JVA RFP PW2016-18 8.25.16ORIGINAL
The City of South Miami, Florida (hereinafter referred to "CSK ) throue, its chief executive officer (City
Manager) hereby solicits sealed proposals responsive to the City's request (hereinafter referred to "Request
for Proposals" or " ,, , Ail references in this Solicitation (also referred to as an "Invitabon for Proposals" or
"Invitation to id" to "City" small be a reference to the City Manager, or the manager's designee, for the City of
South Miami unless otherwise specifically defined.
The Cit:f is here-by reaues i sensed proposals in response to SW 78 Street & SW 62 Avenue ay
Improvements," :.'.;.u,::°:a S «.x..,sti.>., is 'to contra u; jog = . "< ,v e,ev necessary ,for t1he Completion
rcq -nn ....£c.. a .c.x w-111 the Scope of w--« _ 6, .. r a r,e._, a Al and. the Schedule of .._.._ux.....y E",..
Au on .., '"a a. .� the �,�; ,s.,7.,...._ _..,u. F .�, r,N and S a�» L ,� 4.� o a ,,� �� t < <; a A '� ��.. eke �_ plans <,a� � r
specifications, ff any, described in this Sol"citarrw. n (hereinafter referred ed to €mss u5 ske -cl or "Project"",
interested persons who wish to respond to this Solicitation can obtain the complette Solicitation package at
Orty ClerWs office Monday through Friday from 9:00 am. to 4:00 p.m. or by accessing the following webpal
http-llwww.southmiamift.gov/ which is the City of South Miami's web address for solicitation informad
Proposals are subject to the Standard Terms and Conditions contained in the complete Solicitation Packa
including all documents listed in the Solicitation,
Maria M, Menendez, CMC
City Clerk, City of Sourth Miami
SCOPE OF SERVICES and SCHEDULE OF VALUES
SW 78 Street & SW 62 Avenue Roadway Improvements
RFP #PW2016-1 8
the he Scope of Services and the Schedule of Values, if any, are set forth in the attached EXHIBIT I
SCHEDULE OF EVENTS
E
END OF SECTION
No
Event
Date* E
Advertisement/ Distribution of Soficimbon & Cone of
E
ISilence begins
/
11:00 AM
F
A Pre- F g
8/10/201
.,.. ..�.�., . � «. m e .. n , Questions .o.
8` _ S, .�, 016
10 03,10, AM
4
iDeadline to t Responses to Questions
8/ 9/20
10.00 AM
el s e Re
$12512016 1
10-00 AM
END OF SECTION
s s
Ro
This checklist indicates the forms and documents required to be submitted for this solicitation and to be Presented
by the deadline set for within the solicitation. Fulfillrnent of all solicitation requirements listed is mandatory for
consideration of response to the solicitation. Additional documents may be required and, if so, they will be
derid ed in an addendum to this Solicitation. The response shall include the following items:
Proposal posal Packa shall consist of one I I ) original unbound
proposal, one I) additional copy and one t I digital or comparable
-'
medium including Flash Dnve, DVD or CD) copy I z
Submit this checklist along with your Proposal indicating the completion and submission of each required forms
and/or documents.
END OF SECTION
JE-^ MIT 2
Construction Bid roam EXH1131T
Signed Contract Documents ents (All — including General Conditions
Supplementary Conditions EXHIBIT 4, S,
and if attached) &6
Performance and Payment Bonds Condition Award. Not
required with Serb at EXHIBIT 7 & 8
Respondents Qualification Statement
List of Proposed Subcontractors and Principal Suppliers
Non-Collusion Affidavit
C
Public Ent4 Crimes and Conflicts of Interest
Drug Free
Workplace
Acknowledgement of Conformance with OSHA Standards
Affidavit Concerning Federal & State Vendor Listings
Related Party Transaction Verification Farm
Presentation Team Declaration/Affidavit of Representation
Submit this checklist along with your Proposal indicating the completion and submission of each required forms
and/or documents.
END OF SECTION
RESPONDENT QUALIFICATION
SW 78 Street & SW 62 Avenue Roadway Improvements
The response to this questionnaire shall be utilized at pa =r—, of the CITY'S overall Proposal Evaluation and
RESPONDENT selection.
1, Number of similar proiects completed,
a) In the passe S years 12..
In the past S years On Schedule 12
b In the past 10 years 13
In the past 10 years On Schedule
2, List the last three (3) completed similar p` olecEs, --013 , r , 3ze Improvement Project fOr J.i-f < p-le .
SfteS- NE 911, Street and NE 8711, Stee r�ronn NE
rz z a: '' ...... .
_..
r ne A_ d e-ss: NW -1 Sree
Owner Telephone: 786-3715-0004
Original Contract Completion pletion Ti e
gays;: 180 Day
Thomas ° , Peps
121:012015
Original Contract Completion Efate; May 2014
Owner Telephone:
May 2214 -
$332.939.13
$632.929.:0
2013 Garden torm Sewers- Phan: 1 project No B30183
Cav of Miami
444 NW 2nd Ave f i s. FL 33 131
305 -724 -3340
Original Contract rnpleti n Time
( ays "r 133 Guys
Original Contract C O Dleti n Date: .lure 2014
Actual Final Contract Completion
Date: june 2014
Orl&al Contract Pride, $770.078, 50
Actual Final Contract Price $776,678,50
2015- Englewood Road Storm Sewer Improvements
C) Project Name:
Phase It Project No 830011
Owner Name:
City of Miami
Owner Address:
444 NW 2nd Ave Miami, FL 33131
Owner Telephone:
305 - 724 -8840
Original Contract Completion Time
Cit y of Miami
(Days):
150 Days
Original Contract Completion Date:
May 2015
Actual Final Contract Completion
Date:
May 2015
Original Contract Price:
$1.896,806.72
Act_,ai F'nai Contrac° Prim:
3t 895 806 72
3. Current workload
Project Name
T6339- SR 968 from
W Flagler to E of 17th
Owner
Florida department of
Transportation
305 - 654 -7020
$8,785.728 75
2015- NW 33rd Street
Roadway Improvements
Cit y of Miami
305 -416 -2588
$5,899,864.98
2014- PTP Roadway
Improvements for NW 74th Street
Miami Dade County
Public Works
786-375 -0003
$6,447,92922
Northeast Transit HUB
Enhancements 163rd St Mall
Miami -Dade Count Transit
y
786 473 -5250
$1,374,797.43
4. The following information shall be attached to the proposal.
a) RESPONDENT'S home office organization chart. See Attached
b) RESPONDENT's proposed project organizational chart. See Attached
c) Resumes of proposed key project personnel, including on -site Superintendent. See Attached
S. List and describe any:
Thomas F. Pepe
12/1 0120 15
13
'ist other Government Agencies or Quasi-Government Agencies for which you ihave done business
within the past five (5) years,
Name of Agency: City of Miami
Address'. 444 NVV 2nd Avenue, Miami, F! 33131
ele-nhone No.� 0J 5 - 4 It 6" - 9'
Type of Proiecc:
Multiple Proiects
Name of Agency:
City of Hollywood
Address:
4600 Holh0000d Blvd, HolWwood, FL 33412E
Telephone No.:
954-805-3681
Contact Person:
Clese Aurelus
Type of Project:
8-Inch Water Main and Site Restoratior
Name of Agency:
Miami -Dade Coun!y_ _______ _
Address:
1 _c°�ri4, � Iiion and Ope-_n Spacce�
Miami-Dade 1"1 our i!y
Telephone No,,-
786-586-8325
Contact Person:
Lydia Sal as
Type of Project,
New Construction and Recons'ruction of Bike Pa 9-
0
LIST OF PROPOSED SUBCONTRACTORS AND PRINCIPAL SUPPLIERS
SW 78 Street & SW 62 Avenue Roadway Improvements
RFP #PW2016 -18
Respondent shall list all proposed subcontractors, if subcontractors are allowed by the terms of this Solicitation to
be used on this project if they are awarded the Contract
Classification of Work
Landscape
Subcontractor Name
Address
Telephone, Fax &
Email
Sodding and Turf Work
Electrical
Irrigation
Paving
Graphics
Utilities
Excavation
Building
Structures
Plumbing
Painting
Testing Laboratory
Soil Fumigator
Signs
pgJ Striping
9800 NW South River Drive
786 - 258 -3929
305 -485 -1873
jackie pjstnping.com
Other:
This list shall be provided to the City of South Miami by the apparent lowest responsive and responsible Bidder
within five (5) business days after Bid Opening.
Thomas F. Pepe
121!012015
END OF SECTION
15
STATE OF FLORIDA
COUNTY OF
MIAMI -DADS
ACKNOWLED9EME-N!
STATE OF FLORIDA
COUNTY OF MIAMI -Lea DE
On this the 25 day of 20j Q ry Public of rdhe Swte
before me, the undersigned Now
of Florida, personally appeared (Name(s) of individual(s) who appeared before notary)
Im
M A afM' n e) isAre fibscribed to the within
instrument, and helshe/they acknowledge that iSselthr ccd it : -,-/
WITNESS my hand and official sue.
NOTARY e
SEAL OF OFFICE:
(Name €z Notary Public Print, Stamp or qpe as
Personally kno to m, or
Personal identification,
Type of identification Produced
mid take an oath, or
Did Not rake an oatch,
The award of any contract hereunder is subject to the provisions of Chapter 112, Florida State
Statutes. Respondents rust disclose with their Proposals; the name of any officer, director, partner, associate or
agent who is also an officer or employee of the City of South, Miami or its agencies.
5-00VORN STATEMENT PURSUANT TO SE,('-,-r'10N 28-1-133 2,
N �. V�. _ .LAMES
THIS F0,RM KUST BE SSIGNED ANE)SWORN TO IN THE PRESE-MICE-OF A NOTARY PUBLIC OR OTHER
OFFICIAL AUTHORIZED TO ADMINISTER OATHS,
This sworn statement is submitted to
ffit of South Miami
[print ,Fame of the public entity)
by dose M Alvarez President
[Print individual's name and title
for dIA Fri irr €r ctrwtr, lnc.
print name of entity submitting sworn statement]
whose business address is 6600 NW 32 Avenue
and (if applicable) its Federal Employer Identification Number (FEIN) is 48-1277685 (if the
entity has no FERN, include the Social Security Number of the individual signing this sworn statement
1
3. 1 understand that "convicted" or "conviction" as defused in Paragraph 287.133 41 ) b, Florida
Statutes, means a finding of guilt or a conviction of a public entity crim=e, with or without an adjudication
of guilt, in any federal or state trial court of record relating to charges brought by indictment or
information after July 1, 1989, as a result of a jury verdict, non-jury trial, or entry of a plea of guilty or
nolo contenders.
4. l understand that an "affiliate" as defined in Paragraph 287,133 1) (a), Florida Statutes means:
a predecessor or successor of a person convicted of a public entity crime; or
(b An entity under the control of any natural person who is active in the management of the entity
and who has been convicted of a public entity crime, The term "affiliate" includes those officers,
Thomas F. Pepe
12/10/2015
Im
I understand that a "person" as defined in Paragnaph 287.1 11 , florid4—Statutgs, means any
natural person or entity organized tinder the Caves of any state or of the United States with the lei
power to enter into a binding contract and which bids or proposal or applies to bid or proposal on
contracts for the provision of goods or services let by a public entity; or which otherwise transacts r
applies to nsact business with a public entity. The to "person" includes those officers, directors,
executives, partners. shareholders, employees, € e . b °s, and agent who are active in management f an
entity.
, Based on information and befiet Line statement which I have marked below is tru in relat=ion to the
e:nt.i`y submit t is sworn state ,t.. f inn icetee ,N h ch statement ap i es,.l.
X Neither the en.-dinry subrnitaxing this sworn smarromern., nor any of its officer-5s, director , ex-,ecutwes,
nor any ffilietre of the ntitr has been char en with and convicted r <; a public entity crime subsequent to
July I � 1 989.
-The entity submitting fng this sworn statement, car one or more of its officers, directors, executives,
partners, shareholders, employees. members, or agents who are active in the management ent of the entity,
or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July
1, 1989,
I UNDERSTAND THAT T HE SUBMISSION OF THIS FORD TO THE CONTRACTING OFFICIO FOP, TIE PUBLIC ENTITY
INDENTIFIED IN PARAGRAPH I (ONE) ABOVE IS FOR THAT PUSUC ENTITY ONLY, ANDITHAT TJ41S FORM IS VALID
THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN HICH IT IS FILED I Aub/UNDFOrAND THAT I AI*
REQUIRED T O INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO"A COO, CT 4 EXCESS S O THE
THRESHOLD L i A 9s UNT PROVIDED IN SECTION 287,017, Fl: I TE BY TWO OF ANY
CHANGE IN THE INFORMATION CONTAINED Its THIS FORM.
Is
Im
ACKNOWLEDGEMENT O CONFORMANCE .22H»°
STANDARDS
TO THE CITY OF SOUTH Maw
Witn ess \ ^
s a TWAVI 40 1#1#_1
The person, or enti
m
before any board, commission or agency of the City within the past two years other than as
follows: (if
necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must
make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath),
(8) No Other Fhmm, nor ?my officers or directors -of that Other Finm or anyone who hars, a financial interest greater
than 5% in trka-t Other Fir- , nor any r,e nnber of - use persons' irnarnediate, farnfly (Le,, spouse, parents, children,
Drot., ers asoi sisuersq nor auny of my innnnediato, famnidy memnibers 'hereina r referred t, wis "Relaaed F r-bes"'I" hays
responded t a salficitasion -by thhe Ohty in, ovtuch � or Finrn that, i represenit or � yone who has a fl'nancial
interest greater thaan 5% in dhe Firm, or any member of those persons' immediate famfly I'Le. spouse, parents,
children, brothers -and sisters' have also responded, offer" t an dhe following:
if
necessary, use a separate sheet to supply additional information that will not fit on dhis line; however, you must
make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath).
[while the ethics code still applies, if the person executing this form is doing so on behalf of a fi r. whose stock is
publicly traded, the statement in this se Lion (8) shall be based solely on the signatory's personal knowledge and
he/she is not required to make an independent investigation into the Other Firm, or the Firm he/she represents, as
to their officers, directors or anyone having a financial interest in those Firms or any of their any member of those
persons' immediate family]
Print Name & fitle. Jose M Alvarez, President
Date- 8/25/2016
IM
Sec. 3A- 1. - Conflict of interest and code of ethics ordinance,
m
Im
m
(Ord. No. 6-99-1680, § 2, 3-2-99)
Editor's rote- Ord, No. 6-99-1680, § 1, adopted 3-2-99, repealed §§ $ I and 8A-2 in their entirety and replaced
them with new §§
-€ and 8A-2, Former §§ —I and 8A-2 permined to declaration of policy and definWons, respectively, and
derived from Ord. No. 634, §§ 1 1 _ ), 1 1 - adopted Jana 1 I , 1 969.
PRESENTATION TEAM I
Pursuant to '92,525(2), Florida Statutes, the undersigned, Jose M Alvarez makes the following
dedaration, under -- enaft-y- of per-jurv:
Listed below are all individuals who may make a presentation on behalf of the entiry that the afflant
represents, Please note; No person shall appear before any committee on behalf of anyone unless he
or she has been listed as part of the firm's presentation team pursuant to this paragraph or unless he
or she is registered with the Clerk's office as a lobbyist and has paid all applicable lobbyist registration
fees.
Jose M Alvarez
10105M
UM
For the purpose of this Affidavit of Representation only, the listed members of the presentation team,
with the exception of any person otherwise required to register as a lobbyist, shall not be required to
4
pay any registratiop le 4s. The Affidavit of Representation shall be filed with the City Clerk's office at the
E
NOTICE OF AWARD
RFP #PW2016-18
mow
A ke r te # 1-1
Alternate 14 2 -
Akernate #1
m
END OF SECTION
In
PUBLIC CONSTRUCTION CONTRACT
TO.- DATE-
PROJECT DESCRIPTION, SW 78 Street yr s Improvements Project RFP
in accordance wfth Plans and specifications, if any, as may be prepared in ol or in part by
CONSULTANT, referenced in the Supplementary Conditions and Contract Documents.
You are hereby notified to commence N/ k in accordance orikh, the >„sntrac dated on or before
ou are to complete the work within 111-g-Al-r—nd- edays, The date of ca pledon of all Work is
(Print s u )
City Manager, or designee
Receipt of the above Notice to Proceed is hereby acknowledged by
on this day of , 2
END OF SECTION
SW 78 Street & S 62 Avenue Roadway Improvements
RFP #PW2016-1 8
1. Scope of Work:
The awarded vendor must obtain any permits required, The pity will waive all City permit fees. Permits
that may be required by other agencies will be the responsibility of the awarded vendor, including
applicable fees.
Work activity is limited to the hours from 7:00 a.m, through 6:00 p.m,, on weekdays from Monday
through Friday.
It. Site Locations:
The project is located on SW 78' Street, between SW 63' Avenue and SVV 62' Avenue, and SW
Avenue between South Dixie Highway and SW 78' Street, inclusive of the intersection at SW 7W` ' St
and SW 62' Avenue. The limits are defined in the exhibit titled "Exhibit 1, Attachment
Construction Plans and Site Locations". I
Values utilized for the purpose of this RFP are approximate, Contractor is responsible to field verify the
areas, and quantities as Der the limits defined by the sketch for each location.
M
i AF i i f 3
PROJECT TO A SINGLE CONTRACTOR BASED ON THE LUMP AMOUNT
Ill. Plans and ltlt
Plans prepared by SRS Engineering, tit d 'Roadway and Sidewalk improvements at 6231 Sal 78th stree '
are a part of this RFP by ay of reference.
K, ° . -jec Duration & Liq i � ate }gages^
The current e,, >.ma..e .. complete, o vt uab int of he D-J .,t_ iS 60 calendar a s ,.,uustin -,.a..
compk—dom The-n—lolplasm paint shall be installed 30 calendar dar. afteer substantial completion, From thhe
Notice to roceed, the project is to be completed in 90 total calendar days.
Note: Liquidated Damages shall be paid by the Contractor at the rate of $1,000,00 dollars per day, plus any
monies paid by the Owner to the Consultant if any, or additional engineering and inspection services, if earn,
associated with such delay.
V. Warranty:
The standard manufacturer's warranty information must be provided in writing for all equipment being
proposed, including installation by an authorized dealer.
Schedule of Values/Summary of Quantities
SW 78 Street & SW 62 Avenue Roadway Improvements
RFP #PW2016-18
Schedule of Values
1 DESCRIPTION
UNIT
QTY.
U. P'i..
Ct
Ncr
110-1-1 1 Clearing and Grubbing I
€
i
8,550000 1
8.500.00
101-1 1 Mobilization
LS
1
118,000 00 18,000,00
102-1 Maintenance of Traffic
LS
1
15,0001001
15,000,0o
MH
80
11 45-00
3600� !
o
SY
'92
1 920.00
582
34, 100-00 1
-
Sy
92
20,00
---------- ---------- . . ........ — – - -- - - ------ ----- ----
'-5-HI, Asp1hi, It Cuncrete 1," Namir al 'resurtw.,:,ng, �'ncL
-T,92
3 34- 1 - 13 bituminous tack coat
T N
225,00
88, 00
425- 1-901 11 Catch Basin Type P as per MDCPW Standards SD-/'-,6
A
A 5rUU 00
443 -70-4 1 Wiltration Trench (18" HDPE)
LF
25
235 00 I
5,3.5.0
NM
0,25
513,000,00
1,250.001
LF
404
3.00 1
1,212.001
LF
345
s 500 1
1,725,001
LF
3
x.00
425,00!
711-11-125 24" Solid White Thermoplastic Paint 1
------------------
LF
t 75
6.00
450�,0101
711-11-211 6" Yellow Therm oplastic Pain t
NM
03
5,00 1
0-00
1 50000 1
711-11-131 6" White Skip (10'-30') Thermoplastic Paint 1
GM
0,05
5,000.00
250,001
711-11-231 6" Yellow Skip (10'-30') Thermoplastic Paint
GM
0.05
5,00000
250001
-111-11-151 6" White Skip (24) Thermoplastic Paint
LF
52
711-11-2SI 1 6" Yellow Skip t2'-4') Thermoplastic Paint
LF
114
1 3,00 1
342001
711-11-170 1 White Arrow
EA
4
1 200,00
800.00 I
480,001
3,200.00
195,679,001
110-1-1 Clearing and Grubbing
This item includes the asphalt pavement removal (asphalt, base and sub-base) and sod removal for new asphalt
pavement as per SRS Engineering Drawings (asphalt removal is approx. 84 SY and sod removal is approx, 154 SY),
102-14 Traffic Control Officer
The off -duty Police officer hours item is an estimate, Selected contractor will be required to apply for a right of way
permit, during which Police will evaluate the MOT plan and assess if an off -duty police officer will be required, if the
contractor believes that more than 80 hours are required for this project, the contractor shall adiust the quantities and
total cost for this item in the proposal. If the number of hours required is less than the proposed number of hours, the
difference shall be credited to the City,
334-1-13 Type S-111 Asphalt Concrete for 1" Norninal resurfacing
R11
Quantities shown in SRS Engineering drawings for asphalt work is included in this ?ay item, The - , (" Thick) is
included in this pay item and shall be replaced with asphalt Type -111.
All concrete work such as curbing, new sidewalk and driveways as depicted in the SRS Engineering Drawings are not to
be included within this RFR„ This work is to be done by others.
"cast for Thermoplastic paint shall include de ter p r a paint,
All Pay items are referring to the T standards and specifications
END OF SECTION
EXHIBIT 2
g
No insurance required by the CITY shall be issued or written by a surplus lines carrier unless authorized
in writing by the CITY and such authorization shall be at the i s sole and absolute discretion- The
iav shill qm_z. 3mhase insumn- from d shall' : intai_= x!-3e in su,.. -,ce w 1 ' a compsny companies
1xvurfully a;-,urhorized to sell insu'r-a—rice in the State of Roricc, on atppro-ved by the StateofFlor"'da, as
a. `` < .,.x r.,.. ,Y
e o P F a.. - . _ . r r o , laim �s et . _,^r . b <_� ,. _e, x arise r w._
< �_� operations r,> ..ate t,..._.a'r_.::. �..,,g- which fz.3 ,y _ mss= < :.e.�, ,,:.. whether
such ..s-per— ations be by the FIRM or by a, Subcontractor or may anyone direcdy or indirectly employed loyed b
any of them, or by anyone for whose acu any of diern may be liable: a) claims under workers'
compensation, disability benefit and other similar empls yee benefit acts which are applicable to the Work
to be performed; b) claims for damages because of bodily injury, occupational sickness or disease, or
death of the FI M's employees, c) claims for damages because of bodily injury, sickness or disease, or
dearch of any person other than the FI la's employees; d) claims for damages insured by usual personal
injury liability coverage; e) claims for damages, rather than to the Work itself, because of injury to or
destruction of tangible prop", including loss of use resulting there from; (f) claims for damages because
of bodily injury, death of person or property damage arising out of ownership, maintenance or use of a
motor vehicle; ) claims for bodily injury or property damage arising out of completed operations; and
(h) claims involving contractual liability insurance applicable to the FIRM's obligations under the Con
1.03 W orlrers' orxrpensatican Insurance at the statutory amount to all employees in compliance with the
"Workers` Compensation Law" of the State of Florida including Chapter 440, Florida Statutes, as presently written
or hereafter amended, and all applicable federal laws. In addition, the policy (ies) roust include: Employers` liability
at the statutory coverage amount, The FIRM shall further insure that all of its Subcontractors maintain appropriate
levels of Worker's Compensation Insurance,
1.i4 2 ercial omprehen ive Genea l liabili t insurance with broad form endorsement, well as
automobile liability, completed operations and products liability, contractual liability, severa aility of interest with
crass liability provision, and personal injury and property damage liability with limits of 1,000,000 combined single
In
m
E, If the FIRM is proVWing professional services, such as would be provided by an architect, engineer,
attorney, or accountant to rums a fear, then in such event and in addition to the above requirements,
the FIRM shall also provide Professional Liability Insurance on a Florida approved form in the amount of
1,000,000 with per claim ff any, coot to exceed of the limit of liability providing for all
sums which the FIRM shall become legally obligated to of as damages for claims arising out f dhe
se -ices. or work perf'ormed by he FIRM sts agents, . representatives, Sub ' antra -c-or s or asvglls, or by
.,... w..<. ,: ,ed for rju, years ,. G :> c P .x,,„.' r _a". e corwtruction vU..w acceptance of any Pro�er- by
this Akgreer-nent, However, l e FIRM ,na.:E. k K. hra a Spe6fic Projiect . , azessio,.w. Liability, Insui a ce. in the
amount t and under r terms specified, abo v .., which is also acceptable, No ,...w..., ce sha"11 be issued by a
surplus li es carrier unless authorized in writing by the city at the city's sole, absolute and unfettered
discretion.
a• ` -•
Is
•
M�W I
RFP #PW2016-1 8
W*V%AA;J1rWAA*1 MJL-
BID FORM
THIS PROPOSAL IS SUBMITTED TO:
Steven Alexander
City Manager
City of South Miami
6130 Sunset Drive
South Miami, FL 33143
I . If this Proposal is accepted, the undersigned Respondent agrees to enter Into a Contract with &,.e Ory of
Sce th Miami in the form inciuded in this Soficl=tion Package and to perforin and furnish all ,vork as
speciffiled or indicated in t a SoliCitation, including as sec fiortin in Exhibit I ,.-Scope of Services) �or the
Proposed Price as set forth below, -- ithM the Cantnac;t TIme an "'11 in, zccardance with the other tue,,rms and
conditions of the Soflic-itAdon Paclaag
1 Respondent accepts all of -, e terms and conditions of the Solicitation and Instructions to Respondents,
including without limitation those dealing with &,e disposition of ProposaUBid Bond, if required. This
Proposal will remain subject to acceptance for 180 calendar days after the day of the Proposal Opening,
The Respondent, by signing and submitting this proposal, agrees to all of the terms and conditions of the
form of contract that is a part of the Solicitation package with appropriate changes to conform to the
information contained in this Bid Form, Respondent agrees to sign and submit the Bonds, if required by
this Solicitation, required insurance documents, and other documents required by the Solicitation,
including the Contract if not already submitted, within ten (10) calendar days after the dare of the City's
Notice of Award.
3. In submitting this Proposal, Respondent represents that
a. Respondent has examined copies of all the Solicitation Documents and of the following Addenda, if any
(receipt of all which is hereby acknowledged.)
Addendum No. I & 2 Dated: 8/812016 & 8/1112016
b. Respondent has familiarized himself with the nature and extent of the Contract Documents, the proposed
work, site, locality, and all local conditions and laws and regulations that in any manner may affect cost,
0
a, € his Proposal is genuine and not rnade in the tnverest of or on behal-: of any undisclosed person, firm or
corp-or"'ition, arl"d Is not subrmrtedi Pursuant ric any agreement or rules of anty group, associari On'
�. .., . e ha, . _ _.. 4 , ,. w_ .. _.�... .� ....�.. �. w.._ a ,..
, m, at ,
„.� w: ., .. ..,. . _,_... , ..�. „� r... .,_ . . F .__n,' s.� ..�.. _ ..,_..,..,.. .
CITY,
otherw;se to obtain, for itself any a,-'-' vanaage over any other Resporident or over the Respondent understands and agrees that the Contract Price is the mount that it needs to furnish and
install all of the Work complete and in place. The Sched :le of Values, if required, is provided for the
purpose of Proposal Evaluation and when initiated by the CITY, It shall form the basis for calculating the
pricing of change orders, The Contract Price shall not be adjusted in any way so as to result in
deviation from the Schedule of Values, except to the extent that the CITY changes the Scope of the
Work after the Contract Cate. As such, the Respondent shall furnish all labor, materials, equipment,
tools, superintendence and services necessary to provide a complete, in place. Project for the Proposal
Price, If this Solicitation rewires the completion of a Cost and T echnical Proposal, as may be set forth in
in an exhibit to this Solicitation, such proposal must be attached to this Bid Farm and will take
the place of the Lump Sum price, otherwise, the Contract 'rice for the completed work is
as follows:
LUMP SUM BASF PRICE: _ 1 d, 79 dollars and ._ —cents
Alternates: #1 N A =t ;r
fee breakdown for each task included in the lump sum contract price, if applicable, must
be provided, Failure to provide this information shall reader the proposal non - responsive.
, The ENTIRE WORK shall be completed„ in full, within 90 calendar days from the com encer ent date
set forth in the NOTICE TO PROCEED. Failure to complete the entire work during the described time
period shall result in the assessment of liquidated damages as may be see forth in the Contract.
Insert the following information for future communication with you concerning this Proposal:
RESPONDENT: JVA En ineerinet C ntr ctor, Inc,
Thomas F, Pepe
1 21 1 4120 1 5
47
8, If a cost & tethnical proposal is required by the Solicitation, Respondent hereby certifies that all of the
fwts and responses to the questions posed in the cost & technical proposal,
a part of the Solicitation, are true and correct and are hereby adopted as part of this Construction Bid
Form, and are made a part of this proposal, by reference.
SUBMITTED THIS 25th DAY OF
August 20'6
pany
Telephone Number
305) 696- 1
Nash „ cr Pe , n Au €zet- to ...ud rnit P ow..osa.f.
Fax Number
Slgnatw& r
Email Address
Y4
_
E y=G
Pre,
zi
END OF SECTION
CONSTRUCTION CONTRACT
THIS CONTRACT was made and entered into can this day of , by
and between (hereafter referred to
"Contractor"), and the City of South Miami them fter referred to as " ner' , through its City Manager (hereafter
referred to as "City').
IN WITNESS WHEREOF, the parties hereto have executed tWs Contract on tho day and date set forth
net to rheir name below and may be signed in one or more counterparts, eacivof whichIshalt without proof or
accounti the or-her counterpart, be deemed an original Contract.
CONTRAC is Jv"Ak
a � i U -
Print Signatory's Name:
Title of Signatorf: ''e dent
affimam
OWNER: CITY OF SOUTH MIAMI
IN
I
ELMM
CONSTRUCTION CONTRACT
GENERAL O
s +
m
R n CL D EL N Y MA R
mm
J
ORRELADO INTERPAR-ETATIORA-14 M-TEWI OF _NTI-R-ACTED O-C U-M VENTS
m
m
conclusions or interpretations made by the CONTRACTOR on the basis of the information made
available by the OW CONSULTANT,
117R - - 1 t
Contractor shall comply with the hrisurarce rean iremernts se. fio—n-h in the
SUIDD!eme-ntary C-onditions to the Con-tr ct'-
A--RIICLE-4= —00NTR&C-I0—WS —IES
�)
or Materials E �ui nne�ntProd�ucts and �Susd�tutions-
Thomas R Pepe
12i 1012015
M
m
Electrical Power and Li h in
6J6 Electrical power required during construction shall be provided by each prune CONTRAC70R as
required by it. This service shad be installed by a qualified electrical Contractor approved by the
CONSULTANT. Lighting shall be provided by the CONTRACTOR in all spaces at all times where
necessary for goad and proper workmanship, for inspection or for safety, No temporary power shall be
used off temporary lighting lines without specific approval of the CONTRACTOR.
laws and R ulatiOns:
m
a
m
m
8, i The C11-f wilt' issue all communications to the CONTRACTOR through the CONSULT ANT,
8-2 1n, cases of termination of employ, ment of - e CONSUU3ANT, the CITY wig! hp. dnt a CONSULTANT
whose st us under the Contract Discuvnenvs sina'! be d et. of dke mrmmr C-ONSULTA-1off
8-3 'The 01--' the da- required - ethem under d e
8A The C11"Y'S dudens in, resp-ect zco providing lands and emsement are set ff-ord in Paragraphs + 1 and 4.2.
8,5 The C1 —1Y shill have the neht to take Possession. of and use any completed or partally completed
portions of the VVork, notwithstanding the fact that the time for completing Lhe entire Work or any
portion thereof may not have expired; but such taking possession and use shafl not be deemed an
acceptance of any Work not completed in accordance with the Contract Documents,
Measurement of -Qrant tigs.
M
m
m
CITY and provided it was not in any way, whether in whole or in part the result of the fault of the
HM The amount of credit to be allowed by CONTRACTOR to OWNER for any such change which resuks in
a net decrease in cost will be the amount of the actual net decrease in costs calculated in the same
manner as provided in I I.$. When both ad s and credits are involved in any one change, the net
shaH be computed to include overhead and prok Wentified separately, for both additions and credit,
provWW however. the CONTRACTOR shall not be entided to clahn lost proftm f6r any Work not
performed,
M
ARTICLE 14 - PAYMENTS AND COMPLETION-
m
C:0 fir e � ?
In the event td t the R withholds payment from a Subcontractor or Supplier, tl? e sar e
amount of money shall be withheld from the '?l T OR's payment until the issue is resolved by
Thomas F. Pepe
12110/2015
written agreement bet een t hem and then a joint cheat shah be made payable to the person i
AMCLk-U=--'5Q-Sft KIM :AMP -IRRMINATIQ16L
C-
y at auny tdme amd' Without cause, —uspe.-rid th �, Work or arq povuon
thereof -,' --r a peHa
d Af
not nnor, d an ninety (90) cajendar dayss by no-dice m wrin ng to the COIN TIRAC T'OR and -L. e
CONSULTANT, which shall fix the date on which YVork shall be resumed, The CONTRUACTOR shall be
allowed an Increase in the Contract Price or an extension of the Contract Time, or biatch, direcdy
attributable to any suspension and if a claim is timeiy made and if it is allowed under the to of Articles
I I or Article 12.
If after termination of the CONTIZ-ACTOR under this Section, it is determined by a court of competent
jurisdiction for any reason that the CONTRACTOR was not in del' suk the rights and obligations of the
OWNER and the CONTRACTOR thatl be the same as if the termination had been issued pursuant to
Section S.
I S.3 Where the CONTRACTOR'S services have been so terminated by the CITY said termination shall not
M
m
IT I OWNER and CONTRACTOR knowingly, irrevocably voluntarily and intentionally waive any right either
may have to a trial by jury in State or Federal Court proceedings in respect any action, proceeding,
lawsuit or counterclaim arising out of the Contract Documents ments or the performance of the Work
thereunder.
193 If CONTRACCTOR or its subcontractor does not comply with a public records request, the CITY shall
have the right to enforce this contract provision by specific performance and the person who violates this
provision small be liable to OWNER for its costs of enforcing this provision, including attorney fees
incurred in all proceedings, whether administrative or civil court and in all appellate proceedings.
Thomas p
12/10/201S
20 .1 If any provision of the Contract or the application thereof to any person or situation shall to n extent,
be held invalid or unenforceable, the remainder of the Contram and the application of such provisions to
persons or situations o6er than those as to which it shall have been held invalid or unenforceable shall
not be affected thereby, and shall continue in frill force and effect, and be enforced to the fullest extent
permitted by law,
1.1 The CONTRACTOR is an independent CONTRACTOR under t$ e Contract Services provided by the
CONTRACTOR R shall be by employees of the CONTRACTOR and subject to supervision by the
CONTRACTOR, and not as officers, employees, r agents of the OWNER. Personnel policies, tax
responsibilities, spacial security and health insurance, employee benefits, purchasing policies and other
similar administrative procedures, applicable to services rendered under the Contract shall be these of
the CONTRACTOR.
TI ASSIGNMENT.
2, € The CONT kA.,C a R. shall not transfer or assign any of its . € t;.:�. or duties, obligations and responsibilities
arisipg under t...`."-3 terms, s, conditions ns a d Drovisions of this Contract without . nor pnor w. itee., consent of the
..,3 Mane ,rte . The "t, H., not a e,,,s , < ..,� . a ., and-b o, "l consent � the as5ignrrient of the
CO8xTAVAC,OR glhcs. e .z its sole ..l a_.s.. ut ,.scr _se ....., �...lo the
2
"'.€" "�"v assign dudes, obligations t i is ;.':`t„ the ' shail not
consent to such assignment unless CONTRACT remains i;i%d e � a �r� #t# liable �� � breach
o>
the Agreement by &,e assignee, the assignee meets all of the 1 ,s re u €r ments to the IT-Y"s sole
satisfaction and the assignee execrates all of the Coat ct' ocu nts that were required to be executed
by the CONTRACTOR
IN WITNESS WHEREOF, the parties hereto have exec,
inclusion as part of the Contract Documents n this 25th day
CONTRACTOR:
Signature.
Print Signatory's r
he eneral ' nditio s to acknowledge l eir
Title of Signatory- President
EXHIBIT 6
Supplementary Conditions
x
RFP #PW20 16- 19
UNNNEM
Signature:
Maria Menendez
City Clerk
Read and Approved as to r rm, Language,
Legality, d Execution Thereof-
EN
SECTION
a
f
e.
Solum, Miami
Project Name: SW 78 St and SW 62 Avenue Roadway Improvements
RP NO. PW2016-18
Date: August 8, 2016
IE-rnailfwebpage
Sent, ",ax'I
This addenduirn :subn-6ssion is issued to clariff , supplement and/or mo 'if S
y the previously issued
Solickption, and is hereby made part of the Documents. All requirements of the Documents
not modified herein shall remain in full force and effect as originally set forth. It shall be the
sole responsibility of the bidder to secure Addendums that may be issued for a specific
solicitation.
Could you please provide engineers estimate for RPP #PW2016-18 SW 78 Street & SW 62
Avenue Roadway Improvements Project?
Page I of I
Z�
1
Slout1 Iami
CAPITAL IMPROVEMENT PROGRAM 5 -YEAR PLAN
FY17 FT to Fr 19 F!' 20
- - -- - " - " --
pRWEC7CiES[1pPT1W7 3 SOf
I
TIIAfF6C C.ALPANG
Pinecrest Villas/ Snapper Creek Traffic Calming - Construction
(Between 62 AVE, 80 ST & US l; Between 80 ST to 87 ST, From 57 PTP
AVE to 62 AVE)
F1 SS Esamaeed Fy sa
E�p►nses
-
250,040
-±
, .
Twin Lakes /Bird Estates Traffic Calming - Construction
(Between 61 AVE & 64 AVE, From 40 ST to 44 ST; Between 56 ST to
64 ST, From 62 AVE to 67 AVE)
PTP
575,000
: 75 C:
Mango Terrace\Traffic Calming - Construction
(Between 67 AVE and 69 AVE, From 72 ST to 80 ST)
LOGT
240,000
60,000
Manor Lane Traffic Calming - Construction
(Between 72 ST and US 1, from 63 AVE to 67 AVE)
PTP
200,000
38,000
t
Cocoplum Traffic Calming - Construction
(S 62 AVE & SW 67 AVE, Front SW 64 ST & SW 72 ST)
PTP
150 cyx
i {
I
i bSi3OC�
60AVer,ue Tsaff,C Calrotng DeviCes (Betwee!<S6 ST a«d 63' '-j CIP
C'ywidaDramage:mprovements SWDTF
35,0'
150, u
5 6�3
- 54,000 i
Twin Lakes Roadway & Drainage Improvements - Construction
SWDTF
91,500
61,500
LOGT
60,000
40,53027' p ,
DEP
85,000
- - ""
PTP
60,004
42 Street drainage Design and Roadway Reconstruction
SWDTF
50,000
19,440
PTP
85,000
85,000
78 Street & 63 Avenue Drainage & Roadway Reconstruction
SWDTF
50,000
50,000
- -
86,762
PTP
85,000
Citywide Roadway & Drainage Phase 6 - Construction
Part 1! SW 74 Terrace (58 AVE to 59 AVE)
__
I ROAD INFRASTRUCTURE
South Miami Intermodal Transportation Plan - Design
LOGT
45,E
PTP
.. -. .
555.WG
"-
�.
PTP
100,000
South Miami Intermodal Transportation Plan - Construction
PTP
125,000
South Miami Intermodal Transportation Plan - Contingency
PTP
225.0 P
( 100,000
75,000
75,000
75,000
SW 64 Street Bike Lane and Road Improvements
CDBG
3�6,01,,j
--
PTP
34,OOU
Citywide Street Resurfacing Program (Various locations)
LOGT
60,000
31,530
i 40,04'_ 60,000
60,000
60,000
60,000
PTP
Citywide Sidewalk Repairs
PTP
40,000
38,000
8D,O;ti
40,000
40,000
40,000
40,000
Citywide Street Improvements
LOGT
25,000
16,890
_ - .C:'k
25,000
25,000
25,000
25,000
60 Place Road Resurfacing (Between 40 & 44 ST)
PTP
50,000
50,000
±5. Xl
61 Avenue Roadway Improvement (Between 40 & 44 ST)
PTP
I
62 Avenue Design and Roadway Reconstruction (85 ST to 70 ST)
TAP*
PTP
270,000
i17,.1 i
a
Road Resurfacing - SW 58 ST (62 PL to 62 AVE)
PTP
42.D00
Road Resurfacing - SW 66 AVE & SW 50 TR (51 TR to 67 AVE)
PTP
53.x" _
Road Resurfacing - SW 78 ST (62 AVE to 63 AVE)
PTP
51:0
« 1 -D'
Road Resurfacing - SW 81 ST (62 AVE to 60 AVE)
PTP
Road Resurfacing - SW 59 PL (74 ST to 76 ST)
PTP
52,000
Road Resurfacing - SW 61 ST (62 PL to 62 AVE)
PTP
I
40,000
Road Resurfacing - SW 66 ST (67 AVE to 66 CT)
PTP
75,000
Road Resurfacing - SW 68 AVE (72 ST to 76 TR)
PTP
45,000
Road Resurfacing - SW 79 ST (63 PL to 59 AVE)
PTP
i -)
150,000
Road Resurfacing - SW 76 TR (69 AVE to 67 AVE)
PTP
40,000
CITY OF SOUTH MIAMI BUDGET FY 2015 -2016 54
South Miami
Project Name: SW 78 St and SYS 62 Avenue Roadway Improvements
p NO, W I - I
Dare: August 1 I , 2016
Sent: - x „il' eb ar
This addendum submission issued to /. supplement ? off' modit the previously .tea
Solicitation, and is hereby made part of the Documents, All requirements of the Documents
not modified herein shall remain in full force and effect as originally sit forth. 1t shall be the
sole responsibility of the bidder to secure Adden ums that may be issued for a specific
solicitation.
The number of hours for Police officers is reflected as 60 hours in the scope of work and
hours in the Schedule of Values. T his value is an allowance and may be reflected as 80 hours,
The traffic sensor loops located on S` 2-n Avenue, South of the intersection with South Dixie
Highway US I j are not to be disturbed and shall be protected during the construction of the project,
The traffic loops are outside the limits of the project.
The plans specified in the scope of work, prepared by SAS Engineering and titled "Roadway
and Sidewalk Im rovements" are included within this addendu m. As noted in the scope of
work, all concrete work is to be performed by others.
Pa s
South Miami
THE CITY OF PLEASANT LIVING
Pre -Bid Conference
Sign -In Sheet
Date: August 10, 2016
RFP Title: SW 78' Street & SW 62 Avenue Roadway
Improvement Project
U=,"
Please Print Clearl
1
RFP #PW2016 -18
.4.M C' TG �° OC'oa �d,n
3
4 M�
5
7
5
10
11
X:A Pure has ing \Request for Proposals & Qualification (RFPs )`,.SW 78 Street & SW 62 Avenue Roadway Improvement s`,Pre- BidyPre -Bid SW
74 St Improvements 7.21.16.doc
;INSURED
JVA Engineering Contractor, Inc.
6600 NW 32nd Ave
?Allarnl FL 3347
,0 V .,,,_ -G ZEti
R z
A X x CA00449045
ALL WN D SCHEDuLED
AUT0S A�
,: E AUrUS UTrU , ..
UMBRELLA LIAS
EXC ESS LIAO
'WORKERS COMPENSATION
N LOYERS ABI ! r i N
_ Y t -P F , r ,e 083053174
NiA
'Mandatory 1,1 NH�
�s escrs � unaw
CESCRIPTIGN
Equipment Floater 2 MSH 42
1E a v�a _ . s.�..€,�:: , i1
12/13120.15 12311312016 ! SCADLY NjURY �, a� •,
.AGE
PE R
TA __.
TUT
1211312 0 15 12.19312016x E L E A > C 0 CE _ . 1.000,00
-EASE Y <_;, : .' T r 1;0011,00=
_.._ --
12 {$3;2595 120 "1312015 Lease >' erted 100,001
u-ft:'f.i OF €.xrur,JiT =S. _C. -s€ da, ;s:..:..LL S tACUIRD 401: .C",..o�,,: >�,
CERTIFICATE HOLDER
Cite of South €pitn!
6130 Sunset D= ie
South Miami, €. =3943
CORD 25 (2014/01)1
HUREMNUIZIMM
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES -` BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE MLLL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS
1998-2014 ACORD CORPORATION, All rights reserved,
PRODUCER
P AME
BROWN & BROWN OF FLORIDA INC
�
€HONE 305 -36 � 3i� , No, ii5 -?
C N
14900 W 79th Court cite #200
A ..
Miami Lakes, FL 33046-5869
-
Matthew Sees
� -
_
I INSURER Landmark American iris.
33138
WSURED JVA Engineering Contractor In
INSURER B Great American insurance Co.
Alvarez
.lose
6600 NW 32nd Ave
WSURER c
iar i, FL. 33149
MSUPER D .
r UREP E:
INSURER F:
COVERAGES CERTIFICATE NUMBER:
REVISION NUMBER:
r-77 —177 a,
E,... x . _ _,.v ..� _« , ,
._ I-ERNI OR
_ B
�, ; T
u
s
_ua
�_
TYRE
LTR OF ftaURANXE
�.
A X C OEI Er RA, LP U� .
; ,3
N'TLb
i00,0001
$5,000 Per cc ed
w EX f
5e a �
4 Af- GREGATc ,.WIT 6'PPLI_u PEP
GE11. �
G i RAL k;r:" .cv.M T E
-.
... ,� 00,00
2,000,00
AUTOMOBILE LIABILITY
Ea c
NON-OWNED r € T NED
cR F Ih'.TW
H;RE".. AUTOS AUTOS
OS
Per i- -
- --
sz r A r�AS cc'c
u = ,t c rffrr
3,000,
rxc s LSA ;_ + 13 4 746
i2?3i1 Cs15 i 131 {i1 c
3,000,00
fttti
(Mandatory in NH)
EL S,E,.,EA.,r P.3LlT✓ €.t;'
S
DESCRIPTION OF OPERATIONS I LOCATiONS I VEHICLES (ACORD 101, A aitiord! Remarks Schedule, may be attached it -pore space is required)
CERTIFICATE HOLDER IS LISTED AS AN ADDITIONAL i ilR iT i RESPECTS T
GENERAL LIABILITY WHEN REQUIRED BY WRITTEN CONTRACT
ACORD 25 12014/01) The ACOR[ name and logo are registered marks of A ORi
U
Z
� h
w
�S
0
_w
W
a m
o
w 2L
Luca! Business Tax Receipt
Miarni- -Dade County, State of Florida
- HiS :S NOT A P, ILL -- ?)O }- PAY
55621f
3USINESS NAMEILOCATION RECEIPT NO,
;VA ENGINEERING CONTrRACfOR INC RENEWAL
6600 NW 32 AVE 68327416
,MIAMI FL 33147
EXPO ES
SEPTEMBER 30, 2016
Must be displayed at place of bvsittess
Pursuant to County Code
Chapter SA - Art. 9 & 10
OWNER SEC. TYPE OF BUSlN61a4i PAYMENT RECEIVED
!VA ENGINEERING CONiFG1CtOR INC x`36 GENERAL BUILDING CONTRACTOR BY TAX COLLECTOR
VUarker {s} CGC1516849 57500 08/18.,"2015
CREOITCARD- -15 -04 €426
This Local bu5mtss Tax Receipt only confirms payment of tae total Business Tax_ The Receipt is not o hcensa.
permit or a certification of the holders qualifications. to do business. Holder must comply with any quvornmontal
or nongovarnmentaf regulatory laws and requrr<<maais which apply to drn busiusM
The RECEIPT N0, above must be displayed on all commercial vehicles - Miami -!lade Code Sac U -276.
For unore information, visit wwyglp otidglkia ltaxcQj KMr
t<
`40
C'd
a1 2
U)
Lu
CC
. UJ
Wm
x2ij
LAJ
-Vo
:0
x
cc t
cn
0
CD
*goo
cm L)
tII
wrw
vo
to
in
4
9z tz.
, I
.A
mi
ILI
Q
V7
mF
Lo
0-
I<
Ni
Y
V)
0
L)
Zw
oil
z . .
j lcE
It
111 ti.
few
0
C.)
u Z
:0
x
cc t
cn
0
CD
*goo
cm L)
tII
wrw
vo
to
in
4
9z tz.
, I
.A
mi
ILI
Q
V7
mF
Lo
0-
I<
Ni
Y
V)
0
L)
Zw
oil
z . .
j lcE
It
111 ti.
Y
yC
}t �F1j a
Mia ' Cow,� St ,
:S IS NOT 9IL{ - D0 NJ
4925161
BUSINESS NAM91LOCATION
IVA ENGINEERING CONTRACTOR INC
6600 NW 32 AVE
MIAMI fl 33147
STtr:. p
Ex..
514UW" Must be displayed at placrt of business
Pursuant to County Code
Chapter SA - Art. 9 & 10
OWNER SEC, TYPE: OF BUSINESS PAYMENT RECEIVED
TVA ENGINEERING CONTRACTOR INC 196 SPECLAVI Y ENGINEERING CONTRACT 91 TAX COLLECTOR
Worker(s) I E221300 $75.00 08/16%2015
CUDiTCRRD - -15 -041426
this local Business Tax Receipt only confirms payment of the local Business Tac The Receipt is not s lieeusa,
permit, or a t'emticatioe of the hoidofs queblicaiiens, ra do business Holder new comply with any governmeutai
or nanQavernmentel raqulatory laws and regmremetttzt which apply to the busmesa
The RECEIPT NO about must lie displayed on it comlmemc al vehicles - Kamf -Dade Coda Sec da -21G_
fur nrore information, visit �yiW np�ttiitlade.ggv kgwleCiof
ok
r STATE OF FLORIDA
*w DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
-~' CONSTRUCTION INDUSTRY LICENSING BOARD
' 41IF 2601 BLAIR STONE ROAD
TALLAHASSEE FL 32399 -0783
ALVAREZ, JOSE M
JVA ENGINEERING CONTRACTOR INC
6600 NW 32ND AVE
MIAMI FL 33147
Congratulations[ With this license you become one of the nearly
one million Floridians licensed by the Department of Business and
Professional Regulation. Our professionals and businesses range
from architects to yacht brokers, from boxers to barbeque
restaurants, and they keep Florida's economy strong.
Every day we work to improve the way we do business in order
to serve you better. For information about our services, please
log onto www.myfloridalicense.com. There you can find more
information about our divisions and the regulations that impact
you, subscribe to department newsletters and learn more about
the Department's initiatives.
Our mission at the Department is: License Efficiently, Regulate
Fairly. We constantly strive to serve you better so that you can
serve your customers- Thank you for doing business in Florida,
and congratulations on your new license!
RICK SCOTT, GOVERNOR
0- 1cENS! NUMBER
(850) 487 -1395
Qe. STATE OF FLORIDA
►-' DEPARTMENT OF BUSINESS AND
PROFESSIONAL_ REGULATION
CGC1516849 ISSUED: 08/14/2016
CERTIFIED GENERAL CONTRACTOR
ALVAREZ, JOSE M
JVA ENGINEERI14ri CDNTRAC T C1ti INC
IS CERTIFIED unoer the provisions of Ch 489 FS
ExC <abon dale AUG". 2018 L'648`:1000 83
DETACH HERE
KEN LAWSON, SECRETARY
STATE OF FLORIDA
DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
CONSTRUCTION INDUSTRY LICENSING BOARD
The GENERAL CONTRACTOR
Named below IS CERTIFIED
Under the provisions of Chapter 489 FS.
Expiration date: AUG 31, 2018
ALVAREZ, JOSE M
JVA ENGINEERING CONTRACTOR INC
6600 NW 32ND AVE
MIAMI FL 3,3147
s3� r
❑ ` '' ❑
ISSUED 08/14/2616 DISPLAY AS REQUIRED BY LAW SEQ # L1 60 8 1 40 0034 83
- STATE OF FLORIDA
DEPARTMENT" OF BUSINESS AND PROFESSIONAL REGULATION
!e
� CONSTRUCTION INDUSTRY LICENSING BOARD
2601 BLAIR STONE ROAD
TALLAHASSEE FL 323090783
ALVAREZ, JOSE M
JVA ENGINEERING CONTRACTOR INC
6600 NW 32ND AVE
MIAMI FL 33147
Congratulations! With this license you become one of the nearly
one million Floridians licensed by the Department of Business and
Professional Regulation Our professionals and businesses range
from architects to yacht brokers, from boxers to barbeque
restaurants, and they keep Florida's economy strong.
Every day we work to improve the way we do business in order
to serve you better. For information about our services, please
log onto www.myfioridalicense.com. There you can find more
information about our divisions and the regulations that impact
you, subscribe to department newsletters and learn more about
the Department's initiatives.
Our mission at the Department is License Efficiently, Regulate
Fairly_ We constantly strive to serve you better so that you can
serve your customers- Thank you for doing business in Florida.
and congratulations on your new license!
RICK SCOTT, GOVERNOR
LICENSE NUMBER
•
(850) 487 -1395
STATE OF FLORIDA
DEPARTMENT OF BUSINESS AND
PROFESSIONAL REGULATION
CUC1224696 ISSUED 08/14/2016
CERT UNDERGROUND A, EXQAV GNTR
ALVAREZ, JOSE M
JVA ENGINEERING CONTRACTOR INC
IS CERTIFIED under the provisions of Ch 469 FS.
E,p- ration date AUG 31 201E C 166814 G4371
DETACH HERE
KEN LAWSON, SECRETARY
STATE OF FLORIDA
DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
CONSTRUCTION INDUSTRY LICENSING BOARD
The UNDERGROUND UTILITY & EXCAVAI IUN Uk)
Named below IS CERTIFIED
Under the provisions of Chapter 489 FS.
Expiration date- AUG 31, 2018
�s
0
ISSUED: 08114(2016 DISPLAY AS REQUIRED BY LAW SECS # L1 608 1 4400437 1
MiAmi-Da ran h Ph: '305) 696-7902
AtA_ _S
6600 NW 32 Ave Fax.- (305) 696-7903
Miami, FL 33147 -ma l: cg@jvaengineerina.com
ExpMimue 2009-Present JVA Engineering Contractor, Inc,
tAmi- ct s . (305) 696 -7 i
6600 NW 32 Ave Fax, 0 6596-7903
Siam_, FL 3314 mail: j a vaengineering.com
Experknw 2002-Current Engineering Contractor, Inc-.
2007 City of Sweetwater — Various Street Improvements
Storm Drainage System, Sidewalks & Asphalt Paving
2006 Jeri Moriarty & Associates of Florida, Inc- - Trump Tower It Site Work,
Storm Drainage yste t, Sanitary Sewer System and lr at r Distribution
n
2006 John Moriarty & Associates of Florida, inc. -- Trump Tower III Site
Work, ; Storm Drainage System, Sanitary Sewer System and Water
Distribution
235 Sri W nstr t €gin Ire. y t Say 55cy 3yg 1°, i
W r , Asphalt Paving, Concrete, Storer Drainage System, Sanitary Sewer
System and Water Distribution
C' V rk n ,
Sewer e. t Walter b _.o.
Certfu-mbom 2509 -2012 Army Ccrp of Engineers- Quality Control Manager
2510 OSHA 0 -Ho ur
State of Florida
Certified General Contractor #k-,GC 151
Certified Underground Utility Contractor #CUC1224696
froward License
Primary Pipelines License # 07-1A14144-X
Major Roads License # 07-3A-,IL4148-X
Miami Dade Clounly License
Engineering Contractor License # E221 3
Education 2002 - Current Miami Dade Community College Miami, F4
Associate in Arts
1999 ®20102 South West High School Diploma Miami, Fl
High School Diploma
I'D
m
■
I
e-CNA
(D
(D
NOON"*
(C)
It
a
1
i
i
i
i
i
CL
Z
CL
�
(D
N
i
i
i
E
E
E
•
a
N
SON".
N
•
I
I
m
CD
a
;3
Eli
'ID �D
R
rs
--Tr-
--c
zt '82,
N
SON".
N
•
I
I
m
CD
a
;3
Eli
'ID �D
R
N
SON".
N
•
I
I
m
CD
a
ELV="CJ
E"C31"F=_ I=—EZINC3
CONTR A CT0R, talc.
8/25/2016
South Miami City Hall
6130 Sunset Drive
South Miami, Florida 33143
Attn: Office of the City Clerk
Re.: ]VA Engineering Contractors' Past Experience and Corporate
References
Please allow this letter to serve as an official listing of our active and completed
jobs for the past five years. The following list provides corporate References for
each project that can speak of our professional competency, manpower and
financial capability to perform your project:
SW 78 Street & SW 62 Avenue Roadway Improvements
RFP# PW2016 -18
The following is an official list of IVA's COMPLETED and ACTIVE projects for
private and government sectors and corporate references that can verify our
competency and reliability. All of the projects below were fully executed and
submitted on a timely manner. IVA Engineering Contractor, Inc. provided all
manpower, equipment, and maintenance facilities for the completion of these:
Tri -C Construction Co., Inc.
100 W. Cypress Creek Rd.
Ft. Lauderdale, FL 33309
Contact: Chris Lawrence
Phone: (954) 677 -0356
Fax: (954) 677 -0359
2005 Tri - C Construction Co, Inc. - CVS Pharmacy #589737th & 199th
Completion Date: January 2006
Amount: $371,260.00
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
6600 NW 32 d Ave
Miami, FL 33147
TeL 305 - 696- 7902`Fax: 305 - 696 -7903
2005 Tri - C Construction Co, Inc, - CVS Pharmacy #7131 Kendall & 127th
Completion Date: February 2006
Amount- $323,856,31
Scope of work: Water Distribution, Storm Water Dist, Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
2007 Tri - C Construction Co, Inc. - CVS Pharmacy # 6732 871' & Hagler
Completion Date- August 2007
Amount: $688,823,453
Scope of work. Water Distribution, Storm Water Dist, Sewer Dist- Excavaton &
Grading, Asrpihalt Pavement, .,-;oncrete Pavement,
2006 John Moriarty & Associates of Florida, Inc. — Trump Tower 11
Amount.- $288,359,00
Scope of work- Water Distribution, Storm Water Dist, Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
2006 John Moriarty & Associates of Florida, Inc. — Trump Tower III
Amount: $ 298,024,00
Scope of work: Water Distribution, Storm Water Dist, Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
2006 Trademark Metal Recycling
Completion Date'. January 200.7
Amount- $365£820,00
Scope of work: : Asphalt Pavement, Drainage Distribution.
2007 3939 NW 25 1h Street
Completion Date: August 2007
rriou t: $91,600.00
Scope of work: Storm eater Dist., Excavation & Grading, Asphalt Pavement,
Concrete Pavement.
2007 Various Locations Improvements (Drainage, Concrete & Asphalt
Pavement).
Amount: $55,786.25
Completion Date: July 2007
2007 Retail Building 7� Flagler
Completion Date: August 2007
Amount: $3,500,000
Scope of r: eater Distribution, Storm Water Dist, Serer Dist,, Excavation
Grading, Asphalt Pavement, Concrete Pavement.
Village of Pinrt
2645 Pnrf Parkway
Pinecrest, Florida 331
Contact: Daniel F. Morefti
Phone: •
Fax: (305) 669-6919
2007 SW 79th Ave Roadway m r v me t
Completion Date: November 2007
Amount-, $280,196,50
Scope of work- Storm Water System, Asphalt Pavement, Concrete Pavement.
X007 1 € Ave Improvements
Completion Date. August 2007
Amount- $10,700.000
Scope of work, , Storm eater System, Asphalt Pavement, Concrete Pavement.
2008 Village e
Amount". 15H50,000,00
Scope f fork: Canal Bank Restoration
2013 Pine Needle Lane & Pock Garden Storm Aster Improvements
Completion Date: March 2014 (Active)
Amount: $1,012,000.00
Scope of Work: Storm 'Aster System, Asphalt, Concrete Pavement
2007 Town Center One at Dadeland
Completion Date; December 2008
Amount: $490,000.00
Scope of work: Water Distribution, Storm Water Dist., Sever Dist., Excavation
Grading, Asphalt Pavement, Concrete Pavement.
County Aviation Department
4200 NW 36st Street, Building
Miami, FL
Contact: Johnny Peterson
Phone:
E-mail: joet
,0_mikegconst.com
MIA- NW 67 1h Ave & NW 36" Street Intersection Improvements
Completion Date- October 2011
Value. $977,000.00
Scope: Storm Sewer Distribution and Roadway Reconstruction
Miami-Dade County--Parks, Recreation, and Open Spaces Depart-ment
Floor
2nd 1�,
UN Z Street, 4r
276 NO
Miami, FL 33128
III III
Contact: Lydia Salas
Phone: 305-755-5456
Fax: 305-755-7995
Cell: 786-586-8325
E-mail: lvdias(&miamidade.qov
2007 Biscayne Garden Park Improvement
Completion Date- November 2007
Amount- $329,601.10
Scope of work: Storm Water Dist., Sewer Dist., Excavation & Grading, Asphalt
Pavement, Concrete Pavement
Black Creek Trail Segment A-Phase 1, 11, and III
Completion Date'. August 2013
Amount, $2,054,514.45
Scope of Work.- New Construction and Reconstruction of Bike Path,
I I I NW I Street
Miami, FL 33128
C*ntpcti Jews Gowz
2008 V%JASD Roadway Rehabilitation Contract
Completion Date, June 2008
Amount: $323,000.00
Scope of work: Asphalt Pavement
Contact: Rakeshpal Singh Gill
Phone:786 -3 -0003
PTP Pavement Marking nsstallafio!l
C.'omoletion Date: October 2011
Amount, $ 356,572_78
Scope of Work-, Pavement Markings
2014- PTP Roadway Improvements for NW 4th Street
Project No, 20130202
Miami Dade County Water & Sewer Department
Phone: 786 552 8142
-mail:
qo
Install " DI Water Main
Project Number; ER# 15865
Amount: $698,858.67
Scope of work: eater Distribution; Asphalt Pavement
NAP Misc,-12 Sanitary Sewer Improvements
Project Number RPQ T1026
Amount. $ 636;558,26
Scope of work; Gravity Sewer, Force Main, Asphalt Pavement Restoration;
ConcreTe
Miami-Dade County Transit
701 Coon
Miami, FL
Contact, H Habibn a _ P,E.
5
Northeast st Tres it HUB Enhancements 16 3 SL Mal'!
Completion Date: February, 2016
Project Number: C1 6'
Amount- $1,374,797.43
Scope of Work- Drainage & Roadway Improvements
Miami, FL 33'
City ball 12-Inch eater Main Extension
Amount- $217.851.15
Scope of work; Water Distribution. Asphalt Pavement
Citywide Resurfacing Project Phase 11
Project Number: SM-261 m -'W
Amount- $195,788.34
Scope of for; Road Resurfacing, filling, Tearing and Grubbing, Asphalt
Placement, Metro Reflective Pavement Markers and Striping
City of Miami
444 NW 2 nd Ave,
Miami, FL 33131
Contact: Eric Rush
Phone: 954-682-9063 or 305-416-1298
Contact: Robert Fenton
Phone: 786-263-2133
E-mail: dentqnf§miamiq2_y.q0M
Contact; Maurice Hardie
Phones 305- 724 -8840
E- Mail: mhardie@miamigwi-conn
g ntamt: Valentines ` nuigbo
Phone: 6 -2588
- Mail:,
2011 Kinloch Storm Sewer Improvements PH -ii
Completion Date, November 201
Amount. $898,630.00
Scope of Word: Storm Sewer Distribution and Roadway eon tru ti n
2013 Miami River Greenw y NW 5th Street Bridge Extension
Project N,: ®31336
Completion plate: October 2013
Amount: $896,813,25
Scope of Work: Road Improvements, Milling & Resurfacing, Drainage
Improvements, Curb & Gutter, Sidewalk Repairs, Striping, Signs, and ADA ramp
upgrades
20,15- Englewood Road Storm Sewer improvements Phase 11
Project No-, B30011
Completion Date: May. 2015
Amount., $1,896,80161,72
Scope of Work, Drainage & Roadway improvements
2015- NW 33 d Street Roadway Improvement's
Project No: B30724
Completion Date, September, 2016
Amount: $5,899,864.98
Scope of Work: Water Main & Roadway Improvement
Scope of work- Various Site and Marine Construction
01pa-Locka Head Start Facility
Amount: $165,000.00
Scope of work: eater Distribution, Storm Water Dist., Excavation & Grading,
Asphalt v me t.
2012 Surface Lot E Taxi & Overflow Parking Lot
Amount- $216,470.00
Completion Date: January 2013
Scope of work: Parking lot reconstruction, Asphalt Milling, New Asphalt, New
Concrete
2014 Seaboard Marine Cargo Terminal Redevelopment Phase ii
Project No.: 2003 - 032.04
Amount, $6,196,835.57
Completion
Scope o, Wte k. Upgrading Na ,.. - t,l,t y , ,. r. z -t ,.,,re and Pavement or
Approximately 8 Acres
YEMC Construction
4750 Ste` 24 Ih Street
Miami, FL
Contact:
Coral Way Offices
Amount- $105,067,50
Scope of work: Storm Water Dist. Sewer Dist.; Excavation & Grading, Asphalt
Pavement, Concrete Pav ment,
Community Bible Baptist Church
mo rrt: 214,417.00
Scope of work. Water Distribution, Storm Water Dist. Sewer Dist., Excavation
Grading, Asphalt Pavement, Concrete Pavement.
VP Construction
7600 Red Rd #128
Miami F1 33143
Contact: George Perendes
Phone: (305) 667- 6060
Valencia Village
Amount- $218,276.50
Scope of work Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Comclrete Pavement,
I ftu;wl
Phone: 305-640-7103
Project Number: E6110
Amount- $1,336,493,07
Completion Date: September 2014
Scope of Work: Rehabilitation and Improvement of Parking Lot
Doral, FL 33178
Juan R, Alvarez
305-640-1345
E-mail: Juan.A1v!arez1,8A1varezEnq.co
I
Waterstone Way
Amount $1,054,313.50
Scope of Work- Concrete, Drainage, Asphalt Striping, Manhole, Manhole,
Sanitary Sewer, and 8" Water Main
Beacon Tradeport Development District
Amount $120,000
Scl-ope of Work- Concrete
Opa-Locka, FL 33054
J
Fax: 305-953-2824
Email: Mnacir@opa1ockaf1._qov
2012 NW 143r'i Street Drainage & Roadway Improvements Project
Completion Date: June 2013
Project Number: 11-2012100
Amount: $468,644,80
Scope of Work: Installation of new Drainage System, Road Rehabilitation, Repair
and Renovations of existing Sidewalks
2013 Burlington Drainage Improvements
Completion Date" June 2013
Project Number- 12-1712200
Amount- $463,529.45
Scope of Work-, Drainage Improvements
City of Hollywood
2600 Hollywood Blvd.
Hollywood, FL
Contact: Clete Aurelus
mzffmla���
Fax: 954-921-3258
E-mail: caurelusiObhoiNwo
L;
E-mail: h_qrayr&sibfi.net
2013New Port Fishing Pier and Restaurant Utilities
Completion Date.- June 2013
Amount- $174,2130.00
Scope of Work: 8" PVC Water Main
Federal Highway Administration
Eastern Federal Lands Highway Divisil
21400 Ridgetop Circle
Sterling VA 20166-6511
Contact: Donald McIntosh
Phone: 305-242-7771
E-mail: donald.macintosh@dotgov
2013 Everglades National Park
Completion Date, December 2013
Amouft $850,000
Scope of Work: Resurfacing & Rehabilitation of 1,09 miles of A-Loop Road (NPS
Route 220), 1,26 miles of Long Pine Key Access Road (NS Route 228),
Superpave Asphalt Concrete Pavement Overlay, Pavement Markings and other
Miscellaneous Work.
Citty
y of No Miami
776 NE 125'- Street
North Miami, LF 33161-4116
Contact: Wisler Pierre Louis
Phone: 305-895-9838
E-mail: pwisler@northmiamifl.gov
2014 Biscayne Boulevard Force Main Improvements
Project No.- 19-13-14
If you have any questions, please do not hesitate to contact us,
lose M. Alvarez, President
Inc. IVA Engineering Contractor, I