2Agenda Item No:2.
City Commission Agenda Item Report
Meeting Date: September 15, 2020
Submitted by: Aurelio Carmenates
Submitting Department: Public Works & Engineering
Item Type: Resolution
Agenda Section:
Subject:
A Resolution authorizing the City Manager to negotiate and enter into a contract with UAG Construction LLC.,
for the Sunset Drive median landscape improvements from SW 69th Avenue to US-1 and roadway modification
to the alignment along Sunset Drive from SW 62nd Avenue to East of SW 61st Court. 3/5 City Manager-Public
Works & Engineering)
Suggested Action:
Attachments:
Memo Const Award Sunset btwn 69av to us1 (9-10-20)PWD-Final.docx
Reso_Const_Award_for_Sunset_btwn_69av_to_us1__9-10-20_PWD-Final (1).docx
RFP v3 FINAL Sunset Drive Modifications6.30.20CArevPWD.pdf
Sunset Drive Modifications_Complete Set_20200624.pdf
UAG CONSTRUCTION Bidding Document (26).PDF
Pre-Bid Meeting RFP PW2020-19 8.25.20 .pdf
DEMAND STAR RFP PW2020-19.pdf
SUN BIZ UAG CONSTRUCTION 9.3.20.pdf
2020.08.20 Miami Daily Business Review RFP #PW2020-19.pdf
1
CITY OF SOUTH MIAMI
OFFICE OF THE CITY MANAGER
INTER-OFFICE MEMORANDUM
TO:The Honorable Mayor & Members of the City Commission
FROM:Shari Kamali, City Manager
DATE:September 15, 2020
SUBJECT:A Resolution authorizing the City Manager to negotiate and enter into a contract with
UAG Construction LLC., for the Sunset Drive median landscape improvements from SW
69th Avenue to US-1 and roadway modification to the alignment along Sunset Drive
from SW 62
nd Avenue to East of SW 61st Court.
BACKGROUND:In an effort to provide options for the City Commission to consider,the City’s solicitation
required respondents to provide prices for different sections of the project as detailed
below:
Option A consists of roadway modification/re-alignment and minor
landscape improvement on Sunset Drive between US-1 and SW 62nd
Avenue.
Option B consists of landscape improvements on Sunset Drive median
between SW 62nd Avenue and SW 69th Avenue and the third
Option C is the completion of the entire project, Option A and Option B.
The City issued a work order to a professional engineering firm selected during the
CCNA process to design and developed construction drawings. The design and
construction documents were approved by City Staff and Miami-Dade County
Department of Transportation and Public Works.
The City received a total of five (5) proposals in response to a solicitation. Two of the
five proposals received were incomplete and removed from further consideration.
Pursuant to review, it was determined that UAG Construction LLC., is the most
responsive and responsible bidder for this proposal.
The City reserves the right to award the project to a single respondent for each option.
Option A, Option B,or Option C. Also, one respondent may be awarded one Option and
another Respondent may be awarded another Option.
The City recommends UAG Construction LLC for all three options.
Below please find the Qualified Proposals Received as part of the solicitation:
2
CITY OF SOUTH MIAMI
OFFICE OF THE CITY MANAGER
INTER-OFFICE MEMORANDUM
A contingency amount of five percent (5%) will be included over the proposal amount
of $459,900.52 to address for unknown factors that may arise during the work.
AMOUNT:Amount up to $ 482,895 which includes a five percent (5%) for contingency.
FUND &ACCOUNT:The expenditure shall be charged $200,000 to the to the Capital Improvement Program
Fund account number 301-1730-541-6450, $150,000 to the Local Option Gas Tax Trust
Fund account number 112-1730-541-6210, and $133,000 to the Capital Improvement
Program Fund account number 301-1790-519-6450.
ATTACHMENTS:Resolution
RFP PW2020-19 Construction Documents with Exhibits
Design Plans
UAG Construction LLC., Proposal
Virtual Pre-bid Sign in sheet
Demand Star Results
Sun Biz, UAG Construction LLC
DRB Advertisement
Contractor Bid Price Option A Bid Price Option B Bid Price Option C
UAG Construction LLC $183,500.98 $276,399.52 $459,900.50
C & I Construction $228,440.00 $352,337.00 $580,777.00
Visual Scape NO BID $546,698.90 NO BID
3
Page 1 of 2
RESOLUTION NO.:______________________1
2
A Resolution authorizing the City Manager to negotiate and enter into a contract with UAG 3
Construction LLC., for the Sunset Drive median landscape improvements from SW 69th Avenue 4
to US-1 and roadway modification to the alignment along Sunset Drive from SW 62nd Avenue to 5
East of SW 61st Court. 6
WHEREAS,the City Mayor and Commission desires to provide landscape improvements on Sunset Drive 7
between SW 69th Avenue and US-1 similar to the existing landscaping within the City limits along US-1 and modify 8
the roadway alignment along Sunset Drive from SW 62nd Avenue to East of SW 61st Court; and 9
WHEREAS, the City Commission budgeted for this project in the Capital Improvement Program 5-Year 10
Plan; and11
WHEREAS,the City issued a work order to a professional engineering firm selected during the CCNA 12
process to design and developed construction drawings; and13
WHEREAS,design and construction documents were developed and approved by City Staff and Miami-14
Dade County Department of Transportation and Public Works; and15
WHEREAS,to provide options for the City Commission to consider, the City’s solicitation required 16
respondents to provide prices for different sections of the project; and17
WHEREAS, option A consists of roadway modification/alignment and landscape improvement on Sunset18
Drive between US-1 and SW 62nd Avenue. Option B consists of landscape improvements on Sunset Drive between 19
SW 62nd Avenue and SW 69th Avenue and the third Option C is the completion of the entire project, Option A and 20
Option B; and21
WHEREAS,the City received a total of five (5) proposals in response to a construction solicitation; and22
WHEREAS,two of the five proposals received were incomplete and removed from further consideration; 23
and24
WHEREAS,the City reserves the right to award the project to a single respondent for each option. Option 25
A, Option B, or Option C. Also, one respondent may be awarded one Option and another Respondent may be 26
awarded another Option; and27
WHEREAS,the City recommends UAG Construction LLC for all three options for an amount up to $482,895 28
which includes a five percent (5%) contingency for unknown factors that may arise during the work; and29
WHEREAS,the Mayor and Commission desire to authorize the City Manager at her discretion to allow 30
work on Saturdays; and31
WHEREAS, the Mayor and City Commission desire to authorize the City Manager to negotiate and enter 32
into a contract with UAG Construction LLC., for the median landscape improvements on Sunset Drive between SW 33
69th Avenue and US-1 and roadway modifications along Sunset Drive from SW 62nd Avenue to EastofSW 61st Court34
for an amount up to $482,895 which includes a five percent (5%) for contingency for unknown factors that may 35
arise during the work36
WHEREAS, the expenses shall be charged $200,000 to the to the Capital Improvement Program Fund 37
4
Page 2 of 2
account number 301-1730-541-6450, $150,000 to the Local Option Gas Tax Trust Fund account number 112-1730-1
541-6210, and $133,000 to the Capital Improvement Program Fund account number 301-1790-519-6450.2
3
NOW THEREFORE, BE IT RESOLVED BY THE MAYOR AND CITY COMMISSIONERS OF THE CITY OF SOUTH 4
MIAMI, FLORIDA:5
Section 1. The foregoing recitals are hereby ratified and confirmed as being true and they are incorporated 6
into this resolution by reference as if set forth in full herein.7
Section 2.The City Manager is authorized to negotiate the price, terms and conditions and to execute a 8
contract with UAG Construction LLC., for the Sunset Drive median landscape improvements from SW 69th Avenue 9
to US-1 and roadway modification to the alignment along Sunset Drive from SW 62nd Avenue to East of SW 61st 10
Court for an amount up to $482,895 and a five percent (5%) for contingency for unknown factors that may arise 11
during the work. A copy of the approved form of contract is attached. The expenditure shall be charged $200,000 12
to the to the Capital Improvement Program Fund account number 301-1730-541-6450, $150,000 to the Local 13
Option Gas Tax Trust Fund account number 112-1730-541-6210, and $133,000 to the Capital Improvement Program 14
Fund account number 301-1790-519-6450.15
Section 3. Corrections. Conforming language or technical scrivener-type corrections may be made by the 16
City Attorney for any conforming amendments to be incorporated into the final resolution for signature.17
18
Section 4:Severability.If any section, clause, sentence, or phrase of this resolution is for any reason held 19
invalid or unconstitutional by a court of competent jurisdiction, the holding shall not affect the validity of the 20
remaining portions of this resolution. 21
22
Section 5: Effective Date:This resolution shall become effective immediately upon adoption. 23
24
25
PASSED AND ADOPTED this _____ day of_______________, 2020. 26
27
ATTEST: APPROVED: 28
29
___________________________________________30
CITY CLERK MAYOR31
32
READ AND APPROVED AS TO FORM,COMMISSION VOTE: 33
LANGUAGE, LEGALITY AND EXECUTION Mayor Philips: 34
THEREOF Vice Mayor Welsh:35
Commissioner Harris:36
___________________________Commissioner Liebman: 37
CITY ATTORNEY Commissioner Gil:38
39
5
CITY OF SOUTH MIAMI
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
SUBMITTAL DUE DATE: September 3, 2020 at 10 AM
Solicitation Cover Letter
The City of South Miami, Florida (hereinafter referred to as “Owner”) through its chief executive officer (City
Manager) hereby solicits sealed proposals responsive to the City’s request (hereinafter referred to as “Request for
Proposals” or “RFP”). All references in this Solicitation (also referred to as an “Invitation for Proposals” or
“Invitation to Bid) to “City” will be a reference to the City Manager, or the manager’s designee, for the City of
South Miami unless otherwise specifically defined or unless the context in which the word is used requires it to
mean the City of South Miami.
The City is hereby requesting sealed proposals in response to this RFP #PW2020-19 “SUNSET DRIVE
ROADWAY & LANDSCAPING MODIFICATIONS” project. The purpose of this Solicitation is to contract
for the services necessary for the completion of the project in accordance with the Scope of Services, (EXHIBIT
1, Attachments A, B, & C) and Respondent’s Cost and Technical Proposal, or the plans and/or specifications, if
any, described in this Solicitation (hereinafter referred to as “the Project” or “Project”).
Interested persons who wish to respond to this Solicitation can obtain the complete Solicitation package by
accessing the following webpage: http://www.southmiamifl.gov/ which is the City of South Miami’s web address
for solicitation information. Proposals are subject to the Standard Terms and Conditions contained in the complete
Solicitation Package, including all documents listed in the Solicitation.
The City will only receive submittals electronically through the DemandStar Electronic Bid System
(E-Bidding). To register as a business, go to https://network.demandstar.com/ See directions for registering
and signing into your DemandStar user account on the next page following this Solicitation Cover Let ter.
Proposals must be received electronically through DemandStar, no later than 10:00 A.M. local time (the
“Closing Date”) on September 3, 2020 and any Proposal received by the City through DemandStar after 10:00
a.m. local time on said date will not be accepted under any circumstances. Hand delivery will not be accepted.
BID OPENING VIA VIDEO CONFERENCING:
The opening of E-Bids for this solicitation will occur at 10:30 A.M. local time on (the Closing Date, September
3, 2020. The City Clerk will conduct the Bid Opening through video conferencing using the Zoom platform.
Members of the public may view the meeting via Zoom at https://zoom.us/j/3056636339 ,or listen to the meeting on
a dedicated phone line by dialing +1-786-635-1003 Meeting ID: 3056636339.
NON-MANDATORY PRE-BID MEETING VIA VIDEO CONFERENCING
A Non-Mandatory Pre-Bid meeting will be conducted through video conferencing on August 25, 2020 at
10:00 AM using the Zoom platform. Interested parties who are considering attending the Pre -Bid
meeting, must identify your Company Name in the “Participants List” on the Zoom platform. The
meeting will be held regardless of weather conditions. After the meeting, an email will be sent, confirming your
attendance, to the attention of Steven P. Kulick, Chief Procurement Officer at skulick@southmiamifl.gov
Members of the public may view the meeting via Zoom at https://zoom.us/j/3056636339 ,or listen to the meeting on
a dedicated phone line by dialing +1-786-635-1003 Meeting ID: 3056636339.
The City reserves the right to award the Project to the person with the lowest, most responsive, responsible
Proposal, as determined by the City, subject to the right of the City, or the City Commission, to reject any and all
proposals, and the right of the City to waive any irregularity in the Proposals or Solicitation procedure and subject
also to the right of the City to award the Project, and execute a contract with a Respondent or Respondents, other 1 of 118 6
than to the one who provided the lowest Proposal Price and, if the Scope of the Work is divided into distinct
subdivisions, to award each subdivision to a separate Respondent.
Nkenga A. Payne, CMC
City Clerk
City of South Miami
2 of 118 7
DemandStar Registration and User Account Sign-in Directions
The following is an example of the procedure on April 3, 2020 and it is subject
to change after that date.
Go to https://network.demandstar.com/ which on April 3, 2020 brings up the
following message.
If you do not have an account with DemandStar, click on “Create Your
Account” otherwise, if you have an account, click on the “x” in the upper right-hand
corner of this message and it will bring you to the following user sign in page.
3 of 118 8
SCOPE OF SERVICES and SCHEDULE OF VALUES
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
The Scope of Services and the Schedule of Values, if any, are set forth in the attached EXHIBIT 1,
ATTACHMENTS A, B & C.
END OF SECTION
4 of 118 9
SCHEDULE OF EVENTS
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
No Event Date* Time*
(EST)
1 Advertisement/ Distribution of Solicitation & Cone of
Silence begins 8/14/2020 10:00 AM
2
NON-MANDATORY Pre-RFP Meeting:
Mandatory Pre-RFP meeting will be conducted through
video conferencing using the Zoom platform.
Interested parties who are considering submitting
a proposal, must identify your Company Name in
the “Participants List” on the Zoom platform.
After the meeting, an email will be sent, confirming your
attendance, to the attention of Steven P. Kulick, Chief
Procurement Officer at skulick@southmiamifl.gov
Members of the public may view the meeting via Zoom at
https://zoom.us/j/3056636339 ,or listen to the meeting on
a dedicated phone line by dialing +1-786-635-1003
Meeting ID: 3056636339. 8/25/2020 10:00 AM
3 Deadline to Submit Questions 8/28/2020 10:00 AM
4 Deadline to City Responses to Questions 8/31/2020 10:00 AM
5
Deadline to Submit RFP Response:
The City will only receive submittals electronically
through the DemandStar Electronic Bid System (E-
Bidding). To register as a business, go to
https://network.demandstar.com/ 9/3/2020 10:00 AM
6
BID OPENING VIA VIDEO CONFERENCING
VIA THE ZOOM PLATFORM at
https://zoom.us/j/3056636339 ,or listen to the meeting
on a dedicated phone line by dialing +1-786-635-1003
Meeting ID: 3056636339. 9/3/2020 10:30 AM
7 Projected Announcement of selected Contractor/Cone of
Silence ends 9/15/2020 7:00 PM
END OF SECTION
5 of 118 10
INSTRUCTIONS for RESPONDENT
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
IT IS THE RESPONSIBILITY OF THE RESPONDENT TO THE SOLICITATION TO ENSURE THAT
THE RESPONSE TO THE SOLICITATION (HEREINAFTER ALSO REFERRED TO AS THE
“PROPOSAL” THROUGHOUT THE CONTRACT DOCUMENTS) REACHES THE CITY CLERK
ON OR BEFORE THE CLOSING HOUR AND DATE STATED ON THE SOLICITATION FORM.
1. Purpose of Solicitation. The City of South Miami is requesting proposals for the lowest and most responsive
price for the Project. The City reserves the right to award the contract to the Respondent whose proposal is
found to be in the best interests of the City.
2. Qualification of Proposing Firm. Response submittals to this Solicitation will be considered from firms normally
engaged in providing the services requested. The proposing firm must demonstrate adequate experience,
organization, offices, equipment and personnel to ensure prompt and efficient service to the City of South Miami.
The City reserves the right, before recommending any award, to inspect the offices and organization or to take
any other action necessary to determine ability to perform in accordance with the specifications, terms and
conditions. The City of South Miami will determine whether the evidence of ability to perform is satisfactory
and reserves the right to reject all response submittals to this Solicitation where evidence submitted, or
investigation and evaluation, indicates inability of a firm to perform.
3. Deviations from Specifications. The awarde d firm must clearly indicate, as applicable, all areas in which the
services proposed do not fully comply with the requirements of this Solicitation. The decision as to whether an
item fully complies with the stated requirements rests solely with the City of South Miami.
4. Designated Contact. The awarded firm must appoint a person to act as a primary contact with the City of
South Miami. This person or back-up must be readily available during normal work hours by phone, email, or in
person, and must be knowledgeable of the terms of the contract.
5. Precedence of Conditions. The proposing firm, by virtue of submitting a response, agrees that City’s General
Provisions, Terms and Conditions herein will take precedence over any terms and conditions submitted with
the response, either appearing separately as an attachment or included within the Proposal. The Contract
Documents have been listed below in order of precedence, with the one having the most precedence being at
the top of the list and the remaining documents in descending order of precedence. This order of precedence
will apply, unless clearly contrary to the specific terms of the Contract or General Conditions to the Contract:
a) Addenda to Solicitation
b) Attachments/Exhibits to the Solicitation
c) Solicitation
d) Attachment/Exhibits to Supplementary Conditions
e) Supplementary Conditions to Contract, if any
f) Attachment/Exhibits to Contract
g) Contract
h) General Conditions to Contract, if any
i) Respondent’s Proposal
6. Response Withdrawal. After Proposals are opened, corrections or modifications to Proposals are not
permitted, but the City may allow the proposing firm to withdraw an erroneous Proposal prior to the
confirmation of the proposal award by City Commission, if all of the following is established:
a) The proposing firm acted in good faith in submitting the response;
b) The error was not the result of gross negligence or willful inattention on the part of the firm;
c) The error was discovered and communicated to the City within twenty-four (24) hours (not including
Saturday, Sunday or a legal holiday) of opening the proposals received, along with a request for
permission to withdraw the firm’s Proposal; and
d) The firm submits an explanation in writing, signed under penalties of perjury, stating how the error
was made and delivers adequate documentation to the City to support the explanation and to show
that the error was not the result of gross negligence or willful inattention nor made in b ad faith.
7. The terms, provisions, conditions and definitions contained in the Solicitation Cover Letter will apply to these
instructions to Respondents and they are hereby adopted and made a part hereof by reference. If there is a
conflict between the Cover Letter and these instructions, or any other provision of this Solicitation, the Cover
Letter will govern and take precedence over the conflicting provision(s) in the Solicitation.
8. Any questions concerning the Solicitation or any required need for clarification must be made in writing, by 10
AM, August 28, 2020 to the attention of Steven P. Kulick, Chief Procurement Officer at
skulick@southmiamifl.gov or via facsimile at (305) 669-2636.
6 of 118 11
9. The issuance of a written addendum is the only official method whereby interpretation and/or clarification of
information can be given. Interpretations or clarifications, considered necessary by the City in response to such
questions, will be issued by a written addendum to the Solicitation Package (also known as “Solicitation
Specifications” or “Solicitation”) by U.S. mail, e-mail or other delivery method convenient to the City and the
City will notify all prospective firms via the City’s website. It is the responsibility of the Respondent to keep
apprised of the publishing of addenda on the City’s website.
10. Verbal interpretations or clarifications will not have any legal effect. No plea by a Respondent of ignorance or
the need for additional information will exempt a Respondent from submitting the Proposal on the required
date and time as set forth in the public notice.
11. Cone of Silence: You are hereby advised that this Request for Proposals is subject to the “Cone of Silence,” in
accordance with Section 8A-7, of the City’s Code of Ordinance. From the time of advertising until the City
Manager issues his recommendation, there is a prohibition on verbal communication with the City’s professional
staff, including the City Manager and his staff and members of the City Commission. The Cone of Silence
ordinance, Section 8A-7, has been duplicated at the end of these instructions.
12. Violation of these provisions by any particular Respondent or proposer will render any recommendation for
the award of the contract or the contract awarded to said Respondent or proposer voidable, and, in such event,
said Respondent or proposer will not be considered for any Solicitation including but not limited to one that
requests any of the following a proposal, qualifications, a letter of interest or a bid concerning any contract for
the provision of goods or services for a period of one year. Contact will only be made through regularly
scheduled Commission meetings, or meetings scheduled through the Purchasing Division, which are for the
purposes of obtaining additional or clarifying information.
13. Lobbying. "Lobbyist" means all persons (including officers and managers of a legal entity), firms, or legal entities
such as a corporation, partnership or limited liability company, employed or retained by a principal (including an
officer of the principal or an employee of the principal whose duties include marketing, or soliciting business,
for the principal) who seeks to encourage the passage, defeat, or modifications of (1) ordinance, resolution,
action or decision of the City Commission; (2) any action, decision, recommendation of the City Manager or
any City board or committee; or (3) any action, decision or recommendation of City personnel during the time
period of the entire decision-making process on such action, decision or recommendation which fo reseeably
will be heard or reviewed by the City Commission, or a City board or committee. All firms and their agents
who intend to submit, or who submitted, bids or responses for this Solicitation, are hereby placed on formal
notice that neither City Commissioners, candidates for City Commissioner or any employee of the City of
South Miami are to be lobbied either individually or collectively concerning this Solicitation. Contact may only
be made through regularly scheduled Commission meetings, or meetings scheduled through the Purchasing
Division, which are for the purposes of obtaining additional or clarifying information or as otherwise provided
for in the City’s Cone of Silence. Any presentation before a selection committee is considered to be lobbying;
however, the presentation team may avoid formal registration by complying with section 8A-5 (c) (9), of the
City’s Code of Ordinances. A presentation team affidavit is provided with this solicitation that may be used to
comply with presentations, if applicable. Anyone who submits a proposal, whether solicited or unsolicited, on
behalf of his or her principal or his or her employer is considered to be a lobbyist and must register. An officer
or manager of a legal entity who is submitting a proposal, whether solicited or unsolicited, is considered to be
a lobbyist. See section 8A-5 of the City’s Code of Ordinances for further information and contact the City
Clerk to register as a lobbyist.
14. Reservation of Right. The City anticipates awarding one contract for services as a result of this Solicitation and
the successful firm will be requested to enter into negotiations to produce a contract for the Project. The City,
however, reserves the right, in its sole discretion, to do any of the following:
a) to reject any and all submitted Responses and to further define or limit the scope of the award.
b) to waive minor irregularities in the responses or in the procedure required by the Solicitation
documents.
c) to request additional information from firms as deemed nec essary.
d) to make an award without discussion or after limited negotiations. It is, therefore, important that all
the parts of the Request for Proposal be completed in all respects.
e) to negotiate modifications to the Proposal that it deems acceptable.
f) to terminate negotiations in the event the City deems progress towards a contract to be insufficient
and to proceed to negotiate with the Respondent who made the next best Proposal. The City
reserves the right to proceed in this manner until it has negotiated a contract that is satisfactory to
the City.
g) To modify the Contract Documents. The terms of the Contract Documents are general and not
necessarily specific to the Solicitation. It is therefore anticipated that the City may modify these
documents to fit the specific project or work in question and the Respondent, by making a Proposal,
agrees to such modifications and to be bound by such modified documents. 7 of 118 12
h) to cancel, in whole or part, any invitation for Proposals when it is in the best interest of the Ci ty.
i) to award the Project to the person with the lowest, most responsive, responsible Proposal, as
determined by the City.
j) to award the Project, and execute a contract with a Respondent or Respondents, other than to one
who provided the lowest Proposal Price.
k) if the Scope of the Work is divided into distinct subdivisions, to award each subdivision to a
separate Respondent.
15. Contingent Fees Prohibited. The proposing firm, by submitting a proposal, warrants that it has not employed
or retained a company or person, other than a bona fide employee, contractor or subcontractor, working in its
employ, to solicit or secure a contract with the City, and that it has not paid or agreed to pay any person,
company, corporation, individual or firm other than a bona fide employee, contractor or sub-consultant, working
in its employ, any fee, commission, percentage, gift or other consideration contingent upon or resulting from
the award or making of a contract with the City.
16. Public Entity Crimes. A person or affiliate who has been placed on the convicted vendor list following a
conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods
or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the
construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases
of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor,
or consultant under a contract with any public entity; and may not transact business with any public entity in
excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months
following the date of being placed on the convicted vendor list.
17. Respondents must use the Proposal Form(s) furnished by the City. All erasures and corrections must have the
initials of the Respondent’s authorized representative in blue ink at the lo cation of each and every erasure and
correction. Proposals must be signed using blue ink; all quotations must be typewritten, or printed with blue
ink. All spaces must be filled in with the requested information or the phrase “not applicable” or “NA”. The
proposal must be delivered on or before the date and time, and at the place and in such manner as set forth in
the Solicitation Cover Letter. Failure to do so may cause the Proposal to be rejected. Failure to include any of
the Proposal Forms may invalidate the Proposal. Respondent must deliver to the City, as part of its Proposal,
the following documents:
a) The Invitation for Proposal and Instructions to Respondents.
b) A copy of all issued addenda.
c) The completed Proposal Form fully executed.
d) Proposal/Bid Bond, (Bond or cashier’s check), if required, attached to the Proposal Form.
e) Certificates of Competency as well as all applicable State, County and City Licenses held by Respondent
f) Certificate of Insurance and/or Letter of Insurability.
18. Goods: If goods are to be provided pursuant to this Solicitation the following applies:
a) Brand Names: If a brand name, make, manufacturer’s trade name, or vendor catalog number is
mentioned in this Solicitation, whether or not followed by the words “approved equal”, it is for the
purpose of establishing a grade or quality of material only. Respondent may offer goods that are equal
to the goods described in this Solicitation with appropriate identification, samples and/or specifications
for such item(s). The City will be the sole judge concerning the merits of items proposed as equals.
b) Pricing: Prices should be stated in units of quantity specified in the Proposal Form. In case of a
discrepancy, the City reserves the right to make the final determination at the lowest net cost to the
City.
c) Mistake: In the event that unit prices are part of the Proposal and if there is a discrepancy between
the unit price(s) and the extended price(s), the unit price(s) will prevail and the extended price(s) will
be adjusted to coincide. Respondents are responsible for checking their calculations. Failure to do so
will be at the Respondent’s risk, and errors will not release the Respondent from his/her or its
responsibility as noted herein.
d) Samples: Samples of items, when required, must be furnished by the Respondent free of charge to the
City. Each individual sample must be labeled with the Respondent’s name and manufacturer’s brand
name and delivered by it within ten (10) calendar days of the Proposal opening unless schedule indicates
a different time. If samples are requested after the Proposal opening, they must be delivered within
ten (10) calendar days of the request. The City will not be responsible for the return of samples.
e) Respondent warrants by signature on the Proposal Form that prices quoted therein are in conformity
with the latest Federal Price Guidelines.
f) Governmental Restrictions: In the event any governmental restrictions may be imposed which would
necessitate alteration of the material quality, workmanship, or performance of the items offered on this
Proposal prior to their delivery, it will be the responsibility of the successful Respondent to notify the
City at once, indicating in its letter the specific regulation which required an alteration. The City of 8 of 118 13
South Miami reserves the right to accept any such alteration, including any price adjustments occasioned
thereby, or to cancel all or any portion of the Contract, at the sole discretion of the City and at no
further expense to the City with thirty (30) days advanced notice.
g) Respondent warrants that the prices, terms and conditions quoted in the Proposal will be firm for a
period of one hundred eighty (180) calendar days from the date of the Proposal opening unless
otherwise stated in the Proposal Form. Incomplete, unresponsive, irresponsible, vague, or ambiguous
responses to the Solicitation will be cause for rejection, as determined by the City.
h) Safety Standards: The Respondent warrants that the product(s) to be supplied to the City conform in
all respects to the standards set forth in the Occupational Safety and Health Act (OSH A) and its
amendments. Proposals must be accompanied by a Materials Data Safety Sheet (M.S.D.S) when
applicable.
19. Liability, Licenses & Permits: The successful Respondent must assume the full duty, obligation, and expense of
obtaining all necessary licenses, permits, and inspections required by this Solicitation and as required by law. The
Respondent will be liable for any damages or loss to the City occasioned by the negligence of the Respondent
(or its agent or employees) or any person acting for or thr ough the Respondent. Respondents must furnish a
certified copy of all licenses, Certificates of Competency or other licensing requirement necessary to practice
their profession and applicable to the work to be performed as required by Florida Statutes, th e Florida Building
Code, Miami-Dade County Code or City of South Miami Code. These documents must be furnished to the
City as part of the Proposal. Failure to have obtained the required licenses and certifications or to furnish these
documents will be grounds for rejecting the Proposal and forfeiture of the Proposal/Bid Bond, if required for
this Project.
20. Respondent must comply with the City’s insurance requirements as set forth in the attached EXHIBIT 2,
prior to issuance of any Contract(s) or Award(s) If a recommendation for award of the contract, or an award
of the contract is made before compliance with this provision, the failure to fully and satisfactorily comply with
the City’s bonding, if required for this project, and insurance requirements as set forth herein will authorize the
City to implement a rescission of the Proposal Award or rescission of the recommendation for award of contract
without further City action. The Respondent, by submitting a Proposal, thereby agrees to hold the City harmless
and agrees to indemnify the City and covenants not to sue the City by virtue of such rescission.
21. Copyrights and/or Patent Rights: Respondent warrants that as to the manufacturing, producing or selling of
goods intended to be shipped or ordered by the Respondent pursuant to this Proposal, there has not been, nor
will there be, any infringement of copyrights or patent rights. The Respondent agrees to indemnify City from
any and all liability, loss or expense occasioned by any such violation or infringement.
22. Execution of Contract: A response to this Solicitation will not be responsive unless the Respondent signs the
form of contract that is a part of the Solicitation package. The Respondent to this Solicitation acknowledges
that by submitting a response or a proposal, Respondent agrees to the terms of the form contrac t and to the
terms of the general conditions to the contract, both of which are part of this Solicitation package. The
Respondent agrees that Respondent’s signature on the Bid Form and/or the form of contract that is a part of
the Solicitation package and/or response to this Solicitation, grants to the City the authority, on the
Respondent’s behalf, to inserted, into any blank spaces in the contract documents, information obtained from
the proposal and, at the City’s sole and absolute discretion, the City may treat the Respondent’s signature on
any of those documents as the Respondent’s signature on the contract, after the appropriate information has
been inserted, as well as for any and all purposes, including the enforcement of all of the terms and condit ions
of the contract.
23. Evaluation of Proposals: The City, at its sole discretion, reserves the right to inspect the facilities of any or all
Respondents to determine its capability to meet the requirements of the Contract. In addition, the price,
responsibility and responsiveness of the Respondent, the financial position, experience, staffing, equipment,
materials, references, and past history of service to the City and/or with other units of state, and/or local
governments in Florida, or comparable private entities, will be taken into consideration in the Award of the
Contract.
24. Drug Free Workplace: Failure to provide proof of compliance with Florida Statute Section 287.087, as amended,
when requested will be cause for rejection of the Proposal as determined by the City.
25. Hold Harmless: All Respondents must hold the City, its officials and employees harmless and covenant not to
sue the City, its officials and employees in reference to its decisions to reject, award, or not award a contract,
as applicable, unless the claim is based solely on allegations of fraud and/or collusion. The submission of a
proposal will act as an agreement by the Respondent that the Proposal/Bid Bond, if required for this project,
will not be released until and unless the Respondent waives any and all claims that the Respondent may have
against the City that arise out of this Solicitation process or until a judgment is entered in the Respondent’s
favor in any suit filed which concerns this proposal process. In any such suit, the pr evailing party will recover
its attorney’s fees, court costs as well as expenses associated with the litigation. In the event that fees, court
9 of 118 14
costs and expenses associated with the litigation are awarded to the City, the Proposal/Bid Bond, if required for
this project, will be applied to the payment of those costs and any balance will be paid by the Respondent.
26. Cancellation: Failure on the part of the Respondent to comply with the conditions, specifications, requirements,
and terms as determined by the City, will be just cause for cancellation of the Award or termination of the
contract.
27. Bonding Requirements: The Respondent, when submitting the Proposal, must include a Proposal/Bid Bond, if
required for this project, in the amount of 5% of the total amount of the base Proposal on the Proposal/Bid
Bond Form included herein. A company or personal check will not be deemed a valid Proposal Security.
28. Performance and Payment Bond: The City of South Miami may require the successful Respondent to furnish a
Performance Bond and Payment Bond, each in the amount of 100% of the total Proposal Price, including
Alternates if any, naming the City of South Miami, and the entity that may be providing a s ource of funding for
the Work, as the obligee, as security for the faithful performance of the Contract and for the payment of all
persons or entities performing labor, services and/or furnishing materials in connection herewith. In addition,
if the Respondent’s employees will be working in secure or sensitive areas of the City, the City may require that
the Respondent provides employee bonding, naming the City of South Miami as the obligee on the bond. The
bonds must be with a surety company authorized to do business in the State of Florida.
28.1. Each Performance Bond must be in the amount of one hundred percent (100%) of the Contract
Price guaranteeing to City the completion and performance of the Work covered in the Contract
Documents.
28.2. Each Performance Bond must continue in effect for five years after final completion and acceptance
of the Work with the liability equal to one hundred percent (100%) of the Contract Sum.
28.3. Each Payment bond must guarantee the full payment of all suppliers, material man, laborers, or
subcontractor employed pursuant to this Project.
28.4. Each Bond must be with a Surety company whose qualifications meet the requirements of insurance
companies as set forth in the insurance requirements of this solicitation.
28.5. Pursuant to the requirements of Section 255.05, Florida Statutes, Respondent must ensure that
the Bond(s) referenced above must be recorded in the public records of Miami-Dade County and provide
CITY with evidence of such recording.
28.6. The surety company must hold a current certificate of authority as acceptable surety on federal
bonds in accordance with the United States Department of Treasury Circular 570, current revisions.
29. Proposal Guarantee: Notwithstanding the fact that the Respondent, in submitting a proposal, agrees to the
terms contained in the form of contract that is part of this Solicitation package, the successful Respondent,
within ten (10) calendar days of Notice of Award by the City, must deliver, to the City, the executed Contract
and other Contract Documents that provide for the Respondent’s signature, and deliver to the City the required
insurance documentation as well as a Performance and Payment Bond if these bonds are required. The
Respondent who has the Contract awarded to it and who fails to execute the Contract and furnish the required
Bonds and Insurance Documents within the specified time will, at the City’s option, forfeit the Proposal/Bid
Bond/Security that accompanied the Proposal, and the Proposal/Bid Bond/Security will be retained as liquidated
damages by the City. It is agreed that if the City accepts payment from the Proposal/Bid Bond, that this sum i s
a fair estimate of the amount of damages the City will sustain in case the Respondent fails to sign the Contract
Documents or fails to furnish the required Bonds and Insurance documentation. If the City does not accept the
Proposal/Bid Bond, the City may proceed to sue for breach of contract if the Respondent fails to perform in
accordance with the Contract Documents. Proposal/Bid Bond/Security deposited in the form of a cashier’s
check drawn on a local bank in good standing must comply with the same requirements as a Proposal/Bid Bond.
30. Pre-proposal Conference Site Visits: If a Mandatory Pre-proposal conference is scheduled for this project, all
Respondents must attend the conference and tour all areas referenced in the Solicitation Documents. It will be
grounds for rejecting a Proposal from a Respondent who did not attend the mandatory pre-proposal
conference. No pleas of ignorance by the Respondent of conditions that exist, or that may hereinafter exist, as
a Solicitation result of failure to make the necessary examinations or investigations, or failure to complete any
part of the Solicitation Package, will be accepted as basis for varying the requirements of the Contract with the
City of South Miami or the compensation of the Respondent. The Respondent, following receipt of a survey of
the property, if applicable, is bound by knowledge that can be seen or surmised from the survey and will not be
entitled to any change order due to any such condition. If the survey is provided before the proposal is
submitted, the contract price must include the Work necessitated by those conditions. If the survey is provided
subsequent to the submission of the proposal, the Respondent will have five calendar days to notify the City of
any additional costs required by such conditions and the City will have the right to reject the proposal and award
the contract to the second most responsive, responsible bidder with the lowest price or to reject all bids.
31. Time of Completion: The time is of the essence with regard to the completion of the Work to be performed
under the Contract to be awarded. Delays and extensions of time may be allowed only in accordance with the
provisions stated in the appropriate section of the Contract Documents, including the Proposal Form. No 10 of 118 15
change orders will be allowed for delays caused by the City, other than for extensions of time to complete the
Work.
32. Submittal Requirements: All Proposals must comply with the requirements set forth herein and must include
a fully completed Respondent’s Bid Form found on EXHIBIT 3 and a Respondent’s Cost and
Technical Proposal found on EXHIBIT 4.
33. Cancellation of Bid Solicitation: The City reserves the right to cancel, in whole or part, any request for proposal
when it is in the best interest of the City.
34. Respondent may not discriminate with regard to its hiring of employees or subcontractors or in its purchase of
materials or in any way in the performance of its contract, if one is awarded, based on race, color, religion,
national origin, sex, age, sexual orientation, disability, or familial status.
35. All respondents, at the time of bid opening, must have fulfilled all prior obligations and commitments to the City
in order to have their bid considered, including all financial obligations. Prior to the acceptance of any b id
proposal or quotation, the City's Finance Department will certify that there are no outstanding fines, monies,
fees, taxes, liens or other charges owed to the City by the Respondent, any of the Respondent’s principal,
partners, members or stockholders (collectively referred to as “Respondent Debtors”). A bid, proposal or
quotation will not be accepted until all outstanding debts of all Respondent Debtors owed to the city are paid
in full. No bidder who is in default of any prior contract with the City may have their bid considered until the
default is cured to the satisfaction of the City Manager.
36. Bid Protest Procedure. See attached EXHIBIT 10
37. Evaluation Criteria: If this project is to be evaluated by an Evaluation Committee, the evaluation criteria i s
attached as N/A.
38. Availability of Contract - Any Governmental or quasi-governmental entity, in this or in any other state, or any
federal governmental agency, may avail itself of this solicitation and the contract that is awarded pursuant to this
solicitation and purchase any and all goods/services specified herein from the successful bidder(s)/proposer(s)
at the contract price(s) established herein, when any federal, state, and/or local laws, rules, and regulations
allows the piggybacking off said contract and provided that the successful bidder(s)/proposer(s) is/are in
agreement. Each Governmental or quasi-governmental entity which uses this formal solicitation and resulting
bid contract or agreement will establish its own contract/agreement, place its own orders, issue its own purchase
orders, be invoiced there from and make its own payments, determine shipping terms and issue its own
exemption certificates as required by the successful bidder(s)/proposer(s).
39. Non-Appropriation of Funds. In the event that no funds or insufficient funds are appropriated and budgeted or
are otherwise unavailable in any fiscal period for payments due under any contract awarded pursuant to this
solicitation, then the City, upon written notice to Successful Bidder or their assignee of such occurrence, will
have the unqualified right to terminate the contract without any penalty or expense. No guarantee, warranty or
representation is made that any particular project(s) will be awarded to any Respondent(s).
40. Most Favored Public Entity. Respondent represents that the prices charged to City in the proposal do not
exceed existing prices to other customers for the same or substantially similar items or services for comparable
quantities under similar terms, conditions, wages, benefits, insurance coverage and any other material cost
factors. If respondent’s prices decline, or should respondent, at any time during the term of a contract entered
into with City, provide the same goods or services with the same comparable quantities under similar terms,
conditions, wages, benefits, insurance coverage and any other material cost factors, Respondent must
immediately extend the same prices to City.
41. Confidential and Proprietary Information. Respondents may assert that some trade secrets, financial records,
and proprietary or other confidential information in their unsolicited proposal are confidential information that
they claim to be exempt from disclosure under applicable Florida public records laws. Such information may be
included in the unsolicited proposal, but submitted in a separate, sealed binder, designated on the cover as
CONFIDENTIAL MATERIALS. A Respondent submitting materials claimed to be confidential must include a
cover letter listing all material designated as confidential and clearly mark each page of any material believed to
be a trade secret or other confidential information/document in all capital letters and bold font as
CONFIDENTIAL MATERIALS. If a document is not totally confidential but contains non-confidential and
confidential information, the Respondent must provide a redacted copy of the document and an unredacted
copy. In addition, the Respondent must prepare a list of all the documents claimed to be confidential or
containing confidential information and on the next line under the description of each document the Respondent
must cite the statutory provision that provides the basis for the Respondent’s claim that the document or a
portion of the document is confidential and below the citation the Respondent must copy and paste the
applicable statutory provision (this listing requirement will hereinafter be referred to as “properly list” or
“properly listed” confidential document). The failure to properly list a confidentia l document or the failure to
redact a confidential document that is only partially confidential will result in the waiver of any claim that the
document is confidential or that the unredacted document contains confidential information. If any person or
entity requests that the City produce or disclose any of said purported confidential information or documents, 11 of 118 16
the City will advise the Respondent and afford the Respondent an opportunity to protect its assertion that said
confidential information is exempt from production. If Respondent fails to timely authorize the production of
the information or document and/or fails to timely seek a protective order, and/or is unsuccessful in obtaining
a protective order, the City will produce the requested information or document. The City will not actively
contest any request to disclose such alleged confidential information or document and the City cannot guarantee
that the alleged confidential document or information may not be disclosed should it ultimately be dete rmined
not to be confidential under applicable Florida public records laws. The Respondent must indemnify the City
for any damages and costs the City may incur due to the Respondent’s claim that its document or information
is confidential. The City can only agree to advise the Respondent of such request and give the Respondent an
opportunity, at Respondent’s sole and exclusive cost, to defend the request for disclosure of the confidential
information or document in a Court of competent jurisdiction or other applicable forum.
42. Definitions. The following definitions will govern the interpretation of this RFP:
“Certify”, including all of its tenses, such as “certifies”, “certifying” and “certified”, means the act of swearing
or affirming under penalties of perjury that the facts that are being “certified” are true and correct and it must
be accomplished either by swearing (or affirming) to the truth of the statement before a notary public, or by a
declaration, under penalties of perjury, as to the truth of the statement pursuant to Florida Statutes, Section
92.525.
43. Tie Bids. In the event of tie bids, Respondents will be directed to submit sealed Best and Final Offers and deliver
to the Office of the City Clerk located at South Miami City Hall, 6130 Sunset Drive, South Miami, Florida 33143.
The “Best and Final Offers” must be enclosed in a sealed envelope or container and must have the following
Information clearly printed or written on the exterior of the envelope or container in which the sealed proposal
is delivered: “Best and Final Offers”. On the second line of the envelope insert the Project Name and Solicitation
Number. On the third line of the envelope insert the name of the person or entity who is going to be legally
bound to perform the contractual obligations if awarded the contract.
44. Tie Selection. In the event of a tie by an Evaluation Selection Committee after they have scored each submittal,
the meeting facilitator of the Selection Committee meeting, usually the City’s Procurement Manager, will
tabulate the Selection Committee’s scores and advise the Committee there is a tie score; without advising the
Committee the scores or the Respondents involved. The meeting facilitator will direct the Selection Committee
to re-score the Respondents submittals and, will continue the re-scoring until the tie is broken, and a clear
winner for the award recommendation has been determined. If the tie is not broken after three attempts to
break the tie, all responses will be rejected, and the item will be re -advertised.
45. Rescind the Award. The City reserves the right to rescind the award recommendation, even after the award
recommendation has been conditionally approved by the City Commission but before execution of the Contract
by the City Manager and, by responding to this RFP, Respondent agrees to waive any contractual rights or
equitable claims that Respondent may have accrued following the initial award recommendation by the City
Manager under these conditions.
46. State of Emergency. The City reserves the right, in its so le and absolute discretion, to suspend the work or
services or cancel the contract in the event of an emergency that effects the City of South Miami, its residents
or businesses and that has been declared by the Governor, Mayor of Miami -Dade County or the City Manager.
47. Force majeure. Neither party may hold the other responsible for damages or for delays in performance caused
by force majeure, acts of God, or other acts or circumstances beyond the control of a party or that could not
have been reasonably foreseen, prevented or avoided. For this purpose, such acts or circumstances include,
but not limited to, weather conditions affecting performance, floods, epidemics, war, riots, strikes, lockouts, or
other industrial disturbances, or protest demonstrations. Should such acts or circumstances occur, the parties
will use their best efforts to overcome the difficulties and to resume the work as soon as reasonably possible.
END OF SECTION
12 of 118 17
CONE OF SILENCE ORDINANCE, SECTION 8A-7
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
Chapter 8A of the City of South Miami Code of Ordinances is hereby amended in pertinent part to add
a new section 8A-7 which is to read as follows:
Sec. 8A-7. Cone of Silence:
(A) Definitions.
(1) "Cone of silence", as used herein, means a prohibition of any communication regarding
competitive solicitations such as a request for proposal ("RFP"), request for qualification
("RFQ"), request for information (“RFI”) or request for bid (“RFB”), between:
(a) A potential vendor, service provider, proposer or bidder (hereinafter referred to as the
“Potential Bidder”), or agent, representative, lobbyist or consultant for the Potential Bidder;
(hereinafter referred to as the “Bidder’s Representative”) and
(i) Members of the City Commission or
(ii) City's professional staff or
(iii) Any member of the City's selection, evaluation or negotiation committee.
(b) Members of the City Commission shall not communicate with professional staff or
members of the selection, evaluation and negotiation committees at any point in the
competitive process except as provided in paragraph D (3) below.
(2) “City’s professional staff” means City Department Heads and their staff and the City
Manager and Deputy City Manager and their staff including consultants involved in the
solicitation, evaluation and negotiation process.
(B) Restriction; notice. A cone of silence shall be imposed upon each competitive solicitation,
commencing with the date that the advertisement of said solicitation is published and the
requirements of this section shall be included in the solicitation. At the time of imposition of the
cone of silence, the City Manager or Manager’s designee shall: (a) provide for public notice of the
cone of silence by posting a notice at City Hall; (b) issue a written notice thereof to the affected
Departments; (c) file a copy of such notice with the City Clerk; and (d) serve a copy thereof on
each City Commissioner.
(C) Termination of Cone of Silence. The Cone of Silence shall terminate at the beginning of
the City Commission meeting at which the City Manager makes his or her written
recommendation to the City Commission or at the time that the solicitation process is terminated
by the City Manager. However, if the City Commission refers the Manager's recommendation
back to the Manager or staff for further review, the cone of silence shall be reimposed until the
beginning of the City Commission meeting at which the City Manager makes a subsequent written
recommendation.
(D) Exceptions to applicability. The provisions of this section shall not apply to:
(1) Communications at a duly noticed pre-bid conferences or at any duly noticed public
Selection or Negotiation Committee meeting or duly noticed public City Commission meeting
at which the City Manager has placed the subject of the solicitation on the Agenda;
(2) Communication regarding the solicitation at recorded contract negotiations, recorded
oral presentation or recorded oral question and answer session and recorded contract
negotiation strategy sessions in compliance with the exemption in Florida Statutes Section
286.0113;
13 of 118 18
(3) Briefings made by the City Manager or his designee to the City Commissioners during a
meeting following the completion of the Selection or Negotiation Committee meetings;
(4) Written communication at any time with any City professional staff (not including
selection, evaluation or negotiation committee members), unless specifically prohibited by the
applicable competitive solicitation documents. This section shall not be construed to prevent
written communication between City professional staff and any City selection, evaluation or
negotiation committee. A copy of any written communication made during the cone of
silence shall be contemporaneously filed with the City Clerk by the Potential Bidder or
Bidder’s Representative. The City Clerk shall make copies available to any person upon
request;
(5) Communication that is strictly limited to matters of those processes or procedures that
are contained in the corresponding solicitation document and which communication is
between any person and the City's Purchasing Agent or the City employee who is designated
as being responsible for administering the procurement process for such solicitation;
(6) Communications with the City Attorney and his or her staff;
(7) Communications during any duly noticed site visits to determine the competency and
responsibleness of bidders regarding a particular bid during the time period between the
opening of bids and the time the City Manager makes a written recommendation;
(8) Any emergency procurement of goods or services pursuant to City Code;
(9) Responses to a request made by the City's Purchasing Agent, or the City employee who
is designated as being responsible for administering the procurement process for such
solicitation, for clarification or additional information;
(10) Communications prior to bid opening between City’s professional staff and Potential
Bidders and/or Bidder’s Representatives to enable City staff to seek and obtain industry
comment or perform market research, provided all communications related thereto between
a Potential Bidders and/or Bidder’s Representatives and any member of the City's professional
staff including, but not limited to the City Manager and his or her staff, are in writing or are
made at a duly noticed public meeting.
(F) Penalties. Violation of this section by a particular bidder or proposer, or their representative,
shall render any award to said bidder or proposer voidable by the City Commission and/or City
Manager. Any person who violates a provision of this section may be prohibited from serving on
a City selection or evaluation committee. In addition to any other penalty provided herein,
violation of any provision of this section by a City employee may subject said employee to
disciplinary action at the discretion of the City Manager.
END OF SECTION
14 of 118 19
PROPOSAL SUBMITTAL CHECKLIST FORM
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
This checklist indicates the forms and documents required to be submitted for this solicitation and to be presented
by the deadline set for within the solicitation. Fulfillment of all solicitation requirements listed is mandatory for
consideration of response to the solicitation. Additional documents may be required and, if so, they will be identified
in an addendum to this Solicitation. The response must include the following items:
Attachments and Other Documents described below
to be Completed
IF MARKED WITH AN “X”:
Check
Completed.
X
The City will only receive submittals online and electronically through the
Demand Star Electronic Bid System (E -Bidding). To register as a business,
go to https://network.demandstar.com/ The City, at its discretion, may
request hard copies of proposals received from a specific Respondent or all
Respondents.
X Indemnification and Insurance Documents EXHIBIT 2
X Respondents Bid Form. EXHIBIT 3
X Respondents Cost & Technical Proposal, EXHIBIT 4
X
Signed Contract Documents (All – including General Conditions and
Supplementary Conditions if attached) EXHIBIT 5, 6 & 7
X
Performance and Payment Bonds (As a Condition Award. Not required
with Submittal.) EXHIBIT 8 & 9
X Respondents Qualification Statement
X List of Proposed Subcontractors and Principal Suppliers
X Non-Collusion Affidavit
X Public Entity Crimes and Conflicts of Interest
X Drug Free Workplace
X Acknowledgement of Conformance with OSHA Standards
X Affidavit Concerning Federal & State Vendor Listings
X Related Party Transaction Verification Form
X Presentation Team Declaration/Affidavit of Representation
Submit this checklist along with your proposal indicating the completion and submission of each required forms
and/or documents.
END OF SECTION
15 of 118 20
RESPONDENT QUALIFICATION STATEMENT
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
The response to this questionnaire will be utilized as part of the CITY’S overall Proposal Evaluation and
RESPONDENT selection.
1. Number of similar projects completed,
a) In the past 5 years
In the past 5 years On Schedule
b) In the past 10 years
In the past 10 years On Schedule
2. List the last five (5) completed similar projects.
a) Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
b) Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price
c) Project Name:
Owner Name:
Owner Address: 16 of 118 21
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
d) Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
e) Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
17 of 118 22
3. Current workload
Project Name Owner Name Telephone Number Contract Price
4. The following information must be attached to the proposal.
a) RESPONDENT’s home office organization chart.
b) RESPONDENT’s proposed project organizational chart.
c) Resumes of proposed key project personnel, including on-site Superintendent.
5. List and describe any:
a) Bankruptcy petitions filed by or against the Respondent or any predecessor organizations,
b) Any arbitration or civil or criminal proceedings, or
c)
Suspension of contracts or debarring from Bidding or Responding by any public agency brought
against the Respondent in the last five (5) years
6. Government References:
List other Government Agencies or Quasi-Government Agencies for which you have done business within
the past five (5) years.
Name of Agency:
Address:
Telephone No.:
Contact Person:
Type of Project:
18 of 118 23
Name of Agency:
Address:
Telephone No.:
Contact Person:
Type of Project:
Name of Agency:
Address:
Telephone No.:
Contact Person:
Type of Project:
19 of 118 24
LIST OF PROPOSED SUBCONTRACTORS AND PRINCIPAL SUPPLIERS
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
Respondent must list all proposed subcontractors, if subcontractors are allowed by the terms of this
Solicitation to be used on this project if they are awarded the Contract.
Classification of Work Subcontractor Name Address Telephone, Fax &
Email
Other:
This list must be provided as a part of Respondents submittal to the City of South Miami and in response to this
RFP.
END OF SECTION
20 of 118 25
NON-COLLUSION AFFIDAVIT
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
STATE OF FLORIDA )
)
COUNTY OF MIAMI-DADE )
___________________________________________ being first duly sworn, deposes and states that:
(1) He/She/They is/are the ______________________________________________________
(Owner, Partner, Officer, Representative or Agent) of
__________________________________________ the Respondent that has submitted the
attached Proposal;
(2) He/She/They is/are fully informed concerning the preparation and contents of the attached Proposal
and of all pertinent circumstances concerning such Proposal;
(3) Such Proposal is genuine and is not a collusive or sham Proposal;
(4) Neither the said Respondent nor any of its officers, partners, owners, agents, representatives,
employees or parties in interest, including this affiant, have in any way colluded, conspired, connived or
agreed, directly or indirectly, with any other Respondent, firm, or person to submit a collu sive or sham
Proposal in connection with the Work for which the attached Proposal has been submitted; or to
refrain from Bidding or proposing in connection with such Work; or have in any manner, directly or
indirectly, sought by agreement or collusion, or communication, or conference with any Respondent,
firm, or person to fix any overhead, profit, or cost elements of the Proposal or of any other
Respondent, or to fix any overhead, profit, or cost elements of the Proposal Price or the Proposal
Price of any other Respondent, or to secure through any collusion, conspiracy, connivance, or unlawful
agreement any advantage against (Recipient), or any person interested in the proposed Work;
(5) The price or prices quoted in the attached Proposal are fair an d proper and are not tainted by any
collusion, conspiracy, connivance, or unlawful agreement on the part of the Respondent or any other
of its agents, representatives, owners, employees or parties of interest, including this affiant.
Signed, sealed and delivered in the presence of:
_________________________________ By: ___________________________________
Witness Signature
_________________________________ ___________________________________
Witness Print Name and Title
___________________________________
Date
ACKNOWLEDGEMENT
STATE OF FLORIDA )
)
COUNTY OF MIAMI-DADE )
On this the _______ day of ______________, 20_____, before me, the undersigned Notary Public of the State
of Florida, personally appeared (Name(s) of individual(s) who appeared before notary)
______________________________________________ and whose name(s) is/are Subscribed to the within
instrument, and he/she/they acknowledge that he/she/they executed it.
21 of 118 26
WITNESS my hand and official seal. _______________________________________
Notary Public, State of Florida
NOTARY PUBLIC:
SEAL OF OFFICE: ______________________________________
(Name of Notary Public: Print, Stamp or type as commissioned.)
____ Personally known to me, or
____ Personal identification:
_________________________
Type of Identification Produced
____ Did take an oath, or
____ Did Not take an oath.
22 of 118 27
PUBLIC ENTITY CRIMES AND CONFLICTS OF INTEREST
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
Pursuant to the provisions of Paragraph (2) (a) of Section 287.133, Florida State Statutes – “A person or affiliate who
has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a
Proposal or bid on a Contract to provide any goods or services to a public entity, may not submit a Bid or proposal
for a Contract with a public entity for the construction of repair of a public building or public work, may not submit
bids or proposals on leases or real property to a public entity, may not be awarded to perform Work as a
RESPONDENT, Sub-contractor, supplier, Sub-consultant, or Consultant under a Contract with any public entity,
and may not transact business with any public entity in excess of the threshold amount C ategory Two of Section
287.017, Florida Statutes, for thirty six (36) months from the date of being placed on the convicted vendor list”.
The award of any contract hereunder is subject to the provisions of Chapter 112, Florida State
Statutes. Respondents must disclose with their Proposals, the name of any officer, director, partner, associate or
agent who is also an officer or employee of the City of South Miami or its agencies.
SWORN STATEMENT PURSUANT TO SECTION 287.133 (3) (a),
FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES
THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER
OFFICIAL AUTHORIZED TO ADMINISTER OATHS.
1. This sworn statement is submitted to
____________________________________________________________________________
[print name of the public entity]
by ____________________________________________________________________________
[print individual’s name and title]
for___________________________________________________________________________
[print name of entity submitting sworn statement]
whose business address is
and (if applicable) its Federal Employer Iden tification Number (FEIN) is ____________________ (If the
entity has no FEIN, include the Social Security Number of the individual signing this sworn statement:
___________________________________________________.)
2. I understand that a “public entity crime” as defined in Paragraph 287.133 (1)(g), Florida Statutes, means
a violation of any state or federal law by a person with respect to and directly related to the transaction of
business with any public entity or with an agency or political subdivision of any other state or of the United
States, including, but not limited to , any bid, proposal or contract for goods or services to be provided to
any public entity or an agency or political subdivision of any other state or of the United States and involving
antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation.
3. I understand that “convicted” or “conviction” as defined in Paragraph 287.133 (1) (b), Florida Statutes,
means a finding of guilt or a conviction of a public entity crime, with or without an adjudication of guilt, in
any federal or state trial court of record relating to charges brought by indictment or information after July
1, 1989, as a result of a jury verdict, non-jury trial, or entry of a plea of guilty or nolo contendere.
4. I understand that an “affiliate” as defined in Paragraph 287.133 (1) (a), Florida Statutes, means:
(a) A predecessor or successor of a person convicted of a public entity crime; or
(b) An entity under the control of any natural person who is active in the management of the entity
and who has been convicted of a public entity crime. The term “affiliate” includes those officers,
directors, executives, partners, shareholders, employees, members, and agents who are active in
the management of an affiliate. The ownership by one person of shares constituting a controlling
interest in any person, or a pooling of equipment or income among persons when not for fair
market value under an arm’s length agreement, will be a prima facie case that one person controls 23 of 118 28
another person. A person who knowingly enters into a joint venture with a person who has been
convicted of a public entity crime in Florida during the preceding 36 months will be considered an
affiliate.
5. I understand that a “person” as defined in Paragraph 287.133 (1) (e), Florida Statutes, means any natural
person or entity organized under the laws of any state or of the United States with the legal pow er to enter
into a binding contract and which bids or proposal or applies to bid or proposal on contracts for the
provision of goods or services let by a public entity, or which otherwise transacts or applies to transact
business with a public entity. The term “person” includes those officers, directors, executives, partners,
shareholders, employees, members, and agents who are active in management of an entity.
6. Based on information and belief, the statement which I have marked below is true in relation to the entity
submitting this sworn statement. [Indicate which statement applies.]
_____ Neither the entity submitting this sworn statement, nor any of its officers, directors, executives,
partners, shareholders, employees, members, or agents who are active in the management of the entity,
nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to
July 1, 1989.
_____ The entity submitting this sworn statement, or one or more of its office rs, directors, executives,
partners, shareholders, employees, members, or agents who are active in the management of the entity, or
an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1,
1989.
_____ The entity submitting this sworn statement, or one or more of its officers, directors, executives,
partners, shareholders, employees, members, or agents who are active in the management of the entity, or
an affiliate of the entity has been charged with and convicted of a public entity crime subsequent of July 1,
1989. However, there has been a subsequent proceeding before a Hearing Officer of the State of Florida,
Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it
was not in the public interest to place the entity submitting this sworn statement on the convicted vendor
list. [attach a copy of the final order.]
I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FOR THE PUBLIC ENTITY
IDENTIFIED IN PARAGRAPH 1 (ONE) ABOVE IS FOR THAT PUBLIC ENTITY ONLY, AND THAT THIS FORM IS VALID
THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM
REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE
THRESHOLD AMOUNT PROVIDED IN SECTION 287.017, FLORIDA STATUTES, FOR CATEGORY TWO OF ANY
CHANGE IN THE INFORMATION CONTAINED IN THIS FORM.
____________________________________
[Signature]
Sworn to and subscribed before me this __________ day of ___________________________, 20____.
Personally known ________________________ ___________________________________
OR Produced identification _________________ Notary Public – State of ________________
_______________________________________ My commission expires ________________
(Type of identification) (Printed, typed or stamped commissioned
Form PUR 7068 (Rev.06/11/92) name of notary public)
24 of 118 29
DRUG FREE WORKPLACE
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
Whenever two or more Bids or Proposals which are equal with respect to price, quality and service are received
by the State or by any political subdivisions for the procurement of commodities or contractual services, a Bid or
Proposal received from a business that certifies that it has implemented a drug-free workplace program will be
given preference in the award process. Established procedures for processing tie Bids or Proposals will be
followed if none of the tied vendors have a drug-free workplace program. In order to have a drug-free workplace
program, a business must:
1) Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing,
possession, or use of a controlled substance is prohibited in the workplace and specifying the
actions that will be taken against employees for violations of such prohibition..
2) Inform employees about the dangers of drug abuse in the workplace, the business’s policy of
maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee
assistance programs, and the penalties that may be imposed upon employees for drug abuse
violations.
3) Give each employee engaged in providing the commodities or contractual services that are under
bid a copy of the statement specified in subsection (1).).
4) In the statement specified in subsection (1), notify the employees that, as a condition of working
on the commodities or contractual services that are under bid, the employee will abide by the
terms of the statement and will notify the employer of any conviction of, or plea of guilty or nolo
contendere to, any violation of chapter 893 or of any controlled substance law of the United
States or any state, for a violation occurring in the workplace no later than 5 days after such
conviction.
5) Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or
rehabilitation program if such is available in the employee’s community, by any employee who is
so convicted.
6) Make a good faith effort to continue to maintain a drug-free workplace through implementation
of this section.
As the person authorized to sign this statement, and under penalties of perjury, I declare that I have read the
foregoing statement and that the facts stated in it are true and that this firm is in full compliance with the above
requirements.
RESPONDENT’s Signature: ___________________________________
Print Name: _________________________________________
Date: ______________________________________________
25 of 118 30
ACKNOWLEDGEMENT OF CONFORMANCE WITH OSHA STANDARDS
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
TO THE CITY OF SOUTH MIAMI
We, _____________________________, (Name of CONTRACTOR), hereby acknowledge and agree that as
CONTRACTOR for the SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS RFP
#PW2020-19 as specified have the sole responsibility for compliance with all the requirements of the Federal
Occupational Safety and Health Act of 1970, and all State and local safety and health regulations, and agree to
indemnify and hold harmless the City of South Miami and STANTEC (Consultant, if any) against any and all
liability, claims, damages, losses and expenses they may incur due to the failure of (Sub-contractor’s names):
____________________________________________________________________________________
to comply with such act or regulation.
CONTRACTOR
_____________________________________ ________________________________
Witness
BY: __________________________________
Name
__________________________________
Title
26 of 118 31
AFFIDAVIT CONCERNING
FEDERAL AND STATE VENDOR LISTINGS
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
The person, or entity, who is responding to the City’s solicitation, hereinafter referred to as “Respondent”, must
certify that the Respondent’s name Does Not appear on the State of Florida, Department of Management Services,
“CONVICTED, SUSPENDED, DISCRIMINATORY FEDERAL EXCLUDED PARTIES and COMPLAINTS VENDOR
LISTINGS”.
If the Respondent’s name appears on one or all the “Listings” summarized below, Respondents must “Check if
Applies” next to the applicable “Listing.” The “Listings” can be accessed through the following link to the Florida
Department of Management Services website:
http://www.dms.myflorida.com/business_operations/state_purchasing/vendor_information/convicted_susp
ended_discriminatory_complaints_vendor_lists
DECLARATION UNDER PENALTY OF PERJURY
I, _____________________ (hereinafter referred to as the “Declarant”) state, that the following facts
are true and correct:
(1) I represent the Respondent whose name is ______________________________.
(2) I have the following relationship with the Respondent __________________ (Owner (if Respondent is a
sole proprietor), President (if Respondent is a corporation) Partner (if Respondent is a partnership), General
Partner (if Respondent is a Limited Partnership) or Managing Member> (if Respondent is a Limited Liability
Company).
(3) I have reviewed the Florida Department of Management Services website at the following URL address:
http://www.dms.myflorida.com/business_operations/state_purchasing/vendor_information/convicted_suspended_di
scriminatory_complaints_vendor_lists
(4) I have entered an “x” or a check mark beside each listing/category set forth below if the Respondent’s
name appears in the list found on the Florida Department of Management Services website for that category or
listing. If I did not enter a mark beside a listing/category, it means that I am attesting to the fact that the
Respondent’s name does not appear on the listing for that category in the Florida Department of Management
Services website as of the date of this affidavit.
Check if
Applicable
___ Convicted Vendor List
___ Suspended Vendor List
___ Discriminatory Vendor List
___ Federal Excluded Parties List
___ Vendor Complaint List
FURTHER DECLARANT SAYETH NOT.
Under penalties of perjury, and as the person authorized to sign this statement, I declare that I have read the
foregoing statement and that the facts stated in it are true and that this firm is in full compliance with the above
requirements. ______________________________
(Print name of Declarant)
By: ___________________________
(Signature of Declarant)
ACKNOWLEDGEMENT
STATE OF FLORIDA )
COUNTY OF MIAMI-DADE )
On this the ____ day of ______________, 20_____, before me, the undersigned authority, personally
appeared ____________________________________ who is personally know to me or who provided the
following identification ______________ and who took an oath or affirmed that that he/she/they executed the
foregoing Affidavit as the Declarant.
WITNESS my hand and official seal. ____________________________
Notary Public, State of Florida
NOTARY PUBLIC:
SEAL ____________________________
(Name of Notary Public: Print,
Stamp or type as commissioned.)
27 of 118 32
RELATED PARTY TRANSACTION VERIFICATION FORM
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
I ______________________________, individually and on behalf of ______________________________
(“Firm”) have Name of Representative Company/Vendor/Entity read the City of South Miami (“City”)’s Code of Ethics,
Section 8A-1 of the City’s Code of Ordinances and I hereby certify, under penalties of perjury that to the best of
my knowledge, information and belief:
(1) neither I nor the Firm have any conflict of interest (as defined in section 8A-1) with regard to the contract or
business that I, and/or the Firm, am(are) about to perform for, or to transact with, the
City, and
(2) neither I nor any employees, officers, directors of the Firm, nor anyone who has a financial interest greater
than 5% in the Firm, has any relative(s), as defined in section 8A-1, who is an employee of the City or who is(are)
an appointed or elected official of the City, or who is(are) a member of any public body created by the City
Commission, i.e., a board or committee of the City, [while the ethics code still applies, if the person executing this
form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (2) must be based
solely on the signatory’s personal knowledge and he/she is not required to make an independent investigation as to
the relationship of employees or those who have a financial interest in the Firm.]; and
(3) neither I nor the Firm, nor anyone who has a financial interest greater than 5% in the Firm, nor any member of
those persons’ immediate family (i.e., spouse, parents, children, brothers and sisters) has transacted or entered
into any contract(s) with the City or has a financial interest, direct or indirect, in any business being transacted
with the city, or with any person or agency acting for the city, other than as follows:
____________________________________________________________________________________
_ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you
must make reference, on the above line, to the additional sheet and the additional sheet must be signed under
oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose
stock is publicly traded, the statement in this section (3) must be based solely on the signatory’s personal
knowledge and he/she is not required to make an independent investigation as to the relationship of those who
have a financial interest in the Firm.]; and
(4) no elected and/or appointed official or employee of the City of South Miami, or any of their immediate family
members (i.e., spouse, parents, children, brothers and sisters) has a financial interest, directly or indirectly, in the
contract between you and/or your Firm and the City other than the following individuals whose interest is set
forth following their names: _______________________________________________
(if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must
make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath).
The names of all City employees and that of all elected and/or appointed city officials or board members, who
own, directly or indirectly, an interest of five percent (5%) or more of the total assets of capital stock in the firm
are as follows:
_______________________________________________________________________________
(if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must
make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath).
[while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is
publicly traded, the statement in this section (4) must be based solely on the signatory’s personal knowledge and
he/she is not required to make an independent investigation as to the financial interest in the Firm of city
employees, appointed officials or the immediate family members of elected and/or appointed official or employee.]
(5) I and the Firm further agree not to use or attempt to use any knowledge, property or resource which may
come to us through our position of trust, or through our performance of our duties under the terms of the
contract with the City, to secure a special privilege, benefit, or exemption for ourselves, or others. We agree that
we may not disclose or use information, not available to members of the general public, for our personal gain or
benefit or for the personal gain or benefit of any other person or business entity, outside of the normal gain or
benefit anticipated through the performance of the contract.
(6) I and the Firm hereby acknowledge that we have not contracted or transacted any business with the City or
any person or agency acting for the City, and that we have not appeared in representation of any third party 28 of 118 33
before any board, commission or agency of the City within the past two years other than as
follows:____________________________________________________________________________ (if
necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must
make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath).
X:\Purchasing\Vendor Registration\12.28.12 RELATED PARTY TRANSACTION VERIFICATION FORM [3].docx
(7) Neither I nor any employees, officers, or directors of the Firm, nor any of their immediate family (i.e., as a
spouse, son, daughter, parent, brother or sister) is related by blood or marriage to: (i) any member of the City
Commission; (ii) any city employee; or (iii) any member of any board or agency of the City other than as follows:
____________________________________________(if necessary, use a separate sheet to supply additional
information that will not fit on this line; however, you must make reference, on the above line, to the additional
sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person
executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (7)
must be based solely on the signatory’s personal knowledge and he/she is not required to make an independent
investigation as to the relationship by blood or marriage of employees, officers, or directors of the Firm, or of any
of their immediate family to any appointed or elected officials of the City, or to their immediate family members].
(8) No Other Firm, nor any officers or directors of that Other Firm or anyone who has a financial interest greater
than 5% in that Other Firm, nor any member of those persons’ immediate family (i.e., spouse, parents, ch ildren,
brothers and sisters) nor any of my immediate family members (hereinafter referred to as “Related Parties”) has
responded to a solicitation by the City in which I or the Firm that I represent or anyone who has a financial
interest greater than 5% in the Firm, or any member of those persons’ immediate family (i.e. spouse, parents,
children, brothers and sisters) have also responded, other than the following:
______________________________________________________________________________________ (if
necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must
make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath).
[while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is
publicly traded, the statement in this section (8) must be based solely on the signatory’s personal knowledge and
he/she is not required to make an independent investigation into the Other Firm, or the Firm he/she represents, as
to their officers, directors or anyone having a financial interest in those Firms or any of their any member of those
persons’ immediate family.]
(9) I and the Firm agree that we are obligated to supplement this Verification Form and inform the City of any
change in circumstances that would change our answers to this document. Specifically, after the opening of any
responses to a solicitation, I and the Firm have an obligation to supplement this Verification Form with the name of
all Related Parties who have also responded to the same solicitation and to disclose the relationship of those
parties to me and the Firm.
(10) A violation of the City’s Ethics Code, the giving of any false information or the failure to supplement this
Verification Form, may subject me or the Firm to immediate termination of any agreement with the City, and the
imposition of the maximum fine and/or any penalties allowed by law. Additionally, violations may be considered by
and subject to action by the Miami-Dade County Commission on Ethics.
Under penalties of perjury, and as the person authorized to sign this statement, I declare that I have read the
foregoing statement, that I have made a diligent effort to investigate the matters to which I am attesting
hereinabove and to the best of my knowledge, information and belief the facts stated in it are true and this firm is
in full compliance with the above requirements.
Signature: ___________________________
Print Name & Title: ______________________________
Date: ________________________
29 of 118 34
Sec. 8A-1. - Conflict of interest and code of ethics ordinance.
(a) Designation.
This section shall be designated and known as the "City of South Miami Conflict of Interest and Code of Ethics
Ordinance." This section shall be applicable to all city personnel as defined below, and shall also constitute a
standard of ethical conduct and behavior for all autonomous personnel, quasi-judicial personnel, advisory
personnel and departmental personnel. The provisions of this section shall be applied in a cumulative manner. By
way of example, and not as a limitation, subsections (c) and (d) may be applied to the same contract or transaction.
(b) Definitions. For the purposes of this section the following definitions shall be effective:
(1) The term "commission members" shall refer to the mayor and the members of the city commission.
(2) The term "autonomous personnel" shall refer to the members of autonomous authorities, boards and agencies,
such as the city community redevelopment agency and the health facilities authority.
(3) The term "quasi-judicial personnel" shall refer to the members of the planning board, the environmental review
and preservation board, the code enforcement board and such other individuals, boards and
agencies of the city as perform quasi-judicial functions.
(4) The term "advisory personnel" shall refer to the members of those city advisory boards and agencies whose
sole or primary responsibility is to recommend legislation or give advice to the city commission.
(5) The term "departmental personnel" shall refer to the city clerk, the city manager, department heads, the city
attorney, and all assistants to the city clerk, city manager and city attorney, however titled.
(6) The term "employees" shall refer to all other personnel employed by the city.
(7) The term "compensation" shall refer to any money, gift, favor, thing of value or financial benefit conferred, or
to be conferred, in return for services rendered or to be rendered.
(8) The term "controlling financial interest" shall refer to ownership, directly or indirectly, of ten percent or more
of the outstanding capital stock in any corporation or a direct or indirect interest of ten percent or more in a fi rm,
partnership, or other business entity at the time of transacting business with the city.
(9) The term "immediate family" shall refer to the spouse, parents, children, brothers and sisters of the person
involved.
(10) The term "transact any business" shall refer to the purchase or sale by the city of specific goods or services
for consideration and to submitting a bid, a proposal in response to a Solicitation, a statement of qualifications in
response to a request by the city, or entering into contract n egotiations for the provision
on any goods or services, whichever first occurs.
(c) Prohibition on transacting business with the city.
No person included in the terms defined in paragraphs (b)(1) through (6) and in paragraph (b)(9) shall enter into
any contract or transact any business in which that person or a member of the immediate family has a financial
interest, direct or indirect with the city or any person or agency acting for the city, and any such contract,
agreement or business engagement entered in violation of this subsection shall render the transaction voidable.
Willful violation of this subsection shall constitute malfeasance in office and shall affect forfeiture of office or
position. Nothing in this subsection shall prohibit or make illegal:
(1) The payment of taxes, special assessments or fees for services provided by the city government;
(2) The purchase of bonds, anticipation notes or other securities that may be issued by the city through
underwriters or directly from time to time.
Waiver of prohibition. The requirements of this subsection may be waived for a particular transaction only by four
affirmative votes of the city commission after public hearing upon finding that:
(1) An open-to-all sealed competitive proposal has been submitted by a city person as defined in paragraphs (b)(2),
(3) and (4);
(2) The proposal has been submitted by a person or firm offering services within the scope of the practice of
architecture, professional engineering, or registered land surveying, as defined by the laws of the state and
pursuant to the provisions of the Consultants' Competitive Negotiation Act, and when the proposal has been
submitted by a city person defined in paragraphs (b)(2), (3) and (4);
(3) The property or services to be involved in the proposed transaction are unique and the city cannot avail itself
of such property or services without entering a transaction which would violate this subsection but for waiver of
its requirements; and
(4) That the proposed transaction will be in the best interest of the city.
This subsection shall be applicable only to prospective transactions, and the city commission may in no case ratify a
transaction entered in violation of this subsection.
Provisions cumulative. This subsection shall be taken to be cumulative and shall not be construed to amend or repeal
any other law pertaining to the same subject matter.
(d) Further prohibition on transacting business with the city.
No person included in the terms defined in paragraphs (b)(1) through (6) and in paragraph (b)(9) shall enter into
any contract or transact any business through a firm, corporation, partnership or business entity in which that 30 of 118 35
person or any member of the immediate family has a controlling financial interest, direct or indirect, with the city
or any person or agency acting for the city, and any such contract, agreement or business engagement entered in
violation of this subsection shall render the transaction voidable. The remaining provisions of subsection (c) will
also be applicable to this subsection as though incorporated by recitation.
Additionally, no person included in the term defined in paragraph (b)(1) shall vote on or participate in any way in
any matter presented to the city commission if that person has any of the following re lationships with any of the
persons or entities which would be or might be directly or indirectly affected by any action of the city commission:
(1) Officer, director, partner, of counsel, consultant, employee, fiduciary or beneficiary; or
(2) Stockholder, bondholder, debtor, or creditor, if in any instance the transaction or matter would affect the
person defined in paragraph (b)(1) in a manner distinct from the manner in which it would affect the public
generally. Any person included in the term defined in paragraph (b)(1) who has any of the specified relationships or
who would or might, directly or indirectly, realize a profit by the action of the city commission shall not vote on or
participate in any way in the matter.
(E) Gifts.
(1) Definition. The term "gift" shall refer to the transfer of anything of economic value, whether in the form of
money, service, loan, travel, entertainment, hospitality, item or promise, or in any other form, without
adequate and lawful consideration.
(2) Exceptions. The provisions of paragraph (e)(1) shall not apply to:
a. Political contributions specifically authorized by state law;
b. Gifts from relatives or members of one's household, unless the person is a conduit on behalf of a third party to
the delivery of a gift that is prohibited under paragraph (3);
c. Awards for professional or civic achievement;
d. Material such as books, reports, periodicals or pamphlets which are solely informational or of an advertising
nature.
(3) Prohibitions. A person described in paragraphs (b)(1) through (6) shall neither solicit nor demand any gift. It is
also unlawful for any person or entity to offer, give or agree to give to any person included in the terms defined in
paragraphs (b)(1) through (6), or for any person included in the terms defined in paragraphs (b)(1) through (6) to
accept or agree to accept from another person or entity, any gift for or because of:
a. An official public action taken, or to be taken, or which could be taken, or an omission or failure to take a pu blic
action;
b. A legal duty performed or to be performed, or which could be performed, or an omission or failure to perform
a legal duty;
c. A legal duty violated or to be violated, or which could be violated by any person included in the term defined in
paragraph (b)(1); or
d. Attendance or absence from a public meeting at which official action is to be taken.
(4) Disclosure. Any person included in the term defined in paragraphs (b)(1) through (6) shall disclose any gift, or
series of gifts from anyone person or entity, having a value in excess of $25.00. The disclosure shall be made by
filing a copy of the disclosure form required by chapter 112, Florida Statutes, for "local
officers" with the city clerk simultaneously with the filing of the form with the clerk of the county and with the
Florida Secretary of State.
(f) Compulsory disclosure by employees of firms doing business with the city.
Should any person included in the terms defined in paragraphs (b)(1) through (6) be employed by a corporation,
firm, partnership or business entity in which that person or the immediate family does not have a controlling
financial interest, and should the corporation, firm, partnership or business entity have substantial business
commitments to or from the city or any city agency, or be subject to direct regulation by the city or a city agency,
then the person shall file a sworn statement disclosing such employment and interest with the clerk of the city.
(g) Exploitation of official position prohibited.
No person included in the terms defined in paragraphs (b)(1) through (6) shall corruptly use or attempt to use an
official position to secure special privileges or exemptions for that person or others.
(h) Prohibition on use of confidential information.
No person included in the terms defined in paragraphs (b)(1) through (6) shall accept employment or engage in
any business or professional activity which one might
reasonably expect would require or induce one to disclose confidential information acquired by re ason of an
official position, nor shall that person in fact ever disclose confidential information garnered or gained through an
official position with the city, nor shall that person ever use such information, directly or indirectly, for personal
gain or benefit.
(i) Conflicting employment prohibited.
No person included in the terms defined in paragraphs (b)(1) through (6) shall accept other employment which
would impair independence of judgment in the performance of any public duties.
(j) Prohibition on outside employment. 31 of 118 36
(1) No person included in the terms defined in paragraphs (b)(6) shall receive any compensation for services as an
officer or employee of the city from any source other than the city, except as may be permitted as follows:
a. Generally prohibited. No full-time city employee shall accept outside employment, either incidental, occasional or
otherwise, where city time, equipment or material is to be used or where such employment or any part thereof is
to be performed on city time.
b. When permitted. A full-time city employee may accept incidental or occasional outside employment so long as
such employment is not contrary, detrimental or adverse to the interest of the city or any of its departments and
the approval required in subparagraph c. is obtained.
c. Approval of department head required. Any outside employment by any full-time city employee must first be
approved in writing by the employee's department head who shall maintain a complete record of such
employment.
d. Penalty. Any person convicted of violating any provision of this subsection shall be punished as provided in
section 1-11 of the Code of Miami-Dade County and, in addition shall be subject to dismissal by the appointing
authority. The city may also assess against a violator a fine not to exceed $500.00 and the costs of investigation
incurred by the city.
(2) All full-time city employees engaged in any outside employment for any person, firm, corporation or entity
other than the city, or any of its agencies or instrumentalities, shall file, under oath, an annual report indicating the
source of the outside employment, the nature of the work being done and any amount of money or other
consideration received by the employee from the outside employment. City employee reports shall be filed with
the city clerk. The reports shall be available at a reasonable time and place for inspection by the public. The city
manager may require monthly reports from individual employees or groups of employees for good cause.
(k) Prohibited investments.
No person included in the terms defined in paragraphs (b)(1) through (6) or a member of the immediate family
shall have personal investments in any enterprise which will create a substantial conflict between private interests
and the public interest.
(I) Certain appearances and payment prohibited.
(1) No person included in the terms defined in paragraphs (b)(1), (5) and (6) shall appear before any city board or
agency and make a presentation on behalf of a third person with respect to any matter, license, contract,
certificate, ruling, decision, opinion, rate schedule, franchise, or other benefit sought by the third person. Nor shall
the person receive any compensation or gift, directly or indirectly, for services rendered to a third per son, who
has applied for or is seeking some benefit from the city or a city agency, in connection with the particular benefit
sought by the third person. Nor shall the person appear in any court or before any administrative tribunal as
counselor legal advisor to a party who seeks legal relief from the city or a city agency through the suit in question.
(2) No person included in the terms defined in paragraphs (b)(2), (3) and (4) shall appear before the city
commission or agency on which the person serves, either directly or through an associate, and make a
presentation on behalf of a third person with respect to any matter, license, contract, certificate, ruling, decision,
opinion, rate schedule, franchise, or other benefit sought by the third person. Nor sh all such person receive any
compensation or gift, directly or indirectly, for services rendered to a third party who has applied for or is seeking
some benefit from the city commission or agency on which the person serves in connection with the particular
benefit sought by the third party. Nor shall the person appear in any court or before any administrative tribunal as
counselor legal advisor to a third party who seeks legal relief from the city commission or agency on which such
person serves through the suit in question.
(m) Actions prohibited when financial interests involved.
No person included in the terms defined in paragraphs (b) (1) through (6) shall participate in any official action
directly or indirectly affecting a business in which that person or any member of the immediate family has a
financial interest. A financial interest is defined in this subsection to include, but not be limited to, any direct or
indirect interest in any investment, equity, or debt.
(n) Acquiring financial interests.
No person included in the terms defined in paragraphs (b)(1) through (6) shall acquire a financial interest in a
project, business entity or property at a time when the person believes or has reason to believe that the financial
interest may be directly affected by official actions or by official actions by the city or city agency of which the
person is an official, officer or employee.
(0) Recommending professional services.
No person included in the terms defined in paragraphs (b)(1) through (4) may recommend the services of any
lawyer or law firm, architect or architectural firm, public relations firm, or any other person or firm, professional
or otherwise, to assist in any transaction involving the city or any of its agencies, provided that a recommendation
may properly be made when required to be made by the duties of
office and in advance at a public meeting attended by other city officials, officers or employees.
(p) Continuing application after city service.
32 of 118 37
(1) No person included in the terms defined in paragraphs (b)(1), (5) and (6) shall, for a period of two years after
his or her city service or employment has ceased, lobby any city official [as defined in paragraphs
(b)(1) through (6)] in connection with any judicial or other proceeding, application, Solicitation, RFQ, bid, request
for ruling or other determination, contract, claim, controversy, charge, accusation, arrest or other particular
subject matter in which the city or one of its agencies is a party or has any interest whatever, whether direct or
indirect. Nothing contained in this subsection shall prohibit any individual from submitting a routine administrative
request or application to a city department or agency during the two -year period after his or her service has
ceased.
(2) The provisions of the subsection shall not apply to persons who become employed by governmental entities,
501(c)(3) non-profit entities or educational institutions or entities, and who lobby on behalf of those entities in
their official capacities.
(3) The provisions of this subsection shall apply to all persons described in paragraph (p)(1) whose city service or
employment ceased after the effective date of the ordinance from which this section derives.
(4) No person described in paragraph (p)(1) whose city service or employment ceased within two years prior to
the effective date of this ordinance shall for a period of two years after his or her service or employment enter
into a lobbying contract to lobby any city official in connection with any subject described in paragraph (p)(1) in
which the city or one of its agencies is a party or has any direct and substantial interest; and in which he or she
participated directly or indirectly through decision, approval, disapproval, recommendation, the rendering of
advice, investigation, or otherwise, during his or her city service or employment. A person participated "directly"
where he or she was substantially involved in the particular subject matter through decision, approval, disapproval,
recommendation, the rendering of advice, investigation, or otherwise, during his or her city service or
employment. A person participated "indirectly" where he or she knowingly participated in any way in the particular
subject matter through decision, approval, disapproval, recommendation, the rendering of advice, investigation, or
otherwise, during his or her city service or employment. All persons covered by this paragraph shall execute an
affidavit on a form approved by the city attorney prior to lobbying any city official attesting that the
requirements of this subsection do not preclude the person from lobbying city officials.
(5) Any person who violates this subsection shall be subject to the penalties provided in section 8A -2(p).
(q) City attorney to render opinions on request.
Whenever any person included in the terms defined in paragraphs (b)(1) through (6) and paragraph (b)(9) is in
doubt as to the proper interpretation or application of this conflict of interest and code of ethics ordinance, or
whenever any person who renders services to the city is in doubt as to the applicability of the ordinance that
person, may submit to the city attorney a full written statement of the facts and questions. The city attorney shall
then render an opinion to such person and shall publish these opinions without use of the name of the person
advised unless the person permits the use of a name.
33 of 118 38
PRESENTATION TEAM
DECLARATION/AFFIDAVIT OF REPRESENTATION
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
This affidavit is not required for compliance with the City’s Solicitation; however, it may be used to avoid
the need to register members of your presentation team as lobbyists. Pursuant to City Ordinance 28-14-
2206 (c)(9), any person who appears as a representative for an individual or firm for an oral presentation
before a City certification, evaluation, selection, technical review or similar committee, must list on an
affidavit provided by the City staff, all individuals who may make a presentation. The affidavit must be
filed by staff with the Clerk's office at the time the committee's proposal is submitted to the City Manager.
For the purpose of this subsection only, the listed members of the presentation team, with the exception
of any person otherwise required to register as a lobbyist, must not be required to pay any registration
fees. No person may appear before any committee on behalf of an anyone unless he or she has been
listed as part of the firm's presentation team pursuant to this paragraph or unless he or she is registered
with the City Clerk's office as a lobbyist and has paid all applicable lobbyist registration fees.
Pursuant to '92.525(2), Florida Statutes, the undersigned, ________________, makes the following
declaration under penalties of perjury:
Listed below are all individuals who may make a presentation on behalf of the entity that the affiant
represents. Please note; No person may appear before any committee on behalf of anyone unless he
or she has been listed as part of the firm's presentation team pursuant to this paragraph or unless he
or she is registered with the Clerk's office as a lobbyist and has paid all applicable lobbyist registration
fees.
NAME TITLE
For the purpose of this Affidavit of Representation only, the listed members of the presentation team,
with the exception of any person otherwise required to register as a lobbyist, will not be required to pay
any registration fees. The Affidavit of Representation must be filed with the City Clerk's office at the time
the committee's proposal is submitted to the City as part of the procurement process.
Under penalties of perjury, I declare that I have read the foregoing declaration and that the facts stated
in it are true and specifically that the persons listed above are the members of the presentation team of
the entity listed below.
Executed this ______ day of ___________________, 20 ___.
___________________________
Signature of Representative
___________________________ ______________________________
Print Name and Title Print name of entity being represented
END OF SECTION
34 of 118 39
NOTICE OF AWARD
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
The City has considered the Proposal submitted by your firm for the SUNSET DRIVE ROADWAY &
LANDSCAPING MODIFICATIONS RFP #PW2020-19 in response to its advertisement for Request for
Proposal and Instructions to Respondents.
You are hereby notified that your Proposal has been accepted for the SUNSET DRIVE ROADWAY &
LANDSCAPING MODIFICATIONS RFP #PW2020-19 in the amount of $___________________,
broken down as follows:
LUMP SUM
TOTAL:
OPTION A:
LUMP SUM
TOTAL:
OPTION B
LUMP SUM
TOTAL:
OPTION C :
You are required by the Instructions to Respondents to execute the Contract Documents at the time of submittal
of proposal and to furnish any required bonding, including a Performance Bond, Payment Bond, and insurance
documents (see Proposal Submittal Checklist Form) within ten (10) day from the date of this notice to you.
Notwithstanding the fact that you have agreed, by responding to the Solicitation, to the terms of the contract
attached to the Solicitation package, if you fail to execute said Contract and to furnish said bonds, the required
insurance documentation within ten (10) calendar days from the date of this notice, the CITY will have the right and
be entitled, in its sole and absolute discretion, to disqualify the Proposal, revoke the award and retain the
Proposal/Bid Bond/Security. Please be advised that if the contract price exceeds $5,000.00 or if it is a multi -year
contract requiring payment out of more than one year’s appropriation, the award and the contract must be approved
by the City Commission before it is binding on the City. Moreover, the award is subject to rescission if the City
Manager determines that it is not in the best interest of the City.
BY: __________________________________
Shari Kamali
City Manager
Dated this ____ day of ______________, 20____
ACCEPTANCE OF NOTICE
Receipt of the above Notice of Award is hereby acknowledged by _______________________________
On this the ______ day of ____________________, 20____.
BY: __________________________
TITLE: __________________________
You are required to return an acknowledged copy of this Notice of Award to the City Manager.
END OF SECTION
35 of 118 40
NOTICE TO PROCEED
PUBLIC CONSTRUCTION CONTRACT
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
TO: DATE:
PROJECT DESCRIPTION: SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19 in accordance with Plans and specifications, if any, as may be prepared in whole or in part by
CONSULTANT, referenced in the Supplementary Conditions and Contract Documents.
You are hereby notified to commence Work in accordance with the Contract dated __________, on or before
___________. You are to complete the work within Option A: 60 calendar days; Option B: 60 calendar
days; Option C; 120 calendar days. The date of completion of all Work is therefore ____________20___.
City of South Miami
BY: __________________________
___________________________
(print name)
City Manager, or designee
ACCEPTANCE OF NOTICE
Receipt of the above Notice to Proceed is hereby acknowledged by ______________________________
on this day of , 20____.
BY: ___________________________
TITLE: ___________________________
END OF SECTION
36 of 118 41
EXHIBIT 1
ATTACHMENT A
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
Scope of Services & Schedule of Values/Summary of Quantities
I. General Requirements:
The work specified in this Request for Proposal (RFP) consists of furnishing all goods,
materials, supplies and services necessary to provide a completed project that meets all
of the needs described in this Scope of Services and as otherwise described in this RFP
(the “Work”). The Work is to be performed in accordance with the specifications and
the contract documents. The Work includes, but is not limited to keeping the project site
clean and safe, the furnishing all labor of Contractor and the labor of all allowable
subcontractors, the cost of dumpster(s) and the disposal of materials as well as the cost
of all engineering and architectural plans, drawings, technical specifications and permits,
all necessary equipment, including rental equipment machinery, tools, transportation,
freight, the coordination with any other City contractor, subcontractor and utility
companies (i.e. power, gas, water), construction safety measures including erecting fencing
and cones, root pruning, sod restoration at affected areas to the City’s satisfaction,
cleaning the construction siter at the end of each working day, maintenance of traffic, and
hiring of off-duty City police officer if required by the City and to perform all of the Work
that is necessary to provide a completed project that meets all of the needs described in
this SCOPE OF SERVICES.
Prior to any digging, Respondents must locate all underground utilities and other facilities
as well as contacting Sunshine 811 to coordinate the process between excavators and
member utilities in Florida so that they can mark the approximate location of underground
lines, pipes and cables on construction site.
Permit fees (not taxes) are waived for permits issued by the City of South Miami. Taxes,
and if required, permit fees from other government entities, are the responsibility of the
Respondent/Contractor however, in all cases; it is the responsibility of
Respondent/Contractor to obtain all licenses and laboratory tests and to prepare
all engineering and architectural plans, drawings, and technical specifications
in order to secure any and all permits required to complete this contractual
service/project. The Contractor is responsible to prepare, pay for and deliver
as built drawings under seal of a licensed architect or engineer at the
conclusion of the Work.
The work associated with this project should be reflected in the Respondent’s
proposal and “Schedule of Values Form, “Scope of Services,” Exhibit 1, Attachment
B.
II. Scope of Work:
The scope of work for Sunset Drive Modifications include a complete modification to the
roadway alignment at Sunset Drive from SW 62nd Avenue to SW 61st Court to achieve
a smoother transition in the eastbound travel lanes and median landscape and irrigation 37 of 118 42
improvements on Sunset Drive between SW 69th Avenue and US-1. The new landscape
will include a variety of predominately native and xeric tree, palm, and shrub species. The
irrigation system was updated to allow for 100% coverage and to provide an automatic
controller with a rain sensor. The Schedule of Values is divided into two zones:
OPTION A: US 1 TO SW 62nd AVENUE
OPTION B: SW 62nd AVENUE TO SW 69TH AVENUE
OPTION C: THE ENTIRE PROJECT, COMBINATION OF A & B
Work activity is limited to the hours from 7:00 a.m. through 6:00 p.m., on
weekdays from Monday through Friday. Lane Closure on Sunset Drive is NOT
allowed any time before 9:00 a.m.
III. Site Location:
Site Location Option A – US-1 to SW 62nd Avenue
Site Location Option B – SW 62nd Avenue to SW 69th Avenue
Please refer to Exhibit 1, Scope of Services, Attachment C, “Sunset Drive Roadway
& Landscaping Modifications Plans”
IV. Pricing:
Respondents shall submit a Lump Sum Price, in accordance in the Scope of Services,
Attachments A, B & C, in Exhibit 4, “Respondents Cost & Technical Proposal,” for:
OPTION A: US 1 TO SW 62nd AVENUE
OPTION B: SW 62nd AVENUE TO SW 69TH AVENUE
OPTION C: THE ENTIRE PROJECT, COMBINATION OF A & B
NOTE: The City reserves the right to award the project to a single
Respondent for each Option; Option A, Option B, or Option C (i.e. one
Respondent may be awarded Option A and another respondent may be
awarded Option B). Respondents may submit Lum Sum pricing for a single
Option or multiple Options.
V. Construction Notes:
Values utilized for the purpose of this RFP are approximate. Contractor is responsible to
field verify the areas, and quantities as per the limits defined by the site plan.
WHEN SUBMITTING THE BID PACKAGE, THE RESPONDENT IS TO
PROVIDE A LUMP SUM PRICE PER THE SCHEDULE OF VALUES, EXHIBIT
1, “SCOPE OF SERVICES, ATTACHMENT B” FOR OPTION A, OPTION B AND
OPTION C AS DESCRIBED IN SECTION III. SCOPE OF SERVICES
38 of 118 43
THE SCHEDULE OF VALUES IS PROVIDED FOR ESTIMATING
PURPOSES, BUT THE LUMP SUM AMOUNT SHALL BE PROVIDED
UNDER EXHIBIT 4, RESPONDENTS COST & TECHNICAL PROPOSAL.”
THE RESPONDENT MUST CARRY THE TREE MITIGATION ALLOTMENT
AS WELL AS THE CONTINGENCY IN THEIR TOTAL BASE BID.
RESPONDENT MUST PROVIDE PRICING FOR THE ADD ALTERNATES
LISTED ON THE PAY ITEMS.
VI. Plans and Specifications:
Please refer to Exhibit 1, “Scope of Services” and Attachment C, “Sunset Drive
Roadway & Landscaping Modifications Plans.”
VII. Project Duration:
The complete construction of the project is Option A: 60 calendar days; Option B:
60 calendar days; Option C: 120 calendar days from notice to proceed.
VIII. Warranty:
If equipment is being provided, the standard manufacturer’s warranty information must
be provided in writing for all equipment being proposed, including installation by an
authorized dealer before final payment is made. If the manufacturer’s warranty is issued
to the respondent/contractor, it shall be assigned to the City.
NOTE: A Performance and Payment Bond is required for the full amount of the
project
END OF SECTION
39 of 118 44
EXHIBIT 1
SCOPE OF SERVICES
ATTACHMENT B
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
“SCHEDULE OF VALUES”
NOTE: THE SCHEDULE OF VALUES IS PROVIDED FOR
ESTIMATING PURPOSES, BUT THE LUMP SUM AMOUNT
SHALL BE PROVIDED UNDER EXHIBIT 4, RESPONDENTS
COST & TECHNICAL PROPOSAL.”
40 of 118 45
1 110-1-1 Clear and Grubbing L.S.1
2 110-4 Removal of Existing Concrete S.Y.80
3 110-4 Removal of Existing Concrete Curb L.F.390
4 104-1 Prevention, Control and Abatement of Erosion and Water Pollution L.S.1
5 110-15-2 Existing Tree Protection and Preservation L.S.1
6 160-4 Type "B" Stabilization (12") (Min. L.B.R. of 40)S.Y.36
7 210-2 Limerock Base (8") (Primed)S.Y.36
8 327-70-1 Milling Existing Asphalt Pavement (1" Average Depth)S.Y.540
9 337-7-82 Asphalt Concrete Friction Course Traffic C, FC-9.5, High Polymer (1" Thick) (Resurfacing)TON 50
10 520-1-10 Concrete Curb and Gutter Type "F" includes Cost of Limerock L.F.175
11 520-2-4 Concrete Curb Type "D" includes Cost of Limerock L.F.165
12 520-3 Concrete Valley Gutter L.F.50
13 522-1 Concrete Sidewalk (4" Thick)S.Y.80
14 526-1 Pavers, Architectural, Sidewalk S.Y.40
15 527-2 Detectable Warning Surface S.F.30
16 570-1-2 Sodding (Pensacola Bahia or Match Existing) (Includes Watering and Maintenance)S.Y.180
17 700-1-60 Single Post Sign, Remove A.S.1
18 706-3 Retro-Reflective Pavement Markers (RPMs)EACH 21
19 711-15-101 Thermoplastic (white) (solid) (6")L.F.700
20 711-15-201 Thermoplastic (yellow) (solid) (6")L.F.260
21 711-11-141 Thermoplastic (white) (skip) (6")L.F.100
22 425-6 Adjust existing valve boxes & meter boxes L.S.1
23 425-74-1 Clean Existing Catch Basins EACH 2
24 580-5-22 Landscaping (Including Tree Removal & Irrigation)L.S.1
25 590-70 Irrigation L.S.1
26 101-1 MOBILIZATION(10%)L.S.1
27 102-1 MAINTENANCE OF TRAFFIC L.S.1
28 102-14 TRAFFIC CONTROL OFFICER H.R.120
29 SUE-001 ADVANCED UTILITIES EXPLORATION SOFT DIGGING EXPLORATION L.S.1
30 PERM-ALLOW PERMIT ALLOWANCE(5%)L.S.1
31 CONT CONTINGENCY(10%)L.S.1
City of South Miami - SCHEDULE OF VALUES
Sunset Drive Modifications (100% Submittal)
South Miami Landscaping, Roadway & Drainage Improvements
OPTION A: US-1 TO SW 62ND AVE
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
ROADWAY PAY ITEMS (OPTION A)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
DRAINAGE PAY ITEMS (OPTION A)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
MISCELLANEOUS ITEMS (OPTION A)
LANDSCAPING PAY ITEMS (OPTION A)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
41 of 118 46
32 580-5-22 Landscaping ( Including Tree Removal & Irrigation)L.S.1
33 590-70 Irrigation L.S.1
34 101-1 MOBILIZATION(10%)L.S.1
35 102-1 MAINTENANCE OF TRAFFIC L.S.1
36 102-14 TRAFFIC CONTROL OFFICER H.R.120
37 SUE-001 ADVANCED UTILITIES EXPLORATION SOFT DIGGING EXPLORATION L.S.1
38 PERM-ALLOW PERMIT ALLOWANCE(5%)L.S.1
39 CONT CONTINGENCY(10%)L.S.1
City of South Miami - SCHEDULE OF VALUES
Sunset Drive Modifications (100% Submittal)
South Miami Landscaping Improvements
OPTION B: SW 62ND AVE TO SW 69TH AVE
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
MISCELLANEOUS ITEMS (OPTION B)
LANDSCAPING PAY ITEMS (OPTION B)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
42 of 118 47
1 110-1-1 Clear and Grubbing L.S.1
2 110-4 Removal of Existing Concrete S.Y.80
3 110-4 Removal of Existing Concrete Curb L.F.390
4 104-1 Prevention, Control and Abatement of Erosion and Water Pollution L.S.1
5 110-15-2 Existing Tree Protection and Preservation L.S.1
6 160-4 Type "B" Stabilization (12") (Min. L.B.R. of 40)S.Y.36
7 210-2 Limerock Base (8") (Primed)S.Y.36
8 327-70-1 Milling Existing Asphalt Pavement (1" Average Depth)S.Y.540
9 337-7-82 Asphalt Concrete Friction Course Traffic C, FC-9.5, High Polymer (1" Thick) (Resurfacing)TON 50
10 520-1-10 Concrete Curb and Gutter Type "F" includes Cost of Limerock L.F.175
11 520-2-4 Concrete Curb Type "D" includes Cost of Limerock L.F.165
12 520-3 Concrete Valley Gutter L.F.50
13 522-1 Concrete Sidewalk (4" Thick)S.Y.80
14 526-1 Pavers, Architectural, Sidewalk S.Y.40
15 527-2 Detectable Warning Surface S.F.30
16 570-1-2 Sodding (Pensacola Bahia or Match Existing) (Includes Watering and Maintenance)S.Y.180
17 700-1-60 Single Post Sign, Remove A.S.1
18 706-3 Retro-Reflective Pavement Markers (RPMs)EACH 21
19 711-15-101 Thermoplastic (white) (solid) (6")L.F.700
20 711-15-201 Thermoplastic (yellow) (solid) (6")L.F.260
21 711-11-141 Thermoplastic (white) (skip) (6")L.F.100
22 425-6 Adjust existing valve boxes & meter boxes L.S.1
23 425-74-1 Clean Existing Catch Basins EACH 2
24 580-5-22 Landscaping (Including Tree Removal & Irrigation)L.S.1
25 590-70 Irrigation L.S.1
26 101-1 MOBILIZATION(10%)L.S.1
27 102-1 MAINTENANCE OF TRAFFIC L.S.1
28 102-14 TRAFFIC CONTROL OFFICER H.R.240
29 SUE-001 ADVANCED UTILITIES EXPLORATION SOFT DIGGING EXPLORATION L.S.1
30 PERM-ALLOW PERMIT ALLOWANCE(5%)L.S.1
31 CONT CONTINGENCY(10%)L.S.1
City of South Miami - SCHEDULE OF VALUES
Sunset Drive Modifications (100% Submittal)
South Miami Landscaping, Roadway & Drainage Improvements
OPTION C: US-1 TO SW 69TH AVE (OPTION A & B)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
ROADWAY PAY ITEMS (OPTION C)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
LANDSCAPING PAY ITEMS (OPTION C)
DRAINAGE PAY ITEMS (OPTION C)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
MISCELLANEOUS ITEMS (OPTION C)
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY
43 of 118 48
EXHIBIT 1
SCOPE OF SERVICES
ATTACHMENT C
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
“SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
PLANS”
Prepared by:
Stantec
44 of 118 49
45 of 11850
SUMMARY OF QUANTITIESDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*G-01SUMMARY OF QUANTITIES46 of 11851
Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*G-02GENERAL NOTES47 of 11852
WIIEEEEEESDD6130615061806193616161436101C-1DEMOLITION PLANSEE PLANSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*NSW 72ND STREET(SUNSET DRIVE)SW 61ST CT CIR
LEGENDSW 61ST CT CIR48 of 11853
WIIEEEEEESDD6130615061806193616161436101C-2GEOMETRY PLANSEE PLANSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*NSW 61ST CT CIRSW 72ND STREET(SUNSET DRIVE)LEGENDSW 61ST CT CIR49 of 11854
WIIEEEEEESDD6130615061806193616161436101C-3PAVEMENT MARKING PLANSEE PLANSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*NSW 72ND STREET(SUNSET DRIVE)SW 61ST CT CIR
LEGENDSW 61ST CT CIR50 of 11855
0+001+002+003+004+005+0012345678910111213141517181920212223Exist tree off-siteExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.01EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.011EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN51 of 11856
6+007+008+009+0010+0011+0020242547484935363726273839404142434445463132333450525155535456575859646667686061626365282930Exist tree off-site69Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.02EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.021EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN52 of 11857
12+0013+0014+0015+0016+0017+0073777879747576707172808283848586878889909181929394959697Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.03EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.031EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN53 of 11858
18+0019+0020+0021+0022+0023+00100101102103104105106107108109111110114115112113979899116Exist tree off-siteExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.04EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.041EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN54 of 11859
24+0025+0026+0027+0028+0029+00116117118119120121122123124125126127128129130131132142143139140141138133134135136137144Exist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.05EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.051EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN55 of 11860
30+0031+0032+0033+0034+0035+00144145146147148149150151152153154155156157158159160161162163164165166167168169170VEMOExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.06EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.061EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN56 of 11861
40+0041+0036+0037+0038+0039+00169170171172173174175176177178179180181182184185190191192193187188189186183Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.07EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.071EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN57 of 11862
42+0046+0047+0043+001+00
10+00 45+0044+00195197196198189194199200201202203204205219218217220229230231232233234235236237238239240241243242244245246247248221222223224206207208209210211225226227215228216212213214Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.08EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.081EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN58 of 11863
48+0049+0050+0051+00248216250249251252253254255256257280281282279278276261262263264265269270271268267266273274275277272283SIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.09EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.091EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: TRANSPLANTS ARE TO BE RELOCATED TO A LOCATION DETERMINED BY THE CITY OF SOUTH MIAMI.59 of 11864
0+001+002+003+004+005+0012345678910111213141517181920212223Exist tree off-siteExist tree off-siteExist tree off-siteBUFR-264CHIH-263ERLI-78ERLI-315CHIH-145FIGI-135PSNE-200SERE-6FIGI-117SRSSRSSRSSRSSRSSRSCHIH-50ERLI-206BUFR-478FIGI-120QUVI-4Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.01PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.011PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.60 of 11865
6+007+008+009+0010+0011+0020242547484935363726273839404142434445463132333450525155535456575859646667686061626365282930Exist tree off-site69ERLI-245BUFR-478CHIH-54FIGI-120ARGL-125ERLI-82ERLI-88ARGL-124CHIH-58SRSSRSSRSERLI-230ARGL-200QUVI-6VEMO-1SERE-3SRSSRSFIGI-153CHIH-257SRSSRSSRSSRSSRSSRSSERE-6Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.02PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.021PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.61 of 11866
12+0013+0014+0015+0016+0017+0073777879747576707172808283848586878889909181929394959697SRSSRSSRSARGL-105ERLI-191FIGI-125QUVI-1SERE-3ARGL-101ERLI-129QUVI-2SERE-5SRSSRSERLI-170ARGL-127ERLI-147FIGI-60FIGI-60CHIH-116BUFR-207SRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.03PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.031PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.62 of 11867
18+0019+0020+0021+0022+0023+00100101102103104105106107108109111110114115112113979899116Exist tree off-siteExist tree off-siteExist tree off-siteARGL-416ERLI-353ERLI-170SERE-3CHIH-132BUFR-207QUVI-3ERLI-324ARGL-460BUFR-516SRSSRSSRSSRSSRSSRSSERE-3QUVI-2FIGI-70QUVI-2BUFR-389SERE-6FIGI-95ERLI-85QUVI-1BUFR-454CHIH-114SERE-3SRSSRSSRSSRSSRSSRSSRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.04PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.041PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.63 of 11868
24+0025+0026+0027+0028+0029+00116117118119120121122123124125126127128129130131132142143139140141138133134135136137144Exist tree off-siteARGL-370ERLI-180SRSSRSSRSSERE-4FIGI-83ERLI-115CHIH-92BUSI-2FIGI-80ERLI-110FIGI-42ERLI-163SRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.05PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.051PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.64 of 11869
30+0031+0032+0033+0034+0035+00144145146147148149150151152153154155156157158159160161162163164165166167168169170VEMOExist tree off-siteExist tree off-siteQUVI-1FIGI-240BUFR-475SRSSRSSRSERLI-146BUSI-2CHIH-95SERE-6FIGI-16FIGI-64SRSSRSSRSFIGI-135SERE-3CHIH-195ERLI-60ARGL-290BUFR-680ARGL-140SRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.06PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.061PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.SEE SHEET LA4.01 FORIRRIGATION IN THIS AREA65 of 11870
40+0041+0036+0037+0038+0039+00169170171172173174175176177178179180181182184185190191192193187188189186183Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESRSSRSSRSBUFR-280ARGL-95ERLI-180FIGI-144LYLA-6SERE-6CHIH-95FIGI-154ERLI-206ERLI-155LYLA-1SRSSRSSRSSRSSRSSRSSERE-3Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.07PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.071PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.SEE SHEET LA4.02 FORIRRIGATION IN THIS AREASEE SHEET LA4.02 FORIRRIGATION IN THIS AREA66 of 11871
42+0046+0047+0043+001+00
10+00 45+0044+00195197196198189194199200201202203204205219218217220229230231232233234235236237238239240241243242244245246247248221222223224206207208209210211225226227215228216212213214Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEERLI-230FIGI-200BUFR-145BUFR-145BUFR-62Exist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainExist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainRemove Exist.ScheffleraRemove Exist.ScheffleraSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBERLI-60SPBA-7ERLI-60SPBA-7ERLI-60SPBA-7SBSBSBSBSBSBSBSBSBSBSBSBSBSBERLI-60SPBA-7ERLI-60SPBA-7CLOCK WILL BE ADDRESSED WITHFUTURE CITY HALL PROJECTANTICIPATED BY YEAR 2022/2023.Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.08PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.081PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.SEE SHEET LA4.03 FORIRRIGATION IN THIS AREA67 of 11872
48+0049+0050+0051+00248216250249251252253254255256257280281282279278276261262263264265269270271268267266273274275277272283SIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESPBA-3BUFR-62BUFR-370SPBA-16JACO-5FIGI-142ERLI-328Exist. FIGIto remainRemove Exist.ScheffleraSBSBSBSBSBSBSBERLI-60SPBA-7SBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.09PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.091PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.68 of 11873
Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA3.01PLANTING NOTES, SPECS, AND DETAILSLANDSCAPE SPECIFICATIONSPART 1 - GENERAL1.1 SCOPEA. Contractor shall provide all labor, materials, equipment, supervision, and related work necessary to complete the landscape work in accordance with theintent of the landscape plans, schedules and these specifications. The extent of work is shown on the drawings which are a part of this document.1.2 CONTRACTOR QUALIFICATIONSA. Landscape installation work to be performed by a Contractor Certified by the Florida Nurserymen, Growers and Landscape Association (FNGLA) as aCertified Landscape Contractor. Any pruning to be supervised by an Arborist, certified by the International Society of Arboriculture (ISA) and licensed inMiami-Dade County.1.3 INVESTIGATION OF UTILITIESA. Prior to beginning work, the Contractor shall be responsible to locate existing underground utilities. Check with all utility companies and Sunshine State, call(811).1.4 SUBSTITUTIONSA. Only materials specified will be accepted, unless approved in writing by the Landscape Architect in advance.1.5 PLANT SIZESA. All plant sizes shall equal or exceed the minimum sizes as specified in the plant list. When plant sizes are specified as a range of size, installed materials shallaverage the mean of the range specified. Plants shall be measured following pruning, with branches in normal position. All necessary pruning shall be done atthe time of planting.1.6 PLANT QUALITYA. All plant material shall be equal to or better than Florida No. 1 as classified by “Grades and Standards for Nursery Plants” by the Division of Plant Industry,Florida Department of Agriculture. They shall have a growth habit that is normal for the species; healthy, vigorous, free from insects, disease and injury.B. The Owner or Landscape Architect reserves the right to refuse any plant material which does not conform to the intent of the written specifications or design.C. CIRCLING ROOTS FOUND ON CONTAINER-GROWN MATERIAL WILL NOT BE ACCEPTED UNLESS REMEDIAL ROOT PRUNING, APPROVED BY THELANDSCAPE ARCHITECT IS DONE BEFORE PLANTING.1.7 PLANT QUANTITYA. The plant quantities shown on the plant list are to be used only as an aid to bidders. In the case of discrepancy between the plant list and the plan, thequantity on the plan shall override the plant list.1.8 UNIT PRICESA. The successful bidder shall furnish to the Owner and the Landscape Architect, a unit price breakdown for all materials. The Owner may, at his discretion,add to or delete from the materials utilizing the unit price breakdown submitted to and accepted by the Owner.1.9 SUBMITTALSA. Fertilizer: The Contractor shall submit to the Owner and Landscape Architect documentation that all the fertilizer used for the project is of the analysisspecified and placed at the rates specified in section 2.2 FERTILIZER.B. Planting soil: The Contractor shall submit a sample of the planting soil (approximately 1 cu. Ft.) for approval by the Landscape Architect prior to delivery tothe site.1.10 CLEAN-UP & MAINTENANCE OF TRAFFICA. Follow procedures in FDOT Index 600 for maintenance of traffic during construction.B. At the end of each work day, the Contractor shall remove debris and shall barricade the un-filled holes in a manner appropriate in the path of pedestriansand motorists.C. Upon completion of the work or any major portion of the work or as directed by the Landscape Architect, all debris and surplus material from his work shallbe removed from the job site.1.11 MAINTENANCE PRIOR TO ACCEPTANCEA. The Contractor is responsible to maintain the plantings until they are accepted under the provisions of 1.12 “ACCEPTANCE OF INSTALLATION”.1. Plants: Begin maintenance immediately following the final plant installation operation for each plant and continue until all plant installation is complete andaccepted. Maintenance shall include watering all plants, weeding, mulching, pest and disease control, tightening and repairing of guys, repair of braces,removal of dead growth, resetting of plants to proper grade or up-right position, restoration of plant saucer, litter pick-up in plant beds and other necessaryoperations to assure specified minimum grade of Florida No. 1.2. Turf Areas: Begin maintenance of turf immediately following the placement of sod and continue until sod installation is complete and accepted.Maintenance shall include but not be limited to, watering, leveling, mowing, weed and pest control, fungus and disease control and other necessary operationsas determined by the Landscape Architect and good nursery practice.3. Re-setting or straightening trees and palms:The Contractor shall re-set and/or straighten trees and palms as required at no additional cost to the Owner unless caused by sustained winds of 75 mph ormore. Then, the costs of the operations may be charged to the owner. Re-set trees within 48 hours.1.12 ACCEPTANCE OF INSTALLATIONA. Inspection: Inspection of the work, to determine completion of contract work, exclusive of the possible replacement of plants and turf, will be made by theLandscape Architect at the conclusion of the maintenance period. Written notice requesting such an inspection and submitted by the Contractor at least ten (10)days prior to the anticipated date.1.13 GUARANTEEA. Guarantee all plants for a period of one year (CCD). Guarantee shall commence from the date of written acceptance. Plant material which is on the siteand scheduled to be relocated is not covered by the guarantee except in the case of Contractor's negligence or work that has been done in an unworkman-likemanner. The Contractor is not responsible for loss due to acts of god, (i.e.) sustained winds of 75 mph or more, floods, frost, lightning, vandalism or theft.1.14 REPLACEMENT A. Replacement shall be made during the guarantee period as directed by the Landscape Architect within ten (10) days from time of notification. For allreplacement plant material, the guarantee period shall extend for an additional forty-five (45) days beyond the original guarantee period. The Contractor shallbe responsible to provide water to the replacement plants in sufficient quantity to aid in their establishment. At the end of the guarantee period, inspection willbe made by the Landscape Architect, upon written notice requesting such inspection and submitted by the Contractor at least five (5) days before the anticipateddate. Replacement plants must meet the requirements of Florida No. 1 at time of inspection. Remove from the site all plants that are dead or in a state ofunsatisfactory growth, as determined by the Landscape Architect. Replace these and any plants missing due to the Contractor's negligence as soon as conditionspermit.1. Materials and Operations: All replacement plants shall be of the same kind and size as indicated on the plant list. The Contractor shall supply and plant theplants as specified under planting operations.2. Cost of Replacements: A sum sufficient to cover the estimated cost of possible replacements, including material and labor will be retained by the Owner andpaid to the Contractor after all replacements have been satisfactorily made and approved by the Landscape Architect.PART 2 - MATERIALS2.1 PLANTING SOILA. Planting soil for trees, shrubs and ground covers shall be of the composition noted on the plans, measured by volume.B. Soil for Sodded Areas: shall be coarse lawn sand.2.2 FERTILIZERA. Fertilizer for trees, palms, shrubs, and groundcovers shall be as follows: LESCO Palm Special 13-3-13 or equal, Sulfur coated with iron and other minorelements and maximum of 2% chlorine, or brand with equal analysis. The fertilizer shall be uniform in composition, dry and free flowing and shall be deliveredto the site in the original unopened containers, bearing the manufacturer's guaranteed analysis. Fertilizer for sod and seeded areas shall be 8-6-8, 50%organically derived nitrogen, or equal.2.3 WATERA. The Contractor shall provide potable water on site, available from the start of planting. The Contractor is responsible to ascertain the location andaccessibility of the water source. The Contractor is responsible to provide the means of distribution (i.e. water truck, hoses, etc.) for distribution of water to theplanting areas.2.4 MULCHA. Mulch shall be shredded Melaleuca mulch (Florimulch) as manufactured by Forestry Resources, Inc., or equal.2.5 ROOT BARRIER MATERIALA. Root barrier material shall be 24" deep polypropolylene panels by DeepRoot or approved equal.B. Install per details in the plans.PART 3 - INSTALLATION PROCEDURES3.1 LAYOUTA. Verify location of all underground utilities and obstructions prior to excavation.3.2 HERBICIDE TREATMENTA. In all areas infected with weed and/or grass growth, a systemic herbicide, such as Roundup, shall be applied per manufacturer's rates. When it has beenestablished where work will be done, the systemic herbicide shall be applied in accordance with manufacturer's labeling to kill all noxious growth. Contractorshall schedule his work to allow more than one application to obtain at least 95% kill of undesirable growth. If necessary, Contractor shall conduct a test toestablish suitability of product and applicator to be used on this project, prior to execution of the full application.3.3 PLANT PIT EXCAVATION AND BACKFILLINGA. Trees: See the Planting and Bracing Details and notes.B. All planting holes shall be hand dug where machine dug holes may adversely affect utilities or improvements.C. Shrubs and Groundcover: Shrubs and groundcover shall be planted in a soil bed as described in the notes and details. Space shrubs and provide setbackfrom curb and pavements as shown in the plans.D. Watering of field-grown plants: Thoroughly puddle in water to remove any air pockets in the plant hole.3.4 WATERINGA. The Contractor is responsible to provide the water for all new plants and transplants and means of distribution (i.e. hand watering or water truck) during themaintenance period and extending into the period after acceptance until the full schedule as listed below is complete. Water for trees and other large fieldgrown plants shall be supplemented by hand or water truck, in addition to the irrigation system, (if one is provided). Contractor can adjust watering scheduleduring heavy rain season upon approval of the Landscape Architect.AMOUNT OF WATER PER APPLICATIONFor trees up to 5 inch caliper - 5 gallonsFrom 5 to 8 inch caliper - 25 gallons9 inch and up caliper - 50 gallonsFREQUENCY OF WATERDaily for the first week3 times per week for weeks 2 - 52 times per week for weeks 6 - 81 time per week for weeks 9 - 12B. Water in plants by thoroughly soaking of the entire root ball immediately after planting. For large trees and shrubs, add water while backfillinghole to eliminate any air pockets in the soil around the root ball.C. Water shrubs, sod and groundcover a minimum of once daily for a week or until an irrigation system is fully operational. If no irrigation systemis to be installed, the Contractor shall be responsible for watering the shrub, sod, and groundcover for the time specified above, after installation ofeach section of the planting installed.3.5 FERTILIZINGA. Add fertilizer on top of the surface of shrubs beds and tree and palms root balls two (2) months after installation. Fertilize sod within two (2)days after installing after planting of each segment of the job. Fertilizer shall be applied after soil has been well moistened. Fertilizer shall bewashed off of plant leaves and stems immediately after application. Apply at the following rates:1. Trees and Large Shrubs: One (1) pound per inch of trunk diameter, spread evenly over the root ball area.2. Shrubs: One half (1/2) handful per shrub, spread evenly over the root ball area.3. Groundcover: Twelve (12) pounds per 100 sq. ft. of bed area.4. Sod: Twelve (12) pounds per 1,000 sq. ft. Wash fertilizer off blades immediately after spreading.3.6 MULCHINGA. Spread mulch two (2) inches thick uniformly over the entire surface of shrubs and groundcover beds, depth measured after settling, unlessotherwise specified in the plans. Provide 36” diameter bed of mulch, measured from outer edge of the trunk, for all trees and palms planted in sodareas. Keep mulch away from contact with the trunk. Create a 6” high ring of mulch at the outer edge of tree and palm holes.3.7 GUYING AND BRACINGA. See the details bound herewith or made part of the plans.3.8 SODDINGA. Provide a blanket of lawn sand as described in the notes in these plans. Prior to planting, remove stones, sticks, etc. from the sub-soil surface.Excavate existing non-conforming soil as required so that the finish grade of sod is flush with adjacent pavement or top of curb as well as adjacentsod in the case of sod patching.B. Place sod on moistened soil, with edges tightly butted, in staggered rows at right angles to slopes. The sod shall be rolled with a 500 poundhand roller immediately after placing.C. Keep edge of sod bed a minimum of 18” away from groundcover beds and 24” away from edge of shrub beds and 36” from trees, measuredfrom the edge of plant or tree trunk.D. Sod shall be watered immediately after installation to uniformly wet the soil to at least two inches below the bottom of sod strips.E. Apply fertilizer to the sod as specified in Section 3.5.F. Excavate and remove excess soil so top of sod is flush w/top of curb or adjacent pavement, or adjacent existing sod.PLANT BED PREPARATION NOTES1. In all areas where new sod and shrub and groundcover masses are to be planted, kill all existing weeds by treating with Round-upprior to beginning soil preparation.2. In all shrub and groundcover beds, prepare soil as described for either condition, over the entire area to be planted:Condition A:If any compacted road base or asphalt or rocky soil is encountered, remove compacted material entirely to allow an 18” depth ofplanting soil. Backfill the entire area of the shrub and groundcover beds with 18” planting soil (as specified in Plans) to within 2inches of the adjacent pavement or top of curb. Remove all debris and rocks and pebbles larger than 1 inch in size and level thegrade before planting.Condition B:Where no compacted soil is encountered, thoroughly mix 6 inches of planting soil into the existing soil to a depth of 18 inches. Ifrequired, excavate and remove the existing soil to lower the grade, so that the prepared mix is finished to a minimum of 2 inchesbelow top of curb or adjacent walkway. Remove all debris and rocks and pebbles larger than 1 inch in size and level the grade beforeplanting.For all sod areas, spread a 2” deep layer of lawn sand prior to sodding. Remove all debris and rocks and pebbles larger than 1 inchin size and level the grade before sodding. Remove, if required, existing soil so that top of sod is flush with and adjacent top of curbor pavement.SPACING OF PLANTS (SEE PLANT SPACING DETAIL)1. Plants shall be planted sufficiently away from edges of pavements or curbs, to allow for growth toward the edges of the bed.PROTECTION OF PLANTS1. The Contractor shall be responsible to protect existing trees and shrubs in and adjacent to the area of work. Erect barriers asnecessary to keep equipment and materials, any toxic material, away from the canopy drip line of trees and shrubs. DO NOT PILESOIL OR DEBRIS AGAINST TREE TRUNKS OR DEPOSIT NOXIOUS BUILDING SUPPLIES OR CHEMICALS WITHIN THE DRIPLINE.DISTANCE VARIES FOR EACH SPECIES SPACINGWALL, CURB, EDGE OF PAVEMENT, OR EDGE OF BEDSHRUB SPACING DIAGRAM15'EDGE OF PAVEMENTROOT BARRIER INSTALLATION DETAILCURBPLAN VIEWLESS THAN 8 FT.When trees are to be installed CLOSERTHAN 8 FT. from edge of walks or curbs,install a root barrier. The root barrier shallextend a minimum of 15 ft. from the edgeof the trunk in either direction.24"Install root barrier so top of barrier isflush with top of grade.N.T.S.ROOT BARRIER(24" DEEP) See PLANT LISTVARIESN.T.S.EDGE OF PAVEMENTINSTALL WHEN 8'OR LESSCURB15'TREE TRUNK6"SHRUB INSTALLATION DETAILABOVE SURROUNDING GRADESET TOP OF ROOT BALL 1 1/2" - 2"VARIES
PLANTING SOIL.min.min8"2" MULCH FLUSH WITH ADJACENTPAVEMENT (KEEP AWAY FROMSHRUB STEMS)N.T.S.BELOW THE TOP HALF OF THE ROOTBALL. COMPLETELY REMOVE REMOVE ANY PORTION OF WIREBASKETS OR BURLAP ABOVE THE TOP HALF OF THE ROOTBALL. FOLD BACK BURLAP COVERINGS MULCH WITHIN 3" OF THETRUNKINSTALL 2" OF MULCH OVER3" DIAMETER CIRCLE AROUNDTHE TRUNK. DO NOT PLACESET ROOTBALL SOPROVIDE THREE 2'X4' PINE STAKES120 APART ATTACH W/NAILS TO BATTENS NO NAILS IN TREEALL SYNTHETIC ROOTBALL ROCKS 2" OR LARGER REMOVEDFINISHED GRADEHOLES TO ACCOMMODATE PLANTS SHALL BE A MINIMUMOF THREE TIMES THE SIZED OF THE PLANT ROOTBALL.ALL BACKFILL FOR TREES SHALL BE EXISTING SOIL WITH ALL(NOT TO EXCEED 12 MONTHS FROM THE COMPLETIONOF THE PROJECT).ALL SUPPORT MATERIALS ARE TO BE REMOVED FROM THE TREES ONCE THE TREES HAVE BECOME ESTABLISHEDNOTE - IRREGULAR OR MULTI-STEMED TREES SHALL HAVE A SIMILAR STAKING PATTERN AS SINGLE TRUNKED TREES. STAKES NEED NOT ALL BE 6" HIGH TEMPORARY RETENTION RING OF SOIL TO ASSIST IN IRRIGATION OF THE TREE. REMOVE RING 3 MONTHS FERTILIZER SHALL BE INSTALLED AS PER THE WRITTEN SPECIFICATIONS.LIGHTLY COMPACTED SUBGRADE3 TIMES ROOT BALL DIAMETERTOP SOIL5/8" DIAMETER NYLON STRAPS WRAPPED AROUND TRUNK & PULLED TAUT, TIED TOBOTTOM OF PLANTING PIT(2)2" DIA. 8' LONG WOOD DOWELS 120 APART DRIVEN THROUGH 6"
12"UNDER 3 1/2" CALIPERN.T.S.PLANTING & BRACING DETAILSOIL WITH ALL ROCKS 2" OR LARGER REMOVEDFINISHED GRADEHOLES TO ACCOMMODATE PLANTS SHALL BE A MINIMUM OF THREE TIMES THE SIZED OF ALL BACKFILL FOR TREES SHALL BE AS EXISTINGFERTILIZER SHALL BE INSTALLED AS PER THE WRITTEN SPECIFICATIONS.LIGHTLY COMPACTED SUBGRADE3 TIMES ROOT BALL DIAMETERTOP SOILTOP HALF OF THE ROOTBALL.COMPLETE REMOVE ALL SYNTHETICREMOVE ANY PORTION OF WIREBASKETS ABOVE THE TOP HALF OFTHE ROOTBALL. REMOVEBURLAP COVERINGS BELOW THEROOTBALL COVERING MATERIALSWOOD STAKES TOP OF STAKES5(2"X4"X16" WOOD BATTENS5 LAYERS OF BURLAPSTEEL BANDTRUNK FLARE OR TOP ROOTIS 2" ABOVE SURROUNDING GRADESET ROOTBALL SOTRUNK FLARE OR TOP ROOTIS 2" ABOVE SURROUNDING GRADE18"DETAIL A N.T.S.12" MIN
2"X4"TOP OF STAKE ATOR FLUSH WITHOR BELOW GRADEOVER 3 1/2" CALIPERN.T.S.PLANTING & BRACING DETAILBATTEN DETAIL BN.T.S.EDGE OF BELOW OR FLUSH WITH GRADEBECOME ESTABLISHED(NOT TO EXCEED 12 MONTHS FROM THE COMPLETION OF THE ALL SUPPORT MATERIALS ARE TO BE REMOVED FROM THE TREES ONCE THE TREES HAVE NOTE - IRREGULAR OR MULTI-STEMED TREESSHALL HAVE A SIMILAR STAKING PATTERN AS SINGLE TRUNKED TREES. STAKES NEED NOT MULCH WITHIN 3" OF THETRUNKINSTALL 2" OF MULCH OVER3" DIAMETER CIRCLE AROUNDTHE TRUNK. DO NOT PLACEDETAIL AALL BE ATTACHED TO EVERY STEM PROJECT).WOOD DOWELS.THE PLANT BALL.ATTACHED TO EVERY STEM. AFTER INSTALLATION. TREES & PALMS OVER 12" CALIPERNOTE- USE 4" X 4" STAKESCOVERING MATERIALS.6" HIGH TEMPORARY RETENTION RING OF SOIL TO ASSIST IN IRRIGATION OF THE TREE. REMOVE RING 3 MONTHS AFTER INSTALLATION. (UNLESS OTHERWISE SPECIFIED)3' FOR 36"-48" o.c. SPACED SHRUBS18" FOR 12"-18" o.c. SPACED SHRUBS24" FOR 24" o.c. SPACED SHRUBSPLANTING PITSIZE:NOTES:FINISH LEGEND:(MF) MILL FINISH-NATURAL ALUMINUMPERMALOCCLEANLINEALUMINUM EDGINGTOP OF EDGING TOBE MAXIMUM OF12" (12.7MM) ABOVESURFACE MATERIALBED MEDIA ORAGGREGATECOMPACT GRADESADJACENT TOEDGING TO AVOIDSETTLING12" (305MM)ALUMINUM STAKESTO LOCK INTOPREFORMED LOOPSON THE EDGINGINSTALL PER MANUFACTURER'S"INSTALLATION GUIDELINES"8'-0" (2.44 M) SECTIONS TO INCLUDE(3) 12" (305 MM) ALUMINUM STAKES.16'-0" (4.88 M) SECTIONS TOINCLUDE (5) 12" (305 MM)ALUMINUM STAKES.CORNERS - CUT BASE EDGING UPHALFWAY ANDFORM A CONTINUOUS CORNER.PERMALOC CLEANLINE ASMANUFACTURED BYPERMALOC CORPORATION,HOLLAND MI.(800) 356-9660,(616) 399-9600CONTRACTOR'S NOTE:FOR PRODUCT ANDPURCHASING INFORMATIONVISIT:WWW.PERMALOC.COM1.2.3.4.5.6.0.072" (1.82MM) THICK18" X512" (3.2MM X 140MM),w/ 0.135" (3.43MM) EXPOSED TOP LIPISOMETRIC VIEWNTSSTAKESPERMALOC CORPORATION, 13505 BARRY STREET HOLLAND, MI, 49424(800) 356-9660 PHONE: (616) 399-9600 fax: (616) 399-9770 WWW.PERMALOC.COMTMCPERMALOCLEANLINEALUMINUM LANDSCAPE EDGINGALUMINUM EDGING DETAILN.T.S.69 of 11874
30+0031+0032+0033+0034+0035+00144145146147148149150151152153154155156157158159160161162163164165166167168169170VEMOExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.01IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.011IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA70 of 11875
40+0041+0036+0037+0038+0039+00169170171172173174175176177178179180181182184185190191192193187188189186183Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESRSSRSSRSSRSSRSSRSSRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.02IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.021IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREANEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA71 of 11876
42+0046+0047+0043+001+00
10+00 45+0044+00195197196198189194199200201202203204205219218217220229230231232233234235236237238239240241243242244245246247248221222223224206207208209210211225226227215228216212213214Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.03IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.031IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA72 of 11877
48+0049+0050+0051+00248216250249251252253254255256257280281282279278276261262263264265269270271268267266273274275277272283SIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.04IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.041IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA73 of 11878
(locate in area of free rainfall)MINI-Clik II Rain Sensor RAINBIRD ____ Series ControllerElectric ControllerIRRIGATION MATERIALS LISTPVC sleeves shall be ScheduleIrrigation Control Wirepipe running through it)Flexible PVC or Polypipe (for swing joints)40 PVC (sized 2 sizes larger than the RAINBIRD 200-PESB 2" Electromechanical PVC laterals & mains shall be schedule40 PVC (sized as shown on plans)Solenoid Control ValveITEMKEY11as requiredas requiredQTY.Series w/MPR nozzles RAINBIRD Spray Heads 1800 @ 30 PSI12" pop-up on risers in shrub beds4" pop-up in grass areas15-H15-F15-est15-cst WM2" WATER METERMAINas required1as requiredEC15-sst 10-T10-H10-F15-T(1.85 gpm)(3.7 gpm)(.61 gpm)(1.21 gpm)(1.21 gpm)(.53 gpm)(.79 gpm)(1.58 gpm)(1.23 gpm)(See Civil Plans)as requiredas requiredas requiredDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA5.01IRRIGATION NOTES, SPECS, AND DETAILSIRRIGATION EXPANSION NOTESIt is anticipated that after completion of these tasks there will be a fullyfunctioning automatic irrigation system (equipped with an automaticrain-shut off device) that will provide irrigation to all landscape areaswith 90% overlap of spray.If there is an existing irrigation system:1. The Contractor shall locate existing connection to water source(pump and well, lake intake or water meter), controller, rain shutoff device, valves and mainline. The Contractor shall then verifythat all systems are in working order and perform a flow test todetermine the amount of water flow and pressure throughout thesystem.2. The Contractor shall verify that the existing controller has enoughavailable stations for the additional required zones. If thecontroller does not then the Contractor shall furnish and installanother controller capable of handling all of the zones. TheContractor may suggest installing another controller to tandem onthe existing controller. The Owner will decide if this is acceptable.3. If there is no existing rain shut off device then the Contractor shallfurnish and install a new one. The Contractor is responsible toensure that the electrical hook up is performed to all applicablecodes and ordinances.4. The Contractor shall furnish and install new zone valves as requiredand wire them back to the existing (or new) controller.5. It may be necessary to extend the existing mains. If necessary, theContractor shall be responsible of trenching and backfilling andrepair of roadway or other paved surfaces. After the installation ofthe additional main, the Contractor shall perform a pressure test asspecified in the General Notes.6. Based on the flow test the Contractor shall zone and pipe theheads located in the Irrigation Head Layout Plan. The Contractorshall ensure that the zones and laterals are sized sufficiently toensure that there is proper pressure to run the irrigation heads attheir optimum pressure.If there is not an existing irrigation system:1.The Contractor purchase and install a new 2” water meter andbackflow assembly. This assembly shall comply with all local codesand ordinances.2. The Contractor shall furnish all necessary controllers, rain shut offdevices, valves, mains, laterals and heads necessary to install theproposed system. The Contractor is responsible for all necessaryelectrical wiring to operate the controller and rain shut off device.3. The Contractor shall be responsible of trenching and backfillingand repair of roadway or other paved surfaces when installingmains.4. The Contractor shall furnish and install new zone valves as requiredand wire them back to the controller.5. The Contractor shall zone and pipe the heads located in theIrrigation Head Layout Plan. The Contractor shall ensure that thezones and laterals are sized sufficiently to ensure that there isproper pressure to run the irrigation heads at their optimumpressure.P.V.C. LATERAL1/2" SCH. 40 STREET "L"FLEXIBLE P.V.C. OR TORO FUNNY PIPE (MIN. 18" LONG)6" ABOVE TOP OF PLANT AT TIME OF PLANTING#5 REBAR STAKED WITH BLACK PLASTIC TIESTOP AND BOTTOM(PAINT REBARS BLACK)FINISH GRADETOP OF SHRUBSOR GROUNDCOVERABOVE HIGHEST
SPRINKLER HEAD
TO IRRIGATION SYSTEM18" min.12"
18" MIN.2" BELOW TOP OFPLANT IF 12" POP-UPS ARE USEDGENERAL NOTES:1. SCOPE OF WORK: The Contractor shall furnish all labor, machinery, tools, supplies, andequipment as necessary to construct and provide an operating system, as indicated in thePlans. The work shall include, but not be limited to, furnishing materials (pipe, valves,sprinkler heads, fittings, controllers, electrical, wire and fittings, primer, glue, etc.), layout,protection to the public, excavation, assembly, installation, backfilling, compaction, repair ofroad or pavement surfaces, controller and low voltage feed to the valves, clean-up,maintenance and guarantee, and as-built plans.2. Contractor shall coordinate with General Contractor or other pertinent Contractors on thejob to insure that sleeves are provided and installed under hard surfaces to allow access toall areas to be irrigated. All sleeves shall be constructed of Schedule 40 PVC. Bury allsleeves a minimum of 24" below the surface. Sleeve to be 2 times the size if the pipe runningthrough it. Sleeve shall extend 24" past the edge of pavement into the area to be irrigated.3. GUARANTEE: The irrigation system shall be guaranteed for a minimum of one calendaryear from the time of final acceptance.4. REPAIR UTILITIES: The Contractor shall be responsible to verify the location of all utilitiesby hand excavation or other appropriate measures before performing any work that mayresult in damage to utilities structures, or property. The Contractor shall take immediatesteps to repair, replace, or restore all services to any utilities which are disrupted due to hisoperations. All costs involved in disruption of service and repairs due to negligence on partof the Contractor shall be his responsibility.5. AS-BUILT DRAWINGS: Prints of the plans will be supplied to the Contractor for recording"as-built" information. Immediately upon installation of any work which deviates from what isshown on the Plans, the Contractor shall clearly indicate such changes in red pencil on theprints. Such changes shall include, but not be limited to, changes in (1) materials; (2) sizesof material; (3) location; and (4) quantities.6. The entire installation shall fully comply with all applicable local and state codes andordinances. The Contractor shall take out all required plumbing and electrical applicationsand permits, arrange for all necessary inspections and shall pay all fees and expenses inconnection with same as part of work under the contract.7. UNIT PRICES: The successful bidder shall furnish, to the Owner, a unit price breakdownfor all materials. The Owner may at his own discretion, add to or delete from the materials,using the unit price breakdown submitted to and accepted by the Owner.8. MAINTENANCE PERIOD: The irrigation system shall be maintained for a period of 90days after final acceptance of installation. Maintenance shall include checking of the system2 times per week. Contractor shall be responsible to replace/repair any broken ormalfunctioning parts of the system including those damaged by accidents or vandalism.Repairs shall be made immediately at the time of inspection or when notified by theLandscape Architect.9. The irrigation system shall provide 100% coverage with a minimum of 90% overlap ofwater spray.10. The system is design to provide sprinkler precipitation rates that are nearly equal in eachzone. Mixing of sprinklers with widely varying precipitation rates in a zone will not beaccepted.11. All pipe shall be made of Schedule 40 PVC, except flexible PVC (or Toro funny pipe) forflexible swing joint and Schedule 80 galvanized steel pipe for all above ground fittings. Pipelocations shall be adjusted in the field. When laying out mains and laterals, locate pipe nearedges of pavement or against buildings wherever possible, to allow space for plant rootballs.Coordinate pipe locations with plantings. Bury all mains 18" below surface and laterals 12".Depth shall be measured to top of pipe.12. Keep pop-up sprinkler heads a minimum of 8" from edges of pavement and curbing, andheads on risers a minimum of 18", or as indicated in the pans.13. All heads located in shrub or groundcover beds shall be installed on a riser as perdetails in the plans. All other heads shall be installed on a swing joint as per details in theplans.14. Place irrigation control wire in conduit in the same trench as mains and under the main.ASI wire shall be #14 or larger solid copper U.L. approved underground direct burial cableand shall be continuous with no splices from controller to solenoid valve.15. Valve locations are schematic and shall be adjusted in the field. Each valve shall be in aseparate valve box (10" x 16") min.). When grouping valve boxes in grass or groundcoverareas, set boxes a minimum of 12" apart to allow grass or groundcover to grow betweenthem. When possible, hide valve boxes in shrub beds, a minimum of 12" from edge of beds.Set all valve boxes, concrete or plastic, in ground with cover flush with finish grade, and level,with a minimum of 6" of pea gravel at the bottom of the box, with at least 2" of clearancefrom the bottom of the valve to the top of the gravel.16. TESTING: Notify the Landscape Architect in writing when testing will be conducted.Conduct test in the presence of the Landscape Architect. After all PVC assembly is completedthe lines shall be flushed to insure that no rocks, sand, or other foreign debris remains in thelines. The mains shall be filled with water and all outlets shall be capped and plugged. Themain shall be pressurized to 100 PSI for a minimum of one hour. No section of the main willbe approved if the pressure drops more than 5 PSI at the end of the one hour period. Leaksshall be repaired immediately and the system shall be re-tested until found satisfactory by theLandscape Architect.MINI-CLIK II RAIN SENSOR(install where rainfall is unrestricted)(as specified)(same size as meter)ELEC. SOLENOID VALVEBACKFLOW PREVENTIONGATE VALVEWATER METER(in plastic valve box)PVC MAINELECTRIC CONTROLLERUL APPROVED CONTROL WIREFINISH GRADEP.V.C. LATERALAMETEK VALVE BOX OR EQUALSOLENIOD VALVE6" PEA GRAVELGATE VALVE12"
12"CONNECTION TO METER DETAILN.T.S.IRRIGATION SYSTEM ONLYN.T.S.TYPICAL SOLENOID VALVE ASSEMBLYN.T.S.FLEXIBLE SWING JOINT DETAILN.T.S.SPRINKLER ON RISER DETAIL FOR SHRUB AREASN.T.S.WEATHERPROOF, NON-METALLICTERMINUS. UL APPROVEDRAIN SENSOR MOUNTED TO PIPERAIN SENSOR DETAIL#6 SOLID COPPER CONDUCTOR(BARE OR WITH GREEN COLOREDINSULATION.)UL APPROVED GROUND CLAMPATTACH PRIOR TO PAINTING14" WIDE MIN. NYLON "LOCK TIGHT"BANDS 24" 0.C.1-1-14" SCH 40 GALV STEEL PIPE POST10' LONG X 34" DIA COPPER CLADGROUND RODN.T.S.FINISH GRADEPVC CONDUIT CAST INTOFOOTING2" MIN. ABOVE FINISH GRADEUL APPROVED NON METALLICWEATHERPROOF PULL-BOXUL APPROVED NON METALLIC UVRESISTANT, RIGID CONDUIT SIZE ASNEEDED.SMOOTH FINISHED CONCFOOTING SLOPED TO DRAIN6"12" MIN. DIA.3' MIN.4"MIN.TO CONTROLLER18" MIN.5'-0"18"THREADED GALV STEEL PIPE ENDNOTE:ALL WIRE CONNECTIONS SHALL BE APPROVED WATERTIGHT CONNECTIONS.FINISH ENTIRE ASSEMBLY, EXCEPT FOR EQUIPMENT, WITH FLAT BLACK ACRYLIC ENAMEL PAINT.PRIME METALLIC SURFACES WITH ZINC CHROMATE PRIOR TO FINISHING.CAP18"MAIN (see plan for size)CAP WIRE ENDS (wiring for zones)PVC CONDUITPVC 1" RISERSLIP FITTINGDETAIL OF STUB-OUT FOR FUTURE USEN.T.S.PLASTIC VALVE BOX(size as required)PLAN VIEWN.T.S.ELEVATION VIEWN.T.S.METER VAULT2"6"CONC. SLABWITH #4 @12" EW60" MAX.TEST COCKBALL VALVECONC. SLABBALL VALVEMETER VAULT8"8"8"8"PLPLNOTES:-MATERIALS: PIPES AND FITTINGS SHALL BE APPROVED BY ASAE STANDARDS APPENDIX F .-THE ASSEMBLY SHALL BE INSTALLED WITH MINIMIUM HORIZONTAL CLEARANCES OF 30 INCHES FREE FROMOBSTRUCTIONS IN ALL DIRECTIONS.-GUARD POSTS SHALL BE INSTALLED IF THE ASSEMBLY IS EXPOSED TO POSSIBLE DAMAGE FROM VEHICULARTRAFFIC, AS DETERMINED BY THE DEPARTMENT.-THE ASSEMBLY SHALL BE INSTALLED IN AN ACCESSIBLE LOCATION, APPROVED BY THE DEPARTMENT.-PIPING SHALL BE SCHEDULE 40 BRASS OR TYPE K COPPER PIPE WITH THREADED FITTINGS IN ACCORDANCEWITH WASD CONSTRUCTION SPECIFICATIONS FOR DONATION WATER MAINS. PVC PIPING IS NOTACCEPTED BY WASD.-THE DEPARTMENT SHALL HAVE UNRESTRICTED AND CONTINUOUS ACCESS TO THE VACUUM BREAKERASSEMBLY.-SEE SPECIFICATIONS AND CONTACT DEPARTMENT FOR CURRENTLY APPROVED TYPES OF BACKFLOWPREVENTION ASSEMBLIES AND PRESSURE VACUUM BREAKERS (SEE WS 4.18 SHEET 4 OF 4 OR ON THIS SHEET)BACKFLOW PREVENTION ASSEMBLY DETAILBACKFLOW PREVENTION ASSEMBLY PER LOCAL CODES AND ORDINANCESBACKFLOW PREVENTION ASSEMBLY PER LOCAL CODES AND ORDINANCES74 of 11879
75 of 11880
EXHIBIT 2
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
Insurance & Indemnification Requirements
Insurance
A. Without limiting its liability, the contractor, consultant or consulting firm (hereinafter referred to as
“FIRM” with regard to Insurance and Indemnification requirements) must procure and maintain at its
own expense during the life of the Contract, insurance of the types and in the minimum amounts stated
below as will protect the FIRM, from claims which may arise out of or result from the contract or the
performance of the contract with the City of South Miami, whether such claim is against the FIRM or an y
sub-contractor, or by anyone directly or indirectly employed by any of them or by anyone for whose acts
any of them may be liable.
B. No insurance required by the CITY may be issued or written by a surplus lines carrier unless authorized
in writing by the CITY and such authorization is at the CITY’s sole and absolute discretion. The FIRM
must purchase insurance from and must maintain the insurance with a company or companies lawfully
authorized to sell insurance in the State of Florida, on forms approved by the State of Florida, as will
protect the FIRM, at a minimum, from all claims as set forth below which may arise out of or result from
the FIRM's operations under the Contract and for which the FIRM may be legally liable, whether such
operations be by the FIRM or by a Subcontractor or by anyone directly or indirectly employed by any of
them, or by anyone for whose acts any of them may be liable: (a) claims under workers' compensation,
disability benefit and other similar employee benefit acts which are applicable to the Work to be
performed; (b) claims for damages because of bodily injury, occupational sickness or disease, or death of
the FIRM's employees; (c) claims for damages because of bodily injury, sickness or disease, or death of
any person other than the FIRM's employees; (d) claims for damages insured by usual personal injury
liability coverage; (e) claims for damages, other than to the Work itself, because of injury to or
destruction of tangible property, including loss of use resulting ther e from; (f) claims for damages because
of bodily injury, death of a person or property damage arising out of ownership, maintenance or use of a
motor vehicle; (g) claims for bodily injury or property damage arising out of completed operations; and
(h) claims involving contractual liability insurance applicable to the FIRM's obligations under the Contract.
Firm’s Insurance Generally. The FIRM must provide and maintain in force and effect until all the Work to be
performed under this Contract has been completed and accepted by CITY (or for such duration as is otherwise
specified hereinafter), the insurance coverage written on Florida approved forms and as set forth below:
Workers’ Compensation Insurance at the statutory amount as to all employees in compliance with the
"Workers' Compensation Law" of the State of Florida including Chapter 440, Florida Statutes, as presently written
or hereafter amended, and all applicable federal laws. In addition, the policy (ies) must include: Employers' Liability
at the statutory coverage amount. The FIRM must further ensure that all of its Subcontractors maintain
appropriate levels of Worker's Compensation Insurance.
Commercial Comprehensive General Liability insurance with broad form endorsement, as well as
automobile liability, completed operations and products liability, contractual liability, severability of interest with
cross liability provision, and personal injury and property damage liability with limits of $1,000,000 combined single
limit per occurrence and $2,000,000 aggregate, including:
• Personal Injury: $1,000,000;
• Medical Insurance: $5,000 per person;
• Property Damage: $500,000 each occurrence;
Umbrella Commercial Comprehensive General Liability insurance must be written on a Florida approved
form with the same coverage as the primary insurance policy but in the amount of $1,000,000 per claim and
$2,000,000 Annual Aggregate. Coverage must be afforded on a form no more restrictive than the latest edition of
the Comprehensive General Liability policy, without restrictive endorsements, as filed by the Insurance Services
Office, and must include:
(a) Premises and Operation
(b) Independent Contractors 76 of 118 81
(c) Products and/or Completed Operations Hazard
(d) Explosion, Collapse and Underground Hazard Coverage
(e) Broad Form Property Damage
(f) Broad Form Contractual Coverage applicable to this specific Contract, including any hold harmless
and/or indemnification agreement.
(g) Personal Injury Coverage with Employee and Contractual Exclusions removed, w ith minimum limits of
coverage equal to those required for Bodily Injury Liability and Property Damage Liability.
Business Automobile Liability with minimum limits of One Million Dollars ($1,000,000.00) plus an additional
One Million Dollar ($1,000,000.00) umbrella per occurrence combined single limit for Bodily Injury Liability and
Property Damage Liability. Umbrella coverage must be afforded on a form no more restrictive than the latest
edition of the Business Automobile Liability policy, without restrict ive endorsements, as filed by with the state of
Florida, and must include:
(a) Owned Vehicles.
(b) Hired and Non-Owned Vehicles
(c) Employers' Non-Ownership
Subcontracts: The FIRM agrees that if any part of the Work under the Contract is sublet, the subcon tract must
contain the same insurance provision as set forth in these insurance and indemnification requirements, other than
the Fire and Extended Coverage Insurance and substituting the word Subcontractor for the word FIRM where
applicable.
Fire and Extended Coverage Insurance (Builders’ Risk), IF APPLICABLE:
A. In the event that this contract involves the construction of a structure, FIRM must maintain, with an
Insurance Company or Insurance Companies acceptable to the CITY, "Broad" form/All Risk Insurance on
buildings and structures, including Vandalism & Malicious Mischief coverage, while in the course of
construction, including foundations, additions, attachments and all permanent fixtures belonging to and
constituting a part of said buildings or structures. The policy or policies must also cover machinery, if the
cost of machinery is included in the Contract, or if the machinery is located in a building that is being
renovated by reason of this contract. The amount of insurance must, at all times, be at least equal to the
replacement and actual cash value of the insured property. The policy must be in the name of the CITY
and the CONTRACTOR, as their interest may appear, and must also cover the interests of all
Subcontractors performing Work.
B. All of the provisions set forth in the Miscellaneous section below apply to this coverage unless it would be
clearly not applicable.
Miscellaneous:
A. If any notice of cancellation of insurance or change in coverage is issued by the insurance company or
should any insurance have an expiration date that will occur during the period of this contract, the FIRM
Is responsible for securing other acceptable insurance prior to such cancellation, change, or expiration
so as to provide continuous coverage as specified in this section and so as to maintain coverage during
the life of this Contract.
B. All deductibles must be declared by the FIRM and must be approved by the CITY. At the option of the
CITY, either the FIRM must eliminate or reduce such deductible or the FIRM must procure a Bond, in a
form satisfactory to the CITY covering the same.
C. The policies must contain waiver of subrogation against CITY where applicable, must expressly provide
that such policy or policies are primary over any other collectible insurance that CITY may have. The
CITY reserves the right at any time to request a copy of the required policies for review. All policies
must contain a “severability of interest” or “cross liability” clause without obligation for premium
payment of the CITY as well as contractual liability provision covering FIRM’s duty to indemnify the City
as provided in this Agreement.
D. Before starting the Work, the FIRM must deliver to the CITY and CONSULTANT certificates of such
insurance, acceptable to the CITY, as well as the insurance binder, if one is issued, the insurance policy,
including the declaration page and all applicable endorsements and provide the name, address and
telephone number of the insurance agent or broker through whom the policy was obtained. The insurer
must be rated A.VII or better per A.M. Best’s Key Rating Guide, latest edition and authorized to issue
insurance in the State of Florida. All insurance policies must be written on forms approved by the State
of Florida and they must remain in full force and effect for the duration of the contract period with the
CITY. The FIRM may be required by the CITY, at its sole discretion, to provide a “certified copy” of the
Policy (as defined in Article 1 of this document) which must include the declaration page and all required
endorsements. In addition, the FIRM must deliver, at the time of delivery of the insurance certificate, the
following endorsements:
(1) a policy provision or an endorsement with substantially similar provisions as follows:
77 of 118 82
“The City of South Miami is an additional insured. The insurer must pay all sums that the City of
South Miami becomes legally obligated to pay as damages because of ‘bodily injury”, ‘property
damage’, or ”personal and advertising injury” and it will provide to the City all of the coverage
that is typically provided under the standard Florida approved forms for commercial general
liability coverage A and coverage B”;
(2) a policy provision or an endorsement with substantially similar provisions as follows:
“This policy must not be cancelled (including cancellation for non-payment of premium),
terminated or materially modified without first giving the City of South Miami ten (10) days
advanced written notice of the intent to materially modify the policy or to cancel or terminate
the policy for any reason. The notification must be delivered to the City by certified mail, with
proof of delivery to the City.”
E. If the FIRM is providing professional services, such as would be provided by an architect, engineer,
attorney, or accountant, to name a few, then in such event and in addition to the above requirements,
the FIRM must also provide Professional Liability Insurance on a Florida approved form in the amount of
$1,000,000 with deductible per claim if any, not to exceed 5% of the limit of liability providing for all
sums which the FIRM becomes legally obligated to pay as damages for claims arising out of the services
or work performed by the FIRM its agents, representatives, Sub Contractors or assigns, or by any
person employed or retained by him in connection with this Agreement. This insurance must be
maintained for four years after completion of the construction and acceptance of any Project covered by
this Agreement. However, the FIRM may purchase Specific Project Professional Liability Insurance, in the
amount and under the terms specified above, which is also acceptable. No insurance may be issued by a
surplus lines carrier unless authorized in writing by the city at the city’s sole, absolute and unfettered
discretion.
Indemnification Requirement
A. FIRM accepts and voluntarily incurs all risks of any injuries, damages, or harm which might arise
during the work or event that is occurring on the CITY's property due to the negligence or other fault of FIRM or
anyone acting through or on behalf of FIRM.
B. FIRM must indemnify, defend, save and hold CITY, its officers, affiliates, employees, successors and
assigns, harmless from any and all damages, claims, liability, losses, claims, demands, suits, fines, judgments or cost
and expenses, including reasonable attorney’s fees, paralegal fees and investigative costs incidental there to and
incurred prior to, during or following any litigation, mediation, arbitration and at all appellate levels, which may be
suffered by, or accrued against, charged to or recoverable from the City of South Miami, its officers, affiliates,
employees, successors and assigns, by reason of any causes of actions or claim of any kind or nature, including
claims for injury to, or death of any person or persons and for the loss or damage to any property arising out of a
negligent error, omission, misconduct, or any gross negligence, intentional act or harmful conduct of FIRM, its
contractor/subcontractor or any of their officers, directors, agents, representatives, employees, or assigns, or
anyone acting through or on behalf of any of them, arising out of this Agreement, incident to it, or resulting fr om
the performance or non-performance of FIRM's obligations under this AGREEMENT.
C. FIRM must pay all claims, losses and expenses of any kind or nature whatsoever, in connection
therewith, including the expense or loss of the CITY and/or its affected officers, affiliates, employees, successors
and assigns, including their attorney’s fees, in the defense of any action in law or equity brought against them and
arising from the negligent error, omission, or act of FIRM, its Sub-Contractor or any of their agents,
representatives, employees, or assigns, and/or arising out of, or incident to, this Agreement, or incident to or
resulting from the performance or non-performance of FIRM's obligations under this AGREEMENT.
D. FIRM agrees and recognizes that neither the CITY nor its officers, affiliates, employees, successors
and assigns are to be held liable or responsible for any claims, including the costs and expenses of defending such
claims which may result from or arise out of actions or omissions of FIRM, its contractor/subcontractor or any of
their agents, representatives, employees, or assigns, or anyone acting through or on behalf of the them, and arising
out of or concerning the work or event that is occurring on the CITY's property. In reviewing, approving or
rejecting any submissions or acts of FIRM, CITY in no way assumes or shares responsibility or liability for the acts
or omissions of FIRM, its contractor/subcontractor or any of their agents, representatives, employees, or assigns,
or anyone acting through or on behalf of them.
E. FIRM has the duty to provide a defense with an attorney or law firm approved by the City of South
Miami, which approval will not be unreasonably withheld.
F. However, as to design professional contracts, and pursuant to Section 725.08 (1), Florida Statutes,
none of the provisions set forth herein above that are in conflict with this subparagraph must apply and this
subparagraph must set forth the sole responsibility of the design professional conce rning indemnification. Thus,
the design professional’s obligations as to the City and its agencies, as well as to its officers and employees, is to 78 of 118 83
indemnify and hold them harmless from liabilities, damages, losses, and costs, including, but not limited t o,
reasonable attorneys’ fees, to the extent caused by the negligence, recklessness, or intentionally wrongful
conduct of the design professional and other persons employed or utilized by the design professional in the
performance of the contract.
END OF SECTION
79 of 118 84
EXHIBIT 3
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
RESPONDENTS
BID FORM
THIS PROPOSAL IS SUBMITTED TO:
Shari Kamali
City Manager
City of South Miami
6130 Sunset Drive
South Miami, FL 33143
1. If this Proposal is accepted, the undersigned Respondent agrees to enter into a Contract with the City of
South Miami in the form included in this Solicitation Package and to perform and furnish all work as specified
or indicated in this Solicitation, including as set forth in Exhibit 1 (Scope of Services, Attachment A, B &
C) for the Proposed Price as set forth below, within the Contract Time and in accordance with the other
terms and conditions of the Solicitation Package.
2. Respondent accepts all of the terms and conditions of the Solicitation and Instructions to Respondents,
including without limitation those dealing with the disposition of Proposal/Bid Bond, if required. This
Proposal will remain subject to acceptance for 180 calendar days after the day of the Proposal Opening.
The Respondent, by signing and submitting this proposal, agrees to all of the terms and conditions of the
form of contract that is a part of the Solicitation package with appropriate changes to conform to the
information contained in this Bid Form. Respondent agrees to sign and submit the Bonds, if required by
this Solicitation, required insurance documents, and other documents required by the Solicitation,
including the Contract if not already submitted, within ten (10) calendar days after the date of the City ’s
Notice of Award.
3. In submitting this Proposal, Respondent represents that:
a. Respondent has examined copies of all the Solicitation Documents and of the following Addenda, if any
(receipt of all which is hereby acknowledged.)
Addendum No. Dated:
b. Respondent has familiarized himself with the nature and extent of the Contract Documents, the proposed
work, site, locality, and all local conditions and laws and regulations that in any manner may affect cost,
progress, performance or furnishing of the Work.
c. Subsurface conditions: If applicable to this Solicitation, the Respondent represents that:
i. Respondent has studied carefully all reports and drawings, if applicable, of subsurface conditions and
drawings of physical conditions.
ii. Respondent has obtained and carefully studied (or assumes responsibility for obtaining and carefully
studying) all such examinations, investigations, explorations, tests and studies in addition to or to
supplement those referred to in this paragraph which pertain to the subsurface or physical conditions
at the site or otherwise may affect the cost, progress, performance, or the furnishing of the Work at
the Contract Price, within the Contract Time and in accordance with the other terms and conditions
of the Contract Documents. The Respondent hereby acknowledges that no additional examinations,
investigations, explorations, tests, reports or similar information or data are, or will, be required by
Respondent for any reason in connection with the Proposal. The failure of the Respondent to request
a pre-bid marking of the construction site by any or all utility companies will create an irrefutable
presumption that the Respondent’s bid, or proposal price, has taken into consideration all possible
underground conditions and Respondent, if awarded the contract, will not be entitled to a change order
for any such condition discovered thereafter.
iii. Respondent has correlated the results of all such observations, examinations, investigations,
explorations, tests, reports and studies with the terms and conditions of the Contract Documents.
iv. Respondent has reviewed and checked all information and data shown or indicated in the Solicitation
Package or in the Contract Documents with respect to existing Underground Facilities or conditions
at or contiguous to the site and assumes responsibility for the accurate location of all Underground 80 of 118 85
Facilities and conditions that may affect the Work. No additional examinations, investigations,
explorations, tests, reports or similar information or data in respect to any Underground Facilities or
conditions are, or will be, required by Respondent in order to perform and furnish the Work at the
Contract Price, within the Contract Time and in accordance with the other terms and conditions of
the Contract Documents unless the Proposal specifically states that the contract price is subject to
adjustment for future discovery of underground facilities and/or conditions that affect the cost of the
Work and unless the respondent makes a written request to the City for additional information prior
to submitting the bid or proposal as required in subsection ii above,
d. Respondent has given the City written notice of all conflicts, errors or discrepancies that it has discovered
in the Contract Documents and, if any conflicts, errors or discrepancies have been found and notice
given, the Respondent represents, by submitting its proposal to the City, that the Respondent has
received sufficient notice of the resolution thereof from the City, that such resolution is acceptable to
Respondent and that the Respondent waives any claim regarding the conflicts, errors or discrepancies.
e. This Proposal is genuine and not made in the interest of or on behalf of any undisclosed person, firm or
corporation and is not submitted pursuant to any agreement or rules of any group, association,
organization, or corporation; Respondent has not directly or indirectly induced or solicited any other
Respondent to submit a false or sham Proposal; Respondent has not solicited or induced any person, firm
or corporation to refrain from responding; and Respondent has not sought by collusion or otherwise to
obtain for itself any advantage over any other Respondent or over the CITY.
4. Respondent understands and agrees that the Contract Price is the amount that it needs to furnish and install
all the Work complete and in place. The Schedule of Values, if required, is provided for the purpose of
Proposal Evaluation and when initiated by the CITY, it will form the basis for calculating the pricing of change
orders. The Contract Price may not be adjusted in any way to result in a deviation from the Schedule of
Values, except to the extent that the CITY changes the Scope of the Work after the Contract Date. As
such, the Respondent must furnish all labor, materials, equipment, tools, superintendence, and services
necessary to provide a complete, in place, Project for the Proposal Price. If this Solicitation requires the
completion of a Respondent Cost and Technical Proposal, Exhibit 4, as may be set forth in an exhibit
to this Solicitation, such proposal must be attached to this Bid Form and will take the place of the Lump
Sum Price, otherwise, the Contract Price for the completed work is as follows:
TO SUBMIT A LUMP SUM COST PROPOSAL, REFER TO EXHIBIT 4 “RESPONDENTS
COST & TECHNICAL PROPOSAL”
A fee breakdown for each task included in the lump sum contract price, if applicable, must be provided.
Failure to provide this information will render the proposal non-responsive.
5. The ENTIRE WORK for project in accordance with Exhibit 1, Scope of Services, Attachment A, B &
C must be completed, in full, within120 calendar days from the commencement date set forth in the
NOTICE TO PROCEED. Failure to complete the entire work during the described time will result in the
assessment of liquidated damages as may be set forth in the Contract.
6. Insert the following information for future communication with you concerning this Proposal:
RESPONDENT:
Address:
Telephone:
Facsimile:
Contact Person
7. The terms used in this Proposal which are defined in the Contract have the same meaning as is assigned to
them in the Contract Documents, unless specifically defined in this Solicitation Package.
8. If a Respondent’s Cost & Technical Proposal is required by the Solicitation, Respondent hereby certifies
that all of the facts and responses to the questions posed in the Cost & Technical Proposal, if such an exhibit
81 of 118 86
is made a part of the Solicitation, are true and correct and are hereby adopted as part of this Respondents
Bid Form, and are made a part of this proposal, by reference.
9. By submitting this proposal, I, on behalf of the business that I represent, hereby agree to the terms of the
form of contract contained in the Solicitation package and I agree to be bound by those terms, with any
appropriate blank boxes, if any, checked and any blank lines filled in with the appropriate information
contained in the Solicitation Documents and this Proposal, or such information that the City and I have
agreed upon in the course of contract negotiations and which have been confirmed by the City in writing,
including e-mail confirmation, if any. I hereby certify under penalties of perjury that I am the lawful
representative of the business entity referenced in this Bid Form, that I have authority to bid for that entity,
that I have authority to sign contracts for that entity and bind it to those contract terms and that all of th e
information and representations contained herein are true and correct.
SUBMITTED THIS
DAY OF 20____.
PROPOSAL SUBMITTED BY:
Company Telephone Number
Name of Person Authorized to Submit Proposal Fax Number
Signature Email Address
Title
END OF SECTION
82 of 118 87
EXHIBIT 4
RESPONDENTS COST & TECHNICAL PROPOSAL
BID FORM
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
IN ACCORDANCE WITH EXHIBIT 1, “SCOPE OF SERVICES, ATTACHMENTS
A, B & C, RESPONDENTS MAY SUBMIT LUMP SUM PRICING FOR A SINGLE
OPTION OR MULTIPLE OPTIONS.
LUMP SUM:
OPTION A: US 1 TO
SW 62 AVENUE
LUMP SUM:
OPTION B: SW 62
AVENUE TO SW 69TH
AVENUE
LUMP SUM:
OPTION C:
(OPTIONS A & B
COMBINED)
$ ___________________ $________________________ $ ___________________
NOTE: The City reserves the right to award the project to a single
Respondent for each Option; Option A, Option B, or Option C (i.e. one
Respondents may be awarded Option A and another Respondent may be
awarded Option B). Respondents may submit Lum Sum pricing for a single
Option or multiple Options.
SUBMITTED THIS
DAY OF 20____.
PROPOSAL SUBMITTED BY:
Company Telephone Number
Name of Person Authorized to Submit Proposal Fax Number
Signature Email Address
Title
END OF SECTION
83 of 118 88
EXHIBIT 5
CONSTRUCTION CONTRACT
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
THIS CONTRACT was made and entered into on this _________ day of _________________, 20____,
by and between _________________________________________________ (hereafter referred to as
“Contractor”), and the City of South Miami (hereafter referred to as “Owner”), through its City Manager (hereafter
referred to as “City”).
.
Contractor, for the consideration set herein, hereby agrees with Owner as follows:
1. Contractor must furnish all labor, materials, equipment, machinery, tools, apparatus, transportation and any
other items necessary to perform all of the work shown on and described in the Contract Documents and
must do everything required by this Contract and the other Contract Documents hereinafter referred to
as the Work.
2. The Contract Documents must include this Contract, General Conditions to the Contract, if any, the
drawings, plans, specifications and project manual, if any, any supplementary or special conditions, other
documents referring to this contract and signed by the parties , the solicitation documents (“hereinafter
referred to as “Bid Documents”) and any documents to which those documents refer which are used by
Owner as well as any attachments or exhibits that are made a part of any of the documents described
herein.
3. Contractor must commence the Work to be performed under this Contract on a date to be specified in a
Notice to Proceed and must complete all Work hereunder within the length of time set forth in the
Contract Documents.
4. Owner hereby agrees to pay to Contractor for the faithful performance of this Contract, subject to additions
and deductions as provided in the Contract Documents and any properly approved, written change orders,
in lawful money of the United States, the Lump Sum amount of:
______________________________________________________________Dollars ($_________________. __)
(Spell Dollar Amount above) (“Contract Price”).
5. The expenses of performing Work after regular working hours, and on Sunday and legal holidays must be
included in the Contract Price. The City may demand, at any point in time, that any part, or all, of the Work
be performed after regular working hours. In such event, the Respondent will have no right to additional
compensation for such work. However, nothing contained herein authorizes work on days and during hours
that are otherwise prohibited by ordinance unless specifically authorized or instructed in writing by the City.
6. If the Work is expected to require more than one month, Owner will make monthly partial payments to
Contractor on the basis of a duly certified and approved schedule of values for the Work performed
during each calendar month by Contractor, less the retainage (all as provided for in the Contract
Documents), which is to be withheld by Owner until completion and acceptance of the complete project in
accordance with this Contract and the other Contract Documents and until such Work has been accepted
by the City.
7. Upon submission by Contractor of evidence satisfactory to Owner that all labor, material, and other costs
incurred by Contractor in connection with the construction of the Work have been paid in full, and after
compliance with the terms for payment provided for in the Contract Documents, final payment on account
of this Contract must be made within sixty (60) calendar days after the completion by Contractor of all
Work covered by this Contract and the acceptance of such Work by Owner.
8. The Work must be completed in: Option A: 60 calendar days; Option B: 60 calendar days; Option
C: 120 calendar days. In the event that Contractor fails to complete the Work within the time limit
stipulated in the Contract Documents, or the extended time limit agreed upon, in accordance with the
procedure as more particularly set forth in the Contract Documents, liquidated damages must be paid by
Contractor at the rate of Option A; $1,250 dollars per day; Option B: $1,250 per day; Option C:
$2,500.00 dollars per day,
9. It is further mutually agreed between the parties hereto that if a Payment and/or Performance Bond (“Bond”)
is required and if, at any time after the execution of this Contract and the Bond for its faithful performance
and payment, the City deems the Surety or Sureties upon such bond(s) to be unsatisfactory, or if, for any
reason such bond ceases to be adequate to cover the performance of the Work or payment to
subcontractors and suppliers, Contractor must, at its expense within five (5) business days after the receipt
of notice from the City so to do, furnish an additional bond or bonds in such form and amount and with 84 of 118 89
such Surety or Sureties as are satisfactory to the City. In such event, no further payment to Contractor
will be deemed to be due under this Contract until such new or additional security for the faithful
performance of the Work is furnished in the manner and in the form satisfactory to the City.
10. No additional Work or extras may be done unless the same is duly authorized in writing, and in advance
of the work, by appropriate action by the City and in accordance with the Contract Documents.
11. The date that this contract was “made and entered into” and its effective date is the date that the contract is the
signed by the City or, if the contract is required to be approved by resolution of the City Commission, then the
Effective Date is the date of the resolution approving the Contract whichever is the later date.
IN WITNESS WHEREOF, the parties hereto have executed this Contract on the day and date set
forth next to their name below and may be signed in one or more counterparts, each of which will, without proof
or accounting for the other counterpart, be deemed an original Contract.
CONTRACTOR: _______________________________
Signature: ________________________________
Print Signatory’s Name: ________________________________
Title of Signatory: ________________________________
ATTESTED: OWNER: CITY OF SOUTH MIAMI
Signature: _______________________ Signature: ______________________
Nkenga A. Payne Shari Kamali
City Clerk City Manager
Read and Approved as to Form, Language,
Legality, and Execution Thereof:
Signature: ________________________
City Attorney
85 of 118 90
EXHIBIT 6
CONSTRUCTION CONTRACT
GENERAL CONDITIONS
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
ARTICLE 1 – DEFINITIONS
Whenever used in these General Conditions or in the other Contract Documents, the following terms have the
meaning indicated. These definitions always apply when the section of the Contract specifically refers to this
Article for the purpose of interpreting a word or group of words in that section of the Contract Document.
However, when the section of the Contract, where the word to be defined is used, does not specifically refers to
this Article to define the word or group of words, the definitions contained in this Article will not apply unless the
word or group of words, in the context of it or their use in the Contract Document in question, is/are ambiguous
and open for interpretation. In addition, these definitions do not apply to interpret terms in a specific provision of
a Contract Document if that specific provision contains a definition of th e term in question:
Addenda: Written or graphic documents issued prior to the Bid Opening which modify or interpret the Contract
Documents, Drawings and Specifications, by addition, deletions, clarifications, or correction.
Application for Payment: A form approved by the City’s consultant (CONSULTANT), if any, or the City Manager
which is to be used by CONTRACTOR in requesting progress payments.
Bid: The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices and other
terms for the Work to be performed.
Bidder: Any person, firm or corporation submitting a response to OWNER’s solicitation for proposals or bids for
Work.
Bid Documents: The solicitation for bids or proposals and all documents that make up the solicitation including
the instructions, form of documents and affidavits.
Bonds: Bid bond, performance and payment bonds and other instruments of security, furnished by
CONTRACTOR and its surety in accordance with the Contract Documents and in accordance with the laws of
the State of Florida.
Change Order: A written order to CONTRACTOR signed by the City Manager authorizing an addition, deletion
or revision in the Work, or an adjustment in the Contract Price or the Contract Time issued after execution of
the Contract.
Work Order Proposals: Written proposals from CONTRACTOR in response to orders or request for work
based on the Scope of the Work provided by OWNER to CONTRACTOR. The proposal includes line item
pricing, where there are multiple locations, and the timeframe for completing the work.
City: The City Manager for the City of South Miami, 6130 Sunset Drive, South Miami, FL 33143, or manager’s
designee, unless the context wherein the word is used should more appropriately mean the City of South Miami.
City Manager: Includes the City Manager’s designee.
Construction Observer: An authorized representative of CONSULTANT, if any, or otherwise a representative of
OWNER assigned to observe the Work performed and materials furnished by CONTRACTOR. CONTRACTOR
will be notified in writing of the identity of this representative.
Contract Documents: The Contract Documents include the Contract between OWNER and CONTRACTOR,
other documents listed in the Contract and modifications issued after execution of the Contract as well as all Bid
Documents including but not limited to the solicitation for Bid, CONTRACTOR’S Bid, the Bonds, Insurance
endorsements, Insurance Certificates and policies, the Notice of Award, the Notice to Proceed, the General
Conditions, Special Conditions, if any, any Supplementary Conditions, the Technical Specifications, Drawings,
including any incorporated specifications, addenda to the drawings issued prior to execution of the Contract,
Change Orders, Construction Change Directives and any written order for a minor change in the Work, and
written modifications to any of the Contract Documents.
Contract Price: The total moneys payable to CONTRACTOR pursuant to the terms of the Contract Documents.
Contract Time: The number of calendar days stated in the Contract for the completion of the Work.
Contracting Officer: The individual who is authorized to sign the contract documents on behalf of OWNER.
CONTRACTOR: The person, firm or corporation with whom OWNER has executed the Contract.
CONSULTANT: The person identified as CONSULTANT in the Supplementary Conditions or, if none, then
OWNER’s designated representative as identified in the Supplementary Conditions.
Day: A period of twenty-four hours measured from the beginning of the day at 12:01 a.m. and it will be presumed
to be a calendar day unless specifically designated as a business day.
Days: The number of twenty-four (24) hour periods following the event to which the word “days” refers
commencing at 12:01 a.m. at the start of the next day. Therefore, in computing any period of time prescribed or
allowed by the Contract Documents, the day of the act, event or default from which the designated period of time 86 of 118 91
begins to run will not be included. The last day of the period so computed will be included unless it is a Saturday,
Sunday or legal holiday, in which event the period will run until the end of the next business day that is not a
Saturday, Sunday or legal holiday.
Defective Work: Work that is unsatisfactory, faulty, or deficient in that it does not conform to the Contract
Documents, or does not meet the requirements of any applicable inspection, reference standard, test, or approval
referred to in the Contract Documents, or has been damaged prior to CONSULTANT’S recommendation of final
payment (unless responsibility for the protection thereof has been delegated to OWNER); substitutions that are
not properly approved and authorized, any deficiency in the Work, materials and equipment; materials and
equipment furnished under the Contract that are not good quality and new unless otherwise required or
permitted by the Contract Documents.
Drawings: The drawings which show the character and Scope of the Work to be performed and which have been
prepared or approved by CONSULTANT, or if none, then by an architect or engineer hired by City Manager and
are referred to in the Contract Documents.
Field Order: A written order issued by CONSULTANT which clarifies or interprets the Contract Documents in
accordance with Paragraph 9.3 or orders minor changes in the Work in accordance with paragraph 10.2.
Modification: (a) A written amendment of the Contract Documents signed by both parties, (b) a Change Order
signed by both parties, (c) a written clarification or interpretation if issued by CONSULTANT in accordance with
paragraph 9.3 or (d) a written order for minor change or alteration in the Work issued by CONSULTANT
pursuant to Paragraph 10.2. A modification may only be issued after execution of the Contract, it must be in
writing and signed by the party against whom the modification is sought to be enforced.
Non-conforming Work means work that does not conform to the Contract Documents and includes wo rk that is
unsatisfactory, faulty, or deficient or that does not meet the requirements of any applicable inspection, reference
standard, test, or that does not meet any approval required by, or referred to in, the Contract Documents, or
work that has been damaged prior to CONSULTANT’s recommendation of final payment (unless responsibility for
the protection thereof has been assumed in writing by OWNER).
Notice of Award: The written notice by City Manager to the apparent successful Bidder stating that upon
compliance with the conditions precedent to be fulfilled by it within the time specified, C ity Manager will execute
and deliver the Contract to him.
Notice to Proceed: A written notice given by City Manager to CONTRACTOR (with copy to CONSULTANT)
fixing the date on which the Contract Time will commence to run and on which CONTRACTOR must start to
perform its obligations under the Contract Documents.
Owner. The City of South Miami.
Person: An individual or legal entity.
Project: The entire construction operation being performed as delineated in the Contract Documents.
Policy: The term “policy” as used in the Contract Documents means the insurance binder, if it is issued, the
declaration page of the policy and the body of the policy, including all endorsements.
RFP: Request for Proposal.
Scope of Services. This phrase refers to the scope of the services or work to be performed and it has the same
meaning as Scope of the Work unless the context in which the phase is used clearly means otherwise.
Shop Drawings: All drawings, diagrams, illustrations, brochures, schedules and other data which are prepared by
CONTRACTOR, a Subcontractor, manufacturer, supplier, or distributor, and which illustrate the equipment,
material or some portion of the work and as required by the Contract Documents.
Samples: Physical examples which illustrate materials, equipment or workmanship and establish standards by which
the Work will be judged.
Specifications: Those portions of the Contract Documents consisting of written technical descriptions of
materials, equipment, construction systems, standards and workmanship as applied to the Work.
Subcontractor: An individual, firm or corporation having a direct contract with CONTRACTOR or with any
other Subcontractor for the performance of a part of the Work at the construction site.
Substantial Completion: The date, as certified by CONSULTANT, when the construction of the Project or a
certified part thereof is sufficiently completed, in accordance with the Contract Documents, so that the Project, or
a substantial part, can be utilized for the purposes for which it was intended without restriction or limitation to
any degree, other than for the repair of minor “punch list” items; or if there be no such certification, the date
when final payment is due in accordance with paragraph 14.9. However, in no event will the project or portion
thereof, be deemed to be substantially completed until a certificate of occupancy or certificate of use is lawfully
issued by the applicable governmental agency. A certificate of Substantial Completion, issued by CONSULTANT,
will be null and void if it is based on false, misleading or inaccurate information, from any source, or when it would
not have been issue but for the consideration of Work th at is thereafter found to be defective to a degree greater
than that which would normally to be considered by C ity Manager to be minor “punch list” work.
Supplier: Any person or organization who supplies materials or equipment for the Work, including the fabrication
of an item, but who does not perform labor at the site of the Work. 87 of 118 92
Surety: The individual or entity who is an obligor on a Bond and who is bound with CONTRACTOR for the full
and faithful performance of the Contract and for the payment of all labor, services and materials used on the
project.
Work: Any and all obligations, duties and responsibilities necessary for the successful performance and completion
of the Contract.
Notice: The term “Notice” as used herein means and includes all written notices, demands, instructions, claims,
approvals and disapprovals required to obtain compliance with Contract requirements. Written notice will be
deemed to have been duly served if delivered in person to the individual or to a member of the firm or to an
officer of the corporation for whom it is intended, or to an authorized representative of such individual, firm, or
corporation, or if delivered at or sent by registered mail to the last known business address. Unless otherwise
stated in writing, any notice to or demand upon OWNER under this Contract must be delivered to City Manager
and CONSULTANT.
ARTICLE 2 – PRELIMINARY MATTERS
Award:
2.1 The City Manager reserves the right to reject any and all Bids, at its sole discretion. Bids will be
awarded by OWNER to the lowest responsive and responsible Bidder. No Notice of Award will be given
until the City Manager has concluded its investigation, as it deems necessary, to establish, to the
satisfaction of the City Manager, which Bidder is the most responsive and responsible of all the Bidders to
complete the Work within the time prescribed and in accordance with the Contract Documents. The
City Manager reserves the right to reject the Bid of any Bidder who is not believed to be, in the sole
discretion and satisfaction of City Manager, to be sufficiently responsible, qualified and financial able to
perform the work. In analyzing a Bid, the City Manager may also take into consideration alternate and unit
prices, if requested by the Bid forms. If the Contract is awarded, the City Manager will issue the Notice of
Award and give the successful Bidder a Contract for execution within ninety (90) day after opening of
Bids.
Execution of Contract:
2.2 At least four counterparts of the Contract, the Performance and Payment Bond, the Certificates of
Insurance, the Binder of Insurance if issued, the Insurance Declaration Page if not included in the Policy of
Insurance, the Policy of Insurance required by the Contract Documents, the written notice of designated
supervisor or superintendent as provided in Section 6.1 of the General Conditions and such other
Documents as required by the Contract Documents must be executed and delivered by CONTRACTOR
to the City Manager within ten (10) calendar days of receipt of the Notice of Award. A Contract
Document that requires the signature of a party may be executed in counterparts separately by each of
the parties and, in such event, each counterpart separately execute d will, without proof or accounting for
the other counterpart be deemed an original Contract Document.
Forfeiture of Bid Security/Performance and Payment Bond, if any are required by the applicable RFP:
2.3 Within ten (10) calendar days of being notified of the Award, CONTRACTOR must furnish a
Performance Bond and a Payment Bond containing all the provisions of the Performance Bond and
Payment Bond attached.
2.3.1 Each Bond must be in the amount of one hundred percent (100%) of the Contract Price
guaranteeing to OWNER the completion and performance of the Work covered in such Contract
as well as full payment of all suppliers, material man, laborers, or Subcontractor employed pursuant
to this Project. Each Bond must be with a Surety company whose qualifications meet the
requirements of Sections 2.3.4, 2.3.5, and 2.3.6.
2.3.2 Each Bond must continue in effect for five years after final completion and acceptance of the Work
with the liability equal to one hundred percent (100%) of the Contract Sum.
2.3.3 Pursuant to the requirements of Section 255.05(1), Florida Statutes, CONTRACTOR must ensure
that the Bond(s) referenced above are recorded in the public records of Miami-Dade County and
provide City Manager with evidence of such recording.
2.3.4 Each Bond must be executed by a surety company authorized to do business in the State of Florida
as a surety, having a resident agent in the State of Florida and having been in business with a record
of successful continuous operation for a least five (5) years.
2.3.5 The surety company must hold a current certificate of authority as acceptable surety on federal
bonds in accordance with the United States Department of Treasury Circular 570, current
revisions.
2.3.6 OWNER will only be required to accept a surety bond from a company with a rating A. VII or
better. 88 of 118 93
2.3.7 Failure of the successful Bidder to execute and deliver the Contract and deliver the required bonds
and Insurance documents will be cause for the City Manager to annul the Notice of Award and
declare the Bid and any security therefore forfeited.
Contractor’s Pre-Start Representation:
2.4 CONTRACTOR represents that it has familiarized itself with, and assumes full responsibility for having
familiarized itself with the nature and extent of the Contract Documents, Work, locality, and with all local
conditions and federal, state and local laws, ordinance, rules and regulations that may in any manner affect
performance of the Work, and represents that it has correlated its study and observations with the
requirements of the Contract Documents. CONTRACTOR also represents that it has studied all surveys
and investigations, reports of subsurface and latent physical conditions referred to in the specifications
and made such additional surveys and investigations as it deems necessary for the performance of the
Work reflected in the Contract Documents and that he has correlated the results of all such data with
the requirements of the Contract Documents.
Commencement of Contract Time:
2.5 The Contract Time will commence to run on the date stated in the Notice to Proceed.
Starting the Project:
2.6 CONTRACTOR must start to perform its obligations under the Contract Documents on the date the
Contract Time commences to run. No Work may be done at the site (as defined in Article 1), prior to
the date on which the Contract Time commences to run, except with the written consent of the C ity
Manager.
Before Starting Construction:
2.7 Before undertaking each part of the Work, CONTRACTOR must carefully study and compare the
Contract Documents and check and verify pertinent figures shown thereon and all applicable field
measurements and conditions. It must at once report in writing to CONSULTANT any conflict, error, or
discrepancy which it may discover. Neither OWNER nor CONSULTANT will be liable for any harm,
damage or loss suffered by CONTRACTOR as a result of its failure to discover any conflict, error, or
discrepancy in the Drawings or Specifications nor will CONTRACTOR be entitled to any compensation
for any harm, damage or loss suffered by CONTRACTOR due to any conflict, error, or discrepancy in
the Contract Documents.
Schedule of Completion:
2.8 Within Five (5) business days after delivery of the Notice to Proceed by City Manager to
CONTRACTOR, CONTRACTOR must submit to CONSULTANT for approval, an estimated
construction schedule indicating the starting and completion dates of the various stages of the Work, and
a preliminary schedule of Shop Drawing submissions. CONSULTANT will approve this schedule or
require revisions thereto within seven (7) calendar days of its submittal. If there is more than one
CONTRACTOR involved in the Project, the responsibility for coordinating the Work of all
CONTRACTORS will be provided in the Special Conditions.
2.9 Within five (5) business days after delivery of the executed Contract by City Manager to
CONTRACTOR, but before starting the Work at the site, a pre-construction conference will be held to
review the above schedules, to establish procedures for handling Shop Drawings and other submissions,
and for processing Applications for Payment, and to establish a working understanding between the
parties as to the Project. Present at the conference will be OWNER’S representative, CONSULTANT,
Resident Project Representatives, CONTRACTOR and its Superintendent.
Qualifications of Subcontractors, Material men and Suppliers:
2.10 Within five (5) business days after bid opening, the apparent lowest responsive and responsible Bidder
must submit to the City Manager and CONSULTANT for acceptance a list of the names of
Subcontractors and such other persons and organizations (including those who are to furnish principal
items of materials or equipment) proposed for those portions of the Work as to which the identity of
Subcontractors and other persons and organizations must be submitted as specified in the Contract
Documents. Within thirty (30) calendar days after receiving the list, CONSULTANT will notify
CONTRACTOR in writing if either the City Manager or CONSULTANT has reasonable objection to any
Subcontractor, person, or organization on such list. The failure of the City Manager or CONSULTANT
to make objection to any Subcontractor, person, or organization on the list within thirty (30) calendar
days of the receipt will constitute an acceptance of such Subcontractor, person or 89 of 118 94
organization. Acceptance of any such Subcontractor, person or organization will not constitute a waiver
of any right of OWNER or CONSULTANT to reject defective Work, material or equipment, or any
Work, material or equipment not in conformance with the requirements of the Contract Documents.
2.11 If, prior to the Notice of Award, the City Manager or CONSULTANT has reasonable objection to any
Subcontractor, person or organization listed, the apparent low Bidder may, prior to Notice of Award,
submit an acceptable substitute without an increase in its bid price.
2.12 The apparent silence of the Contract Documents as to any detail, or the apparent omission from them of
a detailed description concerning any Work to be done and materials to be furnished, will be regarded as
meaning that only best practices are to prevail and only materials and workmanship of the best quality are
to be used in the performance of the Work.
ARTICLE 3–CORRELATION, INTERPRETATION AND INTENT OF CONTRACT DOCUMENTS
3.1 It is the intent of the Specifications and Drawings to describe a complete Project to be constructed in
accordance with the Contract Documents. The Contract Documents comprise the entire Contract
between OWNER and CONTRACTOR. They may be altered only by a modification as defined in Article
1.
3.2 The Contract Documents are complementary; what is called for by one is as binding as if called for by all
the documents. If CONTRACTOR finds a conflict, error or discrepancy in the Contract Documents, it
must, before proceeding with the Work affected thereby, immediately call it to CONSULTANT’s
attention in writing. The various Contract Documents are complementary; in case of conflict, error or
discrepancy, the more stringent interpretation and requirement that will provide the maximum benefit to
OWNER will apply
3.3 The words “furnish” and “furnish and install”, “install”, and “provide” or words with similar meaning will
be interpreted, unless otherwise specifically stated, to mean “furnish and install complete in place and
ready for service”.
3.4 Miscellaneous items and accessories which are not specifically mentioned, but which are essential to
produce a complete and properly operating installation, or usable structure, providing the indicated
functions, must be furnished and installed without change in the Contract Price. Such miscellaneous items
and accessories must be of the same quality standards, including material, style, finish, strength, class,
weight and other applicable characteristics, as specified for the major component of which the
miscellaneous item or accessory is an essential part, and will be approved by CONSULTANT before
installation. The above requirement is not intended to include major components not covered by or
inferable from the Drawings and Specifications.
3.5 The Work of all trades under this Contract must be coordinated by CONTRACTOR in such a manner as
obtain the best workmanship possible for the entire Project, and all components of the Work must be
installed or erected in accordance with the best practices of the particular trade.
3.6 CONTRACTOR will be responsible for making the construction of habitable structures under this
Contract rain proof, and for making equipment and utility installations properly perform the specified
function. If CONTRACTOR is prevented from complying with this provision due to the Drawings or
Specifications, CONTRACTOR must immediately notify CONSULTANT in writing of such limitations
before proceeding with construction in the area where the problem exists.
3.7 Manufacturer’s literature, when referenced, must be dated and numbered and is intended to establish the
minimum requirements acceptable. Whenever reference is given to codes, or standard specifications or
other data published by regulating agencies or accepted organizations, including but not limited to
National Electrical Code, applicable State Building Code, Florida Building Code, Federal Specifications,
ASTM Specifications, various institute specifications, and the like, it will be understood that such reference
is to the latest edition including addenda in effect on the date of the Bid.
3.8 Brand names where used in the technical specifications, are intended to denote the standard or quality
required for the particular material or product. The term "equal" or "equivalent", when used in
connection with brand names, will be interpreted to mean a material or product that is similar and equal
in type, quality, size, capacity, composition, finish, color and other applicable characteristics to the material
or product specified by trade name, and that is suitable for the same use capable of performing the same
function, in the opinion of CONSULTANT, as the material or product so specified. Proposed equivalent
items must be approved by CONSULTANT before they are purchased or incorporated in the Work.
(When a brand name, catalog number, model number, or other identification, is used without the phrase
"or equal", CONTRACTOR must use the brand, make and model specified).
3.9 Throughout this agreement the male pronoun may be substituted for female and neuter and vice versa
and the singular words substituted for plural and plural words substituted for singular wherever
applicable.
3.10 All technical interpretations will be made by CONSULTANT as set forth in Section 9.3 below. 90 of 118 95
3.11 CONTRACTOR must advise CONSULTANT, prior to performing any work involving a conflict in the
Contract Documents and CONSULTANT will make the final decision as to which of the documents will
take precedence. If there is a conflict between or among the Contract Documents, only the latest
version will apply and the latest version of the Contract Documents. CONSULTANT must use the
following list of Contract Documents as a guide. These documents are set forth below in the order of
their precedence so that all the documents listed above a given document should have precedence over
all the documents listed below it.
(a) Change Orders
(b) Amendments/addenda to Contract
(c) Supplementary Conditions, if any
(d) Contract with all Exhibits thereto
(e) General Conditions
(f) Written or figured dimensions
(g) Scaled dimensions
(h) Drawings of a larger scale
(i) Drawings of a smaller scale
(j) Drawings and Specifications are to be considered complementary to each other
ARTICLE 4 – AVAILABILITY OF LANDS SUBSURFACE CONDITIONS REFERENCE POINTS
Availability of Lands:
4.1 OWNER will furnish, as indicated in the Contract Documents, the lands upon which the Work is to be
done, rights-of-way for access thereto, and such other lands which are designed for the use of
CONTRACTOR. Easements for permanent structures or permanent changes in existing facilities will be
obtained and paid for by OWNER, unless otherwise specified in the Contract Documents. Other access
to such lands or rights-of-way for CONTRACTOR'S convenience will be the responsibility of
CONTRACTOR.
CONTRACTOR must provide for all additional lands and access thereto that may be required for
temporary construction facilities or storage of material and equipment.
4.2 The City Manager will, upon request, furnish to the Bidders, copies of all available boundary surveys and
subsurface tests at no cost.
Subsurface Conditions:
4.3 CONTRACTOR acknowledges that he has investigated prior to bidding and satisfied himself as to the
conditions affecting the Work, including but not limited to those bearing upon transportation, disposal,
handling and storage of materials, availability of labor, water, electric power, roads and uncertainties of
weather, river stages, tides, water tables or similar physical conditions at the site, the conformation and
conditions of the ground, the character of equipment and facilities needed preliminary to and during
prosecution of the Work. CONTRACTOR further acknowledges that he has satisfied himself as to the
character, quality and quantity of surface and subsurface materials or obstacles to be encountered insofar
as this information is reasonably ascertainable from an inspection of the site, including all exploratory
work done by OWNER/ CONSULTANT on the site or any contiguous site, as well as from information
presented by the Drawings and Specifications made part of this Contract, or any other information made
available to it prior to receipt of bids. Any failure by CONTRACTOR to acquaint itself with the available
information will not relieve it from responsibility for estimating properly the difficulty or cost of
successfully performing Work. OWNER assumes no responsibility for any conclusions or interpretations
made by CONTRACTOR on the basis of the information made available by OWNER/ CONSULTANT.
Differing Site Conditions:
4.4 CONTRACTOR must within forty-eight (48) hours of its discovery, and before such conditions are
disturbed, notify the City Manager in writing, of:
4.4.1 Subsurface or latent physical conditions at the site differing materially from those indicated in the
Contract Documents, and
4.4.2 Unknown physical conditions at the site, of an unusual nature, differing materially from those
ordinarily encountered and generally inherent in Work of the character provided for in this
Contract. The City Manager will promptly investigate the conditions, and if it finds that such
conditions do materially differ to the extent as to cause an increase or decrease in
CONTRACTOR'S cost of, or the time required for, performance of any part of the Work under
this Contract, an equitable adjustment will be made and the Contract modified in writing
accordingly.
91 of 118 96
4.5 No claim of CONTRACTOR under this clause will be allowed unless CONTRACTOR has given the
notice required in 4.4 above; provided, however, the time prescribed therefore may be extended by the
City Manager, but only if done in writing signed by the City Manager or CONSULTANT.
ARTICLE 5 – INSURANCE Contractor must comply with the insurance requirements set forth in the
Supplementary Conditions to the Contract.
ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES
Supervision and Superintendence:
6.1 CONTRACTOR must supervise and direct the Work. It will be solely responsible for the means,
methods, techniques, sequences and procedures of construction. CONTRACTOR must employ and
maintain a qualified supervisor or superintendent (hereinafter referred to as “Supervisor” at the Work
site who must be designated in writing by CONTRACTOR, before CONTRACTOR commences the
Work and within the time required by the Contract, as CONTRACTOR'S representative at the site. The
Supervisor or the person designated will have full authority to act on behalf of CONTRACTOR and all
communications given to the Supervisor will be as binding as if given to CONTRACTOR. The
Supervisor(s) will always be present at each site as required to perform adequate supervision and
coordination of the Work. (Copies of written communications given to the Supervisor will be mailed to
CONTRACTOR'S home office).
6.1.1 CONTRACTOR must keep one record copy of all Specifications, Drawings, Addenda,
Modifications and Shop Drawings at the site at all times and in good order and annotated to show
all changes made during the construction process. These must be available to CONSULTANT
and any OWNER Representative at all reasonable times. A set of “As-Built” drawings, as well as
the original Specifications, Drawings, Addenda, Modifications and Shop Drawings with annotations,
will be made available to City Manager at all times and it must be delivered to the City Manager
upon completion of the Project.
Labor, Materials and Equipment:
6.2 CONTRACTOR must provide competent, suitably qualified personnel to lay out the Work and perform
construction as required by the Contract Documents. It must always maintain good discipline and order
at the site.
6.3 CONTRACTOR must furnish all materials, equipment, labor, transportation, construction equipment and
machinery, tools, appliances, fuel, power, light, heat, local telephone, water and sanitary facilities and all
other facilities and incidentals necessary for the execution, testing, initial operation and completion of the
Work.
6.4 All materials and equipment must be new, except as otherwise provided in the Contract
Documents. When special makes or grades of material which are normally packaged by the supplier or
manufacturer are specified or approved, such materials must be delivered to the site in their original
packages or containers with seals unbroken and labels intact.
6.5 All materials and equipment must be applied, installed, connected, erected, used, cleaned and conditioned
in accordance with the instructions of the applicable manufacturer, fabricator, or processors, except as
otherwise provided in the Contract Documents.
Work, Materials, Equipment, Products and Substitutions:
6.6 Materials, equipment and products incorporated in the Work must be approved for use before being
purchased by CONTRACTOR. CONTRACTOR must submit to CONSULTANT a list of proposed
materials, equipment or products, together with such samples as may be necessary for them to determine
their acceptability and obtain their approval, within ninety (90) calendar days after award of Contra ct
unless otherwise stipulated in the Special Conditions. No request for payment for "or equal" equipment
will be approved until this list has been received and approved by CONSULTANT.
6.6.1 Whenever a material, article or piece of equipment is identified on the Drawings or Specifications
by reference to brand name or catalog number, it is understood that this is referenced for the
purpose of defining the performance or other salient requirements and that other products of
equal capacities, quality and function must be considered. CONTRACTOR may recommend the
substitution of a material, article, or piece of equipment of equal substance and function for those
referred to in the Contract Documents by reference to brand name or catalog number, and if, in
the opinion of CONSULTANT, such material, article, or piece of equipment is of equal substance
and function to that specified, CONSULTANT may approve its substitution and use by
CONTRACTOR. Incidental changes or extra component parts required to accommodate the
92 of 118 97
substitute will be made by CONTRACTOR without a change in the Contract Price or the
Contract Time.
6.6.2 No substitute may be ordered or installed without the written approval of CONSULTANT who
will be the judge of quality.
6.6.3 Delay caused by obtaining approvals for substitute materials will not be considered justifiable
grounds for an extension of construction time.
6.6.4 Should any Work or materials, equipment or products not conform to requirements of the
Drawings and Specifications or become damaged during the progress of the Work, such Work or
materials must be removed and replaced, together with any Work disarranged by such alterations,
at any time before completion and acceptance of the Project. All such Work must be done at the
expense of CONTRACTOR.
6.6.5 No materials or supplies for the Work may be purchased by CONTRACTOR or any
Subcontractor that are subject to any chattel mortgage or under a conditional sale or other
agreement by which an interest is retained by the Seller. CONTRACTOR warrants that they
have good title to all materials and supplies used by them in the Work.
6.6.6 Non-conforming Work: The City of South Miami may withhold acceptance of, or reject items
which are found upon examination, not to meet the specification requirements or conform to the
plans and drawings. Upon written notification of rejection, items must be removed or uninstalled
within five (5) business days by CONTRACTOR at his own expense and redelivered and/or
reinstalled at his expense. Rejected goods left longer than thirty (30) calendar days will be
regarded as abandoned and OWNER will have the right to dispose of them as its own property
and CONTRACTOR thereby waives any claim to the good or to compensation of any kind for
said goods. Rejection for non-conformance or failure to meet delivery schedules may result in
CONTRACTOR being found in default.
6.6.7 In case of default by CONTRACTOR, the City of South Miami may procure the articles or
services from other sources and hold CONTRACTOR responsible for any excess costs
occasioned or incurred thereby.
6.6.8 OWNER reserves the right, in the event CONTRACTOR cannot provide an item(s) or service(s)
in a timely manner as requested, to obtain the good and/or services from other sources and
deducting the cost from the Contract Price without violating the intent of the Contract.
Concerning Subcontractors:
6.7 CONTRACTOR may not employ any Subcontractor, against whom the City Manager or CONSULTANT
may have reasonable objection, nor will CONTRACTOR be required to employ any Subcontractor who
has been accepted by the City Manager and CONSULTANT, unless CONSULTANT determines that
there is good cause for doing so.
6.8 CONTRACTOR is be fully responsible for all acts and omissions of its Subcontractors and of persons and
organizations directly or indirectly employed by it and of persons and organizations for whose acts any of
them may be liable to the same extent that they are responsible for the acts and omissions of persons
directly employed by them. Nothing in the Contract Documents create any contractual relationship
between OWNER or CONSULTANT and any Subcontractor or other person or organization having a
direct contract with CONTRACTOR, nor may it create any obligation on the part of OWNER or
CONSULTANT to pay or to see to payment of any subcontractor or other person or organization,
except as may otherwise be required by law. City Manager or CONSULTANT may furnish to any
Subcontractor or other person or organization, to the extent practicable, evidence of amounts paid to
CONTRACTOR on account of specified Work done in accordance with the schedule values.
6.9 The divisions and sections of the Specifications and the identifications of any Drawings does not control
CONTRACTOR in dividing the Work among Subcontractors or delineating the Work performed by any
specific trade.
6.10 CONTRACTOR agrees to bind specifically every Subcontractor to the applicable terms and conditions of
the Contract Documents for the benefit of OWNER.
6.11 All Work performed for CONTRACTOR by a Subcontractor must be pursuant to an appropriate
agreement between CONTRACTOR and the Subcontractor.
6.12 CONTRACTOR is be responsible for the coordination of the trades, Subcontractors material and men
engaged upon their Work.
6.12.1 CONTRACTOR must inserted in all subcontracts relative to the Work appropriate provisions to
bind Subcontractors to CONTRACTOR by the terms of these General Conditions and other
Contract Documents insofar as applicable to the Work of Subcontractors, and give
CONTRACTOR the same power as regards to terminating any subcontract that City Manager
may exercise over CONTRACTOR under any provisions of the Contract Documents. 93 of 118 98
6.12.2 The City Manager or CONSULTANT will not undertake to settle any differences between
CONTRACTOR and their Subcontractors or between Subcontractors.
6.12.3 If in the opinion of CONSULTANT, any Subcontractor on the Project proves to be incompetent
or otherwise unsatisfactory, they must be promptly replaced by CONTRACTOR when directed
by CONSULTANT in writing.
6.12A Discrimination: No action may be taken by the any subcontractor with regard to the fulfilment of the
terms of the subcontract, including the hiring and retention of employees for the performance of Work
that would discriminate against any person on the basis of race, color, creed, religion, national origin, sex,
age, sexual orientation, familial status or disability. This paragraph must be made a part of the
subcontractor’s contract with CONTRACTOR.
Patent Fees and Royalties:
6.13 CONTRACTOR must pay all license fees and royalties and assume all costs incident to the use of any
invention, design, process or device which is the subject of patent rights or copyrights held by
others. CONTRACTOR must indemnify and hold harmless OWNER and CONSULTANT and anyone
directly or indirectly employed by either of them from against all claims, damages, losses and expenses
(including attorney's fees) arising out of any infringement of such rights during or after the completion of
the Work, and must defend all such claims in connection with any alleged infringement of such rights.
6.14 CONTRACTOR is responsible for determining the application of patent and/or royalty rights as to any
materials, appliances, articles or systems prior to bidding. However, he is not responsible for such
determination on systems which do not involve purchase by them of materials, appliances and articles.
Permits:
6.15 CONTRACTOR must secure and pay for all construction permits and licenses and must pay for all
governmental charges and inspection fees necessary for the prosecution of the Work, which are
applicable at the time of his Bid. When such charges are normally made by OWNER and when so stated
in the Special Conditions, there will be no charges to CONTRACTOR. The City Manager will assist
CONTRACTOR, when necessary, in obtaining such permits and licenses. CONTRACTOR must also pay
all public utility charges.
Electrical Power and Lighting:
6.16 Electrical power required during construction must be provided by each prime CONTRACTOR as
required by it. This service must be installed by a qualified electrical Contractor approved by
CONSULTANT. Lighting must be provided by CONTRACTOR in all spaces at all times where necessary
for good and proper workmanship, for inspection or for safety. No temporary power may be used off
temporary lighting lines without specific approval of CONTRACTOR.
Laws and Regulations:
6.17 CONTRACTOR must comply with all notices, laws, ordinances, rules and regulations applicable to the
Work. If CONTRACTOR observes that the Specifications or Drawings are at variance therewith, it must
give CONSULTANT prompt written notice thereof, and any necessary changes must be adjusted by an
appropriate modification. If CONTRACTOR performs any Work knowing it to be contrary to such laws,
ordinances, rules and regulations, and without such notice to CONSULTANT, it must bear all costs
arising there from; however, it will not be its primary responsibility to make certain that the Drawings and
Specifications are in accordance with such laws, ordinances, rules and regulations.
Discrimination:
6.17A No action may be taken by CONTRACTOR with regard to the fulfilment of the terms of the Contract,
including the hiring and retention of employees for the performance of Work that would discriminate
against any person on the basis of race, color, creed, religion, national origin, sex, age, sexual orientation,
familial status or disability.
Taxes:
6.18 Cost of all applicable sales, consumer use, and other taxes for which CONTRACTOR is liable under the
Contract must be included in the Contract Price stated by CONTRACTOR.
Safety and Protection:
6.19 CONTRACTOR is be responsible for initiating, maintaining and supervising all safety precautions and
programs in connection with the Work. They must take all necessary precautions for the safety of, and
must provide the necessary protection to prevent damage, injury or loss to:
6.19.1 All employees and other persons, who may be affected thereby, 94 of 118 99
6.19.2 All the Work and all materials or equipment to be incorporated therein, whether in storage on or
off the site, and
6.19.3 Other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements,
roadways, structures and utilities not designated for removal, relocation or replacement in the
course of construction.
6.20 CONTRACTOR must designate a responsible member of their organization at the site whose duty must
be the prevention of accidents. This person must be CONTRACTOR'S Superintendent unless otherwise
designated in writing by CONTRACTOR to the City Manager.
Emergencies:
6.21 In emergencies affecting the safety of persons or the Work or property at th e site or adjacent thereto,
CONTRACTOR, without special instruction or authorization from CONSULTANT or City Manager, is
obligated to act, at his discretion, to prevent threatened damage, injury or loss. He must give
CONSULTANT prompt written notice of any significant changes in the Work or deviations from the
Contract Documents caused thereby. If CONTRACTOR believes that additional Work done by him in an
emergency which arose from causes beyond his control entitles him to an increase in the Contract Price
or an extension of the Contract Time, he may make a claim therefore as provided in Articles 11 and 12.
The City Manager reserves the right, in the City Manager’s sole and absolute discretion and when in the
best interest of the City, to suspend the work or services or cancel this contract in the event of an
emergency that effects the City of South Miami, its residents or businesses and that has been declared an
emergency by the Governor, Mayor of Miami-Dade County or by the City Manager pursuant to the City
Manager’s Emergency Management powers set forth in Ch. 14 of the City’s Code of Ordinances. In such
event, the CONTRACTOR is only be entitled to be paid for the reasonable value of the work performed
and any costs advanced that cannot be mitigated by CONTRACTOR.
Shop Drawings and Samples:
6.22 After checking and verifying all field measurements, CONTRACTOR must submit to CONSULTANT for
review, in accordance with the accepted schedule of shop drawing submissions, six (6) copies (or at
CONSULTANT option, one reproducible copy) of all Shop Drawings, which must have been checked by
and stamped with the approval of CONTRACTOR. The Shop Drawings must be numbered and identified
as CONSULTANT may require. The data shown on the Shop Drawings must be complete with respect
to dimensions, design criteria, materials of construction and the like to enable CONSULTANT to review
the information without any unnecessary investigation.
6.23 CONTRACTOR must also submit to CONSULTANT for review, with such promptness as to cause no
delay in Work, all samples required by the Contract Documents.
All samples must have been checked by and stamped with the approval of CONTRACTOR, identified
clearly as to material, manufacturer, any pertinent catalog numbers and the use for which intended.
6.24 At the time of each submission, CONTRACTOR must notify CONSULTANT, in writing, of any
deviations between the Shop Drawings or samples and the requirements of the Contract Documents.
6.25 CONSULTANT must review with responsible promptness Shop Drawings and Samples, but his review is
only for conformance with the design concept of the Project and for compliance with the information
given in the Contract Documents. The review of a separate item as such will not indicate review of the
assembly in which the items functions. CONTRACTOR must make any corrections required by
CONSULTANT and must return the required number of corrected copies of Shop Drawings and
resubmit new samples until the review is satisfactory to CONSULTANT. CONTRACTOR must notify
CONSULTANT, in writing, of any prior Shop Drawing or revisions to Shop Drawings that are in conflict
with each submission or re-submission. CONTRACTOR'S stamp of approval on any Shop Drawings or
sample will constitute representation to OWNER and CONSULTANT that CONTRACTOR has either
determined and/or verified all quantities, dimension, field construction criteria, materials, catalog numbers
and similar data or they assume full responsibility for doing so, and that they have reviewed or
coordinated each Shop Drawing or sample with the requirements of the Work and the Contract
Documents.
6.26 No Work requiring a submittal of a Shop Drawing or sample may be commenced until the submission has
been reviewed and approved in writing by CONSULTANT. A copy of each Shop Drawing and each
approved sample must be kept in good order, in a book or binder, in chronological order or in such other
order required by CONSULTANT in writing, by CONTRACTOR at the site and must be available to
CONSULTANT.
6.27 CONSULTANT’s review of Shop Drawings or samples will not relieve CONTRACTOR from his
responsibility for any deviations from the requirements of the Contract Documents unless
CONTRACTOR has informed CONSULTANT, in writing, to each deviation at the time of submission 95 of 118 100
and CONSULTANT has given written approval to the specific deviation, nor may any review by
CONSULTANT relieve CONTRACTOR from responsibility for errors or omissions in the Shop
Drawings or samples.
6.27A CONTRACTOR is be liable to OWNER for any additional cost or delay that is caused by its failure to
notify CONSULTANT of any of said deviations or conflicts between Shop Drawings or due to errors in
the Shop Drawings or samples.
Cleaning Up:
6.28 CONTRACTOR must clean up behind the Work as much as is reasonably possible as the Work
progresses. Upon completion of the Work, and before acceptance of final payment for the Project by
OWNER, CONTRACTOR must remove all his surplus and discarded materials, excavated material and
rubbish as well as all other material and equipment that does not form a part of the Work, from the
property, roadways, sidewalks, parking areas, lawn and all adjacent property. In addition,
CONTRACTOR must clean his portion of Work involved in any building under this Contract, so that no
further cleaning by OWNER is necessary prior to its occupancy and he must restore all property, both
public and private, which has been disturbed or damaged during the prosecution of the Work so as to
leave the whole Work and Work Site in a neat and presentable condition.
6.29 If CONTRACTOR does not clean the Work site, OWNER may clean the Work Site of the materials
referred to in paragraph 6.28 and charge the cost to CONTRACTOR.
Public Convenience and Safety:
6.30 CONTRACTOR must, at all times, conduct the Work in such a manner as to ensure the least practicable
obstruction to public travel. The convenience of the general public and of the residents along and
adjacent to the area of Work must be provided for in a satisfactory manner, consistent with the
operation and local conditions. "Street Closed" signs must be placed immediately adjacent to the Work,
in a conspicuous position, at such locations as traffic demands. At any time that streets are required to be
closed, CONTRACTOR must notify law enforcement agencies and in particular, the City of South Miami
Police Department, before the street is closed and again as soon as it is opened. Access to fire hydrants
and other fire extinguishing equipment must be provided and maintained at all times.
Sanitary Provisions:
6.31 CONTRACTOR must provide on-site office, and necessary toilet facilities, secluded from public
observation, for use of all personnel on the Work Site, whether or not in his employ. They must be kept
in a clean and sanitary condition and must comply with the requirements and regulations of the Public
Authorities having jurisdiction. They may not commit a public nuisance. Temporary field office and
sanitary facilities must be removed upon completion of the Work and the premises must be left clean.
Indemnification:
6.32 Contractor must comply with the indemnification requirements set forth in the RFP and in EXHIBIT 2
of the Supplementary Conditions (Insurance and indemnification requirements).
6.33 In the event that any action or proceeding is brought against OWNER or CONSULTANT by reason of
any such claim or demand, CONTRACTOR, upon written notice from the City Manager, must defend
such action or proceeding by counsel satisfactory to the City Manager. The indemnification provided
above obligates CONTRACTOR to defend at its own expense or to provide for such defense, at
OWNER’S option, any and all claims of liability and all suits and actions of every name and description
that may be brought against OWNER or CONSULTANT, excluding only those claims that allege that the
injuries arose out of the sole negligence of OWNER or CONSULTANT.
6.34 The obligations of CONTRACTOR under paragraph 6.33 will not extend to the liability of
CONSULTANT, its agents or employees arising out of (a) the preparation or approval of maps, drawings,
opinions, reports, surveys, Change Orders, designs or specifications or (b) the giving of or the failure to
give directions or instructions by CONSULTANT, its agents or employees provided such act or omission
is the primary cause of injury or damage.
6.34A All of the forgoing indemnification provisions will survive the term of the Contract to which these
General Conditions are a part. Indemnification may not exceed an amount equal to the total value of all
insurance coverage required by Section 5.1 of this document. Indemnification is limited to damages caused
in whole or in part by any act, omission, or default of CONTRACTOR, CONTRACTOR’s
subcontractors, sub-subcontractors, materialmen, or agents of any tier or their respective employees to
the extent caused by the negligence, recklessness, or intentional wrongful misconduct of the indemnifying
party and persons employed or utilized by the indemnifying party in the performance of the construction
contract. 96 of 118 101
Responsibility for Connection to Existing Work:
6.35 CONTRACTOR must connect its Work to each part of the existing Work, existing building or structure
or Work previously installed as required by the Drawings and Specifications to provide a complete
installation.
6.36 Excavations, grading, fill, storm drainage, paving and any other construction or installations in rights-of-
ways of streets, highways, public carrier lines, utility lines, either aerial, surface or subsurface, etc., must
be done in accordance with requirements of the special conditions. OWNER will be responsible for
obtaining all permits necessary for the Work described in this paragraph 6.36. Upon completion of the
Work, CONTRACTOR must present to CONSULTANT certificates, in triplicate, from the proper
authorities, stating that the Work has been done in accordance with their requirements.
6.36.1 OWNER will cooperate with CONTRACTOR in obtaining action from any utilities or public
authorities involved in the above requirements.
6.36.2 CONSULTANT is responsible for obtaining elevations of curbs and gutters, pavement, storm
drainage structures, and other items which must be established by governmental departments as
soon as grading operations are begun on the site and, in any case, sufficiently early in the
construction period to prevent any adverse effect on the Project.
Cooperation with Governmental Departments, Public Utilities, Etc.:
6.37 CONTRACTOR is responsible for making all necessary arrangements with governmental departments,
public utilities, public carriers, service companies and corporations (hereinafter referred to as “third
parties”) owning or controlling roadways, railways, water, sewer, gas, electrical conduits, telephone, and
telegraph facilities such as pavements, tracks, piping, wires, cables, conduits, poles, guys, etc., including
incidental structures connected therewith, that are encountered in the Work in order that such items are
properly shored, supported and protected, that their location is identified and to obtain authority from
these third parties for relocation if CONTRACTOR desires to relocate the item. CONTRACTOR must
give all proper notices, must comply with all requirements of such third parties in the performance of his
Work, must permit entrance of such third parties on the Project in order that they may perform their
necessary work, and must pay all charges and fees made by such third parties for their work.
6.37.1 CONTRACTOR'S attention is called to the fact that there may be delays on the Project due to
work to be done by governmental departments, public utilities, and ot hers in repairing or moving
poles, conduits, etc. CONTRACTOR must cooperate with the above parties in every way
possible, so that the construction can be completed in the least possible time.
6.37.2 CONTRACTOR must be familiar with all codes, laws, ordinances, and regulations which in any
manner affect those engaged or employed in the Work, or materials and equipment use in or
upon the Work, or in any way affect the conduct of the Work, and no plea of misunderstanding
will be considered on account of damage or delay caused by his ignorance thereof.
Use Premises:
6.38 CONTRACTOR must confine its apparatus, storage of materials, and operations of its workmen to the
limits indicated by law, ordinances, permits and directions of CONSULTANT and City Manager, and may
not unnecessarily encumber any part of the site or any areas off site.
6.38.1 CONTRACTOR nay not overload or permit any part of any structure to be loaded with such
weight as will endanger its safety, nor may it subject any work to stresses or pressures that will
endanger it.
6.38.2 CONTRACTOR must enforce the rules and regulation promulgated by CONSULTANT and
OWNER as well as their instructions with regard to signs, advertisements, fires and smoking.
6.38.3 CONTRACTOR must arrange and cooperate with the City Manager in routing and parking of
automobiles of its employees, subcontractors and other personnel, as well as that of the material
delivery trucks and other vehicles that come to the Project site.
6.38.4 The City Manager will designate specific areas on the site for storage, parking, etc. and the job site
must be fenced to protect the job site and the general public.
6.38.5 CONTRACTOR must furnish, install and maintain adequate construction office facilities for all
workers employed by it or by its Subcontractors. Temporary offices must be provided and
located where directed and approved by CONSULTANT. All such facilities must be furnished in
strict accordance with existing governing regulations. Field offices must include telephone
facilities.
Protection of Existing Property Improvements:
6.38 Any existing surface or subsurface improvements, such as pavements, curbs, sidewalks, pipes or utilities,
footings, or structures (including portions thereof), trees and shrubbery, not indicated on the Drawings or noted 97 of 118 102
in the Specifications as being removed or altered must be protected from damage during construction of the
Project. Any such improvements damaged during construction of the Project must be restored at the expense
of CONTRACTOR to a condition equal to that existing at the time of award of Contract.
ARTICLE 7 - WORK BY OTHERS.
7.1 OWNER may perform additional Work related to the Project or may let other direct contracts therefor
which must contain General Conditions similar to these. CONTRACTOR must afford the other
contractors who are parties to such direct contracts (or OWNER, if it is performing the additional Work
itself), reasonable opportunity for the introduction and storage of materials and equipment and the
execution of Work, and must properly connect and coordinate its Work with theirs.
7.2 If any part of CONTRACTOR'S Work depends upon proper execution or results of the Work of any
other contractor or OWNER, CONTRACTOR must promptly report to CONSULTANT in writing any
defects or deficiencies in such Work that render it unsuitable for CONTRACTOR’s Work.
7.3 CONTRACTOR must do all cutting, fitting and patching of the Work that may be required to make its
several parts come together properly and fit to receive or be received by such other
Work. CONTRACTOR may not endanger any Work of others by cutting, excavating or otherwise
altering their Work and may only cut or alter their Work with the written consent of CONSULTANT
and of the other contractor whose work will be affected.
7.4 If the performance of additional Work by other contractors or OWNER is not noted in the Contract
Documents prior to the execution of the Contract, written notice thereof will be given to
CONTRACTOR prior to starting any such additional Work. If CONTRACTOR believes that the
performance of such additional Work by OWNER or others will cause CONTRACTOR additional
expense or entitles him to an extension of the Contract Time, he may make a claim therefore as provided
in Articles 11 and 12.
7.5 Where practicable, CONTRACTOR must build around the work of other separate contractors or must
leave chases, slots and holes as required to receive and to conceal within the general construction Work
the work of such other separate contractors as directed by them. Where such chases, slots, etc., are
impracticable, the Work will require specific approval of CONSULTANT.
7.6 Necessary chases, slots, and holes not built or left by CONTRACTOR must be cut by the separate
contractor requiring such alterations after approval of CONTRACTOR. CONTRACTOR must do all
patching and finishing of the work of other contractors where it is cut by them and such patching and
finishing will be at the expense of CONTRACTOR
7.7 Cooperation is required in the use of site facilities and in the detailed execution of the Work. Each
contractor must coordinate their operation with those of the other Contractors for the best interest of
the Work in order to prevent delay in the execution thereof.
7.8 Each of several contractors working on the Project Site must keep themselves informed of the progress
of the work of other contractors. Should lack of progress or defective workmanship on the part of other
contractors interfere with CONTRACTOR’s operations, CONTRACTOR must notify CONSULTANT
immediately and in writing. Lack of such notice to CONSULTANT will be construed as acceptance by
CONTRACTOR of the status of the work of other contractors as being satisfactory for proper
coordination of CONTRACTOR’s own Work.
7.9 The cost of extra Work resulting from lack of notice, untimely notice, failure to respond to notice,
Defective Work or lack of coordination will be CONTRACTOR’s cost.
7.10 The City Manager reserves the right in the event CONTRACTOR cannot provide an item(s) or service(s)
in a timely manner as requested, to obtain the good and/or services from other sources and deducting the
cost from the Contract Price without violating the intent of the Contract.
ARTICLE 8 – CITY’S RESPONSIBILITIES.
8.1 The City Manager will issue all communications to CONTRACTOR through CONSULTANT.
8.2 In cases of termination of employment of CONSULTANT, the City Manager will appoint a
CONSULTANT whose status under the Contract Documents will be that of the former CONSULTANT.
8.3 The City Manager will promptly furnish the data required of them under the Contract Documents.
8.4 OWNER’S duties in respect to providing lands and easements are set forth in Paragraphs 4.1 and 4.2.
8.5 OWNER will have the right to take possession of and use any completed or p artially completed portions
of the Work, notwithstanding the fact that the time for completing the entire Work or any portion
thereof may not have expired; but such taking possession and use will not be deemed an acceptance of
any Work not completed in accordance with the Contract Documents.
98 of 118 103
ARTICLE 9 – CONSULTANTS’ STATUS DURING CONSTRUCTION.
City’s Representative:
9.1 CONSULTANT will be OWNER’S representative during the construction period. The duties and
responsibilities and the limitations of authority of CONSULTANT as OWNER’S representative during
construction are set forth in Articles 1 through 16 of these General Conditions and will not be extended
without written consent of the City Manager and CONSULTANT.
9.1.1 CONSULTANT’s decision, in matters relating to aesthetics, will be final, if within the terms of the
Contract Documents.
9.1.2 Except as may be otherwise provided in this contract, all claims, counterclaims, disputes and other
matters in question between OWNER and CONSULTANT arising out of or relating to this
Contract or the breach thereof, will be decided in a court of competent jurisdiction within the
State of Florida.
Visits to Site:
9.2 CONSULTANT must provide an inspector to make periodic visits to the site at each phase of
construction to observe the progress and quality of the executed Work and to determine if the Work is
proceeding in accordance with the Contract Documents. His efforts must be directed toward providing
assurance for OWNER and all applicable regulatory agencies that construction is in compliance with the
Construction Documents and applicable laws, rules and regulations. On the basis of these on site-
observations as an experienced and qualified design professional, he must keep the City Manager informed
of the progress of the Work and must guard OWNER against defects and deficiencies in the Work of
CONTRACTOR.
Clarifications and Interpretations:
9.3 CONSULTANT will issue, with reasonable promptness, such written clarifications or interpretations of
the Contract Documents (in the form of Drawings or otherwise) as it may determine necessary, which
will be consistent with, or reasonably inferable from, the overall intent of the Contract Documents. If
CONTRACTOR seeks an increase in the Contract Price or extension of Contract Time based on a
written clarification and/or interpretation, it will be required to submit a timely claim as provided in
Articles 11 and 12.
Measurement of Quantities:
9.4 All Work completed under the Contract will be measured by CONSULTANT according to the United
States Standard Measures. All linear surface measurements will be made horizontally or vertically as
required by the item measured.
Rejecting Defective Work:
9.5 CONSULTANT will have authority to disapprove or reject Work that is "Defective Work" as defined in
Article 1. It will also have authority to require special inspection or testing of the Work including Work
fabricated on or off site, installed or completed as provided. If CONSULTANT requires testing of
completed Work, the cost of such inspections and/or testing must be approved in writing by the City
Manager. All consequential cost of such inspections and testing, including but not limited to the cost of
testing and inspection, the cost of repairing any of the Work, or the work of others, the cost to move
furniture and equipment and/or the cost to provide alternative facilities until the repair work can be
completed, must paid by CONTRACTOR if the Work is found to be Defective Work.
Shop Drawings, Change Orders and Payments:
9.6 In connection with CONSULTANT responsibility as to Shop Drawings and samples, see paragraphs 6.25
through 6.28, inclusive.
9.7 In connection with CONSULTANT’s responsibility for Change Orders see Articles 10, 11, and 12.
9.8 In connection with CONSULTANT responsibilities with respect to the Application for Payment, etc., see
Article 14.
Decisions on Disagreements:
9.10 CONSULTANT will be the initial interpreter of the Construction Documents.
Limitations on Consultant's Responsibilities:
9.11 CONSULTANT will not be responsible for the construction means, methods, techniques, sequences or
procedures, or the safety precautions and programs incident thereto.
99 of 118 104
9.12 CONSULTANT will not be responsible for the acts or omissions of CONTRACTOR, or any
Subcontractors, or any of their agent, servants or employees, or any other person performing any of the
Work under or through them.
ARTICLE 10 - CHANGES IN THE WORK.
10.1 Without invalidating the Contract, the City Manager may, at any time or from time to time, order
additions, deletions or revisions in or to the Work which will only be authorized by a written Change
Orders. Upon receipt of a Change Order, CONTRACTOR must proceed with the Work involved. All
such Work must be performed under the applicable conditions of the Contract Documents. If any
authorized written Change Order causes an increase or decrease in the Contract Price or an extension
or shortening of the Contract Time, an equitable adjustment will be made as provided in Article 11 or
Article 12. A written Change Order signed by the City Manager and CONTRACTOR indicates their
agreement to the terms of the Change Order. All Change Orders must be certified by CONSULTANT
as to the appropriateness and value of the change in the Work as well as to any change in the time to
complete the Work under the circumstances. The failure to include a time extension in the Change
Order or in the request for a change order will result in a waiver of any extension of time due to the
change in the work as reflected in the Change Order.
10.2 CONSULTANT may authorize minor changes or alterations in the Work not involving extra cost and not
inconsistent with the overall intent of the Contract Documents without the need for a forma l written
Change Order provided CONTRACTOR does not request additional time or additional
compensation. These may be accomplished by a written Field Order. If CONTRACTOR believes that
any change or alteration authorized by CONSULTANT’s Field Order would entitles CONTRACTOR to
an increase in the Contract Price or extension of Contract Time, it must submit a written notice of intent
to demand a Change Order within twenty-four (24) hours of the issuance of the Field Order and submit a
written proposal for Change Order within four (4) days thereafter, otherwise CONTRACTOR will be
deemed to have waived such claim.
10.3 Additional Work performed by CONTRACTOR without authorization of a written Change Order will
not entitle it to an increase in the Contract Price or an extension of the Contract Time, except in the
case of an emergency as provided in paragraph 6.21 and except as provided in paragraph 10.2.
10.4 The City Manager will execute appropriate Change Orders prepared by CONSULTANT covering
changes in the Work, to be performed as provided in paragraph 4.4, and Work performed in an
emergency as provided in paragraph 6.21 and any other claim of CONTRACTOR for a change in the
Contract Time or the Contract Price which is approved by CONSULTANT.
10.5 It is CONTRACTOR'S responsibility to notify its Surety of any changes affecting the general Scope of the
Work or change in the Contract Price or Contract Time and the amount of the applicable bonds will be
adjusted accordingly. CONTRACTOR must furnish proof of such an adjustment to the City Manager
before commencement of the Change Order Work. The Work will be stopped until CONTRACTOR
provides such proof of adjustment in the Bond amount and any such delay will be charged to
CONTRACTOR.
ARTICLE 11 – CHANGE OF CONTRACT PRICE.
11.1 The Contract Price constitutes the total compensation payable to CONTRACTOR for Performing the
Work. All duties, responsibilities and obligations assigned to or undertaken by CONTRACTOR will be at
its expense without changing the Contract Price.
11.2 The City Manager may, at any time, without written notice to the sureties, by written order designated or
indicated to be a Change Order, make any change in the Work within the general scope of t he Contract,
including but not limited to changes to or in:
11.2.1 Specifications (including drawings and designs);
11.2.2 Method or manner of performance of the Work.
11.2.3 OWNER-furnished facilities, equipment, materials, services, or site; or
11.2.4 Acceleration in the performance of the Work.
11.3 Except as provided in this section, or sections referred to in this section, no order, statement, or conduct
of the City Manager will be treated as a Change Order or entitle CONTRACTOR to an equitable
adjustment unless and until the change in the Work is specifically and expressly provided for in a written
Change Order, or as otherwise provided in another section of the Contract Documents.
11.4 When a Change Order is issued by CONSULTANT and signed by the City Manager or issued by the City
Manager in writing, CONTRACTOR must perform the Work even if CONTRACTOR does not agree
with the dollar amount of the Change Order. If any Change Order causes an increase or decrease in
CONTRACTOR'S cost of, or the time required for, the performance of any part of the Work under this
100 of 118 105
Contract, for which the City Manager and CONTRACTOR cannot reach a timely agreement, an equitable
adjustment based on the cost of the Work will be made and the Contract modified accordingly.
11.5 If CONTRACTOR intends to assert a claim for an equitable adjustment or contest the equitable
adjustment made by CONSULTANT, it must, within ten (10) calendar days after receipt of a written
Change Order, submit to the City Manager and CONSULTANT a written notice including a statement
setting forth the general nature and monetary extent of such claim for equitable adjustment, time
extension requested and supporting data. In determining the cost of the Change Order, the costs will be
limited to those listed in section 11.7 and 11.8.
11.6 No claim by CONTRACTOR for an equitable adjustment hereunder will be allowed if not submitted in
accordance with this section or if asserted after final payment under this Contract.
11.7 The value of any Work covered by a Change Order or of any claim for an increase or decrease in the
Contract Price will be determined in one of the following ways:
11.7.1 By negotiated lump sum.
11.7.2 On the basis of the reasonable cost and savings that results from the change in th e Work plus a
mutually agreed upon fee to CONTRACTOR to cover overhead and profit not to exceed 15%. If
CONTRACTOR disagrees with CONSULTANT’s determination of reasonable costs, the
CONTRACT must provide a list of all costs together with backup documentation
11.8 The term cost of the Work means the sum of all direct extra costs necessarily incurred and paid by
CONTRACTOR in the proper performance of the Change Order. Except as otherwise may be agreed
to in writing by City Manager, such costs must be in amounts no higher than those prevailing in Miami-
Dade County and may only include the following items:
11.8.1 Payroll costs for employees in the direct employ of CONTRACTOR in the performance of the
Work described in the Change Order under schedules of job classifications agreed upon by City
Manager and CONTRACTOR. Payroll costs for employees not employed full time on the Work
must be apportioned on the basis of their time spent on the Work. Payroll costs must be limited
to: salaries and wages, plus the costs of fringe benefits which may include social security
contributions, unemployment, excise and payroll taxes, workers' compensation, health and
retirement benefits, sick leave, vacation and holiday pay applicable thereto. Such employees may
include superintendents and foremen at the site. The expenses of performing Work after regular
working hours, on Sunday or legal holidays will be included in the above only if authorized by
OWNER and provided it was not in any way, whether in whole or in part the result of the fault of
CONTRACTOR due to negligence of CONTRACTOR or those acting by or through him or due
in whole or in part to Defective Work of CONTRACTOR.
11.8.2 Cost of all materials and equipment furnished and incorporated in the Work, including costs of
transportation and storage, and manufacturers' field services required in connection
therewith. CONTRACTOR must notify the City Manager of all cash discounts that are available
and offer OWNER the opportunity to deposit funds with CONTRACTOR for the payment for
items that offer a discount. Cash discounts will accrue to CONTRACTOR unless
CONTRACTOR fails to timely notify the City Manager of the discounts or if OWNER deposits
funds with CONTRACTOR with which to make payments in which cases the cash discounts will
accrue to OWNER. All trade discounts, rebates and refunds, and all returns from sale of surplus
materials and equipment will accrue to OWNER, and CONTRACTOR must make provisions so
that they may be obtained.
11.8.3 Payments made by CONTRACTOR to the Subcontractors for Work performed by
Subcontractors. If required by City Manager, CONTRACTOR must obtain competitive bids from
Subcontractors acceptable to him and must deliver such bids to City Manager who will then
determine, with the advice of CONSULTANT, which Bids will be accepted. No subcontract may
be a cost-plus contract unless approved in writing by the City Manager. If a Subcontract provides
that the Subcontractor is to be paid on the basis of Cost of Work plus a fee, the cost of the
Work will be determined in accordance this section 11.8 and in such case the word
“Subcontractor” will be substituted for the word “CONTRACTOR”.
11.8.4 Rentals of all construction equipment and machinery, except hand tools, and the parts thereof
whether rented from CONTRACTOR or others in accordance with rental agreements
approved by City Manager with the advice of CONSULTANT, and the costs of transportation,
loading, unloading, installation, dismantling and removal thereof - all in accordance with terms of
said rental agreements. The rental of any such equipment, machinery or parts must cease when
the use thereof is no longer necessary for the Work.
11.8.5 Sales, use or similar taxes related to the Work, and for which CONTRACTOR is liable, imposed
by any governmental authority.
101 of 118 106
11.8.6 Payments and fees for permits and licenses. Costs for permits and licenses must be shown as a
separate item.
11.8.7 The cost of utilities, fuel and sanitary facilities at the site.
11.8.8 Minor expenses such as telegrams, long distance telephone calls, telephone service at the site,
expressage and similar petty cash items in connection with the Work.
11.8.9 Cost of premiums for additional Bonds and insurance required solely because of changes in the
Work, not to exceed two percent (2%) of the increase in the Cost of the Work.
11.9 The term “Cost of the Work” does NOT include any of the following:
11.9.1 Payroll costs and other compensation of CONTRACTOR'S officers, executives, principals (of
partnership and sole proprietorships), general managers, engineers, architects, estimators, lawyers,
agents, expediters, timekeepers, clerks and other personnel employed by CONTRACTOR
whether at the site or in its principal or a branch office for general administration of the Work
and not specifically included in the schedule referred to in Subparagraph 11.5.
11.9.2 Expenses of CONTRACTOR'S principal and branch offices other than its office at the site.
11.9.3 Any part of CONTRACTOR'S capital expenses, including interest on CONTRACTOR'S capital
employed for the Work and charges against CONTRACTOR for delinquent payments.
11.9.4 Cost of premiums for all bonds and for all insurance policies whether or not CONTRACTOR is
required by the Contract Documents to purchase and maintain the same (except as otherwise
provided in Subparagraph 11.8.9).
11.9.5 Costs due to the negligence of CONTRACTOR, any Subcontractor, or anyone directly or
indirectly employed by any of them or for whose acts any of them may be liable, including but not
limited to, the correction of defective work, disposal of materials or equipment wrongly supplied
and making good any damage to property.
11.9.6 Other overhead or general expense costs of any kind and the costs of any item not specifically
and expressly included in Paragraph 11.8.
11.10 CONTRACTOR'S fee which will be allowed to CONTRACTOR for its overhead and profit will be
determined as follows:
11.10.1 A mutually acceptable firm fixed price; or if none can be agreed upon.
11.10.2 A mutually acceptable fixed percentage (not to exceed 15%).
11.11 The amount of credit to be allowed by CONTRACTOR to OWNER for any such change which results in
a net decrease in cost will be the amount of the actual net decrease in costs calculated in the same
manner as provided in 11.8. When both additions and credits are involved in any one change, the net will
be computed to include overhead and profit, identified separately, for both additions and credit, provided
however, CONTRACTOR will not be entitled to claim lost profits for any Work not performed.
ARTICLE 12 - TIME FOR COMPLETION, LIQUIDATED DAMAGES AND CHANGE OF THE
CONTRACT TIME.
12.1 Time is of the essence to this contract and the date of beginning and the time for completion of the Work
are essential conditions of the Contract. Therefore, the Work must be commenced on the date specified
in the Notice to Proceed and completed within the time specified for completion of the work.
12.2 CONTRACTOR must proceed with the Work at such rate of progress to ensure full completion within
the Contract Time. It is expressly understood and agreed, by and between CONTRACTOR and City
Manager, that the Contract Time for the completion of the Work described herein is a reasonable time,
taking into consideration the average climatic and economic conditions and other factors prevailing in the
locality of the Work. No extension of time will be granted due conditions that CONTRACTOR knew of
or should have known of before bidding on the project or due to inclement weather, except as provided
in section 12.7.
12.3 If CONTRACTOR fails to complete the Work within the Contract Time, or extension of time granted by
the City Manager, then CONTRACTOR must pay to OWNER the amount of liquidated damages as
specified in the Contract Documents for each calendar day after the scheduled date for completion as
adjusted by written Change Orders that extended the completion date.
12.3.1 These amounts are not penalties but are liquidated damages incurred by OWNER for its inability
to obtain full use of the Project. Liquidated damages are hereby fixed and agreed upon between
the parties, recognizing the impossibility of precise ly ascertaining the amount of damages that will
be sustained as a consequence of such delay, and both parties desiring to obviate any question or
dispute concerning the amount of said damages and the cost and effect of the failure of
CONTRACTOR to complete the Contract on time. The above-stated liquidated damages will
apply separately to each phase of the Project for which a time for completion is given.
12.3.2 City Manager is authorized to deduct the liquidated damages from monies due to
CONTRACTOR for the Work under this Contract. 102 of 118 107
12.4 The Contract Time may only be changed by a written Change Order. Any claim for an extension in the
CONTRACT TIME will be based on written notice delivered to the City Manager and CONSULTANT
within five (5) business days of the occurrence of the event giving rise to the claim and stating the general
nature of the claim including supporting data. All claims for adjustment in the Contract Time will be
evaluated and recommended by CONSULTANT, with final approval by the City Manager. Any change in
the Contract Time resulting from any such claim must be incorporated in a written Change Order.
12.5 All time limits stated in the Contract Documents are of the essence of the Contract.
12.6 No damage claim for delay is allowed and CONTRACTOR’s sole remedy for delay caused by OWNER
will be an extension of time for the period of delay.
12.7 Extensions to the Contract Time for delays caused by the effects of inclement weather will not be granted
unless the weather was unusual for South Florida and could not have been anticipated, the abnormal
weather is documented by records from the national weather service and the abnormal weather is
documented to have had a substantial affected on the construction schedule.
12.8 No Damages for Delay: CONTRACTOR agrees that he will not have any claim for damages due to delay
unless the delay exceeds 6 months, whether individually or cumulatively, and then the damages will be
limited to increased cost of materials that were unanticipated and that would not have been incurred but
for the delay. Other than as set forth above, the only remedy for any delay will be limited to an extension
of time as provided for in Section 12.4 which will be the sole and exclusive remedy for such resulting
delay. Other than as set forth above, CONTRACTOR will not be entitled to an increase in the Contract
Price or payment or compensation of any kind from OWNER for direct, indirect, consequential, impact
or other costs, expenses or damages, including but not limited to, costs of acceleration or inefficiency,
overhead or lost profits, arising because of delay, disruption, interference or hindrance from any cause
whatsoever, whether such delay, disruption, interference or hindrance be reasonable or unreasonable,
foreseeable or unforeseeable, or avoidable or unavoidable.
12.9 CONTRACTOR waives all claims that are not presented to City Manager in writing on or before the
21st day following the date of the event upon which the claim is based.
12.10 Dispute Resolution: If any dispute concerning a question of fact arises under the Contract, other than
termination for default or convenience, CONTRACTOR and the city department responsible for the
administration of the Contract will make a good faith effort to resolve the dispute. If the dispute cannot
be resolved by agreement, then the department with the advice of the City Attorney and CONSULTANT
will rule on the disputed issue and send a written copy of its decision to CONTRACTOR.
CONTRACTOR must comply with such decision and may not delay the project.
ARTICLE 13 – GUARANTEE.
13.1 CONTRACTOR guarantees and unconditionally warrants through either the manufacturer or
CONTRACTOR directly, all materials and equipment furnished and Work performed for patent Defective
Work for a period of one (1) year from the date of Final Acceptance as indicated in CONSULTANT Letter
of Recommendation of Acceptance, if issued, the Certificate of Occupancy, if issued, or the Certificate of
Completion, if issued by City Manager, whichever is applicable and if more than one is applicable, the one
that is issued last, for patent Defective Work,. CONTRACTOR guarantees and unconditionally warrants
through either the manufacturer or CONTRACTOR directly, all materials and equipment furnished and
Work performed for three (3) years from the date of Final Acceptance as indicated in CONSULTANT
Letter of Recommendation of Acceptance, if issued, the Certificate of Occupancy, if issued, or the
Certificate of Completion, if issued by City Manager, whichever is applicable and if more than one is
applicable, the one that is issued last, for lat ent Defective Work. The City Manager will give notice of
observed defects with reasonable promptness. In the event that CONTRACTOR should fail to commence
to correct such Defective Work within ten (10) calendar days after having received written notice o f the
defect, or should CONTRACTOR commence the corrective work, but fail to prosecute the corrective
work continuously and diligently and in accordance with the Contract Documents, applicable law, rules and
regulations, the City Manager may declare an event of default, terminate the Contract in whole or in part
and cause the Defective Work to be removed or corrected and to complete the Work at
CONTRACTOR's expense, and the City Manager will charge CONTRACTOR the cost thereby
incurred. The Performance Bond will remain in full force and effect through the guarantee period.
13.2 The specific warranty periods listed in the Contract Documents, if different from the period of time listed
in Section 13.1, will take precedence over Section 13.1.
13.3 CONTRACTOR must act as agent, on a limited basis for OWNER, at the City Manager’s option, solely
for the follow-up concerning warranty compliance for all items under manufacturer’s
Warranty/Guarantee and for the purpose of completing all forms for Warranty/Guarantee coverage
under this Contract. 103 of 118 108
13.4 In case of default by CONTRACTOR, the City of South Miami may procure the articles or services from
other sources and hold CONTRACTOR responsible for any excess costs occasioned or incurred
thereby.
13.5 The City Manager may withhold acceptance of, or reject items which are found upon examinat ion, not to
meet the specification requirements. Upon written notification of rejection, items must be removed
within five (5) business days by CONTRACTOR at his own expense and redelivered at his expense.
Rejected goods left longer than thirty (30) calendar days will be regarded as abandoned and City Manager
will have the right to dispose of them as its own property and CONTRACTOR thereby waives any claim
to the good or to compensation of any kind. Rejection for Non-Conforming Work or failure to meet
delivery schedules may result in the Contract being found in default.
ARTICLE 14 - PAYMENTS AND COMPLETION.
Payments to Contractor
14.1 CONTRACTOR will not be entitled to any money for any work performed before the issuance of a
Notice to Proceed on the form described in the Contract Documents and the issuance by City Manager
of a “purchase order”, or any other document, does not and will not authorize the commencement of the
Work. At least ten (10) calendar days before each progress payment falls due (but not more often than
once a month), CONTRACTOR must submit to CONSULTANT a partial payment estimate filled out and
signed by CONTRACTOR covering the Work performed during the period covered by the partial
payment estimate and supported by such data as CONSULTANT may reasonably require. All progress
payment applications after the first progress payment must be accompanied by partial releases of lien
executed by all persons, firms and corporations who have furnished labor, services or materials
incorporated into the work during the period of time for which the previous progress payment was made,
releasing such claims and lien rights, if any, of those persons. If payment is requested on the basis of
materials and equipment not incorporated in the Work but delivered and suitably stored at or near site,
the partial payment estimate must also be accompanied by such supporting data, satisfactory to the City
Manager, which establishes OWNER’s title to the material and equipment as well as certificates of
insurance providing coverage for 100% of the value of said material and equipment covering the material
and equipment from all casualties as well as theft, vandalism, fire and flood. CONTRACTOR must
replace at its expense any stored materials paid for which are either damaged or stolen before
installation. CONSULTANT will within ten (10) calendar days after receipt of each partial payment
estimate, either certifying in writing its approval of payment and present the partial payment estimate to
the City Manager, or return the partial payment estimate to CONTRACTOR, indicating in writing his
reasons for refusing to approve payment. In the latter case, CONTRACTOR may make the necessary
corrections and resubmit the partial payment estimate. OWNER, will within thirty (30) calendar days of
presentation to it of any approved partial payment estimate, pay CONTRACTOR a progress payment on
the basis of the approved partial payment estimate. City Manager may retain ten (10%) percent of the
amount of each payment until Final Completion and Acceptance of all Work covered by the Contract
Documents. Any interest earned on the retainage will accrue to the benefit of OWNER.
14.2 CONTRACTOR, before it receives final payment, must deliver to the City Manager a Contractor’s Final
Payment Affidavit as set forth in the Florida Construction Lien Statute as well as final releases of lien
executed by all persons who have performed or furnished labor, services or materials, directly or
indirectly, which was incorporated into the Work. If any person refuses to provide such a release or
provides a conditional release, the City Manager will have the right to issue a joint check made payable to
CONTRACTOR and such person.
14.3 Punch list
City Manager and CONTRACTOR will develop a single list of items required to render complete,
satisfactory, and acceptable the construction services purchased by the local governmental entity. Within
30 calendar days after reaching substantial completion of the Project, City Manager will prepare a punch
list of items that need to be completed and, within 5 days after the list of items has been developed and
reviewed, the City Manager will deliver the punch list to CONTRACTOR. If the Project relates to more
than one building or structure, or involves a multiphase project, the City Manager will prepare a separate
punch list for each building and structure and if it is a multiphase project, for each phase, within 30 days of
substantial completion of such building, structure and phase. [See Sec. 255.07, Fla. Stat.]
The final contract completion date may not be less than 30 days after the delivery of the list of items. If
the list is not timely delivered to CONTRACTOR, the contract time for completion must be extended by
the number of days OWNER exceeded the required delivery date.
Contractor's Warranty of Title 104 of 118 109
14.3 CONTRACTOR warrants and guarantees that title to all Work, materials and equipment covered by an
Application for Payment whether the Work, material or equipment is incorporated in the Project or not,
will have passed to OWNER prior to the making of the Application for Payment, free and clear of all
liens, claims, security interest and encumbrances (hereafter in these General Conditions referred to as
"Liens"); and that no Work, materials or equipment, covered by an Application for Pay ment, will have
been acquired by CONTRACTOR or by any other person performing the Work at the site or furnishing
materials and equipment for the Project, under or pursuant to an agreement under which an interest
therein or encumbrance thereon is retained by the seller or otherwise imposed by CONTRACTOR or
such other person.
Approval of Payment
14.4 CONSULTANT’s approval of any payment requested in an Application for Payment will constitute a
representation by him to OWNER, based on CONSULTANT’s on site observations of the Work in
progress as an experienced professional and on his review of the Application for Payment and supporting
data, that the Work has progressed to the point indicated in the Application for Payment; that, to the
best his knowledge, information and belief, the quality of the Work is in accordance with the Contract
Documents (subject to an evaluation of the Work as a functioning Project upon substantial completion as
defined in Article 1, to the results of any subsequent tests called for in the Contract Documents and any
qualifications stated in his approval); and that CONTRACTOR is entitled to payment of the amount
approved. However, the approval of such payment does not mean and may not imply that
CONSULTANT made exhaustive or continuous on-site observations to check the quality or the quantity
of the Work, or that he has reviewed the means, methods, techniques, sequences and procedures of
construction or that he has made any examination to ascertain how or for what purpose
CONTRACTOR has used the moneys paid or to be paid to him, or that title to any Work, materials, or
equipment has passed to OWNER free and clear of any liens.
14.5 CONTRACTOR will not be entitled to be paid unless:
(a) the labor and materials listed on a payment application have been used in the construction of this
Work or, as to materials included in the request for payment that have not yet been incorporated into
the construction, such materials are on the site or stored at an approved location, and
(b) payment received from the last payment application has been used to fully pay for all the laborers,
subcontractors and materials reflected in that request, other than amounts that are in dispute and that
are listed in the payment application with reasonable clarity as to the reason for withholding payment with
the name, addresses and telephone number of the person whose request is being withheld. The payment
application must contain the forgoing statement and the statement must be certified by CONTRACTOR
as being true.
In the event that CONTRACTOR withholds payment from a Subcontractor or Supplier, the same amount
of money will be withheld from CONTRACTOR’s payment until the issue is resolved by written
agreement between them and then a joint check will be made payable to the person in question and
CONTRACTOR in accordance with the settlement agreement, otherwise the money will be held by
OWNER until a judgment is entered in favor of CONTRACTOR or the person, in which case the money
will be paid according with said judgment. Nothing contained herein will indicate an intent to benefit any
third persons who are not signatories to the Contract.
14.6 CONSULTANT may refuse to approve the whole or any part of any payment if, in its opinion, it is unable
to make such representations to OWNER as required this Section 14. It may also refuse to approve any
payment, or it may void any prior payment application certification because of subsequently discovered
evidence or the results of subsequent inspection or tests to such extent as may be necessary in its
opinion to protect OWNER from loss because:
14.6.1 of Defective Work, or completed Work has been damaged requiring correction or replacement,
14.6.2 the Work for which payment is requested cannot be verified,
14.6.3 claims of Liens have been filed or received, or there is reasonable evidence indicating the probable
filing or receipt thereof,
14.6.4 the Contract Price has been reduced because of modifications,
14.6.5 OWNER has correct Defective Work or completed the Work in accordance with Article 13.
14.6.6 of unsatisfactory prosecution of the Work, including failure to clean up as required by paragraphs
6.29 and 6.30,
14.6.7 of persistent failure to cooperate with other contractors on the Project and persistent failure to
carry out the Work in accordance with the Contract Documents,
14.6.8 of liquidated damages payable by CONTRACTOR, or 105 of 118 110
14.6.9 of any other violation of, or failure to comply with provisions of the Contract Documents.
14.7 Prior to Final Acceptance, City Manager, with the approval of CONSULTANT, may use any completed or
substantially completed portions of the Work provided such use does not interfere with
CONTRACTOR’s completion of the Work. Such use will not constitute an acceptance of such portions
of the Work.
14.8 The City Manager has the right to enter the premises where the Work is being performed for the
purpose of doing Work not covered by the Contract Documents. This provision may not be construed
as relieving CONTRACTOR of the sole responsibility for the care and protection of the Work, or the
restoration of any damaged Work except such as may be caused by agents or employees of OWNER.
14.9 Upon completion and acceptance of the Work CONSULTANT will issue a Certificate attached to the
Final Application for Payment that the Work has been accepted by it under the conditions of the
Contract Documents. The entire balance found to be due CONTRACTOR, including the retained
percentages, but except such sums as may be lawfully retained by OWNER, will be paid to
CONTRACTOR within thirty (30) calendar days of completion and acceptance of the Work.
14.10 Upon The awarded CONTRACTOR will be strongly encouraged to register as an ePayables Vendor with
OWNER. The Bank of America ePayables Solution is an automated card payment process that shifts
accounts payable disbursements to corporate purchasing cards. ePayables, streamline the process of
making payments to your organization going forward, City Manager will provide CONTRACTOR with a
credit card account number to keep on file. This card has unique security features, with $0 of available
funds until an invoice is approved for payment. After an invoice has received proper and complete
approval, an electronic remittance advice will be sent via e-mail, or fax, which notifies CONTRACTOR
that the funds have been transferred in to the account linked to the card for the amount listed on the
invoice and/or remittance email. Please refer to the ePayables Questions & Answers Form contained in
this RFP or contact OWNER’s Finance department at (305) 663-6343 with any questions.
Acceptance of Final Payment as Release
14.11 The Acceptance by CONTRACTOR of Final Payment will be and will operate as a release to OWNER
and a waiver of all claims and all liability to CONTRACTOR other than claims previously filed and
unresolved. The waiver includes all things done or furnished in connection with the Work and for every
act and neglect of OWNER and others relating to or arising out of this Work. Any payment, however,
final or otherwise, will not release CONTRACTOR or its sureties from any obligations under the
Contract Documents or the Performance Bond and Payment Bonds.
14.12 CONSULTANT may void any certification of Substantial Completion or Final Completion of the Work as
may be necessary in his opinion to protect OWNER from loss if he determines, because of subsequently
discovered evidence or the results of subsequent inspection or tests, that:
14.12.1 the Work is defective, or that the completed Work has been damaged due to the fault of
CONTRACTOR or any individual or entity operating under or through it requiring correction
or replacement to the extent that the project is no longer Substantially Comple ted, or in the
case of Final Completion certification, is no longer Finally Competed.
14.12.2 the Work necessary to be completed for the purpose of certifying the work as being
Substantially Completed or Finally Completed cannot be verified,
14.12.3 claims or Liens have been filed or received, or there is reasonable evidence indicating the
probable filing or receipt thereof that, if valid and paid, would reduce the amount owing to
CONTRACTOR BY 20% in the case of Substantial Completion and 5% in the case of Final
Completion.
14.12.4 there is Defective Work the value of which, if deducted from the contract price would reduce
the amount owing to CONTRACTOR BY 20% in the case of Substantial Completion and 5% in
the case of Final Completion.
14.13 If CONSULTANT de-certifies any portion of the Work that was certified (“Initial Certification”) by
CONSULTANT, CONTRACTOR must repay to OWNER any money paid as a result of said Initial
Certification being issued which will be paid only when the decertified work is re-certified.
ARTICLE 15 – SUSPENSION OF WORK AND TERMINATION.
15.1 The City Manager may, at any time and without cause, suspend the Work or any portion t hereof for a
period of not more than ninety (90) calendar days by notice in writing to CONTRACTOR and
CONSULTANT, which will fix the date on which Work will be resumed. Except for the City Manager’s
exercising his right to suspend or terminate the contract pursuant to Article 6, Section 6.21 due to a state
of emergency, CONTRACTOR will be allowed an increase in the Contract Price or an extension of the
Contract Time, or both, directly attributable to any suspension and if a claim is timely made and if it is
allowed under the terms of Articles 11 or Article 12. 106 of 118 111
City May Terminate
15.2 If CONTRACTOR is adjudged bankrupt or insolvent, or if he makes a general assignment for the benefit
of its creditors, or if a trustee or receiver is appointed for CONTRACTOR or for any its property, or if
he files a petition to take advantage of any debtor's act, or to reorganize under bankruptcy or similar laws,
or if he repeatedly fails to supply sufficient skilled workmen or suitable materials or equipment, or if he
repeatedly fails to make prompt payments to Subcontractors or for labor, materials or equipment or he
disregards laws, ordinances, rules, regulations or orders of any public body having jurisdiction, or if he
disregards the authority of CONSULTANT, or if he otherwise violates any provision of, the Contract
Documents, then the City Manager may, without prejudice to any other right or remedy and after giving
CONTRACTOR and the Surety seven (7) calendar days written notice, terminate the services of
CONTRACTOR and take possession of the Project and of all materials, equipment, tools, construction
equipment and machinery thereon owned by CONTRACTOR, and finish the Work by whatever method
it may deem expedient. In such case CONTRACTOR will not be entitled to receive any further payment
until the Work is finished. If the unpaid balance of the Contract Price exceeds the direct and indirect
costs of completing the Project, including compensation for additional professional services, such excess
will be paid to CONTRACTOR. If such costs exceed such unpaid balance, CONTRACTOR or the
Surety on the Performance Bond must pay the difference to OWNER. Such costs incurred by OWNER
will be determined by CONSULTANT and incorporated in a Change Order.
If after termination of CONTRACTOR under this Section, it is determined by a court of competent
jurisdiction for any reason that CONTRACTOR was not in default, the rights and obligations of OWNER
and CONTRACTOR will be the same as if the termination had been issued pursuant to Section 15.5
15.3 Where CONTRACTOR'S services have been so terminated by the City Manager said termination will not
affect any rights of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any
retention or payment of moneys by OWNER due CONTRACTOR will not release CONTRACTOR
from liability.
15.4 Upon seven (7) calendar days’ written notice to CONTRACTOR and CONSULTANT, the City Manager
may, without cause and without prejudice to any other right or remedy, elect to terminate the Con tract
for the convenience of OWNER. In such case, CONTRACTOR will be paid for all Work executed and
accepted by the City Manager as of the date of the termination, minus any deduction for damage or
Defective Work. No payment will be made for profit for Work which has not been performed.
15.4A OWNER reserves the right in the event CONTRACTOR cannot provide an item(s) or service(s) in a
timely manner as requested, to obtain the good and/or services from other sources and deducting the
cost from the Contract Price without violating the intent of the Contract.
Removal of Equipment
15.5 In the case of termination of this Contract before completion for any cause whatever, CONTRACTOR, if
notified to do so by the City Manager, must promptly remove any part or all of its equipment and supplies
from the property of OWNER. Should CONTRACTOR not remove such equipment and supplies, the
City Manager will have the right to remove them at the expense of CONTRACTOR and
CONTRACTOR agrees that OWNER will not be liable for loss or damage to such equipment or
supplies. Equipment and supplies will not be construed to include such items for which CONTRACTOR
has been paid in whole or in part.
Contractor May Stop Work or Terminate
15.6 If, through no act or fault of CONTRACTOR, the Work is suspended for a period of more than ninety
(90) calendar days by the City Manager or by order of other public authority, or under an order of court
or CONSULTANT fails to act on any Application for Payment within thirty (30) calendar days after it is
submitted, or OWNER fails to pay CONTRACTOR any sum approved by CONSULTANT, within thirty
(30) calendar days of its approval, and presentation, then CONTRACTOR may, upon twenty (20)
calendar days written notice to the City Manager and CONSULTANT, terminate the Contract. The City
Manager may remedy the delay or neglect within the twenty (20) calendar days. If timely remedied by
OWNER, the Contract will not be considered terminated. In lieu of terminating the Contract, if
CONSULTANT has failed to act on an Application for Payment or OWNER has failed to make any
payment as afore said, CONTRACTOR may upon ten (10) calendar days’ notice to the City Manager and
CONSULTANT stop the Work until it has been paid all amounts then due.
Indemnification of Independent Consultant. 107 of 118 112
15.7 CONTRACTOR and the City Manager hereby acknowledges that if CONSULTANT is an independent
contractor of OWNER, CONSULTANT may be reluctant to rule on any disputes concerning the
Contract Documents or on the performance of CONTRACTOR or OWNER pursuant to the terms of
the Contract Documents. Therefore, OWNER, at CONSULTANT’s request, agrees to provide
CONSULTANT with a written indemnification and hold harmless agreement to indemnify and hold
CONSULTANT harmless as to any decision in this regard before CONSULTANT makes an
interpretation, de-certifies a payment application, decertifies Substantial Completion, decertifies Final
Completion, certifies an event of default, or approves any action which requires the approval of
CONSULTANT.
ARTICLE 16 – MISCELLANEOUS.
16.1 Whenever any provision of the Contract Documents requires the giving of written notice it will be
deemed to have been validly given if delivered in person to the individual or to a member of the firm or
to an officer of the corporation for whom it is intended, or if delivered at or sent by registered or
certified mail, postage prepaid, to the last known business address.
16.2 The Contract Documents are the property of OWNER. CONTRACTOR and CONSULTANT will have
the right to keep one record set of the Contract Documents upon completion of the Project.
16.3 The duties and obligations imposed by these General Conditions, Special Conditions and Supplementary
Conditions, if any, and the rights and remedies available hereunder, and, in particular but without
limitation, the warranties, guarantees and obligations imposed upon CONTRACTOR by the Contract
Documents and the rights and remedies available to OWNER and CONSULTANT thereunder, will be in
addition to, and will not be construed in any way as a limitation of, any rights and remedies available by
law, by special guarantee or by other provisions of the Contract Documents.
16.4 Should OWNER or CONTRACTOR suffer injury or damage to its person or property because of any
error, omission, or act of the other or of any of their employees or agents or others for whose acts they
are legally liable, claim must be made in writing to the other party within twenty-one (21) calendar days of
the first observance of such injury or damage.
ARTICLE 17 - WAIVER OF JURY TRIAL.
17.1 OWNER and CONTRACTOR knowingly, irrevocably voluntarily and intentionally waive any right either
may have to a trial by jury in State or Federal Court proceedings in respect to any action, proceeding,
lawsuit or counterclaim arising out of the Contract Documents or the performance of the Work
thereunder.
ARTICLE 18 - ATTORNEYS FEES JURISDICTION / VENUE / GOVERNING LAW.
18.1 The Contract will be construed in accordance with and governed by the law of the State of Florida.
18.2 The parties submit to the jurisdiction of any court of competent jurisdiction in Florida regarding any claim
or action arising out of or relating to the Contract or Contract Documents. The parties agree that venue
of any action to enforce the Contract is in Miami-Dade County, Florida.
18.3 Except as may be otherwise provided in the Contract Documents, all claims, counterclaims, disputes and
other matters in question between OWNER and CONTRACTOR arising out of or relating to this
Contract or the breach thereof, will be decided in a court of competent jurisdiction within the State of
Florida.
ARTICLE 19 - PROJECT RECORDS.
19.1 The City Manager has the right to inspect and copy during regular business hours at OWNER’S expense,
the books and records and accounts of CONTRACTOR which relate in any way to the Project, and to
any claim for additional compensation made by CONTRACTOR, and to conduct an audit of the financial
and accounting records of CONTRACTOR which relate to the Project. CONTRACTOR will retain and
make available to City Manager all such books and records and accounts, financial or otherwise, which
relate to the Project and to any claim for a period of three (3) years following final completion of the
Project. During the Project and the three (3) year period following final completion of the Project,
CONTRACTOR must provide City Manager access to its books and records upon five (5) business day’s
written notice.
19.2 CONTRACTOR and all of its subcontractors are required to comply with the public records law
(s.119.0701) while providing services on behalf of OWNER and CONTRACTOR, under such conditions,
must incorporate this paragraph in all of its subcontracts for this Project. CONTRACTOR and its
subcontractors are specifically required to: (a) Keep and maintain public records required by the public
agency to perform the service; (b) Upon request from the public agency's custodian of public records, 108 of 118 113
provide the public agency with a copy of the requested records or allow the records to be in spected or
copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as
otherwise provided by law; (c) Ensure that public records that are exempt or confidential and exempt
from public records disclosure requirements are not disclosed except as authorized by law for the
duration of the contract term and following completion of the contract if the contractor does not transfer
the records to the public agency; and (d) Upon completion of the contract, transfer, at no cost, to the
public agency all public records in possession of the contractor or keep and maintain public records
required by the public agency to perform the service. If the contractor transfers all public records to the
public agency upon completion of the contract, the contractor must destroy any duplicate public records
that are exempt or confidential and exempt from public records disclosure requirements. If the
contractor keeps and maintains public records upon completion of the contract, the contractor must
meet all applicable requirements for retaining public records. All records stored electronically must be
provided to the public agency, upon request from the public agency's custodian of public records, in a
format that is compatible with the information technology systems of the public agency.
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE
APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE
CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS
RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN
OF PUBLIC RECORDS AT 305-663-6340; E-mail:
npayne@southmiamifl.gov; 6130 Sunset Drive, South Miami, FL 33143.
19.3 If CONTRACTOR or its subcontractor does not comply with a public records request, the C ity Manager
has the right to enforce this contract provision by specific performance and the person who violates this
provision is liable to OWNER for its costs of enforcing this provision, including attorney fees incurred in
all proceedings, whether administrative or civil court and in all appellate proceedings.
ARTICLE 20 – SEVERABILITY.
20.1 If any provision of the Contract or the application thereof to any person or situation is, to any extent,
held invalid or unenforceable, the remainder of the Contract, and the application of such provisions to
persons or situations other than those as to which it is held invalid or unenforceable will not be affected
thereby, and will continue in full force and effect, and be enforced to the fullest extent permitted by law.
ARTICLE 21 – INDEPENDENT CONTRACTOR.
21.1 CONTRACTOR is an independent CONTRACTOR under the Contract. Services provided by
CONTRACTOR must be by employees of CONTRACTOR and subject to supervision by
CONTRACTOR, and not as officers, employees, or agents of OWNER. Personnel policies, tax
responsibilities, social security and health insurance, employee benefits, purchasing policies and other
similar administrative procedures, applicable to services rendered under the Contract must be those of
CONTRACTOR.
ARTICLE 22 – ASSIGNMENT.
22.1 CONTRACTOR may not transfer or assign any of its rights or duties, obligations and responsibilities
arising under the terms, conditions and provisions of this Contract without prior written consent of the
City Manager. The City Manager will not unreasonably withhold and/or delay OWNER’S consent to the
assignment of CONTRACTOR’s rights. The City Manager may, in the manager’s sole and absolute
discretion, refuse to allow CONTRACTOR to assign its duties, obligations and responsibilities. In any
event, OWNER is not obligated to consent to such assignment unless CONTRACTOR remains jointly
and severally liable for any breach of the Agreement by the assignee, the assignee meets all of OWNER’s
requirements to the City Manager’s sole satisfaction and the assignee executes all of the Contract
Documents that were required to be executed by CONTRACTOR.
ARTICLE 23 – FORCE MAJEURE.
23.1 Neither party may hold the other responsible for damages or for delays in performance caused by force
majeure, acts of God, or other acts or circumstances beyond the control of a party or that could not have
been reasonably foreseen, prevented or avoided. For this purpose, such acts or circumstances include, but
not limited to, weather conditions affecting performance, floods, epidemics, war, riots, strikes, lockouts, or
other industrial disturbances, or protest demonstrations. Should such acts or circumstances occur, the
109 of 118 114
parties will use their best efforts to overcome the difficulties and to resume the work as soon as reasonably
possible.
IN WITNESS WHEREOF, the parties hereto have executed the General Conditions to acknowledge
their inclusion as part of the Contract Documents on this ____ day of ________________, 20___,
CONTRACTOR: ___________________________
Signature: ___________________________
Print Signatory’s Name: ___________________________
Title of Signatory: ___________________________
ATTESTED: OWNER: CITY OF SOUTH MIAMI
Signature: _______________________ Signature: ________________________________
Nkenga A. Payne Shari Kamali
City Clerk City Manager
Read and Approved as to Form, Language,
Legality, and Execution Thereof:
Signature: ________________________
City Attorney
110 of 118 115
EXHIBIT 7
Supplementary Conditions
CONSTRUCTION CONTRACT
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
A. Consultant: In accordance with ARTICLE 1 of the General Conditions the consultant (CONSULTANT)
is defined as the person identified as the consultant in the Supplementary Conditions or if none, then
OWNER’s designated representative as identified in the Supplementary Conditions. CONSULTANT’s, if
any, and OWNER’s Designated Representative’s name, address, telephone number and facsimile number
are as follows:
Consultant: STANTEC
901 Ponce de Leon
Suite 900
Coral Gables, FL 33134
Ph: 305/445-2900
Fax: 305/445-3334
B. Termination or Substitution of Consultant: Nothing herein will prevent the City Manager from terminating
the services of CONSULTANT or from substituting another “person” to act as CONSULTANT.
C. Plans for Construction: The successful CONTRACTOR will be furn ished ___________ sets of Contract
Documents without charge. Any additional copies required will be furnished to CONTRACTOR at a cost
to CONTRACTOR equal to the reproduction cost.
D. The Scope of Services, also referred to as the Work in the contract documen ts, is as set forth in the RFP
and in the attached EXHIBIT 1, Attachments A, B & C to the RFP and if there is a conflict the
attached Exhibit will take precedence.
E. Contractor must comply with the insurance and indemnification requirements is set forth in t he RFP and in
the document set forth in the attached EXHIBIT 2 to the RFP and if there is a conflict the attached
Exhibit will take precedence.
F. The Work must be completed in 120 calendar days unless a shorter time is set forth in the Contract and
in such event the Contract will take precedent notwithstanding any provision in the General Conditions to
the Contract that may be to the contrary.
G. CONTRACTOR has reviewed and checked all information and data with respect to existing Underground
Facilities or conditions at or contiguous to the site and assumes responsibility for the accurate location of
all Underground Facilities and conditions that may affect the Work. It is agreed by the parties th at no
additional examinations, investigations, explorations, tests, reports or similar information or data in respect
to any Underground Facilities or conditions are, or will be, required by CONTRACTOR to perform and
furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms
and conditions of the Contract Documents.
H. CONTRACTOR has given the City Manager written notice of all conflicts, errors or discrepancies that it
has discovered in the Contract Documents and, if any conflicts, errors or discrepancies have been found
and notice given, CONTRACTOR represents, by submitting its proposal to the City Manager, that
CONTRACTOR has received sufficient notice of the resolution thereof from the City Manager, that such
resolution is acceptable to CONTRACTOR and that CONTRACTOR waives any claim regarding the
conflicts, errors or discrepancies.
I.
IN WITNESS WHEREOF, the parties hereto have executed the Supplementary Conditions to
acknowledge their inclusion as part of the Contract on this ____ day of ________________, 20___,
CONTRACTOR: ______________________________
Signature: ______________________________
Print Signatory’s Name:_______________________________
Title of Signatory: ______________________________
111 of 118 116
ATTESTED: OWNER: CITY OF SOUTH MIAMI
Signature: _______________________ Signature: __________________________
Nkenga A. Payne Shari Kamali
City Clerk City Manager
Read and Approved as to Form, Language,
Legality, and Execution Thereof:
Signature: ________________________
City Attorney
112 of 118 117
EXHIBIT 8
FORM OF PERFORMANCE BOND
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
(Required as a Condition of Award and Prior to the Contractor Receiving a Notice to
Proceed. Not Required with Submittal)
KNOW ALL MEN BY THESE PRESENTS:
That, pursuant to the requirements of Florida Statute 255.05, we,
________________________________, whose business address is _______________ and whose telephone
number is __________________, as Principal (hereinafter referred to as “Contractor”), and
_____________________________________________, whose business address is _______________ and
whose telephone number is __________________, as Surety, are bound to the City of South Miami whose
business address is _______________ and whose telephone number is __________________, [[and Miami -Dade
County whose business address is _________________________ and wh ose telephone number is
_______________________]]as Obligee, (hereinafter referred to as “City”) in the amount of
________________________ Dollars ($_________________) for the payment whereof Contractor and Surety
bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally.
WHEREAS, Contractor has entered into a Contract, for the SUNSET DRIVE MODIFICATIONS
RFP #PW2020-15 project awarded on the ___________ day of ___________________, 20___, under
Contract Number ______ by the City for the construction of ________________________________ (brief
description of the Work) in accordance with drawings (plans) and specifications prepared by _______________.
which Contract is hereby made a part hereof by reference, and is hereafter referred to as the “Contract”;
THE CONDITION OF THIS BOND is that the Contractor:
Fully performs the Contract between the Contractor and the City for the SUNSET DRIVE ROADWAY
& LANDSCAPING MODIFICATIONS RFP #PW2020-19 within 120 calendar days after the date of
Contract commencement as specified in the Notice to Proceed and in the manner prescribed in the Contract; and
1. Indemnifies and pays City all losses, damages (specifically including, but not limited to, damages for
delay and other foreseeable consequential damages), expenses, costs and attorney’s fees, including
attorney’s fees incurred in appellate proceedings, mediation and arbitration, if any, that City sustains
because of default by Contractor under the Contract or caused by or arising out of any action or
proceeding to enforce the Contract or this Bond; and
2. Upon notification by the City, correct any and all patently defective or faulty Work or materials that
appear within one (1) year from the date of Final Acceptance as indicated in th e CONSULTANT
Letter of Recommendation of Acceptance, if issued, the Certificate of Occupancy, if issued, or the
Certificate of Completion, if issued by the City, whichever is applicable and if more than one is
applicable, the one that is issued last, for patent Defective Work, and correct any and all latent defects
that are discovered before the expiration of the third (3rd) year following the date of Final Acceptance
as indicated in the CONSULTANT Letter of Recommendation of Acceptance, if issued, the Cert ificate
of Occupancy, if issued, or the Certificate of Completion, if issued by the City, whichever is applicable
and if more than one is applicable, the one that is issued last; and
3. Performs the guarantee of all Work and materials furnished under the Contract for the time specified
in the Contract.
If all the forgoing conditions are met, then this Bond is void, otherwise it will remain in full force and effect.
Whenever Contractor is, and declared by the City to be, in default for failing to perform in strict accordance
with any of the terms of the Contract, the Surety must promptly remedy the default as well as perform in the
following manner:
Complete the Contract in accordance with the Contract’s terms and conditions provided the City
makes available, as Work progresses, that portion of the Contract Price that has not already been paid
to, or on behalf of, the Contractor. The City will not be required to pay any more than the amount of
the Contract Price. The surety will not be obligated to pay more than the maximum amount for
which the Surety may be liable as set forth in the first paragraph of this bond. If the Surety fails to
commence the Work within thirty (30) days of receipt of the City’s declaration of a default or if the
Surety fails to man the job with sufficient forces, or suspends the Work, for more than thirty (30)
days, either consecutive or in combination with separate occasions, the City has the option, in the
City’s sole discretion, and without waiving its right to any other remedy or dam ages provided for by
this bond, to complete the Work with other forces and the Surety must pay for the cost to complete 113 of 118 118
the Work. The term “balance of the Contract Price” as used in this paragraph, means the total
amount payable by City to Contractor under the Contract and any amendments thereto, less the
amount properly paid by the City to the Contractor.
No right of action may accrue on this Bond to or for the use of any person or corporation other than the
City named herein.
The Surety hereby waives notice of and agrees that any changes in or under the Contract Documents and
compliance or noncompliance with any formalities connected with the Contract will not affect the Surety’s
obligation under this Bond.
IN WITNESS WHEREOF, the above bonded parties have executed this instrument under their
several seals on this ___________ day of _____________________, 20___, the name and the corporate seal
of each corporate party being hereto affixed and these presents being duly signed by its undersigned
representative.
IN PRESENCE OF:
______________________________ ____________________________________
(Individual, President, Managing Member or General Partner, etc.)
______________________________ ____________________________________
(Business Address)
____________________________________
(City/State/Zip)
____________________________________
(Business Telephone)
OR ____________________________________
(Corporate Name)
ATTEST: _______________________________
(President)
__________________________________ ____________________________________
Secretary (Business Address)
____________________________________
(City/State/Zip)
____________________________________
(Business Telephone)
IN THE PRESENCE OF: __________________INSURANCE COMPANY:
__________________________________ BY: ____________________________(SEAL) (Agent
and Attorney-in-fact Signature)
__________________________________ ____________________________________
(Business Address)
____________________________________
(City/State/Zip
____________________________________
(Business Telephone)
STATE OF FLORIDA )
)
COUNTY OF MIAMI-DADE )
On this, the ________ day of __________________, 20___, before me, the undersigned notary public of the State of
Florida, the foregoing performance bond was acknowledged by _____________________________ (Corporate Officer),
_________________________________ (Title), of ___________________ (Name of Corporation), a
_____________________ (State of Incorporation) corporation, on behalf of the corporation.
WITNESS my hand and official seal. _______________________________________
Notary Public, State of Florida
NOTARY PUBLIC:
SEAL OF OFFICE: ________________________________
(Name of Notary Public: Print, Stamp
or Type as commissioned.)
____ Personally known to me, or
____ Personal identification: _________________________
Type of Identification Produced
____ Did take an oath, or____ Did Not take an oath.
114 of 118 119
EXHIBIT 9
FORM OF PAYMENT BOND
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
(Required as a Condition of Award and Prior to the Contractor Receiving a Notice to
Proceed. Not Required with Submittal)
KNOW ALL MEN BY THESE PRESENTS:
That, pursuant to the requirements of Florida Statute 255.01, et seq., Florida Statutes, we,
_______________________________________, whose business address is _______________ and whose
telephone number is _____________,as Principal, (hereinafter referred to as “Contractor”), and
________________________________, whose business address is _______________ and whose telephone
number is __________________, as Surety, are bound to the City of South Miami, whose business address is
_______________ and whose telephone number is __________________, [[and Miami-Dade County whose
business address is _________________________ and whose telephone number is
_______________________]]as Obligee, (hereinafter referred to as “City”) in the amount of
_____________________________Dollars ($_________________) for the payment whereof Contractor and
Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally.
WHEREAS, Contractor has, by written agreement, entered into a Contract for the SUNSET DRIVE
ROADWAY & LANDSCAPING MODIFICATIONS RFP #PW2020-19, awarded on the ___________
day of ___________________, 20___, under Contract Number ________ for the construction of
________________________________(brief description of the Work) by the City in accordance with
drawings (plans) and specifications, if any, prepared by ____________________ which Contract is hereby made a
part hereof by reference and is hereafter referred to as the “Contract”;
THE CONDITION OF THIS BOND is that if the Contractor:
1. Promptly performs the construction work in the time and manner prescribed in the
Contract; and
2. Promptly makes payments to all claimants, as defined in Section 255.05, Florida Statutes,
supplying Contractor with labor, materials, or supplies, used directly or indirectly by Contr actor
in the prosecution of the work provided for in the Contract; and
3. Pays City all losses, damages, expenses, costs, and attorney’s fees, including those incurred in
any appellate, mediation or arbitration proceedings, if any, that Owner sustains because of a
default by Contractor under the Contract; and
4. Performs the guarantee of all work and materials furnished under the contract for the time
specified in the contract, then this obligation will be void; otherwise, it will remain in full force
and effect.
Any action instituted by a claimant under this bond for payment must be in accordance with the notice
and time limitation provisions in Section 255.05(2), Florida Statutes.
The Surety hereby waives notice of and agrees that any changes in or under the Co ntract
Documents and compliance or noncompliance with any formalities connected with the Contract will not
affect the Surety’s obligation under this Bond.
IN WITNESS WHEREOF, the above bonded parties have executed this instrument under their
several seals on this ___________ day of _____________________, 20___, the name and the corporate seal
of each corporate party being hereto affixed and these presents being duly signed by its undersigned
representative.
IN PRESENCE OF:
______________________________ ____________________________________
(Individual, President, Managing Member or General Partner, etc.)
______________________________ ____________________________________
(Business Address)
____________________________________
(City/State/Zip)
____________________________________
(Business Telephone)
OR ____________________________________ 115 of 118 120
(Corporate Name)
ATTEST: _______________________________
(President)
__________________________________ ____________________________________
Secretary (Business Address)
____________________________________
(City/State/Zip)
____________________________________
(Business Telephone)
IN THE PRESENCE OF: __________________INSURANCE COMPANY:
__________________________________ BY: ____________________________(SEAL)
(Agent and Attorney-in-fact Signature)
__________________________________ ____________________________________
(Business Address)
____________________________________
(City/State/Zip
____________________________________
(Business Telephone)
STATE OF FLORIDA )
)
COUNTY OF MIAMI-DADE )
On this, the ________ day of __________________, 20___, before me appeared ____________________________
who is the _________________________________ (Title), of ___________________ (Name of legal entity), a
_____________________ (State of Incorporation) company or partnership, on behalf of the corporation and who is
personally known by me or who provided me with the following type of identification ____________________ and who took
an oath or affirmed that he/she is the person who signed the foregoing payment bond.
WITNESS my hand and official seal. _______________________________________
Notary Public, State of Florida
NOTARY PUBLIC:
SEAL ________________________________
(Name of Notary Public: Print, Stamp
or Type as commissioned.)
*Power of Attorney must be attached.
END OF SECTION
116 of 118 121
EXHIBIT 10
City of South Miami Bid Protest Procedures
RESOLUTION OF PROTESTED SOLICITATIONS AND AWARDS
(FORMAL PROCEDURE)
SUNSET DRIVE ROADWAY & LANDSCAPING MODIFICATIONS
RFP #PW2020-19
The following procedures will be used for resolution of protested solicitations and awards. The word
“bid”, as well as all of its derivations, shall mean a response to a solicitation, including requests for
proposals, requests for a letter of interest and requests for qualifications.
(a) Notice of Intent to Protest. Any actual or prospective bidder who perceives itself to be
aggrieved in connection with any formal solicitation or who intends to contest or object to any bid
specifications or any bid solicitation shall file a written notice of intent to file a protest with the City
Clerk’s office within three calendar days prior to the date set for opening of bids. A notice of intent to
file a protest is considered filed when received by the City Clerk’s office by e-mail or, if hand delivered,
when stamped with the City Clerk’s receipt stamp containing the date and time of receipt of a notice of
intent to file a protest. Any actual responsive and responsible bidder who perceives itself to be
aggrieved in connection with the recommended award of a contract and who wishes to protest the
award, shall file a written notice of intent to file a protest with the City Clerk’s office within three
calendar days after the City Commission meeting at which the recommendation is considered for action.
A notice of intent to file a protest is considered filed when received by the City Clerk’s office by e-mail
or, if hand delivered, when stamped with the City Clerk’s receipt stamp containing the date and time of
receipt.
(b) Protest of solicitation. A protest of the solicitation or award must be in writing (“Protest
Letter”) and submitted to the City Clerk’s office within five calendar days after the date of the filing of
the notice of intent to file a protest. The Protest Letter is considered filed when the Protest Letter and
the required filing fee of $1,000 are both timely received by the City Clerk’s office. In order for the
Protest Letter and filing fee to be considered timely delivered by hand delivery, the date stamp of the
Clerk’s office must appear on the original Protest Letter and/or a copy of the Protest Letter and the
date stamp must also appear on a copy of the check issued for the payment of the filing fee, or, if
payment is made in cash, a receipt must be issued by the Clerk’s office reflecting the date of receipt of
the payment. While the Clerk may accept the Protest Letter by email, the Protest Letter shall not be
considered to be timely received until and unless the required filing fee of $1,000 is received by the City
Clerk’s office and, if payment is in cash, a receipt is issued with the date of the receipt of payment, or if
payment is by check, a copy of the check is stamped by the Clerk with the date stamp of the Clerk’s
office showing the date of receipt. The Protest Letter shall state with particularity the specific facts and
law upon which the protest is based, it shall describe and attach all pertinent documents and evidence
relevant and material to the protest and it shall be accompanied by any required filing. The basis for
review of the protest shall be the documents and other evidence described in and attached to the
Protest Letter and no facts, grounds, documentation, or other evidence not specifically described in and
attached to the Protest Letter at the time of its filing shall be permitted or considered in support of the
protest.
(c) Computation of time. No time will be added to the above time limits for service by mail. The
last day of the period so computed shall be included unless it is a Saturday, Sunday, or legal holiday in
which event the period shall run until the next day which is not a Saturday, Sunday, or legal holiday.
(d) Challenges. The written protest may not challenge the relative weight of the evaluation criteria
or any formula used for assigning points in making an award determination, nor shall it challenge the
City’s determination of what is in the City’s best interest which is one of the criteria for selecting a
bidder whose offer may not be the lowest bid price.
(e) Authority to resolve protests. The Purchasing Manager, after consultation with the City
Attorney, shall issue a written recommendation within ten calendar days after receipt of a valid Protest
Letter. Said recommendation shall be sent to the City Manager with a copy sent to the protesting party.
The City Manager may then, submit a recommendation to the City Commission for approval or
117 of 118 122
disapproval of the protest, resolve the protest without submission to the City Commission, or reject all
proposals.
(f) Stay of procurement during protests. Upon receipt of a timely, proper and valid Protest Letter
filed pursuant to the requirements of this section, the City shall not proceed further with the solicitation
or with the award or execution of the contract until the protest is resolved by the City Manager or the
City Commission as provided in subsection (e) above, unless the City Manager makes a written
determination that the solicitation process or the contract award must be continued without delay in
order to avoid potential harm to the health, safety, or welfare of the public or to protect substantial
interests of the City or to prevent youth athletic teams from effectively missing a playing season.
END OF DOCUMENT
118 of 118 123
124
SUMMARY OF QUANTITIESDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*G-01SUMMARY OF QUANTITIES125
Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*G-02GENERAL NOTES126
WIIEEEEEESDD6130615061806193616161436101C-1DEMOLITION PLANSEE PLANSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*NSW 72ND STREET(SUNSET DRIVE)SW 61ST CT CIR
LEGENDSW 61ST CT CIR
127
WIIEEEEEESDD6130615061806193616161436101C-2GEOMETRY PLANSEE PLANSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*NSW 61ST CT CIRSW 72ND STREET(SUNSET DRIVE)LEGENDSW 61ST CT CIR
128
WIIEEEEEESDD6130615061806193616161436101C-3PAVEMENT MARKING PLANSEE PLANSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*NSW 72ND STREET(SUNSET DRIVE)SW 61ST CT CIR
LEGENDSW 61ST CT CIR
129
0+001+002+003+004+005+0012345678910111213141517181920212223Exist tree off-siteExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.01EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.011EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN130
6+007+008+009+0010+0011+0020242547484935363726273839404142434445463132333450525155535456575859646667686061626365282930Exist tree off-site69Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.02EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.021EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN131
12+0013+0014+0015+0016+0017+0073777879747576707172808283848586878889909181929394959697Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.03EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.031EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN132
18+0019+0020+0021+0022+0023+00100101102103104105106107108109111110114115112113979899116Exist tree off-siteExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.04EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.041EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN133
24+0025+0026+0027+0028+0029+00116117118119120121122123124125126127128129130131132142143139140141138133134135136137144Exist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.05EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.051EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN134
30+0031+0032+0033+0034+0035+00144145146147148149150151152153154155156157158159160161162163164165166167168169170VEMOExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.06EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.061EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN135
40+0041+0036+0037+0038+0039+00169170171172173174175176177178179180181182184185190191192193187188189186183Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.07EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.071EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN136
42+0046+0047+0043+001+00
10+00 45+0044+00195197196198189194199200201202203204205219218217220229230231232233234235236237238239240241243242244245246247248221222223224206207208209210211225226227215228216212213214Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.08EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.081EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAIN137
48+0049+0050+0051+00248216250249251252253254255256257280281282279278276261262263264265269270271268267266273274275277272283SIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA1.09EXISTING TREE DISPOSITION PLANNSCALE: 1" = 20'020'40'80'LA1.091EXISTING TREE DISPOSITION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: TRANSPLANTS ARE TO BE RELOCATED TO A LOCATION DETERMINED BY THE CITY OF SOUTH MIAMI.138
0+001+002+003+004+005+0012345678910111213141517181920212223Exist tree off-siteExist tree off-siteExist tree off-siteBUFR-264CHIH-263ERLI-78ERLI-315CHIH-145FIGI-135PSNE-200SERE-6FIGI-117SRSSRSSRSSRSSRSSRSCHIH-50ERLI-206BUFR-478FIGI-120QUVI-4Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.01PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.011PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.139
6+007+008+009+0010+0011+0020242547484935363726273839404142434445463132333450525155535456575859646667686061626365282930Exist tree off-site69ERLI-245BUFR-478CHIH-54FIGI-120ARGL-125ERLI-82ERLI-88ARGL-124CHIH-58SRSSRSSRSERLI-230ARGL-200QUVI-6VEMO-1SERE-3SRSSRSFIGI-153CHIH-257SRSSRSSRSSRSSRSSRSSERE-6Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.02PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.021PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.140
12+0013+0014+0015+0016+0017+0073777879747576707172808283848586878889909181929394959697SRSSRSSRSARGL-105ERLI-191FIGI-125QUVI-1SERE-3ARGL-101ERLI-129QUVI-2SERE-5SRSSRSERLI-170ARGL-127ERLI-147FIGI-60FIGI-60CHIH-116BUFR-207SRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.03PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.031PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.141
18+0019+0020+0021+0022+0023+00100101102103104105106107108109111110114115112113979899116Exist tree off-siteExist tree off-siteExist tree off-siteARGL-416ERLI-353ERLI-170SERE-3CHIH-132BUFR-207QUVI-3ERLI-324ARGL-460BUFR-516SRSSRSSRSSRSSRSSRSSERE-3QUVI-2FIGI-70QUVI-2BUFR-389SERE-6FIGI-95ERLI-85QUVI-1BUFR-454CHIH-114SERE-3SRSSRSSRSSRSSRSSRSSRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.04PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.041PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.142
24+0025+0026+0027+0028+0029+00116117118119120121122123124125126127128129130131132142143139140141138133134135136137144Exist tree off-siteARGL-370ERLI-180SRSSRSSRSSERE-4FIGI-83ERLI-115CHIH-92BUSI-2FIGI-80ERLI-110FIGI-42ERLI-163SRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.05PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.051PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.143
30+0031+0032+0033+0034+0035+00144145146147148149150151152153154155156157158159160161162163164165166167168169170VEMOExist tree off-siteExist tree off-siteQUVI-1FIGI-240BUFR-475SRSSRSSRSERLI-146BUSI-2CHIH-95SERE-6FIGI-16FIGI-64SRSSRSSRSFIGI-135SERE-3CHIH-195ERLI-60ARGL-290BUFR-680ARGL-140SRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.06PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.061PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.SEE SHEET LA4.01 FORIRRIGATION IN THIS AREA144
40+0041+0036+0037+0038+0039+00169170171172173174175176177178179180181182184185190191192193187188189186183Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESRSSRSSRSBUFR-280ARGL-95ERLI-180FIGI-144LYLA-6SERE-6CHIH-95FIGI-154ERLI-206ERLI-155LYLA-1SRSSRSSRSSRSSRSSRSSERE-3Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.07PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.071PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.SEE SHEET LA4.02 FORIRRIGATION IN THIS AREASEE SHEET LA4.02 FORIRRIGATION IN THIS AREA145
42+0046+0047+0043+001+00
10+00 45+0044+00195197196198189194199200201202203204205219218217220229230231232233234235236237238239240241243242244245246247248221222223224206207208209210211225226227215228216212213214Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLEERLI-230FIGI-200BUFR-145BUFR-145BUFR-62Exist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainExist. FIGIto remainRemove Exist.ScheffleraExist. FIGIto remainRemove Exist.ScheffleraRemove Exist.ScheffleraSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBERLI-60SPBA-7ERLI-60SPBA-7ERLI-60SPBA-7SBSBSBSBSBSBSBSBSBSBSBSBSBSBERLI-60SPBA-7ERLI-60SPBA-7CLOCK WILL BE ADDRESSED WITHFUTURE CITY HALL PROJECTANTICIPATED BY YEAR 2022/2023.Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.08PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.081PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.SEE SHEET LA4.03 FORIRRIGATION IN THIS AREA146
48+0049+0050+0051+00248216250249251252253254255256257280281282279278276261262263264265269270271268267266273274275277272283SIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESPBA-3BUFR-62BUFR-370SPBA-16JACO-5FIGI-142ERLI-328Exist. FIGIto remainRemove Exist.ScheffleraSBSBSBSBSBSBSBERLI-60SPBA-7SBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA2.09PLANTING PLANNSCALE: 1" = 20'020'40'80'LA2.091PLANTING PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMEXIST. SHRUBSEXIST. TREE/PALMTO BE TRANSPLANTEDTO BE REMOVEDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.147
Drawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA3.01PLANTING NOTES, SPECS, AND DETAILSLANDSCAPE SPECIFICATIONSPART 1 - GENERAL1.1SCOPEA. Contractor shall provide all labor, materials, equipment, supervision, and related work necessary to complete the landscape work in accordance with theintent of the landscape plans, schedules and these specifications. The extent of work is shown on the drawings which are a part of this document.1.2CONTRACTOR QUALIFICATIONSA. Landscape installation work to be performed by a Contractor Certified by the Florida Nurserymen, Growers and Landscape Association (FNGLA) as aCertified Landscape Contractor. Any pruning to be supervised by an Arborist, certified by the International Society of Arboriculture (ISA) and licensed inMiami-Dade County.1.3INVESTIGATION OF UTILITIESA. Prior to beginning work, the Contractor shall be responsible to locate existing underground utilities. Check with all utility companies and Sunshine State, call(811).1.4SUBSTITUTIONSA. Only materials specified will be accepted, unless approved in writing by the Landscape Architect in advance.1.5PLANT SIZESA. All plant sizes shall equal or exceed the minimum sizes as specified in the plant list. When plant sizes are specified as a range of size, installed materials shallaverage the mean of the range specified. Plants shall be measured following pruning, with branches in normal position. All necessary pruning shall be done atthe time of planting.1.6PLANT QUALITYA. All plant material shall be equal to or better than Florida No. 1 as classified by “Grades and Standards for Nursery Plants” by the Division of Plant Industry,Florida Department of Agriculture. They shall have a growth habit that is normal for the species; healthy, vigorous, free from insects, disease and injury.B. The Owner or Landscape Architect reserves the right to refuse any plant material which does not conform to the intent of the written specifications or design.C. CIRCLING ROOTS FOUND ON CONTAINER-GROWN MATERIAL WILL NOT BE ACCEPTED UNLESS REMEDIAL ROOT PRUNING, APPROVED BY THELANDSCAPE ARCHITECT IS DONE BEFORE PLANTING.1.7PLANT QUANTITYA. The plant quantities shown on the plant list are to be used only as an aid to bidders. In the case of discrepancy between the plant list and the plan, thequantity on the plan shall override the plant list.1.8UNIT PRICESA. The successful bidder shall furnish to the Owner and the Landscape Architect, a unit price breakdown for all materials. The Owner may, at his discretion,add to or delete from the materials utilizing the unit price breakdown submitted to and accepted by the Owner.1.9SUBMITTALSA. Fertilizer: The Contractor shall submit to the Owner and Landscape Architect documentation that all the fertilizer used for the project is of the analysisspecified and placed at the rates specified in section 2.2 FERTILIZER.B. Planting soil: The Contractor shall submit a sample of the planting soil (approximately 1 cu. Ft.) for approval by the Landscape Architect prior to delivery tothe site.1.10 CLEAN-UP & MAINTENANCE OF TRAFFICA. Follow procedures in FDOT Index 600 for maintenance of traffic during construction.B. At the end of each work day, the Contractor shall remove debris and shall barricade the un-filled holes in a manner appropriate in the path of pedestriansand motorists.C. Upon completion of the work or any major portion of the work or as directed by the Landscape Architect, all debris and surplus material from his work shallbe removed from the job site.1.11 MAINTENANCE PRIOR TO ACCEPTANCEA. The Contractor is responsible to maintain the plantings until they are accepted under the provisions of 1.12 “ACCEPTANCE OF INSTALLATION”.1. Plants: Begin maintenance immediately following the final plant installation operation for each plant and continue until all plant installation is complete andaccepted. Maintenance shall include watering all plants, weeding, mulching, pest and disease control, tightening and repairing of guys, repair of braces,removal of dead growth, resetting of plants to proper grade or up-right position, restoration of plant saucer, litter pick-up in plant beds and other necessaryoperations to assure specified minimum grade of Florida No. 1.2. Turf Areas: Begin maintenance of turf immediately following the placement of sod and continue until sod installation is complete and accepted.Maintenance shall include but not be limited to, watering, leveling, mowing, weed and pest control, fungus and disease control and other necessary operationsas determined by the Landscape Architect and good nursery practice.3. Re-setting or straightening trees and palms:The Contractor shall re-set and/or straighten trees and palms as required at no additional cost to the Owner unless caused by sustained winds of 75 mph ormore. Then, the costs of the operations may be charged to the owner. Re-set trees within 48 hours.1.12 ACCEPTANCE OF INSTALLATIONA. Inspection: Inspection of the work, to determine completion of contract work, exclusive of the possible replacement of plants and turf, will be made by theLandscape Architect at the conclusion of the maintenance period. Written notice requesting such an inspection and submitted by the Contractor at least ten (10)days prior to the anticipated date.1.13 GUARANTEEA. Guarantee all plants for a period of one year (CCD). Guarantee shall commence from the date of written acceptance. Plant material which is on the siteand scheduled to be relocated is not covered by the guarantee except in the case of Contractor's negligence or work that has been done in an unworkman-likemanner. The Contractor is not responsible for loss due to acts of god, (i.e.) sustained winds of 75 mph or more, floods, frost, lightning, vandalism or theft.1.14 REPLACEMENT A. Replacement shall be made during the guarantee period as directed by the Landscape Architect within ten (10) days from time of notification. For allreplacement plant material, the guarantee period shall extend for an additional forty-five (45) days beyond the original guarantee period. The Contractor shallbe responsible to provide water to the replacement plants in sufficient quantity to aid in their establishment. At the end of the guarantee period, inspection willbe made by the Landscape Architect, upon written notice requesting such inspection and submitted by the Contractor at least five (5) days before the anticipateddate. Replacement plants must meet the requirements of Florida No. 1 at time of inspection. Remove from the site all plants that are dead or in a state ofunsatisfactory growth, as determined by the Landscape Architect. Replace these and any plants missing due to the Contractor's negligence as soon as conditionspermit.1. Materials and Operations: All replacement plants shall be of the same kind and size as indicated on the plant list. The Contractor shall supply and plant theplants as specified under planting operations.2. Cost of Replacements: A sum sufficient to cover the estimated cost of possible replacements, including material and labor will be retained by the Owner andpaid to the Contractor after all replacements have been satisfactorily made and approved by the Landscape Architect.PART 2 - MATERIALS2.1PLANTING SOILA. Planting soil for trees, shrubs and ground covers shall be of the composition noted on the plans, measured by volume.B. Soil for Sodded Areas: shall be coarse lawn sand.2.2FERTILIZERA. Fertilizer for trees, palms, shrubs, and groundcovers shall be as follows: LESCO Palm Special 13-3-13 or equal, Sulfur coated with iron and other minorelements and maximum of 2% chlorine, or brand with equal analysis. The fertilizer shall be uniform in composition, dry and free flowing and shall be deliveredto the site in the original unopened containers, bearing the manufacturer's guaranteed analysis. Fertilizer for sod and seeded areas shall be 8-6-8, 50%organically derived nitrogen, or equal.2.3WATERA. The Contractor shall provide potable water on site, available from the start of planting. The Contractor is responsible to ascertain the location andaccessibility of the water source. The Contractor is responsible to provide the means of distribution (i.e. water truck, hoses, etc.) for distribution of water to theplanting areas.2.4MULCHA. Mulch shall be shredded Melaleuca mulch (Florimulch) as manufactured by Forestry Resources, Inc., or equal.2.5ROOT BARRIER MATERIALA. Root barrier material shall be 24" deep polypropolylene panels by DeepRoot or approved equal.B. Install per details in the plans.PART 3 - INSTALLATION PROCEDURES3.1LAYOUTA. Verify location of all underground utilities and obstructions prior to excavation.3.2HERBICIDE TREATMENTA. In all areas infected with weed and/or grass growth, a systemic herbicide, such as Roundup, shall be applied per manufacturer's rates. When it has beenestablished where work will be done, the systemic herbicide shall be applied in accordance with manufacturer's labeling to kill all noxious growth. Contractorshall schedule his work to allow more than one application to obtain at least 95% kill of undesirable growth. If necessary, Contractor shall conduct a test toestablish suitability of product and applicator to be used on this project, prior to execution of the full application.3.3PLANT PIT EXCAVATION AND BACKFILLINGA. Trees: See the Planting and Bracing Details and notes.B. All planting holes shall be hand dug where machine dug holes may adversely affect utilities or improvements.C. Shrubs and Groundcover: Shrubs and groundcover shall be planted in a soil bed as described in the notes and details. Space shrubs and provide setbackfrom curb and pavements as shown in the plans.D. Watering of field-grown plants: Thoroughly puddle in water to remove any air pockets in the plant hole.3.4WATERINGA. The Contractor is responsible to provide the water for all new plants and transplants and means of distribution (i.e. hand watering or water truck) during themaintenance period and extending into the period after acceptance until the full schedule as listed below is complete. Water for trees and other large fieldgrown plants shall be supplemented by hand or water truck, in addition to the irrigation system, (if one is provided). Contractor can adjust watering scheduleduring heavy rain season upon approval of the Landscape Architect.AMOUNT OF WATER PER APPLICATIONFor trees up to 5 inch caliper - 5 gallonsFrom 5 to 8 inch caliper - 25 gallons9 inch and up caliper - 50 gallonsFREQUENCY OF WATERDaily for the first week3times per week for weeks 2 - 52times per week for weeks 6 - 81 time per week for weeks 9 - 12B. Water in plants by thoroughly soaking of the entire root ball immediately after planting. For large trees and shrubs, add water while backfillinghole to eliminate any air pockets in the soil around the root ball.C. Water shrubs, sod and groundcover a minimum of once daily for a week or until an irrigation system is fully operational. If no irrigation systemis to be installed, the Contractor shall be responsible for watering the shrub, sod, and groundcover for the time specified above, after installation ofeach section of the planting installed.3.5FERTILIZINGA. Add fertilizer on top of the surface of shrubs beds and tree and palms root balls two (2) months after installation. Fertilize sod within two (2)days after installing after planting of each segment of the job. Fertilizer shall be applied after soil has been well moistened. Fertilizer shall bewashed off of plant leaves and stems immediately after application. Apply at the following rates:1. Trees and Large Shrubs: One (1) pound per inch of trunk diameter, spread evenly over the root ball area.2. Shrubs: One half (1/2) handful per shrub, spread evenly over the root ball area.3. Groundcover: Twelve (12) pounds per 100 sq. ft. of bed area.4. Sod: Twelve (12) pounds per 1,000 sq. ft. Wash fertilizer off blades immediately after spreading.3.6MULCHINGA. Spread mulch two (2) inches thick uniformly over the entire surface of shrubs and groundcover beds, depth measured after settling, unlessotherwise specified in the plans. Provide 36” diameter bed of mulch, measured from outer edge of the trunk, for all trees and palms planted in sodareas. Keep mulch away from contact with the trunk. Create a 6” high ring of mulch at the outer edge of tree and palm holes.3.7GUYING AND BRACINGA. See the details bound herewith or made part of the plans.3.8 SODDINGA. Provide a blanket of lawn sand as described in the notes in these plans. Prior to planting, remove stones, sticks, etc. from the sub-soil surface.Excavate existing non-conforming soil as required so that the finish grade of sod is flush with adjacent pavement or top of curb as well as adjacentsod in the case of sod patching.B. Place sod on moistened soil, with edges tightly butted, in staggered rows at right angles to slopes. The sod shall be rolled with a 500 poundhand roller immediately after placing.C. Keep edge of sod bed a minimum of 18” away from groundcover beds and 24” away from edge of shrub beds and 36” from trees, measuredfrom the edge of plant or tree trunk.D. Sod shall be watered immediately after installation to uniformly wet the soil to at least two inches below the bottom of sod strips.E. Apply fertilizer to the sod as specified in Section 3.5.F. Excavate and remove excess soil so top of sod is flush w/top of curb or adjacent pavement, or adjacent existing sod.PLANT BED PREPARATION NOTES1. In all areas where new sod and shrub and groundcover masses are to be planted, kill all existing weeds by treating with Round-upprior to beginning soil preparation.2. In all shrub and groundcover beds, prepare soil as described for either condition, over the entire area to be planted:Condition A:If any compacted road base or asphalt or rocky soil is encountered, remove compacted material entirely to allow an 18” depth ofplanting soil. Backfill the entire area of the shrub and groundcover beds with 18” planting soil (as specified in Plans) to within 2inches of the adjacent pavement or top of curb. Remove all debris and rocks and pebbles larger than 1 inch in size and level thegrade before planting.Condition B:Where no compacted soil is encountered, thoroughly mix 6 inches of planting soil into the existing soil to a depth of 18 inches. Ifrequired, excavate and remove the existing soil to lower the grade, so that the prepared mix is finished to a minimum of 2 inchesbelow top of curb or adjacent walkway. Remove all debris and rocks and pebbles larger than 1 inch in size and level the grade beforeplanting.For all sod areas, spread a 2” deep layer of lawn sand prior to sodding. Remove all debris and rocks and pebbles larger than 1 inchin size and level the grade before sodding. Remove, if required, existing soil so that top of sod is flush with and adjacent top of curbor pavement.SPACING OF PLANTS (SEE PLANT SPACING DETAIL)1. Plants shall be planted sufficiently away from edges of pavements or curbs, to allow for growth toward the edges of the bed.PROTECTION OF PLANTS1. The Contractor shall be responsible to protect existing trees and shrubs in and adjacent to the area of work. Erect barriers asnecessary to keep equipment and materials, any toxic material, away from the canopy drip line of trees and shrubs. DO NOT PILESOIL OR DEBRIS AGAINST TREE TRUNKS OR DEPOSIT NOXIOUS BUILDING SUPPLIES OR CHEMICALS WITHIN THE DRIPLINE.DISTANCE VARIES FOR EACH SPECIES SPACINGWALL, CURB, EDGE OF PAVEMENT, OR EDGE OF BEDSHRUB SPACING DIAGRAM15'EDGE OF PAVEMENTROOT BARRIER INSTALLATION DETAILCURBPLAN VIEWLESS THAN 8 FT.When trees are to be installed CLOSERTHAN 8 FT. from edge of walks or curbs,install a root barrier. The root barrier shallextend a minimum of 15 ft. from the edgeof the trunk in either direction.24"Install root barrier so top of barrier isflush with top of grade.N.T.S.ROOT BARRIER(24" DEEP) See PLANT LISTVARIESN.T.S.EDGE OF PAVEMENTINSTALL WHEN 8'OR LESSCURB15'TREE TRUNK6"SHRUB INSTALLATION DETAILABOVE SURROUNDING GRADESET TOP OF ROOT BALL 1 1/2" - 2"VARIES
PLANTING SOIL.min.min8"2" MULCH FLUSH WITH ADJACENTPAVEMENT (KEEP AWAY FROMSHRUB STEMS)N.T.S.BELOW THE TOP HALF OF THE ROOTBALL. COMPLETELY REMOVE REMOVE ANY PORTION OF WIREBASKETS OR BURLAP ABOVE THE TOP HALF OF THE ROOTBALL. FOLD BACK BURLAP COVERINGS MULCH WITHIN 3" OF THETRUNKINSTALL 2" OF MULCH OVER3" DIAMETER CIRCLE AROUNDTHE TRUNK. DO NOT PLACESET ROOTBALL SOPROVIDE THREE 2'X4' PINE STAKES120 APART ATTACH W/NAILS TO BATTENS NO NAILS IN TREEALL SYNTHETIC ROOTBALL ROCKS 2" OR LARGER REMOVEDFINISHED GRADEHOLES TO ACCOMMODATE PLANTS SHALL BE A MINIMUMOF THREE TIMES THE SIZED OF THE PLANT ROOTBALL.ALL BACKFILL FOR TREES SHALL BE EXISTING SOIL WITH ALL(NOT TO EXCEED 12 MONTHS FROM THE COMPLETIONOF THE PROJECT).ALL SUPPORT MATERIALS ARE TO BE REMOVED FROM THE TREES ONCE THE TREES HAVE BECOME ESTABLISHEDNOTE - IRREGULAR OR MULTI-STEMED TREES SHALL HAVE A SIMILAR STAKING PATTERN AS SINGLE TRUNKED TREES. STAKES NEED NOT ALL BE 6" HIGH TEMPORARY RETENTION RING OF SOIL TO ASSIST IN IRRIGATION OF THE TREE. REMOVE RING 3 MONTHS FERTILIZER SHALL BE INSTALLED AS PER THE WRITTEN SPECIFICATIONS.LIGHTLY COMPACTED SUBGRADE3 TIMES ROOT BALL DIAMETERTOP SOIL5/8" DIAMETER NYLON STRAPS WRAPPED AROUND TRUNK & PULLED TAUT, TIED TOBOTTOM OF PLANTING PIT(2)2" DIA. 8' LONG WOOD DOWELS 120 APART DRIVEN THROUGH 6"
12"UNDER 3 1/2" CALIPERN.T.S.PLANTING & BRACING DETAILSOIL WITH ALL ROCKS 2" OR LARGER REMOVEDFINISHED GRADEHOLES TO ACCOMMODATE PLANTS SHALL BE A MINIMUM OF THREE TIMES THE SIZED OF ALL BACKFILL FOR TREES SHALL BE AS EXISTINGFERTILIZER SHALL BE INSTALLED AS PER THE WRITTEN SPECIFICATIONS.LIGHTLY COMPACTED SUBGRADE3 TIMES ROOT BALL DIAMETERTOP SOILTOP HALF OF THE ROOTBALL.COMPLETE REMOVE ALL SYNTHETICREMOVE ANY PORTION OF WIREBASKETS ABOVE THE TOP HALF OFTHE ROOTBALL. REMOVEBURLAP COVERINGS BELOW THEROOTBALL COVERING MATERIALSWOOD STAKES TOP OF STAKES5(2"X4"X16" WOOD BATTENS5 LAYERS OF BURLAPSTEEL BANDTRUNK FLARE OR TOP ROOTIS 2" ABOVE SURROUNDING GRADESET ROOTBALL SOTRUNK FLARE OR TOP ROOTIS 2" ABOVE SURROUNDING GRADE18"DETAIL A N.T.S.12" MIN
2"X4"TOP OF STAKE ATOR FLUSH WITHOR BELOW GRADEOVER 3 1/2" CALIPERN.T.S.PLANTING & BRACING DETAILBATTEN DETAIL BN.T.S.EDGE OF BELOW OR FLUSH WITH GRADEBECOME ESTABLISHED(NOT TO EXCEED 12 MONTHS FROM THE COMPLETION OF THE ALL SUPPORT MATERIALS ARE TO BE REMOVED FROM THE TREES ONCE THE TREES HAVE NOTE - IRREGULAR OR MULTI-STEMED TREESSHALL HAVE A SIMILAR STAKING PATTERN AS SINGLE TRUNKED TREES. STAKES NEED NOT MULCH WITHIN 3" OF THETRUNKINSTALL 2" OF MULCH OVER3" DIAMETER CIRCLE AROUNDTHE TRUNK. DO NOT PLACEDETAIL AALL BE ATTACHED TO EVERY STEM PROJECT).WOOD DOWELS.THE PLANT BALL.ATTACHED TO EVERY STEM. AFTER INSTALLATION. TREES & PALMS OVER 12" CALIPERNOTE- USE 4" X 4" STAKESCOVERING MATERIALS.6" HIGH TEMPORARY RETENTION RING OF SOIL TO ASSIST IN IRRIGATION OF THE TREE. REMOVE RING 3 MONTHS AFTER INSTALLATION. (UNLESS OTHERWISE SPECIFIED)3' FOR 36"-48" o.c. SPACED SHRUBS18" FOR 12"-18" o.c. SPACED SHRUBS24" FOR 24" o.c. SPACED SHRUBSPLANTING PITSIZE:NOTES:FINISH LEGEND:(MF) MILL FINISH-NATURAL ALUMINUMPERMALOCCLEANLINEALUMINUM EDGINGTOP OF EDGING TOBE MAXIMUM OF12" (12.7MM) ABOVESURFACE MATERIALBED MEDIA ORAGGREGATECOMPACT GRADESADJACENT TOEDGING TO AVOIDSETTLING12" (305MM)ALUMINUM STAKESTO LOCK INTOPREFORMED LOOPSON THE EDGINGINSTALL PER MANUFACTURER'S"INSTALLATION GUIDELINES"8'-0" (2.44 M) SECTIONS TO INCLUDE(3) 12" (305 MM) ALUMINUM STAKES.16'-0" (4.88 M) SECTIONS TOINCLUDE (5) 12" (305 MM)ALUMINUM STAKES.CORNERS - CUT BASE EDGING UPHALFWAY ANDFORM A CONTINUOUS CORNER.PERMALOC CLEANLINE ASMANUFACTURED BYPERMALOC CORPORATION,HOLLAND MI.(800) 356-9660,(616) 399-9600CONTRACTOR'S NOTE:FOR PRODUCT ANDPURCHASING INFORMATIONVISIT:WWW.PERMALOC.COM1.2.3.4.5.6.0.072" (1.82MM) THICK18" X512" (3.2MM X 140MM),w/ 0.135" (3.43MM) EXPOSED TOP LIPISOMETRIC VIEWNTSSTAKESPERMALOC CORPORATION, 13505 BARRY STREET HOLLAND, MI, 49424(800) 356-9660 PHONE: (616) 399-9600 fax: (616) 399-9770 WWW.PERMALOC.COMTMCPERMALOCLEANLINEALUMINUM LANDSCAPE EDGINGALUMINUM EDGING DETAILN.T.S.148
30+0031+0032+0033+0034+0035+00144145146147148149150151152153154155156157158159160161162163164165166167168169170VEMOExist tree off-siteExist tree off-siteDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.01IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.011IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA149
40+0041+0036+0037+0038+0039+00169170171172173174175176177178179180181182184185190191192193187188189186183Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESRSSRSSRSSRSSRSSRSSRSSRSSRSDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.02IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.021IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREANEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA150
42+0046+0047+0043+001+00
10+00 45+0044+00195197196198189194199200201202203204205219218217220229230231232233234235236237238239240241243242244245246247248221222223224206207208209210211225226227215228216212213214Exist tree off-siteSIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.03IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.031IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA151
48+0049+0050+0051+00248216250249251252253254255256257280281282279278276261262263264265269270271268267266273274275277272283SIGHT DIST. TRIANGLESIGHT DIST. TRIANGLESBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBSBDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA4.04IRRIGATION PLANNSCALE: 1" = 20'020'40'80'LA4.041IRRIGATION PLAN1" = 40' REDUCEDPLANT LEGENDEXIST. TREE/PALMTO REMAINNOTE: MAINTAIN AND/OR REPAIR EXISTING IRRIGATION ACCORDING TOIRRIGATION EXPANSION NOTES (SHEET LA5.01) UNLESS OTHERWISE NOTED.NEW AND/OR ADJUSTEDIRRIGATION IN THIS AREA152
(locate in area of free rainfall)MINI-Clik II Rain Sensor RAINBIRD ____ Series ControllerElectric ControllerIRRIGATION MATERIALS LISTPVC sleeves shall be ScheduleIrrigation Control Wirepipe running through it)Flexible PVC or Polypipe (for swing joints)40 PVC (sized 2 sizes larger than the RAINBIRD 200-PESB 2" Electromechanical PVC laterals & mains shall be schedule40 PVC (sized as shown on plans)Solenoid Control ValveITEMKEY11as requiredas requiredQTY.Series w/MPR nozzles RAINBIRD Spray Heads 1800 @ 30 PSI12" pop-up on risers in shrub beds4" pop-up in grass areas15-H15-F15-est15-cst WM2" WATER METERMAINas required1as requiredEC15-sst 10-T10-H10-F15-T(1.85 gpm)(3.7 gpm)(.61 gpm)(1.21 gpm)(1.21 gpm)(.53 gpm)(.79 gpm)(1.58 gpm)(1.23 gpm)(See Civil Plans)as requiredas requiredas requiredDrawing No.ScaleRevisionProject No.SheetofConsultantsRevisionIssuedSealwww.stantec.comThe Contractor shall verify and be responsible for all dimensions. DO NOT scale thedrawing - any errors or omissions shall be reported to Stantec without delay.The Copyrights to all designs and drawings are the property of Stantec. Reproductionor use for any purpose other than that authorized by Stantec is forbidden.901 Ponce de Leon Blvd. Suite 900Coral Gables, Florida 33134MIAMI-DADE COUNTY, FLORIDASunset Drive ModificationsCity of South Miami215614561*LA5.01IRRIGATION NOTES, SPECS, AND DETAILSIRRIGATION EXPANSION NOTESIt is anticipated that after completion of these tasks there will be a fullyfunctioning automatic irrigation system (equipped with an automaticrain-shut off device) that will provide irrigation to all landscape areaswith 90% overlap of spray.If there is an existing irrigation system:1.The Contractor shall locate existing connection to water source(pump and well, lake intake or water meter), controller, rain shutoff device, valves and mainline. The Contractor shall then verifythat all systems are in working order and perform a flow test todetermine the amount of water flow and pressure throughout thesystem.2.The Contractor shall verify that the existing controller has enoughavailable stations for the additional required zones. If thecontroller does not then the Contractor shall furnish and installanother controller capable of handling all of the zones. TheContractor may suggest installing another controller to tandem onthe existing controller. The Owner will decide if this is acceptable.3.If there is no existing rain shut off device then the Contractor shallfurnish and install a new one. The Contractor is responsible toensure that the electrical hook up is performed to all applicablecodes and ordinances.4.The Contractor shall furnish and install new zone valves as requiredand wire them back to the existing (or new) controller.5.It may be necessary to extend the existing mains. If necessary, theContractor shall be responsible of trenching and backfilling andrepair of roadway or other paved surfaces. After the installation ofthe additional main, the Contractor shall perform a pressure test asspecified in the General Notes.6.Based on the flow test the Contractor shall zone and pipe theheads located in the Irrigation Head Layout Plan. The Contractorshall ensure that the zones and laterals are sized sufficiently toensure that there is proper pressure to run the irrigation heads attheir optimum pressure.If there is not an existing irrigation system:1.The Contractor purchase and install a new 2” water meter andbackflow assembly. This assembly shall comply with all local codesand ordinances.2.The Contractor shall furnish all necessary controllers, rain shut offdevices, valves, mains, laterals and heads necessary to install theproposed system. The Contractor is responsible for all necessaryelectrical wiring to operate the controller and rain shut off device.3.The Contractor shall be responsible of trenching and backfillingand repair of roadway or other paved surfaces when installingmains.4.The Contractor shall furnish and install new zone valves as requiredand wire them back to the controller.5.The Contractor shall zone and pipe the heads located in theIrrigation Head Layout Plan. The Contractor shall ensure that thezones and laterals are sized sufficiently to ensure that there isproper pressure to run the irrigation heads at their optimumpressure.P.V.C. LATERAL1/2" SCH. 40 STREET "L"FLEXIBLE P.V.C. OR TORO FUNNY PIPE (MIN. 18" LONG)6" ABOVE TOP OF PLANT AT TIME OF PLANTING#5 REBAR STAKED WITH BLACK PLASTIC TIESTOP AND BOTTOM(PAINT REBARS BLACK)FINISH GRADETOP OF SHRUBSOR GROUNDCOVERABOVE HIGHEST
SPRINKLER HEAD
TO IRRIGATION SYSTEM18" min.12"
18" MIN.2" BELOW TOP OFPLANT IF 12" POP-UPS ARE USEDGENERAL NOTES:1. SCOPE OF WORK: The Contractor shall furnish all labor, machinery, tools, supplies, andequipment as necessary to construct and provide an operating system, as indicated in thePlans. The work shall include, but not be limited to, furnishing materials (pipe, valves,sprinkler heads, fittings, controllers, electrical, wire and fittings, primer, glue, etc.), layout,protection to the public, excavation, assembly, installation, backfilling, compaction, repair ofroad or pavement surfaces, controller and low voltage feed to the valves, clean-up,maintenance and guarantee, and as-built plans.2. Contractor shall coordinate with General Contractor or other pertinent Contractors on thejob to insure that sleeves are provided and installed under hard surfaces to allow access toall areas to be irrigated. All sleeves shall be constructed of Schedule 40 PVC. Bury allsleeves a minimum of 24" below the surface. Sleeve to be 2 times the size if the pipe runningthrough it. Sleeve shall extend 24" past the edge of pavement into the area to be irrigated.3. GUARANTEE: The irrigation system shall be guaranteed for a minimum of one calendaryear from the time of final acceptance.4. REPAIR UTILITIES: The Contractor shall be responsible to verify the location of all utilitiesby hand excavation or other appropriate measures before performing any work that mayresult in damage to utilities structures, or property. The Contractor shall take immediatesteps to repair, replace, or restore all services to any utilities which are disrupted due to hisoperations. All costs involved in disruption of service and repairs due to negligence on partof the Contractor shall be his responsibility.5. AS-BUILT DRAWINGS: Prints of the plans will be supplied to the Contractor for recording"as-built" information. Immediately upon installation of any work which deviates from what isshown on the Plans, the Contractor shall clearly indicate such changes in red pencil on theprints. Such changes shall include, but not be limited to, changes in (1) materials; (2) sizesof material; (3) location; and (4) quantities.6. The entire installation shall fully comply with all applicable local and state codes andordinances. The Contractor shall take out all required plumbing and electrical applicationsand permits, arrange for all necessary inspections and shall pay all fees and expenses inconnection with same as part of work under the contract.7. UNIT PRICES: The successful bidder shall furnish, to the Owner, a unit price breakdownfor all materials. The Owner may at his own discretion, add to or delete from the materials,using the unit price breakdown submitted to and accepted by the Owner.8. MAINTENANCE PERIOD: The irrigation system shall be maintained for a period of 90days after final acceptance of installation. Maintenance shall include checking of the system2 times per week. Contractor shall be responsible to replace/repair any broken ormalfunctioning parts of the system including those damaged by accidents or vandalism.Repairs shall be made immediately at the time of inspection or when notified by theLandscape Architect.9. The irrigation system shall provide 100% coverage with a minimum of 90% overlap ofwater spray.10. The system is design to provide sprinkler precipitation rates that are nearly equal in eachzone. Mixing of sprinklers with widely varying precipitation rates in a zone will not beaccepted.11. All pipe shall be made of Schedule 40 PVC, except flexible PVC (or Toro funny pipe) forflexible swing joint and Schedule 80 galvanized steel pipe for all above ground fittings. Pipelocations shall be adjusted in the field. When laying out mains and laterals, locate pipe nearedges of pavement or against buildings wherever possible, to allow space for plant rootballs.Coordinate pipe locations with plantings. Bury all mains 18" below surface and laterals 12".Depth shall be measured to top of pipe.12. Keep pop-up sprinkler heads a minimum of 8" from edges of pavement and curbing, andheads on risers a minimum of 18", or as indicated in the pans.13. All heads located in shrub or groundcover beds shall be installed on a riser as perdetails in the plans. All other heads shall be installed on a swing joint as per details in theplans.14. Place irrigation control wire in conduit in the same trench as mains and under the main.ASI wire shall be #14 or larger solid copper U.L. approved underground direct burial cableand shall be continuous with no splices from controller to solenoid valve.15. Valve locations are schematic and shall be adjusted in the field. Each valve shall be in aseparate valve box (10" x 16") min.). When grouping valve boxes in grass or groundcoverareas, set boxes a minimum of 12" apart to allow grass or groundcover to grow betweenthem. When possible, hide valve boxes in shrub beds, a minimum of 12" from edge of beds.Set all valve boxes, concrete or plastic, in ground with cover flush with finish grade, and level,with a minimum of 6" of pea gravel at the bottom of the box, with at least 2" of clearancefrom the bottom of the valve to the top of the gravel.16. TESTING: Notify the Landscape Architect in writing when testing will be conducted.Conduct test in the presence of the Landscape Architect. After all PVC assembly is completedthe lines shall be flushed to insure that no rocks, sand, or other foreign debris remains in thelines. The mains shall be filled with water and all outlets shall be capped and plugged. Themain shall be pressurized to 100 PSI for a minimum of one hour. No section of the main willbe approved if the pressure drops more than 5 PSI at the end of the one hour period. Leaksshall be repaired immediately and the system shall be re-tested until found satisfactory by theLandscape Architect.MINI-CLIK II RAIN SENSOR(install where rainfall is unrestricted)(as specified)(same size as meter)ELEC. SOLENOID VALVEBACKFLOW PREVENTIONGATE VALVEWATER METER(in plastic valve box)PVC MAINELECTRIC CONTROLLERUL APPROVED CONTROL WIREFINISH GRADEP.V.C. LATERALAMETEK VALVE BOX OR EQUALSOLENIOD VALVE6" PEA GRAVELGATE VALVE12"
12"CONNECTION TO METER DETAILN.T.S.IRRIGATION SYSTEM ONLYN.T.S.TYPICAL SOLENOID VALVE ASSEMBLYN.T.S.FLEXIBLE SWING JOINT DETAILN.T.S.SPRINKLER ON RISER DETAIL FOR SHRUB AREASN.T.S.WEATHERPROOF, NON-METALLICTERMINUS. UL APPROVEDRAIN SENSOR MOUNTED TO PIPERAIN SENSOR DETAIL#6 SOLID COPPER CONDUCTOR(BARE OR WITH GREEN COLOREDINSULATION.)UL APPROVED GROUND CLAMPATTACH PRIOR TO PAINTING14" WIDE MIN. NYLON "LOCK TIGHT"BANDS 24" 0.C.1-1-14" SCH 40 GALV STEEL PIPE POST10' LONG X 34" DIA COPPER CLADGROUND RODN.T.S.FINISH GRADEPVC CONDUIT CAST INTOFOOTING2" MIN. ABOVE FINISH GRADEUL APPROVED NON METALLICWEATHERPROOF PULL-BOXUL APPROVED NON METALLIC UVRESISTANT, RIGID CONDUIT SIZE ASNEEDED.SMOOTH FINISHED CONCFOOTING SLOPED TO DRAIN6"12" MIN. DIA.3' MIN.4"MIN.TO CONTROLLER18" MIN.5'-0"18"THREADED GALV STEEL PIPE ENDNOTE:ALL WIRE CONNECTIONS SHALL BE APPROVED WATERTIGHT CONNECTIONS.FINISH ENTIRE ASSEMBLY, EXCEPT FOR EQUIPMENT, WITH FLAT BLACK ACRYLIC ENAMEL PAINT.PRIME METALLIC SURFACES WITH ZINC CHROMATE PRIOR TO FINISHING.CAP18"MAIN (see plan for size)CAP WIRE ENDS (wiring for zones)PVC CONDUITPVC 1" RISERSLIP FITTINGDETAIL OF STUB-OUT FOR FUTURE USEN.T.S.PLASTIC VALVE BOX(size as required)PLAN VIEWN.T.S.ELEVATION VIEWN.T.S.METER VAULT2"6"CONC. SLABWITH #4 @12" EW60" MAX.TEST COCKBALL VALVECONC. SLABBALL VALVEMETER VAULT8"8"8"8"PLPLNOTES:-MATERIALS: PIPES AND FITTINGS SHALL BE APPROVED BY ASAE STANDARDS APPENDIX F .-THE ASSEMBLY SHALL BE INSTALLED WITH MINIMIUM HORIZONTAL CLEARANCES OF 30 INCHES FREE FROMOBSTRUCTIONS IN ALL DIRECTIONS.-GUARD POSTS SHALL BE INSTALLED IF THE ASSEMBLY IS EXPOSED TO POSSIBLE DAMAGE FROM VEHICULARTRAFFIC, AS DETERMINED BY THE DEPARTMENT.-THE ASSEMBLY SHALL BE INSTALLED IN AN ACCESSIBLE LOCATION, APPROVED BY THE DEPARTMENT.-PIPING SHALL BE SCHEDULE 40 BRASS OR TYPE K COPPER PIPE WITH THREADED FITTINGS IN ACCORDANCEWITH WASD CONSTRUCTION SPECIFICATIONS FOR DONATION WATER MAINS. PVC PIPING IS NOTACCEPTED BY WASD.-THE DEPARTMENT SHALL HAVE UNRESTRICTED AND CONTINUOUS ACCESS TO THE VACUUM BREAKERASSEMBLY.-SEE SPECIFICATIONS AND CONTACT DEPARTMENT FOR CURRENTLY APPROVED TYPES OF BACKFLOWPREVENTION ASSEMBLIES AND PRESSURE VACUUM BREAKERS (SEE WS 4.18 SHEET 4 OF 4 OR ON THIS SHEET)BACKFLOW PREVENTION ASSEMBLY DETAILBACKFLOW PREVENTION ASSEMBLY PER LOCAL CODES AND ORDINANCESBACKFLOW PREVENTION ASSEMBLY PER LOCAL CODES AND ORDINANCES153
154
490 NW South River Dr.
Miami FL 33128
Phone: (305)901-1228
City of South Miami September 3, 2020
Procurement Division
6130 Sunset Drive
South Miami, Fl 33143
Attn: Steven P Kulick
Chief Procurement Officer
RE: Sunset Drive Modifications
RFP # PW2020-19
Mr. Kulick
UAG Construction is please to present our bid proposal for the above mentioned project. With
over 20 years of combined experience in FDOT Roadway projects UAG brings a unique skill set
that will be applied to this project to ensure its timely completion.
Over the past 4 years UAG Construction has successfully self-performed the following scopes:
Drainage
o Storm Water Management
o French Drain / Exfiltration Trenches
o Manhole and Utility Adjustments
Clearing
o Concrete Removal
o Asphalt Removal
o Site Clearing
o Debris Disposal
Asphalt
o Trench Restoration
o Miscellaneous Asphalt for Pedestrian Paths
o Roadway Asphalt
Material Purchasing
Crew Management – Subcontracted
Concrete
o F, D, E, Valley Curb
o 4” & 6” Sidewalk
o 6” Driveways
o Flumes
UAG is a growing company with personnel that have a variety of skill sets. Below please find a
listing of our active personnel
155
Page 2 of 2
(2) Project Managers
(4) Superintendents
(1) Office Manager
(3) Operators
(4) Skilled Laborers
Below please find our list of equipment and resources
308 Caterpillar Excavator
T190 Bobcat
CB14 Caterpillar Roller
Tampers
Street Saws
Concrete Cutting Saws
Demolition Hammers
Construction Trailer
Utility Vehicles
In addition to our owned resources we have open equipment rental accounts with the
following venders
Kelly Tractor
Synergy Equipment
Marcinkoski Gradall
Action Rental
UAG Construction is currently approved as a Prime Bidder with FDOT in District 4, District 6,
and Florida Turnpike. We have attached our Payment and Performance Bond for reference.
UAG Construction is looking forward to starting a relationship with the City of South Miami with
this project and hopefully working on future roadway improvements within the city limits.
Sincerely,
Andy Diaz
Senior Project Manager
156
157
158
159
160
161
162
163
164
165
166
167
168
169
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
1 110-1-1 Clear and Grubbing L.S. 1 432.00$ 432.00$
2 110-4 Removal of Existing Concrete S.Y. 80 19.85$ 1,587.60$
3 110-4 Removal of Existing Concrete Curb L.F. 390 8.31$ 3,240.00$
4 104-1
Prevention, Control and Abatement of Erosion and
Water Pollution L.S. 1 1,296.00$ 1,296.00$
5 110-15-2 Existing Tree Protection and Preservation L.S. 1 1,296.00$ 1,296.00$
6 160-4 Type "B" Stabilization (12") (Min. L.B.R. of 40) S.Y. 36 93.30$ 3,358.80$
7 210-2 Limerock Base (8") (Primed) S.Y. 36 90.39$ 3,254.04$
8 327-70-1 Milling Existing Asphalt Pavement (1" Average Depth) S.Y. 540 10.91$ 5,890.32$
9 337-7-82
Asphalt Concrete Friction Course Traffic C, FC-9.5,
High Polymer (1" Thick) (Resurfacing)TON 50 218.70$ 10,935.00$
10 520-1-10
Concrete Curb and Gutter Type "F" includes Cost of
Limerock L.F. 175 23.20$ 4,060.80$
11 520-2-4 Concrete Curb Type "D" includes Cost of Limerock L.F. 165 23.76$ 3,920.40$
12 520-3 Concrete Valley Gutter L.F. 50 14.80$ 739.80$
13 522-1 Concrete Sidewalk (4" Thick) S.Y. 80 49.48$ 3,958.20$
14 526-1 Pavers, Architectural, Sidewalk S.Y. 40 54.00$ 2,160.00$
15 527-2 Detectable Warning Surface S.F. 30 32.40$ 972.00$
16 570-1-2
Sodding (Pensacola Bahia or Match Existing) (Includes
Watering and Maintenance)S.Y. 180 16.95$ 3,051.00$
17 700-1-60 Single Post Sign, Remove A.S. 1 270.00$ 270.00$
18 706-3 Retro-Reflective Pavement Markers (RPMs) EACH 21 4.32$ 90.72$
19 711-15-101 Thermoplastic (white) (solid) (6") L.F. 700 1.08$ 756.00$
20 711-15-201 Thermoplastic (yellow) (solid) (6") L.F. 260 1.08$ 280.80$
21 711-11-141 Thermoplastic (white) (skip) (6") L.F. 100 1.08$ 108.00$
Sub TOT 51,657.48$
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
22 425-6 Adjust existing valve boxes & meter boxes L.S. 1 540.00$ 540.00$
23 425-74-1 Clean Existing Catch Basins EACH 2 810.00$ 1,620.00$
Sub TOT 2,160.00$
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
24 580-5-22 Landscaping (Including Tree Removal & Irrigation) L.S.1 59,207.31$ 59,207.31$
25 590-70 Irrigation L.S. 1 8,553.60$ 8,553.60$
Sub TOT 67,760.91$
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
26 101-1 MOBILIZATION(10%) L.S. 1 18,350.00$ 18,350.00$
27 102-1 MAINTENANCE OF TRAFFIC L.S. 1 18,142.68$ 18,142.68$
28 102-14 TRAFFIC CONTROL OFFICER H.R. 120 59.40$ 7,128.00$
29 SUE-001
ADVANCED UTILITIES EXPLORATION SOFT
DIGGING EXPLORATION L.S. 1 1,620.00$ 1,620.00$
30 PERM-
ALLOW PERMIT ALLOWANCE(5%) L.S. 1 8,340.95$
31 CONT CONTINGENCY(10%) L.S. 1 8,340.95$
Sub TOT 61,922.59$
TOT OPT A 183,500.98$
OPTION A: US-1 TO SW 62ND AVE
ROADWAY PAY ITEMS (OPTION A)
DRAINAGE PAY ITEMS (OPTION A)
LANDSCAPING PAY ITEMS (OPTION A)
MISCELLANEOUS ITEMS (OPTION A)
170
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
32 580-5-22 Landscaping ( Including Tree Removal & Irrigation) L.S.1 199,721.79$ 199,721.79$
33 590-70 Irrigation L.S. 1 9,266.40$ 9,266.40$
Sub TOT 208,988.19$
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
34 101-1 MOBILIZATION(10%) L.S. 1 13,413.75$ 13,413.75$
35 102-1 MAINTENANCE OF TRAFFIC L.S. 1 8,400.00$ 8,400.00$
36 102-14 TRAFFIC CONTROL OFFICER H.R. 120 57.75$ 6,930.00$
37 SUE-001
ADVANCED UTILITIES EXPLORATION SOFT
DIGGING EXPLORATION L.S. 1 1,575.00$ 1,575.00$
38 PERM-
ALLOW PERMIT ALLOWANCE(5%) L.S. 1 11,965.35$ 11,965.35$
39 CONT CONTINGENCY(10%) L.S. 1 25,127.23$ 25,127.23$
Sub TOT 67,411.33$
TOT OPT B 276,399.52$
MISCELLANEOUS ITEMS (OPTION B)
OPTION B: SW 62ND AVE TO SW 69TH AVE
LANDSCAPING PAY ITEMS (OPTION B)
171
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
1 110-1-1 Clear and Grubbing L.S. 1 432.00$ 432.00$
2 110-4 Removal of Existing Concrete S.Y. 80 19.85$ 1,587.60$
3 110-4 Removal of Existing Concrete Curb L.F. 390 8.31$ 3,240.00$
4 104-1
Prevention, Control and Abatement of Erosion and
Water Pollution L.S. 1 1,296.00$ 1,296.00$
5 110-15-2 Existing Tree Protection and Preservation L.S. 1 1,296.00$ 1,296.00$
6 160-4 Type "B" Stabilization (12") (Min. L.B.R. of 40) S.Y. 36 93.30$ 3,358.80$
7 210-2 Limerock Base (8") (Primed) S.Y. 36 90.39$ 3,254.04$
8 327-70-1 Milling Existing Asphalt Pavement (1" Average Depth) S.Y. 540 10.91$ 5,890.32$
9 337-7-82
Asphalt Concrete Friction Course Traffic C, FC-9.5,
High Polymer (1" Thick) (Resurfacing)TON 50 218.70$ 10,935.00$
10 520-1-10
Concrete Curb and Gutter Type "F" includes Cost of
Limerock L.F. 175 23.20$ 4,060.80$
11 520-2-4 Concrete Curb Type "D" includes Cost of Limerock L.F. 165 23.76$ 3,920.40$
12 520-3 Concrete Valley Gutter L.F. 50 14.80$ 739.80$
13 522-1 Concrete Sidewalk (4" Thick) S.Y. 80 49.48$ 3,958.20$
14 526-1 Pavers, Architectural, Sidewalk S.Y. 40 54.00$ 2,160.00$
15 527-2 Detectable Warning Surface S.F. 30 32.40$ 972.00$
16 570-1-2
Sodding (Pensacola Bahia or Match Existing) (Includes
Watering and Maintenance)S.Y. 180 16.95$ 3,051.00$
17 700-1-60 Single Post Sign, Remove A.S. 1 270.00$ 270.00$
18 706-3 Retro-Reflective Pavement Markers (RPMs) EACH 21 4.32$ 90.72$
19 711-15-101 Thermoplastic (white) (solid) (6") L.F. 700 1.08$ 756.00$
20 711-15-201 Thermoplastic (yellow) (solid) (6") L.F. 260 1.08$ 280.80$
21 711-11-141 Thermoplastic (white) (skip) (6") L.F. 100 1.08$ 108.00$
Sub TOT 51,657.48$
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
22 425-6 Adjust existing valve boxes & meter boxes L.S. 1 540.00$ 540.00$
23 425-74-1 Clean Existing Catch Basins EACH 2 810.00$ 1,620.00$
Sub TOT 2,160.00$
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
24 580-5-22 Landscaping (Including Tree Removal & Irrigation) L.S.1 280,000.00$ 280,000.00$
25 590-70 Irrigation L.S. 1 17,820.00$ 17,820.00$
Sub TOT 297,820.00$
ITEM PAY ITEM DESCRIPTION UNITS QUANTITY UNIT PRICE TOTAL
26 101-1 MOBILIZATION(10%) L.S. 1 21,600.00$ 21,600.00$
27 102-1 MAINTENANCE OF TRAFFIC L.S. 1 10,800.00$ 10,800.00$
28 102-14 TRAFFIC CONTROL OFFICER H.R. 240 59.40$ 14,256.00$
29 SUE-001
ADVANCED UTILITIES EXPLORATION SOFT
DIGGING EXPLORATION L.S. 1 1,620.00$ 1,620.00$
30 PERM-
ALLOW PERMIT ALLOWANCE(5%) L.S. 1 19,995.67$ 19,995.67$
31 CONT CONTINGENCY(10%) L.S. 1 39,991.35$ 39,991.35$
Sub TOT 108,263.02$
TOT OPT C 459,900.50$
MISCELLANEOUS ITEMS (OPTION C)
LANDSCAPING PAY ITEMS (OPTION C)
DRAINAGE PAY ITEMS (OPTION C)
OPTION C: US-1 TO SW 69TH AVE (OPTION A & B)
ROADWAY PAY ITEMS (OPTION C)
172
173
174
175
176
177
178
179
180
181
182
183
184
185
186
187
188
189
190
191
192
193
194
195
196
197
198
199
200
201
RESPONDENT QUALIFICATION STATEMENT
SUNSET DRIVE MODIFICATIONS
RFP#PW2020-11
The response to this questionnaire shall be utilized as part of the CITY’S overall Proposal Evaluation and
RESPONDENT selection.
1. Number of similar projects completed,
a)In the past 5 years
In the past 5 years On Schedule
b)In the past 10 years
In the past 10 years On Schedule
2. List the last five (5) completed similar projects.
a)Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
b) Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price
c) Project Name:
Owner Name:
5IF4BOETPG,FZ#JTDBZOF1PPM1BUIT
5IF4BOETPG,FZ#JTDBZOF"TTPDJBUJPO*OD
0DFBO%SJWF
,FZ#JTDBZOF'-
%BZT
*&YQSFTT4FHNFOU"#
$PNNVOJUZ"TQIBMU$PSQPSBUJPO
/8UI4USFFU
.JBNJ'-
%BZT
/P%BUF5JNFJTPGUIF&TTFODF
.BZ
5IF4BOETPG,FZ#JTDBZOF$PNNPO"SFBT
5IF4BOETPG,FZ#JTDBZOF"TTPDJBUJPO
202
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
d) Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
e) Project Name:
Owner Name:
Owner Address:
Owner Telephone:
Original Contract Completion Time
(Days):
Original Contract Completion Date:
Actual Final Contract Completion Date:
Original Contract Price:
Actual Final Contract Price:
0DFBO%SJWF
,FZ#JTDBZOF'-
%BZT
+VOF
.BZ
43&YQSFTT-BOFT
$PNNVOJUZ"TQIBMU$PSQPSBUJPO
/8UI4USFFU
.JBNJ'-
"VHVTU
"QSJM
203
3. Current workload
Project Name Owner Name Telephone Number Contract Price
4. The following information shall be attached to the proposal.
a)RESPONDENT’s home office organization chart.
b)RESPONDENT’s proposed project organizational chart.
c)Resumes of proposed key project personnel, including on-site Superintendent.
5. List and describe any:
a)Bankruptcy petitions filed by or against the Respondent or any predecessor organizations,
b)Any arbitration or civil or criminal proceedings, or
c)
Suspension of contracts or debarring from Bidding or Responding by any public agency brought
against the Respondent in the last five (5) years
6. Government References:
List other Government Agencies or Quasi-Government Agencies for which you have done business within
the past five (5) years.
Name of Agency:
Address:
Telephone No.:
Contact Person:
Type of Project:
5
48UI
5IF4BOETPG,FZ
#JTDBZOF
.BSBUIPO,FZ
$PNNVOJUZ"TQIBMU$PSQ
8BSSFO4USJGMJOH
5IF4BOET$POEPNJOJVN
)BMMFZ&OHJOFFSJOH
'MPSJEB%FQBSUNFOUPG5SBOTQPSUBUJPO
4VXBOOFF4USFFU5BMMBIBTTFF
'MPSJEB
204
Name of Agency:
Address:
Telephone No.:
Contact Person:
Type of Project:
Name of Agency:
Address:
Telephone No.:
Contact Person:
Type of Project:
205
206
207
208
209
210
211
212
213
214
LIST OF PROPOSED SUBCONTRACTORS AND PRINCIPAL SUPPLIERS
SUNSET DRIVE MODIFICATIONS
RFP #PW2020-XX
Respondent shall list all proposed subcontractors, if subcontractors are allowed by the terms of this
Solicitation to be used on this project if they are awarded the Contract.
Classification of Work Subcontractor Name Address Telephone, Fax &
Email
Other:
This list shall be provided as a part of Respondents submittal to the City of South Miami and in response to this
RFP.
END OF SECTION
.054JHOBHF
4USJQJOH
5SVDLJOH
.BUFSJBM
.BUFSJBM
"TQIBMU
"DNF#BSSJDBEF
3PBESVOOFS
$"5SVDLJOH
7VMDBO
8IJUF3PDL
3BOHFS.BUFSJBMT
#VSSJT3E
%BWJF
'-
JOGP!BDNFCBSSJDBEFTDPN
/8UI"WF
)JBMFBI(BSEFOT
'-
/85)45
1&.#30,&1*/&4
'-
/8UI4U
.JBNJ
'-
1IPOF
'BY
/8OE"WF
)JBMFBI
'-
/8OE"WF
)JBMFBI
'-
*OGP!832VBSSJFTDPN
1IPOF
'BY
..(SPVOEXPSLT-BOETDBQF 484USFFU
)PNFTUFBE'-
1IPOF
'BY
NNHSPVOEXPSLT!ZBIPPOFU
215
216
217
218
219
220
221
222
223
224
225
226
https://southmiamiflgov.sharepoint.com/Finance/procurement/Shared Documents/Purchasing/Request for Proposals & Qualification
(RFPs)/2020 ver3 SUNSET DRIVE MODIFICATIONS/PRE BID/Pre-Bid Meeting RFP PW2020-19 8.25.20 .doc
VIRTUAL
Non-Mandatory Pre-Bid Conference
Sign-In Sheet
Date:
August 25, 2020
RFP Title: Sunset Drive Roadway & Landscaping
Modifications
RFP No.: PW 2020-19
Please Print Clearly
Name/Title Company Name/ E-mail Address Telephone No.
1 Johnny Dao Florida Construction Engineering 305) 883-7601
jdao@fcebuild.com
2 Kiehl Semler GSLA DESIGN Kiehl Semler <kiehl@gsladesign.com>
3 J. Quintero VisualScape
4 Nicloe Perez SFL Properties
5 Carlos Herdocia Stantec
6
7
8
9
10
11
227
https://southmiamiflgov.sharepoint.com/Finance/procurement/Shared Documents/Purchasing/Request for Proposals & Qualification
(RFPs)/2020 ver3 SUNSET DRIVE MODIFICATIONS/PRE BID/Pre-Bid Meeting RFP PW2020-19 8.25.20 .doc
228
Member Name CITY OF SOUTH MIAMI
Bid Number RFP PW2020-19
Bid Name SUNSET DIRVE RAODWAY & LANDSCAPING MODIFICATIONS
3 Document(s) found for this bid
22 Planholder(s) found
584 NOTIFIED
Supplier Name Address1 City State Zip Phone Attributes
Action Property Services 1825 Main Street
Fort
Lauderdale FL 33326 9546513177
Blue Native Landscape &
Irrigation 201 SW 2nd Ave Florida City FL 33034 3058724050
Bob's Barricades 921 Shotgun Rd Sunrise FL 33326 9544232627
C&I Construction and
Design Inc.
14031 SW 143 Court
Unit 6 Miami FL 33186 3052556067
Calvin, Giordano &
Associates, Inc.
1800 Eller Drive
Suite 600
Fort
Lauderdale FL 33316 9549217781
Coco Tree Service, Corp 3300 NE 192 ST AVENTURA FL 33180 3057289445
ConstructConnect 3825 Edwards Rd Cincinnati OH 45209 8772271680
DeAngelo Brothers LLC
100 North Conahan
Drive Hazleton PA 18201 5704591112
Dodge Data
4300 Beltway Place,
Ste 150 Arlington TX 76018 4133767032
FG Construction LLC 2701 N.W. 35th Ct.Tamarac FL 33309 9548564925
Asian/Hawaiia
n Owned
Florida Blacktop Inc.
1287 W. Atlantic
Blvd.
Pompano
Beach FL 33069 9549439700
Kailas Contractors 3450 W 84 Street Hialeah FL 33018 3057220099
Kalex Construction &
Developement Inc 11401 SW 40TH ST.MIAMI FL 33165
Magnum Construction
Management, LLC
6201 SW 70th St,
1st Floor Miami FL 33143
Miliani Construction Corp 2051 Nw 112 Ave Miami FL 33172 3054244414
Hispanic
Owned
Paveway Systems, Inc.
114 Indian Lakes
Lane Florahome FL 32140 3866591316
Small
Business,
Woman
Owned
Reef Tropical 1A Barracuda Lane Key Largo FL 33037 3053672005
SFL Property Maintenance
Corp 17718 Sw 139 Court Miami FL 33177
Sun Eagle General
Contractors, Corp.12300 SW 130 st Miami FL 33186 3057413847
Superior Landscaping &
Lawn Service, Inc.2200 NW 23 Avenue Miami FL 33142 3056340717
The Green Experts
4121 SW 47th Ave
#1335 Davie FL 33314 8887700072 Small Business
VisualScape Inc.17801 NW 137 Ave Miami FL 33018 3053622404
229
230
231
232
233