 CONTRACTOR may not transfer or assign any of its rights or duties, obligations and responsibilities arising under the terms, conditions, and provisions of this Contract without prior written consent of the City Manager. The City Manager will not unreasonably withhold and/or delay OWNER’S consent to th e assignment of CONTRACTOR’s rights. The City Manager may, in the manager’s sole and absolute discretion, refuse to allow CONTRACTOR to assign its duties, obligations and responsibilities. In any event, OWNER is not obligated to consent to such assignment unless CONTRACTOR remains jointly and severally liable for any breach of the Agreement by the assignee, the assignee meets all of OWNER’s requirements to the City Manager’s sole satisfaction and the assignee executes all of the Contract Documents that were required to be executed by CONTRACTOR. ARTICLE 23 – FORCE MAJEURE. 23.1 Neither party may hold the other responsible for damages or for delays in performance caused by force majeure, acts of God, or other acts or circumstances beyond the control of a party or that could not have been reasonably foreseen, prevented or avoided. For this purpose, such acts or circumstances include, but not limited to, weather conditions affecting performance, floods, epidemics, war, riots, strikes, lockouts, or other industrial disturbances, or protest demonstrations. Should such acts or circumstances occur, the parties will use their best efforts to overcome the difficulties and to resume the work as soon as reasonably possible. ARTICLE 24- E-VERIFY(448.095(2) 24.1 As a condition precedent to entering into this Agreement, and in compliance with Section 448.095, Fla. Stat., Contractor, and its subcontractors must register with and use the E -Verify system to verify work authorization status of all employees hired after January 1, 2021. 24.1.1 Contractor must require each of its subcontractors to provide Contractor with an affidavit stating that the subcontractor does not employ, contract with, or subcontract with an unauthorized alien. Contractor must maintain a copy of the subcontractor's affidavit as part of and pursuant to the records retention requirements of this Agreement. 24.1.2 The City, Contractor, or any subcontractor who has a good faith belief that a person or entity with which it is contracting has knowingly violated Section 448.09(1), Fla. Stat. or the provisions of this section must terminate the contract with the person or entity. 24.1.3 The City, upon good faith belief that a subcontractor knowingly violated the provisions of this section, but that the Contractor otherwise complied, must promptly notify Contractor and Contractor must immediately terminate the contract with the subcontractor. 24.1.4 A contract terminated under the provisions of this Section is not a breach of contract and may not be considered such. 24.1.5 Any contract termination under the provisions of this Section may be challenged no later than 20 calendar days after the date on which this Agreement is terminated pursuant to paragraph b. or c. above. 24.1.6 Contractor acknowledges that upon termination of this Agreement by the City for a violation of this Section by Contractor, Contractor may not be awarded a public contract for at least one (1) year. Contractor further acknowledges that Contractor is liable for any additional costs incurred by the City as a result of termination of any contract for a violation of this Section. 157 of 162 165 24.1.7 Subcontracts. Contractor or subcontractor must insert in any subcontracts the clauses set forth in this Section, including this Subsection, requiring the subcontractors to includ e these clauses in any lower tier subcontracts. Contractor is responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in this Section and Contractor's failure to enforce compliance is a substantial and material breach of this Agreement. ARTICLE 25 –ANTI DISCRINIMATION 25.1 Contractor and all of its employees, subcontractors and subconsultants, while performing work for the City, including the hiring and retention of employees for the performance of Work, are prohibited from discriminating against anyone on the basis of race, color, religion, family status, sex (including sexual orientation, gender identity and intersexuality), height, weight, domestic partnership status, labor organization membership, political affiliation, national origin, age, disability or any other classification that is federally defined as a “protected class” and Contractor must take all steps necessary to prevent such discrimination by all of its employees, subcontractors and subconsultants who are performing work for the City and must ensure nondiscrimination in all programs, services and activities that are part of the Scope of Services. A violation of this paragraph is a substantial, material breach of this Contract. 25.2 Contractor must include in all of its subcontracts the following clause: “Subcontractors and all of their employees, subcontractors and subconsultants, while performing work for the City, including the hiring and retention of employees for the performance of Work, are prohibited from discriminating against anyone on the basis of race, color, religion, family status, sex (including sexual orientation, gender identity and intersexuality), height, weight, domestic partnership status, labor organization membership, political affiliation, national origin, age, disability or any other classification that is federally defined as a “protected class”. Subcontractors must take all steps necessary to prevent such discrimination by all of their employees, subcontractors and subconsultants who are performing work for the City and must ensure nondiscrimination in all programs, services and activities that are part of the Scope of Services. A violation of this paragraph is a substantial, material breach of this Subcontract.” IN WITNESS WHEREOF, the parties hereto have executed the General Conditions to acknowledge their inclusion as part of the Contract Documents on this ____ day of ________________, 20___, CONTRACTOR: ___________________________ Signature: ___________________________ Print Signatory’s Name: ______________________ Title of Signatory: ___________________________ ATTESTED: OWNER: CITY OF SOUTH MIAMI Signature: _______________________ Signature: ________________________________ Nkenga A. Payne Shari Kamali City Clerk City Manager Read and Approved as to Form, Language, Legality, and Execution Thereof: Signature: ________________________ City Attorney END OF SECTION 158 of 162 166 EXHIBIT 6 Supplementary Conditions CONSTRUCTION CONTRACT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 A. Consultant: In accordance with ARTICLE 1 of the General Conditions the consultant (CONSULTANT) is defined as the person identified as the consultant in the Supplementary Conditions or if none, then OWNER’s designated representative as identified in the Supplementary Conditions. CONSULTANT’s, if any, and OWNER’s Designated Representative’s name, address, telephone number and facsimile number are as follows: Consultant: N/A B. Termination or Substitution of Consultant: Nothing herein will prevent the City Manager from terminating the services of CONSULTANT or from substituting another “person” to act as CONSULTANT. C. Plans for Construction: CONTRACTOR will be furnished one (1) sets of Contract Documents without charge. Any additional copies required will be furnished to CONTRACTOR at a cost to CONTRACTOR equal to the reproduction cost. D. The Scope of Services, also referred to as the Work in the contract documents, is as set forth in the RF Q and in the attached EXHIBIT 1, Attachments A, B, C & D to the RFQ and if there is a conflict the attached Exhibit will take precedence. E. Contractor must comply with the insurance and indemnification requirements is set forth in the RF Q and in the document set forth in the attached EXHIBIT 2 to the RFQ and if there is a conflict the attached Exhibit will take precedence. F. The Work must be completed in 60 calendar days unless a shorter time is set forth in the Contract and in such event the Contract will take precedent notwithstanding any provision in the General Conditions to the Contract that may be to the contrary. G. CONTRACTOR has reviewed and checked all information and data with respect to existing Underground Facilities or conditions at or contiguous to the site and assumes responsibility for the accurate location of all Underground Facilities and conditions that may affect the Work. It is agreed by the parties that no additional examinations, investigations, explorations, tests, reports or similar information or data in respect to any Underground Facilities or conditions are, or will be, required by CONTRACTOR to perform and furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents. H. CONTRACTOR has given the City Manager written notice of all conflicts, errors or discrepancies that it has discovered in the Contract Documents and, if any conflicts, errors or discrepancies have been found and notice given, CONTRACTOR represents, by submitting its proposal to the City Manager, that CONTRACTOR has received sufficient notice of the resolution thereof from the City Manager, that such resolution is acceptable to CONTRACTOR and that CONTRACTOR waives any claim regarding the conflicts, errors or discrepancies. IN WITNESS WHEREOF, the parties hereto have executed the Supplementary Conditions to acknowledge their inclusion as part of the Contract on this ____ day of ________________, 20___. CONTRACTOR: _____________________________ Signature: ______________________________ Print Signatory’s Name:_______________________________ Title of Signatory: ______________________________ 159 of 162 167 ATTESTED: OWNER: CITY OF SOUTH MIAMI Signature: _______________________ Signature: __________________________ Nkenga A. Payne Shari Kamali City Clerk City Manager Read and Approved as to Form, Language, Legality, and Execution Thereof: Signature: ________________________ City Attorney END OF SECTION 160 of 162 168 EXHIBIT 7 City of South Miami Bid Protest Procedures RESOLUTION OF PROTESTED SOLICITATIONS AND AWARDS (FORMAL PROCEDURE) CONSTRUCTION CONTRACT DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022- 18 The following procedures will be used for resolution of protested solicitations and awards. The word “bid”, as well as all of its derivations, means a response to a solicitation, including requests for proposals, requests for a letter of interest and requests for qualifications. i. Notice of Intent to Protest. Any actual or prospective bidder who perceives itself to be aggrieved in connection with any formal solicitation or who intends to contest or object to any bid specifications or any bid solicitation shall file a written notice of intent to file a protest with the City Clerk’s office within three calendar days prior to the date set for opening of bids. A notice of intent to file a protest is considered filed when received by the City Clerk’s office by e-mail or, if hand delivered, when stamped with the City Clerk’s receipt stamp containing the date and time of receipt of a notice of intent to file a protest. Any actual responsive and responsible bidder who perceives itself to be aggrieved in connection with the recommended award of a contract and who wishes to protest the award, shall file a written notice of intent to file a protest with the City Clerk’s office within three calendar days after the City Commission meeting at which the recommendation is considered for action. A notice of intent to file a protest is considered filed when received by the City Clerk’s office by e-mail or, if hand delivered, when stamped with the City Clerk’s receipt stamp containing the date and time of receipt. ii. Protest of solicitation. A protest of the solicitation or award must be in writing (“Protest Letter”) and submitted to the City Clerk’s office within five calendar days after the date of the filing of the notice of intent to file a protest. The Protest Letter is considered filed when the Protest Letter and the required filing fee of $1,000 are both timely received by the City Clerk’s office. In order for the Protest Letter and filing fee to be considered timely delivered by hand delivery, the date stamp of the Clerk’s office must appear on the original Protest Letter and/or a copy of the Protest Letter and the date stamp must also appear on a copy of the check issued for the payment of the filing fee, or, if payment is made in cash, a receipt must be issued by the Clerk’s office reflecting the date of receipt of the payment. While the Clerk may accept the Protest Letter by email, the Protest Letter shall not be considered to be timely received until and unless the required filing fee of $1,000 is received by the City Clerk’s office and, if payment is in cash, a receipt is issued with the date of the receipt of payment, or if payment is by check, a copy of the check is stamped by the Clerk with the date stamp of the Clerk’s office showing the date of receipt. The Protest Letter shall state with particularity the specific facts and law upon which the protest is based, it shall describe and attach all pertinent documents and evidence relevant and material to the protest and it shall be accompanied by any required filing. The basis for review of the protest shall be the documents and other evidence described in and attached to the Protest Letter and no facts, grounds, documentation, or other evidence not specifically described in and attached to the Protest Letter at the time of its filing shall be permitted or considered in support of the protest. iii. Computation of time. No time will be added to the above time limits for service by mail. The last day of the period so computed shall be included unless it is a Saturday, Sunday, or legal holiday in which event the period shall run until the next day which is not a Saturday, Sunday, or legal holiday. 161 of 162 169 iv. Challenges. The written protest may not challenge the relative weight of the evaluation criteria or any formula used for assigning points in making an award determination, nor shall it challenge the City’s determination of what is in the City’s best interest which is one of the criteria for selecting a bidder whose offer may not be the lowest bid price. v. Authority to resolve protests. The Purchasing Manager, after consultation with the City Attorney, shall issue a written recommendation within ten calendar days after receipt of a valid Protest Letter. Said recommendation shall be sent to the City Manager with a copy sent to the protesting party. The City Manager may then, submit a recommendation to the City Commission for approval or disapproval of the protest, resolve the protest without submission to the City Commission, or reject all proposals. vi. Stay of procurement during protests. Upon receipt of a timely, proper and valid Protest Letter filed pursuant to the requirements of this section, the City shall not proceed further with the solicitation or with the award or execution of the contract until the protest is resolved by the City Manager or the City Commission as provided in subsection (e) above, unless the City Manager makes a written determination that the solicitation process or the contract award must be continued without delay in order to avoid potential harm to the health, safety, or welfare of the public or to protect substantial interests of the City or to prevent youth athletic teams from effectively missing a playing season. END OF DOCUMENT 162 of 162 170 Tabulation Sheet Agency Name City of South Miami Bid Number RFQ-RFQ #FN2022-18-0-2022/SK Bid Name DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM Bid Due Date 09/01/2022 10:00:00 Eastern Bid Opening Closed 6 responses found.online,  offline,  not submitting,  not received  Company Responded Address Bid Amount Alt Bid Amount Declared Attributes Documents Sent Complete 1 .ADS Technology 09/01/2022 05:36:00 Eastern 2520 coral way, ste 2-322, Miami,  FL, 33145  $0.0000 0.0000 Bidding Document  2 .Alfi Electronics, Inc 08/31/2022 12:35:18 Eastern 3100 N 29th Court, 105, Hollywood, FL, 33020  $0.0000 0.0000 Bidding Document  3 .Bryant Integrated Technologies 08/30/2022 11:17:23 Eastern 2035 Harding  Street, Suite 100, Hollywood, FL,  33020  $0.0000 0.0000 Bidding Document  4 .Eyecast 08/30/2022 15:24:38 Eastern 9726 E Indigo St, 303, Palmetto Bay, FL, 33157  $0.0000 0.0000 Bidding Document  5 .Integrated Security Systems 09/01/2022 09:42:54 Eastern 1876 NW 7 Street, Miami, FL, 33125 $0.0000 0.0000 Bidding Document  6 .Snappy Internet & Telecom 09/01/2022 01:57:40 Eastern 7372 SW 48 Street, Miami, FL, 33155 $0.0000 0.0000 Bidding Document  171 1 ✓ 1 ✓ 1 ✓ 1 ✓ 1 ✓ 1 ✓ Parking Security Cameras Quote # 004232 Version 1 Prepared for: City of South Miami We have prepared a quote for you P: E: david@adstechsystems.com W:172 P: E: david@adstechsystems.com W: Cameras Product Description Qty Project: New IP camera system building wide. New cameras will be installed in: -All corners of each floor -All Elevator landings -Inside elevator Cabs -Inside stairway flights -Floor driveway -Outside Perimeter area -Management Parking area -LPR at entry points Each NVR will have 8 x10 TB drive. 82 Cameras across 2 NVRs All Turing camera and NVR has 3 year manufacture warranty extended warranty along with service agreements All hard drive carry 3 year manufacture warranty. All Switches carry 1 year manufacture warranty. All cabling in conduit with permit required ADS is not responsible for drywall or concrete repair work. ADS is not responsible for painting of repair areas, conduits. ADS is fire caulk all riser conduits Bld will provide parking for 1-2 work trucks during duration of project All electrical telecom should be place on emergency generator circuit. Does include lift, ADS will provide boom lift for install where needed. Does not include any act of god damage Does not include any damaged to cable, cameras, conduits and equipment damaged by powers outages or other vendors. Does not included Permit Related costs(Permit Drawings, Permit Fee)(estimated 3-5K) Does not included added elevator senior tech work if elevator control tech has not properly setup elevator as requested for floor control. Price does not include cutting doors for access control if not access control ready Price does not include conduit, cabling for management office for computers, displays and phones. TBD Price does not include any TV for cable or digital display or new view stations.Provided by client unless additional requested Payment schedule Permit Drawings and permit fee not included in quoted price and billed separately due after permit issued. Any changes will be bill separately as approved change orders. Payment schedule to be submitted upon approval and discussion. City will assist on permit processing. Turing Video Smart 64-Channel Performance NVR with Turing Vision Bridge - Network Video Recorder - HDMI - 4K Recording 2 Western Digital Purple Pro 10 TB Hard Drive - 3.5" Internal - SATA (SATA/600) - Conventional Magnetic Recording (CMR) Method - Server, Video Surveillance System, Storage System Device Supported - 7200rpm - 550 TB TBW - 5 Year Warranty 16 Turret -Turing Video Smart 8 Megapixel 4K Network Camera - Color - Turret - 131.23 ft Infrared Night Vision - Ultra 265, H.265, H.264, Motion JPEG, H.264 BP, H.264 (MP) - 3840 x 2160 - 2.80 mm- 12 mm Varifocal Lens - 4.3x Optical - CMOS - Junction Box 30 Dec 12, 2022Quote #004232 v1 Page: 2 of 5173 P: E: david@adstechsystems.com W: Cameras Product Description Qty Dome - Turing Video Smart 8 Megapixel 4K Network Camera - Color - Dome - 131.23 ft Infrared Night Vision - Ultra 265, H.265, H.264, MJPEG, H.264 BP, H.264 (MP), H.264 HP - 3840 x 2160 - 2.80 mm- 12 mm Varifocal Lens - 4.3x Optical - CMOS - Ceiling Mou 44 MiniDome - Turing Video Smart 4 Megapixel HD Network Camera - Color - Mini Dome - 98.43 ft Infrared Night Vision - Ultra 265, H.265, H.264, Motion JPEG, H.264 BP, H.264 (MP), H.264 HP - 2688 x 1520 - 2.80 mm Fixed Lens - CMOS - Junction Box Mount, Pole M 2 Turing Video Smart 4 Megapixel Network Camera - Color - Dome - 492.13 ft Infrared Night Vision - Ultra 265, H.265, H.264, Motion JPEG - 2688 x 1520 - 4.50 mm- 148.50 mm Varifocal Lens - 33x Optical - CMOS - Wall Mount, Junction Box Mount, Pole 4 LPR - Turing Video Smart 2 Megapixel Full HD Network Camera - Color - Bullet - 328.08 ft Infrared Night Vision - Ultra 265, H.265, H.264, MJPEG, H.264 HP, H.264 (MP), H.264 BP, H.265 (MP) - 1920 x 1080 - 5 mm- 50 mm Zoom Lens - 10x Optical - CMOS - 2 CORE/CAMERA/5YR SUBSCRIP 82 Subtotal:$45,000.00 CablingConduit Product Description Qty 3/4in EMT per foot 1500 Conduit Assembling Kit 30 1in EMT per foot 500 Conduit Assembling Kit 60 Box of 1000 Ft Cat6 Cable 31 Box of EZCrimp Cat6 -100 3 Elevators Netsys Converter with PoE Remote Unit 2 CablingConduit 2 Man Team Installation 1 CablingConduit Unifi Switch Pro 48 POE 2 Fiber Aqua 6 Fiber, Multimode Fiber Optic Cable 10 Gbit - 500Ft Spool 3 Dec 12, 2022Quote #004232 v1 Page: 3 of 5174 P: E: david@adstechsystems.com W: CablingConduit Product Description Qty Fiber Optic Wall Mount Enclosure(No Module)3 12 Fiber LC Multimode Adapter Strip, 6 Duplex LC Ports 10GB 3 Fiber Termination 8 Corning LC Unicam Connector OM3 OM4 rated 50/125 8 Fiber Patch Cables 4 Subtotal:$84,978.00 Dec 12, 2022Quote #004232 v1 Page: 4 of 5175 P: E: david@adstechsystems.com W: Parking Security Cameras Prepared by:Prepared for:Quote Information: Support Services City of South Miami Quote #: 004232 David C. Suarez 3056770592 ext 101 david@adstechsystems.com 6130 Sunset Drive South Miami, FL 33143 Steven Kulick (305) 663-6339 skulick@southmiamifl.gov Version: 1 Delivery Date: 12/12/2022 Expiration Date: 01/03/2023 Quote Summary Description Amount Cameras $45,000.00 CablingConduit $84,978.00 Total:$129,978.00 Taxes, shipping, handling and other fees may apply. We reserve the right to cancel orders arising from pricing or other errors. Support Services City of South Miami Signature: Name:David Suarez Title:President, ADS Technology Corp Date:12/12/2022 Signature: Name:Steven Kulick Date: Dec 12, 2022Quote #004232 v1 Page: 5 of 5176 ADS 144¥-V-t-9 Maintance Agreement Quote # 004176 Version 1 Prepared for: City of South Miami We have prepared a quote for you P: E: david@adstechsystems.com W:177 P: E: david@adstechsystems.com W: Cameras Product Description Qty ADS Service Agreement with South Miami for Parking Garage - Per year for 5 Year Term After Year 1 Camera Support Plan: -Regular service hours 8-6 Monday - Friday. On-Call available for support covered items for off normal hours and weekend -Unlimited Remote troubleshooting of cameras -Unlimited Onsite troubleshooting of cameras -Covers routine adjust of cameras viewpoints and angles -Testing and re terminating camera cables(Cabling, Conduit Not included) -Adjust camera mounts and brackets when needed -Troubleshoot and install client view software -Assistant and maintain remote camera view and access list of cameras -Labor replacement of cameras due to failure. -Physical camera replace cost included for exact units.(LPR, Standard building wide camera, Elevator cameras) Not Included -Does not included theft or vandalism of cameras. -Does not include any damaged done as a result of Act of God. -New cabling and conduits -New camera installation. -Camera upgrade not due to failure -Maintain network switches related to cameras system if present -Custom camera analytic configurations -Fees associated with elevator work if needed NVR Support Plan: -Unlimited Remote troubleshooting of cameras, NVR and DVR -Unlimited Onsite troubleshooting of cameras, NVR and DVR -Troubleshoot and install client view software -Assistant and maintain remote camera view and access list of cameras Not Included -Physical cost NVR and hard drives of manufacture warranties -Maintain network switches related to cameras system if present CORE/CAMERA/1YR SUBSCRIP 82 MSA Camera Support 2 MSA Camera Support 82 MSA Network switch\UPS 2 Monthly Subtotal:$0.00 Subtotal:$22,810.00 Dec 8, 2022Quote #004176 v1 Page: 2 of 3178 P: E: david@adstechsystems.com W: Maintance Agreement Prepared by:Prepared for:Quote Information: Support Services City of South Miami Quote #: 004176 David C. Suarez 3056770592 ext 101 david@adstechsystems.com 6130 Sunset Drive South Miami, FL 33143 Steven Kulick (305) 663-6339 skulick@southmiamifl.gov Version: 1 Delivery Date: 12/08/2022 Expiration Date: 12/31/2022 Quote Summary Description Amount Cameras $22,810.00 Total:$22,810.00 Monthly Expenses Summary Description Amount Cameras $0.00 Monthly Total:$0.00 Taxes, shipping, handling and other fees may apply. We reserve the right to cancel orders arising from pricing or other errors. Support Services City of South Miami Signature: Name:David Suarez Title:President, ADS Technology Corp Date:12/08/2022 Signature: Name:Steven Kulick Date: Dec 8, 2022Quote #004176 v1 Page: 3 of 3179 ADS 144¥-V-t-9 EXHIBIT 3 EVALUATION AND SELECTION CRITERIA Design and Install a Parking Garage Security System RFQ #FN2022- 18 Scoring and Average Ranking Phase I - Competitive Selection-Ranking; maximum 100 points per committee member. Proposals will be evaluated by an Evaluation Selection Committee that will evaluate and rank proposals on the technical criteria listed below. The Evaluation Selection Committee will be comprised of appropriate City personnel and/or members of the community, as deemed necessary, with the appropriate experience and/or knowledge. Respondents deemed as best suited and qualified will be selected by The Evaluation Selection Committee for discussion and/or presentations, ranking and subsequent negotiations with the highest ranked Respondent. The criteria are itemized with their respective weights for a maximum total of one hundred (100) points per Evaluation Selection Committee member. The evaluation factors used for determining qualifications for scoring and ranking, including average ranking order, shall include: Technical Criteria: a) RESPONDENTS QUALIFICATIONS (Maximum Point Value – 50) i. Number of years of experience in the design and installation of security camera surveillance systems for residential and commercial applications. Company and/or predecessors must have at least five (5) years of experience in this field. ii. Background in handling similar size projects: company must have successfully completed a project involving the commercial design and installation of a security camera surveillance system within the past five (5) years. iii. Degree of experience in all areas of a security camera surveillance design and installation process. v. Proof of satisfactory or better performance on contracts of similar scope and size: references and letters of reference must verify successful completion of similar projects. vi. Number of similar projects: company and/or predecessors must have completed at least five (5) similar projects within the last 5 years. b) PROJECTS (Maximum Point Value – 50) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, managerial approach, environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. 129 of 162 180 Average Ranking Order: Each Evaluation Selection Committee member shall rank each Respondent; #1 (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters and the lowest number represents the most qualified firm. In the example below, Respondent B’s total Rank Score is 6, divided by the number of Raters (4) equals the lowest number of 1.50 and therefore Respondent B is considered the most qualified and eligible for the award of a contract, subject to satisfactory negotiations: Respondent B = 6 (Rank Score) Divided by the Number of Raters (4) = 1.50 Phase II - Oral Presentations Upon completion of the criteria evaluation indicated above by the Evaluation Selection Committee, including rating, and ranking, the Evaluation Selection Committee may choose to conduct an oral presentation and/or interviews with the Respondent (s) who the Evaluation Selection Committee deems to warrant further consideration based such things as scores in clusters; based on the preliminary rating and rankings, and/or maintaining competition. Upon completion of the oral presentation(s) and/or interviews, the Evaluation Selection Committee will perform a final review to re-evaluate, re-rate, and re-rank the Proposals, as described above, remaining in consideration based upon the written documents, combined with the oral presentation. Phase III – Competitive Negotiations A final ranking of all firms or short-listed firms will be submitted to the City Manager for review and approval. In order to fulfill the City’s needs and meet the requirements in accordance with Exhibit 1 “Scope of Services, Attachments A, B, C & D” the City intends to award a contract to complete the work as described in Exhibit 1, “Scope of Services Attachments A, B, C, & D.” The City Manager shall commence negotiations with the first ranked firm. If those negotiations are unsuccessful, negotiations will be opened with the next ranked firm, etc. Negotiations shall continue until the City Manager has successfully completed negotiations with a firm and shall execute a contract with the City in accordance with City Commission approval. The City reserves the right to reject all Respondents, to request clarification of information submitted or to request additional information from any Respondent, and to waive any irregularities in any submittal. END OF SECTION Respondent Ranking Order Rater #1 Rater #2 Rater #3 Rater #4 AVG RANK RESPONDENT A 4 2 1 3 2.50 RESPONDENT B 1 1 3 1 1.50 RESPONDENT C 2 3 2 2 2.25 RESPONDENT D 5 4 4 5 4.50 RESPONDENT E 3 5 3 4 3.75 130 of 162 181 BIDDER A. ALI A. RIVEROL L. CORBIN C. MARENCO AVG RANK TOTAL ADS TECHNOLOGY 3 6 3 3 3.75 ALFIE ELECTROINICS 6 3 3 1 3.25 BRYANT ELECTRONICS 5 5 2 4 4.00 EYECAST 4 2 4 6 4.00 INTEGRATED SCEURITY 1 1 1 2 1.25 SNAPPY INTERNET 2 4 5 5 4.00 BIDDER A. ALI A. RIVEROL L. CORBIN C. MARENCO SCORES TOTAL ADS TECHNOLOGY 82 95 70 95 342 ALFIE ELECTROINICS 44 98 70 95 307 BRYANT ELECTRONICS 74 96 80 80 330 EYECAST 75 99 60 60 294 INTEGRATED SCEURITY 84 100 90 95 369 SNAPPY INTERNET 83 97 50 70 300 Respondent Ranking Order EVALUATION SCORING SHEET DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM Respondent Scores SHORT LIST 182 THE OTY Of PUASAI\ T LMNG 183 THE CITY OF PLEASANT LIVING Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www .southm iam ifl .gov RFQ Title: DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ No.: RFQ #FN2022-I 9 DIRECTIONS: Please score each firm, for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by adding each criteria for a total score by proposer. The maximum score total score for each proposer is I 00 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; #I (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The Lowest Average Rank Score will be recommended for the award. RESPONDE-NTS QUALIFICATIONS (Maximum Point Value - 50) i. Number of years of experience in the design and installation of security camera surveillance systems for residential and commercial applications. Company and/or predecessors must have at least five (5) years of experience in this field. a) ii. Background in handling similar size projects: company must have 2l 1 successfully completed a project involving the commercial design and installation of a security camera surveillance system within the past five (5) years. iii. Degree of experience in all areas of a security 1 8 '8 camera surveillance design and installation process. Page 1 of 2 184 A9> v. Proof of satisfactory or better performance on contracts of similar scope and size: 1 references and letters 0 of reference must verify successful completion of similar projects. vi. Number of similar projects: company 8 and/or predecessors must have completed at least five (5) similar projects within the last s ears. PROJECTS (Maximum Point Value -50) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and '-15 sequencing, managerial ~3 ri 5 3S 3a:, 41+ approach, b) environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. Re,viewed by: (..Print Name) Page 2 of 2 185 THE CITY O F PLEASANT LIVING Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 3 3143 (305) 663-6339 www.sourhmi a mifl.gov RFQ Title: DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ No.: RFQ #F N2022-l 9 DIRECTIONS: Please score each firm , for each specific criteria provided. Scoring is ba sed on e a ch c r ite ria list ed below with a max imum score for each cri t eria. The tota l score fo r e ach proposer is calcu lated by add ing e ach c ri teri a for a total score by p r opose r. The maximum score total score for each proposer is I 00 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; #I (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The Lowest Average Rank Score will be recommended for the award. a) RESPONDENTS QUALIFICATIONS (Maximum Point Value - 50) i. ii. Number of years of experience in the design and installation of security camera surveillance systems for residential and applications. Company f r I / ([) commercial <; and/or predecessors I '-t''\) must have at least five (5) years of experience in this field. Background in handling similar size projects: company must have successfully completed a project involving the commercial design and installation of a security camera surveillance system within the past five (5) years. iii. Degree of experience in all areas of a security camera surveillance design and installation process. BRYAM T EYECAST Page 1 of 2 186 b) v. Proof of satisfactory or better performance on contracts of similar scope and size: references and letters of reference must verify successful completion of similar projects. vi. Number of similar projects: company and/or predecessors must have completed at least five (5) similar projects within the last 5 ears. PROJECTS (Maximum Point Value -SO) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, managerial '(' f'--,. approach, ._) V environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. Reviewed by: Page 2 of 2 00 0\ 4 Date ~ 187 Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 33 I 43 (305) 663-6339 www .southmiamifl .gov RFQ Title: DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ No.: RFQ #FN2022-19 DIRECTIONS: Please score each firm, for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by adding each criteria for a total score by proposer. The maximum score total score for each proposer is 100 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; #I (Highest Total Score), #2 (Next Highest Score), and so on . The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled . The total is divided by the number of Raters. The Lowest Average Rank Score will be recommended for the award. - - Criteria ~ ADS ALFIE BRYANT EYECAST INTEGRA"TED SNAPPY TECH. SECURITY INTERNET RESPONDENTS QUALIFICATIONS (Maximum Point Value - 50) i. Number of years of experience in the design and installation of security camera surveillance systems for JO residential and s·o i@ commercial ,;o applications. Company ~@ and/or predecessors must have at least five ~() (5) years of experience in this field. a) ii . Background in handling similar size projects: company must have successfully completed a project involving the commercial design and installation of a security camera surveillance system within the past five (5) years. iii. Degree of experience in all areas of a security camera surveillance design and installation process. Page 1 of 2 188 b) v. Proof of satisfactory or better performance on contracts of similar scope and size: references and letters of reference must verify successful completion of similar projects. vi. Number of similar projects : company and/or predecessors must have completed at least five (5) similar projects within the last 5 ears. PROJECTS (Maximum Point Value -SO) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, managerial approach, environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. Reviewed by: t/" so Dau,lpk Page 2 of 2 189 ,,,. THE CITY OF PLEASANT LIVING Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www.southmiamifl.gov .RFQ Title: DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ No.: RFQ #FN2022-I 9 DIRECTIONS: Please score each firm , for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score fo r each criteria. The total score for each proposer is calcul ated by adding each criteria for a total score by proposer. The maximum score total score for each proposer is I 00 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; #I (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The lowest Average Rank Score will be recommended for the award. Criteria ADS . •fFIE BRYANT EYE CAST IN TEG RATED SNAPPY TECH ' .E.CU RITY IN TERNET ·:: ' RESPONDENTS QUALIFICATIONS (Maximum Point Value - SO) i. Number of years of -z...O experience in the ,s ZS design and installation z~ zo z_O of security camera surveillance systems for residential and commercial applications. Company and/or predecessors must have at least five (5) years of experience in this field. a) ii. Background in handling ,s-similar size projects: zO company must have ,o successfully completed zo -z_O \0 a project involving the commercial design and installation of a security camera surveillance system within the past five (5) years. iii. Degree of experience -z._() '\ -in all areas of a security z,O ,s ,o ~ camera surveillance -ZD design and installation process. Page 1 of 2 190 V. Proof of satisfactory or better performance on contracts of similar s \S 5 \S s scope and size: ' references and letters of reference must verify successful completion of similar projects. vi. Number of similar projects: company s s and/or predecessors must have completed at least five (5) similar projects within the last 5 ears. PROJECTS (Maximum Point Value -50) i. Evaluation of designs of similar scopes and size, 0 0 constructability, phasing 0 \S zo t I I 0 of the work staging and l sequencing, managerial approach, b) environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. S" Date: (Signature) Page 2 of 2 BIDDER A. ALI A. RIVEROL L. CORBIN C. MARENCO AVG RANK TOTAL RANK ADS TECHNOLOGY 1 1 3 1 1.50 1 ALFIE ELECTROINICS 2 3 1 3 2.25 2 INTEGRATED SECURITY 3 2 2 2 2.25 2 BIDDER A. ALI A. RIVEROL L. CORBIN C. MARENCO SCORES TOTAL RANK ADS TECHNOLOGY 92 100 80 100 372 1 INTEGRATED SECURITY 75 99 85 95 354 2 ALFIE ELECTROINICS 79 98 90 85 352 3 FINAL NOTE: IN THE EVENT COMPETITIVE NEGOTIATIONS FAIL WITH ADS TECHNOLOGY, TOTAL SCORES ARE USED TO BREAK THE TIE BETWEEN INTEGRATED SECURITYAND ALFIE ELECTRONICS. Respondent Ranking Order EVALUATION SCORING SHEET DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM Respondent Scores 191 THE OTY OF PLEASAJ\ T LM!'l{G 192 THE CITY OF PLEASANT LIVING FINAL Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www.southmiamifl .gov RFQ Title: DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ No.: RFQ #FN2022-I 9 DIRECTIONS: Please score each firm, for each specific criteria provided. Sco r ing is based on e a ch criteri a listed below with a max im um sco r e fo r each crite ri a . The total score for each proposer is ca lcu la ted by adding e a ch criteria fo r a total score by pr opos er. The maximum score totaJ score for each proposer is I 00 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; # I (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The Lowest Average Rank Score will be recommended for the award. Criteria ADS ALF I E INTEGRATED T EC H. SECURITY RESPONDENTS QUALIFICATIONS (Maximum Point Value -SO) i. Number of years of experience in the design and installation of security camera surveillance systems for residential and commercial applications. ~D Company and/or predecessors ,~D ~D must have at least five (5) years of experience in this field. V ii. Background in handling similar size projects: company must have successfully completed a project involving the a) commercial design and installation of a security camera surveillance system within the past five (5) years. iii . Degree of experience in all areas of a security camera surveillance design and installation process. V. Proof of satisfactory or better performance on contracts of similar scope and size: references and letters of reference must verify successful completion of similar projects . Page 1 of 2 193 b) vi. Number of similar projects: company and/or predecessors must have completed at least five (5) similar projects within the last 5 years . PROJECTS (Maximum Point Value-50) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, managerial approach, environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. 60 Page 2 of 2 Date: 194 THE CITY OF PLEASANT LIVING FINAL Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www.southmiamifl .gov RFQ Title: DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ No.: RFQ #FN2022-19 DIRECTIONS: Please score each firm, for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by adding each criteria for a total score by proposer. The maximum score total score for each proposer is I 00 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; # I (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The Lowest Average Rank Score will be recommended for the award. a) RESPONDENTS QUALIFICATIONS (Maximum Point Value -SO) i. Number of years of experience in the design and installation of security camera surveillance systems for residential and commercial applications. Company and/or predecessors must have at least five (5) years of experience in this field. ii. iii. Background in handling similar size projects: company must have successfully completed a project involving the commercial design and installation of a security camera surveillance system within the past five (5) years. Degree of experience in all areas of a security camera surveillance design and installation process. v. Proof of satisfactory or better performance on contracts of similar scope and size: references and letters of reference must verify successful completion of similar projects. I 'O ' 0 Page 1 of 2 195 b) vi. Number of similar projects: company and/or predecessors must have completed at least five (5) similar projects within the last 5 years . PROJECTS (Maximum Point Value -SO) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, managerial approach, environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. Total Score: Rani< 9 Additional Comments: ,.; Reviewed by: (Print Name) Page 2 of 2 .,_ Date: 196 RFQ Title: RFQ No.: FINAL Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www .southm iamifl .gov DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ #F N2022-19 DIRECTIONS: Please score each firm, for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by adding each criteria for a total score by proposer. The maximum score total score for each proposer is I 00 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; #I (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The Lowest Average Rank Score will be recommended for the award. ··-,_ ---~ - Criteria ADS ALFIE INTEGRATED TECH. SECURITY .. RESPONDENTS QUALIFICATIONS (Maximum Point Value -SO) i. Number of years of experience in the design and installation of security camera surveillance systems for residential and commercial applications . Company and/or predecessors must have at least five (S) years of experience in this field. ii. Background in handling similar size projects: company must have successfully completed a project involving the a) commercial design and installation of a security camera surveillance system within the past five (S) years. iii. Degree of experience in all areas of a security camera surveillance design and installation process. V. Proof of satisfactory or better performance on contracts of similar scope and size: references and letters of ~( ----reference must verify c_/D t./l. successful completion of similar projects . Page 1 of 2 197 b) Reviewed by: vi . Number of similar projects: company and/or predecessors must have completed at least five (5) similar projects within the last 5 years. PROJECTS (Maximum Point Value-SO) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, managerial approach, environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. Page 2 of 2 Date: /-71-27._ 198 THE CITY OF PLEASANT LIVING FINAL Evaluation Scoring Sheet Procurement Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www.southm iamifl .gov RFQ Title: DESIGN & INSTALL A PARKING GARAGE SECURITY SYSTEM RFQ No.: RFQ #FN2022-19 DIRECTIONS: Please score each firm, for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by adding each criteria for a total score by proposer. The maximum score total score for each proposer is I 00 points. Each Evaluation Selection Committee member shall rank each Respondent based on the Technical and Price Criteria total score for each Respondent; # I (Highest Total Score), #2 (Next Highest Score), and so on. The rankings for each Respondent by each Selection Committee Member (Rater) are added and totaled. The total is divided by the number of Raters. The Lowest Average Rank Score will be recommended for the award. Criteria. ADS ALFIE INTEGRATED TECH. SECURITY RESPONDENTS QUALIFICATIONS (Maximum Point Value -50) i. Number of years of experience 1.,15 in the design and installation of is 70 security camera surveillance systems for residential and commercial applications. Company and/or predecessors must have at least five (5) years of experience in this field. ii. Background in handling similar size projects: company must ti:) have successfully completed a 7,c.; 15 project involving the a) commercial design and installation of a security camera surveillance system within the past five (5) years. iii. Degree of experience in all \~ \ s areas of a security camera ' '? surveillance design and installation process. V. Proof of satisfactory or better ,o performance on contracts of \ t) s similar scope and size : references and letters of reference must verify successful completion of similar projects. Page 1 of 2 199 vi. Number of similar projects: company and/or predecessors must have completed at least ~D t0 \0 five (5) similar projects within the last S years. PROJECTS (Maximum Point Value -50) i. Evaluation of designs of similar scopes and size, constructability, phasing of the work staging and sequencing, \0 t0 b) managerial approach, \0 environmental control methods, work quality control, safety and construction schedule and understanding and awareness of permitting requirements. Total Score: l 00 toS C\ Rank \ 3 z_ Additional Comments: Reviewed by_: C A. '2 l o,:-:. \V1 p.. e. 6 ;-J C O -~_:_---=---:..,_;-=-:::;_-___ _ (Print Name) Page 2 of 2 Member Name City of South Miami Bid Number RFQ-RFQ #FN2022-18-0-2022/SK Bid Name DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM 24 Planholder(s) found 694 NOTIFIED SupplierNameFullNameEmail Address1 City StatePostalCode ADS Technology David suarezdavid@adstechsystems.com2520 Coral Way Miami FL 33145 DeclaredAttributes Alfi Electronics, Inc Samuel Benomtyoffice@alfielectronics.com3100 N 29th Court Hollywood FL 33020 AMERICAN INTEGRATED Levy Acslevyacs@gmail.com2253 VISTA PARKWAY NORTH West Palm Beach FL 33411 Small Business BidPrime API User API Userbptest@demandstar.com1301 S IH 35 Frontage Rd Austin TX 78741 Bryant Integrated Technologies Leon Chlimperleon@bryantintegrated.com1170 NORTH FEDERAL HWY Fort Lauderdale FL 33304 Canseco Electrical Contractors,Inc.Barbara Cansecobarbara@cansecoelectric.com7175 SW 43rd Street Miami FL 33155 Hispanic Owned, Small Business, Com-Tech Jay Hilljay.hill@com-tech.com124 Andrew Drive, Suite 100 Stockbridge GA 30281 Small Business, Woman Owned ConstructConnect ConstructConnect Bid Opportunitiescontent@constructconnect.com3825 Edwards Rd Cincinnati OH 45209 Dodge Data Bonny Mangolddodge.docs@construction.com4300 Beltway Place, Ste 150 Arlington TX 76018 Eyecast Milangela Moralesmmorales@eyecast.com9726 E Indigo St Palmetto Bay FL 33157 Geutebrück USA, Inc.Terry OttingerTerry.Ottinger@GeutebruckUSA.com537 US Highway 301 South Tampa FL 33619 Global Security Products Gary Lisciogl@paradyme360.com745 W SR 434 Longwood FL 32750 Veteran Owned IFSS John Petersonjpeterson@ifssi.com1970 Dana Drive Fort Myers FL 33907 Small Business, Veteran Owned Innuvo Inc.Aileen Livermanaliverman@innuvo.com3300 Corporate Ave Weston FL 33331 Small Business Integrated Security Systems Jennifer Medinajennifer.medina@convergint.com6300 SW 93 Ct Miami FL 33173 Interlink Group Professional Services, Jill Steinbergjsteinberg@interlinkgroup.net7825 NW 29TH STREET Doral FL 33122 Lumen Construction Services Rasheed Muslimanirkm@lumenccm.com6267 Sunset Drive Miami FL 33143 Regions Security Services, Inc.Carlos Rivero, Jr.crivero@RegionsSecurity.us1100 NW 72nd Ave Miami FL 33126 Hispanic Owned, Small Business, Snappy Internet & Telecom Frank Aquinobilling@snappytelecom.netPO Box 552186 Miami FL 33355 Southern Lock & Supply Company Pete Auseklispauseklis@southernlock.comPO Box 1980 Pinellas Park FL 33780-1980 Strategic Supplies and Services Peter Handstrategicsuppliesandservices@gmail.com115 Cottage Lane Nashville TN 37214 Sytec-USA, Inc Armando Garciamandy@sytecusa.com7141 N Waterway Dr Miami FL 33155 Hispanic Owned, Small Business TADEOS ENGINEERING LLC Luis De La Hozluis@tadeosengineering.com7910 NW 168th Terrace HIALEAH FL 33016 Triad Security Group Rob RYanrob.triad@gmail.com8450 W State Road 84 Fort Lauderdale FL 33324 2 Document(s) found for this bid 200 201 MIAMI -DADE STATE OF FLORIDA COUNTY OF MIAMI-DADE : Before the undersigned authority personally appeared MARIA MESA , who on oa th says that he or she is the LEGAL CLERK. Lega l Notices of the Mia mi Daily Bu siness Review f /k/ a Miami Review , a da ily (except Saturda y, Sunday and Legal Holidays) newspaper . published at Miami in Miami-Dade County. Florida ; that the attached copy of advertisem ent . be in g a Legal Advertisement of Notice in the matter of CITY OF SOUTH MIAMI -RFQ #FN2022-18 in the XXXX Court, was published in sa id newspaper by print in the iss ue s of and/or by pub li cation on the newspape~s website , if authorized , on 08 /05/2022 Affiant further says tha t the newspaper complies with all lega l for publication in cha pter 50. Florida 5 (S MARJA MESA personally known to me CITY OF SOUTH MIAMI DESIGN AND INST ALL A PARKING GARAGE SECURITY SYSTEM RFQ #FN2022-18 SUBMITTAL DUE DATE: SEPTEMBER 1, 2022 AT 10 AM The City is hereby requesting sealed proposals in response to this RFQ#2022-18, DESIGN AND INSTALL A PARKING GARAGE SECURITY SYSTEM. The purpose of this Solicitation is to contract for the serv ices necessary for the completion of the project in accordance with the Scope of Services, (EXH/BfT 1, Attachments A, B C & DJ and the plans and/o~ specifications, if any, described in this Solicitation (herein after referred to as 'the Project ' or "Project '). interested persons who wish to respond to this Solicitation can obtain the complete Solicitation package by accessing the following webpage: http://www.southmiamifl.gov/ which is the City of South Miami's web address for solicitation information. The City will only receiv e submittals electronically through the DemandStar Electronic Bid System IE-Bidding). To register as a business, go to ht!Q§://network.de andstar.com/ Proposals must be received electronically through DemandStar, no later than 10:00 A.M. local time (the "Closing Date") on September 1, 2022 and any Proposal received by the City through DemandStar after 10:00 a.m. local time on said date will not be accepted under any circumstances. Hand delivery will not be accepted . E-BID OPENING VIA VIDEO CONFERENCING: The opening of E-Bids for this solicitation will occur at 10:30 A.M . local time on (the Closing Date, September 1, 2022. The City Clerk will conduct the E-Bid Opening through video conferencing using the Zoom platfonn. Members of the public may view the meeting via Zoom at htt s://zoom. u~56636339, or listen to the meetin g on a dedicated phone li ne by dialing + 1-786-635-1003 Meeting ID : 3056636339. 8/5 Nkenga A. Payne, CMC, FCRM City Clerk, City of South Miami 22 -116/0000612695M 12/9/22, 2:08 PM Detail by Entity Name https://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directionType=Initial&searchNameOrder=ADSTEC…1/2 Document Number FEI/EIN Number Date Filed Effective Date State Status Department of State / Division of Corporations / Search Records / Search by Entity Name / Detail by Entity Name Florida Profit Corporation ADS TECHNOLOGY CORP Filing Information P08000017084 26-1979910 02/15/2008 02/16/2008 FL ACTIVE Principal Address 2520 SW 22 STREET 2-322 MIAMI, FL 33145 Mailing Address 2520 SW 22 STREET 2-322 MIAMI, FL 33145 Registered Agent Name & Address SUAREZ, DAVID C 2520 SW 22 STREET 2-322 MIAMI, FL 33145 Officer/Director Detail Name & Address Title P SUAREZ, DAVID C 2520 SW 22 STREET STE 2-322 MIAMI, FL 33145 Title VP DACOSTA, ANTHONY 2520 SW 22 STREET 2-322 MIAMI, FL 33145 D C Florida Department of State 202 '1 Ds 11m10N of r}jJJr ~.org LDJUJDJs .. /i'l'JD~t"'f~ wt vjfirl!JJ Sime oj Flvr/dl.J w?init? 12/9/22, 2:08 PM Detail by Entity Name https://search.sunbiz.org/Inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directionType=Initial&searchNameOrder=ADSTEC…2/2 Annual Reports Report Year Filed Date 2020 06/17/2020 2021 01/11/2021 2022 05/01/2022 Document Images 05/01/2022 -- ANNUAL REPORT View image in PDF format 01/11/2021 -- ANNUAL REPORT View image in PDF format 06/17/2020 -- ANNUAL REPORT View image in PDF format 04/04/2019 -- ANNUAL REPORT View image in PDF format 03/29/2018 -- ANNUAL REPORT View image in PDF format 04/30/2017 -- ANNUAL REPORT View image in PDF format 04/20/2016 -- ANNUAL REPORT View image in PDF format 01/13/2015 -- ANNUAL REPORT View image in PDF format 04/30/2014 -- ANNUAL REPORT View image in PDF format 04/26/2013 -- ANNUAL REPORT View image in PDF format 03/29/2012 -- ANNUAL REPORT View image in PDF format 03/16/2011 -- ANNUAL REPORT View image in PDF format 02/02/2010 -- ANNUAL REPORT View image in PDF format 06/25/2009 -- ANNUAL REPORT View image in PDF format 02/15/2008 -- Domestic Profit View image in PDF format Florida Department of State, Division of Corporations 203 2520 SW 22 STREET 2-322 MIAMI, FL 33145 Current Principal Place of Business: Current Mailing Address: 2520 SW 22 STREET 2-322 MIAMI, FL 33145 Entity Name: ADS TECHNOLOGY CORP DOCUMENT# P08000017084 FEI Number: 26-1979910 Certificate of Status Desired: Name and Address of Current Registered Agent: SUAREZ, DAVID C 2520 SW 22 STREET 2-322 MIAMI, FL 33145 US The above named entity submits this statement for the purpose of changing its registered office or registered agent, or both, in the State of Florida. SIGNATURE: Electronic Signature of Registered Agent Date Officer/Director Detail : I hereby certify that the information indicated on this report or supplemental report is true and accurate and that my electronic signature shall have the same legal effect as if made under oath; that I am an officer or director of the corporation or the receiver or trustee empowered to execute this report as required by Chapter 607, Florida Statutes; and that my name appears above, or on an attachment with all other like empowered. SIGNATURE: Electronic Signature of Signing Officer/Director Detail Date FILED May 01, 2022 Secretary of State 8858855248CC DAVID C SUAREZ PRESIDENT 05/01/2022 2022 FLORIDA PROFIT CORPORATION ANNUAL REPORT No Title P Name SUAREZ, DAVID C Address 2520 SW 22 STREET STE 2-322 City-State-Zip:MIAMI FL 33145 Title VP Name DACOSTA, ANTHONY Address 2520 SW 22 STREET 2-322 City-State-Zip:MIAMI FL 33145 204 205 MIAMI-DADE STATE OF FLORIDA COUNTY OF MIAMI-DADE: Before the undersigned au thority perso nally appeared GUILLERMO GARCIA , who on oath says that he or she is th e DIRECTOR OF OPERATIONS , Leg al Notices of the Miami Daily Business Re vi ew f/k/a Miami Review , a da il y (except Saturday , Sunday and Lega l Holidays) newspaper, publ ished al Miami in Miami-Dade County, Florid a; that th e attached copy of advertisement , be ing a Legal Advertisement of Notice in the matter of CITY OF SOUTH MIAMI -PUBLIC HEARINGS -DEC . 20 , 2022 in the XXXX Court , was published in said newspaper by print in the issues of and/or by publication on the newspaper's website , if authorized, on 12/09/2022 Affian\ fu rthe r says that the newspaper complies with all legal require ments for publication in chapter 50, Flori da Sta tute s. Swor and subscribed before me this 9 day of DECEMBER , A.D. 2022 GU ILL ERMO GARCIA persona lly known to me ,../~-~Y.~~---ROSANA SALGADO t_;(&)~} Commission # HH 336987 ·-~~,:;,·;1i.o.~~_.. Expires November 30 2026 ....... , . CITY OF SOUTH MIAMI, FLORIDA CITY COMMISSION NOTICE OF PUBLIC HEARINGS In order to balance the need for the City of South Miami to function and conduct vital business during the COVID 19 pandemic and, at the same time , to protect the health , safety and welfare of its citizens, officers, officials and admin istrative staff, and pursuant City of South Miam i Code , Chapter 286 .011 , Fla. Stat, the City's Home Rule Powers, and City Manager's declaration of a state of emergency due to the Coronavirus, the City will be holding its City Commission Meeti ng live in chambers and VIRTUALLY through communicat ions med ia technology (CMl) until the state of emergency has ended or social distancing is no longer requ ired by any relevant Executive Orders. All Commission members will participate in Chambers or by video conferencing through the Zoom platform and members of the public may join the meeting via Zoom at (htt s:/ zoom.usr/3056636338 and participate. At a minimum, at least three members of the City Commission will be physical ly present in the City Commission Chambers 1 and they will be broadcast on the Zoom platform along with all other members of the Commission, City Staff and the public who may attend remotely from the Commission Chambers and from other locations . 206 Ci+'/ of Sol)-\-v\ Miam\ Public Heav,ngs The meeting is scheduled to begin on Tuesda December 20 2 ....fil 7:00 .m. to consider the following public hearing item(s): A Resolution by the Mayor and City Commissioners of the City of South Miami authorizing the Mayor to negotiate and execute a multi-year emplo~ent contract with the City Manager In substantially the attached form. A Resolution authorizing the City Manager to enter into a multi-year lease agreement for City copiers onto a piggyback agreement with OMNIA Partners, a purchasing cooperative: A Resolution authorizing the City Manager to purchase and enter into a multi-year maintenance and service agreement with ADS Technology for the South Miami Par1clng Garage security system. Resolution relating to a Flnal Plat application ..to....Q!lo w.._a replat of a 0.954-acre property, comprised of three contiguous, vacant parcels bound by SW 64th Terrace to the north and SW 61st Court to the west of the three parcels, and as legally described herein. An Ordinance amending the City of South Miami, Florida, Code of Ordinances, Chapter 2, Article I, Section. 2-2.1 regarding rules of procedure of City Commission to conform to the November 8, 2022, Charter referendum concerning the number of required Commission meetings. An Ordinance amending the C i ty of South Miami Code of Ordinances, Chapter 2, Article Ill, and repealing Section 2-26.7 - Commercial Development Board and amending Section 2-26. 10 and converting the Par1clng Board Into the "Hometown District Advisory Board." An Ordinance of the City of South Miami, Florida, abandoning the north 5 feet of the right of way described as the South 10 feet of Lot 37 W. A. Larkins Subdivision as recorded at Plat Book 3 at Page 198 of the public records of Miami-Dade County, Florida. If you d esi re to present evidence or you are unable to use Zoom, there are procedures to follow and other options available including a dedicated phone line to listen and participate in the meeting and limited public attendance, all of which is set forth in the meeting notice posted at City Hall and at httP.://www.sout mia 'fl. ov/580/Public-Meetin s-Noti ces. Anyon e who wishes to rev iew pend ing application, supporting documen ta tion or who desi re to have documents made available for viewing by everyone during th e mee ting must contact the City Clerk by calling 305-663-6340 . Note tha pu uant to Florida Statutes 286.0105, a person who decides-to appeal any decis ion made by a Board , Agency or Commiss ion with respect to any matter considered at its meeting or hearing, a record of the proceedings will be required for sai d appeal and such person will be required to have a verbatim transcript of the proceedings Inc lu ding the testimony and evidence upon which the appeal is to be based . ADA: To request a modification to a policy, practice or procedure or to re- quest an auxiliary aide or service in order to participate in a City program , activity or event, you must on or before 4:00 p.m. 3 business days before the meeting (not counting the day of the meeting) deliver your request to the City Clerk by telephone: 305-663-6340, by mail at 6130 Sunset Drive , South Miami, Florida or email at npayne@southmiamifl .gov. NkengaA. Payne, CMG, FCRM City Clerk 1 The minimum standards for adopting a ll:Solution or enacting an ordinance are set forth in 166.041(4) ... A majority ol the members of the governing body shall constitute a quorum . An affirmativa vote of a maprity of a quorum present is necessary to enact any ord inance or adopt any resolution . •- 12/9 22-57l0000635324M SUNDAY DECEMBER 11 2022 NEIGHBORS ...................................................................................................19SE 207 MIAMI-~ C o m m u n i t y C o u. n c i I I cmmmiiiil' B o a rd Va c a n c I e s I Several Community Councils are accepting applications for appointments to the following subareas: Community Council 2 (Northeast) Subarea-23 Subarea-24 Subarea-26 Community Council 5 (Country Club of Miami) Subarea-53 Community Council 7 (Biscayne Shores) Subarea -71(a) Subarea -71(b) Subarea -72(a) Subarea -72(b) Subarea -73(a) Subarea -73(b) Community Council 8 (North Central) Subarea-81 Subarea -85 Subarea -At-Large Community Council 10 (Westchester) Subarea -101 Subarea -103 Subarea -105 Community Council 11 (West Kendall) Subarea -112 Subarea -113 Subarea -115 Subarea -116 Subarea -At-Large Community Council 12 (Kendall) Subarea -124 Community Council 14 (Red land) Subarea -141 Community Council 15 (South Bay) Subarea -155 Subarea -156 Community Council 16 (Fisher Island) Subarea -161-(b) Subarea-161-(f) Applicants must be registered voters and reside within the physical boundaries of the Council area for at least six (6) months prior to appointment, and for at least three (3) years as a resident elector of Miami-Dade County. An appointment to the vacancy will expire upon the certification of the 2024 primary election. For more information, interested candidates should contact the Zoning Agenda Coordinator's Office of the Miami-Dade County Department of Regulatory and Economic Resources (RER) at 305-375-1244. Candidates will be required to submit a copy of their voter registration card, photo ID and an updated resume to the Zoning Agenda Coordinator's Office at Stephen P. Clark Center, 111 NW 1st Street, 11th Floor, Miami, Florida 33128. Miami-Dade County employees are not eligible. For legal ads online, go to~ CITY OF SOUTH MIAMI, FLORIDA CITY COMMISSION NOTICE OF PUBLIC HEARINGS In order to balance the need for the City of South Miami to function and conduct vital business during the COVID 19 pandemic and, at the same time, to protect the health, safety and welfare of its citizens, officers, officials and administrative staff, and pursuant City of South Miami Code, Chapter 286.011, Fla . Stat, the City's Home Rule Powers , and City Manager's declaration of a state of emergency due to the Coronavirus, the City will be holding its City Commission Meeting live in chambers and VIRTUALLY through communications media technology (CMT) until the state of emergency has ended or social distancing is no longer required by any relevant Executive Orders . All Commission members will participate in Chambers or by video conferencing through the Zoom platform and members of the public may join the meeting via Zoom at (https ://zoom.us/j/3056636338) and participate. At a minimum, at least three members of the City Commission will be physically present in the City Commission Chambers' and they will be broadcast on the Zoom platform along with all other members of the Commission, City Staff and the public who may attend remotely from the Commission Chambers and from other locations. The meeting is scheduled to begin on Tuesday, December 20, 2022, at 7:00 p.m. to consider the following public hearing item(s): A Resolution by the Mayor and City Commissioners of the City of South Miami authorizing the Mayor to negotiate and execute a multi-year employment contract with the City Manager in substantially the attached form. A Resolution authorizing the City Manager to enter into a multi-year lease agreement for City copiers onto a piggyback agreement with OMNIA Partners, a purchasing cooperative. A Resolution authorizing the City Manager to purchase and enter Into a multi-year maintenance and service agreement with ADS Technology for the South Miami Parking Garage security system. A Resolution relating to a Final Plat application to allow a replat of a 0.954-acre property, comprised of three contiguous, vacant parcels bound by SW 64th Terrace to the north and SW 61 st Court to the west of the three parcels, and as legally described herein. An Ordinance amending the City of South Miami, Florida, Code of Ordinances, Chapter 2, Article I, Section. 2-2.1 regarding rules of procedure of City Commission to conform to the November 8, 2022, Charter referendum concerning the number of required Commission meetings. An Ordinance amending the City of South Miami Code of Ordinances, Chapter 2, Article Ill, and repealing Section 2-26.7 -Commercial Development Board and amending Section 2-26.10 and converting the Parking Board into the "Hometown District Advisory Board." An Ordinance of the City of South Miami, Florida, abandoning the north 5 feet of the right of way described as the South 10 feet of Lot 37 W. A. Larkins Subdivision as recorded at Plat Book 3 at Page 198 of the public records of Miami-Dade County, Florida. If you desire to present evidence or you are unable to use Zoom, there are procedures to follow and other options available including a dedicated phone line to listen and participate in the meeting and limited public attendance, all of which is set forth in the meeting notice posted at City Hall and at http://www.southmiamifl.gov/580/Public-Meetings-Notices. Anyone who wishes to review pending application , supporting documentation or who desire to have documents made available for viewing by everyone during the meeting must contact the City Clerk by calling 305-663-6340. Note that pursuant to Florida Statutes 286.0105, a person who decides to appeal any decision made by a Board , Agency or Commission with respect to any matter considered at its meeting or hearing, a record of the proceedings will be required for said appeal and such person will be required to have a verbatim transcript of the proceedings including the testimony and evidence upon which the appeal is to be based. ADA: To request a modification to a policy, practice or procedure or to request an auxiliary aide or service in order to participate in a City program , activity or event, you must on or before 4:00 p.m. 3 business days before the meeting (not counting the day of the meeting) deliver your request to the City Clerk by telephone: 305-663-6340, by mail at 6130 Sunset Drive, South Miami, Florida or email at npayne@southmiamifl.gov. Nkenga A. Payne, CMC, FCRM City Clerk 'The minimum standards for adopting a resolution or enacting an ordinance are set forth in 166.041(4) -A majority of the members of the governing body shall constitute a quorum. An affirmative vote of a majority of a quorum present is necessary to enact any ordinance or adopt any resolution.•-- 99 of 162 208 r;;;;===============================================================================================;=======================;;:::::==================-----------;;;,;:,;--~-;;.;-===;;;;,-, Ir ___ ._. __ ...,, oc ::i Q; O; :r;! co: Lf) ' 1 ;· I .,.,..,.,·,.... 11 Ll:-53-,,,;i c~.J~ILI ••-ci \~.~~ -- ' -' C BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305-444-4433 fax 305-444•0181 EMAIL: bdamiamiObellsouth.net IBJ ;---. f / / ---------· ------------ ·-·-- ······· _i,if;\V_ SEC,TIONN-!l!NG 'J ~f~ru:R::DED ' ··OQ- / Client: 1-5' P\iC SCHEDULtEao -, ,, SER,1CE 24' MINIM!)J,l BU.( • GRADE TO N~ UT!,jli' f9I l .. t .. ◄/\. PROVIDED BY' F.P.W ,t ,_, -• ~ - •>• ·-- '""--~ ·•·-...... ---•·•---'~·'· .:. ,_ • ., ··'·· •.,,,"J.~:;.•···· '-"~~--•''"'''''' ',' 1 -~-.r---:::·~---::-~: -----,J ___ ,c,s_~ - / N105 [f]<l75cd N104 ! 75cdl::{!f _,,.. N / M I II ,l 511,TCH N108 7 5cd t::ill!) 109 L1-32 R ~ NEW OVERHEAD-----+_,... SER'/ICE FOR EXISTING \ TENANT TO BE PROVIDED BY F.P.L ~ /7 j ~ NEWIJTIUli'PQE------ PROl-1DED BY F.P.L. -• · Nl 10 J™ 75cd N109 , ?lied [::{!] : OJ I' ' FIRST LEVEL ELECTRICAL POWER PLAN SCALE 3132' 0 1 '-0' WITH Proposed New Project City of South Miami . <l' <l' NEW OVERHEAD----=/f- SER'/ICE FOR EXISTING TENANT TO BE PROVIDED BY F.P.L. / PB FR DA Mi '10 T -.. N112 . ·-' 75cd F / PROVIDE 2.0' E.M.T. EMPli' CONDUIT FROM ELECTRICAL' SER'/ICE TO FUTURE TENANT o PROVIDE 1.0' E.M.T. EMPTt CONDUIT FROM TELEPHONE BOARD TO FUTURE TENANT! / PROVIDE 2.0' E.M.T. EMPli' CONDUIT FROM ELECTRICAL SER'/ICE TO FUTURE TENN{T o---_,,1R0"1DE 1.o• E.M.T. EMPr/ CONDUIT FROM TELEPHONE' BOAAD TO FUTURE TENANT' IT] II] 'v·· ... ·-_ -PROVIDE 2.0' E.M.T. EMPlY ,, , -, CCNDUIT FROM a..ECTRICAL ! SERVICE TO FUTURE TENANT 1>----,ROVIDE 1.0' E.1,1.T. EMPli' CCN DUIT FROM TELEPHONE BOARD TO FUTURE TENA/IT ~--PR0"1DE 2.0' E.M.T. EMPTY CONDUIT FROM ELECTRIC.Al.. SER'/ICE TO FUTURE TENANT ~--PROVIDE 1.0' E.M.T. EMPli' CONDUIT FROM TELEPHONE BOARD TO FUTURE TENANT Nl 15 [ID'.)<175cd J12 [ill ,~, ·x.__ ·-· ..... . Ll:c66. @] rn:::J M. N119 ' 7 5cd t::ill!) : 116 date September 01, 2006 sheet title rexlslon Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility __LZ::,_ GENERAL REVISION 09/05/06 Q\ COOROINATION 11/15/06 /4\ OWNER CIWJGES 01/09/07 ,15\ OWNER CIWJGES 02/22/07 ELECTRICAL PO WE R PLAN S.W. 73rd Street & 58th Avenue, South Miami, Florida project number 20058'9 drawn by ZM (f) ! C: t /( ' ' i i SCALE : AS SHOWN sheet number E-1.1P 102 of 162 209 BLITSTEIN DESIGN ASSOCIATES AR0007570 i I \,7l5cd ' \ \ ELEV1 L1-1 . ·····1.....-.,,i.····· ' I !I ' ~ \ ' \ ·re]~ -·· ' \ \ \ ' Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida , ,. i ·='~"'1''" T . : . .:. ~. ;.:. ... ····· ···················7~·= == ..., ~~· . . ..... f' / t / h ;-······· -··.J '''-:,; ···----··-7 ,./ ......... :·:·~· CXJN0,-1 ""1 illllllED .. r_,, N ,, J/ ' i ~--IUI 1" ~ CONDUIT 10 IWW:ER'S OFFICE ON FIRST Fl.OOR. SEE TYPICAL RISER ON DRAWING E6.0. PR<MDE 1~" Elf'1Y CONOUT ALONG lHIS CENTER W,11,L ON EAClt F1.00R FROM lHE SECOND lHRU FOURTH, .. ,,_.,,.. " ,,,_ ....... =:.:...:::;:;:..:.::::::::.:..-_-,;J,' ,_.., _____ _,_11',_'.0cd,,, . • ,, " '······'"'············-' @ii!ii(...... ........ . .....••... WWWiii • ,,_., ,,,,..---.. ,,,.,,...,•· ,,.,..-,, r-------.. r:./ I ' I I I I / ' / ' I / ' ' ' I // I I I I I (I) SECOND LEVEL ELECTRICAL POWER PLAN SCALE: 3132" a 1 '-0" WITH Proposed New Project City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility ..... ·····················.-.............. . I ! I i ! ' ! / I ! ' ! ! I N206 I ! i ! I ' / I ! I ; ! ! ·-,,·-·· \ I I I I ! I ; I ! / ! / \ \ .. \ I I ' ' / ' I ' \ \ \ !----····. ·+···· \ ..... 11@4</M .... K.M ..•.... date September 01, 2006 rexlslon ...1£..._ OWNER CHANGES 02/21/07 sheet title ELECTRICAL POWER PLAN I !j I j I I , ,ao ,,,., a AlffllM1ll IIDKEII ; N IEM 1 en CRPF int stUfT i 111P II IEIES 11111 1HE IF-UmrtR i!IDE: 1--IIDIN FM: FEEi' 0f .... ...._ IP/100,, IEM' DUIY FUSED = r:;-:.;;,,ri: ~ SCALE : AS SHOWN sheet number E·2.1P 104 of 162 210 J BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 SeYlla Aveooe Coral Cables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamiamiobellsouth.net IT1 Ii I i I. 75cd l2-25 !Ill I ~ ... ~.:.. [~; 1 -.,. !:t ELEV 1~ 'i! I !1 . ·, ... , .. ,, .. ' ~/1 ~;l ~/! /, I 11 / /! N.302 NJQ1 \ \ \,H_,_ :';TR:!PING '."1WJ Client: 1 Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida ............ ~,-z ........ •.• .... , ''-··· i On all w,1lkhg st•tf~oos iv1th a s!or>o cf !am~ uian 5% · prr:nM.18'! a ':li1p resii>.tJrnt fihL<;~. des-:.·Mbml -"~ 8 med11;m , salted foish, __ we __ ! On all surtooos with a Ai¢pe greater t!1an 6%. provide a slip ! re5is!.8.r1t fi,.,ish. ' i Oo not a!k,w any cross ~l◊pl"Ji'. to m«'.eed 114" per foot or 2tr~. . =;=•·••■§· .. ·•···=•=••··· § .. § .... ~·=•--·~··• .... ~, .. ~c.~~--· .... ~. ~= -l ........ ···""l!l, ... ,-... •· .•. ~.······. -;,:~_:_::_::_:_::····· .. ,.--.--.--''-""="S~•;;ss-;,\"'~ ' \ \ N ""'··········-····· ..... : ~RE--C .. ST F.Yf:BRfl'N W: Oi::'.OORArlVE H.MlJNO CD TffiRD LEVEL FJ ECTRICAL POWER PLAN WITH Proposed New Project SCALE• 3132" = 1'-0" City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida --------- ·-·7 1z=,~=·:•·•·"'""" N.306 N.305 x.=El /]~ .. / date September 01, 2006 rexlslon ...ill__ OWNER CHANGES 'YJ./22/07 ' 4- I :::.::•::::t2",• sheet tltle ELECTRICAL POWER PLAN project number 2tZJtZJ5~ drawn by ZM A :i iii I! I l' ! ' ' I 1 H ' II 1· '. I SCALE : AS SHOWN sheet number E-3.1P 106 of 162 211-■l!1itl Ill FJECIBO\. ~ Slll.Ei\i\.i BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevllla Avenue Coral Gables, Fl 33134 305 444 4433 fax 305 444-0181 EMAIL: bdamlamobellsouthnet ' J / l ; l -; (' 'i I ' ; / ! /,/ _______ _ L2-5 \ \ ' ' F= --. ··--,) .... -... -'._ Wt . ~ . ~ WILLIAM A BERRY & ASSOCIATES'. ~ CONSULTING ENGINEERS : -_ 10200 NW 25111 STREET, SUITE 111 -, DORAL, FL 33172 - TELEPHONE: 305-513-9000 ·- FAX: 305-513-9100 M EB 0006543 --0971 ELIZABETH l PRIOA P-E-#59464 Client: Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue Miami, Florida WITH N ' ' / ' ' ' / y ....,_4 ___ :_ .. ,.,...~J ' : i """"'~""''""f""·~ \ l ! ······' ' Cl) IOURTH LEVEL FT F.ClRICAL POWER PLAN Proposed New Project ,-··-··-··-···----··~------" SCALE: 3132" = 1'-0" E'.:I ··~ii%>1H'"" ............... ::r:::: \ \ \ \ \ \ -- ,---i---·f -, i - I / I i ! I I \ / ~1;·~~-«<=~l ;._;;;;;; ,,i,_\\ /Cb,.,.,,,~; ... -_.,,_-~ .. ~;;; i=====::===:::====±= I date September 01, 2006 ' _! I ! ! ! City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility rexlslon ...LJi::i_ OWNER CHANGES 02/22/07 S.W. 73rd Street & 58th Avenue, South Miami, Florida \ \ \ -\ \ \ \ \ \ \ \ \ \ \ \ \ \ \ I I i \, \ ! ! / ' i ' -·······'-" ....... _ .~. . ~::>¼ sheet title ! ELECTRICAL POWER PLAN project number 20058'3 .i ... _ I drawn by ZM \ ' \ \ \ \ ' \ \ \ \ \ \ \ \ ~ i - i SCALE : AS SHOWN sheet number E·4.1P 108 of 162 212 m B C BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Sevilla Avenue Coral Gables, Fl 33134 305•444-4433 fax 305-444-0181 EMAIL; bdamiamiObellsouthnet 1 2' / " . -, ! r • ,i, , I'. ---' --, -,. -~-----, --,- •--~-~-~ .......... --------------·· ----, _________ ., __ ~--=·---~~, . ' --,· r --I ·;··· --' - :---1-----·-----·' ·--------------···-------------·----·-·--------··· --~--·----·-.. --· --,----------... ----·----·--·---_, ____ _ >·.• -----____ L =---»'>...~= ·--' --...... . ,,..,.~li·•=•"< ---------~--~~,.-e..d.,_, --------t- . 7 8 9 -.... ,.- . ---' ··---------~-----...... ---. ------------·--. -------------·--· · -· ~-------------, --"-·-· ---------, i -------J .. \----' .. -· --. ---.-·--,------r ------'' ' - - . ----.. , , __ 1---·-. --_-,.-•-7 ---------·--------------"--~---~~-' l2-.1 , .11\Jf.d ! ·-• ; . . . . .• . . .,. 11QcdJ.i~3 ~= --~--=,--, -==~_:;._;-_::._:_;,::: -·---·----'-f.,;;~,::7 ,.. .• ,,~~~"' "-~""'•''"'";"' :;,_=::.r=-:-_::_;;., "'-=""-"''-~·--"-= ~~----~ i, ::;;,_~...,:~--;;:_:_::;_] ' ' ·---. --' Client: ·-.-,---.----., --t···· --. , ·····------·-----+-------·--·-, .. -------·----· ------------------------------------- - ---------~ ----·------.. --------·-· --·----------T------·--·------------ -------------• .. -i -.------~ ·---···---··---,..,. __ .. _, ---------------·-' ----' ____ ; _____ ._ -' __ ·- ' ' ' ··-·---.. ..,--,----------·-·--- . . . ! N ' ---···-~ -~-- - . ,-. --~ - - ------' -·----·. -··----. c._--,,.·-·· ,-~-, -, --- -· -------___ .J (DFIFTH LEVEL ELECTRICAL POWER PLAN SCALE: 3/32" = 1'-0" WITH Proposed New Project L:Z-3 I \ ---L· ____ -< -----' -'---'--·'-----' Mr. Mark Richman M.R. Properties Inc. 18500 NE 5th Avenue City of South Miami 6130 Sunset Drive South Miami, Florida 33143 South Miami Municipal Parking Facility Miami, Florida S. W. 73rd Street & 58th Avenue, South Miami, Florida d a t e September 01, 2006 rex.ision __fsi::,.___ OWNER CHN-IGES 0'2/22/07 / . · ., ' ·.10 -~-' ------------~ ... - I sheet title ELECTRICAL POWER PLAN profect number 20058,S drawn by ZM _..._,._,. .. 1 1 : ! ''' .-- 'i. SCALE : AS SHOWN sheet number E-5.1P 62 of 162213 1!1ti ,-----BLITSTEIN DESIGN ASSOCIATES AR0007570 ARCHITECTURE INTERIOR DESIGN 285 Se-.illa Avenue Coral Cable,, Fl 33134 30~ fax 305-444-0181 EMAIL: bdamlamlObetlsouthnet .J.ltlll'L l!llllilfi i ;r-~,,F=---~l-r,.."11 I +------& ~ 1 g ' & @ • ~ ~ ~ :;; a ~ --~ • Proposed New Project @STAIR 1 SECTION ""''·""' South Miami Municipal Parking Facility S.W. 73rd Street & 58th Avenue, South Miami, Florida rn i 19 ~.'.-n.~~PARlll);(I / .-~L_. __ ---1 mc,--,,,.',r7J'l'l, -~ ·-·-··-·-••i-----·· ,~I I i ,_ -·j.· !' ! date May17,2006 rtvlslon 1-i & ¥ ~ , ........ --f.l_:~~11 * @STAIR 2 SECTION ,hut title STAIR TOWERS p1oj1ct numbu drawn by D.M.