The URL can be used to link to this page

JVA ENGINEERING CONTRACTOR, INC.CITY • Mayor: Vice Mayor: 1MISSION Philip K. Stoddard, PhV josh Liebman Valerie Newman Walter Harris Bob Welsh CHARTERED OFFICIALS City Manager: Hector Mirabile, PhD City Attorney: Thomas Pepe, Esq. City Clerk: Maria M. Menendez, CMC Keith A. Ng, CFM Capital Improvements Program City of South Miami "Excellence, Integrity and Inclusion" @ thomasfpepe-09-28-1 1 (Updated tfp 4-30-2012) CITY OF SOUTH MIAMI SUNSET DRIVE DOWNTOWN MEDIAN The City of South Miami, Florida, hereinafter referred to as "City ", is hereby soliciting sealed proposals. The submittal, consisting of one (1) original unbound proposal, three (3) additional copies to the Office of the City Clerk, South Miami City Hall, 6130 Sunset Drive, South Miami, Florida 33143. Sealed Proposals must be received by the City Clerk, either by mail or hand delivery, no later than 2:00 P.M. local time on Tuesday, July 17, 2012. A public opening will take place at 2:00 P. M. in the City Commission Chambers located at City Hall on the same date. Any Proposals received after 2:00 P.M. local time on said date will not be accepted under any circumstances. Any uncertainty regarding the time a Proposal is received will be resolved against the Bidders. The Project is generally described as: Construction of a landscaped median along Sunset Drive between SW 57th Avenue and SW 58th Avenue. The scope of work for this project includes and is not limited to milling and resurfacing, curbing, new signage, pavement marking and striping, tree planting, sodding and irrigation. In accordance with Section 174 of the City Ordinance, a Performance and Payment Bond is required for the full amount of the project. The work involved with the project shall include, but may not be limited to, the furnishing of all labor, materials, tools, equipment, machinery, superintendence and services necessary for the complete in place construction of the project. A Mandatory Pre -bid Meeting will be conducted at City Chambers at 10:00 am located at 6130 Sunset Drive, South Miami 33143. Pre -Bid Meeting shall be held at the site on Monday, July 9, 2012. The conference shall be held regardless of weather conditions. Proposals are subject to the attached Standard Terms and Conditions contained in the complete bid package. Interested Bidders who wish to bid on this RFP can obtain the complete bid package at City's website at cityofsouthmiarnL net / index. php ?src= gendocs &ref= Bid Posting20I0 &category =RFPs- and -Bids or at the City Clerk's office Monday through Friday from 9:00 A.M. to 4:00 P.M. The City of South Miami reserves the right to award the bid to the lowest, most responsive, responsible bidder, as determined by the City Commission, subject to the right of the City to reject any and all bids, to waive any irregularity in the bids or bidding procedure and subject also to the right of the City to award bid and contract to bidders other than the low bidder. Maria Menendez, CMC South Miami City Clerk © thomasfpepe- 09 -28 -1 I Proinosal Submittal Checklist Form Sunset Drive Downtown Median This checklist indicates the forms and documents required to be submitted for this solicitation and to be presented by the deadline as set forth within the solicitation. Fulfillment of all solicitation requirements listed is mandatory for consideration of response to the solicitation. Additional documents may be required and, if so, they will be identified in an addendum to this RFP. The response shall include the following items: X Bidder Form X Bid Bond X Bidder Qualification Statement X Non - Collusion Affidavit X Public Entity Crimes and Conflicts of Interest X Drug Free Workplace X Acknowledgement of Conformance with OSHA Standards X List of Proposed Subcontractors and Principal Suppliers 15 17 21 22 25 26 27 Submit this checklist along with your proposal indicating the completion and submission of each required forms and /or documents. © thomasfpepe- 09 -28 -II (Updated 05 -16 -2012) Page 7 THIS BID IS SUBMITTED TO: Dr. Hector Mirabile City Manager City of South Miami 6130 Sunset Drive South Miami, FL 33143 The undersigned BIDDER proposes and agrees, that if this Bid is accepted, to enter into a Contract with the City of South Miami in the form included in the Contract Documents which are part of this Bid Package to perform and furnish all work as specified or indicated in the Contract Documents for the Contract Price and within the Contract Time indicated therein and in accordance with the other terms and conditions of the Contract Documents which include those prepared by Palm Engineering Group, Inc. BIDDER accepts all of the terms and conditions of the Advertisement or Invitation to Bid and Instructions to BIDDERS, including without limitation those dealing with the disposition of Bid Bond /Security. This Bid will remain subject to acceptance for 90 days after the day of the Bid opening. BIDDER agrees to sign and submit the Contract with the Bonds, Insurance Certificate and other documents required by the Bidding requirements within ten (10) calendar days after the date of the City's Notice of Award. 2. In submitting this Bid, BIDDER represents, as more fully set forth in the Contract, that: a. BIDDER has examined copies of all the Bidding Documents and of the following Addenda (receipt of all which is hereby acknowledged.) Addendum No. 1 Dated: 7/16/2012 Addendum No. 2 Dated: 7/16/2012 Addendum No. 3 Dated: 7/19/2012 Addendum No. Dated: b. BIDDER has familiarized himself with the nature and extent of the Contract Documents, the proposed work, site, locality, and all local conditions and laws and regulations that in any manner may affect cost, progress, performance or furnishing of the Work. c. BIDDER has studied carefully all reports and drawings of subsurface conditions and drawings of physical conditions. d. BIDDER has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying) all such examinations, investigations, explorations, tests and studies in addition to or to supplement those referred to in (c) above which pertain to the subsurface or physical conditions at the site or otherwise may affect the cost, progress, performance, or the furnishing of the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents. The BIDDER hereby acknowledges that no additional examinations, © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 8 investigations, explorations, tests, reports or similar information or data are, or will, be required by BIDDER for any reason in connection with the Bid. e. BIDDER has correlated the results of all such observations, examinations, investigations, explorations, tests, reports and studies with the terms and conditions of the Contract Documents. f. BIDDER has reviewed and checked all information and data shown or indicated on the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of all Underground Facilities. No additional examinations, investigations, explorations, tests, reports or similar information or data in respect to any Underground Facilities are, or will be required, by BIDDER in order to perform and furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents. g. BIDDER has given written notice of all conflicts, errors or discrepancies that it has discovered in the Contract Documents and, if any conflicts, errors or discrepancies have been found and notice given, the BIDDER represents, by submitting its bid to the City, that the BIDDER has received sufficient notice of the resolution thereof by Consultant, that such resolution is acceptable to BIDDER and the BIDDER waives any claim regarding the conflicts, errors or discrepancies. h. This Bid is genuine and not made in the interest of or on behalf of any undisclosed person, firm or corporation and is not submitted in conformity with any agreement or rules of any group, association, organization, or corporation; BIDDER has not directly or indirectly induced or solicited any other BIDDER to submit a false or sham Bid; BIDDER has not solicited or induced any person, firm or corporation to refrain from Bidding; and BIDDER has not sought by collusion or otherwise to obtain for itself any advantage over any other BIDDER or over the CITY. 3. BIDDER understands and agrees that the Contract Price is the lump sum that it needs to furnish and install all of the Work complete and in place. The Schedule of Values is provided for the purpose of Bid Evaluation and when initiated by the CITY, it shall form the basis for calculating the pricing of change orders. The Contract Price shall not be adjusted in any way so as to result in a deviation from the Schedule of Values, except to the extent that the CITY changes the scope of the Work after the Contract Date. As such, the Contractor shall furnish all labor, materials, equipment, tools, superintendence and services necessary to provide a complete, in place Project for the Bid Price of. LUMP SUM BASE BID: dollars and Eighty Seven Thousand Four Hundred Thirty One Twenty Two Alternates: #1 #2 #3 0 cents #5 #6 #7 m $87,431.22 © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 9 A fee breakdown for each task must be completed in the table shown above. Failure to complete this information shall render the proposal non-responsive. 4. The ENTIRE WORK mhu|| be comp|etod, in full, within 60 Calendar Days from the date stipulated in the NOTICE TOPROCEED. Failure tocomplete the entire work during the described time period shall result inthe assessment of liquidated damages as set forth in Paragraph 6 of the Contract. 5. Communications concerning this Bid shall be addressed to: BIDDER: JVA Engineering Contractor, Inc. Address: 6600 2JYJ 32nd Ave, Miami, FL 33147 Telephone: 305-6 Facsimile: Attention: Jose M. Alvarez 6. The terms used in this Bid which are defined inthe General Conditions of the Contract shall have the same meaning as is assigned to them in the General Conditions. BID SUBMITTED BY: JVA l Company Jose M. Alvare Name of Persdn Auth --- -- tractor, —Inc. 305-696-7902 Telephone Number 1=1N1WIT&I-re z,ignature ~° President Title � � 305-696-7903 Fax Number Email Address FAILURE TO COMPLETE, SIGN, & RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE @ || (Updated 05-16-2012) Page 10 Capital Improvement Program Sunset Drive Downtown Median Schedule of Values Company: JVA Engineering Contractor, Inc . Item No. I Item Description Unit I Quantity I Unit Cost I Total Cost GRAND TOTAL Eighty Seven Thousand Four Hundred Thirty 1 87, 431.22 Notes: One and Twenty Two Cents This revised schedule of values must be submitted to vendor a responsive bid. The quantities stated in the bid form are approximate and are intended to establish competitive unit prices IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. 2 PAY ITEM DESCRIPTION • Mobilization and Dust Control- This item shall include the preparatory work and operations in mobilizing for beginning work on the project, including, but not limited to, those operations necessary for the movement of personnel, equipment, supplies, and incidentals to the project site. Payment will be based on a lump sum for mobilization. • Maintenance of Traffic — This item shall include the Lump sum price for furnishing all necessary traffic control including but not limited to flag persons, cones, markers, signs, lighting, flags, and other control devices for directing traffic and to maintain safety, and other aides for the duration of the project. Included in this bid item is the payment of an off -duty law enforcement officer to control and direct traffic. Since this item is bid as a lump sum, payment will be in accordance with the cost breakdown as approved by the Consultant and measured as required by, and satisfactory to, the Consultant. All MOT devices required must conform to applicable standards. • Regular Excavation — This item concerns Cubic Yards for Regular Excavation within the limits defined by Details on the Plans and the FDOT Specifications. The price bid shall be full compensation, as to each cubic yard removed and disposed of offsite, for furnishing all necessary labor, materials, tools, and equipment and for performing all work required for excavation, widening and other required general excavation, including but not limited to the loading, transporting, and proper disposal of the removed materials. Payment will be paid for based on the number of Cubic Yards removed, and disposed of offsite, times the unit bid price for Regular Excavation. • Milling Existing Asphalt Pavement, I" Average Depth — This item concerns the price per Square Yard that is milled from the existing asphalt pavement (approximately I -inch average depth) within the limits defined by the Details on the Plans and the FDOT Specifications. Greater widths and depths than are defined by the Plan and Specifications, and removal of unauthorized work as required by the City, are at the Contractor's sole expense unless the Contractor has a written change order for such work. The price bid shall be full compensation for furnishing all necessary labor, materials, tools, and equipment and for performing all work required for milling of the existing asphaltic concrete surface, including the cost of removal and disposal of milled material from the project site. • Type I Asphaltic Concrete- Square Yards. This item shall include the furnishing and installing Type S -1 Asphaltic concrete for permanent paving repairs within the limits defined by details on the plans, the FDOT specifications and /or the Standard Details and the map or drawing designation. Placement of asphalt must be placed in a manner that maintains the existing crown and the grade. Greater widths and depths than are defined by the Plan and Specifications, and removal of unauthorized work as required by the City, are at the contractor's sole expense, either for the installation, or for removal of unauthorized work as required by the City, unless the Contractor has a written change order for such work. The price shall be full compensation for furnishing all that is necessary for a complete asphaltic concrete surface course installation including but not limited to supplying all labor, materials, tools, and equipment and for performing all work required for preparing and transporting mixture, tack cost application, placing, compacting, and testing. Payment will be based on the number of square yards of Type S- I asphaltic concrete required to perform the contracted work. The area to be asphalted shall be the same as the area designated on a map or drawing of the area to be milled and © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 12 any areas not so designated and milled that are asphalted, and the removal of unauthorized work as required by the City, shall all be at the contractor's sole expense. • Concrete Curb — This item is the unit price for each Linear foot needed to install concrete curb as required by the plans, the FDOT Specifications and /or Miami Dade County Standard Details or the quantity identified on the plans and as directed by the City. The Price bid shall be full compensation for furnishing all necessary labor, materials, tools, and equipment and for performing all work required for preparing and transporting mixture, formwork, placing for a complete concrete curb for each foot authorized and installed. Payment will be based on the number of linear feet of concrete curb and gutter times the unit bid price. All linear feet of concrete curb shall be authorized in writing signed by the City Manager or his designee. • Performance Turf, Sod — This item is the unit price for each Square Yard for sodding within the limits defined by Details on the Plans and Specifications and the FDOT specifications. The price bid shall be full compensation for furnishing all necessary labor, materials, tools, and equipment and for performing all work required for sodding of new swales and any other grassy areas disturbed during construction, including the loading, transporting, and proper disposal of the removed materials for each square yard authorized and installed. Payment will be based on the number of square yards of authorized and installed times the unit bid price. All square yards shall be authorized in writing signed by the City Manager or his designee. • Single Post Sign, Less Than 12 SF — This item is the unit price for each sign for furnishing and installing Single Post Signs (Less than 12 square feet) within the limits defined by Details on the Plans, the Specifications, and the FDOT Specifications. The price bid shall be full compensation for furnishing all necessary labor materials, tools and equipment and for performing all work required for the complete installation of a single post signage, ready for service and all other similar items as required or necessary, to original locations and to equal or better than original conditions; and all other appurtenant and miscellaneous items and work. Included in the unit cost are all survey, submittals, and shop drawing work; all loading, unloading, and transport costs to installation location and any other cost or thing necessary to complete the work. Payment will be based on the number of authorized and installed Single Post Signs (Less than 12 square feet) times the unit bid price. The signs to be installed, and their location, shall be designated and authorized in a writing signed by the City Manager. • Painted Pavement Marking, Standard, White, Solid, 12" — This item is the unit price for each Lineal Foot of furnished and installed Solid Painted Pavement Marking (White, 12 -inch) within the limits defined by Details on the Plans, the Specifications, and the FDOT Specifications. The price bid shall be full compensation for furnishing all necessary labor, materials, tools, and equipment and for performing all work required for the complete installation of solid traffic stripe (white, 12- inch), ready for service, and shall include temporary paving, pavement marking, pedestrian crossings markings and all other similar items as required or necessary, at the original locations and to equal or better than original conditions; and all other appurtenant and miscellaneous items and work necessary to provide a complete job. Included in the unit cost are all survey, submittals, and shop drawing work; all loading, unloading, and transport costs to installation location and any other cost or thing necessary to complete the work. Payment will be based on the number of authorized linear feet of Solid Painted Pavement Marking (white, 12 -inch) installed times the unit bid price. All Lineal feet shall be authorized in writing signed by the City Manager or his designee. © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 13 • Painted Pavement Marking, Standard, Yellow, Solid, 6" — This item is the unit price for each Net Mile required for the furnishing and installing of Solid Painted Pavement Marking (Yellow, 6 -inch) within the limits defined by Details on the Plans, the Specifications, and the FDOT Specifications. The price bid shall be full compensation for furnishing all necessary labor, materials, tools, and equipment and for performing all work required for the complete installation of solid traffic stripe (yellow, 6- inch), ready for service, and shall include temporary paving, pavement marking, pedestrian crossings markings and all other similar items as required or necessary, to original locations and to equal or better than original conditions; and all other appurtenant and miscellaneous items and work. Included in the unit cost are all survey, submittals, and shop drawing work; all loading, unloading, and transport costs to installation location and any other cost or thing necessary to complete the work. Payment will be based on the authorized and installed net mile of Solid Painted Pavement Marking (yellow, 6 -inch) times the unit bid price. All net miles shall be authorized in writing signed by the City Manager or his designee. • Performance and Payment Bond - This item shall include the lump sum price for the cost of bonds. • Permits and Insurance — This item shall include a lump sum for all permits and any required insurance. © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 14 STATE OF FLORIDA ) COUNTY OF MIAMI -DADE ) KNOW ALL MEN BY THESE PRESENTS, that we, JVA ENGINEERING CONTRACTOR, INC. as Principal, and WESTERN SURETY COMPANY as Surety, are held and firmly bound unto the City of South Miami, a municipal corporation of the State of Florida in the sum of Five Percent of Bid Proposal Submitted -- -- Dollars ($ 5% ----- -------- ---- -) lawful , money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that: WHEREAS, the Principal has submitted the accompanying Bid dated July 13, 2012 , for the Sunset Drive Downtown Median. it was a condition precedent to the submission of said Bid that a Bid Bond in the amount of five percent (5 %) of the Base Bid be submitted with said Bid as a guarantee that the BIDDER would, fulfill the obligations of the invitation to bid and bid documents; NOW THEREFORE, A. If the principal shall not withdraw said bid within ninety (90) days after the date for opening of the same, and shall, within ten (10) days after the prescribed forms are presented to it for signature, enter into a written contract with the Owner in accordance with the bid as accepted, and give bonds with good and sufficient surety or sureties, as may be required, for the faithful performance and proper fulfillment of such contract, then the above obligations shall be void and of no effect, otherwise to remain in full force and effect. B. However, in the event of the principal's unauthorized withdrawal of said bid within ninety (90) days after the date of the opening of the same or the failure to enter into a written contract with the Owner in accordance with the bid as accepted, and /or the failure to provide the City with bonds issued from good and sufficient surety or sureties, as may be required, for the faithful performance and proper fulfillment of such Contract within ten (10) days after the prescribed forms are presented to it for signature and /or in the event that the principal is not awarded the bit but fails to waive all claims that arose or might have arisen out of the bid process in the event that the bid is not awarded to the principal, then the above obligations shall remain in full force and effect and the bond shall thereafter be disburse, by court order, to the Owner in the full amount of the bond if the Bid Documents provide for liquidated damages under the circumstance of the case or, if liquidated damages are not applicable, then in an amount that is adequate to fully compensate the Owner for all of its damages incurred due to the breach of the terms of this Bond, including all attorney fees, court costs and legal expense incurred by the City for any and all proceedings required to obtain the court order of disbursement, including the cost of all appeals or other proceedings, as well as the fees and costs incurred to collect these damages. IN WITNESS WHEREOF, the above bonded parties have executed this instrument under their several seals this 13th day of July 2012, the name and the corporate seal of each corporate party being hereto affixed and these presents being duly signed by its undersigned representative. © thomasfpepe- 09 -28 -1 I (Updated 05 -I6 -2012) Page 15 9 111-0 ON ATTEST: Secretary *Impress Corporate Surety Seal 6600 N.W. 32nd Avenue (Business Address) Miami, Florida 33147 (City/State/Zip) (305) 696-7902 (Business Phone-)- IMPORTANT Surety companies executing bonds must appear on the Treasury Department's most current list (circular 570 as amended) and be authorized to transact business in the State of Florida. FAILURE TO COMPLETE, SIGN ,.,&,RETURN THIS FORM MAY DISOUALIFY.. YOU R BID @ thomasfpepe•09-28-1 I (Updated 05 -16 -2012) Page 16 POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint Laura D Mosholder, John R Neu, Charles J Nielson, Brett M Rosenhaus, Kevin WojtoWicz, Mary C Aceves, Glenn Arvantis, Charles D Nielson, David R hoover, Individually of Miami Lakes, FL, its true and lawful Attomey(s) -in -Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature the By -Law of the corporation printed on the reverse hereof is still . In Unlimited Amounts. and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney T lir$17 r Y to fhe attthprity, herehv Given are hereF latifled arld n„n,n4i neA - -moo r-- J J b" • I ' This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corporate seal to be hereto affixed on this 12th day of May, 2010. SC A%� State of South Dakota ss County of Minnehaha WESTERN SURETY COMPANY Paul rBruflat, Senior Vice President On this 12th day of May, 2010, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Senior Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires 4 f D. KRELL s November 30, 2012 NOTARY PUBLI sEAL s C S' S SEAL SOUTH DAItOTA 9ahw� yh5haa�whw� 5Hh5k� by + CERTIFICATE I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby' certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 13 day of �CA�60, 2012 WESTERN SURETY COMPANY L. Nelson, Assistant Secretary Form F4280 -09 -06 The BIDDER'S response to this questionnaire shall be utilized as part of the CITY'S overall Bid Evaluation and Contractor selection. I. Number of similar construction projects completed, a) In the past 5 years 5 On Schedule 5 b) In the past 10 years 8 On Schedule 2. List the last three (3) completed similar projects. a) Project Name: Owner Name: Owner Address: Owner Telephone: Original Contract Completion Time (Days) Original Contract Completion Date: Actual Final Contract Completion Date: Original Contract Price: Actual Final Contract Price: b) Project Name: Owner Name: Owner Address: Owner Telephone: Kinloch storm Sewer Imp. City of Miami 444 NW 2nd Ave., Miami, FL 305 - 250 -5430 360 Days March 2012 November 2011 $898,630 $787,620 NW 143rd Street Drainage & Road City of Opa-Locka 780 Fisherman Street, Opa -Lock 786 - 382 -917 Original Contract Completion Time (Days): 180 Days Original Contract Completion Date: Actual Final Contract Completion Date: Original Contract Price: Actual Final Contract Price: C) Project Name: Owner Name: Owner Address: August 2012 May 2012 468,644.80 $468,644.80 Perrine Cutler Ridge Water& Miami -Dade WASD 3071 SW 38th Ave. Miami,FL Owner Telephone: 786-552-8142 Original Contract Completion Time (Days): 365 Days © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 17 Original Contract Completion Date: Actual Final Contract Completion Date: Original Contract Price: Actual Final Contract Price: 3. Current workload August 2012 March 2012 $2,254,103.10 $2,254,103.10 Project Name aping Owner Name Telephone Number ity of Hollywo d 954 - 805 -3681 $930,000 Furnish & Inst. Miami -Dade 786 - 552 -8142 $2,254,103 Black Creek Trail Segment Miami -Dade Par Rs 305 - 755 -7830 1,854,373 © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 18 4. The following information shall be provided for this project. a) Estimated total demolition man -hours Percent man -hours to be performed by Contractor's b) permanent staff Permanent man -hours to be performed by direct hired c) employees for this project 5 Hours 99% 1% % d) Percent man -hours to be performed by Subcontractors 0% 5. The following information shall be attached to the bid. a) Contractor's home office organization chart. See Attached b) Contractor's proposed project organizational chart. See Attached c) Resumes of proposed key project personnel, including on -site Superintendent. See Attached 6. List and describe any: a) Bankruptcy petitions filed by or against the BIDDER or any predecessor organizations, None b) Any arbitration or civil or criminal proceedings, or None Suspension of contracts or debarring from Bidding by any public agency brought C) against the BIDDER in the last five (5) years. None © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 19 7. Government References: List other Government Agencies or Quasi - government Agencies for which you have done business within the past five (5) years. Name of Agency: Miami -Dade Water & Sewer Department Address: 3071 SW 38th Avenue, Miami, FL 33146 Telephone No.: 786-552-8142 Contact Person: Nelson Cespedes Type of Project: Various, See Attached Name of Agency: Port of Miami Address: 1015 North America Way, Miami, FL 33132 Telephone No.: 305 - 347 -4988 Contact Person: Bart Sanfilipo Type of Project: Various, See Attached Name of Agency: City of Hollywood Address: 2600 Hollywood Blvd., Hollywood, FL Telephone No.: 954-805-3681 Contact Person: Clece Aurelus Type of Project: 8" Water Main FAILURE TO COMPLETE, SIGN, & RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE ©thomasfpepe- 09 -28 -II (Updated 05 -16 -2012) Page 20 Non-Collusion Affidavit Sunset Drive Downtown Median STATE OF FLORIDA ) COUNTY OF MIAMI-DADE ' Jose M. Alvarez being first duly sworn, and states that: (|) He/She/They is/anatbe President J\D\ Engineering kOvvner, Partner, Officer, Representative orAgent) Cootr�otor, Inc. the BIDDER that has submitted the attached B|U' (2) He/She/They is/are fx|k' informed with respect to the preparation and contents of the attached B|[) and of all pertinent circumstances concerning such 8|[}; (3) Such 8|[) is genuine and is not collusive or sham BID; (4) Neither the said 8|C>UER nor any of its officers' partners, owners, ogents, representatives, employees or parties in interest, including this affiant, have in any way co||uded, conupired, connived or agreed, directly or indirectly, with any other BIDDER, firm, or person to submit o collusive or sham BID in connection with the Work for which the attached 8|[) has been submitted; orto refrain from bidding or proposing in connection with such Work; or have in any manner, directly orindirectly, sought 6v agreement orcollusion, or communication, or conference with any BIDDER, firm, or person to fix any overhead, profit, or cost elements of the BID or of any other BIDDER, or to fix any overhead, profit, or cost elements of the BID Price h BID Price of any other BIDDER, through connivance, or unlawful agreement any advantage against Recip tx or any person interested in the proposed Work; (5) The price or prices quoted in the attached BID are fair and tainted byany co||umion, conspiracy, connivance, or unlawful agreement part BIDDER orany rarties other of its ogents, representatives, ovnerx, employees or of erent' including this affiunc Signed, sealed & delivered in the presence of. 8n Subscribed and sworn to before methis MIS V Apt Jose MAAivarez Print Name and Title 17th day My Commission Expires: 8/21/2013 @ || (Updated 05- 16-2012) Page 21 Pursuant to the provisions of Paragraph (2) (a) of Section 287.133, Florida State Statutes — "A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a Bid on a Contract to provide any goods or services to a public entity, may not submit a Bid on a Contract with a public entity for the construction of repair of a public building or public work, may not submit bids on leases or real property to a public entity, may not be awarded to perform Work as a Contractor, supplier, Subcontractor, or Consultant under a Contract with any public entity, and may not transact business with any public entity in excess of the threshold amount Category Two of Section 287.017, Florida Statutes, for thirty six (36) months from the date of being placed on the convicted vendor list ". The award of any contract hereunder is subject to the provisions of Chapter 112, Florida State Statutes. BIDDERS must disclose with their Bids, the name of any officer, director, partner, associate or agent who is also an officer or employee of the City of South Miami or its agencies. SWORN STATEMENT PURSUANT TO SECTION 287.133 (3) (a), FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS, 1. This sworn statement is submitted to City of South Miami [Print name of the public entity] By Jose M. Alvarez, President [Print individual's name and title] For JVA Engineering Contractor, Inc. [Print name of entity submitting sworn statement] Whose business address is 6600 NW 32nd Ave., Miami, FL 33147 [Print full mailing address] and applicable) its Federal Employer Identification Number (FEIN) is 4 - 1277685 (If the entity has no FEIN, include the Social Security Number of the individual signing this sworn statement: 2. 1 understand that a "public entity crime" as defined in Paragraph 287.133 (1)(g), Florida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to , any bid or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation. 3. 1 understand that "convicted" or "conviction" as defined in Paragraph 287.133 (1) (b), Florida Statutes, means a finding of guilt or a conviction of a public entity crime, with or without an adjudication of guilt, in any federal or state trial court of record relating to charges brought © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 22 by indictment or information after July I, 1989, as a result of a jury verdict, non -jury trial, or entry of a plea of guilty or nolo contendere. 4. 1 understand that an "affiliate" as defined in Paragraph 287.133 (1) (a), Florida Statutes, means: (a) A predecessor or successor of a person convicted of a public entity crime; or (b) An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in any person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. 5. 1 understand that a "person" as defined in Paragraph 287.133 (1) (e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or applies to bid on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. 6. Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this sworn statement. [Indicate which statement applies.] X Neither the entity submitting this sworn statement, nor any of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent of July 1, 1989. However, there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it was not in the public interest to place the entity submitting this sworn statement on the convicted vendor list. [Attach a copy of the final order.] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FOR THE PUBLIC ENTITY INDENTIFIED IN PARAGRAPH I (ONE) ABOVE IS FOR THAT PUBLIC ENTITY ONLY, AND THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED, I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017, FLORIDA STATUTES, FOR CATEGORY TWO OF ANY CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 23 Signed, sealed & delivered in the presence of. By: 0\\kk� i i I I iijIllIz. Subscribed and sworn to bef O,\ kWAit 1'jth day of 12 FAILURE TO COMPLETE, SIGN, & RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE @ thomasfpepe-09-28-1 I (Updated 05-16-2012) Page 24 Whenever two or more Bids which ona md vv�h eq respect to price, quality and service are received by the State or by any political subdivisions for the procurement of commodities or contractual services, a Bid received from a business that certifies that ichas implemented o drug- free workplace program shall be given preference in the award process. Established procedures for processing tie Bids shall be followed if none of the tied vendors have m drug-free workplace program. |n order to have a drug-free workplace program, u business shall: |\ Publish u statement notifying employees that the un|avvh/| manufacture, distribution, dispensing, possession, or use ofacontrolled substance is prohibited in the o and specifying the actions that shoUbe taken against employees for vio|udonsof such p hibition. 2) Inform employees about the dangers of drug abuse in the workplace, the business' policy of maintaining z drug-free workplace, any available drug counse8ng, rehabilitation, and employee assistance proQnama, and the penalties that may 6e imposed upon employees for drug abuse violations. ]} Give each employee engaged in providing the commodities or contractual services that are under Bid m copy of the statement specified in Subsection (|). 4\ In the statement specified in Subsection (|)' notify the emp|oyees, that, as a condition of working of the commodities or contractual services that are under 0d, he employee shall abide by the terms of the statement and shall notify the employee of any conviction of, or plea of guilty or nu6x contendene to' any violation of Chapter 893 or of any controlled substance law of the United States or any sLute, for u violation occurring in the workplace no later than five (5) days after such conviction. 6) Impose a sanction on' or require the satisfactory participation in udrug abuse assistance or rehabilitation program, if such is available in the employee's community, by any employee who is so convicted. 6) Make u good faith effort to con ti nue to � X` free workplace through implementation of this section. As the person authorized to sign the statement, | ce r hat him m complies fully with the above requirements. I BIDDER's Signature: Print Name: Jose M. Al Date: 7 112Z2 012 FAILURE TO COMPLETE.SIGN, & RETURN THIS FORM MAY DIQUALIFY YOUR RESPONS m |/ (Updated m5-|u-2o|4 Page 25 ' Acknowledgement of Conformance with OSHA Standards I Sunset Drive Downtown MediA TO THE CITY OF SOUTH MIAMI JVA Engineering Contractor, Inc. (Name of hereby acknowledge and agree that as Contractors for the Sunset Drive Downtown Median, as specified have the sole responsibility for compliance with all the requirements of the Federal Occupational Su6gv and Health Act of 1970. and all State and local safety and health reXu|otionu, and agree to indemnify and hold harmless the City of South Miami against any and all |iub|||ty, doinny. damages, |uoseu and expenses they may incur due to the failure nf(subcuntractor'anumus): to comply with such act or regulation. CONTRACTOR J\DA Enginee# /Co�tVactoz, Inc. Name Jose M. Al�azez FAILURE TO COMPLETE, SIGN, & RETURN THIS FORM MAY DISQUALIFY YOUR RESPONSE @ || (Updated m5-|6-zo|4 Page 26 List of Proposed Subcontractors and Principal Suppliers Sunset Drive Downtown Median BIDDER shall list all Proposed Subcontractors to be used on this project if they are awarded the Contract. Classification of Work Landscape Subcontractor Name .. Email Sodding & Turf Work responsible bidder within five (5) Electrical Bid Opening. Irrigation Paving Park Amenities Graphics NO SUBCONTRACTORS Utilities Excavation Building Structures Plumbing Painting Testing Laboratory Soil Fumigator Signs [Other: This list shall be provided to the City of South Miami by the apparent lowest responsive and responsible bidder within five (5) calendar days after Bid Opening. © thomasfpepe- 09 -28 -1 I (Updated 05 -16 -2012) Page 27 ADDENDUM No. I Project Name: Sunset Drive Downtown Median RFP RFP NO. I Not Applicable Date: July 16, 2012 Sent: Fax /E- mail /webpage This addendum submission is issued to clarify, supplement and /or modify the previously issued Request for Proposals (RFP) Documents, and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. • Proposal submittals shall include an electronic copy, either CD or flash drive, in addition to one original hard copy and three copies. • Bid Bond is Waived • Performance and Payment Bond (100% of the Total Cost) is required in accordance with Sec. 17 -6 of the City's Ordinance. • Estimated project cost $45K to $50K • Any requests for additional information or clarification should be submitted in writing by 2:00 PM, local time on Friday, July 13, 2012 to the attention of Steven Kulick, C.P.M. Purchasing Manager at skulick @southmiamifl.gov or via facsimile at (305) 667 -7806. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. �f nti y Y Fy ADDENDUM No. I Project Name: Sunset Drive Downtown Median RFP RFP NO. I Not Applicable Date: July 16, 2012 Sent: Fax /E- mail /webpage This addendum submission is issued to clarify, supplement and /or modify the previously issued Request for Proposals (RFP) Documents, and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. • Proposal submittals shall include an electronic copy, either CD or flash drive, in addition to one original hard copy and three copies. • Bid Bond is Waived • Performance and Payment Bond (100% of the Total Cost) is required in accordance with Sec. 17 -6 of the City's Ordinance. • Estimated project cost $45K to $50K • Any requests for additional information or clarification should be submitted in writing by 2:00 PM, local time on Friday, July 13, 2012 to the attention of Steven Kulick, C.P.M. Purchasing Manager at skulick @southmiamifl.gov or via facsimile at (305) 667 -7806. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. ADDENDUM No. 2 Project Name: Sunset Drive Downtown Median RFP RFP NO. Not Applicable Date: July 16, 2012 Sent: Fax /E- mail /webpage This addendum submission is issued to clarify, supplement and /or modify the previously issued Request for Proposals (RFP) Documents, and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. • The Bid due date is extended to Tuesday, July 24, 2012 at I I:00 AM. • Proposal submittals shall include an electronic copy, either CD or flash drive, in addition to one original hard copy and three copies. • Bid Bond is Waived • Performance and Payment Bond (100% of the Total Cost) is required in accordance with Sec. 17 -6 of the City's Ordinance. • Estimated project cost $45K to $50K • Any requests for additional information or clarification should be submitted in writing by 2:00 PM, local time on Friday July 20, 2012 to the attention of Steven Kulick, C.P.M. Purchasing Manager at skulick @southmiamifl.gov or via facsimile at (305) 667 -78060 IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. ADDENDUM No. 3 Project Name: Sunset Drive Downtown Median RFP RFP NO, Not Applicable Date: July 19, 2012 Sent: Fax /E- mail /webpage This addendum submission is issued to clarify, supplement and /or modify the previously issued Request for Proposals (RFP) Documents, and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. Question #I: Some of the line items in the schedule of values appear to be incomplete. Please provide the following: o Landscape — Large Plants (units, quantities) o Tree Root Barrier (units, quantities) o Irrigation o Thermoplastic - Yellow Lines (18 ")(units, quantities) Answer to #I: Please see attached revised Schedule of Values on Page 21 REVISED SCHEDULE OF VALUES IS PROVIDED ON PAGE 2: I U O U (z u 0) L W cz mc 1 c O cz N (z L O O Cz _ 70 L O V � O i O V � Q L � (n W •• Q � > �o IL V i 0 U cz 0 U ai w I LMM Cz U Cz O cz N cz i 0 JVA Engineering Contractor, Inc.- Equipment Owned as of May 31, 2012 ASPHALT PAVER IA -01 ASPHALT PAVER IA -02 ASPHALT PAVER IA -03 LEEBOY NEAL ALLAT 7000 DM -3000 SP -50 BACKHOES B -01 CAT 416 1990 BACKHOES B -02 JOHN DEERE 310 -D 1990 BACKHOES B -03 CAT 416 -C 1998 BACKHOES B -04 CAT 420E -IT 2009 BACKHOES B -05 JOHN DEERE 310 -D 1990 COLD PLANNER CP -01 ROADTEC RX400 SKID STEER S -01 MUSTANG 940 -E 1995 LOADER SKID STEER S -02 CAT 216 2000 LOADER SKID STEER S -03 CAT 248 2002 LOADER SKID STEER S -04 CAT 268 -B 2005 ,LOADER BROOM BS 01 MASSEY 243 2001 SWEEPER FERGUSON BROOM BS -02 TENNANT 355 SWEEPER BULLDOZERS D -01 CASE 450 -B 1983 BULLDOZERS D -02 CASE 850 -C 1984 BULLDOZERS D -03 CAT D5 -C 1996 BULLDOZERS D -04 CAT D -5G LGP 2004 EXCAVATORS E -01 JOHN DEERE 690 -DLC 1988 EXCAVATORS E -02 CAT 320 -CL 2004 EXCAVATORS E -03 CAT 325 -CL 2004 EXCAVATORS E -04 CAT 305 -CCR EXCAVATORS E -05 CAT 328DLCR 2007 GRADERS G -02 JOHN DEERE 670 -B 1988 GRADERS G -03 VOLVO G -80 2003 LOADER L -01 CAT 928 -G 2001 LOADER L -02 CAT 924 -G 2004 TACK MACHINE TM -01 PIPA 1988 TACK MACHINE TM -02 PIPA WATER TRUCK WT -02 FORD 1995 WATER TRUCK WT -01 INTERNATIONAL 1981 ROLLERS R -01 EAGER BEAVER SRH -150 ROLLERS R -02 ROSCO DELUXE ROLLPAC III ROLLERS R -03 INGRAM A -6T ROLLERS R -04 LEEBOY T -400 ROLLERS R -05 DYNAPAC CA -15 ROLLERS R -06 DYNAPAC CC -102 1994 ROLLERS R -07 CAT CB -214E 2006 ROLLERS R -08 DYNAPAC CA -252 2000 ROLLERS R -09 LEEBOY 400 2006 ROLLERS R -10 CAT CB -434 -D 2006 ROLLERS R -11 IFERGUSON SP -912 EIV G I"EERI"G CONTRACTOR, I N C . July 17, 2012 City of South Miami City Clerk 6130 Sunset Drive South Miami, FL 33143 Attn: City Clerk Re: JVA Engineering Contractors' Past Experience and Corporate References Please allow this letter to serve as an official listing of our active and completed jobs for the past five years, The following list provide corporate References for each project and show professional competency, manpower and financial capability to perform the scope of work for your project identified as Sunset Drive Downtown Median, The following is an official list of ]VA's completed and active projects from private and government sectors and corporate references that can verify our competence and reliability, All of the projects below were fully executed and submitted on a timely manner, JVA Engineering Contractor, Inc. provided all manpower, equipment, and maintenance facilities for the completion of these: Tri -C Construction Co, Inc. 100 W. Cypress Creek Rd. Ft. Lauderdale, FL 33309 Contact: Chris Lawrence Phone: (954) 677 -0356 Fax: (954) 677 -0359 2005 Tri - C Construction Co, Inc, - CVS Pharmacy #5897 37th & 199th Completion Date: January 2006 Amount: $371260.00 Scope of work: Water Distribution, Storm Water Dist, Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, 2005 Tri - C Construction Co, Inc. - CVS Pharmacy #7131 Kendall & 127th Completion Date: February 2006 Amount: $323,856.31 6600 NW 32 "d Ave Miami, FL 33147 Tel: 305 - 696 -7902' Fax: 305 - 696 -7903 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, 2007 Tri - C Construction Co, Inc. - CVS Pharmacy #6732 87th & Flagler Completion Date: August 2007 Amount: $688,823.45 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, John Moriarty & Associates of Florida, Ind. 1942 Tyler Street Hollywood, FL 33020 Contact: Bill Suarez Phone: (954) 261 -0781 Fax: (305) 944 -5352 2006 John Moriarty & Associates of Florida, Inc. — Trump Tower II Amount: $288,359.00 Scope of work: Water Distribution, Storm Water Dist, Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, 2006 John Moriarty & Associates of Florida, Inc. — Trump Tower III Amount: $ 298,024000 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. MAD Construction Corp. 3930 NW 26th Street Miami, FL 33142 Contact: Alan Janney Phone: (305) 871 -6410 Fax: (305) 871 -1293 2006 Trademark Metal Recycling Completion Date: January 2007 Amount: $365,820.00 Scope of work: Asphalt Pavement, Drainage Distribution. 2007 3939 NW 25th Street Completion Date: August 2007 Amount: $91,600.00 Scope of work: Storm Water Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. City of Sweetwater 500 SW 109th Avenue Sweetwater, FL 33174 Contact: Antero Espinosa Phone: (305) 221 -0411 Fax: (305) 480 3849 2007 Various Locations Improvements (Drainage, Concrete & Asphalt Pavement). Amount: $55,786.25 Completion Date: July 2007 Kimley -Horn and Associates, Inc. 1691 Michigan Avenue Suite 400 Miami Beach, FL 33139 Contact: Walter Lugo Phone: (305) 673 -2025 Fax: (305) 673 -4882 2007 Retail Building 87th & Flagler Completion Date: August 2007 Amount: $2,860,492.66 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. Village of Pinecrest 12645 Pinecrest Parkway Pinecrest, Florida 33156 Contact: Daniel F. Moretti Phone: (305) 669 -6916 Fax: (305) 669 -6919 2007 SW 791h Ave Roadway Improvements Completion Date: November 2007 Amount: $280,196.50 Scope of work: Storm Water System, Asphalt Pavement, Concrete Pavement, 2007 SW 70th Ave Improvements Completion Date: August 2007 Amount: $10,700.000 Scope of work: Storm Water System, Asphalt Pavement, Concrete Pavement, KM Plaza Construction Services 120 NE 27th Street Suite 600 Miami, FL 33137 Contact: Robert Lalle Phone: (786) 693 -8717 Fax: (786) 693 -8738 2007 Town Center One at Dadeland Completion Date: December 2008 Amount: $490,000.00 Scope of work: Water Distribution, Storm Water Dist., Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. Miami -Dade County Aviation Department 4200 NW 36st Street, Building 5A Miami, FL Contact: Johnny Peterson Phone: MIA- NW 67th Ave & NW 36th Street Intersection Improvements Completion Date: October 2011 Value: $977,000.00 Scope: Storm Sewer Distribution and Roadway Reconstruction Miami -Dade County -Park & Recreation Department 11395 SW 79th Street Miami, FL 33173 Contact: Dan Crawford Phone: 305 - 596 -4460 Ext: 239 2007 Biscayne Garden Park Improvement Completion Date: November 2007 Amount: $329,601.10 Scope of work: Storm Water Dist., Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, Miami Dade County Public Works Department 111 NW 1 Street Miami, FL 33128 Contact: Jesus Gonzalez Phone: 305 375 2172 2008 WASD Roadway Rehabilitation Contract Completion Date: June 2008 Amount: $323,000.00 Scope of work: Asphalt Pavement Miami Dade County Public Works Department 111 NW 1 Street Miami, FL 33128 Contact: Nestor Melian Phone: 786 - 375 -0004 PTP Pavement Marking Installation Completion Date: October 2011 Amount: $ 356572.78 Scope of Work: Pavement Markings 200897 th Ave Roadway Widening Completion Date: January 2009 Amount: $ 5141615.63 Scope of work: Asphalt Pavement, Clearing, Grubbing, Earthwork, Utility Adjustments, Fencing & Guardrail, and Concrete Miami Dade County Water & Sewer Department 3071 SW 38 Ave, Miami, FI 33146 Contact: Nelson Cespedes Phone: 786 552 8142 Perrine Cutler Ridge Water & Sewer Improvements Completion Date: Active Project Number: TP0067 Amount: $2,254,103.10 Scope of Work: Water Main, Gravity Sewer and Force Main Furnish and Install 36 -Inch DI Water Main in NW 87th Ave Completion Date: Active Project Number: T1562 Amount: $907,216.57 Scope of Work: Water Main, Gravity Sewer and Force Main Install 24" DI Water Main Project Number: ER# 15865 Amount: $698,858.67 Scope of work: Water Distribution, Asphalt Pavement NAP Misc. -12 Sanitary Sewer Improvements Project Number: RPQ T1026 Amount: $ 838,558.26 Scope of work: Gravity Sewer, Force Main, Asphalt Pavement Restoration, Concrete City of South Miami 4795 SW 75th Avenue Miami, FL 33155 Contact: Ajibola Balogun Phone: (305) 668 -7355 City Hall 12 -Inch Water Main Extension Amount: $217,851.15 i Scope of work: Water Distribution, Asphalt Pavement Citywide Resurfacing Project Phase II Project Number: SM- 2011 -16 -PW Amount: $$195,788.34 Scope of Work: Road Resurfacing, Milling, Clearing and Grubbing, Asphalt Placement, Retro Reflective Pavement Markers and Striping City of Miami 444 NW 2nd Ave, Miami, FL 33131 Contact: Eric Rush 2011 Kinloch Storm Sewer Improvements PH -II Completion Date: November 2011 Amount: $898,630.00 Scope of Work: Storm Sewer Distribution and Roadway Reconstruction Port of Miami 1015 North America Way Miami, FL 33132 Contact: Bart Sanfilipo Phone: 305 - 347 -4988 Contact: Juan Bergouignan Phone: 305 - 347 -4974 Scope of work: Various Site and Marine Construction Opa Locka Head Start Facility Amount: $165,000.00 Scope of work: Water Distribution, Storm Water Dist., Excavation & Grading, Asphalt Pavement, YEMC Construction 14750 SW 24th Street Miami, FL Contact: Carlos Armas Phone: (305) 219 0862 Coral Way Offices Amount: $105,067.50 Scope of work: Storm Water Dist, Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, Gamma Construction 4850 SW 72 Ave Miami, FL 33155 Contact: Jorge Jones Phone: 305 661 1569 Community Bible Baptist Church Amount: 214,417.00 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, VP Construction 7600 Red Rd #128 Miami Fl 33143 Contact: George Perendes Phone: (305) 667- 6060 Valencia Village Amount: $218,276.50 Scope of work: Water Distribution, Storm Water Dist, Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement, FDOT 1000 NW 111th Ave, Room 6203 Miami, FL 33172 Contact: John Bolton Phone: 305 - 654 -7019 Fax: 305 - 654 -7020 Roadway Improvements on SR 959 Coral Way to SW 22nd Street Amount $73,932.00 Scope of Work: Drainage, and Asphalt Restoration, Striping and Signage. Alvarez Engineers, Inc. 10305 NW 41 St. Suite 103 Doral, FL 33178 305 - 640 -1345 Waterstone Way Amount $1,054,313.50 Scope of Work: Concrete, Drainage, Asphalt Striping, Manhole, Manhole, Sanitary Sewer, and 8" Water Main Beacon Tradeport Development District Amount $120,000 Scope of Work: Concrete City of OPA =LOCKA 780 Fisherman Street Opa- Locka, FL 33054 Contact: Nasir Mohammad Phone: 786 - 382 -7917 Fax: 305 - 953 -2824 NW 143rd Street Drainage & Roadway Improvements Project Completion Date: Active Project Number: 11 -201 21 00 Amount: $468,644.80 Scope of Work: Installation of new Drainage System, Road Rehabilitation, Repair and Renovations of existing Sidewalks City of Hollywood 2600 Hollywood Blvd, Hollywood, FL Contact: Clece Aurelus Phone: 954 - 805 -3681 Fax: 954 - 921 -3258 Distribution Piping Upgrades on N 56th Ave from Douglas Street to Stirling Road to N 58th Ave. Completion Date: Active Amount: $930,000.00 Scope of Work: 8" Water Main and Site Restoration If you have any questions, please do not hesitate to contact us. Sincerely, Jose M. Alvarez, President JVA Engineering Contractor, Inc. CESAR R. GONZALEZ 7810 S.W. 131 Avenue Miami, Florida 33183 (305) 382 =3920 ACADEMIC BACKGROUND Fall 1994 Bachelor of Science Degree in Civil Engineering, Florida International University in Miami, Florida. LICENSE STATE GENERAL CONTRACTOR LICENSE Issued: December1 S, 2001 EXPERIENCE Fifteen Years of Professional Experience in Civil and Environmental Engineering, Feb. 2009 to Civil Engineering/Project Manager, JVA Engineering Contractor, Inc Present Planning, design, and construction of countywide projects involving storm sewers, storm water pump stations and drainage wells, road reconstruction and street resurfacing. Sep. 2007 to General Contractor, Feb. 2009 Building new construction of single family homes, commercial and residential additions by own Contractor's Company. August2004 to Senior Project Manager, City of Miami Department of Capital Sep. 2007 Improvements Advance professional and administrative work with management responsibilities, planning, directing, designing and coordinating the activities of project managers and the staff of C.I.P. to city wide engineering projects to ensure that goals or objectives are accomplishes within prescribed time frame and funding parameters. Supervision is exercised over project managers, engineers and construction professionals, and administrative or related staff. Oct. 2002 to Project Manager, City of Miami Department of Capital Improvements. August 2004 Planning, design, and construction of capital improvements projects involving storm sewers, storm water pump stations and drainage wells, road reconstruction and street resurfacing. Supervise the preparation of finished plans and specifications for CIP projects. Supervise and assist inspectors in overseeing construction work. Plan, assign, and supervise the work of an engineering team within the Civil Engineering Division of the Department of Capital Improvements Programs. Serve as a technical member of the Consultant selection Committee for the procurement of professional engineering services of CIP projects. June. 1996 to Civil Engineer I, City of Miami Department of Public Works. Oct. 2002 Senior Project Manager for a variety of complex public works projects under Civil/ Highways/ Environmental category from design to construction phase including preparation of bid specifications, field inspection, and complete coordination with utility companies and other public and private agencies. Experienced in water main design, sanitary sewer design, parking lot development including calculations and irrigation systems, and roadway and drainage improvements. Oversee Public Works Consultant projects using and implementing best management practices. Assigned to daily supervision of plans review under Building and Zoning Department and also Hearing Boards. Prepare and execute Covenants for non standard improvements in the public right of way in coordination with several City Departments, Nov. 1995 to Engineer Technician III, City of Miami Department of Public Works. June 1996 Assigned to perform line and grade inspections for P.W. under the Construction Division. Assists project manager in providing inspection services on complex project during construction and coordinating with the neighbors. April 1992 to Engineering Assistant, City of Miami Department of Public Works. Nov. 1995 Assisted Professional Engineers in editing designs in computer, locating underground details for engineering projects, and field inspections (Topography and Leveling). SKILLS Speak and write fluently in English and Spanish (native speaker). Proficient with ACAD 2000, EXCEL, WORD and WINDOWS NT. Very familiar with the permitting process at MDWASD, DERM, Florida Department of Health, MIAMI- DADE Public Works. REFERENCES Available upon request. Miami -Dade Branch Ph: (305) 696 -7902 6600 NW 32 Ave Fax: (305) 696 -7903 Miami, FL 33147 e -mail: jma @jvaengineering.com Jose Mario Alvarez Experience 2002- Current JVA Engineering Contractor, Inc. President 2011 Miami -Dade Water & Sewer Improvements - Perrine /Cutler Ridge Water & Sewer Improvements Basin A P0067- 4,991 LF of Water Main Installation, 5,035 LF of Sanitary Sewer Installation and 848 LF of 12" Gravity Sewer Installation, Sewer Lateral Installations and Restoration 2011 Miami -Dade Aviation Department- MIA NW 67th Ave and NW 36th Street Intersection Improvements, Land Clearing, Excavation, Earthwork, Pre - Stressed Concrete Pipe Storm Sewer Distribution, Subgrade, Base and Asphalt Pavement 2011 City of Miami- Kinloch Storm Sewer and Road Construction Project, Storm Drainage Distribution, Asphalt Pavement, and Concrete Work 2010 Marlins Ballpark, Storm Water Distribution 2009 Miami -Dade Water & Sewer- 8" Water Main Extension, Excavation Water Main Distribution, Restoration including Asphalt Pavement, and Concrete work 2009 Miami -Dade County Water & Sewer Department, NAP Misc. 12" Sanitary Sewer and Force Main Improvements, sanitary sewer and force main replacements, asphalt restoration, concrete restoration. 2009 Miami -Dade County Water & Sewer Department, Pump Station No. 57 Upgrade Sewage Pump Station including place suitable backfill material; refurbish wet well; electrical work, concrete sidewalk; and restoration 2009 Miami -Dade County Water & Sewer Department, Pump Station No. 46 Upgrade Sewage Pump Station including place suitable backfill material; refurbish wet well; electrical work, concrete sidewalk; and restoration 2009 Port of Miami, Cruise Terminal D &E Runway Extension for PBB and Mooring Bollards Construction of reinforced concrete runway and wheel pad slabs; compression auger cast piles; mooring bollards foundation concrete caps; tension auger cast piles; procurement and installation of six mooring bollards and demolition of abandoned electrical bays 2009 Port of Miami, Fender /Curb /Pad Eye Plate Repairs And Installation - Gantry Area Installation of fenders, pad eyes, and curbs for seawall. 2008 Miami -Dade Public Works, Rdwy Widening of 97th Ave Clearing & Grubbing, Excavation, Limerock Base, Milling, Paving, Concrete Work, Fencing & Guardrails, Electrical Work, Roadway Widening Signage, Pavement Markings & Signage, and Construction of New Roads 2008 Alvarez Engineers, Waterstone Way Widening at SW 312 St Clearing & Grubbing, Excavation, Limerock Base, Milling, Drainage, Manhole Installations, Paving, Concrete Work, Fencing & Guardrails, Electrical Work, Roadway Widening Signage, Pavement Markings & Signage 2008 FDOT, SR 959 Rdwy Improvements Excavation, Drainage Limerock Base, Milling, Paving, Signage, Pavement Markings 2008 John Moriarty & Associates of Florida Icon Brickell Site Work, Storm Drainage System, Sanitary Sewer System and Water Distribution, Asphalt Pavement, Concrete Work, Pavement Markings & Signage Certifications 2008 Miami -Dade Water & Sewer Department, Nap Misc, 12" Sanitary Sewer and Force Main Project Installation of 12" DIP Sewage Force Main, 12" DIP Gravity Sewer, Manhole installation and Pavement Repairs 2008 Miami -Dade County Water & Sewer Department, Installation of 24" DI Water Main, Construction of 24" Iron Ductile Water Main sub aqueous crossing canal C103 2008 Village of Pinecrest, Public Works Complex Drainage and Asphalt Resurfacing, Drainage and Asphalt Resurfacing 2008 City of South Miami, City Hall Water Main Improvements, Installation of 12" Water Main along Sunset Dr. and Asphalt Restoration 2008 Miami -Dade County, WASD Roadway Rehabilitation, Street Asphalt Pavement Rehabilitation 2008 Coreland Construction Co, Opa -Locka Head Start Facility, Storm Drainage System, Sanitary Sewer System, Water Distribution, Asphalt Pavement 2007 Miami -Dade County Park & Recreation Department, Biscayne Garden Park Improvements, Grading, Drainage, & Sidewalk 2007 KM Plaza, Town Center One at Dadeland, Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2007 Tri - C Construction Co, Inc. - CVS Pharmacy #6732 87 & Flagler Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2007 Robertson Properties Group — Nationwide Theaters, W. Flagler St Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2007 City of Sweetwater — Various Street Improvements Storm Drainage System, Sidewalks & Asphalt Paving 2006 John Moriarty & Associates of Florida, Inc. — Trump Tower II Site Work, Storm Drainage System, Sanitary Sewer System and Water Distribution 2006 John Moriarty & Associates of Florida, Inc. — Trump Tower III Site Work, Storm Drainage System, Sanitary Sewer System and Water Distribution 2005 Tri - C Construction Co, Inc. - CVS Pharmacy #5897 37th & 199th Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2005 Tri - C Construction Co, Inc. - CVS Pharmacy #7131 Kendall & 127th Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2009 -2012 2010 State of Florida Army Corp of Engineers- Quality Control Manager OSHA 30 -Hour Certified General Contractor #CGC1516849 Certified Underground Utility Contractor #CUC1224696 Broward License Primary Pipelines License # 07- 1A14144 -X Major Roads License # 07 -3A- 14148 -X Miami Dade County License Engineering Contractor License # E221300 Education 2002— Current Associate in Arts Miami Dade Community College Miami, FI 1999 -2002 South West High School Diploma Miami, Fl High School Diploma ALVAREZ JOSE M Is n Now undo ft ON" 0003 0007 0009 0010 @�Gkna ** sawd SS CERTIFICATE OF E221300 -C�CLL= QUALIFYING TRADE(S) PIPE LINE ENG PAVING ENGINEERING EXCAU 6 GRADING ENG LAND CLEAR 3 GRUBY X61 I. I L. vI FL-v►w%IUH DEPARTMENT OF BUSINESS AND PROF E-1;; tJA;: CONSTRUCTION INDUSTRY LICENSI1N7G BOARD 1940 NORTH MONROE STREET TALLAHASSEE FL 32399 -0 '783 ALVAREZ, JOSE M JVA ENGINEERING CONTRACTOR INC 6600 NW 32ND AVE MIAMI FL 33147 Congr)tulationsl With this license �.:f; >..,., )(I 'e ;ne ,f rile ,,e,ir;, Floridians licensed by the Department J} f!II i nP5 i 1n,J }� Ci }NStidjn jl iZ? jU' ]hr r' Our professionals and businesses r )n Je fn�m _tnh�te�as to y,lcht tlr�:kers boxers to barbegue feSteuflrltS any -! rhey ko.�p f I- )r „(. -1 S •'CCr!imI%j Every day we'•vork to unprove the ,v.ly Ae .!u For information about our sernres I•I. „_f ,�r,tr�wN,myfloridaticense com There you can find nuxe ulf�.�rmah�'F) .1bC111 iur f.!r,i;�ons ,1n�1 the r.�)f�lahc n•; rr 1� mpaCt YOU, Subscribe t0 .IP, parjrllefjt ,1 ?,y SI ?t!ori lll�! IY�aln tl. )(? ,7I), )'It II .� Departments initlatp�es Our mission at the Departments License Effirlr�ntly. Regul,lte Thank you for doing lu Prlests in Fexi(jzj. land'ron p It lat,0M. o(IjOUrt1,0W ��e ra�.;II �tl IlF STATE OF FLORIDA X350) 487 -1395 j. SrArEUrFI.rHIDa ACd k DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CGC1516849 06/02/10 098169897 CERTIFIED GENERAL CONTRACTOR ALVAREZ, JOSE M JVA ENGINEERING CONTRACTOR INC IS CF.RTIFTEr) in 14r rh• provision* of Ch. 489 Fs ” `At: " It AUG 11 • 2012 L100602009 ?4 DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSI;IG BOARD DATE BATCH NUMBER LICENSE NBR - - -- SEQ# L100602008 34 06 02/2010 110 98169897 CGC1516849 The GENERAL CONTRACTOR Named below IS CERTIFIED Under the provisions of Chapter 489 FS. Expiration date: AUG 31, 2012 ALVAREZ, JOSE M JVA ENGINEERING CONTRACTOR INC 6600 NW 32ND AVE MIAMI FL 33147 CHARLIE CRIST GOVERNOR DI;SPLAY AS REQI)IF?Eli R—r t_,:y CHARLIE LIEM INTERIM SECRETARY STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL,-, r,c;•'J` AI T `CI CONSTRUCTION INDUSTRY LICENSING BOARD 1940 NORTH MONROE STREET TALLAHASSEE FL 32399 -0783 ALVAREZ, JOSE M JVA ENGINEERING CONTRACTOR INC 6600 NW 32ND AVE MIAMI FL 33147 Congratulations! With this hcense y,)u t;ecome une of the nearly one nnlhoo Floridians licensed by the Department of 13us1ness and Professional Rey +,lat c r. Our professionals and businesses tinge from architects to yacht hrokers fri;in boxers to barbeque restaurants, sand they keep Flonda s economy °;trony Every day we work to improve the N,ry 'Ne do business 0 order to verve irn., b,: rtes For information about our services. ple• +se loy unto www.myfforidalicense.cona There you can find more information About our d,vislons and the regul:lh�ms tt�,11 impact you. subscribe to depa,tment newsletters .and 4�arn more about !I:e Departrnent*s initiatives Our mission at the Department is Lice11Se Efficiently, Regulate F_nrly l +le constantly strive to serve you better so that you can carve your custc;m rs Thank you for doing business in Florida..ind congratulations on your new hcefigw DE cACH IIFRF `� -1- STATE OF FLORIDA !350) SrArE OF FLORIDA t t+ = DEPARTMENT OF PROFESSIONAL 487 -1395 AC# 1.19 8 It BUSINESS AND REGULATION CUC1224696 06/02/10 098169893 CERT UNDERGROUND & EXCAV CNTR ALVAREZ, JOSE M JVA ENGINEERING CONTRACTOR INC IS CERTIFIED indar the provisions of Ch.489 FS o 30-•1 AUG 31, 2012 L10060201011 DEPARTMENT OF BUSINESS AND PROFESSIONAL RE(IUL:ATION CONSTRUCTION INDUSTRY LICENSING BOARD _ SEQ# L10060201019 LICENSE NBR 06/02/20101098169893 ICUC1224696 The UNDERGROUND UTILITY & EXCAVATION CO Named below IS CERTIFIED Under the provisions of Chapter 489 FS. Expiration date: AUG 31, 2012 ALVAREZ, JOSE M JVA ENGINEERING CONTRACTOR INC 6600 NW 32ND AVE MIAMI FL 33147 CHARLIE CRIST GOVERNOR DISPt_AY AS REOI)IREU RY I.A,', CHARLIE LIEM INTERIM SECRETARY 140 W, FLAGLER ST. 1st FLOOR MIAMI, FL 33130 . , , , 492516 -1 BUSINESS NAME / LOCATION JVA ENGINEERING 6600 NW 32 AVE 33147 UNIN DADE nu..nn-vMaiG a %Jvl•I ► - MAIM VE- hLURIDA EXPIRES SEPT. 30, 2012 MUST BE DISPLAYED AT PLACE OF BUSINESS PURSUANT TO COUNTY CODE CHAPTER SA - ART. 9 8 10 THIS IS NOT A 131LL - DO NOT PAY RENEWAL CONTRACTOR INC CC SIRE E221300 5141 COUNTY OWNER JVA ENGINEERING CONTRACTOR INC Sec, rryy of Business 19r SPECIALTY ENGINEERING CONTRACT r1 +1S IS ONLY A LOCAL DUSWESS rAX RECEIPT. IT ^CES 1401 PERMIT Mg (OLDER TO VIOLArt ANY EXISTING REGULA rORY OR IOffWa LAWS Of THE COUNTY :,R Cr T+ES. V+on DOES IT EXEMPT rHE PER4ff FROM ANY CENSE REGUIREO BY law. 1`1+11 19 'rot A CERTIMAnON OR 0411 HOLDER'S OUALr➢1CA• nONs. PAYMENT RECEriEO 'AIAWOADE COUNTY TAX COLLECTOR; 07/18/2011 02210018001 000075.00 SEE OTHER SIDE MIAMI -DARE COUNTY TAX COLLECTOR 140 W. FLAGLER ST. 1 at FLOOR MIAMI, FL 33130 WORKER /S 1 DO NOT FORWARD JVA ENGINEERING CONTRACTOR INC JOSE M ALVAREZ PRES 6600 NW 32 AVE MIAMI FL 33147 2011 MUNICIPAL CONTRACTOR'S 2012 TAX RECEIPT MIAMI -DADE COUNTY • STATE OF FLORIDA PURSUANT TO COUNTY CODE SEC, 10 -24 EXPIRES SEPT. 30, 2012 THIS IS NOT A BILL - DO NOT PAY RECEIPT NO. 30- 5141858 CC N0: E221300 BUSINESS NAME / LOCATION JVA ENGINEERING CONTRACTOR INC 6600 NW 32 AVE OWNER :JVA ENGINEERING CONTRACTOR INC 124 RECEIPT HOLDER !.1A BUSINESS AS A CONI AS SPECIFIED HEREC SEE BACK OF RECEIPT FOR SPECIALTY ENGINEERING CONTRA A LIST OF NON- PARTICIPATING MUNICIPALITIES Rece ;pt holder must 00 NOT FORWARD register in the city .,,here Nor$( 13 to be JVA ENGINEERING CONTRACTOR INC done. JOSE M ALVAREZ PRES 6600 NW 32 AVE MIAMI FL 33147 ,A,"eT+T .LCe.ro MIAMI -DADE COUNTY 2011 LOCAL BUSINESS TAX RECEIPT 2012 TAX COLLECTOR MIAMI -DADE COUNTY, STATE OF FLORIDA 140 W. FLAGUER ST. EXPIRES SEPT. 30, 2012 1st FLOOR MUST BE DISPLAYED AT PLACE OF BUSINESS MIAMI, FL 33130 PURSUANT TO COUNTY CODE CHAPTER 8A - ART. 9 & 10 656211 -1 -- .iNFSS TAX nF_E1PT IT BUSINESS NAME / LOCATION :ER TO - ,'a;LATF JVA ENGINEERING A t CRY ,[R CONTRACTOR INC 6600 NW 32 AVE :5 IT Elf'APT 33147 UNIN DADE ANY )TITER COUNTY OWNER ;WPED BY LAIN I1 „5 S ' A -Ent 'i'', JVA ENGINEERING CONTRACTOR INC ScC. Type 01 BU91f)Q8S 196 GENERAL BUILDING CONTRACTOR S :S -'1 r A .. K: AI -- .iNFSS TAX nF_E1PT IT 'S 'JOT PFIMIT '14E :ER TO - ,'a;LATF allot ;NNG iEGIp. A t CRY ,[R PING LA NS 'IF n.E .NTY IR :• "FS 'Wn :5 IT Elf'APT ').E DER+m`IA ANY )TITER 'MIT IR :',9E ;WPED BY LAIN I1 „5 S ' A -Ent 'i'', -AT, N IF .F is VENT PE r FD 'A C'ADF. NTY '.1X if CaCq 07/18/2011 02210018004 000075.00 SEE OTHER !;IOF FIR (I S. N PERT RENEWAL RECEIPT NO. 683274 -6 STATE# CGC1516849 WORKER /S 1 DO NOT FORWARD JVA ENGINEERING CONIRACTOR INC JOSE M ALVAREZ PRES 6600 NW 32 AVE MIAMI FL 33147 11, 11111111, I I 1 1 I 1 1111, 1, 1111111111 I I l ill III I M ,11111111441 MIAMI -DADE COUNTY 2011 LOCAL BUSINESS TAX RECEIPT 2012 TAX COLLECTOR MIAMI -DADE COUNTY - STATE OF FLORIDA 140 W. FLAGLER ST. EXPIRES SEPT. 30, 2012 1st FLOOR MUST BE DISPLAYED AT PLACE OF BUSINESS MIAMI, FL 33130 PURSUANT TO COUNTY CODE CHAPTER 8A - ART. 9 & 10 I! w, .`; ; ll ) I AY Iii 1. ! -J) ^i(') I- PA IT` 656212 -9 BUSINESS NAME ! LOCA FION JVA ENGINEERING CONTRACTOR INC 6600 NW 32 AVE 33147 UNIN DADE COUNTY OWNER JVA ENGINEERING CONTRACTOR INC Sec. type of Business 196 SPECIALTY ENGINEERING CONTRACT •NL• A ?a AL NESS :Ad :IEC F.PT .r S lair .'FPVIT '1,F :ER I'1 ..nl .A7E ',NY �I FIG PF -;,P-A' iq. • R NG •A,VS ,.'.F '•,E S iT -`.IPr naF ')FR,nr,V ANY )!;,FIT MI "q "1 <E .;.NFU 9v �.AN !Ws o! A FN!if','A1It'N .F PIF`4T -it tF .EO Al CA[ F "I •I 'A[ I E,. • q 07/18/2011 02210018003 000075.00 FIR U S. M PERT RENEWAL RECEIPT NO. 683275 -3 STATE# CUC1224696 WORKER /S 1 DO NOT FORWARD JVA ENGINEERING CONTRACTOR INC JOSE M ALVAREZ PREPS 6600 NW 32 AVE MIAMI FL 33141 125 � ��M CERTIFICATE OF LIABILITY INSURANCE DATE (MM /D2011) lz /lz /zo11 PRODUCER (305)822 -7800 FAX (305)558 -4294 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Collinsworth, Alter, Fowler & French LLC ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE 8000 Governors Square Blvd HOLDER, THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Suite 301 Miami Lakes, FL 33016 INSURERS AFFORDING COVERAGE NAIC IN INSURED IVA Engineering Contractor, Inc. INSURER A: National Trust Insurance Co 20141 6600 SW 32nd Ave INSURERS: FCCI Insurance Company 10178 Miami, FL 33147 INSURERc: Federal Insurance Company 20281 INSURER D INSURER E .oWA'A� .z•31*1 � THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADD'L TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS A GENERAL LIABILITY X COMMERCIAL GENERAL LIABILITY CLAIMS MADE OCCUR IX BLANKET ADDTL INSD GL0009584 XCU NOT EXCLUDED 12/13/2011 12/13/2012 EACH OCCURRENCE $ 1,000,00 DAMAGE TO RENTED $ loo, 00 MEO EXP (Any one person) $ 5 , 00 PERSONAL 8 ADV INJURY $ 19 000, 00 X WAIVER OF SUBRO GENERAL AGGREGATE $ 2 , 000, 00 GEN'L AGGREGATE LIMIT APPLIES PER: POLICY X PRO- JECT LOC PRODUCTS - COMP /OP AGG $ 29000,000 AUTOMOBILE LIABILITY ANY AUTO ALL OWNED AUTOS CA0014904 12/13/2011 12/13/2012 COMBINED SINGLE LIMIT (Ea accident) $ 11000,000 X A SCHEDULED AUTOS HIRED AUTOS BODILY INJURY (Per person) $ X NON -OWNED AUTOS BODILY INJURY (Per accident) $ X PROPERTY DAMAGE (Per accident) $ GARAGE LIABILITY AUTO ONLY - EA ACCIDENT $ ANY AUTO OTHER THAN EA ACC $ AUTO ONLY: AGG $ A EXCESS/UMBRELLA LIABILITY OCCUR FI CLAIMS MADE UMB0009901 12/13/2011 12/13/2012 EACH OCCURRENCE $ 19000,000 X AGGREGATE $ 19000,000 $ RETENTION $ 10,00 X1DEDUCTIBLE $ WORKERS COMPENSATION AND EMPLOYERS' LIABILITY 001WC11A63078 12/13/2011 12/13/2012 X WC STATU- OTH- B ANY PROPRIETOR /PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? If yes, describe under SPECIAL PROVISIONS below. � ITCA�ID MARINE C DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES / 4546 -50 -46 12/13/2011 12/13/2012 EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS E.L. EACH ACCIDENT $ 11000,000 E.L. DISEASE - EA EMPLOYE $ 11000,000 E.L. DISEASE - POLICY LIMIT $ 19000,000 LEASED /RENTED EQPT $100,000. SCHEDULED EQPT $1,168,400. MISC. TOOLS $10,000. ity of South Miami is named as additional insured with respect to general liability. Leased/Rented coverage term 6 months. After 6 months equipment needs to be scheduled on the policy. City of South Miami 6130 Sunset Drive South Miami, FL 33143 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES. AUTHORIZED REPRESENTATIVE Michael Nielson /EDITH A%% Vrlu zD tzuU1/U0) ©ACORD CORPORATION 1988