Loading...
Res No 073-16-14628RESOLUTION NO.: _0_7_3_-_1_6_-_1_4_6_2_8 __ _ A Resolution authorizing the City Manager to negotiate and to enter into a contract with Centurion Partners Health & Fitness d/b/a Fitnessmith for new exercise equipment at the Gibson-Bethel Community Center. WHEREAS, the City's Parks and Recreation Department desires to install new exercise equipment for our active residents at the Gibson-Bethel Community Center; and WHEREAS, a majority of the current exercise equipment was donated by the University of Miami and Police Department. This equipment consists of a variety of cardio and weight training apparatus. Several pieces of equipment are in poor condition and outdated; and WHEREAS, in response to RFP #PR2016-05, the Contractor is responsible for including a trade-in allowance for the existing cardio and strength equipment, removal of existing equipment and carpet flooring; and, installation of new rubberized commercial gym flooring, new commercial cardio and strength exercise equipment and three (3) 32" LED Samsung televisions; and WHEREAS, in an effort to reduce the City's insurance, prevent workout injuries and limit patrons who lift -and then drop -weights to get in shape, the City will replace all free benches, including incline, decline, and flat, with Smith Machines. A Smith Machine is a piece of equipment used in weight training; it consists of a barbell that is fixed within steel rails, allowing only vertical or near-vertical movement; and WHEREAS, all existing dumbbells, including those that are greater than 75 pounds will be replaced with new dumbbells 75 pounds and less. The current carpet flooring will be replaced with commercial rubberized gym flooring to absorb the impact of weighted objects; and WHEREAS, the City submitted a Request for Proposal (RFP) #PR2016-05 on Monday, March 7, 2016 for "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center." The City received two (2) proposals that were evaluated, ranked and scored by a Selection Committee on Wednesday, April 6, 2016; and WHEREAS, the Evaluation Committee has declared Life Fitness as non-responsive for failing to provide a quote for rubberized commercial gym flooring and three (3) LED Samsung flat screen televisions. Both the City Attorney and Procurement Division Manager concur that Life Fitness proposal is non-responsive; and WHEREAS, Centurion Partners Health & Fitness d/b/a Fitnessmith was the highest ranked respondent and is recommended for project #PR2016-05. Furthermore, Fitnessmith bid at $95,527.77 can be completed well within the City's allocated budget of $121,000 in its Capital Improvement Program for this project; and WHEREAS, City staff consulted with the contractor's references as to hands on experience and received positive feedback. Based on the aforementioned information, City staff recommends entering into an agreement with Fitnessmith due to quality and durability of eqUipment, cost, qualification and experience; and , __ a Pg. 2 of Res. No. 073-16-14628 WHEREAS, the total expenditure in the amount of $95,859.80 shall be charged to the Parks and Recreation Capital Improvement account number 301-2000-572-6450, which has a balance of $257,942 before this request was made. NOW, THEREFORE, BE IT RESOLVED BY THE MAYOR AND CITY COMMISSION OF THE CITY OF SOUTH MIAMI, FLORIDA THAT: Section 1. The City Manager is authorized to negotiate and to enter into a contract with Centurion Partners Health & Fitness d/b/a Fitnessmith for an amount not to exceed $95,5277.77 for the purchase and installation of new fitness equipment at Gibson-Bethel Community Center. The City Manager is also authorized to expend an additional $5,000 for any unknown factors that may arise. Section 2. Severability. If any section clause, sentence, or phrase of this resolution is for any reason held invalid or unconstitutional by a court of competent jurisdiction, the holding shall not affect the validity of the remaining portions of this resolution. Section 3. Effective Date. This resolution shall become effective immediately upon adoption by vote of the City Commission. PASSED AND ADOPTED this 19th:lay of April ,2016. ~ MAYO COMMISSION VOTE: 5-0 Mayor Stoddard: Yea Vice Mayor Welsh: Yea Commissioner Edmond: Yea Commissioner Liebman: Yea Commissioner Harris: Yea ,- THE CITY OF PLEASANT LIVING TO: FROM: Via: DATE: SUBJECT: BACKGROUND: CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM The Honorable Mayor & Members of the City Commission Steven Alexander, City Manager Quentin Pough, Director of Parks & Recreation " Aprif 19, 2016 Agenda Item NO.:_"_ A Resolution authorizing the City Manager to negotiate and to enter into a contract with Centurion Partners Health & Fitness d/b/a Fitnessmith for new exercise equipment at the Gibson-Bethel Community Center. The City's Parks and Recreation Department desires to install new exercise equipment for our active residents at the Gibson-Bethel Community Center. A majority of the current exercise equipment was donated by the University of Miami and Police Department. This equipment c~nsists of a variety of cardio and weight training apparatus. Several pieces of equipment are in poor condition and outdated. In response to RFP #PR2016-0S, the Contractor is responsible for including a trade-in allowance for existing cardio and strength equipment, removal of existing equipment and carpet flooring; and, installation of new rubberized commercial gym flooring, new commercial cardlo and strength exercise equipment and three (3) 32" LED Samsung televisions. In an effort to reduce the City's insurance, prevent workout injuries and limit patrons who lift -and then drop -weights to get in shape, the City will replace all free benches, including incline, decline, and flat, with Smith Machines. A Smith Machine is a piece of equipment used in weight training; it consists of a barbell that is fixed within steel rails, aI/owing only vertical or near-vertical movement. Furthermore, the existing real squat machine will be replaced with a Smith Machine and the free- standing bicep curl bar will be replaced with a biceps curl apparatus machine. All existing dumbbells, including those that are greater than 75 pounds will be replaced with new dumbbells 75 pounds and less. The current carpet flooring will be replaced with commercial rubberized gym flooring to absorb the impact of weighted objects. City personnel will continue to staff and enforce rules at the fitness room. • t ~ South rMiami THE CITY OF PLEASANT LIVING VENOORS& BIOAMOUNT: EXPENSE: FUNO& ACCOUNT: CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM -' The City submitted a Request for Proposal (RFP) #PR2016-05 on Monday, March 7, 2016 for "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center." The City received two (2) proposals that were evaluated, ranked and scored by a Selection Committee on Wednesday, April 6, 2016. The Evaluation Committee has declared life Fitness as non-responsive for failing to provide a quote for rubberized commercial gym flooring and three (3) LED Samsung flat screen televisions. Both the City Attorney and Procurement Division Manager concur that Ufe Fitness proposal is non-responsive. Centurion Partners Health & Fitness d/b/a Fitnessmith was the highest ranked respondent and is recommended for project #PR2016-05. Furthermore, Fitnessmith bid at $95,527.77 can be completed well within the City's allocated budget of $121,000 in its Capital Improvement Program for this project. As a value added feature, Fitnessmith is waiving its fee and providing the City with four (4) quarterly preventative maintenance visits per year for three (3) years valued at $3,600 dollars. City staff consulted with the contractor's references as to hands on experience and received positive feedback. Based on the aforementioned information, City staff recommends entering into an agreement with Fitnessmith due to quality and durability of equipment, cost, qualification and experience. Please find below a breakdown of all submitted bids. VENDORS BloAMOUNT Ufe Fitness (proposal non-responsive) $81,339.80 Centurion Partners Health & Fitness d/b/a Fitnessmith $95,527.77 Amount not to exceed-$100,527.77. To account for any unknown factors that may arise, a $5,000 contingency over the proposal of $95,527.77 is requested. The contractor, however, will be issued a purchase order in the amount of $95,527.77. The expenditure shall be charged to the Parks and Recreation Capital Improvement account number 301-2000-572.-6450, which has a balance of $257,942 before this request was made. '- THE CITY OF PLEASANT LIVING ATTACHMENTS: CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM Resolution Non Mandatory Pre-Bid Conference Sign-In Sheet Bid Opening Report Bid Proposal Summary Evaluation Score Sheets Fitnessmith Proposal References -Fitnessmith SunBiz -Fitnessmith Demand Star Results Miami Daily Business Review I I 1 ! I i I I I I I I· I. 1/ t Date: RFP Title: RFP No.: SoutOOiami THE OTY OFPLfASANT LIVING Pre-Bid Conference Sign-In Sheet March 22,"2016 Purchase & Install. Fitness" Center Equip. at Gibson Bethel Community Ctr PR2016-05 X:\Purchasing\TempJates\Pre Bid Meeting\Pre-Bid Meeting Sign-In Sheet.doc BID OPENING REPORT Bids were opened on: Thursday, March 31. 2016 after: 1O:00am For: RFP # PR 2016-05 PurchaselInstall of Fitness Ctr Equip for Community Center COMP ANIES THAT SUBMITTED "NET LUMP SUM PROPOSALS: 1. Centurion Partners Health and Fitness d/b/aFitnessmith 2. Life Fitness THE ABOVE BIDS HAVE NOT BEEN CHECKED. AMOUNT: $95,527.77 $81,339.80 THE BIDS ARE SUBJECT TO CORRECTION AFTER THE BIDS HAVE BEEN COMPLETELY REVIEWED. Witness:_.,=...l....:::--_-L-~:.:::...!~--- RFP PR2016-05 Fitness Equip Purchase and Install for the Community Center NOTE: RESULTS ARE NOT FINAL UNTIL AN AWARD RECOMMENDTION BY THE CITY MANAGER Bid Public Entity Drug Signed Bid Price Less Preferred Wall Package (1 Bidder List of Non Col •• Cl'lmesand free OSHA Fed. State Related Presentation Proof Contract Sun Bidder Trade-In Brand Flooring Mount Trade-In Org; 5 Quatlf Refs. Subs' Affidavit Conflicts of Workpl Stds Ustings Party Dec. oflns with Biz Allowance TV Copies; 1 Interest original Digital) ace .. .... Ufe Fitness $81,339.90 Yes No No $4,975 X X X X X X X X X X N/A X N/A X Centurion Partners dba $95,527.77 No Yes Yes $4;050 x x x x x x x x x x x X N/A X Fitnessmith , i ' ... Till: CITY Of' f'l.fASANIIiVING Evaluation Scoring Sheet Purchasing Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www.southmiamifl.gov RFP Title: RFP No.: Purchase & Install of Fitness Center Equip for the Glbson·Bethel Community Ctr. PR2016·05 DIRECTIONS: Please score each firm, for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by adding each criteria for a total score by proposer. The maximum score total score for each proposer Is 100 points. 1. 2. 3. 4. Maximum 30 Points Value Added Proposals; Maximum 30 Points Price Proposell and Trade-in Allowance to the City; Maximum 25 Points References and Previous Work/Installations of Similar Equipment; Maximum 15 Points ~ (Signature) Page 1 of 1 ~O 3 0 J"O .(i1 South'Miami THE CITV OF PLEASANT LIVING Evaluation Scoring Sheet -' Purchasing Division 6130 Sunset Drive South Miami. Florida 33143 (305) 663-6339 www.southmiamifl.gov RFP Title: Purchase & Install of Fitness Center Equip for the Gibson-Bethel Community Ctr. RFP No.: PR2016-05 DIRECTIONS: Please score each fiim. for each specific criteria provided. Scorjng is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by.adding each criteria for a total score by proposer. The maximum score total score for each proposer Is 100 points. 1. 2. 3. 4. Brand, Durability and Warranty of Proposed Equipment; Maximum 30 Points Value Added Proposals; Maximum 30 Points Price Proposal and Trade-in Allowance to the City; Maximum 25 Points References and Previous Work/Installations of Similar Equipment; Maximum 15 Points 2S 30 2'Z \2.. =-~-----,c--:-------::::'''''::==-'::...\!.----Date: ~ \ "" h 10 (Signature) Page 1 of 1 1 I \ , ' ... THE Crry OF PLEASANT LIVING Evaluation Scoring Sheet Purchasing Division 6130 Sunset Drive South Miami, Florida 33143 (305) 663-6339 www.southmiamifl.gov RFP Title: Purchase & Install of Fitness Center Equip for the Gibson-Bethel Community etr. RFP No.: PR2016-05 DIRECTIONS: Please score each firm, for each specific criteria provided. Scoring is based on each criteria listed below with a maximum score for each criteria. The total score for each proposer is calculated by adding each criteria for a total score by. proposer. The maximum score total score for each proposer Is 100 points. 1. 2. 3. 4. Brand, Durability and Warranty of Proposed Equipment; Maximum 30 Points Value Added Proposals; Maximum 30 Points Price Proposal and Trade-in Allowance to the City; Maximum 25 Points References and Previous Work/Installations of Similar Equipment; Maximum 15 Points Page 1 of 1 ,..,0 (/ ~o Proposal Submittal Checklist Form "Purchase and Installation ·of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PRlO I 6-05 This checklist indicates the (orms and documents required to be submitted for this solicitation and to be presented by the deadline set for within the solicitation. Fulfillment of all solicitation requirements listed is mandatory for consideration of response to the solicitation. Additional documents may be required and, if so, they will be identified in an addendum to this Solicitation. The response shall include the following items: X X X X X X X X X X X X X X Attachments and Other Documents descnbed below CI I lee ( to be Completed IF MARKED WITH AN "X": Completed. One <I) Original Unbound Proposal. five (5) Additional Copies and V One (I) Digital Copy Indemnification and Insurance Documents EXH'BIT2 V Bid Form. EXHIBIT 3 if Respondents Cost and Technical Proposal. EXHIBI7' 4 V Sirl'ed Contract Documents (All -including General Conditions /' and Supplementary Conditions if attached) EXHIBIT 5 Respondents Qualification Statement V list of Proposed Subcontractors and Principal Suppliers V Non-Collusion Affidavit .../' Public Entity Crimes and Conflicts of Interest ../' Drug Free Workplace / Acknowledgement of Conformance with OSHA ~tandards / .. ..,.... AffidaVit Concerning Federal & State Vendor Listings V Relat.ed Party Transaction VerificatiQn Form V 4 Presentation Team Declaration! Affidavit Clf Repre~entation J' Submit this checklist along With your proposal indicating the completion and submission of each required forms andlor documents. Thomas F. Pepa I J/I OJ;! 0 I 5 END OF SECTION 1 _ RESPONDENT QUALIFICATION STATEMENT "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PRlOI6-0S The response to this questionnaire shall be utilized as part of the CITY'S overall Proposal Evaluation and RESPONDENT selection. I. Number of similar projects completed. a) In the past 5 years b) In the past to years "CD:) p\u~ tj,bOO ~\O~ 2. Ust the last three (3) completed similar projects. a) Project Name: O\~ ~~$~ -S"o~ t!\\~ ~~~ b) c) Thotna£ F. Pel"' 12110/2015 Owner Name: Owner Add,-ess: Owner Telephone~ !-\\:O N(X\n_.~fS'rAb~ ~\~~(~ g\!rl&-:1QU~.~ ~~:~I Final Contract Completion _~~~\",\~\-\.aj£O~.\!...:3:::=.... ____ ~ __ ~_ Original Contract Price: ".j,d~6D.~::.c:OO:J~::. .• ~O~O~~ ______ _ Project Name: Owner Name: Owner Address: Owner T eleph()ne: Actual Final Contract Pate: Original Contract Price: Project Name: Owner Name: Owner Address: Owner Telephone: _~~~t~ Completion .3~\\aD\~ !U....cto, DOC. Do Actual Final Contract Completion Date: .. " .. -... Original Contrllct Prite: ~ aa~;J$, Q;) 1;Z z}--Sl7-7J7, 11 /lqooo~ 4. The following information shall be attached to the proposal. a) RESPONDENT's home office organization chart. b) RESPONDENT's proposed project organizational chart. c) Resumes of proposed key project personnel, including on-site Superintendent. 5. List and describe any: a) Bankruptcy petitions fded by or against: the Respondent or any predecessor organizations, b) Any arbitration or civil or criminal proceedings, or Suspension of contracts or debarring from Bidding or Responding by any public agency brought c) against the Respondent in the last five (S) years 6. Govemment References: List other Government Agencies or QUi)si~Government Agencies for which you within the past five {S} years. have done business Name of Agency: -{L~Q~. Address: Telephone No.: Contact Per~n: Type of Project: Thomas F. Pepe 12110/2015 l.(4 ~ S-~cl 13 COLO (\!o! -+ tre e.. k t>("'(! \~ jSi cJ J. '- . Name of Agency: Address: T eJephone No.: Contact Person: Type of Project Name of Agency: Address: Telephone No.: Contact Person: Type of Project Thomas F. Pepe 12110/2015 ~'\-4 I:)~ nlQ(f"\·1~ -r\rc.. ~'i ~ ') 're ~+U=~Cl...\ ~..} ~:5"-Sb,\-3,boO M+ul..iY t, iJ Ipetd--IN ,xctHIIII / .1+-~)~~~1\ (h~ ·~Si C. \<M'" .... 2~ {DO s {h"1 rTLt fWe. END OF SECTION 14 LIST OF PROPOSED SUBCONTRACTORS AND PRINCIPAL SUPPLIERS "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PR10 16-05 Respondent shall list all proposed subcontractors. if subcontractors are allowed by the terms of this Solicitation to be used on this are awarded the ContracL Other: to within five (5) business days after Bid Opening. Thomas F. Pepe IlII01l015 END OF SECTION IS STATE OF FLORIDA COUNTY OF MIAMI-DADE NON COLLUSION AFFIDAVIT ) ) ) 'M.~ttt~ ~ich\ccv.c being first duly sworn. deposes and states that (I) He/ShefThey is/are the DixY' f (Owner, Partner, Office-r-, :::R,.e .... p""'re=-s-=-e ... n ... ta ... ti-v ... ~-o-r-A:-g-e-n-:t)-o-f:---------------- ():-w-I )£'1 ON ~iZTN 82S H.9\LTJI ;, hTN~ Respondent that has submitted the' attached Proposal; -, (2) He/Sherrhey is/are fully informed concerning the preparation and contents of the attached Proposal and of all pertinent circumstances concerning such Proposal; (3) Such Proposal is genuine and is not a collusive or sham Proposal; (4) Neither the said Respondent nor any of itS officers. partners. owners. agentS, representatives. employees or parties in interest, including this affiant. have in any way colluded. conspired. connived or agreed. directly or indirectly. With any other Respondent, firm, or person to submit a collusive or sham Proposal in connection with the Work for which the attached Proposal has been submitted; or to refrain from Bidding or proposing in connection with such Work; or have in any manner. directly or indirectly, sought by agreement or collusion. or communication, or conference with any Respondent, firm, or person to fix any overhead, profit. or cost elements of the Proposal or of any other Respondent. or to fix any overhead, profit. or cost elements of the Proposal Price or the Proposal Price of any other Respondent. or to secure through any collusion, conspiracy, connivance, or unlawful agreement any advantage against (Recipient), or any person interested in the proposed Work; (5) The price or prices quoted in the attached Proposal are fair and proper and are not tainted by any collusion. conspiracy, connivance, or unlawful agreement on the part of the Respondent or any other of its agents, representatives. owners. employees or parties of interest, including this affiant. delivered in the presence of: Witness ACKNOWLIiD&!sMENT r-"::':7':~------------, /iJ'."~.. STACIA. ANNOAA FOREMAN ~.: ,-: MY COMMISSION. EEB88705 STATE OF FlORJDA COUNTY OF MIAMI-DADE •• ~ EXPIRES Januuy zr. 2017 I f ~ (.el7. Sie.otS3 I'bIdaNola."s. •• CDIl On this the ~ \ day or Naffu , 20lJ.£-, before me, the underSigned Notal, Public of the State· of Florida. personally appeared (Name(s) of indiVidual(s) who appeared before notary) Thomas F. Pepe 12/10/20IS 16 -' N ICHAf'L Scre H JLONE and whose name(s) is/are Subscribed to the within instrument. and he/shelthey acknowledge that he/SheJthey~xecuted it. WITNESS my hand and official seal. ~ O~P~UbliC, S~ate of Florida .............. NOTARY PUBUC: ' 0~ ___ ~ _ SEAL OF OFFICE: ~JIi \~WJ1' STACIAANNORA FOREMAN MY COMMISSION" EE880705 EXPIRES Janu8Iy 'D, 2017 Thoma$ F. Pepa 12110120lS 17 (Name of Notary Public Print Stamp or type as commissioned.} £ Personally known to me, or Pet50nal identification: Type of Identification Produced Did take an oath. or Oid Not take an oath. PUBLIC ENTITY CRIMES AND CONFLICTS OF INTEREST Pursuant to the provisions of Paragraph (2) (a) of Section 287.133, Florida State Statutes -"A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a Proposal or bid on a Contract to prOVide any goods or services to a public entity. may not submit a Bid or proposal for a Contract with a public entity for the construction of repair of a public bUilding or public work, may not submit bids or proposals on leases or real property to a public entity, may not be awarded to perform Work as a RESPONDENT, Sub-contractor. supplier, Sub-consultant. or Consultant under a Contract with any public entity. and may not transact business with any public entity in excess of the threshold amount Category Two of Section 287.017, Rorida Statutes, for thirty six (36) months from the date of being placed on the convicted vendor list". The award of any contract hereunder is subject to the prOVIsions of Chapter 112. Florida State Statutes. Respondents must disclose with their Proposals, the name of any officer, director, partner, associate or agent who is also an officer or employee of the City of South Miami or its agencies. SWORN STATEMENT PURSUANT TO SECTION 287.133 (3) (a). FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. . I. This swor'},statement is submitted to ~jTtj Q~ Soum N.AMI . . [print name of the public entity] by '\l'CH/~EL-~ (CHI LeNt=: j") [print individual's~me and title] , I for LFNIIlj2IDI'-I I A'j2TNE/?S /-1 CA?-TH i i;TNt='.:SS [print name of entity submitting sworn statement] ~ whose business address is -3fo/yi QUAt--ITUM I3LV 1> &'!dt-rrQN \3rAC-1-' ,~'-3E:i-ldW and (if applicable) its Federal Employer Identification Number (FEIN) is l-/~-C)d'}&i)4f.J (If the entity has no FEIN. include the Sodal Security Number of the individual signing this sworn statement: -----------------_.) 2. I understand that a "public entity crime" as defined in Paragraph 287. I 33 (I )(g). Aorida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to • any bid, proposal or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud. theft, bribery. collusion. racketeering. conspiracy. or material misrepresentation. 3. 1 understand that "convicted" or "conviction" as defined in Paragraph 287.133 (I) (b), Florida 4. Statutes, means a finding of gUilt or a conviction of a pUblic entity crime, with or without an adjudication of gUilt, in any federal or state trial court of record relating to charges brought by indictment or information after July I. 1989. as a result of a jury verdict, non-jury trial, or entry of a plea of guilty or nolo contendere. (a) (b) I understand that an "affiliate" as defined in Paragraph 287.133 (I) (a), Florida Statutes, means: A predecessor or successor of a person convicted of a public entity crime; or An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" inc/udes those officers, directors. executives, partners, shareholders, employees, members. and agents who are active in Thomas F. Pepe 121.012015 18 -, the management of an affiliate. The ownership by one person of shares constituting a controlling interest in any person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a pubHc entity crime in Aorida during the preceding 36 months shall be considered an affiliate. s. I understand that a "person" as defined in Paragraph 287.133 (I) (e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or proposal or applies to bid or proposal on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers. directors. executives, partners, shareholders, employees, members. and agents who are active in management of an entity. 6. Bas~ on information and belief. the statem~rtt which I have marked below is true in relation to the entity submitting this sworn statement. [Indicate which statement applies.] /" Neither the entity submitting thiS sworn statement, nor any of its officers. directors. executives, partners. shareholders. employees. memb~rs. or agents who are active in the management of the entity. nor any affiliate of the entity has been charged with and .convicted of a public entity crime subsequent to July I, 1989. __ The entity submitting this sworn statement, or one or more of its officers. directors. executives, . partners. shareholders. employees. members. or agents who are active in the management of the entity. or an affiliate of the entity has been cha~d with and convicted of a public entity crime subsequent to July 1,1989. __ The entity submi.tting this sworn statement. or one or more of its officers. directors, executives. partners. shareholders. employees. members. or agents who are active il) the management of the entity. or an affihate of the entity has been charged with and convicted of a public entity crime subsequent of July I. 1989. However. there has been a subsequent proceeding before a Hearing Officer of the State of Florida. Division of AdministratiVe Hearings and the Final Order entered by the Hearing Officer determined that it was not in the public interest to place the entity submitting this sworn statement on the convicted vendor list. [attach a copy of the final order.] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTMCTING OffiCER FOR THE PUBUC ENTITY INDENTIFIEDIN PARAGRAPH I (ONE) ABOVE.lS FOR THAT PUBLIC ENTITY ONLY. AND THAT THIS FORM /S VAlID THROUGH DECEMBER. 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT lAM REQUIRED TO INFORM THE PUBUC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017. flORIDA STATUTES. FOR CATEGORY lWO OF ANY CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. Sworn to and subscribed before me this -"d~.&.I __ d'Y of ~. .lOfr . . Personally known _-lV~ _______ _ OR Produced identification _______ _ (Type of identification) Form PUR 7068 (Rev.06/11192) Thomas F. Pepe 1211011015 19 r:'=1~ Notary Public -State of ---Jr::IY.::L..!lIO!...l_'&;~"'==--_ My commission expires 1/'iJ-.1 ka, , (P1inted. typed or stamped commissioned name of notary public) ,.' ·~L· .. ·STAClAANNORA FOREMAN ~ ~~ . :*: ·-1 MYCOMMISSlON·'EE888705· . . EXPIRES January 27. 2017 , , DRUGFREEVVORKPLACE Whenever two or more Bids or Proposals which are equal with respect to price. quality and service are received by the State or by any political subdivisions for the procurement of commodities or contractual services, a Bid or Proposal received from a business that certifies that it has implemented a drug-free workplace program shall be given preference in the award process. Established procedures for processing tie Bids or Proposals shall be followed jf none of the tied vendors have a drug-free workplace program. In order to have a drug-free workplace program. a business shall: I) Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing. possession. or use of a controlled substance is prohibited in the workplace and specifying the actions that shall be taken against employees for violations of such prohibition. 2) Inform employees about the dangers of drug abuse in the workplace, the business' policy of maintaining a drug-free workplace, any available drug counseling. rehabilitation, and employee assistance programs. and the penalties that may be imposed upon employees for drug abuse violations. 3) Give each employee engaged in providing the commodities or contractual services that are under Bid a copy of the statement specified in Subsection (I). 4) In the statement specified in Subsection (I). notify the employees. that. as a condition of working of the commod'lties or contractual services that are under Bid. he employee shall abide by the terms of the statement and shall notify the employee of any conviction of, or plea of guilty or nolo contendere to. any violation of Chapter 893 or of any controlled substance Jaw of the United States or any state, for a Violation occurring in the workplace no later than five (5) business days after such conviction. 5) Impose a sanction on. or require the satisfactory partidpation in a drug abuse assistance or rehabilitation program, if such is available in the employee's community. by any employee who is so convicted. 6) Make a good faith effort to continue to maintain a drug-free workplace thl'ough implementation of this section. As the person authorized to sign the statement. , certify that this firm complies fully with the above requirements. RESPONDENT's Signature: ~-- Pri" N,me IU ,cCzo.,l rei c.h II~ Date: -:3/17-11_ Thomas F. Pepe 12/10/2015 20 ACKNOWLEDGEMENT OF CONFORMANCE WITH OSHA STANDARDS TO THE CITY OF SOUTH MIAMI We, £~~ . ; (Name of CONTRACTOR). hereby acknowledge and agree that as CONTRACTOR for the "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center." project as specified have the sole responsibility for compliance with all the requirements of the Federal Occupational Safety and Health Act of 1970. and all State and local safety and health regulations. and agree to indemnify and hold harmless the City of South Miami and NlA (Consultant. if any) against any and all liability. claims. damages. losses and expenses they may incur due to the failure of (Sub-contractor's names): to comply with such act or regulation. CONTR¢;~~~ TIde Tl'aQrnas F. Pepe 1211012015 ~kY YtccA Witness 21 , , AFFIDAVIT CONCERNING FEDERAL AND STATE VENDOR LISTINGS The person, or entity, who is responding to the City's solicitation, hereinafter referred to as "Respondent". must certify that the Responde~'s name Does Not appear on the State of FlOrida, Department of Management Services, "CONVICTED, SUSPENDED, DISCRIMINATORY FEDERAL EXCLUDED PARTIES and COMPLAINTS VENDOR USTINGS". If the Respondent's name Does appear on one or all the "Listings" summarized below, Respondents must "Check if Applies" next to the applicable "li~ng." The "listings" can be accessed through the following link to the Rorida Department of Management Services website: httr;rUwww.dms.mrf!orida.com!business operations/state purchasinr!vendor information/convicted susp ended discriminato!] complaints vendor lists DECLARATION UNDER PENALTY OF PERJURY I, {\,\ 1~\-i.C\!;L :=":xl, CHI t.6N[ (hereinafter referred to as the "Declarant") state, under penalty of perjury, that the follOWing statements are true and correct: --;-") i I . (I) I represent the Respondent whose name is &I'IWi2.IDN r.\'\ZINfi2~ b{;AL-nl." ~ hT"'ESS (2) 1 have the following relationship with the Respondent MANA(;;JI NQ l.!k-j\fi3~(ownef (if Respondent is a sole proprietor). President (if Respondent is a corporation) Partner (if Respondent is a partnership), General Partner (if Respondent is a Limited Partnership) or Managlnl: Member> (if Respondent is a Limited Liabirlty Company). (3) J have reviewed the Florida Department of Management Services website at the follOWing URL address: http://www.dms.ri1yflorida.comlbusiness _operation$lstate-purchasinglvendor -,nformation!convicted _suspended_ di scriminatory _complaints_vendor _lists (4) I have entered an "x" ora check mark beside each listingfcategory set forth below if the Respondent's name appears in the list found on the Florida Department of Management Services website for that category or listing. If I did not enter a mark beside a listing/category, it means that I am attesting to the fact that the Respondent's name does not appear on the listing for that category in the Florida Department of Management Services website as of the date of this affidavit. Check if Applicable Convicted Vendor List Suspended Vendor list Discriminatory Vendor List Federal Excluded Parties Ust Vendor Complaint Ust FURTHER DECLARANT SAYETH NOT e L J L l'-'I.ICi-i o.t::L~ ICt4 1 L.-O}-Je-- }=Deda~n: By:~" , (Sign~[ure of Declarant) ACKNOWLEDGEMENT STATE OF FLORIDA ) COUNTY OF MIAMI-DADE ) ~i~ thed.L day of !g~ ,20-"t-. before me, the underSigned authority, personally appeared ~ 0 \ cs,ci~ __ " who is personally know to me or who provided the follOwing identification ~ X OD.tY)nd who took an oath or affirmed that that he/she/they executed the foregoing Affidavit as the Declarant. WITNESS my hand and official seal. NOTARY PUBLIC: SEAL ~STACIA __ ;-: :-: MY COMMISSION .. EE88810S ThomasF.I" 11110nOiS ..... EXPIAES January 27. 2017 " ~-.otlla .- 22 (Name of Notary Public: Print, Stamp or type as commissioned.) RELATED PARTY TRANSACTION VERIFICATION FORM _.p:\1lA-!!t\..I(,A-"::::"V~· .:uJ..a...a.::i~::--' individually and on behalf of ~~\~ C'Firm" have Name of Representative CompanyNendorlEntity read the City of South Miami ("City")'s Code of Ethics, Section SA-I of the Oty's Code of Ordinances and I hereby certify. under penalty of perjury that to the best of my knowledge, information and belief: (I) neither I nor the Firm have any conflict of interest (as defined in section SA-I) With regard to the contract or business that I, andlor the Firm, am (are) about to perform (or, or to transact with, the City, and (2) neither I nor any employees, officers, directors of the Firm, nor anyone who has a financial interest greater than 5% in the Firm, has any relative(s), as defined in section SA-I, who is an employee of the City or who is(are) an appointed or elected official of the City. or who is(are) a member of any public body created by the City Commission, I.e., a board or committee of the City, [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock i~ publicly traded, the statement in this section (2) shall be based solely on the signatorys personal knowledge and he/she is not required to make an independent investigation as to the relationship of employees or those who have a financial interest in the Firm.}; and (3) neither I nor the Firm, nor anyone who has a financial interest greater than 5% in the Firm, nor any member of those persons' immediate family (I.e., spouse, parents, children, brothers and sisters) has transacted or entered into any contract(s) with the City or has a financial interest, direct or indirect. in any business being transacted with the city, or with any person or agency acting tor the city, other than as follows: _ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). [whae the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publidy traded. the statement in this section (3) shall be based solely on the signatory's personal knowledge and he/she is not required to make an independent investigation as to the relationship of those who have a financial interest in the Finn.]: and (4) no elected andlor appointed official or employee of the City of South Miami, or any of their immediate family members (I.e., spouse, parents, children, brothers and sisters) has a financial interest. directly or indirectly. in the contract between you and/or your Firm and the City other than the follOWing individuals whose interest is set forth follOWing their names: . (if necessary, use a separate sheet to supply additional information that will not fit on this line; however. you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). The names of all City employees and that of all elected and/or appointed city officials or board members, who own, directly or indirectly, an interest of five percent (5%) or more of the total assets of capital stock in the firm are as follows: (if necessary, use a separate sheet to supply additiOnal Information that wiD not fie on this line; however, you must make reference. on the above line, to the additional sheet and the additional sheet must be signed under oath). (whae the ethics code still applies, if the person executing. this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (4) shall be based solely on the signatory's personal knowledge and he/she is not required to make an independent investigation as to the financial interest in the Firm of city employees, appointed officials or the immediate family members of elected andlor appointed official or employee.] (5) I and the Firm further agree not to use or attempt to use any knowledge, property or resource which may come to us through our position of trust, or through our performance of our duties under the terms of the contract with the City. to secure a special privilege, benefit, or exemption for ourselves, or others. We agree that we may not disclose or use information. not available to members of the general public, (or our personal gain or benefit or for the personal gain or benefit of any other person or business entity, outside of the normal gain or benefit anticipated through the performance of the contract. (6) I and the Firm hereby acknowledge that we have not contracted or transacted any business with the City or any person or agency acting for the City, and that we have not appeared in representation of any third party before any board, commission or agency of the City Within the past two yeal's other than as Thomas F. Pepe 12110/2015 23 follows: , _p' _____ .,_ ". _. _ _ _ (if necessary. use a separate sheet to supply additional information that will not fit ot! this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). X:\PurchasingWendor Registration\l2.28.12 RELATED PARTY TRANSACTION VERIFICATION FORM [3].docx (7) Neither I nor any employees. officers. or directors of the Firm, nor any of their immediate family (i.e .• as a spouse. son. daughter, parent, brother or sister) is related by blood or marriage to: (i) any member of the City Commission; (ii) any city employee; or (iii) any member of any board or agency of the City other than as follows: ~ _____________________ (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (7) shall be based solely on the signatory's personal knowledge and he/she is not required to make an independent investigation as to the relationship by blood or marriage of employees. officers, or directors of the Firm. or of any of their immediate family to any appointed or elected officials of the City, or to their immediate family members]. (8) No Other Firm, nor any officers or directors of that Other Firm or anyone who has a financial interest greater than 5% in that Other Firm, nor any member of those persons' immediate family (i.e., spouse, parents, children, brothers and sisters) nor any of my immediate family members (hereinafter referred to as "Related Parties") has responded to a solicitation by the City in which I or the Firm that I represent or anyone who has a financial interest greater than 5% in the Firm, or any member of those persons' immediate family (Le. spouse, parents, children, brothers and sisters) have also responded, other than the follOwing: _____ ~---_--__ ----________________ (if necessary. use a Sepal1lte sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additlonal sheet and the additional sheet must be signed under oath). [while the ethics code stili applies, if the person executing this form is doing so on behalf of a firm whose stock is pUblicfy traded, the statement in this section (8) shall be based solely on the signatory's personal knowledge and helshe is not reqUired to make an independent investigation into the Other Firm, or the Firm he/she represents, as to their officers, directors or anyone having a financial interest in those Firms or any of their any member of those persons' immediate family.] (9) I and the Firm agree that we are obligated to supplement this Verification Form and inform the City of any change in circumstances that would change our answer$ to this document. SpeCifically, after the opening of any responses to a solicitation, I and the Firm have an obligation to supplement this Verification Form with the name of all Related Parties who have also responded to the same solicitation and to disclose the relationship of those parties to me and the Firm. (10) A violation of the City's Ethics Code, the giving gf any false information or the failure to supplement this Verification Form, may subject me or the Firm to immediate termination of any agreement with the City. and the imposition of the maximum fine and/or any penalties allowed by law. Additionally, violations may be conSidered by and subject to action by the Miami-Dade County CommiSSion on Ethics. Under penalty of perjury, I declare that I have made a diligent effort to investigate the matters to which I am attesting hereinabove and that the statements made hereinabove are true and correct to the best of my knowledge, information and belief. Signature: dA ~ P,;n' N':'(T t? ~.~~~~\\\lf'e- Date: ~ d-l I. , Tl10mas F. Pep'" 1111012015 ." . Sec. SA-I. -Conflict of interest and code of ethics ordinance. (a) Designtltion. This section shall be designated and known as the "City of South Miami Conflict of Interest and Code of EthicS Ordinance." This se.ction shall be applicable to all city personnel as defined below, and shall also constitute a standard of ethital conduct and behavior for all autonomous personnel. quasi-judicial personnel. advisory personnel and departmental personnel. The provisions of this section shall be applied in a cumulative manner. By way of example. and not as a limitation. subsections (c) and (d) may be applied to the same contract or transaction. (b) Definitions. For the purposes of this section the following definitions shall be effective: (I) The term "commission members" shall refer to the mayor' and the members of the city commission. (2) The term "autonomous personnel" shall refer to the members of autonomous authorities, boards and agenCies. such as the city community redevelopment agency and the health facilities authority. (3) The "term "quasi-judicial personnel" shall refer to the members of the planning board. the environmental review and preservation board. the code enforcement board and such other individuals, boards and agencies of the city as perform quasi-judicial functions. (4) The term ;'advisory personnel" shall refer to the members of those city advisory boards and agenCies whose sole or primary responsibility is to recommend legislation or give advice to the city commission. . (5) The term "departmental personnel" shall refer to the city clerk, the city manager. department heads. the city attorney. and all assistants to the city clerk, city manager and city attorney,however titled. (6) The term "employees" shall refer to aU other personnel employed by the city. (7) The term "compensation" shall refer to any money. gift, favor. thing of value or finanCial benefit conferred. or to be conferred. in return for services rendered or to be rendered. (8) The term "controllfng financial interest" shall refer to ownership. directly or indirectly. of ten percent or more of the outstanding capital stock in any corporation or a direct or indirect interest of ten percent or more in a firm. partnership, or other business entity anhe time of transacting business with the city. (9) The term "immediate family" shall refer to the spouse, parents. children, brothers and sisters of the person involved. (10) The term "transact any business" shall refer to the purchase Or sale by the city of specific goods or services for consideration and to submitting a bid. a proposal in response to a SoliCitation, a statement of qualifications in response to a request by the city. or entering into contract negotiations for the provision on any goods or services. whichever first occurs, (c) Prohibition on transacting business with the city. No person included in the terms defined in paragraphs (b)(l) through (6) and in paragraph (b)(9) shall enter into any contract or transact any business in which that person or a member of the immediate family has a financial interest. direct or indirect with the city or any person or agency acting for the city. and any such contract, agreement Ot" business engagement entered in violation of this subsection shall render the transaction voidable. Willful violation of this subsection shall constitute malfeasance in office and shall affect forfeiture of office or position. Nothing in this subsection shall prohibit or make illegal: (I) The payment of taxes, special assessments or fees for services provided by the dty government; (2) The purchase of bonds, anticipation notes or other securities that may be issued by the city through underwriters or directly from time to time. Waiver of prohibition. The requirements of this subsection may be waived for a particular transaction only by four affirmative votes of the city commission after public hearing upon finding that: (I) An open-to-all sealed competitive proposal has been submitted by a city person as defined in paragraphs (b)(2). (3) and (4); (2) The proposal has been submitted by a person or firm offering services Within the scope of the practice of architecture; professional engineering, or registered I;md surveying, as defined by the laws of the state and pursuant to the provisions of the Consultants' Competitive Negotiation Act. and when the proposal has been submitted by a city person defined in parngraphs (b)(2), (3) and (4); . . (3) The property or services to be involved in the proposed transaction are unique and the city cannot avail itself of such property or services without entering a transaction which would violate this subsection but for waiver of i~ reqUirements; and (4) That the proposed transaction will be in the best interest of the city. This subsection shall be applicable only to prospective transactions. and the dty commiSSion may in no case ratify a transaction entered in violation of this subsection. Provisions cumulative. This subsection shall be taken to be cumulative and shall not be construed to amend or repeal any other law pertaining to the same subject matter. (d) further prohibition on tronsacting business with the dty. Thomas F. Pepe 11IIOlZOl5 No person included in the terms defined in paragraphs (b)(l) through (6) and in paragraph (b)(9) shall enter into any contract or transact any business through a firm, corporation. partnership or business entity in which that person or any member of the immediate family has a controlling financial interest, direct or indirect. with the city or any person or agency acting for the city, and any such contract, agreement or business engagement entered in violation of this subsection shall render the transaction voidable. The remaining provisions of subsection (c) will also be applicable to this subsection as though incorporated by recitation. Additionally. no person included in the term defined in paragraph (b) ( I) shall vote on or participate in any way in any matter presented to the city commission if that person has any of the following relationships with any of the persons or entities which would be or might be directly or indirectly affected by any action of the city commission: (I) Officer, director. parmer, of counsel, consultant, employee, fiduciary or beneficiary; or (2) Stockholder. bondholder. debtor, or creditor. if in any instance the transaction or matter would affect the person defined in paragraph (b)(I) in a manner distinct from the manner in which it would affect the public generally. Any person included in the term defined in paragraph (b)(I) who has any of the specified relationships or who would or might, directly or indirectly, realize a profit by the action of the city commission shall not vote on or panicipate in any way in the matter. (E.) GiftJ. ( I) Definition. The term "gift" shall refer to the transfer of anything of economic value. whether in the form of money. service. loan. travel. entertainment. hospitality, item or promise. or in any other form. without adequate and lawful consideration. (2) Exceptions. The provisions of paragraph (e)(I) shall not apply to: a. Political contributions specificaily authorized by state law; b. Gifts from relatives or members of one's household. unless the person is a conduit on behalf of a third party to the delivery of a gift that is prohibited under paragraph (3); . c. Awards for professional or civic achievement; d. Material such as books. reports, periodicals or pamphlets which are solely informational or of an advertising nature. (3) Prohibitions. A person described in paragraphs (b)(1) through (6) shall neither solicit nor demand any gift. It is also unlawful for any person or entity to offer, give or agree to give to any person inclUded in the terms defined in paragraphs (b)(I) through (6), or for any person included in the terms defined in paragraphs (b)(I) through (6) to accept or agree to accept from another person or entity. any gift for or because of: a. An official public ·action taken. or to be taken. or which could be taken, or an omission or failure to take a public action; b. A legal duty performed or to be performed. or which could be performed, or an omission or failure to perform a legal duty; c. A legal duty .violated or to be violated, or which could be violated by any person included in the term defined in paragraph (b)(I); or d. Attendance or absence from a public meeting at which official action is to be taken. (4) Disdosure. Any person included in the term defined in paragraphs (b)(f) through (6) shall disclose any gift. or series of gifts from anyone person or entity. having a value in excess of $25.00. The disclosure shall be made by filing a copy of the disclosure form required by chapter 112, Florida Statutes. for ulocal officers" with the city clerk simultaneously with the filing of the form with the clerk of the county and with the Florida Secretary of State. (f) CompullOry disclosure by employees of firms doing business with the city. Should any person included in the terms defined in paragraphs (b)(I> through (6) be employed by a corporation. firm, partnership or business entity in which that person or the immediate family does not have a controlling financial interest, and should the corporation. firm, partnership or business entity have substantial business commitments to or from the city or any city agency, or be subject to direct regulation by the City or a City agency. then the person shall file a sworn statement disclosing such employment and interest with the clerk of the city. (g) E.xploitation of official position prohibited. No person included in the terms defined in paragraphs (b)( I) through (6) shall corruptly use or attempt to use an official position to secure special privileges or exemptions for that person or others. (h) Prohibition on use of confidential information. No person included in the terms defined in paragraphs (b)(l) through (6) shall accept employment or engage in any business or profeSSional activity which one might reasonably expect would require or induce one to disclose confldential Information acqUired by reason of an official position, nor shall that person in fact ever disclose confidential information garnered or gained through an official position with the city. nor shall that person ever use such information, directly or indirectly. for personal gain or benefit. Thomas F. Pape 1211012015 :46 (i) Conflicting employment prohibited. No person included in the terms defined in paragraphs (b)(l) through (6) shall accept other employment which would impair independence of judgment in the performance of any public duties. 0) Prohibition on outside employment (I) No person included in the terms defined in paragraphs (b)(6) shall receive any compensation for services as an officer or employee of the city from any source other than the city, except as may be permitted as follows: a Generally prohibited. No full~time city employee shall accept outside employment, either incidental, occasional or ochelwise, where city time, equipment or material Is to be used or where such employment or any part thereof is to be performed on city time. b. When permitted. A full-time city employee may accept incidental or occasional outside employment so long as such employment is not contrary, detrimental or adverse to the interest of the city or any of its departments and the approval required in subparagraph c. is obtained. c. Approval of department head required. Any outside employment by any full-time city employee must first be approved in writing by the employee's department head who shali maintain a complete record of such employment. d. Penalty. Any person convicted of violating any provision of this subsection shall be punished as provided in section I-I I of the Code of Miami-Dade County and, in addition shall be subject to dismissal by the appointing authority. The city may also assess against a violator a fine not to exceed $500.00 and the costs of investigation incurred by the city. (2) All full-time city employees engaged in any outside employment for any pej'son, firm. corporation or entity other than the city, or any of its agencies or instrumentalities, shall file, under oath, an annual report indicating the source of the outside employment. the nature of the work being done and any amount of money or other consideration received by the employee from the outside employment. City employee reports shall be filed with the city clerk. The reportS shall be available at a reasonable time and place for inspection by the public. The city manager may reqUire monthly reports from individual employees or groups of employees for good cause. (k) Prohibited lnve.stments. No person included in the terms defined In paragraphs (b)(I) through (6) or a member of th.e immediate family shall have personal investments in any enterprise which will create a substantial conflict between private interests and the public interest. (I) Certain app'earonces and payment prohibited. (I) No person induded in the terms defined in paragraphs (b)(I). (5) and (6) shall appear before any city board or agency and make a presentation on behalf of a third person with respect to any matter. license. con~ct, certificate. ruling. decision. opinion, rate schedule, franchise. or other benefit SQught by the third person. Nor shall the person receive any compensation or gift, directly or indirectly, for services rendered to a third person, who has applied for or is seeking some benefit from the city or a dty agency, in connection with the particular benefit sought by the third person. Nor shall the person appear in any court or before any administrative tribunal as counselor legal advisor to a party who.seeks legal reli~f from the city or a city agency through the suit in question . . (2) No person induded in the terms defined in parag~phs (b)(2), (3) and (4) shall appear before the city commission or agency on which the person serves. either directly or through an associate, and make a presentation on behalf of it. third person with respect to any matter, license, contract, certificate, ruling, decision, opinion. rate schedule, franchise, or other benefit sought by the third person. Nor shall such person receive any compensation or gift, directly or indirectly, for services rendered to a third party who has applied for or is seeking some benefit from the city commission or agency on which the person serves in connection with the particular benefit sought by the third party. Nor shall the person appear in any court or before any administrative tribunal as counselor legal advisor to a third pa,·ty who seeks legal relief from the dty commission or agency on which such person serves through the suit in question. . (m) Actions prohibited when financ;ial interests involve". No person "ncluded in the te,'ms defined in paragraphs (b) (I) through (6) shall participate in any official action directly or indirectly affecting a business in which that person or any member of the immediate family has a financial interest. A financial interest is defined in this subsection to include. but not be limited to, any direct or indirect interest in any investment. equity. or debt. (n) Acquiring finanCial interests, No person inclvded in the terms defined in paragraphs (b)( I) through (6) shall acquire a financial interest in a project, business entity or property at a time when the person believes or has reason to believe that the financial intel'est may be directly affected by official actions or by official actions by the city or city agency of which the person is an official, officer or employee. (0) Recommending professional services. Thom~f.P~fl !VI01l1l15 No person included in the terms defined in paragraphs (b)(l> through (4) may recommend the services of any lawyer or law firm, architect or architectural firm. public relations firm. or any other person or firm. professional or otherwise. to assist in any transaction involving the city or any of its agencies, provided that a recommendation may properly be made when required to be made by the duties of office and in advance at a public meeting attended by other city officials. officers or employees. (p) Continuing application after city service. (I) No person included in the terms defined in paragraphs (b)(I). (S) and (6) shall, for a period of two years after his or her City service or employment has ceased, lobby any city official [as defined in paragraphs (b)(I) through (6)] in connection with ariy judicial or other proceeding. application. Solicitation. RFQ. bid. request for ruling or other determination. contract. claim, controversy, charge, accusation. arrest or other particular subject matter in which the city or one of its agencies is a party or has any interest whatever. whether direct or indirect. Nothing contained in this subsection shall prohibit al1Y individual from submitting a routine administrative request or application to a city department Dr agency during the two-year period aftel-his or her service has ceased. (2) The provisions of the subsection shall not apply to persons who become employed by governmental entities, 50 I (c)(3) non-profit entities or educational institutions or entities. and who lobby on behalf of those entities in their official capacities. (3) The provisions of this subsection shall apply to all persons described j n paragraph (p)( I) whose city service or employment ceased after the effective date of the ordinance from which this section derives. (4) No person described In paragraph (pH I) whose city service or employment ceased Within two years prior to the effective date of this ordinance shall for a period of two years after his or her service or employment enter into a lobbying contract to lobby any city official in connection With any subject described in paragraph (p)(1) in which the city or one of its agencies is a party or has any direct and substantial interest; and in which he or she participated directly or indirectly through deciSion. approval. disapproval. recommendation. the rendering of adVice. investigation, or otherwise, during his or her city service or employment. A person participated "directly" where he or .she was substantially involved in the particular subject matter through decision. approval. disapproval, recommendation. the rendering of advice, investigation. or otherwise. during his or her city service or employment. A person participated "indirectly" where he or she knowingly partiCipated in any way in the particular subject matter through decision, approval. disapproval. recommendation, the rendering of adVice. investigation, or otherwise. during his or her city service or employment. All persons covered by this paragraph shall execute an affidavit on a form approved by the city attorney prior to lobbying any City offiCial attesting that the requirements of this subsection do not preclude the person from lobbying city officials. (5) Any person who violates this subsection shall be subject to the penalties provided in section 8A-2(p). (q) City attorney to render opinions on request. Whenever any person included in the terms defined in paragraphs (bJ(I) through (6) and paragraph (b)(9) is in doubt as to the proper interpretation or applicatiOn of this conflict of interest and code of ethics ordinance, or whenever any person who renders services to the city is in doubt as to the applicability of the ordinance that person, may submit to the city attorney a fun written statement of the facts and questions. The city attorney shall then I-ender an opinion to such person and shall publish these opinions without use of me name of the person advised unless the person permits the use of a name. (Ord. No. 6-'19-/680, § 2. 3-2-99) Editor's note-Ord. No. 6-99-1680, § I, adopted 3=2.9/;), repealed §§ 81.1.-1 and 8A-2 in their entirety aHa replac;ed them with new §§ 8A-1 and SA-I. Former §§ f$A-1 and 8A-2 per~ineQ 1;0 deoaratien of poli!:y and definitions. r~spt:ctiveJy. and derived from Ord. No. 634. §§ I (lA-I). I (IA-2) adoptedJ"n.11. 1969. Tbomas Il'. Powe 12110/201$ No person included in the term~ defined in paragraphs (b)( I) through (4) may recommend the services of any lawyer or law firm, architect or architectural firm. public relations firm. or any other person or firm. professional or otherwise, to assist in any transaction involving the city or any of its agencies, provided that a recommendation may properly be made when required to be made by the dUties of office and in advance at a public meeting attended by other city officials. officers or employees. (p) Continuing application after city service. (I) No person included in the terms defined in paragraphs (b)( I). (5) and (6) shall. for a period of two years after his or her city service or employment has ceased, lobby any city official [as defined in paragraphs (b)(I) through (6)] in connection with any judicial or other proceeding. application. Solicitation. RFQ. bid. request for ruling or other determination. contract. claim, controversy, charge, accusation. arrest or other particular subject matter in which the city or one of its agenCies is a party or has any interest whatever. whether direct or . indirect. Nothing contained in this subsection shall prohibit any individual from submitting a routine administrative request or application to a city department or agency during the two-year period after his or her service has ceased. (2) The prOvisions of the subsection shall not apply to persons who become employed by governmental entities. 50 I (c)(3) non-profit entities or educational institutions or entities. and who lobby on behalf of those entitieS in their official capacities. (3) The provisions of this subsection shall apply to aU persons described in paragraph (p)( I} whose (:ity service or employment ceased after the effective date of the ordinance from which this section derives. (4) No person described in paragraph (p)(I) whose city service or employment ceased within two years prior to the effective date of this ordinance shall for a period of two years after his or her service or employment enter into a lobbying contract to lobby any city official in connection With any subject described in paragraph (p)(I) in which the dty or one of its agencies is a party or has any direct and substantial interest; and in which he or she participated directly or indirectly through decision. approval. disapproval. recommendation. the rendering of advice, investigation .. or otherwise, during his or her city service or employment. A person participated "directly" where he or .she was substantially involved in the particular subject matter through deCision, approval. disapproval, .recommendation. the rendering of advice. investigation. or otherwise. during his or her city seryke or employment. A person participated "indirectly" where he or she knowingly participated in any way in the particular subject matter through decision, approval, disapproval. recommendation, the rendering of adVice. investigation, or otherwise. during his or her city service or employment. All person.~ covered by this paragraph shall execute an affidavit on a form approved by the city attorney prior to lobbying any City official attesting that the requirements of this subsection do not preclude the person from lobbying city officials. (S) Any person who violates this subsection shall be subject to the penalties provided in section SA-2(p). (q) City attorney to render opinions on reque.!t. Whenever any person included in the terms defined in paragraphS (1»(1) through (6) and paragraph (b)(9) is in doubt as to the proper interpretation or application of this conflict of interest and code of ethics ordinance, or whenever any person who renders services to the city is in dOl,lbt as to the applicability of the ordinance that person, may submit to the city attorney a full written statement of the facts and questions. The city attorney shall then render an opinion to such person and shall publish these op.inions without use of me name of the person advised unless the person permits the use of a name. (Qrd. No. 6.99-/680, § 2. 3-2-99) Editor's note-Ord. No. 6-99-1680. § I, adopted 3:~~99, I?l!ipwlecl §§ 8.4.-1 and 8A"2 in their entirety atlQ replaced them with new §§ SA-I and 8A-L Former §§ SA-I and SA-2 pertained to deoaratJen Qf poli!:y and definitions. respectively. and derived from Ord. No. 634, §§ I (lA-I), I (IA-2) ad()ptedJ'lIl.II. 1969. Tb\>m:u ~. P<¥P" 12/10/~OIS NOTICE OF AWARD "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PRlOI6-0S The City has considered the Proposal submitted by your firm for the "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" in response to its advertisement for Request for Proposal and Instructions to Respondents. You are hereby notified that your Proposal has been accepted for the "Purchase and Installation of Fitness cMer Etii,ent at the Gibson-Bethel Community Center" in the amount of $ ,01. -, , broken down as follows: Base Proposal: ~qq,'j1,.1' Alternate # I: Alternate #2: Alternate #3: You are required by the Instructions to Respondents to execute the Contract Documents at the time of submittal of proposal and to furnish any required Performance Bond, Payment Bond. and Insurance documents (see Proposal Submittal Checklist Form) Within ten (I O) day from the date of this notice to you. Notwithstanding the fact that you have agreed. by responding to the Solicitation. to the terms of the contract attached to the Solicitation package. if you fail to execute said Contract and to furnish said bonds. the required insurance documentation within ten (10) calendar days from the date of this notice. the CITY shall have the right and be entitled. in its sole and absolute discretion. to disqualify the Proposal. revoke the award and retain the Proposal/Bid BondlSecurity. Please be advised that if the contract price exceeds $5.000.00 or if it is a multi-year contract requiring payment out of more than one year's appropriation. the award and the contract must be approved by the City Commission before it is binding on the City. By: ________________________ ___ S~even Alexander City Manager Dated this __ day of _________ ,. 20 __ ACCEPTANCE OF NOTICE Receipt of the above Notice of Award is hereby acknowledged by ______________ _ On this the ____ day of _______ --...:. 20 __ • BY: TITLE: You are required to return an acknowledged copy of this Notice of Award to the City Manager. Thomas F. Pepe 12IIOflOl5 END OF SECTION 30 NOTICE TO PROCEED "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PR20 I ~OS F1Tf..l t::6"5N l·i1-I- TO: 3~1¢ C.JUA)..jjUt-.,( 13~v1:> 3~t-.rT'"(:,N B,€"A~H, t:""t... a~L/C;>(p PROJECT DESCRIPTION: "Purchase and Installadon of Fitness Center Equipment at the Gibson- Bethel Community Center" in accordance with Plans and Scope of Services referenced in the Contract Documents. You are hereby notified to commence Work in accordance with the Contract within 60 workina days from the date specified In a Notice to Proceed. or Purchase Order, (hereinafter referred to as the "Work Commencement Date," dated , on or before . City of South Miami BY: _________ _ (print name) City Manager, or designee ACCEPTANCE OF NOTICE Receipt of the above Notice to Proceed is hereby acknowledged by _____________ _ on this ___ day 01 ______ -', 20 __ , BY; Trr~: _____________ _ Thomas F. Pepe 12/1012015 END OF SECTION 31 EXHIBIT #1 Scope of Services Attachment A "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PR10 16·05 I. Scope of Work: The work specified in this Request for Proposal (RFP) shall consists of furnishing all goods. materials, supplies and services. including but not limited to the furnishing all labor of Contractor and all allowable subcontractors. disposal of materials. and cost of machinery, tools, transportation, equipment rental and permits, to perform all of the Work described below and which is necessary to provide a completed project that meets all of the needs described in this Scope of Services. Permit fees are waived for permits required to be issued by the City of South Miami. Permit fees from other government entities. if reqUired. shall be the responsibility of the Respondent/Contractor however. in all cases; it is the responsibility of Respondents/Contractors to secure any and all permits that may be reqUired for this project. Contractor is responsible for all safety measures for the site from the time the Notice to Proceed is issued until the City accepts the finished project in writing. Contractor shall select one access path for the site (to be approved by the City) and shall be responsible for complete restoration upon completion including, but not limited to, re-grading and repair or replacement of irrigation. sod. sidewalks. curbs. trees and/or other plants and any other items damaged by Contractors vendors, subcontractors, employees, representatives. etc.. to the City's satisfaction. Work activity is limited to the hours from 7:00 a.m. through 5:00 p.m., on weekdays from Monday through Friday. The City'S Parks and Recreation Department is soliciting proposals from qualified companies/contractors to: I) Remove and dispose of existing fitness and cardio equipment and carpet flooring and; 2) Supply. deliver and install new commercial fitness equipment, new 3/8" rubberized commercial gym flooring in the fitness/wellness and cardio rooms. and; 3) Provide and install three (32") LED Samsung teleVisions. or equivalen.t brand/manufacturer. at the GlbsonMBethel Community Center. located at 5800 Southwest 66 th Street, South Miami. Florida 33143. All equipment shall be delivered and installed on the second (rd) level at the community center. There is one (I) elevator with access to the rd floor, as well as a flight of stairs. A. Value Added Proposals: The City is seeking "value added" proposals from Respondents. Some "value added" suggestions are: Thomas F. Pepe 12(1011015 32 '., a) Preventative maintenance services for a period of time. Respondents shall specify the specific maintenance program and duration. b) Installation of rubberized commercial gym flooring for no additional charge. These are on'y suggestions -the City is not requiring Respondents to provide ·'value odded" items as part of this proposal; however, it will be considered during the evaluation phase, refer to Exhibit #6 ··Evaluation Selection Criterla/' B. Trade-In Allowances: Respondents shall include a "Trade-in Allowance" for existing Cardio and Strength equipment, please refer to Exhibit #4, "Respondents Cost and Technical Proposal." Trade-in Allowances shall indude all required labor and equipment, if necessary, for the breakdown, removal, and transportation of existing Cardio and Strength equipment from the City's fitness center. c. Equivalent Items: The City .has researched fitness equipment and determined that the brand name of the eqUipment listed in Tables A: Cardio Equipment and B: Strength Equipment demonstrates the quality and durability desired. Respondents may· submit pricing on eqUivalent items. It is at the sole discretion of the City to make the determination If a product will be acceptable as an equivalent. NOTE: Itespondent shall include, as a part of their proposal, descriptive and detail equipment literature with their submittal, warranty information, and 3- dimensional drawings/facility designs of all proposed equipment for the cardio and strength rooms. Table A: Cardio Equipment Qty. Equipment 3 Treadmill 2 Elliptical 2 Bike I Rower 2 32" LED TV Table B: Strength Equipment Qty. Equipment I 2 Cable Station/Chin Bar/Step Up Platform I Adjustable Abdominal Bench I Strength Adjustable Bench I Chest Press I Shoulder Press I Seated Row Thomas F. Pepe 1211012015 Description· or Equivalent Brand/Mfg. Life Fitness CLST Integrity Treadmill or similar model Life Fitness CLSX Integrity Cross-Trainer or similar model life Fitness CLSR Integrity Recumbent or similar model Row GX Trainer Samsung (wall mounted) or equivalent Description or Equivalent Brand/Mfg. Up Synrgy360T -Versa Dap Package or similar model Signature Series Adjustable Decline/Abdominal Bench or similar model Hammer Strength Adjustable Bench or similar model Optima Series Chest Press or similar model Optima Series Shoulder Press or similar model Optima Series Seated Row or similar model 33 I I Leg Extension Optima Series Leg Extension or similar model I Leg Curt Optima Series Leg Curl or similar model I Butterfly Optima Series Pec Fly/Rear Delt or similar model I Triceps Optima Series Triceps Extension or similar model I Lat Pull down Optima Series Lat Pull down or similar model I Hip Abductor Optima Series Hip Abductorl Adductor or similar model I Glute Insignia Series Glute or similar model I Lateral Incline Press Hammer Strength Iso-Lateral Incline Press or similar model I Lateral Rowing Hammer Strength Iso-Lateral Rowing or similar model I Leg Press Hammer Strength Linear Leg Press or similar model I Biceps Curl Hammer Strength Select Biceps Curl or similar model 2 Smith Machine w/adjustable Hammer Strength Smith Machine or similar model bench I Dumbbell Rack 3-Tier Optima Series Dumbbell Rack (10 Ibs -60 Ibs) or similar model 5 Medicine Balls w/ rack I each: 4 Ibs; 6 Ibs; 8 Ibs; 10 Ibs; 12 Ibs 3 Mats Fitness Mats I 32" LED TV Samsung (wall mounted), or equivalent 2 Resistance Tubes Life Fitness Resistance Tubes or similar model 2 Double Cord Resistance Tubes Life Fitness Double Cord Resistance Tubes ------l II. Site Location: The site is located within the City of South Miami; Gibson-Bethel Community Center, located at 5800 Southwest 66th Street, South Miami, Florida 33143. III. Second Floor Plans: Second Floor Plans are included and are part of this RFP by way of reference; Exhibit #1, Scope of Services, Attachment 8. The fitness room is labeled as "Well ness/Fitness" and the cardio room is labeled as "Recreation Room." The fitness room is approximately 1,768 sq. ft. and the cardio room is apprOXimately 547 sq. ft. IV. Project Funding: This project is funded through City funds. For fiscal year 20 16, the City of South Miami has allocated $121,000 in its Capital Improvement Program towards this project. V. Project Duration: The current estimate to complete project is 60 workine days from issuance of a Notice to Proceed. Thomas F. Pepe IlI1012015 34 d .. VI. Warranty: The standard manufacturer's warranty information must be provided in writing for all equipment being proposed, including installation by an authorized dealer. Thomas F. Pepe 1211012015 END OF SECTION 3S i I i I EXHIBIT #1 Scope of Services Attachment B "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PR20 16-05 Thomas F. Pepe IlII0I1015 GIBSON-BETHEL COMMUNITY CENTER SECOND FLOOR PLANS 36 ~)-.. {----- ~il' --.- ~ ,-! ;,,\'_.ir------ ~, i .. ! ~; I ~?-+---- 1 t' I ,'ik'} .. (-------, I d i ._ I ',"!/'~r--.--- .. _-_ .... _----_ .... _-------- fLOOfLP..!.8N LEG~ General l/ote9 .... 9ymbd l.egU1d tI&I IA[(.Il sn.o P.IR1ntOll :m::m::m::: flat' 8" GflIZ'" ~ COHCR£l£BU):KWAU. 10 nf: UOBUY _._- flJllQlttC Ar,tMN-ROO!.IlW4t .""" <TID ... " ROQI,I moa:n ~o sr ....... ,IETSOUJ.REmoT~ ell! !IlII~IWIT ........ ,_ e;=~=~~r:. 'B \,._. PROFtl£ Of AJruliE 2-STOOn COI£1I[O W'" KEY PLAN V) I- <:: Lw ~ ::::, (.) C) Q <: a f---.. C,,) ::::, Cl::: "- t/) <: a C,,) ~ ~ ~)- City 01 South MI."" III ., ... f '" I!! z III " III .. 5i 0 .. c a: ~ " .. !S x Sl § .. III .. .. ~ .. > " >-'" -I: 0: 10 ~ ~~ ;~ II " !~ It ~ II ;l ~ 'I " h A2.2 EXHIBIT #2 "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PR10 16-0S 1.01 A Insurance & Indemnification Requirements Insurance Without limiting its liability, the contractor, consultant or consulting firm (hereinafter referred to as "FIRM" with regard to Insurance and Indemnification requirements) shall be required to procure and maintain at its own expense during the life of the Contract, insurance of the types and in the minimum amounts stated below as will protect the FIRM, from claims which may arise out of or result from the contract or the performance of the contract with the City of South Miami, whether such claim is against the FIRM or any sub-contractor, or by anyone directly or indirectly employed by any of them or by anyone for whose acts any of them may be liable. B. No insurance reqUired by the CITY shall be issued or written by a surplus lines carrier unless authorized in writing by the CITY and such authorization shall be at the CITY's sole and absolute discretion. The FIRM shall purchase insurance from and shall maintain the insurance with a company or companies lawfully authorized to sell insurance in the State of Florida, on forms approved by the State of Florida, as will protect the FIRM, at a minimum, from all claims as set forth below which may arise out of or result from the FIRM's operations under the Contract and for which the FIRM may be legally liable, whether such operations be by the FIRM or by a Subcontractor or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable: (a) claims under workers' compensation, disability benefIt and other similar employee benefit acts which are applicable to the Work to be performed; (b) claims for damages because of bodily injury, occupational sickness or disease, or death of the FIRM's employees: (c) claims for damages because of bodily injUry, sickness or disease, or death of any person other than the FIRM's employees; (d) claims for damages insured by usual personal injury liability coverage; (e) claims for damages, other than to the Work itself, because of injury to or destruction of tangible property. including loss of use resulting there from; (f) claims for damages because of bodily injury, death of a person or property damage arising out of ownership. maintenance or use of a motor vehicle; (g) claims for bodily injury or property damage arising out of completed operations; and (h) claims involving contractual liability insurance applicable to the FIRM's obligations under the Contract. 1.02 Firm's Insurance Generally. The ARM shall prOVide and maintain in force and effect until all the Work to be performed under this Contract has been completed and accepted by CITY (or for such duration as is otherwise speci/led hereinafter), the insurance coverage written on Florida approved forms and as set forth below: 1.03 Workers' Compensation Insurance at the statutory amount as to al/ employees in compliance with the "Workers' Compensation Lawu of the State of Florida including Chapter «0, Florida Statutes, as presently written or hereafter amended, and all applicable federal laws. In addition, the policy (ies) must include: Employers' Liability at the statutory coverage amount. The FIRM shall further insure that all of its Subcontractors maintain appropriate levels of Worker's Compensation Insurance. 1.04 Commercial ComprehensjveGeneral Liability insurance with broad form endorsement, as well as automobile liability, completed operations and products liability, contractual liability, severability of interest with cross liability provision, and personal injury and property damage liability with limits of $1,000,000 combined Single limit per occurrence and $2,000,000 aggregate, including: • Personal Injury: $1,000,000; • Medical Insurance: $5,000 per person; • Property Damage: $500,000 each occurrence; 1.05 Umbrella Commercial Comprehensive General liability insurance shall be written on a Florida approved form with the same coverage as the primary insurance policy but in the amount of $ 1,000,000 per claim and $2,000,000 Annual Aggregate. Coverage must be afforded on a form no more restrictive than the latest edition of the Comprehensive General Liability policy, Without restrictive endorsements, as filed by the Insurance Services Office, and must include: (a) Premises and Operation (b) Independent Contractors (c) Products and/or Completed Operations Hazard Thomas F. Pepe 11110/2015 .. (d) Explosion, Collapse and Underground Hazard Coverage (e) Broad Form Property Damage (t) Broad Form Contractual Coverage applicable to chis specific Contract, including any hold harmless and/or indemnification agreement. (g) Personal Injury Coverage with Employee and C~:mtractuar Exclusions removed, with minimum limits of coverage equal to those required for Bodily Injury Liability and Property Damage Liability. 1.06 Business Automobile liabilit;y with minimum limits of One Million Dollars ($1.000.000.00) plus an additional One Million Dollar ($1.000.000,00) umbrella per occurrence combined single limit for Bodily Injury Liability and Property Damage Uability. Umbrella coverage must be afforded on a form no more restrictive than the latest edition of the Business Automobile liability policy, without restrictive endorsements. as filed by with the state of Florida, and must include; (a) Owned Vehicles. (b) Hired and Non~Owned Vehicles (c) Employers' Non-Ownership 1.07 SUBCONTRACTS: The FIRM agrees that if any part of (he Work under the Contract is subfet. the subcontract shall contain the same insurance prOVision as :;et forth in section 5.1 above and 5.4 below and substituting the word Subcontractor for the word FIR.M and substituting the word FIRM for CITY where applicable. 1.08 Fire 'and Extended Coverage InSUrance (ByildElfs' Risk), IF APPUCABLE: A In the event that this contract involves the construction of a structure, the CONTRACTOR shall maintain, with an Insurance Company Of Insurance Companies acceptable to the CITY, "Broad" form/AiI Risk Insul'3nce on buildings and structUres, including Vandalism & Malicious Mischief coverage. while in the course of construction, including foundations, additions, attachments and all permanent fixtures belonging to and constituting a part of said buildings or stl"\Jctwes, The policy or policies shall also cover machinery, if the cost of machinery is included in the Contract. or if the machinery is located in a building that is being renovated by reason of this contrat;;t. The amount of Insurance must, at all times, be at least equal to the replacement and actual cash valUe of the ins.ured property. The policy shall be in the name of the CITY and the CONTRACTOR, as their interest may appear. and shall also cover the interests of all Subcontractors performing Work. B. All of the .provisions set forth in Section 5.4 herein below shall apply to this coverage unless it would be dearly not appficable. 1.09 Miscellaneous; A. If any notice of cancellation of insurance Qr change in ,overage is iSSUC;lG by the insurar.~e 4;ompany or should any inslJrance have. an expiration da~ that will O(:I:UI· dlJring the period of this contract. the ARM shall be responSible for securing other acceptable insurance prior to such cancellation, change, or expiration so as to provide continuous cove~ge a,s specified in this section and so as to maintain coverage during the life of this Contract. B. All deductibles must be declared by the FIRM and must be approved by the CITY. At the option of the CITY, either the FIRM shall eliminate or reduce such deductible or the FIRM shall procure a Bond. in a form satisfactory to the CITY covering the $ame. C. The polioes shan contain wai"er of subrogation agdinst CITY where applicable, shall expressly provide that such policy or policies are primary over any other collectible insurance that CITY may have. The CITY reserves the right at any time to request a copy of the reqUired policies for review. All polioes shall contain a "severability of interest" or "cross liability" clause withqut obligation for premium payment of the CITY as well as contractual liability provision covering the Contractors duty to indemnify the City as prOVided in thi.s ~reeme.nt. D. Before starting the Work. the FIRM shall deliver to the CITY and CONSULTANT certificates of such insurance, acceptable to the CITY, as well 90S the in:;urance binder. if one is isslIect, the insurance poliCY, including the declaration page and all applicable endQrsements and provide the name, address and telephone number of the insurance agent or broker throll&h whom the policy was obtained. The insurer shall be rated AVII or better per AM. Best's Key Rating Guide, latest edition and authorized to issue insurance in the State of Aorida. An insurance poliCies must be written on forms approved by the State of Florida and they must remain in full force "nd effect for the duration of the contract period with the CITY. The FIRM may be required by the CITY, at its sole discretion. to provide a "certified copy" of the Policy (as defined in Artide I of this do<;ument) which shall include the declaration page and all required endorsements. In addition, the FIRM shall deliver. at the time of delivery of the insurance certificate. the follOWing endorsements: (I) a policy provision or an endol'sement with sub.5tantially similar provisions as fallows: Thomas F. Pepe IlllOnPIS r I I I I ., I I "The City of South Miami is an additional insured. The insurer shall pay all sums that the City of South Miami becomes legally obligated to pay as damages because of 'bodily injury'", 'property damage', or "personal and advertising injury" and it will provide to the City all of the coverage that is typically provided under the standard Florida approved forms for commercial general liability coverage A and coverage B"; (2) a policy provision or an endorsement with substantially similar provisions as follows: "This policy shall not be cancelled (including cancellation for non-payment of premium), terminated or materially modified Without first giving the City of South Miami ten (10) days advanced written notice of the intent to materially modify the policy or to cancel or terminate the policy for any reason. The notification shall be delivered to the City by certified mail, with proof of delivery to the City." E. If the RRM is providing professional services, such as would be provided by an al-chitect, engineer, attorney, or accountant, to name a few, then in such event and in addition to the above requirements, the FIRM shall also provide Professional \,iahility Insurance on a Florida approved form in the amount of $1,000,000 with deductible per claim if any, not to exceed 5% of the limit of liability providing for all sums which the FIRM shan become legally obligated to pay as damages for claims arising out of the services or work performed by the FIRM its agents, representatives, Sub Contractors or assigns, or by any person employed or retained by him in connection with this Agreement. This insurance shall be maintained for four years after completion of the construction and acceptance of any Project covered by this Agreement. However. the FIRM may purchase Specific Project Professional Liability Insurance, in the amount and under the terms specified above. which is also acceptable. No insurance shall be issued by a surplus lines carrier unless authorized in writing by the city at the city's sole. absolute and unfettered discretion. Indemnification Requirement A The Contractor accepts and v~luntar-ily incurs ~Il risks of any injuries. damages, or harm which might arise during the work or event that is occurring on the CITY's property due to the negligence or other fault of the Contractor or anyone acting through or on behalf of the Contractor. B. The Contractol-shall indemnify. defend, save and hold CITY, its officers, affiliates, employees, successors and assigns, harmless from any and all damages. claims, liability, losses, claims, demands. suits. fines. judgments or cost and expenses. including reasonable attorney's fees, paralegal fees and investigative costs incidental there to and incurred prior to, during or follOwing any litigation. mediation, arbitration and at all appellate levels, which may be suffered by, or accrued against. charged to or recoverable from the City of South Miami, its officers. affiliates, employees. successors and assigns, by reason of any causes of actions or claim of any kind or nature, induding daims for injury to, or death of any person or persons and for the loss or damage to any property arising out of a negligent error, omission. misconduct or any gross negligence, intentional act or harmful conduct of the Contractor, its contractor/subcontractor or any of their officers, directors, agents. representatives, employees. or assigns, or anyone acting through or on behalf of any of them, arising out of this Agreement, incident to it, or resulting from the perlormance or non-performance of the Contractor's obligations under this AGREEMENT. C. The Contractor shall pay all claims, lo,sses and expenses of any kind or nature whatsoever, in conllection thereWith, including the expense or loss of the CITY and/or its affected officers. affiliates, employees, successors and assigns, including their attorney's fees. in tfll~ defense of any action in law or equity brought against them and arising from the negligent error, omission. or aCt of the Contra<:tor, its Sub-Cono-actor or any of their agents. representatives. employees. or assigns. and/or ariSing out of, or incident to, this Agreement, or incident to or resulting from the perfQrmance or non-performance of the Contractor's obligations under this AGREEMENT. D. The Contractor agrees and recognizes that oeithet-the CITY nor its officers, affiliates, employees. successors and assigns shall be held liable or responsible for a.oy claims, induding the costs and expenses of defending such claims which may result from or arise out of actions or omissions of the Contractor, its contractor/subcontractor or any of their agents. representatives, employees, or assigns. or anyone acting through or on behalf of the them, and arising out of or concerning the work or event that is occurring on the CITY's property. In reviewing, approving or rejecting any submissions or acts of the Contractor, CITY in no way assumes or sh~res responsibility or liability for the acts or omissions of the Contractor, its contractor/subcontractor or any of theIr agents, representatives. employees. or assign£. or anyone acting through or on behalf or them. E.. ~he Contractor has ~e du~y to provide a defense with an attorney or law firm approved by the City of South MIami, which approval will noc oe unreasonably Withheld. Thomas F. Pepe 12110/2015 F. Howewr, as tQ design professional COntracts, aod pursuant to Section 725.08 (I), Florida Statutes, none of the provisions set forth herein above that a.re in conflict with this subparagraph shall apply and this subparagraph shall set forth the sole responsibility of the design professional concerning indemnification. Thus, the design professional's obligations as to the City and its agencies, as well as to its officers and employees, is to indemnify and hold them harmless from liabilities, damages, losses. and costs, including, but not limited to, reasonable attorneys' fees. to the extent caused by the negligence, recklessness, or lntentionally wrongful conduct of the design professional and other perllons employed or utilized by the design professional in the performance of the contract. l'hom8S F. PeW! !~1I11/10fS ENO OF SE~TJON • 1 EXHIBIT #3 "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Center" RFP #PR20 16-05 BID FORM THIS PROPOSAL IS SUSMITIED TO: Steven Alexander City Manager City of South Miami 6130 Sunset Drive South Mia.mi, FL 33143 I. If this Proposal is aq:epted, the unde .. signll~ Q,~sj}.olldent agrees to enter into a Contract with the City of South Miami in t~le form included in this Solicitation Package and to perform and furnish all work as specified or indicated in this Solicitation, including as set forth in Exhibit I (Scope of Services) for the Proposed Price as set forth below, within the Contract Time and in accordance with the other terms and conditions of the Solicitation Package. 2. Respondent accepts all of .the terms and conditions of the Solicit.'ltion and Instructions to Respondents, including Without limitation those dealing with the disposition of Proposal/Bid Bond. if required. This Proposal will remain subject to acceptance fOI" 180 calendar days after the day of the Proposal Opening. The Respondent, by signing and submitting this proposal. agrees to all of the terms and conditions of the form of contract that is a part of the Solicitation package with appropriate changes [0 conform to the information contained in this Bid Form. Respondellt agrees to sign and submit the Bonds, if required by this Solicitation, required insurance documents. and other documents required by the Solicitation. including the Contract if not already submitted. within ten (10) calendar days after the date of the City's Notice of Award. 3. In submitting this PI'oposal, Respondent r-epn;senr.s that: a. Respondent has examined copies of all ttle Solicitation Pocuments and of the following Addenda, if any (receipt of all which is hereby acl<nowle4~ed,) Addendum NQ. b. Re.spondem~ hilS f\\miliarizefl ~imsl;:!f with th~ t,i\t\lf~ ;wd ~xnmt Qf the C~m~ract OQcuPlf;!nts. d~e prepo~ed work. sit~, !ocality. and all local condition~ and laws a,nd reg\.dafIQns that in any manner may ~ffect c;:ost, progress, performance or furnishing of the Work. 4. Respondent understands and agrees that the Contract Pdce is the amount that it neeqs to flJl'nisn and install all of the Work complete and in place. The Schedule of Values. if required. is provided for the purpose of Proposal EValU:ltion and when initiated by the CITY. it shall form ~ne batis for calculating the pricing of change orders. The Contract Price shall not be adjusted In any way so as to result in a deviation frorr. the Schedule of Values, except to ~he extent that the CITY changes the Scope of the Wort< after the Contract Date. As such, the Respondent shall furnish all labor, materials, eqUipment. tools. superintendence and services necessary to provide a complete. in place, Project for the Proposal Price. If this Solicitation requires the completion of a "Res-pondenu Cost and Technical Proposal:' CIS may be set forth in Exhibit 4 to this Solicitation, such proposal must be attached to this Bid Form and will take the place of the Lump Sum Price, otherwise, the Contract Price for the completed work is as follows: [ Refer to Exhibit 4, "Re~pondent$ COst and T~chniCQI !~r_QP_o_s_a_'_~.··~'_:_·_. ~ 5. The ENTIRE WORK shil,1I be completeq, in full, within 60 wOI"!dng days from the cornmenczement date set forth 1n the NOTICE TO PROCEED. Failure to complete the entire work during the described time period shall result in the ass~ssment of IIquicJ~ted damages as may be set forth in the Contract. 6. Insert the follOWing information for fut\we cOllllllunicoxicn with you concerning this Proposa.l: Thoma$ F. Pepe 12/1G/20lS RESPONOENT: Ad<!re!is: Telephone: Facsimile: Contact Person 7. The terms used in this Proposal which are defined in the Contract shall have the same meaning as is assigned to them in the Contract Docum~nt1i> unless specifi~11y defined in this Solicitation Package. 8. If a Respondents COlit " Technical PYOPQsal. Exhibit 4, is required by the Solicitation, Respondent hereby certifies that all of tile facts and responses to the questions posed in the ResPQndents Cost & Technical' Proposal, if such an exhibit is made a part of the Solicitation, are true and correct and are hereby adopted as part ot this Bid Form, and are made a part of this proposal. by reference. 9. By submitting this ·proposal. I, on beh~lf of the busineS$ that I represent, hereby agree to the terms of the form of contract contained in the Soli(:itation package and I agree to be bound by those terms. with allY appropri'ate blank boxes, if any, checl(ed and any blank lines filled in with the appropriate information contained in the Solicitation Documents and this Proposal. or such information that the City ancl I have agreed upon in the course of contract negotiations and which have been confirmed by the City in writing. indUding e-mail confirmation. if any. I hereby certify under penalty of perjury that I am the lawful representative of the bUsiness entity referenced in this Bid Form. that I have authority to bid for that entity and that all of the information and representations contained herein are true and correct to the best of my information and belief. SUBMITTED THIS Tf1Qm!!S F. ~epe 121 I It/Z(U ~ EXHIBIT #5 CONTRACT "Purchase and Installation of fitness Center Equipment at the Gibson-Bethel Communityt' Center" RFP #PR20 16·05 THIS CONTRACT, entered into this ~ day of M ~ • 2016, by the CITY OF SOUTH MIAMI through its Manager, both of whom shall be hereinafter referred to as the "CITY" where applicable; located at 6130 Sunset Orive. South Miami, FL • E-mail: salexander@southmiamifL&QY and F', +-~c.. rrN\ \ +" . with an office and principal piace of business located at ~b'O d1~I"\ ~~~d E-mail address of ~ALl.~ ~ ~\~~f'\.'~4'~ereinafter called the "CONTRACTOR"). WITNESSETH: WHEREAS, the CITY is in need of Fitness Equipment at the . Gibson-BetheR CommllinityCenter;and . WHEREAS, the CITY desires to retain the CONTRACTOR to provide the required goods and/or services based on the CONTRACTOR's representa,tions that it is qualified and capable of providing said goods and/or services in a professional and timely manner and in accordance with the CITY's goals and requirements; and WHEREAS, the CONTRACTOR has agreed to provide the required goods and/or . services in accordance with the terms and conditions set forth herein. NOW, THEREFORE. in consideration of the mutual covenants and agreements herein contained. the parties agree as follows: I) Engagement of Contractor: Based on the representations of the CONTRACTOR asset out in the following "checked" documents the CITY hereby retains the CONTRACTOR to provide the goods and/or services set forth in said proposal, quote or response to solicitation, whichever is applic;:able, as modified by. the .Contract Documents, or as is otherwise set forth in the Contract Documents defined below (all of which is hereinafter referred to as the Work"). (Check the box immediately preceding the document described below to indicate that such document is part of this contract) -.J Contractor's response to the CITY's written solicitation; Qr -.J Contractor's proposal or quote, or if none, o As described in paragraph 2 below. 2) Contract Documents: The Contract Documents shall include this Contract and the following "checked documents". as well as any attachments or exhibits that are made a part of any of the "checked documentsh • (Check the box immediately preceding the document described below to indicate that such document is part of this contract) o General Conditions to Contract, o Supplementary Conditions, o "Other Documents" referring to in this contract and signed by the parties, ..J SoliCitation documents ("hereinafter referred to iDS "Bid Documents" including any request for bid, request for proposal or similar request) ..J Scope of Services. ..J Contractor's response to the CITY's Bid I;)ocuments, ..J Contractor's proposal or quote, ..J CITrs Insurance & Indemnification Requirements, o Bonding of Employees (the term "employee", as used in this contract, shall include volunteers) • $1,000,000 o Payment Bond. o Performance Bond. This Contract and the General Co~ditions to Contract, Supplementary Conditions, the Solicitation, Scope of Services and "Other Documents", if any are "checked documents", shall take precedent over the response to the CITY's Bid Documents, the proposal or the quote, if any. The "checked documents" are attached hereto and made 21 part hereof by reference. 3) Date of Commencement: The CONTRACTOR shall commence the performance of the Work under this Contract on !UA or a date to be specified in a Notice to Proceed, or Purchase Order, (hereinafter referred to as the "Work Commencement Date"), and shall complete the performance hereunder within 60 working days or the length of time set forth in the Contract Documents, whichever is the shorter period of time. Time is of the essence. 4) Primary Contacts: The Primary Contact Person in charge of administering this Contract on behalf of the CITY is the City Manager ("Manager"), assistant Manager, or the Manager's designee. who shall be designated in a writing signed by the Manager. The Primary Contact Person for the CONTRACTOR and hisJher contact information is as follows: Name: MlchAd Sc.'(.""~((. e-mail:Plieh.1c/f-h~Jlle~reta~~ -Street Address: 3(./0 QuAJI",,,,, OJ~(), IlO:cA.7l'OAof (\cAC ., R. 31.., l.(. 5) kope of Services: The goods and/or services to be provided are as set forth in the "checked documents". 6) Compensation: The CONTRACTOR's compensation for the performance of this contract (hereinafter referred to as the Contract Price) shall be one of the following. as indicated bya checked box, Y'St5,527.77 or as set forth in D CONTRACTOR's response to the CITY's written solicitation, if any, or, if none, then as set out in CONTRACTOR's proposal or quote, or the Scope of Services, whichever is applicable. and as modified by the Contract Documents. 7) Houn of Work: In the event that t~ls contract requires the performance of services, it is presumed that the cost of performing the Work after regular working hours, and on Sunday and legal holidays is included in the Contract Price. However. nothing contained ,. .. ~{' " . '.) herein shall authorize work on .days and during hours that are otherwise prohibited by ordinance unless specifically authorized or instructed in writing by the City Manager, the Manager's assistant or designee. 8) Time Provisions: The tenn of this Contract shall commence on the Work Commencement Date and shall continue fdr",W: qIIay! until it expires on lfilll"Qiea Completion. or unless earlier terminated-according to the Contract Documents. Notwithstanding the foregoing, this Contract may be extended by an additional 60 day period if the extension is in writing and signed by the City Manager. An extension of the term of this Contract is at the CITY's sole and absolute discretion. 9) Termination: This contract may be terminated without cause by the CITY with 30 days of advanced written notice. This provision supersedes and takes precedence over any contrary provisions for termination contained in the Contract DocumentS. 10) Applicable lLa\w all'ild! VenWle: Florida law shall apply to the interpretation and enforcement of this Contract. Venue for all proceedings shall be in Miami-Dade County, Florida. I I) Duties aBllcll Responsibilities: The Contractor shall comply with all applicable laws, ordinances, codes, rules, regulations, and health and safety standards of any governmental body having jurisdiction over any matter related to this Agreement or the goods and/or Services to be performed hereunder, and shall commit no trespass on any private property in performing any of the work embraced by this Agreement. Each and every provision and clause required by law to be inserted in this Agreement shall be deemed to be inserted herein and the Agreement shall be read and enforced as though such provisions and clauses were included herein. 12) Change Orders: No additional Work or extras shall be done unless the same is duly authorized in writing and in advance of the work by appropriate action by the City Manager and in accordance with the Contract Documents. 13) Jl.icenses and Certifications: Contractor shall secure all necessary business and professional licenses at its sole expense prior to executing the Agreement or commencing the Work. 14) Insurance, IndemnificatioBD &: Bonding: CONTRACTOR shall comply with the insurance, indemnification and bonding requirements set forth in the Contract Documents. I 5) Liquidated Damages: In the event that the CONTRACTOR shall fail to complete the Work within the time limit set forth in the Contract Documents. or the extended time limit agreed upon, in accordance with the procedure as more particularly set forth in the Contract Documents, liqUidated damages shall be paid at the rate of SN/A dollars per day until the Work is completed. 16) Jury if'riaU WaDvelF. The parties waive their right to jury trial. 17) Entire Agreements, lM!cdificatDollll. arnd lNIon .. waiver: The Contract Documents constitute the entire agreement of the parties and supersedes any prior agreements, written or oral. The Contract Documents may not be modified or amended except in writing, signed by both parties hereto. The Contract Documents. in general, and this paragraph. in particular, shall not be modified or amended by any acts or omissions of the parties. No failure to exercise and no delay in exercising any right. power or privilege shall operate as a waiver. No waiver of the Contract Oocuments, in whole or part. including the provisions of this paragraph, may be implied by any act or omission. 18) PlUlblic Rec:ol1'ds: CONTRACTOR and all of its subcontractors are required to comply with the public records law (s.119.070 I) while providing goods and/or Services on behalf of the CITY and the CONTRACTOR, under such conditions. shall incorporate this paragraph in all of its subcontracts for this Project. 19) IiackgrGlIIlI1d 5cresnDlIllg. All personnel and volunteers that will provide any service with vulnerable persons. as defined in Section 435.02. Fla. Stat.. involving the City or its Agency in such related activity or who may have access to secure or sensitive areas of the City, must be in compliance with Level II Background Screening and fingerprinting requirements as per, Florida Statute Ch. 435 prior to the scheduled start of any employee or volunteer. CONTRACTOR. shall prevent any and all of its personnel. including volunteers, from engaging in any such related activities without having passed a background screening to the satisfaction of the City. A violation of this requirement shall constitute a substantial breach of the agreement. 20) Drrug Free WOlI"kpDaee. The CONTRACTOR shall comply with the Drug Free Workplace policy set forth in the City of South Miami's Personnel Manual which is made a part of this Contract by reference. 21) Transfer and} Assignmerrnt. None of the work or services under this contract shall be subcontracted or assigned without prior written consent from the SMCRA which may be denied without cause. 22) Notices. All notices given or required under this contract shall be deemed sufficient if sent by a method that provides written evidence of delivery, including e-mail and facsimile transmission and delivered to the CONTRACTOR. or his designated contact person. Return of mail, sent to the address contained herein for the parties or their contact persons. as not deliverable or for failure to claim the mail shall be deemed received on the date that the mail is returned to sender. lIN! WDTNESS WHEREOf, the parties. have executed this Contract, on or before the date first above written, with full knowledge of its content and significance and . intending to be legally bound by the terms hereof. Read and Apj?roved as to Form, Language, Legality and Execution T~ereof: B;/~€ 4:[ ,1.--/ 1f City Attorney [name of signatory] even Alexander City Manager EXHIBIT #6 EVALUATION CRITERIA "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community Cen1:er" RFP #PR20 I 6-05 ~c()rin8 ,and Ranking Phase 1-: Competitive Selection-Ranking; ~a~imum. 109 points. The ~vaiuation factors used for determining qualifications for ranking fn~lude: . I. Brand. Durability and Warranty ~f Prl<)t'l6;?!':d EqlJipment; Maximum 30 PO.ints ~. Val\.!e Added Propo$a.ls; Maximum 30 Points 3. Pri~e Proposal and Tracle.,.in AIIQwanc;~ i::Q th~ City; Maximum 25 Points 4. Referen~es and Previous WQr-klln~t~lI~ip.A$. of Similar Equipmen~; M~imum 15 PQi"t$. jlhilse n .,.,. Competi~i\lt; Neg9tia,.ti0!l~: Following ranking of the most qualified firms. th~ City may negotiate a contract with the mQst qualified ikm for the applicable services as indicated in the "Scope of Services" included with this RFP. If negotiation with highest ranked firm fails. the City shall move to the next highest ranked firm. NOTIFICATION In the event the City el~c~s to hpld OrQ.1 In~~I;y.jew$. interviews will be he!d "fBI), The firm selected will bE! notified by Email. The City ll.ppreciates all responses and will notify all respondents Qf their status in our selectiQn process. The City reServes the right ~o. r~ject any i.l,nd all f!rQj;}9Sals. Thomas F. p.t;p'~ 12fIO/2I)J~ I I i EXHIBIT #7 "Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Community RFP #PR20 I6~05 City of South Miami Bid Protest Procedures RESOLUTION OF PROTI;STEI) SOLICIT ~ TIONS AND AWARDS (FORMAL PROCEDURE) The following procedures shall be used fOI" resolution of protested solicitations and awards. The word "bid", as well as all of its derivations, shall mean a response to a solicitation, including requests for proposals. requests for a letter of interest and requests for qualifications. (a) Notice of Intent to Protest. Any actual or prospective bidder who perceives itself to be aggrieved in connection with any formal solicitation or who intends to contest or object to any bid specifications or any.bid solicitation shall file a written notice of intent to file a protest with the City Clerk's office within three calendar days prior to the date set for opening of bids. A notice of intent to file a protest is considered filed when received by the City Clerk's office bye-mail or, if hand delivered, when stamped with the City Clerk's receipt stamp containing the date and time of receipt of a notice of intent to file a protest. Any actual responsive and responsible bidder who perceives itself to be aggrieved in connection with the recommended award of a contract and who wishes to protest the award, shall file a written notice of intent to file a protest with the City Clerk's office within three calendar days after the City Commission meeting at which the recommendation is considered for action. A notice of intent to file a protest is considered filed when received by the City Clerk's office bye-mail or, if hand delivered. when stamped with the City Clerk's receipt stamp containing the date and time of receipt. (b) Protest of solicitation. A protest of the solicitation or award must be in writing ("Protest letter") and submitted to the City Clerk's office within five calendar days after the date of the filing of the notice of intent to file a protest. The Protest Letter is considered filed when the Protest Letter and the required filing fee of $1,000 are both timely received by the City Clerk's office. In order for the Protest Letter and filing fee to be considered timely delivered by hand delivery, the date stamp of the Clerk's office must appear on the original Protest Letter and/or a copy of the Protest Letter and the date stamp must also appear on a copy of the check issued for the payment of the filing fee, or, if payment is made in cash, a receipt must be issued by the Clerk's office reflecting the date of receipt of the payment. While the Clelok may accept the Protest Letter by email, the Protest letter shall not be considered to be timely received until and unless the required filing fee of $1,000 is received by the City Clerk's office and, if payment is in cash, a receipt is issued with the date of the receipt of payment, or if payment is by check, a copy of the check is stamped by the Clerk with the date stamp of the Clerk's office showing the date of receipt. The Protest letter shall state with particularity the specific facts and law upon which the protest is based, it shall describe and attach all pertinent documents and evidence relevant and material to the protest and it shall be accompanied by any required filing. The basis for review of the protest shall be the documents and other evidence described in and attached to the Protest Letter and no facts, grounds, documentation, or other evidence not specifically described in and attached to the Protest Letter at the time of ~ filing shall be permitted or considered in support of the protest. (c) Computation of time. No time will be a<;lded tQ ~he above time limits for se"\'i~e by mail. The last day of the period so c()mputed shall be included unless it ir. a Saturday, Sunday, or lli:gal holiday in which event the period shall run until the next day which is not a Saturday, Sunday, or legal holiday. (d) Challenges. The written protest may not challenge the relative weight of the evaluation criteria or any formula used for assigning points in making an award determination. rlor shail it challenge the City's determination of what is in the City's best interest which is one of the criteria fOI" selecting a bidder whose offer may not be the lowest: bid price. Thomas f. Pepe 1211012015 (e) Authority to resolve protests. The Pl!r.ch;lsing Manag~r. after consultation with the City Attorney. shall issue a written recommendation with ill ten calendar days after receipt of a valid Protest Letter. Said recommendation shall be sent to the City Manager with a copy sent to the protesting party. The City Manager may then, submit a recommendation to the City Commission for approval or disapproval of the protest, resolve the protest without submission to the City Commission. or reject all proposals. (f) Stay of procurement during protests. Upon receipt of a timely. proper and valid Protest Letter flied pursuant to the requirements of this section, the City shall not proceed further with the sqlicitation or with the award or execution of the contract until the protest is resolved by the City Manager or the City Commission as provided in subsection (e) abov~,unless the City Manager makes a written determination that the solicitation process or the contract award must be continued without delay in order to avoid potential harm to the health, safety, or welfare of the public or to protect substantial interests of the City or to prevent youth athletic teams from effectively missing a playing season. .. , ..... ". ( " EXHIBIT #4 "Purchase and Installation of Fitness Center Equipment at the Gibson.Bethel Community Center" RFP #PR20 16.05 RESPONDENTS COST & TECHNICAL PROPOSAL Note: Indicate if the Respondents proposal is NOT supplying the City's Preferred Brand/Description, refer to fxhibit I, "Scope of Services" Table A and Table 8, by checldng HERE: I 7 Nol If NO is selected, Respondents must provide the brand name, manufacturer and description in the table below; or on a separate sheet attached to Exhibit #4. Table A: Cardio Equipment: Qty. Equipment Description or Equivalent Brand/Mfg. 3 Treadmill 2 Elliptical 2 Bike I Rower 2 32" LED TV (wall mounted) Table B: Strength Equipment: Qty. Equipment Description or Equivalent Brand/Mfg. I 2 Cable Station/Chin Up Bar/Step Up Platform I Adjustable Abdominal Bench I Strength Adjustable Bench I Chest Press I Shoulder Press I Seated Row I Leg Extension I Leg Curl I Butterfly I Triceps I Lat Pulldown I Hip Abductor I Glute I Lateral Incline Press I Lateral Rowing I Leg Press I Biceps Curl .. 2 Smith Machine w/adjustable bench I Dumbbell Rack 5 Medicine Balls wi rack 3 Mats I 32" LED TV Thomas F. Pepe 12110/2015 44 -~ .. ... Resistance Tubes Double Cord Resistance Tubes LUMP SUM PROPOSAL; LUMP SUM PROPOSAL, IN ACCORDANCE WITH EXHIBIT I. "SCOPE OF SERVICES," ATTACHEMENT A" B: $,_q.L.J~'t-I,ti ..... U..s...n..l...%:1....:.'...!-__ USS TRADE IN AllOWANCE ($ 4,r:£IJ. '00 . ) = NET LUMP SUM PROPOSAL: $ NOTE: Respondent shall include, as a part of their proposal, descriptive and detail equipment literature with their submittal, warranty information, and 3- dimensional drawings/facility designs of all proposed equipment for the cardio and strength rooms. SUBMITTED THIS Thomas F. Pepe 121 I OllO 15 ~g. DAYOF -lI~.J-.....!Io~~ ___ lOlb.. END OF SECTION 4S OVERALL WEIGHT RUNNING SURFACE 575.5 Ibs (261.04 kgi 60' )( 21.5" 1152 x 54.6 cm) FEATURES AND SPECIFICATIONS STEP-UP HEIGHl: 9" 122.86 cml FRAME: Custom powdeF-COated steel uniframe MOTOR DRIVE: 5 HP ~ ELECTRICAL: 110 volt dedicated NEMA 5-20 cord; 220 Volt. dedicated NEMA 6-15 cord (optional) CERTIFICATION: UL/CSA, CEo FCC. or CISPR SUSPENSION: Soft Trac® triple celt neoprene rubber. Deck System: Reversible 1" (2.5 em) composite fiberboard. waxing not required ROLLERS: 3" (7.6 cm}sealed bearings COLORS: Frame: StarTlac Silver. Shrouds: Slate Gray. Accents: Black INCLINE RANGE: 0 to 15% in 0.5% increments SPEED RANGE: 0.5 to 12.5mph (O.B to 20 km/hl in 0.1 mph (0. I km/hl increments HR MONITORING: Polar"'Telemetry and Contact Heart Rate System E-TR TREADMILL ................................................................................................................ Model E-TR • Pre-wired for E Series PVS entertainment system • User-friendly console and keypad feature a large service scrolling message window. user-specific workout programs, a dedicatd heart rate display, Polar® telemetry and multiple cup and accessory holder • Soft Trace!> triple cell cushioning system provides maximum shock absorption • 5 HP AC Motor • Centered dual-adjustable personal fans create a more rewarding workout • 21.5" (54.6 em) belt • 9" (22.86 em) step-up height • User weight capacity 500 Ibs (227 kg) WIDTH LENGTH HEIGHT 32-(8'1.3 cml Bl" (206 eml 59.77-(151.81 cm) DISPLAY: Intuitive. tactile response keypad with LED technology READOUTS: Large 8-character message window; Dedicated: Time. distance. indine. speed, heart rate, 1/4-mile motivational track. profile; Scrolling: calories, METs. course profile PROGRAMS: 12 programs including Dynamic Heart Rate Control". Constant Heart Rate Control. Quick Start, Bum Calories, Manual. Increase Endurance. Fitness Test (Modified Balke Warel. Firefighter Test (Modified Gerkin Protocoll STANDARD FEATURES: Personal cooling fans. wraparound Aero Bar. dedicated heart rate display. Entertainment Solutions Ready, Safety Lanyard ENTERTAINMENT: Pre-wired for E Series PVS entertainment system WARRANTY: Structural frame welds 10 years, motor and MCB 5 years parts and labor, all other components warranted for 2 years parts and 1 year labor. wear items 1 year parts and labor 'Warranties are subject to change and may vary internationally 'Contact your StarTrac Sales Representative for full commercial. light commercial and consumer warranty detail 020!4 StarTfIIC All right ,...rved. StarTIlIC. tile StarTrac Iogo •• nd Dynamic: .. eart Rat. Contral.", rogl .... rad trIIdemarlc!l D' ecwelndustrios. LLC. ""'or i. 0 ragistered _de of -. EIOCIn>, Inc. S-CTx CROSS TRAINER ................................................................................ STEP-UP HEIGHT OVERALL WEIGHT r 117.8 em) I <183 )bs (219 kg) FEATURES AND SPECIFICATIONS PEDAL SIZE: 17.5" I x 8" w 145 x 20 em), open ended DISTANCE BETVVEEN PEDALS (O-FACTOR): 2" (508 em) ELECTRICAL: Self-contained power supply, no external power needed AC adapter is available for an upgrade CERTIFICATION: UUCSA or CE COLORS FRAME: StarTrac Silver, Shrouds Slate Gray, Accents: Black RESISTANCE: 20 levels of intensity HR MONITORING: Polar" Telemetry and Contact Heart Rate System READOUTS 4-character message window: Dedicated: Time. heart rale. motivational track, Drof,le scrOlling: Calories. calories, wans, distance, speed, rvJETs I Model S-CTx • Pre-wired for S Series PVS e!"ltertainment system • User-friendly console and keypad feature a large service scrolling message window, user-specific work out programs, a dedicated heart rate display, Polaf'0telemetry, and multiple cup and accessory holders • Efficient footprint and approachable, stable platform with minimal step-up height for easy access from all angles • StarTrac's popular adjustable personal fans create a more rewarding workout • SoftTrac~ pedals provide ultimate shock-absorbing comfort throughout the entire workout • User weight capacity 350 Ibs (159 kg) WIDTH LENGTH HEIGHT 30' 176.2 em) 76-!i93 eml 715' (18i.6 em) PROGRAMS: 10 progrSi115 including Quick Start, Dynamic Heart Rate Control", and Constant Heart Rate Control STANDARD FEATURES: Personal cooling fans, dedicated heart rate display, pre- wired for Start Trae entertsinil1ent solulion, S-Serres pvS entertainment system. Soh Trac" pedals WARRANTY: Light commercial setting: Lrietin1e warranty on frame, 3-year warranty on pans and labor (USA and Canada only)" (Light Commercial warranty tor ali non dues paying facilities 3 years paf1s~abor) @2012 StarTrac All right reserved. StarTrac. the StarTrac togo,Soft Trsc. and DYrlamic Heart Aate Control are registered trademarks of Core Industries. Polar is a registered trademaf'k of Polar Electro, Inc. I S-RBx RECUMBENT BIKE ............................................................................................................ . OVERALL WEIGHT WIDTH 212 Ibs (96.2 kg) 28" (71.12 em) FEATURES AND SPECIFICATIONS FRAME: Custom steel frame PEDALS/CRANK: One-piece crank with sealed bearings. dual-sided pedal. extra long 14" pedal straps with inline skate-style clip ELECTRICAL: Sell-{)ontained power supply. no external power needed. AC adapter is available lor an upgrade CERTIFICATION: UUCSA. CE COLORS: Frame: StarTrac Silver. Shrouds: Slate Gray, Accents: Black RESISTANCE: 20 levels of intensity HR MONITORING: Polar"'Telemetry and Contacl Heart Rate System READOUTS: 4-character message window. Dedicated: Time. RPM. distance. heart rate. motivational track. course profile. resistance level. Scrolling: Calories! METs I.automatic 10ggle1 Model S-RBx • Pre-wired for S Series PVS entertainment system • Walk-through design and intuitive wrap-around seat adjust allow users to access and change seat position with ease • Dual-platform pedals with inline skate-style straps provide user with option for secure hold or strap-free platform workout • Armrests alleviate tension in the shoulders and allow for a more relaxed posture • Improved shroud design for ease of service access • Wrap-around seat adjust provides an intuitive handle for simple seat position changes • StarTrac's popular adjustable personal fans create a more rewarding workout • Contoured backrest for increased airflow and comfort • 3 piece patent pending bottom bracket and pedal system • User weight capacity 350 Ibs (159 kg) LENGTH HEIGHT 66" (167cm) 53" (134.6 cm) PROGRAMS: 10 programs including Dynamic Heart Rate Control". Constant Heart Rate Control. Quick Start. Manual. Burn Calories, Increase Endurance. Burn Fat. Cal one Goal. Distance Goal. Fitness Test STANDARD FEATURES: Personal cooling Ian. dedicated heart rate display. walkthrough design. ~rmrests. wrap-around seat adjust. age-friendly. oversize lont on display ENTERTAINMENT: Pre-wired for S Series entertainment system which includes 15" LCD screen. NTSC/ATSC digital tuner or PAL/SECAM tuner. coaxial ceble connector at base. integrated control keypad. and headphone jack WARRANTY: Ught Commercial warranty for ali non dues paying facilities 3 years parts/labor C2012 StarTrac:AIl right reBerved. StarTrac. the StarTrac logo, and Dynamic Heart Rate Control era registered trademarks of Core Indu~tries. Polar is e registered trademark of Polar Electro, Inc. LEGS Each rowing stroke involves full compression and extension of the legs. working the calves. thighs. hamstrings. buttocks and hips Join the Rowing Community -.--------------.. - CORE Rowing is a great way to work your abdominal and back muscles. A strong core supports a stronger back and belter posture. UPPER BODY Rowing will strengthen and tone your upper body. Shoulders. back and arms are all involved in the rowing stroke. HEART AND LUNGS Because It engages so many muscle groups simultaneously. rowing puts a healthy demand on the cardiovascular system. resulting in improved fitness. The fitness benefits attract people to rowing; the camaraderie and sense of community keep them rowing. Visit concept2.com to join the online rowing community: • Track your training in the Online Logbook. Participate in an online challenge as an Individual oras part of a team. • Rank your best workouts against others. • Sign up for our Workout of The Day (WOOl emails. '_ .. -.------'''----'-" -----•. ----------~. convenience. ohrairiing indoors. "Aln". 1<nIPO'" you will g'et the'same great Workout. The dependable performance of the Model D Indoor Rower has made it our best selling machine. Recognized by athletes as the standard for indoor rowing, the Model D is a solid piece of exercise equipment offered at a great value. Available in black (shownl and light gray. Aluminum rail capped with a stainless-steel track allows the seat to move smoothly and facilitates full leg involvement in the rowing stroke PM5 Performance Monitor ___ ..... Adjustable monitor arm Low·maintenance, nickel plated chain Ergonomic handle allows for natural arm and hand positions I Frame lock enables easy separation for transport and storage Spiral damper controls airflow to the flywheel. allowing users to choose the feel of the stroke Caster wheels make it mobile Separates easily into two parts for storage. Length I Width, ,seat Height ,Weight, Space Required For Use I Stored Dimensions .96" 1;4" .14" 57 IbS' x 4' r 25" x 33" x 54" H I Monitor I Weight Capaoity PM5 -r 500lb . '.,., The Model E Indoor Rower offers presence and durability with its 20 inch frame height and powder coat with glossy finish. From a practical standpoint, the higher frame means easier on-and-off for those with tired knees or mobility considerations. One-piece leg design for both the front and rear legs results in stability and a sure. solid feel. A fully enclosed chain housing keeps the nickel plated chain clean. The Model E includes allthe proven features of the Model D plus those listed here. Available in light gray (shown) and black. One·piece leg design for solid look and feel Separates easily into two parts for storage, The frame is 6" higher. positioning tf19 seat at a comfortable 20" height Len~h ! Widtt.1 Seot Height !Weil!ht I Space Required For Uoe 96" ,24" 20" 651b I . g' "4' Longer monitor arm brings ,/the PM5 closer 10 you /" High gloss, powder· coated frame protects against scratches Stored Dimensions __ I Monitor _ I Weight capacity 27" x 47" x 54" H PM5 1 500 Ib . ----------------- Adjustable feet for leveling . . ..... • The Dynamic.lndoc)r Rower offers' an even clo.sElr simulation to rowi'ngon the water. Unlike the Model 0 and E Indoor Rowers, the'foot~est Of! the Dynamic is free to move and there's minimal movement of body mass throughout the stroke. The Dynamic demands similar concentration and body control to that needed when rowing in a boat, making it an excellent sport-specific training and coaching tool for the competitive rowing athlete. Optional Wind Shield lincludedl can be used to deflect breeze Caster wheels make it mobile Length.1 WIdth . Seat Height Space Required 1:01' Use Stored Dimensions .Welght Capacity 76" .. 24"25:'. .21.5" .7.S·x4· 76".x24,25.".X21.5·:H· 500·lb ...... , ....... ; ...•.... r." ;;: .. -'.: . .... : : ..... -........ PM5 (standard onallm~dels)· Features: . Automatic Operation Monitor turns on wheriyoustart your workout. Performance Data Track distance; speed, pace,calories burned; and watts. . . . User-Friendly Menu Manage a wide range offeatu·res such as preset workouts, games, and multiple language·s: . . Display Options Viewalt data, force curve,pace boat, bar chart, or large print. Backlit DisplayScreen illuminates automatically when you . start your workout. . .... -. . USB Flash Drive Store perforr'rian~e data and/or transfer· data to your Mac or PC. WirelessHeartRate Monitoring using ANT+ andBluetooth. Smart with compatible devices.. .. . . . Connectivity Supports milGhine-to-machine racing, plus connectivity to computers and smartphories . . ~ ·OBluetoothO -.. SMARI. " SSafeware' Product Protection Fitness Protection Plan Manufacturer warranties are limited in both term and coverage. With a Safeware Protection Plan, you'll have Peace of Mind that all of your equipment has the best coverage available. Prepare for the unexpected. Parts costs, trip charges, and labor fees can really add up. Save yourself money and hassles with a Protection Plan. No matter what your fitness needs are ... We've got you covered. Safeware Protection Plans offer coverage on treadmills, ellipcticals, bikes, home gyms and more. On-site service you can rely on. Get repairs on motors, decks, belts, wheels, displays, frames, pulleys, drives, and more. Various protection programs available. Get exactly the type of term and coverage that you want. Ask a sales associate for more details. t{iJNAUT'LUS. NAUTILUSCOMMERCIAL.COM 1.888.678.2476 t{iJNAUT'LUS. NAUTILUSCOMMERCIAL.COM 1.888.678.2476 PURCHASE 1 XPLOAD ZONE PACKAGE & RECEIVE 1 DAY XPLOAD ZONE TRAINING PROGRAM WITH A MASTER TRAINER. PURCHASE 1 XPLOAD ZONE PACKAGE & RECEIVE 1 DAY XPLOAD ZONE TRAINING PROGRAM WITH A MASTER TRAINER. LU CI) :2 ~ CI) => LL c: ~ 0 2: W LU Z 0 :2 CI) C2 ~ CI) => LL I-" c: rn I-0 2: 0.. LU i5 LU ...J co 5 LU 3i: ...J 0 co i$ c: rn 3i: ;::) 2: 0 2: J 3i: ...J ...J C ~ 0 LU <C 0 (!) ~ ~ ~ 0 ...J 2: 3i: ...J ...J Z I-" .....I ;::) CI) en c: => 0.. ~ 0.. ~ LU 0.. ...J ;::) 3i: :§ ~ ~ g w 0 W (\') c: LL LL. W ...J co 5 w 3i: ...J 0 ~ c: rn 3i: ~ 2: 0 ...., 3i: ....I 2: ...J C ~ 0 LU <C 0 (!) !cc ~ 0 ....I 3: ...J 2: 3!: ...J ;::) Z t) ...J rn a:. ;::) 0.. ~ 0.. c: W 0.. .....I ;::) a3 3i: 5 <C l-0 ::l ....I w ...J I-0 LU ;::) (\') c: 0.. LL. LL DUAL ADJUSTABLE PULLEY ............. 4 ............................................................................................................................................ . STACK WEIGHT SHIP WEIGHT 2 x 440 Ibs (2 ,,200 kg) 1.4391bs (552.7 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for lIpl,olstery and frame. HARMONY .................................... StarTrac Silver Frame LEGACY .................................. 0 White Frame eZ014 StarTrac. All rights reserved. StarTrac. the Star Tree foge and Inspiration Strength are registered trademarks of Core Industries •. LLC. Lod;: N Load is a registered trademark of Innovation Strength Technology. UC. Model I P-D9302 o Unlimited high-low cable positioning combinations • All steel adjustable pulleys with single hand adjustment design o lock N load:!) weight selection system e Integrated pull up bar with multi-grip hand pOSitioning o 4 to 1 lifting ratio for smooth low 'Inertia operation o Extended cable travel for a variety of exercises .. Fixed footprint for optimal floor planning and placement o 5 Ib (user) increments (actual) stack weight 440 Ibs / increments 20 Ibs o Intuitive exercise placards featuring 12 targeted movements WIDTH LENGTH HEIGHT 62' 1157 eml 46" il17 cm} 91" (231 cm) WARRANTY: Limited '10 year vvananty on structural frame not Including coatings, 5 years parts on major nlechanical components -guide rods, plates, bearings etc, 1 year on minor mechanical components -plate switches, cables, grips etc., 6 months on uphoJstery, 1 year labor ·Vlfarranties are subject to change and may vary Internationally 'Contact your StarTrac Sales Representative for full commercial, light commercial and consumer w,manty detail ./ INSPIRATION STRENGTH" I ADJUSTABLE ABDOMINAL DECLINE BENCH ••••••••••••••••••••••••• • •••••••••• 0 ................................................... . SHIP WEIGHT 79 Ibs 136 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame SLATE I SILVER Slate Upholstery Star Trac Silver Frame WIDTH 25' 164 cm) C2014 SlarTrec. AU rights reserved. StBfTrac, the StarTrac logo and Instinct are regIStered trademarks of Core Industries. LLC. Model IN-B7200 o Removable wear strap for extended upholstery life " Adjustable back pad for precise positioning o Fixed shin stabilization pads e Dual rollers ar.d hand gr:p for transport " Rubber feet for floor protection LENGTH HEIGHT 53"' (135 em) 34" (86 cm) WARRANTY Limited 10 year war;anty on structural frame nOt including coatmgs. 5 years parts on malor mechanical components -guide rods. plates. bearings etc. 1 year on m,nor mechanical components -plate sWitches. cables. grips etc .. 6 months on upholstery, 1 year labor 'Warrantles are sublect to change ant may vary internanonally 'Contact your Star IleC Sales Representative for ful! commercial. light commercial and conSlimer wafianty detail MULTI-ADJUSTABLE BENCH ................................................................................................... 0 SHIP WEIGHT 88 Ibs (40 kg) FEATURESANDS'PECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE I SILVER Slate Upholstery Star Trac Silver Frame WIDTH 27" (69 em) e2014 StarTrac. All rights rsserved. StarTrac. the SrsrTrac logo and Instinct are registered trademarks Of Core Industlias. LLC. Model IN-B7501 .. Removable wear strap for extended upholstery life Adjustable seat and back pads for precise positioning & Dual rollers and hand grip for transport Rubber feet for floor protection LENGTH HEIGHT 55" {140 em) 18" (46 em) WARRANTY: Limited 10 year warranty on structural frame not Including coatings. 5 years parts on major mechanical components -guide rods. plates, bearings etc, 1 year on m,nor mechanical components -plate switches, cables, grips etc, 6 months on upholstery, 1 year labor 'Warranties are subject to change and may vary internalionally 'Contact your Star Trac Sales Representative for full commercial, light commercial and consumer warranty detail O· ~n~9?n~(:l~9P" : l:J~CS3J U UlJ~~ W STACK WEIGHT SHIP WEIGHT 2351bs 1107 kg) 477 Ibs 1217 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE / SILVER Slate Upholstery Star Trae Silver Frame C2014 SlarTrac. All rights reserved. SwTrac. the S.arTrac logo and Instinct 81B registered trademarks of Core Industries. LLC.Lod< N Load is a registered lriIdemark of Innovation Strength Tecl"lf'lology. L: .. C. WIDTH 28" 171 em) CHEST PRESS Model IL-S2100 o Simple. !ntuitive placard o Removabie wear strap for extended upholstery life G Multi-position hand grips e Adjustable seat pad with "easy up"ratcheting adjustment o Rubber feet for floor protection .. Kevlar ;:ransmission belt for extended life and easy replacement o Featuring the patented Lock N Load® weight selection system LENGTH HEIGHT 55-1140 em) WAR RANTY Limited 10 year warranty on structural frame not Including coatings. 5 years parts on malor mechanical components -guide rods, plates, beanngs etc. 1 year on minor mechanical components -plate sWltches, cables, gnps etc., 6 mo~ths on upholstery, 1 year labor 'Warranties are subject to change and may vary Internationally 'Contact your Star Trac Sales Representat'lve for full commercia!. light commercial and consumer warranty detail .. . STACK'WEIGHT . SHIP WEIGin 190 Ibs 186 kg) 460 Ibs 1209 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE I SILVER Slate Upholstery StarT rae Silver Frame C2014 StarTrac. All rights reserved. SterTrac, the SwTrac logo and Instinct ere rsgislared trademarks of Core Industries, LLC.Loc:k: N Load is a (egi8tarad trademark of Innovation Strength TechnologV. LlC. SHOULDER PRESS WIDTH 53' (135 cm) Model IL-S4100 .. Simple. intuitive placard .. Removable wear strap for extended upholstery life • Multi-position hand grips o Adjustable seat pad with "easy up" ratcheting adjustment o Rubber feet for floor protection o Kevlar transmission belt for extended life and easy replacement o Featuring the patented Lock N Load;!> weight selection system LENGTH HEIGHT 5B" 1147 cml 55" 1140 eml WARRANTY: limited 10 year warranty on structural frame not including coatings. 5 years parts on major mechanical components -guide rods, plates. bearings etc. 1 year on minor mechanical components -plate switches, cables, grips etc, 6 months on upl10lstery. 1 year labor 'Warranties are subject to change and may vary internationally • Contact your StarTrac Sales Representative for full conlmercial, light commercial and consumer warranty detail O· ~Q~c;pn~D~9& . lJ~~ U lJU~~ U STACK WEIGHT SHIP WEIGHT 235 Ibs 1107 kg) 460 Ibs (209 k~: FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame, SLATE I SILVER Slate Upholstery StarTrac Silver Frame =2014 StorTrac. All nghts r889tV8d. StatTrac. the StarTrac logo end InstinCt are reCiStered ttsdem&rk$ of Core Industries. llC.Lock N Lead is a registe'ed traderNJril; of IranovatlOr. Strength Technology. LLC VERTICAL ROW WIDTH 46-(~17cm) Model IL-S3320 .. Simple, intuitive placard Removable wear strap for extended upholstery life o Adjustable seat with "easy up" ratcheting adjustment o Adjustable chest pad with "easy out" ratcheting adjustment Q Multi-position hand grips o Rubber feet for floor protection ~ Kevlar transmission belt for extended life and easy replacement .. Featuring the patented Lock N Load® weight selection system LENGTH HEIGHT 48" (122 em) 55" 1140 em) WARRANTY Limited 10 year warranty on struclUral frame not Including coatings. 5 years parts on malor mechanical components -gUide rods. plates. bearings etc. 1 yeal' on minor mechanical components -plate switches. cables. grips etc .. 6 months on upholstery. 1 year labor 'Warranties are subject to change and may vary internationally • Contac, your Star Trac Sales Representative for full commercial. light commercial and ccnsumer warranlY detail STACK WEIGHT . SHIP WEIGHT 190 Ibs 186 kg) 436 Ibs 1198 kg] fEATURES ANO SPECII'ICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE I SILVER Slate Upholstery StarT rae Silver Frame O2OT4 StarTrac. All rights raservad. starTrac. the StarTrac logo and Instinct ara registered tredemarks of Core Industries. UC.Lod< N Load 10 • (eg;swad _mark Df Innovation Strangth Technology. LLC. LEG EXTENSION WIPTH 37" 194 cm) Model IL-S1010 • Simple, intuitive placard • Removable wear strap for extended upholstery life o Adjustable seat back with "easy up" ratcheting adjustment • Adjustable lower leg/ankle pad for precise fit o Rubber feet for floor protection • Kevlar transmission belt for extended life and easy replacement • Featuring the patented Lock N loadS> weight selection system lENGTH ·HEIGHT 41· 1104 cm) 55-(140 cml WARRAN1Y: Limited 10 year warranty on structural frame not including coatings. 5 years parts on maior mechanical components -guide rods. plates. bearings etc. 1 year on minor mechanical components -plate switches. cables. grips etc., 6 months on upholstery, 1 year labor 'Warranties are subject to change and may vary internationally 'Contact your StarTrac Sales Representative for fuJi commercial, light commercial and consumer warranty detail I I I· I , STACK WEIGHT SHIP WEIGHT 190 Ibs 186 kg} 469 Ibs 1213 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholslery and frame. SLATE I SILVER Slate Upholstery StarTrac Silver Frame @2014 StarTrac. All rights resel'lJed. StarTrac. the StarTrac logo and Instinct ere registered trademarks of Core Industries, LLC.l.ock N load is s registered trademark of Innovation Strength Technology, LLC. WIDTH 3r 194 em) LEG CURL Model IL-S1011 o Simple, intuitive placard Removable wear strap for extended upholstery life Adjustable seat back with "easy up" ratcheting adjustment e Adjustable lower leg/ankle pad for precise fit e Adjustable thigh support stabilization pad .. Rubber feet for floor protection o Kevlar transmission belt for extended liTe and easy replacement .. Featuring the patented Lock N Load~ weight selection system LENGTH HEIGHT 56" 1142 em) 55-(140 em) VVARRANTY. Limited iO year warranty on structural frame not including coatings, 5 ye8rs parts on malor mechanical componen{s -gUide rods, plates, bearrngs etc, 1 year on minor mechanical components -plate switches, cables, gnps etc., 6 momllS on upholslery, 1 yea' labor 'Warrantles are subject 10 change and may vary Internationally 'Contact your StarTrac Saies Representative for iull commercial. irght comrlerCla! and consumer warranty detail DUAL PECTORAL FLYj REAR DELTOID .................. 0 ............................ 0 ., ••• 0 ••• 0· ••••••••••••••••••• 0 •••• ·.0 ••••••••• 0 •••••• •• ........................ . STACK WEIGHT SHIP WEIGHT 190 Ibs 186 kg) 473 Ibs (215 kg) FEATURES AND SPECIRCATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE / SILVER Slate Upholstery StarTrac Silver Frame eZ014 StarTrac. All rights res:ervad. Star Tntc. tile SlarTrac logo end Instinct are registered trademarks of Core Inclustlies. LLC.Lock N Load is. e registered trademark ollnnOViltlon Strength Technology, LLC. Mode11L-D2110 .. Simple, Intuitive placard .. Removable wear strap for extended upholstery life e Multi-position hand grips .. Adjustable seat with "easy up" ratcheting adjustment e Dual exercise option range of motion control: Pectoral Fly and Rear Deltoid o Rubber feet for floor protection .. Featuring the patented Lock N Load'!! weight selection system WIDTH LENGTH . HEIGHT SO" (127 cm) 54" !137cml 79" (201 cm) WARRAN1Y Limited 10 year warranty on structural frame not inciuding coatings, 5 years parts on major mechanical components -guide rods, plates, bearings etc, 1 year on minor mechanical components -plate switches, cables, grips etc .. 6 months on upholstery, 1 year labor 'Warranties are subject to change and may vary internationally 'Contact your Star Trac Sales Representative for full commercial, light commercial and consumer warranty detail STACK WEIGHT SHIP WEIGHT 190 Ibs 186 kg) 423 Ibs {192 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE I SILVER Slate Upholstery Star Trae Silver Frame 02014 StarTrac. All rightS reserved. Star Trac. the StarTrac logo and Instinct ara registared trademarks of Cora Industries, LLC.L.ocIc N L.oa~ is a registered tcadamark of Innovation StrengthTechnologv. LLC. TRICEPS PRESS II .................................................. . WIDTH 61" 1155 cm) Model I L-S5130 o Simple. intuitive placard • Adjustable shoulder stabilization pads .. Removable wear strap for extended upholstery life o Multi-position "flip over" hand gflps .. Adjustable seat with "easy up" ratcheting adjustment o Foot roller pads for stabilization o Rubber feet for floor protection • Kevlar transmission belt for extended life and easy replacement .. Featuring the patented Lock N Load® weight selection system LENGTH HEIGHT 44" 1112 em) 55" 1140 cm) WARRANTY. Limited 10 year warranty on structural frame not Including coatings, 5 years parts on major mechanical components -guide rods, plates, bearings etc, 1 year on minor meclnanical components -plate sWitches, cables, grips etc" 6 months on upholstery, 1 year labor 'Warranties are subject to change and may vary internationally 'Contact your Star Trae Sales Representative for full commercial, light commercial and consumer warranty detail . STACK WEIGI-iT SHIP WEIGHT 235 Ibs (107 kg) 554 Ibs (252 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE I SILVER Slate Upholstery StarTrac Silver Frame 02014 StarTtac. All rights reserved. SterTti!lC. the SlarTmc logo and Instinct are registered tr8damarts of Core Industries.lLC.Lock N Load is 8 registsredtractemark a Innovation Strength Technology. LLC. LAT PULL DOWN ••••• 0 •••••••• II ••••• II .,. 0 ••• II .... II •• , ......... II •••• II WIDTH 47" 1119 cm) Model IL-S3310 e Simple. intuitive placard e Removable wear strap for extended upholstery life .. Adjustable seat with "easy up" ratcheting adjustment 8 Adjustable thigh support stabilization pad .. Rubber feet for floor protection ,. Kevlar transmission belt for extended life and easy replacement .. Multi-position hand grips .. Featuring the patented Lock N Load® weight selection system LENGTH: • HEIGHT 60" [152 em) 73" 1185 em) WARRANTY: Limited 10 year warranty on structural frame not including coatings. 5 years pans on major mechanical components -guide rods, plates. bearings etc, 1 year on minor mechanical components -plate switches, cables. grips etc., 6 months on upholstery. 1 year labor • Warranties are subject to change and may vary internationally 'Contact your Star Trac Sales Representative for full commercial, light commercial and consumer warranty detail DUAL INNER/ OUTER THIGH ........... eo ................................................................................ .. STACK WEIGHT SHIP WEIGHT 150 Ibs {68 kg) 498 Ibs {226 kg; FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE I SILVER Slate Upholstery StarTrac Silver Frame 102014 StarTrac. All rights T888rved. StsrTrac, the SterTrec logo and Instinct <lre regIstered trademarks of Core Industries.lLC.Loc:k N Load is a registar&d trademark of IrtrI()II81ion Strength Technology. LlC. WIDTH 27' 169 em) Mode11L-D1015 o Simple, intuitive placard e Removable wear strap for extended upholstery life .. Walk-through entry design o Modesty weight stack in front of user o Swiveling thigh pads and range of motion control allow for dual exercises: Abductor and Adductor o Rubber feet for floor protection o Kevlar transmission belt for extended life and easy replacement o Featuring the patented Lock N Load'" weight selection system LENGTH HEIGHT 57" (i45 em) 55-(140 em) WAR RANTY: Limiteo 10 year warranty on structural frame not including coatings, 5 years parts on malar mechanical components -guide rods, plates. bearings etc, 1 year on minor mechanical components -plate switches. cables, gnps etc" 6 months on upholstery, 1 year labor 'Warrant,es are s<Jb,ect to change and may vary internationally • Contact your Star Trae Sales Representative for full commerCial, light commercia! and consumer warranty detail I STACKWEIGHT SHIP WEIGHT 120 Ibs (55 kg) 3541bs 1161 kg) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upnolstery and frame. SLATE I SILVER Slate Upholstery StarTrac Silver Frame C2014 SterTrac. All rightS reserved. StarT rae. the StarTrac logo end Instinct ate regiStered trademarks of Core Industries. UC.LocIc: N Load is a registered tf8demark of Innovation SU8nIJth Technology, LlC. WIDTH 37" 194 cm) GLUTE PRESS Mode11L-S1012 .. Simple, intuitive placard .. Removable wear strap for extended upholstery life " Adjustable "flip over" foot platform .. Standing modality .. Unear glute pressing mot'lon .. Rubber feet for floor protection " Kevlar transmission belt for extended life and easy replacement o Featuring the patented Lock N Load® weight selection system LENGTH· HEIGHT 6r 1170 em) 55' {140 cm) WARRANTY: limited 10 year warranty on structural frame not including coatings, 5 years parts on major mechanical components -guide rods, plates, bearings etc, 1 year on minor mechanical components -plate switches. cables, grips etc .. 6 months on upholstery, 1 year labor 'Warrant,es are subject 10 change and may vary Internationally • Contact your Star Trac Sales Representative for full commercial. light commercial and consumer warranty detail OVERALL WEIGHT WIDTH 530 Ibs 1240.4 kg) 50S (128.3 em) FEATURES·AND·S·PECIFICATiONS AVAILABLE COLORS Options for upholstery and frame. HARMONY BlaCk Upholstery StarTrac Silver Frame LEGACY Brown Upholstery o White Frame 02012 StarTrac. AU rights teServed. StarTrac. the Starl'rlc logo and Leverage ilre registered trademarks of eo ... Industries. . INCLINE PRESS Model I P-L2003 o Stainless steel knurled grip e Max capacity 270 Ibs (123 kg) per arm e Starting resistance 151bs (6.8 kg) per arm • Unilateral independent arm motion e Converging motion with user pre-stretch adjustment for optimal start position o Intuitive touch points & user friendly gas shock assisted seat adjust D One of a kind lever and cam system for optimum biomechanics o Low load points for safe and simple use o Integrated plate storage o Weight plates sold separately LENGTH ·HEIGHT 759" (193 em) 51.3" (1305 em) WARRANTY: Star Trac warrants all framework for a period of 10 years. This lirrllted warranty 011 structural frame does n01 include coatings. The follOWing moving parts are warranted for 5 years: rotary bearings. weight stacks, pulleys. guide rods, and structural moving parts. 90 days on upholstery stitching and items not specified . • Additional reslflctlons may apply; see your sales representative for detailed warranty information. 'Warranty is subjeCt to change. LEVEilAGE· . . . OVERALl, WEIGHT . WIDTH. 550 Ibs (249.4 kg) 50.5 -{128.3 cml .. FE!tTURES AN" SPEciFICATIONS AVAILABLE COLORS Options for upholstery and frame. HARMONY Black Upholstery Star Trac Silver Frame LEGACY Brown Upholstery o White Frame 02012 StarTrac. AlllightB reserved. S18rTrac. the StarTrac logo and Leverage are registered trademarks af Core Industries. LOW ROW Model I P -L3004 ,. Stainless steel knurled grip " Max capacity 270 Ibs (123 kg) per arm • Starting resistance 181bs (8.1 kg) per arm It Unilateral independent arm motion ,. Diverging motion with close grip start position ,. Intuitive touch points & user friendly gas shock assisted seat adjust e One of a kind lever and cam system for optimum biomechanics .. Low load points for safe and simple use .. Integrated plate storage o Adjustable chest pad for optimal pre-stretch ,. Weight plates sold separately LENGTH HEIGHT· 78.5" (199.5 em) 46" 1117 cml WARRANTY: Star Trac warrants all framework for a period of 10 years. This limited warranty on structural frame does not include coatings Tile following moving parts are warranted for 5 years: rotary bearings, weight stacks, pulleys, guide rods, and structural moving parts. 90 days on upholstery stitching and items not specified . • Additional restrictions may apply; see your sales representative for detailed warranty information. 'Warranty is subject to change. LEVEilAGE· SHIP WEIGHT WIDTH 566 Ibs 1257 kg) 72-1182.8 eml FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. HARMONY Black Upholstery StarTrac Silver Frame LEGACY Brown Upholstery o White Frame 02012 SterTrac. All ngllts reserwd. Star Tree aOO the StarTtac lOgo are reg'lstered trademarks of Core Industries. ANGLED LEG PRESS ModeiIP-L 1140 o Adjustable angle for back support c I ntegrated plate storage .. Two start options for range of motion o Easy to reach and operate safety stops e Integrated user handle for safe entry and exit .. Integrated OlympIc plate storage .. Rubber feet for fioor protection LENGTH HEIGHT S9T 12278 em! 58-11473 eml WARRANTY Star Trac warrants all framework for a penod of 10 years. This limited warranty on structural frame does not Include coatings. The fOllowing moving paris are warranted for 5 years; rotary bearings. weight stacks, pulleys. guide rods, and structural moving parts 90 days on upholstery stitching and Items not specified 'Additional restrictlDns may apply; see your sales representative lor detailed warranty Inimmation 'Warranty is subiect to change SHIP WEIGHT WIDTH 680 Ibs (309 kg) 89" (226 em) FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for frame. HARMONY ..................... , ............ ,. StarTrac Silver Frame LEGACY ................. 6 ... " ~ ....... 6 ................... 0 White Frame SMITH MACHINE ....... a .................................................................................................... .. Mode11P-L8500 o Rotating Olympic handle insures easy release and reset of bar with each set e Enhanced biomechanics with the 7 degree angle for squatting and pressing motions • Counterbalanced Olympic bar with 151b (6.8 kg) take off weight for all user levels • Adjustable red safety catches to insure proper execution of all exercises • Open front design allows for use of any portable benches • Six marked weight storage pegs per side to accommodate all plate increments • Rubber feet for floor protection LENGTH HEIGHT 67" i170.1 em) 82-1208.2 cml WARRANTY: Umited 10 year warranty on structural frame not including coatings. 5 years parts on major mechanical components -guide rods. plates. bearings etc. 1 year on minor mechanical components -plate switches, cables, grips etc., 6 months on upholstery, 1 year labor 'Warranties are subject to change and may vary internationally 'Contact YOllr Starli'ac Sales Representative for full commercial, light commercial and consumer warranty detail 02014 StarTrac. All rights .... rvad. StarTrac and the StarTrae togo are registered trademarks of Core Industria., LLC. ,!J4!;ii;Wi DUMBBELL RACK (10-PAIR/3-TIER) ••••••••••••••• II ................................................................................................. . SH1PWEIGHT 272 Ibs 1124 kg! FEATURES AND SPECIFICATIONS AVAILABLE COLORS Options for upholstery and frame. SLATE I SILVER Slate Upholstery Star Trac Silver Frame WIDTH 29" 174 cm) @2014 StarTrac. AU rights reserved. SterTrac. the StarTrilc logo and Instinct lire registerea trademarks of Core Industries, lLC. Model IN-RB002 o Compact footprint ~ Rubber dumbbell saddles .. Rubber feet for floor protection LENGTH HEIGHT 87"" 1221 eml 50-1127 cm} WARRANTY: Limited 10 year warranty on structllfal frame not Including cOdlings, 5 years parts on major mechanical components -gUide rods, plates, bearings eTC, 1 year on minor mechanical components -plate switches, cables, grips etc, 6 months on upholstery, 1 year labor 'Warrantles are subject to change and may vary imernationally • Contact your Star Trac Sales Representative for full commercial. light commerCial and consumer warranty detail r:J ~n~qpl;1 G0...n~c=;:?" U U~~ U lJW~~ U 0: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com Cardia STAR TRAC E-TR TREADMILL $7,495.00 $3,995.00 3 $11,985.00 ~ STAR TRAC S-CTx CROSSTRAINER $4,995.00 $3,095.00 2 $6,190;00 STAR TRAC S-RBx RECUMBENT BIKE $2,895.00 $2,095.00 2 $4,190.00 It • CONCEPT 2 MODEL D INDOOR ROWER $1,195.00 $995.00 1 $995.00 '. '"R .~ : . '. ~~: . .-: Subtotal $23,360.00 Strength til NAUTILUS XPlODE ZONE-(1) 5' TRUSS, (1) END FRAME, AND $1,947.00 $1,650.00 1 $1,650.00 (1) F3TOWER NAUTILUS XPLODE ZONE-ACCESSORIES INCLUDE DIP $849.00 $795.00 1 $795.00 :.~=-' STATION, PULL UP BAR, AND LAND MINE. ""'>. • STARTRAC INSTINCT ADJUSTABLE ABDOMINAL I DECLINE ~ $625.00 $554.00 1 $554.00 STAR TRAC INSTINCT MULTI-ADJUSTABLE BENCH $775.00 ~ $662.00 1 $662.00 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 1 of 10 0: (56!) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com Strength ~,~'~i:>~criPtion . " '. 'r. :'-";:.,, '~ ;:. ~::·'~At'):~h;;>'t,· ·:;:::,;j;:;~¥~ .. ,~r'i~~' List Prrce .~U~~UI,,','.".\P~~> ,': ,Ii.t~:t~,;;i;i"i<.;,,:;-. .. .. , STAR TRAC INSTINCT LNL CHEST PRESS $2,875.00 $2,231.00 1 $2,231.00 II ": .. ~- 1bf STAR TRAC INSTINCT LNL SHOULDER PRESS $2,875.00 $2,231.00 1 $2,231.00 d STAR TRAC INSTINCT LNL VERTICAL ROW $2,875.00 $2,231.00 1 $2,231.00 " STAR TRAC INSTINCT LNL LEG EXTENSION $2,875.00 $2,231.00 1 $2,231.00 " STAR TRAC INSTINCT LNL LEG CURL $2,875.00 $2,231.00 1 $2,231.00 (l STAR TRAC INSTINCT LNL PECTORAL FLY / REAR DELTOID $3,195.00 $2,577.00 1 $2,577.00 STAR TRAC INSTINCT LNL TRICEPS PRESS $2,875.00 $2,231.00 1 $2,231.00 b ~ > ftj STAR TRAC INSTINCT LNlLAT PULL DOWN $2,875.00 $2,231.00 1 $2,231.00 Ai STAR TRAC INSTINCT lNLINNER / OUTER THIGH $3,195.00 $2,577.00 1 $2,577.00 STAR TRAC INSTINCT LNLGLUTE PRE'55 $2,875.00 $2,231.00 1 $2,231.00 L .. ~ i ' .. 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 2 of 10 Strength ~ .. ~ • ft ~ &\- Accessories I 0: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com .. ... . . . . STAR TRAC LEVERAGE INCLINE PRESS STAR TRAC LEVERAGE ROW STAR TRAC LEVERAGE ANGLED LEG PRESS PLATE STAR TRAC LEVERAGE BICEPS CURL STAR TRAC LEVERAGE SMITH MACHINE STAR TRAC INSTINCT DUMBBELL RACK, 3 TIER Subtotal TROY PREMIUM RUBBER MEDICINE BALLS + RACK, SET: 4 LB, 6 LB, 8lB,10 LB,12 LB, AND 15 LB BALL : J.jst $2,595.00 $2,595.00 $2,895.00 $2,595.00 $3,495.00 $675.00 .Ust Price. $379.00 $375.00 $2,450.00 1 $2,450.00 1 $2,450.00 1 $2,450.00 1 $2,695.00 2 $675.00 1 $269.00 3 $370.00 1 . ,':' , $2,450.00 $2,450.00 $2,450.00 $2,450.00 $5,390.00 $675.00 $42,528.00 $807.00 $370.00 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 3 of 10 Accessories -- ~. ~q> '--'--Q Flooring Services " . FITNESSMITH -'IHI· 0: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com BODY SPORT EXERCISE MAT WITH EYELETS (56" x 24" x 1/2"), BLACK LIFE FITNESS DOUBLE CORD RESISTANCE BAND, MEDIUM RESISTANCE LIFE FITNESS RESISTANCE TUBE, MEDIUM RESISTANCE Subtotal 8MM ROlLED RUBBER IN BASIC BLACK OR UP TO 10% COLOR FLECK, BASIC COLOR OPTIONS AVAILABLE FLOORING ADHESIVE, 4 GALLON BUCKET INSTALLATION: REMOVAL OF EXISTING FLOOR AND GLUE DOWN INSTALLATION OF NEW flOOR INCLUDED. ADDITIONAL FEES WILL APPLY TO REPAIR OR FLOAT EXISTING FLOOR IF NEEDED. Subtotal SHIPPING -EQUIPMENT EQUIPMENT INSTALLATION: ASSEMBLY, TESTING, INSIDE DELIVERY, SET-UP AND TRASH REMOVAL INCLUDED. Ust $19.95 $28.95 $12.50 list $2.79 $179.00 $4.50 $7,500.00 $6,500.00 $16.50 3 $28.95 2 $12.50 2 $2.39 2600 $159.00 7 $3.50 2600 $6,995.00 1 $6,500.00 1 $49.50 $57.90 $25.00 1 •• ";- $1,309.40 $6,214.00 $1,113.00 $9,100.00 $16,427.00 $6,995.00 $6,500.00 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 4 of 10 0: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com Services Warranty FITNESSMITH QUARTERLY PREVENTATIVE MAINTENANCE PLAN INCLUDES 4 PREVENTATIVE MAINTENANCE VISITS PER YEAR. IF ADDITIONAL SERVICE VISITS ARE NEEDED, OUR PLAN FEATURES REDUCED TRIP FEES OF $25 PER VISIT AND $50 PER HOUR FEE FOR LABOR. FITNESSMITH VALUE ADD FOR CITY OF SOUTH MIAMI -12 QUARTERLY VISITS (4 VISITS FOR 3 YEARS), FEE WAIVED Subtotal 48 MONTH EXTENDED PARTS + LABOR WARRANTY ON STAR TRAC TREADMILLS + ELLIPTICALS. 48 MONTH EXTENDED PARTS AND LABOR WARRANTY ON STAR TRAC RECUMBENT BIKES. Subtotal Trade in Allowance TRADE IN EQUIPMENT Subtotal $500.00 ($500.00) $406.40 $379.20 Total savings: $32,533.35 $300.00 12 ($300.00) 12 $406.40 5 $379.20 2 $3,600.00 ($3,600.00) $13,495.00 $2,032.00 $758.40 $2,790.40 ($4,050.00) 3610 Quantum Blvd I Boynton Beach, FL 33426 Page S of 10 o: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com Prepared for: GIBSON-BETHEL COMMUNITY CENTER GENERAL MANAGER 5800 SW66TH STREET SOUTH MIAMI, FL 33143 PARKS@SOUTHMIAMIFLGOV (305) 668-3876 Proposal Summary Cardio Strength Accessories Flooring Services Warranty Trade in Allowance Total Prepared by: Fitnessmith Michael Scichilone Fax (561) 997-8788 Michael@fitnessmith.com Payment Is 50% down at time of order, 40% prior to delivery and 10% upon install. Details: Proposal#:000723 Version: 1 Delivered: 03/29/2016 Expires: 05/10/2016 $23,360.00 $42,528.00 $1,309.40 $16,427.00 $13,495.00 $2,790.40 ($4,050.00) $95,859.80 0: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com AGREEMENT: The product quotation, purchase orders, shipping documents and these terms and conditions of sale c:onstitutes a continuing sale Agreement between Centurion Partners Health and Fitness, a Florida Limited Liability Company doing business as Fitnessmith (hereafter referred to as ("Fitnessmith") and Buyer, as set forth at the end of this Product Quotation Agreement, for the purchase of any product and services to be provided by Fitnessmith to Buyer. Fitnessmith sales representatives do not have the authority to change or modify the terms and conditions of this Agreement. PURCHASE ORDER: Buyer may provide Buyer's standard form of purchase order to place orders for product and service, but any terms and conditions on such standard form which are in addition to or inconsistent with the terms and conditions of this Agreement will be deemed stricken from such order. If Buyer does not deliver written objection to the terms hereof which are different than those appearing on the Buyer's purchase order, Buyer agrees to all of Fitnessmith's terms and conditions. All purchase orders shall be made or confirmed in writing and are subject to acceptance by Fitnessmith. The Buyer shall be responsible for all costs and fees incurred by Fitnessmith for refused shipments, including freight and insurance costs. Orders cancelled less than thirty (30) days from originally scheduled shipment date will be subject to a cancellation fee of 25% of the value of the purchase order. PRICES: The prices to be paid by Buyer for all products and services purchased hereunder shall be Fitnessmith's standard prices in effect on the date of Fitnessmith's receipt of Buyer's purchase order, less any applicable deductions which may be in effect from time to time. Fitnessmith reserves the right to change its standard prices and to publish a new price list from time to time and at any time, without prior notice to Buyer. Should any new price result in an increase in the price of any product or services, the increased price shall apply to any Buyer order placed after the effective date of the new price. For orders that are placed for delivery more than ninety (90) days into the future, Fitnessmith reserves the right to review and adjust the agreed upon pricing within thirty (30) days of fulfilling the purchase order. In this case, the Buyer has the option of canceling the order with no penalties, if the cancellation is in writing and within ten (10) days of the notification of the price increase. Buyer is solely responsible for any prices it charges to its customer. Nothing in this Agreement shall in any way restrict the Buyer's freedom to sell products at prices determined in accordance with its own judgment. Buyer shall be responsible for all sales, use, or other taxes (other than taxes on Fitnessmith's income or ownership of property), applicable to Buyer's purchase of products and/or services. Buyer shall pay such taxes when invoiced by Fitnessmith or shall supply appropriate tax exemption or resale certificates. Buyer is also responsible for any domestic or foreign forwarding agent or brokerage fees, duties, or other fees and any export licenses which may be necessary to export the products. Seller reserves the right to correct any clerical or mathematical errors at any time. CUSTOM PRODUCT: Fitnessmith requires a non-refundable 50% down payment for all custom products. A purchase order for custom product contractually obligates the Buyer to take delivery. Custom orders are non-cancelable and may not be rescheduled without the prior approval of a corporate officer of Fitnessmith, which may be withheld at the sole and absolute discretion of Fitnessmith. All custom orders have an up charge to be determined by Fitnessmith. All build to order strength orders cancelled less than thirty (30) days from the original scheduled delivery will be subject to a 25% cancellation tee. SHIPMENTS: F.O.B. shipping point shall be Fitnessmith warehouse unless otherwise specified. Risk of loss with respect to Fitnessmith products shall pass to Buyer at the time of delivery of the products to the carrier for shipment. The Buyer assumes all risk involved in the transportation and handling of the equipment or goods once it has left the Fitnessmith warehouse, including, but not limited to, damage during shipment. The Buyer is advised that inspection should be made of any eqUipment or goods before accepting delivery. Acceptance of delivery constitutes acceptance of goods. The Buyer must file its own claim for any type of damages directly with the carrier in the event of any loss or damage during transportation, and must make payment for any equipment of goods purchased from Fitnessmith regardless of any dispute the Buyer may have with any carrier or agents. Fitnessmith will attempt in good faith to ship on or before any scheduled shipment date. Buyer acknowledges that Fitnessmith may, from time to time, be subject to manufacturer production or shipping delays. In such event, Buyer agrees that Fitnessmith may, in its sole discretion, allocate distribution of Fitnessmith's products among its customers, notwithstanding the effect such allocation may have on Buyer's outstanding orders, and Fitnessmith will not be liable for any damage, however described or arising, for a good faith failure to fill any order or for delay in meeting a scheduled shipment date. Fitnessmith may provide reasonable notice to Buyer regarding any material 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 7 of 10 0: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com delay in shipment. Fitnessmith may make partial shipments of Buyer's orders. Such partial shipments shall be separately invoiced and paid for when received, without regard to subsequent shipments. Delay in shipment or delivery of any particular installation shall not alone relieve Buyer of its obligation to accept subsequent installations. Fitnessmith may provide reasonable notice to Buyer in the event of material delays in connection with partial shipment of an order. Fitnessmith will use its best efforts to deliver as specified, but in no event will Fitnessmith be liable for any damage, consequential or otherwise, arising from any failure of Fitnessmith to meet any delivery date. RETURNS: Any Custom Products and/or Customer modified Standard Products ordered from Fitnessmith are non-cancelable and/or non-returnable. Credit may be issued only on those items that are stock items of standard manufacture and in new, salable condition in the original packaging. Any such return shall be at the expense and risk of the Buyer and subject to a 25% restocking charge of the original purchase price. WARRANTY: EACH FITNESSMITH PRODUCT WILL CARRY ITS OWN LIMITED WARRANTY AS SET FORTH BY THE MANUFACTURE. SUCH WARRANTY WILL BE BUYER'S SOLE AND EXCLUSIVE REMEDY FOR ANY BREACH OF WARRANTY AND IS IN LIEU OF ALL OTHER WARRANTIES BY FITNESSMITH, EXPRESSED OR IMPLIED, INCLUDING CONSEQUENTIAL DAMAGES. INSTALLATION: At the time the order is placed, the Buyer will provide Fitnessmith with an installation date. Fitnessmith will make reasonable commercial efforts to install the product on or before the installation date. Product held more than 10 days after the installation date at the Buyer's request will be subject to a storage fee. Product held more than 30 days past the installation date at the Buyer's request will be subject to a 15% restocking fee as well as a storage fee. With the exception of Grand Openings, partial installations require the installed product to be paid per the terms of the invoice. PROPER USAGE: It is imperative that equipment is used properly as to avoid inJUry. Buyer agrees that equipment will not be used in any way other than as designed or intended by the manufacturer. specifically including, but not limited to the following: 1) Keep hands and feet clear of moving parts at all times. 2) Read all machine instructional placards and warnings and direct any questions to a qualified fitness professional prior to use. 3) All strength equipment MUST be secured (bolted and tightened) to a solid, level surface to ensure stabilization and eliminate rocking or tipping. As it pertains to treadmills, Buyer agrees that it is aware of electrical requirements relating to dedicated circuit and plug configurations; additional information can be found in the owner's manual. PAYMENT: Payment is 50% down at time of order, 40% prior to delivery and 10% upon install. All invoices not paid when due shall bear interest at 1.5% per month or the highest rate allowed by law until paid in full. Fitnessmith reserves the right to exercise any of its lawful remedies if Buyer does not make payment when due. Without limiting the proviSions of the immediately preceding sentence, Buyer's failure to pay any invoice for the products and/or services when due shall entitle Fitnessmith to delay installation of orders placed by Buyer and, at Fitnessmith's option, to cancel any pending orders placed by Buyer. Fitnessmith shall have the right to offset and deduct from any amounts due Buyer all sums owing from Buyer to Fitnessmith. To secure the payment and performance of all obligations due and owed by Buyer to Fitnessmith hereunder, Buyer hereby grants Fitnessmith a Uniform Commercial Code purchase money security interest in products purchased from Fitnessmith hereunder and proceeds there from. This Agreement constitutes a security agreement between Buyer, as debtor, and Fitnessmith, as secured party, under the Uniform CommerCial Code, and Fitnessmith has the rights and remedies of a secured party hereunder. Buyer hereby appoints Fitnessmith as its attorney in fact to execute such financing statements as may be required, from time to time, to perfect the security interest granted herein. Fitnessmith may, upon default from Buyer, require Buyer to assemble the products and make them legally available to Fitnessmith for repossession, including reasonable access to the facilities of Buyer, and Fitnessmith shall be entitled to all reasonable expenses of repossession, including reasonable attorney's fees incurred in connection therewith. There will be a $35.00 service charge for each returned check. TERMINATION: 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 8 of 10 0: (561) 529-5590 I F: (561) 997-8788 I W: www.fitnessmith.com Buyer may not terminate this Agreement except by giving Fitnessmith thirty (30) days prior written notice. Upon termination, Buyer will be obligated to pay Fitnessmith immediately any and aU outstanding balances as of the date of termination. MISCELLANEOUS: Delivery dates set forth in any sales order or any confirmation thereof shall be determined to be estimates only. Fitnessmith shall not be liable for delays in performance of any of its obligations under this Agreement if such failure is caused by the occurrence of any contingency beyond its reasonable control, including but not limited to acts of God, strikes and other industrial disturbances, failure of raw material vendors, terrorism, failure of transport, accidents, wars, riots, insurrections, or orders of government agencies. Performance shall be resumed as soon as possible after cessation of such cause. No failure or delay on the part of either party in exercising any right or remedy hereunder will operate as waiver thereof, nor will any or a single or partial exercise of any such right or remedy preclude any other or further exercise thereof of any other right or remedy. No provision of this Agreement may be waived except in a writing signed by the party granting such waiver. Except as speCified herein, all notices, communications and reports required or permitted pursuant to this Agreement shall be in writing, and the same shall be given and shall be deemed to be have been delivered and received on the date served, if personally delivered and three (3) days after mailing, if placed in the United States Mail, postage prepaid, certified mail addressed to the parties at the address set forth below or at such other addresses as may be specified hereafter in writing in accordance with this Section. Severability. In the event that anyone or more of the provisions or parts of any provision, contained in this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any aspect by a court of competent jurisdiction, the same shall not invalidate or otherwise affect any other provision hereof, and this Agreement shall be construed as if such invalid, illegal or unenforceable provision, or part of any provision, had never been contained herein. Applicable Law; Personal Jurisdiction; Venue, This Agreement shall be construed in accordance with. and ali disputes hereunder shall be governed by, the laws of the State of Florida. All parties to this Agreement agree to submit to personal jurisdiction in the County of Palm Beach, State of Florida, United States of America. Any dispute that arises under or relates to this Agreement (whether contract, tort or both) shall be resolved in the applicable Federal or state court in the County of Boynton Beach, State of Florida, United States of America. Section Headings. The section headings contained herein are for convenience only and are not intended to affect the meaning or interpretation of this Agreement. This Agreement does not constitute Buyer to be a partner, employee, agent, franchisee of or in joint venture with Fitnessmith nor does this Agreement authorize Buyer to represent or act for Fitnessmith in any manner. Buyer will have no right or authority to assume or create any obligation of any kind, express or implied, on behalf of Fitnessmith nor may Buyer bind Fitnessmith in any way whatsoever. Buyer acknowledges that is has not paid Fitnessmith any sum of money or any other consideration as a franchise fee or as a condition to signing this Agreement. In the event of any voluntary proceedings in bankruptcy or insolvency by or against Buyer, or in the event of the appointment, with or without Buyer's consent, of an assignee for the benefit of creditors or a receiver. Fitnessmith shall be entitled to cancel any unfilled part of Buyer's purchase without any liability whatsoever. Entire Agreement. The entire agreement between the parties is set forth herein and supersedes all prior discussions and agreements between the parties relating to the subject matter hereof. There are no representations, warranties. covenants, agreements· or collateral understanding, oral or otherwise, expressed or implied, affecting this Agreement which are not expressly set forth herein. This Agreement shall not be supplemented or modified by any course of dealing or trade usage. Attorney's Fees. If any party institutes any action or proceeding, the prevailing party shall be entitled, in addition to such other relief as may be granted, to be reimbursed by the losing party for all costs and expenses incurred thereby, including, but not limited to, reasonable attorneys' fees (including pre-judgment and post-judgment) and costs. 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 9 of 10 0: (561) 529-5590 I F: {561} 997-8788 I W: www.fitnessmith.com Acceptance (If signing below, ALL Quote pages must be returned to Fitnessmith to constitute a valid Purchase Order.) I have read and agree to the Terms and Conditions. Please accept this signed quotation as a purchase order and acceptance of the price, terms, and conditions above. Company Name: GIBSON-BETHEL COMMUNITY CENTER Signature Date Print Name Title 3610 Quantum Blvd I Boynton Beach, FL 33426 Page 10 of 10 ... ::E: .... -:t ~: LLI Z I--II. .. THE CITY OF PLEASANT LIVING REFERENCE CHECK: EXERCISE EQUIPMENT PREPARED BY: PURCHASING DEPARTMENT VENDOR: Centurion Partners Health & Fitness d/b/a Fitnessmith DATE: 04/06/16 REFERENCE: City of Coconut Creek CONTACT: Jacgui Pomerantz 1. How is the vendor's quality of work? Their quality of work is exceptional, very thorough and professional. 2. Were projects completed within established timeframes; on-time and on budget? All projects were completed in the time required and within the allotted budget. 3. Was the number and type of change orders requested in line with the project? Everything requested was in line with the project. 4. How is the vendors Response Time and communication with staff? Response time is impeccable and constant communication was provided. 5. What was the project scope/agreement and project value? The agreement was assist us in deSigning a floor plan for the new fitness center. Then move all the existing equipment down stairs to the new fitness center, discard old equipment and provide new pieces of equipment. The project value for this vendor was $50,000. 1 .Q. ,..".. ..... .:, :'" ~''! South~M'iami REFERENCE CHECK: EXERCISE EQUIPMENT PREPARED BY: PURCHASING DEPARTMENT VENDOR: Centurion Partners Health & Fitness d/b/a Fitnessmith DATE: 04/06/16 REFERENCE: Rocket Fitness CONTACT: Jim McCormick 1. How is the vendor's quality of work? SW-P. J.tv-J"' 2. Were projects completed within established timeframes; on-time and on budget? 3. Was the number and type of change orders requested in line with the project? \ i ~ V. 4. How is the vendors Response TIme and communication with staff? ~~V\ (~~ ll)/.,{~! iwvt L::.v,J·vV' iJ.i;1 Jj\ij'WJ;,.l. I . L S. What was the project scope/agreement and project value? ~~. ( I' ;~ f' J.)/'''.J; i/' ./ , t ;!i"1/~ fA' ).1.,~ {.t l./-d.j L 1 (j 3131/2016 Detail by Entity Name Detail by Entity Name Florida Limited'Liability Company CENTURION PARTNERS HEALTH AND FITNESS, LLC Filing Information Document Number FEI/EIN Number Date Filed State Status Principal Address 3610 Quantum Blvd. Boynton Beach, FL 33426 Changed: 10/17/2013 Mailing Address 3610 Quantum Blvd. Boynton Beach, FL 33426 Changed: 10/17/2013 L13000039419 46-2293242 03/15/2013 FL ACTIVE Registered Agent Name & Address GIANNONE, FRANK 3610 Quantum Blvd Boynton Beach, FL 33426 Address Changed: 01/16/2014 Authorized Person(s) Detail Name & Address Title MGR .. :, CENTURION CAPITAL PARTNERS, LLC 6500 E ROGERS CIRCLE BOCA RATON, FL 33487 Title Manager Scichilone, Michael 3610 Quantum Blvd. http::f/search.sunbiz.org/lnquirylCorporationSearchlSearchResultDelail?inquirytype=EntityName&directionType=lnitial&searchNameOrder=CENTURIONPAR '. 112 3131/2016 , Boynton Beach, FL 33426 Annual Reports Report Year 2014 2015 2016 Document Images Filed Date . 01/16/2014 0·1115/2015 03/02/2016 Detail by Entity Name 03/02/2016 --ANNUAL REPORT View image in PDF format 01/15/2015':'" ANNUAL REPORT View image,in PDF format 01/16/2014 -ANNUAL REPORT View image in PDF format 03/15/2013 --Florida Limited Liability View image in PDF format --------~~----------~ CooyriQht © and PrivaCY PolicIes State of Florida, Department of State http://search.sunbiz.orgllnquiry/CorporationSearchiSearchResultDetail?inquirytype=ErdityName&c!irectionType=lnitiaJ&searchNameOrder=CENTURIONPAR.. 212 2016 FLORIDA LIMITED LIABILITY COMPANY ANNUAL REPORT DOCUMENT# L 13000039419 Entity Name: CENTURION PARTNERS HEALTH AND FITNESS, LLC Current Principal Place of Business: 3610 QUANTUM BLVD. BOYNTON BEACH, Fl 33426 Current Mailing Address: 3610 QUANTUM BLVD. BOYNTON BEACH, FL 33426 US FEI Number: 46-2293242 Name and Address of Current Registered Agent: GIANNONE, FRANK 3610 QUANTUM BLVD BOYNTON BEACH, FL 33426 US FILED Mar 02,2016 Secretary of State CC5875268574 Certificate of Status Desired: No The above named entity submits this statement for the purpose of changing its registerad office or registered agent. or both, in the State of Florida. SIGNATURE: Electronic Signature of Registered Agent Authorized Person(s) Detail : TiUe Name Address MGR CENTURION CAPITAL PARTNERS. LLC 6500 E ROGERS CIRCLE City-State.zip: BOCA RATON FL 33487 Date Title MANAGER Name SCICHllONE, MICHAEL Address 3610 QUANTUM BLVD. Cily-State-Zip: BOYNTON BEACH FL 33426 I hereby cel1ffy th8t flJe information indicated on this report or supplemental report is true and accurate ami that my electronic Signature shall have the sama /flgel effect as If msde under oath; that I am B managing member or manager o( the limited liBbiliiy company or tile receiver or trus"'" empowered 10 execute this report as requi1J1d by Chapter 605, Florida Statutes; and that my name 8ppears above, or on an attachment with all other like empowered. SIGNATURE: STACIA FOREMAN CONTROLLER 03/02/2016 Electronic Signature of Signing Authorized Person(s) Detail Date 3131/2016 Detail by Entity Name Florida Profit Corporation FRANK GIA, INC. Filing Information Document Number FEI/EIN Number Date Filed Effective Date State Status P98000107304 65-0894590 12/29/1998 01/01/1999 FL ACTIVE Detail by Entity Name Last Event Event Date Filed NAME CHANGE AMENDMENT 11/07/2013 Event Effective Date Principal Address 3610 QUANTUM BLVD BOYNTON BEACH, FL 33426. Changed: 08/13/2013 Mailing Address 3610 QUANTUM BLVD BOYNTON BEACH, FL 33426 Changed: 08/13/2013 NONE Registered Agent Name & Address GIANNONE, FRANK 9072 VILLA PORTOFINO CIRCLE BOCA RATON, FL 33496 Name Changed: 05/10/1999 Address Changed: 01/22/2004 Officer/Director Detail Name & Address Title PD GIANNONE, FRANK http://search.sunbiz.orgllnquiry/CorporationSearchlSearchResultDelail?inquirylype=EntityName&directionType=lnitial&searchNameOrder=FITNESSMITH%2...1/2 .. ?/31/2016 9072 VILLA PORTOFINO CIRCLE • BOCA RATON, FL 33496 Title STD GIANNONE, SHERRI 9072 VILLA PORTOFINO CIRCLE BOCA RATON, FL 33496 Annual Reports Report Year 2014 2015 2016 Document Images Filed Date 01/16/2014 02/23/2015 03/02/2016 Detail by Entity Name 03/02/2016 --ANNUAL REPORT View image in PDF format 02/23/2015 -ANNUAL REPORT View image in PDF fonnat 01/16/2014 --ANNUAL REPORT View image in PDF fonnat 11/07/2013 -Name Change View image in PDF fonnat 10/07/2013 --REINSTATEMENT View image in PDF format 02/15/2012 --ANNUAL REPORT View image in PDF fonnat 04/12/2011 -ADDRESS CHNAGE View image in PDF fonnat --------~------------~ 01/27/2011 -ANNUAL REPORT View image in PDF fonnat 02/18/2010 --ANNUAL REPORT View image in PDF fonnat 04/01/2009 -ANNUAL REPORT View image in PDF format 01/31/2008 --ANNUAL REPORT View image in PDF format 02[07/2007 --ANNUAL REPORT View image in PDF fonnat 02/04/2006 --ANNUAL REPORT View image in PDF fonnat 02/04/2005 --ANNUAL REPORT View image in PDF fonnat 01/22/2004 --ANNUAL REPORT View image in PDF fonnat 01/29/2003 -ANNUAL REPORT View image in PDF fonnat 02/11/2002 --ANNUAL REPORT View image in PDF format 01/26/2001 --ANNUAL REPORT View image in PDF format 08/17/2000 --ANNUAL REPORT View image in PDF fonnat 05/10/1999 --Reg. Agent Change View image in PDF format 12/29/1998 --Domestic Profit View image in PDF fonnat http://search.sunbiz.orgllnquiry/CorporationSearchlSearchResultDetail?inquirytype=EntityName&directionType=lnitial&searchNameOrder=FITNESSMITH%2... 212 A. .f" 2016 FLORIDA PROFIT CORPORATION ANNUAL REPORT DOCUMENT# P98000107304 FILED Mar 02, 2016 Secretary of State CC3114894267 Entity Name: FRANK GIA, INC. Current Principal Place of Business: 3610 QUANTUM BLVD BOYNTON BEACH, FL 33426 Current Mailing Address: 3610 QUANTUM BLVD BOYNTON BEACH, FL 33426 FEI Number: 65-0894590 Name and AddreSs of Current Registered Agent: GIANNONE, FRANK 9072 VILLA PORTOFINO CIRCLE BOCA RATON, FL 33496 us . Certificate of Status Desired: No The above named entity submits this statement for the purpose of changing its registered office or registered agent, or both, in the State of Flonda. SIGNATURE: 8ectronic Signature of Registered Agent OffIcer/Director Detail : Title Name Address PO GIANNONE, FRANK 9072 VILLA PORTOFINO CIRCLE City-State-Zip: BOCA RATON FL 33496 Title Name STD GIANNONE, SHERRI Address 9072 VILLA PORTOFINO CIRCLE City-State-Zip: BOCA RATON FL 33496 Date I heteby certify that the/nfwmation indicated on this report or supplemental report islJUe end aocutale and that my e/eclJtmlc sIgnatUre shall have the same IegsJ e/feCI as" mad" under oath; that I am en officer or ditecIorof the COqJ018fion orthe receiver or IJUslee empowered to execute this t8port II. required by Chap/er 807. Florida Statutes; end that my name appears above. or on an a/tIiIchment with all other like empowered. SIGNATURE: FRANK GIANNONE . PRESIDENT 03/0212016 8ectronic Signaturlil of Signing Officer/oirector Detail Date Member Name Bid Number City of South Miami RFP-RFP #PR2016-0S-0- 2016/SK Purchase and Installation of Fitness Center Equipment at the Gibson-Bethel Bid Name Community Center 4 Document(s) found for this bid 76 Notified; 5 Planholder(s) found . Supplier Name Address 1 Busy Body/Gyms To Go 910 SW 2nd PI Fitnessmith link Systems llC 5870 Hummingbird Court M-f Athletic Co POBox 8090 Promaxima Manufacturing 5310 Ashbrook Drive City Pompano Beach Titusville Cranston Houston State Zip Phone Fax Attributes Fl 33069 5617236536 9547811787 AB Fl 32780 4074010031 1111111111 1. Small Business RI 02920 8005567464 8006826950 1. Small Business TX 77081 8002316652 7136679941 .. . --_._--.. ---_. ---------------~.------.. ------.. --~-------------------------------------.. -~-----------------------~-.---------.. -------- <. MIAMI DAILY BUSINESS REVIEW Published Daily except Saturday. Sunday and Legol Hofiday. Miami; Miaml·Dade County. Florida STATE OF FLORIDA COUNlY OF MIAMI.DADE: Before the undersigned authority personally appeared OCTELMA V. fERBEYRE .. who on oath says Ihat he or she is the VICE PRESIDENT. Legal Notices of Ihe . Miami Daily Business Review Ilkla Miami Review. a daily (except Saturday, Sunday and Legal Holidays) newspaper. published at Miami in Miami-Dade Counly.Florida: Ihat the attached copy of advertisement, being a Legal Advertisement of Notice in the matter 01 CITY Of SOUTH MIAMI-RFP #PR2016·0S in the XXXX Court, was published in said newspaper in the issues of 03/14/2016 Affiant rurther says that the said Miami Daily Busines's Review is a newspaper published at Miami. in said Miami-Dade Counly, Florida and thai the said newspaper has heretorore been continuously published in said Miami ·Dade County, ftorida each day (except Saturday, Sltnday and Legal Hofidays) and has been enlered .as second ctass mail matter at the past office in Miami in said Miami-Dade County. Florida, for a period of one year next preceding Ihe first publication of the attached copy of advertisement: and affiant further says that he or she has neither paid nor promised any person. firm or 'corporation any discount, rebate. commission or refund for 111 purpose oj securing this advertisement lor saidneoSj ~~ Sworn to and subscribed before me Ihis ~l:~MARCH. A.D. 2016 ! L ~ Jd Vib~ oS ' ... ' . ©n'irVIQJrF SOIWTIHl WilnAIMUU . ----J.:i?H.JIii1l~G'il.~SE~Ni:HiM$ii' A:iL;fI,;A'irBOtM~!()F-~--' .... ' ·IFD1i"L\'iIESSceru'iilSlRra'QI!}10I;.ilMlSINiyA1i 1i"M!e . (Q1U!5lS01.\'l-161E'ii1Mll:!L·COMMIllIL\'InirVclSL\'I'B'IS~" . ". .. . J1l.lU:I?#JFbIPu20il6.;05 . '. TheCilyishereby requesting sealed. proposals in reSponse \oiOisRFP IIPR2016;OS .' "purchase .. and Installation' oCFitnessCenter' Equipment at the GibsCS'n,Betiict Community Ceriter." The purposeo! tllls'Solicitation' 1510 contraclfor Ihe services necessary foi thecomplelionoflhe project in accordaI)6e\~ilhJhe plaris and/o,'specilicOlions,if',any, described in thi's 'Solicitation (hemi.naflerrefemidto as "thePr.oject" or 'Project"); • Interested .' persons whp wish to.respondtotliisSolic:itation cqn o~t~i'lthe · corilplete SOIiCillltionpackage at the City Clerk'sofiiceMonday:through • Friday from 9:00 3.m.t04:00p:m:orby 3ccessing Ihefcillowillg weiJpage: http://'vviw.so.uthmiamiftgov/which is the City of South Miami's:web address forsoli.citation.informallon. - Sealed 'Proppsals nllIstb!O received by Office of' ihe '.~It}'C{erk,:~lthe~ by inail. or hand delivery, . no later than 10:00a.m,localtrme .on M.arch31, 20'16; Haod (jelivcry.must. be 'made duringll0ntl<t' business ,daYS ilnd hours of the office ofCityClerR~ A public opening will lake place at' ·to:OOIl.m,Onthe same date iiilheCity Caminissir:in Chambers:locatedai · City Hall,GlaO Sl!nset Drive, South Miami '33143. Any 'Proposat· received after 10:00 a.m, local time' on saiddalewi\lllot 'be accepted under any cir- cumstances.· ..... . . . . A-Non;Maridalory pr~~propOSill M~etin9Win· be c~nduc\ed· at~heci.tY·. of SOiltlHJllaiiil's Gibson"Bethcl' CommUliitY'CenlerIQcalod¥ 5800 SW 66.th:S.irliet,Sot.ith'Miart1i, ·FL:3:H43.~n_."'!a!,:h ... ~.2016,.~91S. .. aL '10:00 a.ni. The:coiiferem:e. sllall:behEld regardless 01· weatl\ercondl\lons. . .. _. ". -. . -.: . ·~.:-:~1: . . Maria'.M;Menendez,. CMC GityCleik .. , . City of South Miaiili .. . . " ..... ~ .. 1.6:98{Q0D.9Q~06.84rv1