The URL can be used to link to this page

Res No 160-15-14499RESOLUTION NO.:160-15-14499 A Resolution authorizing the City Manager to negotiate and enter into a contract with Maggolc,Inc for the construction of the Twin Lakes Roadway &Drainage Improvements -Area 1. WHEREAS,the Mayor and City Commission wish to provide roadway and drainage improvements to the area knownasTwinLakes (between SW64 Court and SW63Court,from SW 62 Terrace to SW 64 Street),and WHEREAS,pursuant to a competitive selection process in accordance with the City Charter,itwas determined that Maggolc,Inc submitted abidin the amount of$145,440 that was the most comprehensive and cost effective inits construction approach;and WHEREAS,the City desirestoprovideacontingencyof$14,550over the bid amount for unknown factors that may arise during the work;and WHEREAS,the total expenditure,including the contingency amount,is not to exceed $159,990;and WHEREAS,the MayorandCityCommission desire to authorize the City Manager to negotiateand enter intoacontractwith Maggolc,Inc fortheconstructionofthe Twin Lakes Drainage &Roadway Improvements -Area 1foratotalamountnottoexceed $159,990. NOW,THEREFORE,BE IT RESOLVED BY THE MAYORAND CITY COMMISSIONOF THE CITY OF SOUTH MIAMI,FLORIDA THAT: Section1:The City Managerisauthorizedtonegotiatetheprice,termsandconditions andto execute a contract with Maggolc,Inc for Twin Lakes Roadway&Drainage Improvements - Area1foran amount nottoexceed$145,440,andheisauthorizedtoexpendupto$14,550for unforeseen conditions.Acopyof the approvedformof contract is attached and the City Manager may negotiatea lower price andmore advantageous termsand conditions if approved bythe City Attorney. Section 2:The expenditure shallbechargedto the Local OptionGasTrust account number 112-1730-541-6210 whichhasa balance of $235,000,and charged to the People's Transportation Plan Tax Fund accountnumber 124-1730-541-6490 which hasa balance of $1,508,000,before this request was made. Section3:Ifanysectionclause,sentence,or phrase ofthisresolutionisforanyreason held invalid or unconstitutional bya court of competent jurisdiction,the holdingshallnotaffect the validity of the remaining portions of this resolution. Pg.2 of Res.No.160-15-14499 Section 4.This resolution shall take effect immediately upon adoption. PASSED AND ADOPTED this 6th dayof October 2015. READ AND AP LANGUA ED AS TO FORM LITY AND EXECUTION APPROVED: COMMISSION VOTE:4-0 Mayor Stoddard Yea Vice Mayor Harris Absent Commissioner Welsh yea Commissioner Liebman yea Commissioner Edmond Yea £South'Miami THE CITY OF PLEASANT LIVING CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM To: From: Date: TheHonorableMayor&Members of the City Commission Steven Alexander,CityManager October 6,2015 Agenda Item No.: Subject:A Resolution authorizing the CityManagerto negotiate and enter into a contract with Maggolc,Inc.for the construction of the TwinLakesRoadway&Drainage Improvements- Area 1. Background:TheTwinLakesareahas historically experiencedfloodingandisinneed of drainage improvements.According totheCity of South Miami Stormwater Master Plan,developed in2012,the TwinLakesareaisidentifiedasapriorityarea.Furthermore,the Cityhas received complaints from residents inregardstofloodingalong these streets. The scope includes the implementation of exfiltration systems withcatchbasins that are interconnected to the exitingdrainage system and to reduce the volume of runoff (pollutants)generatedbyastorm event intothe neighboring lakeand canal.Roadway resurfacingwillalsobeincludedaspart of the scope,dueto the requiredrepairsfrom the drainage system installation. Thereare two separateprojectareas,quoted separatelyasdescribedbelow.Thiswas donetoassurethat the approved CIP fundsaresufficientfor the improvements. Area 1-West Side of the Canal •SW 62 Terrace and SW 63 Terrace,from SW 64 Court to SW 63 Court •SW 64 Court and SW 63 Court,from SW62 Terrace to SW 64 Street Area 2-East Side of the Canal •SW 63 Avenue and SW62Place,from SW 62 Terrace to SW 64 Street •SW 62 Terrace,from SW 63 Avenue to SW 62 Court SW 63 Terrace,from SW 62Place to SW 62 Court SW 62 Court,from SW 62 Terrace to SW 63 Terrace. TheCityreceivedfivebidsinresponsetoasolicitation.Pursuanttoreview,itwas determined that Maggolc,Inc.isthe most responsiveandresponsiblebidderforthis proposal.Belowarethe proposals receivedforeachareaquoted: Contractor Areal Area 2 Maggolc,Inc.$145,440.00 $162,630.00 Florida Construction & Engineering $152,514.20 $175,775.31 Coramarca Corp.$157,622.40 $187,655.20 HG Construction Development &Invest.$177,311.00 $208,658.00 RP Utility&ExcavationCorp $228,043.14 $241,292.55 AresolutionforArea2wasapprovedpreviouslyby the CityCommission.Wearenow proceeding with the award forArea1. TheCityhasatotalof$160,000 allocated in FY 16forthisproject.Maggolc,Inc provideda proposalin the amount of $145,440.Acontingency amount of $14,550willbeincluded over the proposal amount to addressfor unknown factors that mayariseduring the work. Amount:Amount not to exceed $159,990 Account:The expenditure shall be charged: •$100,000 to Local OptionGasTrust Fund account number 112-1730-541-6210, •$59,990 tothePeople's Transportation Plan Tax Fund accountnumber124-1730- 541-6490 whichhave balances of$235,000,and$1,508,000respectively,beforethisrequestwas made. Attachments:Resolution Bid Opening Report Maggolc,IncBid Contract RFP&Exhibits BID OPENING REPORT Bids were opened on:Friday.August 14.2015 after;11:00am For;RFP ft PW 2015-19 -Citvwide Drainage Improvement Protects COMPANIES THAT SUBMITTED PROPOSALS:AMOUNT: SW78ST& 63 AV TWIN LAKES AREA 1 AREA 2 1.CORAMARCACORP tiovno-ob ^1551,514.^0 to.cua.iLj 4/t>d,fe3o.06 2.FLORIDA CONSTRUCTION &ENGINEERING.... 3.HG CONSTRUCTION DEVELOPMENT &INVEST. 4.MAGGOLCINC 5.RP UTILITY &EXCAVATION CORP THE ABOVE BIDS HAVE NOT BEEN CHECKED. THE BO)S ARE SUBJECT TO CORRECTION AFTER THE BIDS HAVE BEEN COMPLETELY REVIEWED. City Clerk:|l jkfl^flk %UjjtJi Print Name XJ ]/j~/ Witness: Print Name Witness:lUCcrtb jA AyJfL Print Name 'S*7J/S/ Signature South*Miami THE CITV OF PLEASANT LIVING CITY OF SOUTH MIAMI CHywide Drainage Improvement Projects RFP#PW-20I5-I9 Submittal Due Date:August 14,2015 at 11 AM Solicitation Cover Letter TheCityofSouth Miami,Florida (hereinafter referredtoas "CSM")through its chief executive officer (City Manager)hereby solicits sealedproposals responsive totheCity'srequest (hereinafter referredtoas "Request for ftoposals"or "RFP").Ailreferences In this Solicitation (alsoreferred id asan "Invitation forProposals"or "Invitation to Bid")to "City"shallbeareference to theCity Manager,or the manager's designee,forthe Qty of South Miami unlessotherwise specifically defined. TheCityishereby requesting sealed proposals inresponsetothis RFP #PW-20I5-I9 "Cltywide Drainage Improvement Projects."Thepurposeofthis Solicitation Is tocontractfortheservicesnecessaryfor the completion oftheproject In accordancewiththeScope ofServices,(Exhibit I,Attachment A,B,C £P)and Respondents Gist andTechnical Proposal ExMUt 5,orthe plans and/or specifications,if any,(Exhibit I; Attachment 8 dl D).describedInthis Solicitation (hereinafterreferredtoas "the Project?'or "Project") Interestedpersonswhowishtorespondtothis Solicitation canobtainthecomplete Solicitation package at the CityClerk's office Monday througi Friday from MO A.M.to 4:00 P.M.or fay accessing the following webpages httpr/ftvww.sotittimlamifl.gov/whichIstheCityofSouth Miami's webaddressfor solicitation Information. Proposals aresubject to theStandardTermsandConditions contained in thecomplete Solicitation Package, including alldocumentslistedIn the Solicitation. The Proposal Package shall consistofone(I)original unbound proposal,three(3)additional copiesandone(I) dlgftal (or comparable medium Including Rash Drive,DVD orCD)copy all of which shall be delivered tothe Officeofthe Qty Clerk located at South Miami Chy Hall,6130 Sunset Drive,South Miami,Florida 33143.The entire Proposal Package shall be enclosed ina sealed envelope or container and shafl have the following Envelope Information dearlyprinted or writtenontheexteriorofthe envelope orcontainerIn which the sealed proposalIs delivered:"Cltywide Drainage Improvement Projects/9 RFP flPW-2015-19 andthenameofthe Respondent(person or entityrespondingto the Solicitation.Spedal envelopes suchasthoseprovidedby UPS or Federal Express will notbeopened unless they contain the required Envelope Information onthefrontorbackof the envelope.SealedProposals mustbe received by Office ofthe Qty Clerk,eitherby mail or hand delivery,no toner than 11:00 AH.focal time on August 14,2015.Hand delivery mustbe made during normal business daysandhoursofthe office of City Clerk. A public opening will take place at 11 A.M.onthesamedate In theCity Cbmmisslon Chambers located at Qty Hall,6130 Sunset Drive,South Miami 33143.Any Proposal received after 11 A.M.local timeonsaiddate will not beacceptedunderany circumstances.Any uncertainty regarding thetimea Proposal Is received will beresolved against theperson submitting theproposalandinfavoroftheClerk'sreceipt stamp. A Non-Mandatory Pre-Proposal Meetingwillbe conducted at CityHallin the Commission Chamber*located at 6130 Sunset Drive,South Miami,Fl 33143 on,August 3,2015 at 1030 AM.The conference shall be held regardless ofweather conditions.Proposals are subject tothe terms,conditions and provisions ofthisletteras well astothose provisions,terms,conditions,affidavits and documents contained In this Solicitation Package.TheCityreservesthe right to award theProjecttothepersonwiththe lowest,most responsive,responsible Proposal,as determined bythe City,subject tothe right ofthe City,ortheCity Commission,to rejectanyandallproposals,andtherightoftheCityto waive any Irregularity inthe Proposals or Solicitation procedureandsubjectalsototherightofthe CHy toawardthe Project,andexecuteacontractwitha Respondent or Respondents,otherthantoonewho provided thelowest Proposal Price or,ifthe Scope ofthe Workis divided into distinct subdivisions,to award each subdivision toaseparate Respondent Maria M.Menendez,CMC City Clerk.CityofSouth Miami Proposal Submittal Checklist Form Citywide Drainage Improvement Prelects RFP#PW-20I5-I9 Thischecklist indicates theformsand documents requiredto be submitted forthis solicitation andtobepresented bythe deadline setforwithinthe solicitation.Fulfillment of al solicitation requirements listedismandatoryfor consideration of response tothe sollchation.Additional documents may be required and,ifso,theywillbe Identified In an addendum to this Solicitation.The response shall Include the following items: AtUchm IF MARKED WITH AN Schedule ofValues EXHIBIT I,Attachment A dl C Indemnification and Insurance Documents EXHIBIT 2 Bid Form EXHIBIT 4 Respondents Cost &Technical Proposal,EXHIBITS X Signed ContractDocuments(All -Including GeneralConditions ^_^and Supplementary Conditions ifattached)EXHIBIT 6;7&8 Performance and Payment Bonds(As a Condition Award.Not required with Submittal.)EXHIBIT 9 &10 Respondents Qualification Statement ListofProposedSubcontractors and Principal Suppliers Non-Collusion Affidavit Public Entity Crimesand Conflicts of Interest DrugFreeWorkplace Acknowledgement ofConformancewith OSHAStandards Affidavit ConcerningFederal&StateVendor Listings RelatedPartyTransaction Verification Form PresentationTeam Declaration/Affidavit ofRepresentation s / •" / s s s s s s s y s Submit this checklist along withyour proposal indicating the completion and submission ofeach required forms and/or documents. END OF SECTION RESPONDENT QUALIFICATION STATEMENT Citywide Drainage Improvement Projects RFP#PW-20I5-I9 Theresponseto this questionnaire shall be utilized as part ofthe CITY'S overall Proposal Evaluation and RESPONDENT selection. I.Numberof similar projectscompleted, JA. JS- 2^£- 3*gL a)Inthepast5years In thepast5yearsOn Schedule b)Inthepast 10 years In the past 10 yearsOnSchedule 2.Listthelastthree(3)completed similar projects, a)PkrojectName: Owner Name: Owner Address: Owner Telephone: </</</£u>?**Jl**">66m,?&gg% b) Original Contract Completion Time (Days): Original Contraa Completion Date: Actual Final Contract Completion £—/>•*/»+•Data ^>//£,//S Original Contract Price: Actual Final Contract Price: *//»/* Go Project Name: Owner Name: Owner Address: Owner Telephone: Original Contract Completion Time (Days): Original Contract Completion Date:y //£//S Actual Rnal Contraa Completion Date: Original Contraa Price: Actual Rnal Contraa Price 12 <//iz//£ -zziT gees,vy c)PlnoJettName: Owner Name: Owner Address: OwnerTelephone:3J>S-*//f>-/-Z2>4>/j26>-20£>~2/32 Original Contraa Completion Time (Days): Original Contraa Completion Date: Actual Rnal Contraa Completion Date: Original Contraa Price: Actual Rnal Contraa Price: 3.Current workload *?0 T>* 4jl^/g//V 2>W.9<7 YJ>/.</**.>s. Csv^J^&t- 4.The following information shall be attached tothe proposal. a)RESPONDENTS home office organization chart l/* b)RESPONDENTSproposed projea organizational chart *r c)Resumesofproposedkeyprojea personnel,including on-siteSuperintendent %r 5.list anddescribe any: 13 a)Bankruptcy petitions filed byor against theRespondentoranypredecessor organizations, b)Any arbitration or civil or criminal proceedings,or Suspension of contractsor debarring from Bidding or Responding byany public agency brought c)against the Respondent in the last five (5)years /J}&a)£-" 6.Government References: List other GovernmentAgenciesor Quasi-govemment Agencies forwhichyouhavedone business within thepastfive(5)years.. Name of Agency:(Sjul.J^S^diffouC L*-%) Address:._^^______-_^_«_________. Telephone No.: Contaa Person: Type of Profect: Nameof Agency: Address: Telephone No.:, Contaa Person: Type of Project Name of Agency:^ Address: Telephone No.: Contaa Person: Type of Pro|ect u ENGINEERING CONTRACTOR-UC:&251302 11020 8W 55 ST.,MIAMI,FL 33165 PHONE:78*291-2949 FAX:78*47*8831 ahop^cjfln PROJECTS UNDERCONSTRUCTION(All as aPrime Contractor) Current Workload 1-FDOT-Districtwide (ADA)Push Button-Pedestrian Safety Improvement (Owner FDOT- Dlstrict 6 -$981,885.00)(Executed26%)(Completion August 2015)(305-978-0090 -Marina Gershanovich) 2-Drainage Improvements Project Multiple Sites #20140185 (Miami Dade County $350,000)(Executed75%)(Completion September 30,2015)(305-375-1918-Pedro Marsan) 3-Sub-Basin 10 (SW 88 Ave)Paving &Drainage Improv.(Villageof Palmetto Bay, $922,633)(Executed38%)(Completion November2015)(Danny Casals 305-969-5011) 4-Sidewalk Improvements Multiple Sites (Miami DadeCounty$518,371)(Executed21%) (Completion May 30,2016)(305-297-0795-George Coppolechla) Mario Gonzalez Maggolc Inc./President www- ENGINEERING CONTRACTOR-UC:E-251302 11080 aW 95 ST.,MIAMI,FL 93108 PHONE:786*291-2040 FAX:78*4724831 maflfloiCffiffhftO^m SIMILAR DRAINAGE PROJECTS PERFORMED BY MAGGOLC INC. 1-MIA Building 3050Parking Lot Drainage&Asphalt Improvement ($103,000)(Aviation Department Miami- DadeCounty,CompletedMay2011)(GregTai 305-876 8444)(gtai@mlkegcon8t.com) 2-SW 19 Terrace Roadway and Drainage Improvements ($184,585)(City of Miami,Capital Improvements Department,CompletedOctober2011)(Maurice Hardle 788-229 5463)(mhardie@mlamfgov.com) 3-SR 909(AltonRoad)at West 52StraatDialnaga Improvement ($138,000)(Florida Departmentof Transportation,Completed December 2011)(RolandRodriguez305-345 0696) (mxMguez@pinnacleoei.com) 4-Suncraat DriveftMoaa Ranch Road Stormwater Improvements ($110,000)(Village ofPinecrest,Public Works Dap.,Completed December 2011)(Daniel Moratti 305460 6816)(morettl@plnec7est-4i.gov) 5-Long Key State Park Roadway Improvements ($149,230)(Florida Department ofEnvironmentalProtection, CompletedFebruary2012)(FredHand 650-488 6322)(Frad.Hand@dep.state.fl.ua) 6-Phase IV Drainage Improvement Project ($143,830)(Village of PalmettoBay,Completed November 2012) (Danny Casals 305-969 6091)(dcasals@palmettobay^fl.gov) 7-Kllllan ParkRoad Stormwater Improvement ($218,142)(Village ofPinecrest,CompletedDecember2012) (DanielMoretti 305469 6916)(moretH@pinecre8t-fl.gov) 8-ProgressRd.RoadwayandDrainage improvements ($106,522)(City ofSouth Miami,Completed January 2013)(JorgeVera 305-403 2072)(jvera@80Uthmiamlfl.gov) g-NW8th ST &NW14CT Roadway and Drainage Improvements ($425,895)(Cityof Miami,CompletedMay 2013)(RobertFenton 786-263-2133)(rfoitoru9miamlgov.com) 10-Frledland ManorDrainage Improvements ($406,587)(City of Florida City,CompletedJune2013)(Sean Compel786-502-0770)(sean.compel@stantec.com) 11-Blscayne Island Drainage Improvements ($735,559).(City of Miami,Completed March2014)(Valentine Onuigbo 788-447-8817)(vonuigbo@miamigov.com) 12-Beaoom ProjectArea Improvements-Phase I ($767,132)(Cityof Miami,Completed March 2014)(Robert Fenton 786-263-2133)(rfenton@mlamlgov.com) 13-NW11 ST from27 Ave to 37 Ave.Area Roadway Improvements.($188,874)(Cityof Miami,Completed October 2014)(Valentine Onuigbo 786-447-9817)(vonuibo@mlamlgov.com) 14-NW18PL Road and Drainage Improvements ($473,087.20)(Cityof Miami,Completed March 2015)(Robert Fenton 786-263-2133)(rfsnton@miamlgov.com) 15-Lummua ParkLanding ($222,612.91)(Cityof Miami,CompletedMay2015)(David Adato 305-416 1899/ 786-376 4391)(dadato@mlamlgov.com) 16-Beacom ProjectArea Improvements?Phase II ($818,978.96)(Cityof Miami,CompletedJuly2015)(Robert Fenton 786-263-2133)(rfenton@mlamlgov.com) 0 ENGINEERING CONTRACTOR -UC:6-251302 11020 SW 88 ST.,MIAMI,PL 33165 PHONE:768*914949 PAX:7884724831 "Wflfloicftvyfi99t€0^ CONTRACTS PERFORMED BY MAGGOLC INC. 1-Dralnaga ImprovementforNW22CTfromNW107STtoNW112ST,($318,000)(Mlaml-Dade County Public Works Dept.,CompletedDec.2007).(Alberto Estevez 786-2562627).(esteva@miamidade.gov) 2-Varioua ParkParkingLotRe-stripingftWheelStopReplace.($24,800)(Miami-Dade Park and Recreation Dept Completed March 2008).(305-6964460) 3-Seal CoatandRe-striping of Station 13/Logistics Parking Area.($19,000)(Miami-Dade Fire Rescue Dept. CompletedJuly2008).(786-331 4529) 4-Noranan andJean Reach Part/Foul ballNetting.($25,000)(Mlaml-Dade ParkandRecreation Dept., CompletedJune 2008).(305-586 4460) 5-Olymplo Park Concrete 8ldewaJk Construction.($184,000)(Mlaml-Dade ParkandRecreation Dept, CompletedJuly2008).(Dan Crawford 305-6864460)(dc93@mlamldade.gov) 6-Dolphin Arahaeloglcal Site Concrete Sidewalk Construction.,($114,084)(Mlaml-Dade ParkandRecreation Dept.,CompletedJuly2008).(Dan Crawford 305-596 4460)(dc93@miamidade.gov) 7-Countywlde Repair of ExiatingAaphaltPavement.(Milling ftResurfacing)($849,990)(Florida Department ofTransportation,Dlst.Six,Executed theyear2008andrenewedfortoyear 2000 and 2010,CompletedJune 2011).(JaniceCom 305-258 6350)(Janfce.com@dotstate.fl.us) 8-Countywlde InteraecUona Improvement,Roadway andDrainage.($443,637)(Miami-Dade County Public Works Dept,Completed Dec.2008).(Joaquin Rabassa306-209 9822)(tra@mlamidade.gov) 9-Weet Perrlne Park Concrete Slabs,Sidewalks and Poured In Place.($34,000)(Miami-Dade Park and Recreation Dept,Completed January 2009).(305-598 4460) 10-West Little River Aaphalt Driveways Phaaa IV-B.($68,600)(Miami-Dade CountyOfficeofCommunityand EconomicDevelopment,Completed January 2008).(Mario Barrios 786-469 2112)(mbOT@miamldad8.gov) 11-Brentwood PoolPark New Asphalt Walkways.($34,000)(City of Miami Gardens,Completed April 2000). (305-622 8000)Qallen@miamlgarden8-fl.gov) 12-Country Club of MiamiParcel 1168 ft 1168-E New Aaphalt Walkways.($178,000)(Miami-Dade Parkand Recreation Dept,Completed July 2000).(DanCrawford 305-686 4460)(dc93@mlamldade.gov) 13-Country Club of Miami Grading,Sitework ft Greene.($107,000)(Miami-Dade ParkandRecreationDept., Completed August 2009).(305-506 4460) 14-SR 807(AltonRd)at Allison Dr.forDrainageand Retention Improvements.($134,000)(FDOT,Completed December2009)(AnthonySabbag 305-256 6380)(anthony.sabbag@dot.state.fl.us) 15-West Little River Aaphalt Driveways Phaaa IV-D.($35,000)(Miami-Dade CountyOfficeofCommunityand EconomicDevelopment,Completed December 2000).(Mario Barrios 786-468 2112)(mberr@mlamklade.gov) 16-DJatrlct 2-Sidewalk Repair Project II ($78,300)(Public Works Dep.City of Miami,Completed March 2010) (Fabiola Dubuisson 3054161755 ft305-801 7816)(fdubui8son@miamigov.com) 17-Blue Road Roundabouts Re-Bid ($145,000)(PublicWorksDep.CityofCoralGables,Completed March 2010)(305-460 5018)(epIno@coralgables.com) 18-Harbor Drive Lighting and Resurfacing Improvement ($270,000)(Public Works Dep.VillageofKey Biscayne April2010)(786-255 8765)(wunez@keyblscayne.fl.gov) 18-DIatrict 1-Sidewalk RepairProjectII($88,880)(Public WorksDep.City of Miami,Completed September 2010)(Fabiola Dubuisson 305-4161755 &305-801 7816)(fdubute3on@mfamfgov.com) 20-Golden Shore Park Pavera Sidewalk ($23,885.00)(Public Works Dep.City of Sunny Isles Beach,November 2010)(305-947 0606)(gbatista@sibfl.net) 21-AD Barnes Park Aaphalt Walkways ($86,615.00)(Mlaml-Dade ParkandRecreation Dept,Completed December 2010)(305-755 7885)(rttolon@mlamidade.gov) 22-lnstallatlon of Sidewalks and Ramps along NE12 Ave ($123,750.00)(Public Works Dep.Cityof North Miami,CompletedDecember2010)(Qerardo Hernandez 306-803 6511)(ghemandez@northmlamifl.91v) 23-liitereectlon Realignment SW 139 Terr ft SW 148Dr.and East Guava Street One Way Straat Conversion ($36,775)(Public Works Dep.,VillageofPalmettoBay,Completed December 2010)(305-066 5011) (dcasal8@palmettobay-fl.gov) 24-Dlatrict #3 Cftywlde ADA Sidewalk Improvementa,($107,414)(PublicWorksDep.Cityof Miami,Completed February 2011)(FabiolaDubuisson305 4161755 ft 305-801 7816)(fdubulsson@mlamigov.com) 25-District #1 Cltywlde ADA Sidewalk Improvements,($155,523)(Public Works Dep.City of Miami,Completed May 2011)(Fabiola Dubuisson305 4161755 &305-801 7816)(fdubuisson@miamigov.oom) 26-MIA Building 3858 ParkingLotDrainageft Aaphalt Improvement ($103,000)(AviationDepartment Mlaml- DadeCounty,Completed May 2011)(Greg Tal 305-8768444)(gtal@mikegcon8t.com) 27-MIA-NW67 Ave &NW36 Street Intersection Improvementa ($65,000),(concrete works)(Aviation Department Miami DadeCounty,CompleteJuly 2011)(JohnPeterson 305-622 8000)(jpet@mftegcon8t.com) 28-District #4 Cltywlde ADA Sidewalk Improvementa,($148,387)(PublicWorksDep.Cityof Miami,Completed October 2011)(Fabiola Dubuisson 305-4161755 ft 305-801 7816)(fdubuis8on@mlamigov.com) 28-TamlamICanal MIocoaukee Linear Park,TamlamITrailand SW 122 Ave.($87,783)(Miami DadePark& RecreationDepartment,CompletedOctober 2011)(RubenTeurbe Tolon 786-586 8360)(rttolon@mtamldade.gov) 30-SW 19 Terrace Roadway andDrainage Improvementa ($184,585)(City of Miami,Capital Improvements Department,CompletedOctober 2011)(Maurice Hardle786-228 5463)(mhardle@miamigov.com) 31-8R 808(AttonRoad)at Wast 82 Street Drainage Improvement ($138,800)(Florida Departmentof Transportation,Completed December 2011)(RolandRodriguez305-345 0606) (rrodrijguez@plnnadecei.com) 32-3uncre8t Driveft Moss Ranch Road Stormwater Improvementa ($110,000)(VillageofPinecrest,Public WorksDep.,Completed December 2011)(Daniel Morettl 305-660 6616)(moretU@pInecrest-fl.gov) 33-Long Key State Park Roadway Improvementa ($149,230)(Florida Departmentof Environmental Protection, Completed February 2012)(FredHand 850-488 6322)(Fred.Hand@dep.state.fl.U8) 34-District #2 CltywldeADASidewalkImprovementa.($108,303)(Public WorksDep.Cityof Miami,Completed February 2012)(Fabiola Dubuisson 30&41617SS &305-801 7816)(fdubuis8on@miamigov.com) 35-SW84 Street Corridor improvement,($88,000)(Public WorksDep.CityofSouth Miami,Completed February 2012)(Keith A.Ng 305403 2072)(kng@80UthmiamlH.gov) 36-Long Kay State Park Campground EntranceModification ($40,450)(Florida Departmentof Environmental Protection,CompletedJuly2012)(FredHand 850488 8322)(Fred.Hand@dep.state.fl.us) 37-FOOTLAP Roadway Improvementa Project ($117,371)(Public WorksDep.CityofSweetwater,Completed July2012)(Eric Gomez 305-653 5457)(egomez.egsc@att.net) 38-SR 94/SW 88 ST/KendallDr.at SW 142 Ave ($134,843)(Florida Departmentof Transportation,Completed October2012)(RolandRodriguez 305-345 0886)(nodriguez@plnnaclecel.com) 30-Phase IVDrainage Improvement Project ($143,830)(Village ofPalmettoBay,CompletedNovember2012) (Danny Casals 305-068 5091)(dcttals@palmettobay-fl.gov) 40-Kllllan ParkRoad Stormwater Improvement ($218,142)(Village of Pinecrest,CompletedDecember2012) (Daniel Morettl 305-669 6016)(moretU@pinecrBSt-fl.gov) 41-Progress Rd.Roadway and Drainage Improvements ($106,822)(City of South Miami,CompletedJanuary 2013)(JorgeVera 305-403 2072)Qvera@southmlamifl.gov) 42-ARRA Municipalities Group B:City of Miami Gardens Bus Shelters ($884,000)(MiamiDadeTransit, Completed March 2013)(JavierSalmon 786-473 4710)Qsalmon@miamidade.gov) 43-1-195/Julia Turtle from SR 5/Blscayne Blvd to 8R 807/AltonRd-Bike Path/Trail ($121,520)(Florida Department of Transportation,Completed March 2013)(Roland Rodriguez 305445 0886) (rrodriguez@pinnaclecei.com) 44-NW 8th ST &NW14CT Roadway andDrainage Improvementa ($425395)(Cityof Miami,CompletedMay 2013)(RobertFenton 786-263-2133)(rfenton@miambov.com) 45-Friedland ManorDrainage Improvements ($406,867)(Cityof Florida City,Completed June 2013)(Sean Compel 786-502-0770)(sean.compel@8tantec.com) 46-SR 9(NW27 Ave),FromNW79ST to NW84ST Roadway Improvement^ ofTransportation,Completed July 2013)(RolandRodriguez 305-345 0608)(rrodriguez@plnnaclecel.com) 47-Sidewalk Improvementa along SR MAI Collins Ave @ SR 826/NW 63 ST.($208,821)(Florida Department of Transportation,CompletedOctober 2013)(RolandRodriguez 306-345 0668)(rrodriguez@pinnaclecei.com) 48-Doral Trolley Route 3 Infrastructure Improvementa.($114,216)(Cityof Doral,CompletedNovember2013) (RudydelaTorre 786-238-5012)(mdy.ddatorre@cltyofdoral.com) 40-Doral Trolley Infrastructure Improvementa Cltywlde.($217,348)(Cityof Doral,CompletedDecember2013) (RudydelaTorre786-236-5912)(nidy.delatorre@cityofdoral.com) 50-Wild Lime ParkParking Expansion andConcreteWalkway.($201,442)(Miami DadePark&Recreation Department,CompletedJanuary2014)(Leroy Garcia 786-210-5937)(garcial@mtamldade.gov) 51-Blscayne Island Drainage Improvements ($736,658).(Cityof Miami,CompletedMarch2014)(Valentine Onuigbo 786-447-8817)(vonuigbo@miamigov.com) 52-Beacom Project Area Improvementa-Phase I ($767,132)(Cityof Miami,Completed March 2014)(Robert Fenton 786-283-2133)(rfenton@miamigov.com) 53-Sunaet Drive Downtown Median.(84,683)(City of South Miami,Completed October 2014)(Rtcardo Ayala 305-403-2072)(rayata@southmiamifl.gov) 54-NW11 ST from27 Ave to 37 Ave.Area Roadway Improvementa.($188,874)(Cityof Miami.Completed October 2014)(ValentineOnuigbo 786*447-9817)(vonuigbo@mlamigov.com) 55-DlatrlctwMe Minor Aaphalt Repair.($250,000)(FOOT,District 8,Completed December 2014)(JohnGarzia 305-640-7177)(john.garzia@dot.8tate.fl.ua) 56-MultipleParka -ADA Improvementa ($338,741.88)(Miami DadePark&RecreationDepartment,Completed January2015)(Leopoldo Aybar 786-201-2422)(aybar@mlamidade.gov) 57-NW18PLRoadandDrainage Improvementa ($473,087.20)(City of Miami,CompletedMarch2015)(Robert Fenton786-263-2133)(rfenton@mlamlgov.oom) 58-Lummua ParkLanding ($222,612.81)(City of Miami,Completed May 2015)(David Adato 305-416 1888/ 59-BeaeomProjectAreaImprovementa-Phase II ($818,978.96)(City of Miami,Completed July2015)(Robert Fenton 786-263-2133)(rfenton@mlamfgov.com) ENGINKRING CONTRACTOR-UC:E-251302 11020 SW 55 8T„MIAMI,FL 33188 PHONE:788-281-2848 FAX:7884724831 maanofc@wahoo.com OFFICE ORGANIZATION CHART mum ENOflffiEROiOC»finiACTOR-LIC:&251302 11820 8W 88 8T,IUAMI,PL 88188 PHONE:768481-2848 PAX:78*4124831 PROJECT ORGANIZATION CHART [Mdi ^fjRfc- Engln—ring Contractor -Lie.E-251302 11020 8W558T.,Miami,FL 33165 Phone:786481-2848 Fax:7884724831 "TOflffofcftyalloOtCem j RESUME: MARIOGONZALEZ Superintendent/Project Manager of Maggolc lac 1 i GonzalezisaRoadway Constmction andCivil Engineer withover24years of progressive experience inthe fields ofhighway and railway design,construction,maintenance,and operations.| EDUCATION: InstituteSuperior Polit&mico(Hi*^ Degiee:INGENIERO VIAL (RoadwayConstructionEngineer),July1988.Thisis equivalent toaBachelor . ofScience inCivil Engineering (BSCE)froma regionally accredit^institution ofhighereduw States.E Universidad Cenfralde Venezuela,Caracas,Venezuela. Degiee:INGENIERO CIVIL (CivilEngineer),July 1997. CERTIFICATIONS: -TROXLER Electronic*Ub-Nuclear (2001 ft2004) -FDOT-MUTCD/Mamtf?T]flnce ofTraffic,Intermediate Level (2014) -ASPHALTPA\WGTECHMCIAN-Level 1(2004) -EARTHWORKCONSTRUCTIONINSPECTION--Level 1(2005) -Ad,Concrete FieldTesting Techmman-Grade 1.(2005) -FDOTConcreteFieldInspectorSpecifications.(2005) LICENSES: -General EngineeringContractor -Registeredand Certificate State ofHoridaUndergraundUtilMesC^mtractor. -Registered General Contractor State ofFlorida WORK EXPERIENCE: MAGGOIX INC.,Miami,Florida,USA (June2005to Present). Gonzalezistheowner ainipresident ofMaggolcIiic.,thisisanEn Spedaiizedin WogkE*Wffft& -Beaeom Project Area Drainage end Road Improvements PhaseII(City ofMiami)2015 -NW 18 PL Dralange and Read Improvements (City ofMiami)2015 -Multiple Parks-ADA Improvements (MiamiDadePark&RecDep.)201S -Distrlctwide Minor Asphalt Repair (FDOT)2014 -NW 11 ST from NW 27 Ave to37 Ave Area RoadwayImprov.(City ofMiami)2014 -Sunset DriveDowntownMedian(City ofSouth Miami)2014 -Dorm Ave Drainage Improvements (City ofSouthMiami)2014 -Beaeom ProjectArea Improvements-PhaseI(City ofMiami)2013 -wild lime Park Parking ExpansionandConcrete Walkway (MiamiDadeParkft Rec Dep.)2013 -Blscayne Island Drainage Improvements (City ofMiami)2013 -SMewalkbnpiwementsaloiigSRAlA/Collhu -SR 9 (NW 27 Ave)@ NW 79 ST Roadway Improvements (FDOT)2013 -Friedland ManorDrainage Improvements (City ofFlorida City)2013 -NW 8 ST A NW 14 CT Roadway &Drainage Improvements (City ofMiami)2013 -1-195/Julia Tuttie Bike Path/Trail (FDOT)2013 -ARRA Municipalities Group B:City ofMiamiGardensBusShelters(MiamiDadeTransit)2013 -Progress Rd Roadway ft Drainage Improvements (City of SouthMiami)2012 i -Kiliian Park Rd Stormwater Improvements (Village of Pinecrest)2012 I -Phase IV Drainage Improvements.(Village ofPalmettoBay)2012 -SR 94/Kendall Dr atSW 142 Ave Roadway Improv.(FDOT)2012 | -FDOT LAP Roadway Improvements.(City ofSweetwater)2012 -SW 64StreetCorridorImprov.(City ofSouthMiami)2012 i -District#2atywideADASidewalkImprovements.(atyofMiami)2012 j -Long Key Stete Park-Resurface Campground 2012. -Suncrest Dr.ft Mom Ranch Rd.Stormwater Improvements (Village of Pinecrest)2011.j -SR 909 (Alton Road)at West 52 Street Drainage Improvements (FDOTDistrict6)2011 -SW 19TerraceRoadway ft DrainageImprovements (CIP,City ofMiami)2011. -Tamiarnl CanalMlccosukee linear Park (Miami-Dad^ -District #4 Cltywlde ADA Sidewalk Improvements (City ofMiami)2011 -MIANW36Streetft67Ave Intersect!on Improvement (concrete )(Aviation Department M-D County) 2011 -MIA Building 3050Parking Lot Improvementa(Aviation Department M-DCounty)2011 -District #1 Cltywlde ADA Sidewalk Improvements (City ofMiaim)2011 -District#3 Cltywlde ADA Sidewalk Improvements (City ofMiami)2011 -Intersection Realignment SW 139 Terr,ftSW 140 Br.and Esat Guava ST One Way Street Conversion.j (Village ofPalmettoBay)2010 -Installation of SidewalksandRampsalong NE12 Ave.(City ofNorthMiami)2010. -AD Barm»Park Asphalt Walkways..(M-DCounty Paik ft Recreation)2010. -Golden Shore Park PaversSidewalks.(City ofSunnyIsles).2010 -District I,SidewalksRepair.(City ofMiami).2010 -Crandon Park ADA ParkingSpaceStripingandSigns.(M-DCounty Paikft Recreation)2010. -District II,Sidewalks Repair.(City ofMiami).2010 -HarborDrive Lighting andResurfacingImprov.(VillageofKey Biscayne)2010 -Blue Read Roundabouts andDrainage.(City ofCoralGables)2010 -Drainage RetentionImprovementsofStateRd.907(Alton Rd.)at Allison Drive.MillingandAsphalt Resurfacing.(FDOT,District6)2009 -Country Club of Miami Park Concrete and Asphalt Walkway (Miami-Dade County,Park ft Recreation j Dep.)2009.j -BrendwoedPark Aaphalt Walkway.(City ofMiami Gardens)2009. -WestLittleRiver Improve Asphalt Driveways.(Miami-Dade County Office of Community and Economic i Development)2008. -West Perrine Park ConcreteSlabsandPouredSafetySurface.(M-DCParkand Recreation)2008 -AaphaltPavementRepair.Florida Department of Transportation (District 6).2008-2009,2009-2010 and 2010-2011. -Improve Intersections Countywide Project,Include Milling and Aaphalt Resurfacing.(Sidewalk,Handicap I Ramps,Cub ft Gutters,Pavers,New Pavement,Drainage,Sodding (M-D County Public Work Dep.)2008 -Seal Coatand Restrt^ing of Stetfon 13andLogistics 2008 -DolphinArchaeologicalSiteSidewalkConstruction.(M-DCountyPaik andRecreation)2008. -Otymplc ParkSidewalksConstruction.(M-D CountyPark andRecreation)2007 -Norman ft JeanReachParkFoulBallNetting.(M-DCounty Paik andRecreation)2007 -Drainage ImprovementProjectforNW22CourtfromNW107 ST toNW112ST.(M-DCountyPublic Woik Dep.).2006,etc QftOT Flflcea T*ftefp *7mftllflz wagwnririnp: SRSl^GINEERmG,mC.,Miami,Horida,USA (August 2006 toJuly2007). Construction Ffeld Inspector of1^^(Public Woik Department,Miami-Dade County Projects). -AllaphattaPhasel. -Hardwood Village Phase n. BERMELLO,AJAMIL ft PARTNERS,INC.,Miami,Florida,USA (May 2005 toJuly2006). Quality Control (QC)Construction Inspector (DOT Projects):(Earthwork,Concrete and Asphalt). -Okeechobee Road.(W12 Aveto Palmetto Expwy) -MiamiGarden Drive.(NW2AvetoNW17Ave.) -Biscayne Blvd.(NW 96STto NW 104ST) -GoldenGatePkwy(Naples) -Florida's Turnpike (Griffin Rd to Sunrise Blvd).\ -A-l-A(KeyWest).[ j MARLIN ENGINEERING INC.,Miami,Florida,USA (October 2000-May 2005).\ February2004to May 2005. Construction Field Inspector ofDraiiiage and Roadway (FEMA-DERM,Miami-Dade Ccmnty Projects).1 Activities Included: Verify of stormdrainagestructures in accordance with die approved shop drawings,installation ofdrainageand pollutioncontrol structures,drainagepipe inverts,joints,seals,FrenchDrain Systems,solidpipeplacementand beddingmaterial.ChecktheContractor'scompliance withall Maintenance of Traffic. Reconstruction of Pavement,RoadwayMillingand Resurfacing;reconstruction of CurbandGutterand Sidewalks;Site Restoration,includingGrading ofSwales,Sod Placement;etc Requirements: -Ensurethequalityofthe constructtonwori^asperti Manual,FDOTStandards,andProjectContract Documents. -Ensurethefull restoration ofthe project,iircludrng site cleanli^andsodplacement -Keep reconls ofdaify activities,daUy -Resolve complaints byresidents resulting from construction activities.J ! March 2001 to February 2004:Pfo|otfign^^j ProjectEngineerforthedesign,roadway restoration,andstormdrainagesystems improvement,including independent sitesand community.(DERM/FEMA Program administered by dm Division of Recovery and Mitigation-DORM)in Miami-Dade County and City of Miami Storm Drainage Improvement Program).| Working closely with Microstation and AutoCAD software.j October 2000 to March 2001 and October 2002 to February 2003:Roadway Inspector.j Surveying,inspecting and drawing sketches for roadway restoration projects in Q.N.LP,Public Work ( Department ofMiami-Dade County.Inspecting and supervising construction of asphalt patching,milling and | EN0fNEERma00NTRACT0R-UC:B«iat2 11020 aw ssar^Muau.flsmwPHONE:7BMS1^»M FAX:7W47248S1 MAGGOLC GOVERMENT REFERENCE LISTING 1)Company Nama:MiamiDade County Public Works Department Address:111 NW1*ST14 Floor.Miami.FL 33128 Contact Parson:Joaquin Rabaasa Telephone #305-289 9822.305-989 4943 2)Company Nama:MiamiDadePark&RecreationDepartment. Address:275 NW 2nd Street.4*Floor,Miami,FL 33128 Contact Parson:Ruben Teurbe Tolon/Leroy Garcia Telephone #305 756 5485 3)Company Name:Office of Community &Economic Development M-D County Addroea:701 NW 1st CT14 Floor Miami.FL 33136 Contact Person:Mario Bentos Telephone #786 489 2112 4)Company Name:Florida Departmentof Transportation /Pinnacle ConsuHino Addre8a:1773 NE 206 Street NorthMiami Beach,FL 33179 Contact Person:Roland Rodriguez Telephone #305640 7185 5)Company Name:City of Miami Gardens Address:1060 NW 163 DrMiami Gardens.FL 33169 Contact Person:Osdel Larrea Telephone #305-622 8000 Ext.3107 6)Company Name:City of Miami Addreea:444 SW 2nd Ave.8 Floor,Miami FL 33130 Contact Person:Fabiola Dubuisson Telephone 0 305 4161755 7)Company Name:City of North Miami Addreaa:776 NE 125 Street,NorthMiami,FL33161 Contact Person:Gerardo Hernandez Telephone #3058959831 8)Company Name:Village of Key Blscayne Address:88 West Mclntyre Street,Suite220Key Blscayne,FL 33149 Contact Person:Armando Nunez Telephone #3053657574 9)Company Name:City of Coral Gables Addreea:2800 SW 72 Ave Miami,FL 33155 Contact Person:Ernesto Pino Telephone #305 926 2784 10)Company Name:City of Miami -Capital Improvement Program Addresss444 SW 2nd Ave,8th Floor,Miami,FL33130 Contact Person:Maurice Hardfe Telaphone#786-229 5463 11)Company Name:Stantec Address:901 Ponce de Leon Bivd Suite 900Coral Gables,FL 33134 Contact Person:Sean Compel Telephone #305-445 2900 ExL 2230.786-602 0770 12)Company Name:Village of Pinecrest Address:10800 Red Road,Pinecrest FL 33156 Contact Person:DanielF.MoreM Telaphone #306-669 6916 13)Company Name:City of Florida City Address:404 West Palm Dr.Florida City.FL 33034 Contact Person:Richard Stauts Telephone #305 2476221 /305 7721157 14)Company Name:Coy of South Miami Address:6130 Sunset Drive South Miami 33143 Contact Person:Rlcardo Ayala Telephone #305-403 2063 15)Company Name:City of Miami -0001181 Improvement Program Addrsss:444 SW 2nd Ave,6th Floor,Miami,FL33130 Contact Person:RobertFenton Telephone #786-263-2133 UST OP PROPOSED SUBCONTRACTORS AND PRINCIPAL SUPPLIERS Citywide Drainage Improvement Projects RFP#PW-20I5-I9 Respondent shall 1st ail proposed subcontractors,If subcontractors are allowed bythetermsofthis Solicitation to beosed on this project If they areawarded the Contract Landscape O&teUote.Ft toSoddingandTurfWorkCocoS+*P <&€tr-H4& Tei. 963-i 42/wi/faa- Bectrfcal Irrigation Paving (&$k WSffl.^aX Graphics & %2faL A******W^,4irrw6<fod»*W>M »>*Mi-root Excavation Structures Plumbing Mnting TestingLaboratory Soil Fumigator Signs Other This D«shall be provided totheCityofSouth Miami bythe apparent lowestresponsive and responsible Bidder wftMn five(5)business days after Bid Opening. END OF SECTION is NON COLLUSION AFFIDAVIT STATE OF FLORIDA COUNTYOF MIAMI-DADE ) (I)Me/iihen-hey to/are the &*)l*JLS' .beingfirstduly sworn,deposesandstates that: (?) P) (4) (5) (Owner,Partner,Officer,Representative or Agent)of theRespondentthathassubmitted the Jje£heflliey Ware fully Informed concerning the preparation and contents ofthe attached IVoposal and of all pertinent circumstances concerning such Proposal; Such Proposal is genuine and isnota collusive or sham Proposal; Neither the said Respondent nor any of hs officers,partners,owners,agents,representatives, employees or parties In Interest,including this affiant,have In anyway colluded,conspired,connived or agreed,diYec^orbwflrecdy,withanyother Respondent,firm,or person tosubmita collusive or sham Proposal in connection withthe Work for which the attached Proposal hasbeen submitted;or to refrain from Bidding or proposing In connection with such Work;or have In any manner,directly or indirectly,sou^rt by agreement or collusion,or communication,or conference withany Respondent,firm,orperson to fixanyoverhead,profit;orcost elements ofthe Proposal orofany other Respondent;or to fixany overhead,profit,orcost elements ofthe Proposal Price orthe Proposal Price ofany other Respondent;orto secure through any collusion,conspiracy,connivance, or unlawful agreement any advantage against (Recipient),orany person Interested In the proposed Work; The price or prices quoted In the attached Proposal are fair and proper and arenot tainted byany collusion,conspiracy,connivance,or unlawful agreement on the partoftheRespondentoranyother ofIts agents,representatives,owners,employees or parties of Interest,Incldoftg this affiant and delivered inthepresenceoft Print Name and Title I ACKNOWLEDGEMENT STATE OF FLORIDA ) ) COUNTY OF MIAMI-DADE ) On this the /JIS day of ^^V/7".20 /£before ma the understated Notary Public of the State of Florida,personally appeared (Name(s)of Individuals)who appeared before 16 notary).rf/frit*&£>*>z*/tz> within instrument;and he/she/theyacknowledge that he/she/theyexecuted It WITNESSmyhandand official seal. and whoseDwne(s)Js/are Subscribed tothe NOTARY PUBLIC: SEAL OF OFFICE MO*!*! fe.VUNfSft sWUCrUDOCABAUJWO hg MYCOMMI88IONiFF8WWe jjF EXPIRES July 14.201© I416S flrjrtiMtoiMwtirMfc^ccff' 17 i Rrtet,Stunportype ascoflvnhifoncd.) Personally known tome,or Personal Identification: Type of Identification Produced 'Did take anoath,or Did Not take anoath. PUBLIC ENTITY CRIMES AND CONFLICTS OF INTEREST | f Pursuant to the provisions of Paragraph (2)(a)ofSection 287.133,Florida StateStatutes-"Aperson or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a j Proposal or bid on a Contraa to provide any goods or services to a public entity,may not submit a Bid or !| proposal for a Contract with a public entity for the construction of repair of a public building or public work,may j, not submit bids or proposals on leases or real property toa public entity,may not be awarded to perform Work j asa RESPONDENT,Sub-contractor,supplier.Sub-consultant,or Consultant under a Contract with any public , entity,andmaynottransact business withany public entity In excessofthethresholdamountCategoryTwoof j Section 287.017,Florida Statutes,for thirty sbc (36)months from the date ofbeing placed on the convicted vendor 1UstT.j The award of any contract hereunder is subject to the provisions of Chapter 112,Florida State Statutes.j Respondentsmust disclose withtheir Proposals,thenameofany officer,director,partner,associateoragentwho Is alsoanofficer or employeeofthe Qty ofSouth Miami or its agencies. SWORN STATEMENT PURSUANT TO SECTION 287.133 (3)(a), FLORIDA STATUTES.ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. I.This sworn statement Is submitted to //•/*^*/mi t [print'name ofthe public entity]iprtm iruiiu or uiu puwrc vnui/j at Individual's rape and tideL.*v ~4JC-* [printnaneW entity submitting sworn statement] whose business address is f(O90t>S~tO SS &P and (If applicable)Its Federal Employer Identification Number (FEIN)Is 2^~33g^*^»it?lftha entityhasno FEIN,indude the Social SecurityNumberofthe Individual signing this swornstatement: =,) 2.I understandthata "public entity crime"as defined In Paragraph 287.133 (l)(g),Florida Statutes. meansa violation ofanystate or federal lawbyapersonwithrespecttoanddirectlyrelatedtothe transactionof business withany pubtk entity or withan agency or political subdivision ofanyotherstate or oftheUnited States,including,butnot limited to,any bid,proposal or contractforgoods or services tobe provided toany public entityoran agency or political subdivision ofanyotherstateorofthe UnitedStatesand involving antitrust,fraud,theft,bribery,collusion,racketeering,conspiracy,or material misrepresentation. 3.I understandthat "convicted"or "conviction"as defined in Paragraph 287.133 (I)(b),Bojjsb Statutes*meansa finding ofguilt or a conviction ofa public entitycrime,withorwithoutan adjudication of guilt,In anyfederal or state trial court ofrecord relating tochargesbroughtbyindictment or InformationafterJuly I,1989,asaresultofaJury verdict;non-Jury trial,or entryofapleaofguilty or nolo contendere. 4.I understandthatan "affiliate"as defined in Paragraph 287.133 (I)(a).Florida Statutes,means: (a)Apredecessor or successorofapersonconvictedofa public entity crime,*or (b)Anentityunderthecontrolofanynaturalpersonwhoisactiveinthe management oftheentity andwhohasbeenconvictedofa public entitycrime.Theterm "affiliate"includes those officers. 18 directors,executives,partners,shareholders,employees,members,and agents whoareactive In the management of an affiliate.Theownershipbyonepersonof shares constitutinga controlling interest In any person,ora pooling of equipment or Income among persons whennotfor fair marketvalueunderanarm's length agreement,shall bea prima facie casethatoneperson controlsanotherperson.Apersonwho knowfn^y enters Into a joint venturewithaperson whohasbeenconvicted of a public entitycrimeIn Florida duringthe preceding 36months shall be considered an affiliate. I understand thata"person"as defined In Paragraph 287.133 (1)(e),Florida Statutes,means any natural personorentity organized under die laws of anystateorof die United Stateswiththe legpl power to enterintoa binding contractandwhichbidsor proposal or applies to bid or proposal on contracts forthe provision ofgoodsor services letbya public entity,or which otherwise transacts or applies to transactbusinesswitha pubDc entity.Theterm "person"Includes those officers,directors, executives,partners,shareholders,employees,members,andagentswhoareactiveIn management of an entity. Based on information andbelief,the statement which I have marked below Is true Inrelation to the entitysubmittingthis sworn statement [Indicate whichstatement applies.] ^Neithertheentitysubmittingthissworn statement norany of its officers,directors,executives, partners,shareholders,employees,members,oragentswhoareactivein the management of theentity, norany affiliate oftheentity has been charged withand convicted ofa public entitycrime subsequent to July 1,1989. .The entitysubmittingthisswornstatement;oroneormore of its officers,directors,executives, partners,shareholders,employees,members,or agents whoare active inthe management oftheentity, oran affiliate oftheentityhasbeen charged withandconvicted ofa public entitycrime subsequent to July 1,1989. Theentitysubmitting this swornstatement,or oneor more of its officers,directors,executives, partners,shareholders,employees,members,or agents whoareactive in the management oftheentity, oran affiliate oftheentityhasbeen charged withandconvicted ofa public entitycrimesubsequent of July I,1989.However,therehasbeena subsequent proceeding beforea Hearing Officerofthe State of Florida,Division of Administrative Hearings andthe Rnal Orderenteredbythe Hearing Officer determinedthatftwasnotinthe public interest to place theentity submitting thisswornstatementon the convicted vendorlist [attach acopyofthe final order.] I UNDERSTAND THAT THE SUBMISSION OF THISFORM TO THE CONTRACTING OFRCER FOR THE PUBUC ENTITY INDENTURED IN PARAGRAPH I (ONE)ABOVE IS FOR THAT PUBUC ENTITY ONLY,A)i|DTHATTHIS FORM ISYAUD THROUGH DECEMBER 31 OFTHE CALENDAR YEAR IN WHICH IT I ~ REQUIRED TO INFORM THE PUBUC ENTITY PRIOR TO ENTERING THRESHOLD AMOUNT PROVIDED IN SECTION 287.017,FLORIDA/ CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. UNDBtSTAND THAT I AM iCT IN EXCESS OF THE CATEGORY TWO OF ANY Sworn to and subscribed before methis XO Personally known *^ .day of OR Produced idem (Type of Identification) Form PUR 7068 (Rev.06711/92) YUNBOY BARACALOOCABAUEHO MY COMMtOOION i FF8S9998 EXPIRESJuly14,2019 19 Notary Public -State of.£±_ My commission expires J^///t/20/^i ited,typed or stamped commissioned(Printed,typedorstamped nameofnotary public) DRUG FREE WORKPLACE Whenever twoor more Bids or Proposals whichare equal with respect to price,quality and service are received bytheStateorbyany poUtical subdivisions forthe procurement of commode Proposal received from a business that certifies thatithasimplemented a drug-free workplace program shall be given preference inthe award process.Established procedures for processing tie Bids or Proposals shall be followed if noneofthetied vendors have a drug-free workplace program.In ordertohavea drug-free workplace program,abusinessshall: 1)Publish a statement notifying employees thatthe unlawful manufacture,distribution,dispensing possession,oruse of acontrolledsubstance is prohibited in the workplace and specifying the actions that shall be taken against employees for violations ofsuch prohibition.\ 2)Inform employees about the dangers of drug abuse In the workplace,the business'policy of \ maintaining a drug-free workplace,any available drugcounseling*rehabilitation,and employee '{ assistance programs,and the penalties that may beImposed upon employees for drug abuse j violations. 3)Giveeach employee engaged in providing the commodities or contractual services thatareunder Bid acopyofthestatement specified in Subsection (I). 4)In thestatement specified in Subsection (I),notHy the en^oyees,that,asacondltionofworking ofthecommoditiesor contractual servicesthatareunder Bid,heemployee shall abidebythe terms ofthestatementand shall notifythe employee ofany conviction of,or plea of guilty or nob contendere to,any violation ofChapter893orofanycontrolled substance lawof theUnited Statesorany state,fora violation occurring in the workplace nolaterthan five (5)business days after such conviction. 5)Imposea sanction on,or require the satisfactory participation Inadrugabuse assistance or rehabilitation program,if such Isavailable Inthe employee's community,byanyemployeewho is so convicted. 6)Make a good bj/a\/ftbfyfo/ontinue to maintain a drug-free workplace through Implementation of this As the person authorized to sj§n ttfe stfcp&pRt,Icertify that this firm complies folly with the above requirements. RESPONDENTSSignature:, Print Name:fdartfi ffi/*A^ZrOVi 20 ACKNOWLEDGEMENT OFCONFORMANCE WITH OSHA STANDARDS | TO THE CITY OF SOUTH MIAMI | ( Wa MOJ^^^LC^3ZJC.,(Name of CONTRACTOR),hereby acknowledge and agree that CONTRACf6W#r the Cltywlde Drainage improvement Projects project as specified have the sole responsibility for compliance withalltherequiranentsofthe Federal Occupational Safetyand Health Actof 1970,and all State and local safetyandhealth regulations,andagreeto Indemnify andholdharmlessthe City ofSouth Miamiand ^Consu|tanc^a^alns^anyand all liability,cfaJms,damages,losses and expenses titey may Incurdue to the failure of/Subcontractors names):,W &ffi£uz*Agar BY: Name1 21 as | J-«*fr« AFFIDAVIT CONCERNING FEDERAL AND STATE VENDOR LISTINGS The person,orentity,whoIs responding tothe Qt/s solicitation,hereinafter referred toas "Respondent",must certify thatthe Respondent's nameDoesNot appear on ohe State of Rorida,Department of Management Services, "CONVICTED,SUSPENDED,DISCRIMINATORY FEDERAL EXCLUDEDPARTIESand COMPLAINTS VENDOR LISTINGS". Ifthe Respondent's name Doesappear ononeor all the "Listings"summarized below,Respondents must"Check if Applies"nexttothe applicable "Ustlng."The'listings"can be accessed through the following linktothe Florida Departmentof Management Services website: hmr/fartvwdimf^ ended dlscrhninatorycomplafats^vendor lists I UNDER PENALTY OF PERJURY ,y—ft«r referred to as the "Dedarant")state,under penalty of perjury, that the following statements are true and correct:y //^>/*/**&+/&.^./J(1)Irepresent the Respondent whose name Is a4a&%P*^^5^/"*l>€*ymt*t'*,%S (2)Ihave the following relationship with the Respondent jg^HPwg/bgiXP"(OWher (If Respondent Is a sole proprietor),President Of Respondent Is a corporation)Ruti&r (If Respondent Is a partnership),General Partner (IfRespondentIs alimited Parmer^ Company). (3)I havereviewedthe Florida Department of Management Services websiteatthe following URL address: ht^/www.dmsjnyflortdaxonVbu$Iness_op scrimfnatoiy^oomplalnts^vendorJKsts (4)I haveenteredan V oracheck mark besideeachllstingfcategory setforthbelowifthe Respondent's name appears in thelist found on the RoridaDepartment of Management Services websiteforthat category or listing.IH did notentera nreirtc besidea Hstingfcate^ Respondent's namedoesnot appear onthe fisting forthat category In the Florida Department of Management Services website as ofthe date of this affidavit. Check If Applicable Convicted Vendor List Suspended Vendor Ust Discriminatory VendorUst .Federal ExcludedPartiesUst Vendor Complaint Ust MFURTHERDECLARANT5AYETHNOT.J I _^_jT^T^tiJie ,A %^DECLARATION Ul i following statements aretrueand correct: ACKNOWLEDGEMEI STATE OF FLORIDA ) COUNTY OF MIAMI-DADE ) On th\yhQ££2-dayjif ^r^^HkUT .20 /£*before me,the undersigned authority,personally appeared *14h/WA (£0*J?Jb/i&who Is personalty know to me arwho provided the following Identification —and who took an oath or affirmed jHa^that he/she/they executed the foregoingAffidavitas the Declarant WITNESS myhandand official seal. Notify Public,Stateof RftiRya JBLIC: SEAL KOTARYFUBL.C,Wit/jltf €)#A<H#lQO VUN6»V lARACMOOCWWirnO g MVCOMM!S8»ON#FF8a»96 EXPIRES July 14,2019 1SS 22 ICbfi oomn \of Notary niblic Print, Stamportypeas commissioned.) RELATED PARTY TRANSACTION VERIFICATION FORM I f^gyrto SoQl^^^^M^Vi and on behalfof M(l£fr<*LC'*&*Q ("Rrm")have Nome ofRepresentative OmpanftVendorlEnUtf read the City of South Ntfnb'fOt/ys Codeof Ethics, Section 8A-I ofthe City'sCodeof Ordinances and I hereby certify,under penalty ofperjurythattothebestofmy knowledge,informationand belief. (1)neither I northe Firm haveanyconflictofInterest(as defined insection 8A-I)withregardtothecontract or business tint I,and/or theRrm.am(are)abouttoperformfor,ortotransactwith,the City,and (2)neither I noranyemployees,officers,directors ofthe Rrm,nor anyone whohasa financial Interestgreater than 5%In the Rrm,has any rebtive(s),as defined in section 8A-I.whoisan employee ofthe City orwho is(are) an appointed or elected official ofthe City,orwho is(are)a member ofanypubfic body createdbytheCity Cbmmisslon,ie,aboardor committee oftheQty,[while the ethics code still applies,iftheperson executing this form Isdoingsoon behalf ofa firmwhosestock Is publicly traded,the statement Inthis section (2)shall bebased solely onthe signatory's personal knowledge and he/she is not require to make an Independent Invesdgition asto the relationship of employees orthosewho have a financial interest inthe Rrm.];and (3)neitherI northe Rrm,nor anyone who has a financial Interest greaterthan 5%inthe Rrm,norany member of those persons'immediate family (I.e..spouse,parents,children,brothersand sisters)hastransacted orentered Intoanycontracts)withtheCityorhasa financial Interest,director Indirect,inanybusiness being transacted with the city,orwith any person or agency acting for the ©ity,other than as follows:he city, Juse '(If necessary,use a separate sheet to supply additional Information that will not fit onthis line;however,you mint make reference,onthe above fine,tothe additional sheet and the additional sheetmust be signed under oath),[while the ethics codestill applies,ifthe person executing this form Is doing soon behalf ofa firm whose stock Is pubHdy traded,the statement In thissection (3)shall be based solely onthe signatory's personal knowledge and he/she Isnot required to make an Independent Investigation astothe relationship ofthosewho havea financial InterestIntheRrm.];and (4)no elected and/or appointed official or employee ofthe City ofSouth Miami,or any oftheirImmediate family members (I*-spouse,parents,children,brothers and sisters)has a financial interest;directly or Indirectly,In the contraa betweenyou and/oryourRrmandthe City otherthanthe following Individuals whose Int^est Isset forth following their use a separate names;>Q/^f (tfnecessaiy,use a separate sheetto suppfy additional^ make reference,onthe above line,tothe additional sheet and the additional sheet must be slffied under oath). Hie names of ail Chy employees andthatof ail elected and/orappointed chyofficials orboardmembers,who own,directly or Indirectly,aninterestof five percent (5%)or more ofthetotalassets of capital stockbithe firm are as follows:> t*M (If necessary,use a separate sheet to supply additional Information thatwill notfiton this fine;however,you must make reference,onthe above line,tothe additional sheet and theadditional sheet must be signed under oath), [while the ethics code still applies,ifthe person executing thisform is doing soon behalf ofa firm whose stock Is publicly traded,the statement In this section (4)shall be based solely onthe signatory's personal knowledge and he/she Is not required to make anIndependent Investigation as tothefinancial Interest In the Rrm ofcity employees,appointed officials orthe immediate family members ofelected and/or appointed official or employee.] (5)I and the Rrm further agree notto use or attempt to use any knowledge,property or resource which may come to usthroughour position of trust;or throutfi our performance ofourdutiesunderthetermsofthe contract with the City,to secure a special privilege,benefit,or exemption for ourselves,or others.We agree that we may not disclose or use Information,not available to members ofthe general public,forour personal gain or benefit orforthe personal gain or benefit of any other person or business entity,outside ofthe normal gain or benefit anticipated throughthe performance ofthe contract (6)I and the Rrm hereby acknowledge thatwe have not contracted or transacted any business with the City or any person or agency acting forthe City,and thatwe have not appeared in representation of any third party 23 beforeany board,commission or agency oftheCity within thepasttwo years otherthanas follows:A)/A (if necessary,usea separate sheettosupplyadditional information thatwillnotfitonthis line;however,youmust make reference,ontheabove line,tothe additional sheetandthe additional sheetmust bested underoath). X:\Purchasing\Vendor RegIstrationM2.28.l2 RELATED PARTY TRANSACTION VERIFICATION FORM [3].docx (7)Neither I noranyemployees,officers,or directors ofthe Firm,noranyoftheir Immediate family (I.e„asa spouse,son,daughter,parentbrotheror sister)is related by blood or marriage to:(I)anymemberoftheCity Commission:fU)anycityemployee;or (III)any member of any board or agency oftheCityother than as follows: ^y/Ar '(If necessary,usee separate sheet to supply additional information thatwill not fit on thisline;however,you must make reference,onthe above line,tothe additional sheetandthe additional sheetmustbe signed underoath),[while theethicscode still applies,if the person executing this form is doing soon behalf ofa firm whosestock is publicly traded,thestatementinthis section (7) shall bebasedsolelyonthe signatory's personal knowledge andhe/sheisnot required tomakean Independent Investigation astothe relationship bybloodor marriage of employees,officers,or directors ofthe Rrm,orofany oftheir Immediate femlfy to any appointed or dectedoffidals oftheCity,or to theirimmediate (8)No Other Rim noranyofficersor directors ofthatOtherRrmoranyonewhohasa flnandaJ interestgreater than5%inthatOther Rrm,noranymemberofthose persons'immediate family 0.e*spouse,parents,children, brothero andsisters)rror any of my immediate^ respondedto a solicitation bytheCityinwhich I ortheRrmthat I representor anyone whohasa financial interestgreaterthan5%inthe Rrm,oranymember ofthose persons'Immediate family (he.spouse,parents, children,brothers andsisters)havealsoresponded,other thanthefollowing 6>/A Of necessary,use a separate sheetto supply additional infonration that will notfitonthis fine;however,youmust makereference,ontheabove line,to the additional sheetandthe additional sheetmustbe signed under oath), [while theethicscode still applies,ifthe person executing this form Is doing soon behalf ofa firm whose stock is publicly traded,the statement In this section (8)shall be based solely onthe signatory's personal knowledge and he/sheisnot required tomakean independent investigation intotheOther Rrm,ortheRrm he/sherepresents,as totheir officers,directors or anyone having a financial interest In those Rrmsoranyofthelrany member ofthose persons'Immediate family.] (9)I andtheRrm affnee thatweare obligated to supplement thisVerification Form and informtheChyofany change In circumstances that would change our answers tothisdocument Specifically,afterthe opening ofany responses toa solicitation I andtheRrm haw an obligation to supplement thisVerified Form withthe name of all Related Parties who have also responded tothe same solicitation and to disclose the relationship ofthose parties tomeandtheRrm. (10)A violation ofthe City's Ethics Code,the giving of any false information orthe failure to supplement this Verification Form,maysubject meortheRrmto immediate termination of any agreement with the Chy,and the Imposition of tte maximwn fine and/or any penalties allowed bylaw.Additionally,violations may be considered by and subject to/fiction \fimeMlaml-Dade County Commission on Ethics.Under penalty have made aiiflgent Sett to investigate the matters to which Iam attesting hereinabove and that the stat^ made hereinanovezm/nie and correct tothe best ofmy knowledge,information and belief. Signature:/}**^fi /A A /i_ 24 Sec 8A-I.-Conflict of Interest and code ofethics ordinance. (a)Desfgnotfon. Thissection shall be designated andknownasthe "City ofSouth Miami Conflict ofInterestandCodeof Ethics Ordinance."This section shall be applicable to all dty personnel as defined below,andshall alsoconstitutea standard of ethical conductand behavior for ail autonomous personnel,quasi-Judicial personnel,advisory personnel and departmental personnel.The provisions of this section shall be applied ina cumulative manner.By wayof example,andnotasa limitation,subsections (c)and(d)n^y be applied tothesamecontractor transaction. (b)Derflnttiom.Forthepurposesofthis sectionthe following definitions shall be effective: (1)Theterm "commission members"shall refertothe mayor and the membersofthecity commission. (2)Theterm "autonomous personnel"shall refertothe members of autonomous authorities,boards and agencies, suchasthe dty communityredevelopmentagency andthe health facilities authority. (3)Theterm "quasi-Judicial personnel"shall refertothe members ofthe planning board,the environmental review andpreservation board,the code enforcement boardandsuch other Individuals,boardsand agencies of the dty asperform quasi-Judicial functions. (4)Theterm ladvisory personnel"stallrefertothe members ofthose dty advisory boards andagendas whose soleor primary responsibility Isto recommend legislation or give advice tothedty commission. (5)Theterm "departmental personnel"shall refer tothedty clerk,the dty manager,department heads,the dty attorney,and all assistants tothecity clerk,dty manager anddty attorney,howevertitled. (6)Theterm "employees"shall referto all other personnel employed bythedty. (7)Theterm "compensation"shall refertoanymoney,gift;favor,thingof value or financial benefitconferred or to be conferred,In return for services rendered or to be rendered (8)Theterm "controlling financial Interest"shall referto ownership,directly or indirectly,oftenparentormore ofthe outstanding capital stockin any corporation ora direct or Indirect interett often pereentormoreina finn, partnership,orother business entityat the timeof transacting business withthe dty. (9)Theterm "immediate family"shall refer tothe spouse,parents,children,brothers and sisters ofthe person involved. (10)Theterm 'transact any business"shall refer to die purchase or sale bythecityof specific goods or services for consideration and to submitting a bid a proposal in response toa Solidtation,a statement of qualifications In responsetoarequestbythedty,orenteringintocontract negotiations forthe provision onanygoods or services,whichever first occurs. (c)ProhlbMonontnMiactlngbuMtoenwhhthedtf. No person inducted intheterms defined In paragraphs (b)(I)through (6)and in paragraph (b)(9)shall enter Into anycontract or transact anybusiness In which that person ora member ofthe immediate family has a financial interest,director Indirect withthedtyorany person or agency acting forthe dty,and any such contract, agreement or business ef&gement entered In violation of this subsection shall renderthe transaction voidable. Willfulviolation of this subsection shall constitute malfeasanceInofficeandshallaffect forfeiture of office or position.Nothing hi this subsection shall prohibit ormakeillegal: (1)The payment of taxes,special assessments or fees for services provided bythedty government; (2)The purchase of bonds,anticipation notes orothersecurities that may beissued bythe cftythroi^i underwriters or directly fromtimeto time, Victor of prohibition.The requirements of this subsection may be waived for a particular transaction only by four affirmative votesofthedty commission after public hearing upon finding that: (1)An open-to-all sealed competitive proposal has been submitted by adty person as defined In paragraphs (b)(2), (3)and(4); (2)The proposal has been submitted bya person or firm offering services within the scope ofthe practice of architecture,professional engineering or registered land surveying asdefined bythe laws ofthestateand pursuant tothe provisions ofthe Consultants'Competitive Negotiation Act,and when the proposal has been submitted byadty person defined In paragraphs (b)(2),(3)and (4); (3)The property or services tobe Involved In the proposed transaction are unique and the dty cannot avail itself of such property or services without entering a transaction which would violate this subsection butforwaiver of Its requirements;and (4)Thatthe proposed transaction will beinthebest interest ofthedty. This subsection shall be applicable only to prospective transactions,and the city commission may In nocue ratify a transaction entered In violation ofthis subsection. /Vovfefons ofmufotive.This subsection shall betaken tobe cumulative and shall notbeconstrued to amend or repeal anyotherlaw pertaining tothesamesubjectmatter. 25 (d)Further prohibition on trantactlngbusiness wfth the dty. No person Induded In theterms defined In paragraphs (b)(1)through (6)and in paragraph (b)(9)shall enterInto anycontract or transact any business throtgh afirm corporation,partnership or business entity In which that person oranymember ofthe Immediate family has a controlling financial interest,direct or indirect,withthe dty orany person or agency acting forthedty,andany such contract,agreement or business engagement entered In violation of thissubsection shall render the transaction voidable.The remaining provisions of subsection (c)will also be applicable to this subsection as though Incorporated by recitation. Additionally,no person Induded In theterm defined In paragraph (b)(1)shall voteonor partldpate Inany way In anymatter presented tothe dty commission Ifthat pei^n has any ofthe following relationships withanyofthe personsor entitieswhich wouldbeormightbe directly or Indirectly affected by anyaction ofthedty commission: (I)Officer,director,partner,of counsel,consultant,employee,fidudary or benefidary;or (2)Stockholder,bondholder,debtor,or creditor,If In anyInstance the transaction ormatterwouldaffect the person defined In paragraph (b)(1)ina manner distinct from the manner in which it would affect the public generally.Any person Induded In theterm defined in pai^graph(b)(I)whohasanyofthe spewed refetfonships orwho would ormight,drecdy orIndirectly,i^lze a profit by the actton ofthe ^commission shall not vote on orpartldpate Inanyway Inthe matter. (E)OfU (l)Deflnttion.Theterm "^ft"shall refertothe transfer of anything of economic value,whether In theformof money,service,loan,travel,entertainment,hospitality,Item or promise,or In anyother form,without adequateand lawful consideration. (2)Exceptions.The provisions of paragraph (e)(1)shall not apply to: a.Political contributions specifically authorized bystate law; b.Giftsfrom relatives ormembersofone'shousehold unless the person isaconduiton behalf ofathirdpartyto the delivery of a gjftthatIs prohibited under paragraph^); c Awardsfor professional orcivicachievement; d Material suchas books,reports,periodicals or pamphlets which aresolelyInformational orofan advertising nature. (3)Prohibitions.A person described In paragraphs (b)(1)through (6)shall neither solicit nor demand anygift It Is also unlawful foranypersonorentity to offer,gjveoragreeto gve to anypersonindudedin the termsdefined In paragraphs (b)(1)through (6)»or for any person included In theterms defined In paragraphs (b)(1)througi (6)to j acceptoragree to acceptfromanotherperson or entity,any jgft fororbecauseoft a.Anoffldal public actiontaken,or to betaken,orwhichcouldbe taken,oran omission or failure to takea pubfic action;j b.A legal duty performed or to be performed or which could be performed,oran omission or failure to perform jalegalduty;j cA legal duty violated ortobeviolated,or which could beviolated byany person induded In theterm defined in j paragraph (b)(1);or d Attendance or absence from a public meeting at whlch official action Is to betakea ', (4)Bkdowe.Any person induded Intheterm defined In paragraphs (b)(1)through (6)shall dlsdose anygift,or seriesofgifts from anyone person orentity,having a value In excessof $25.00.The dlsdosure shall bemadeby filing acopy ofthe disclosure form required bychapter 112,Florida Statutes,forlocal officers"withthe dty clerk simultaneously withthe filing ofthe fonn withthe cleric of t^ Rorida SecretaryofState. (f)Compulsory dtefosure by emp/oyem of ffr^ Should anypersonIncluded In theterms defined In paragraphs (b)(1)through (6)be employed bya corporation, firm,partnership or business entity in which that person orthe Immediate family doesnothavea controffing financial Interest,and should the corporation,firm,partnership or business entityhavesubstantial business commitmentstoorfromthe dty orany dty agency,orbe subject todirect reflation bythe dty ora dty agency, thenthe person shall file aswornstatementcflsdoslng such employment andinterestwiththeclerkofthedty. (g)ExpfoHotfon ofofficial portion prohibited. Noperson Induded In theterms defined In paragraphs (b)(l)through (6)shall corruptly useorattempttousean offldal position tosecurespecial privileges orexemptionsforthat person orothers. (h)Prohibitionon use ofcon/tdentfaf Information. No person Induded In theterms defined In paragraphs (b)(1)through (6)shall accept employment or engage in anybusiness or professional activitywhichone might reasonably expect would require or induce oneto dlsdose confidential Information acquired by reason ofan official position,nor shall that person in fact ever disclose confidential Information garnered or gained through an 26 offldalpositionwiththedty,nor shall thatpersoneverusesuch information,directlyor indirectly,for personal gain or benefit. (I)Conflictingemployment prohibited. Noperson Included Inthetermsdefined In paragraphs (b)(1)through (6)shall acceptotheremploymentwhich would Impair independence of Judgment In the performance ofany public duties. (J)Prohibition onoutside employment (I)Noperson Induded intheterms defined In paragraphs (b)(6)shall receive any compensation for services asan officer or employee ofthe dty fromany source other than thedty,exceptasmaybe permitted as follows: a.Generally prohibited No full-time city employeeshall acceptoutside employment,either Incidental,occasional or otherwise,wheredtytime,equipmentor material Istobeusedorwhere such employmentoranypartthereofIs tobeperformedon dty time. b.When permitted A full-time dty employeemayacceptIncidental or occasional outside employmentsolongas suchemploymentisnot contrary,detrimental or aoVem to o^e interest ofthe dty orany of itsdepartmentsand the approval required in subparagraph cIs obtained. c Approval of departmentheadrequired.Anyoutsideemploymentbyany full-time dty employeemustfirstbe approvedInwritingby the employee'sdepartmentheadwho shall maintain acompleterecord of such employment. d Penufty.Any person convicted of violating anyprovision ofthis subsection shall be punished as provided In section Ml of die Code of Miami-Dade County and,In addition shall be subjea to authority.The dty may also assess against aviolatora fine nottoexceed $5(^.00 andthecosts of Investigation incurredby the dty. (2)A(lfcll-tinracJtyemptoyeesef^ otherthanthedty,oranyofIts agendas or Instrumentalities,stall file,under oath,an annual report Indicating the sourceoftheoutsideemployment,thenatureofthework being doneandanyamountof nrioney orother consideration received bytheemployeefromtheoutside employment.Cityemployeereports shall be filed with thedty derk.Thereports shall be available ata reasonabfe timeand plaoa for Inspection by tiwpubfk^The dty manager may require monthlyreportsfrom Individual employees orgroupsofemployeesforgood cause.. (k)ProhibitedInvestments. No person Included In theterms defined In paragraphs (b)(1)through (*)oramemberofthe Immediate family shall have personal investmentsinany enterprise whichwillcreatea substantial conflict between private interests andthepublicInterest (I)Certainappearancesand payment prohibited. (1)No person Induded In theterms defined In paragraphs (b)(1),(5)and(6)shall appear beforeanydty board or agency andmakea presentation onbehalfofathirdpersonwith respea to anymatter,license,ccmtract, certificate,ruling,dedston,opinion,rate schedule,franchise,orother benefitsougitby thethird person.Nor shall thepersonreceiveany compensation or g(ft,directly or indirectly,forservicesrendered to athird person,who has applied fororis seeking some benefit from thedtyoradty agency,In connection withthe particular benefit soughtbythethird person.Nor shall the person appear inanycourtorbeforeanyadministrative tribunal as counselor legal advisor toapartywhoseeks le^relieffrom the city oradty agency through the suit In question. (2)No person Induded intheterms defined In paragraphs (b)(2),(3)and (4)shall appear beforethedty commission oragency on which the person serves,either dfreo^or through an associate,and make a presentation on behalf of athirdpersonwithrespecttoanymatter,license,contract,certificate,ruling decision, opinion,rate schedule,franchise,orother benefitsought bythethird person.Nor shall such person receive any compensation or tfft,directly or Indirectly,for services rendered toathird party whohasapplied foror Is seeking somebenefitfromthedty commission or agency on which the person serves In connection withthe particular benefit soughtbythethird party.Nor shall the person appear In anycourtorbeforeanyadministrative tribunal as counselor legal advisor toa third party who seeks legal relief from thedty commission or agency on which such personservesthroughthesuit In question. (m)Actions prohibitedwhen financial Interests involved. No person Induded In theterms defined In paragraphs (b)(I)through (*)shall participate In anyofficial action cfirecdy or Indirectly affecting a business In which that person or any member ofthe Immediate family has a financial InterestA financial interestis defined In this subsection to indude,butnotbe limited to,anydrect or Indirect InterestInanyinvestment equity,ordebt (n)Acquiringfinancial interests. No person indudedintheterms defined In paragraphs (b)(1)through (6)shall acquire a financial Interest In a project,business entityorpropertyatatimewhenthe person believes orhasreason to believe thatthe financial 27 Interest may be directly affected by official actions orby offldal actions bythedtyorcityagency of which the personIsan offldal,officeror employee. (0)Recommencing pfofsssfofioi services. No person Inducted bithetermsdefined In paragraphs (b)(1)through (4)may recommend the services of any lawyer or law firm,architect or architectural firm,public relations firm,or any otherperson or firm,professional orotherwise,to assist In any transaction invohdng the city or ai^ofIts agencies,prodded that arecommendation may properly bemadewhen required to be made bythe duties of office and in advance ata public meeting attended by other city offidals,officers oremployees. (p)Continuing applicationafter city service. (1)No person Induded En theterms defined in paragraphs (b)(1),(5)and (6)shall,for a period oftwo years after his orher dty service or employment has ceased lobby anydty official [as defined in paragraphs (b)(1)through (6)]In connection with any Judicial orother proceeding,application,Solicitation,RFQ,bid,request for ruling orotherdetermination,contract da!m,controversy,charge,accusation,arrest orother particular subject matterIn which the dty oroneof its agendes Is a party or has any Interest whatever,whetherdirector indirect Nothing contained in this subsection shall prohibit any Individual from submitting a routine administrative requestor application toa dty department or agency during the two-year period afterhis orher service has (2)The provisions ofthe subsection shall not apply to person 501 (c)(3)non-profit entitles or educational Institutions or entity their offldal capacities. (3)The provisions of thissubsection shall apply to all pei^ns described In paragraph (p)(l)whose dty sei^ce or employmentceasedaftertheeffectivedateofthe ordinance from whteh this section derives. (4)No person described in parapaph (p)(l)whose dty service or employment ceased within two years prior to die effective date ofthis ordinance shall for aperiod oftwo years after his or her service oremployment enter In toa lobbying contract tolobbyanydty offidal In connection with any subjett described^ which the dty orone ofitsagendesIsa party orhasanydirect and substantial Interest;and In whteh heorshe partidpated directly or Indirectlythrough decision,approval,disapproval,recommendation,the rendering of advice,investigttion,or otherwise,durin where he orshewas substantially Involved In the particufar subject matterthrough decision,approval,disapproval, recommendation,the rendering ofadvice,Investigation,or otherwise,during hisorher dty service or employmentA person participated "Indirectly"whereheorshe knowingly participated In anyway In the particular subjectmatter through dedston,approval,disapproval,recommendation,the rendering of advice,Investigation,or otherwise,duringhlsorher dty service oremploymentAll persons coveredby this paragraph shall executean affidavit onaform approved fay the dty attorneypriorto lobbying any dty offldal attesting thatthe requirements of this subsection donotpredudethe person from lobbying cityofficials. (5)Anypersonwho violates tirfs subsection shall be subject tothe penalties provided insection8A-2(p). (q)Qty Attorney to renderopinionson request Wheneveranyperson Induded intheterms defined In paragraphs (b)(1)through (*)and paragraph (b)(9)Is in doubtastotheproperInterpretation or application ofthis conflict of Interest andcodeof ethicsordinance,or wheneveranypersonwhoraiders services to thecityUindoubtastotheapplk^iityoftheoralnancethat person,maysubmittothe dty attorneya fell writtenstatementofthe facts andquestions.The dty attorney shall then render an opinion tosuchpersonand shall publish these opinions withoutuseofthenameoftheperson advisedunless the personpermitstheuse ofaname. (Ord No.6-99-1680,§2.3-2-99) Editor's note-Ord No.6-99-1680,§I,adopted 3-2-99,repealed §5 8A-I and 8A-2 In theirentiretyand replaced themwithnew {§ 8A-I and 8A-2.Former §§8A-1 and 8A-2 pertained to declaration of policyand definitions,respectively,and derived from Ord No.634,§§I (IA-1).I (IA-2)adopted Jan.II,1969. END OF SECTION 28 PRESENTATION TEAM DECLARATlON/AFFIDVAiTOF REPRESENTATION This affidavit is notrequiredforcompliancewith the City's Solicitation;however,itmaybeused to avoid the need to register members of yourpresentationteamaslobbyists.Pursuantto CityOrdinance 28-14- 2206(c)(9),anyperson who appearsasarepresentativeforan individual or firm foranoralpresentation beforeaCitycertification,evaluation,selection,technicalrevieworsimilar committee,shall list onan affidavitprovidedby the Citystaff,all individuals whomaymakeapresentation.Theaffidavitshallbe filed by staff with the Clerk's officeat the timethecommittee's proposal Issubmittedto the City Manager.For the purpose of this subsectiononly,thelisted members of the presentation team,with theexception of anypersonotherwiserequiredto register asa lobbyist,shall notbe required topayany registrationfees.Nopersonshallappearbeforeany committee onbehalf of an anyone unlessheorshe has been listedaspart of the firm'spresentation team pursuant to this paragraph orunlessheor she is registeredwith the CityClerk's office asalobbyistandhaspaidallapplicablelobbyistregistrationfees. Pursuant to '92.525(2),Florida Statutes,the undersigned.f^Clf^O fe^miaS^he following dedaratlon under penalty of perjury: Listed belowareall individuals whomaymakea presentation onbehalfof the entitythattheaffiant represents.Please note;Nopersonshallappear before any committee on behalf of anyoneunlesshe orshehas been listedaspart of the firm'spresentation team pursuanttothis paragraph orunlesshe orshe Is registeredwith the Clerk'sofficeasalobbyistandhaspaidallapplicablelobbyistregistration fees. NAME TITLE For thepurpose of thisAffidavit of Representation only,the listed membersof the presentation team, with the exceptionofanypersonotherwise required to register asa lobbyist,shallnotbe required to payany registration fees.TheAffidavitof Representation shall be filed withtheCity Clerk's officeat the timethecommittee's proposal Is submittedtotheCityaspartoftheprocurement process. Underpenalties of perjury,I declare that I haveread the foregoing declarationand that the facts stated In Itjre trpaand specifically that the persons listed above are the members ofthe presentation teamof ted below -/£dav of flu^ASJT .20 (f Print Name and Title /Print name of entity Uins/fejtfesented at EXHIBIT #1 Scope of Sendees A Schedule ofValues/Summary of Quantities Attachment A: Project:SW 78 Street A SW 63 Avenue MM L Scope of Work: Scopeofwork involves performing road,drainage and sidewalk improvements within the Qty ofSouth Miami.Work shall comply with applicable standards,including butnot limited totheFDOTandthe Miami DadeCounty Public Works standards.Work covered under this contract shall also include and is not limited to maintenance of traffic drainage,sidewalk,milling,clearing and grubbing,asphalt placement and striping. Theconstructionistobeperformedper specifications andtheconstructiondocuments ofSW 78th Street Roadway and Drainage Improvements,prepared by T.Y.Un International/Hi Ross.This includes,butisnot limited to,the furnishing of all labor, material,tools,equipment,machinery,disposal ofall materials,superintendenceand servicesnecessaryforthecompletionoftheconstructionof the protect. Theawardedvendormustobtainanypermits required.TheCity will waive ailCity permitfees.Permitsthatmayberequiredby other agencies will bethe responsibility of the awarded vendor,including applicable fees. Work activity is limited tothehoursfrom7:00 a.m.through6:00 p.m.,onweekdays fromMondaythrough Friday. II.Site Locations: 1.SW 78*Street a.WestofSW 63rd Avenue towardsthe South Miami Dog Park, b.East ofSW 63rd Avenue along SW 78th Streetfor approximately 50 LF 2.SW 63rd Avanua.from SW 78th Street;Northtothe limit ofthe FDOT rightof wayonUS I. III.Plaits and Specifications: Plans prepared by T.Y.Un International,tided 'EXHIBIT I,Attachment B-«SW 78** Street Roadway and Drainage Improvements?areapartofthis RFP bywayof reference. IV.Project Duration A Liquidated Damages: The current estimateto complete construction oftheprojectis 60 calendar days substantial completion.Thermoplastic paint shall be installed 30 calendar days after substantial completion.90 total calendar days to final completion from issuance of Notice to Proceed. 32 Liquidated Damages shall be paid bytheContractorattherateof $1,500.00 dollars per day.plus any monies paid bythe Owner tothe Consultant;if any,for additional engineering and inspection services,if any,associated withsuch delay. V.Project Funding: Thisprojectis funded through City Funds. VI.Schedule ofValues: Respondents shall completeandsubmitwiththeir proposal,theattached Schedule of Values. VII.Warranty: Ifequipment is being provided,the standard manufacturer's warranty information must be provided in writing for ail equipment being proposed,including installation byan authorizeddealerbefore final paymentis made. NOTE:Respondents shall quote both Projects;Rmfer to Exhibit 5f "Respondents Costdl Technical Proposal.99 -"SW 78 Street A63 Avenue."and "Twin Lfllm"in accordance with Exhibit I "Scope of Services,"Attachment At B9 C9 D.The City,atitsdiscretion,may award both projects to asingle contractor or,each project to separate contractors. A Performance and Payment Bond Is requiredfor the full amount of the project END OF SECTION 33 VJ/W EXHIBIT #1 Attachment A: "Schedule ofValues" Project -SW 78 Street &SW 63 Avenue Respondents ShaO Complete and Submit With Their Proposal 34 iu/A i t e m N U M B E R 1 0 I T 1 2 1 3 1 4 1 5 1 6 1 7 - 1 8 1 9 2 0 2 1 2 2 2 3 2 4 2 5 P A Y IT E M 1 0 1 - T 1 S T H E 3 " 2 1 0 - 2 2 8 5 - 7 1 1 3 2 7 - 7 0 - 1 3 3 7 - 7 - 4 0 4 5 5 " 3 3 3 T 5 2 2 - 1 § 2 3 " 7 0 0 - 1 - 1 1 7 0 0 - 1 - 1 2 7 0 0 - 1 - 6 0 7 0 6 - 3 71 1 - 1 - 6 1 1 - 1 7 1 1 - 1 - 3 2 1 - 1 7 1 1 - 1 - 1 1 2 - 3 7 1 1 - 1 - 1 1 S 5 4 3 0 - 1 7 5 - 1 1 8 4 4 3 - 7 0 4 4 2 5 - 2 - 6 1 4 2 5 - 1 5 2 1 5 7 0 - 1 - 2 S W 7 8 S t i e e t - 8 c h o o l u l e o f V a l u e s M* & 3 & L c * *£ i a c . P A Y IT E M DE S C R I P T I O N o f T r a f B c L i i f t c f o c k - N o w Op t i o n s ! B a s s < a n d Gr u b b i n g Ma t e r i a l t o r Ra w o r t d n a B a s s (9 T ) Op t i o n a l Ba s e Gr o u p 11 (1 2 * Um a r o c k LB R 1 0 0 , fo r Bo o t re c o n s t r u c t i o n ) ' Mi f f i n g Ex i s t i n g As p h a l t Pa v e m e n t So n c F r t c b t o C o u r s e " n a f f c ( r A v e r a g e ) As a h Co n e Fr t c o o n Co u r s e Tr a f f i c B ( F C - S J U I ^ re s u r f a c i n g 2" re c o n s t r u c t i o n ) M a n h o t e A d l u s t V a i v a A d u s t Si o ^ w a f t C o f t t r e t B , 4 " T h j c k Si d e i w n ( O o n c r o t e , y T h t e K (a n d c o n c r e t e d r i v e w a y ) " St n g t e Po s t S^ n t F & l t L e 8 8 Th a n 1 2 SF S t a t e P o s t Si n n . F& l , 12 - 2 0 S F S t a t e P o s t Si g n . R e m o v e Re f l e c t i v e P a v e m e n t Ma r k e r s fY / Y ) T h e m w t e s f o S t d - C m » e r S u r f a c e s T h e n n o p t a t i c . S t d - O l t o T n e m w c r f a s t l i x V V h t t e . S o B d . ^ Th o t i n o p j a s f i c ; Wh i t e , So f l d , 2 4 " P i p e C u l v e r t Op t i o n a l Ma t e r i a l . R o u n d S h a p e 18 * S / C D F r e n c h P r a t e . 2 4 " H O P E M a n h o l e T y p e P - 8 < 1 0 ' C a t c h B a s i n T y p e C Tu r f . S o d f l h d u t o r a g r a d e d a w a t e a r e a *T h e d > < t e t y P o l i o e o « c e r h « i m l t e m t e a n a t t o i M t e ^ of l k » w f f l be r e q u i r e d . I M h e o o n t r a c f o r b e ^ re q u i r e d it le s e th a n t h e p r o p o s e d n u m b e r o f rt o i i n ^ 1 h e d H b r e n c e 8 h a i ) b e u e d H B d t o 0 ) a C t t y . S W 7 8 S t r e e t - Sc h e d u l e o f Va J u e a - Pa r k i n g Ar e a Th e C t t y w f f l o ^ s t r e t o h a w . a s a s e p a r a t o l t e ^ M fi L SL S L & C ^ Jj E W c ^ P A Y I T E M 71 1 - 1 - 1 4 2 - 1 71 1 , 1 - 6 1 1 , 1 7 1 1 - 1 6 1 3 1 5 4 2 - 7 0 P A Y IT E M DE S C R I P T I O N T h e n r i c a i a s f e S t e i i d a i d . B l u f t S o a d . 6 r Th e r m o p l a s t i c . S t o - O t t e r S u r f a c e s , W h i t e . So C d , 6 " Th e r m o p l a s t i c . W h i t e . SK I P . 6" (2 t t ) B u m p e r G u a r d s . C o n c r e t e ) W h e e l S t o p + 1 3 . 5 5 3 6 U N I T L F N M Q M E A S K E T C H QU A N T I T Y 0 . 0 2 2 0 0 1 UN I T P R I C E m m o u 10 . 7 ' ly tt : ) * * ^ W # l T £ to * * ? * <~ . - - * C O S T ^ ^ IS a L " W > EXHIBIT #1 Attachment B: Project -SW 78 Street &SW 63 Avenue Plans prepared by T.Y.Lin International/HJ Ross "SW 78th Street Roadway and Drainage Improvements* 37 EXHIBIT #1 Scope of Services &Schedule ofValues/Summary of Quantities Attachment C:Project-Twin Lakes I.Scope ofWork: Scopeofwork involves drainage improvements within theChyofSouth Miami.Work shall comply with applicable standards,Including butnot limited totheFDOTand die Miami DadeCounty Public Works standards.Work covered under this contract shall also Include andisnot limited to maintenance of traffic,drainage,milling,clearing and grubbing,andasphaltplacement The construction Is tobe performed per specifications andthe construction documents of Twin Lakes Drainage Improvements,preparedby Civil Works.This includes,but Is not limited to,the furnishing ofalllabor,material,tools,equipment,machinery,disposal of all materials,superintendenceand services necessary forthe completion of the constructionofthe project TheCitywill include additional resurfacing beyondwhatisintheplansin the intersection of SW 63rd Avenue and SW 64th Court The awardedvendormustobtainanypermitsrequired.The CHy will waiveall CHy permit fees.Permits thatmayberequiredby other agencies will bethe responsibility of the awardedvendor,including applicable fees. Work activity is limited tothehoursfrom7:00 am through 6:00 p.m.,on weekdays from Monday through Friday. II.Site Locations: Therearetwo separate projectareastobe considered andquoted separately as described below. Area I •SW 62nd TerraceandSW 63rd Terrace,fromSW64*Court toSW 63rd Court •SW 64th CourtandSW 63*Court fromSW 62nd TerracetoSW 64th Street Area 2 •SW 63rd Avenue andSW 62nd Place,fromSW 62nd TerracetoSW64*Street •SW 62nd Terrace,fromSW 63rd Avenue toSW 62nd Court •SW63"1 Terrace,fromSW 62nd PlacetoSW 62nd Court •SW 62nd Court fromSW 62nd Terrace toSW 63rd Terrace. so III.Plans and Specifications iPlanspreparedbyCivilWorksInc.tided "Twin Lakes Drainage Improvements99 Exhibit I,j Attachment D,are a part of this RFP by way of reference.[ i IV.Project Duration &Liquidated Damages j Thecurrent estimate to complete construction oftheprojectis60 calendar days substantial completion foreachworkarea.Thermoplastic paint shall be installed 30 calendardaysafter substantial completion.90 total calendar days to final completion from issuance of Notice to Proceed.Liquidated Damages shall be f paid by the Contractor at the rate of $2,000.00 dollars per day,plus any monies paid [ by the Owner to the Consultant if any,for additional engineering and inspection j services,ifany,associatedwithsuch delay.I V.Project Funding:j This project is funded through City Funds.[ VI.Schedule ofValues:! Respondents shall completeand submit withtheir proposal,theattached Schedule of Values. VII.Warranty: Ifequipment is being provided,the standard manufacturer's warranty information must be provided in writing for all equipment being proposed,including installation byan authorizeddealerbefore final payment is made. NOTE:Respondents shall quote both Projects;RefertoExhibit5, "Respondents Costdl Technical Proposal99 -"SW 78 Street A 63 Avenue."and "Twin Lakes."in accordance with Exhibit I "Scope of Services/9 Attachment A,B,C,D.The CHy,at itsdiscretion,may award both projecte to asingle contractor or,each project to separate contractors. A Performance and Payment Bond is required forthe fell amount oftheproject END OF SECTION 51 EXHIBIT #1 Attachment C: "Schedule ofValues'1 Project-Twin Lakes Respondents Shall Complete and Submit With Their Proposal 52 Twin Lakes Drainage Schedule of Values Areal JL4*§rg*aLc~ZTUe. Hem Description Unit C-5 C-6 C-7 C-8 C-9 C-10 C-11 C-12 C-13 Quantity I UntiPricel Total I Manhole EA 1 1 0 0 1 1 1 1 0 6 fe*^a&*^j Inlet EA 0 0 2 2 0 0 0 0 0 Iff*0 Exfiltration Trench LF 33 0 0 0 142 143 00 0 318 f96 18"0 Solid Pipe LF 0 40 166 132 125 126 29 34 0 652 ei 15"0 SoRd Pipe LF 0 000 0 0 0 0 0 0 12"Solid Cone.Pipe LF 10 10 0 00 0 10 10 0 40 &S gp* Concrete Collars EA 220 0 0 0 2 20 8 300 Milling(1 inch ave.)SY 408 113 310 89 284 276 81 117 0 1676 $Resurfacing Type S-l (1 jn)TN 22.3 6.2 17.1 4.9 15.6 15.2 4.5 6.4 0.0 92 fdo /Jt£0&. Asphalt Apron 11nch*TN 0.2 0.00.8 0.5 0.0 0.0 0.0 0.0 0.0 1 /BO **/ffl~ Driveway Restoration (Asphalt)TN 0 0 0 1.05 0 0 000 1 tao too*9 Off-Duty Police Officer*"HR 80 $45.00 $3,600.00 Base Rework (10%of M&R)SY 168 tD Total:9 Contractorto verify the pay item notes in the plans,Sheet C-4. *Line item 339-1 Asphalt Apron shall include the cost for asphalt and Dmerock base. **The off-duty Police officer hours itemisan estimate.Selected contractor will be requiredto apply foraright of way permit,during whichPolice wiH evaluate the MOTplanand assess ifan ofMuty police officer wiU be requi^ 80 hours arerequiredfor this project,the contractor shall adujst the quantities andtotsd cost for this itemin the proposal If the number of hours requiredis less than the proposed number of hows,the difference shall be creditedto the City. sy tern Description Manhole Inlet 18"eExfPtratton Trench 18"0 Solid Pipe 15°g Solid Pipe 12"Solid Cone Pipe Concrete Collars Milling(1 inch ave.) Resurfacing Type S-l (1in) Asphalt Apron 11nch* Driveway Restoration (Asphalt) Remove Drainage Structure OfT-Duty Police Officer** Base Rework (10%of M&R) Unit C-14 EA EA LF LF 148 LF LF EA TN 30.9 TN 0.4 TN 0.61 EA HR SY Twin Lakes Drainage Schedule of Values Area 2 Mfi-g-frvto 2*t> Quantity I UntiPricel TotalC-15 C-16 C-17 C-18 C-19 C-20 1 33 37 34 40 5 1010 388 718 461 56.4 21.3 39.5 0.(25> 0.0 0.0 0.8 0.0 0.0 0.5 C-21 C-22 92 163 179 475 235 26.1 12.9 0.4 0.5 feJfeSulKEEai B3f0B0 34.000* 507 20 213 80 387 3rt 3-izr 4*mm -£EL $45.00!$3.600.00 70 Total: Contractor toverify the payitem notes in the plans,Sheet C-4. *Une item 339-1 AsphaltApron shaU includethecostforasphaltand limerock base. **The off-duty Police officerhoursitemisan estimata Selected contractor wiU berequiredtoapply which Police will evaluatetheMOTplanand assess ifanoff-dutypoliceofficer will be required.If the contractor beDves thatmorethan 80 hours are required torthis project,tire contractor shall adujst the quantities and total cost for thisiteminthe proposal Ifthenumber ofhours required islessthanthe proposed numberof houra,the difference shallbe (^edited to A//^ jr* EXHIBIT #1 Attachment D:Project -Twin Lakes Plans prepared by Civil Works,Inc. Twin Lakes Roadway and Drainage Improvements* 56 LIST OF SHEETS: TWIN LAKES DRAINAGE IMPROVEMENTS CITY OF SOUTH MIAMI 4795 SW 75 AVE MIAMI,FLORIDA 33155 SHT.No.PESCfflPnON C-1 COVER SHEET C-2 GENERAL NOTES C-3 DRAINAGE MAP C-4 DRAINAGE STRUCTURE TABLE C-S-22 PLAN SHEETS C-23 DRAINAGE DETAILS ffipi PROJECT LOCATION PX: LOCATION SKETCH PUBUC WORKS EMGKBflNG DrVSON PREPARED BY: CWI CMIWorks,Inc. CONSULTING ENCODERS B481 M.W.17 ST.SUtte 100 OORAl,FL.33126 (305)591-4323 CA 07928 Miami ♦Coral Springs*Orlando v< PERMIT SET 06/01/15 C-1 z-o S31ON1W3N30 1*55" hpgmq mmaoMota sxvoMorwnd I IMS XVM 4i>0i 83d WmtO 3I3N3N0O V WM L^i^^J!**^.3**CBscwoiu ioiic avow nmawoo ao oi 30V sumswbs wmvw oasojoMd wan i saioN govNivaa saaao manuemo aw o*•sshttw "Hoccm tos way aau «y twaro aawtwia mno nv onjmvxhcti ••S33O0V1M1WOWNW 1KB 3B0 OX O0XOVWJI00 -Q310NaSMHIW SS3M t«VGU Oi SI aOVNTVMO Oltim V 7SH X30M 1>I0Z iOQJtewsaoraoxjowoiMjirasanynobouiwxsnjtwhbooxovoimoitwinrwwKttoxooom-jjjS-« wvto him oaroovo aw ckoigo 30 tkw sadkPwsLJSa^ ™.~~,JIQia*ltt,,TO •"•AO0*14*8 UDUVSOI VXV ONV AWCTOaSMSlO 39 TrVHSQJlVAOTTOffllYnjwnnsw-nv ?ivxao onv swwsa.m mowssv knob,sm no saraonus ku WMrSa ox SqiovSmw tr aairwc raytcrdo m sauna*jaw ox damn laoddns jo i*a*tonu)awv »«ntw i»c^SnwonsOMonrtiMsautui joaotMoiMv*him aacnoossvxsooaw.sam w irwavSS m saunin -m mvinv*01 nqovhimoo 'Oxom sbmvjwo ssaott njvkm ox aov sarxran otoasw t* ,JS3UUVW VBM0H3H1 JO £P*0GC NDU3GB KtM aONVflMOOOV M UnOOO ANVJO 33NVAOV M _J"fS»B»MDttn^jy-aummawn -no mvuoyn ncj«-♦ohv irv o-tavomj-avonqiianaOMONOdsauMOouqjamoumujoKamioMMo-noi am,isvai iv mvxnnn tjws *SSvSS»-k2 XNooia xsaivo com aw.w wavon**-wowa jkmuoj aw.*»»lymm mom so,* fWTttflO SV -0VX30 TOtttHOO TV3WU OMOMMZaODO OXOmXBO*1U*^MUM TMB WOUXUiX*TZ TMOO SOP 3ttL 1411ft m00X03*81 3KL HO 'XflO SI1N3HMM WOOM 3U3 SOT 3ML NO 30ISO*TWOWW K^lKttWM^ iM^vdAWMm»v «*»A-muavd w oj^I^^^a^SS^^ M.Joum&J0 33imstiivfiuu^»aMi m oaomsM as ywhs xsoo aw.-ooROdwuorausMOO onum 03MOK»ONMM5 NDWMttOJM OWnitNOO OtMWtt TW JO ONOXasaH 3HL tti aVBNOJQM flUOXmNOOant>«uoo¥MtNoaniiaatvvoojiw am sj onv-mum mgr xiaraiivSosra ormaAjoowMouaasowvsonoonsmaMunoSNoavouradshimaotMouosovmitooKMxxaivaTowxSjS otum tit j»aowmniffna <mv intviMM v»^ ssv»aNasnonr -xs him oaooos-ai ow o3uojs3h ao twhb NOttonJSSo ^oSuSSv SrSrttw©-nf •» "SOWl OUMU MV3H MNMlSnS JO 7Wf<ftO SBXSTWI S3*tt0fWlS TO *1 *Wdtf«»1WH„jj •ozMoxHsvy ox-h Noayousvro oujmu «ts*oo jshmvh ohv ornvto mis tk •sovomw* *Bl 000*01 HO *SQ¥01 OttMtL AWIM9M MOJ atOWUIS MOttVDUBSVD ALOO AAV3H GUmODJM NOH XSV3 'St toMO am.ox xsoo -WNoanav om xv onv xonusnoo oi -MiiaflBM aa iwre xsoo ohx -asioja s^toxovuNoa aa xv voxovtnMOo aw.xs x-rwaai jo oasojsa as tmk xaorotu sml hdmj covoraa -ivbblvii oanmoxi tw >t mi tmt xv CTtMMraM xieswov *nv ox ssaoov mvimvr twhs wiomojuo aw ti lawtMoo 3Hi oi tnjooowi 3W KJtl sta mm omvoossv sisoo ttv ouiw nvaosaoat aj«s jurm ox axmohooov oemhvh onv oaraae A-VBU 1BM3M9 3B TWHS K9NZK1 AMV HSMO attU OaKDMJJV arMlOOi)SSnn 1BH0UM iON SI V0X9WIMD9 aw M9M "Sail lOttO HO SAVOnOHWHIlft 'AVO OtaOJOM 3W JO 0K3 3KL XV K3dt) HO (DSOitta "JD SUMI MO"SKMOBL 011VAV3O 3M31 HOXOVHtHOO 3Kt IMS SOWlSntXtO OH IBOMTI^i YHSJ OHS ONaVOBOVJ /ONBBOB OX HOfiU S»BN1 /AXO 3Mt AS -HNBkkH HOJ ^MnVOUDOC jooratw aw.m oatsn msu iw hoj sotMvtn jons xivns onv awuMJ tw«moxovumoo aw ni twoii QMuwar ox mobm ummwo 3ha oa caow^ooo aw xwmm ttvhb aiy 'SNOdlOWD aiB XNBftinO MM JIBfW 0M2DWIVWJ MM aVBN0J53H 30 TWHS NQIOMUNOO ^tOOCMO jjosau xoauu Amvwoov ion avk omv vxvo awwftv xsaa am nbmj ismvx aa»saovuo ombsos tn ox HOMi inra*a a«iom twhs uoxovmxnoo "mmwgn aata hoj oawtou ao xvn aphm aaa v xvw oaovov ci uoj9vkim»aw 'aavu m —raimn ao tivms NoaaniasMoo him oitteuatM xon sauL aooNx -NOttonusMoo mm <mnoaf Ji a*wo onMNOtt aa nvm sum.fiMosoa •» -suvacn Aiiun oianrj XNJS3Md ao Tm aNt»iosridiM s^ojavaioo MOHDl9VttN00 3HL 'SMWBA ONttSOS JO NptVOOl 19VM3 3Mt AJMP)OX OMOONJ ANV ONffWDJHUoxhoqmsmoH»jsvai xv oat-mlpabi xv to mmKtmtaw xovxmo hvhs hoxovmnoo v tmomv ao "nvw noovsmmvo ivnoujoov on wv icmoMoa 3hi 01 ivijoaat aaaoGNoo ao -whs noxoviBNOd aw,ao jmm smvmmvaw jd awtvuasaMw <nat»3Hl onv MoxavMNOo aw ao aarosaf ao xtm SioruNOO tw tuonaMthM aasojouj ox mtu -saNVdnoo AinBii tw him NOfiVMNooo w M0U.VAV0X3 oxvH ao ONV soOMian oMONxoao ao saunuiTiv ajhmtmsNoxovmNooaw sMixwui9msta"w jo NonvooTaw moj ansNOJsaiaorrvHs imawttHooaHA -caiMVw asaw no mums ion »jv hsmta xwo avu saunrxn tvnoumov •ntmaxud*aov ssnmvno asaw no momsaamn omsoa tiv jo 3ns omv nohvooi aw-4. __<IGH0O3mCllS00TVN00J00V0MlV033VlciMH0a9OLVJ TJ3WVAI ao tivks tovoxMoo sw.aoom oaiojojoM wnnn«wifiNfy>ao oaoonisio XVA ANV M 00 03906(3 MXWNVa XTWVW0»*m SI HMM IKMNBO 00J 03tf03d5 XON SaONVNlUinJJV ONttSBO «3WO »533^1ION3AVJ •3HfU3rtUS ONttStO XNV <SMW NO NftOHS 30 XON AVIt HDIM saamn onv "ssMmoraos isaaox onosoq tiv jo nohvoot xavxi aw.amov qi «nqidwonoo-9 TaMOTW 30 TWHS .SMGtaVaA,XIVHJSV ON -XK3N3AV4 0N0SK3 KIM HSlTU ONV 3NO1H9M0S XV3N V M 30VN 39 TMB NOttigNJOO ^tttSSQ SU2M XNJKMVd «3N aa«*0 *SNVU 30KX OHV tMVM fOTOS JO SDOCaftTOI aMVOTUdV ONV %dOH tHNtX 3W OX OMOODOOV 30 OX SNBVO WLVO OM10OVANSCMVJ ONV NOttVWUfiM JJOH3MM 'S3H3N3N1 NOUVHTUa ^SMSVfl K3LVO> -V3MMO 3NX JO N0IKU1V 3HI OX XWOONB KmWBm30TWMSS30003lOV3ndtfVONVSMVUasSMTKl>U3fl S30HVJSOSfl ANV HQllOmnwr 9NM.VM sarxHOHUiv ohv saooo aisvorvwv km aaovoBooov m ao en snvu asaw jo XNaiw aw a xi v tlOdi)NOtLVXODdBMMlI JD XKaUMVJM VOUOTi 3H1 OMV th»0 UORIMUia SMOM OHOV AIMOOO 30VO-MWI 3K1 XinrTO)(loo)sxxrosat oonNoaa onv Aooirmaw AiMnoo aova-ffivoi "vwn wnos jo AlO JO SllWmilJ 3W WM 33NV0MD3OV XOttOS W 30 TW6 NOaOimiSNOO 30VM(VHa TlVg -soot (oaon)rwuva TCnoa*aoaoaao -WNoavN ox \bb*SNoavAia nv i S3iONlVy3N^ &@z Itf liWf 1 I < b I n STRUCTURE NAME STRUCTURE TYPE SHEET NO.STA.OFFSET RIMELEV.INVERT ELEVATIONS BOTTOM ELEV. REMARKS/STRUa.SI2E N S E W S-l MANHOLE C-S 12+S5.14 21.56'R 7.80 EX.4.37+EX.4.37*1.73 <-)0.27 33*x3.5' S-2 MANHOLE C-S 15+05.64 5.93'R 7.90 EX.3.341 FX3.34±2^0 0,90 3.5'x3.S' S-3 INLET C-7 31+18.33 12.69'ft 7.53 1.40 2.90 (-J0.60 4*ROUND S-4 INLET C-7 32+1335 18.32'L 7.75 1.40 (00.60 33'ROUND S-5 INLET C-8 34+79.11 11.32'ft 7.73 1.62 1.73 <-)177 SKIMMER EASTSIDE5'ROUND S-6 INLET C-8 35+0S.98 15.76'L 7.62 1.62 (-J0.38 3.5'ROUND S-7 MANHOLE C-9 22+00.00 S.OO'R 8.25 1.73 1.73 <->L77 SKIMMER EAST SIDE 3-5'X3.S' S-8 MANHOLE C-10 24+15.00 S.0LTR 8.15 1.73 1.73 HL77 SKIMMER EAST AND WEST SIDE 33'X4.5' S-9 MANHOLE C-ll 42+55.00 21.0TL 7.96 EX.4.S51 EX.4.55*1.73 Ht-77 SKIMMER WEST SIDE 3.S*X3.S* S-1Q MANHOLE C-12 36+36.03 12.30*L 7.80 EX.3.871 EX.3.87*1.73 (-J027 3.5"x3.5' S-ll INLET C-14 52+03.42 12.79^7.73 3.23 1.23 3.5'ROUND S-12 INLET C-14 51+88.26 H.9VL 7.83 1.83 3.23 (-J0.07 33'X4.0I S-13 MANHOLE C-15 53+48.80 5.62'R 7.76 EX.4.06*1.83 {-)0.17 REMOVEEXIST.MH,SKIMMER NORTHSIDE 3.5'X3.5' S-14 INLET C-17 72+07.47 11.89'L 8.23 3.23 1.23 3.5'ROUND S-1S INLET C-17 72+31.07 13.86'R 7.95 EX.5.051 EX.S.40±2.95 0.95 REMOVE EXIST.MANHOLE 3.5*X5.0< S-16 MANHOLE C-18 100+13.93 4.00'R 8.12 EX.3.75*EX.3.75±2.15 (-)135 SKIMMER EAST SIDE 3.S*X3S S-17 NOT USED S-18 INLET C-20 82+16.82 21.13"L 8.20 2.00 0.00 3.5'ROUND S-19 MANHOLE C-21 90+60.00 4.75'R 8.60 2.00 2.00 0.00 4.0*ROUND S-20 MANHOLE C-21 91+81.48 5-00*R 8.47 2.00 2.00 3.10 (-)^50 SKIMMER NORTH SIDE 3.5*X3.5* S-21 INLET C-21 91+81.48 lS.SO'R 8.27 3.19 1.19 3.5'ROUND S-22 INLET C-22 93+46.63 0.32*ft 8.3S 2.00 2.90 (-):L50 SKIMMER SOUTH SIDE 4'ROUND S-23 INLET C-22 102+16.41 15.94*R 8.19 2-90 2.15 BL35 SKIMMER WEST SIDE 5'ROUND PAY ITEM NOTES: 445-70-J INCLUDES COST OF PIPE,BALLASTROCK, FILTER FA&mc,AMD TRENCHRESTORATION. 430-175 42S INCLUDESTHE COST OFTRENCH RESTORATION. INCLUDESTHE COST OF PAVEMENT AND SITE RESTORATION. Item No.Hem Description Unit Quantity 443-703 18"eExfflration Trench LF 606 430-175-118 18^0 Solid Pipe (A.2000)LF 1,159 430-175-115 15"0 Solid Pipe (A-2000)LF 5 430-175-12 \T SoBd Cone Pipe (RCP)LF GO 425-5 Remove Drainage Structure EA 2 425-2-71 Manhole EA 10 425-1-501 Inlet EA 12 339-1 Asphalt Apron 11nch TN 4 334-1-24 Roadway Pavement Destan SY 90 334-1-13 Resurfacing Type S-l (1in)TN 290 334-1-12 Driveway Restoration (Asphalt)TN 2 327-70-1 Mllinodlnchave.)SY 5.268 210-1-9 Base Rework (10%of M&R)SY 527 208-1 Concrete Cedars (Jackets)EA 13 INCLUDES ALL COSTS ASSOOATED WH THE PAVEMENT CONSTRUCTION MCLUMNG PRIME ANDTACK COAT,SAWCUTTWC, INDICATED IN THE PAVEMENT DESIGN USE CLASS NS CONCRETE PER FDOT INDEX 2&? ;WNG PRIME AOJ^M.e/?/<V.AND ALL ITEMS ^\^5-iV;--i:</%,ESKN (SHT C-2l£CWcE«$£•<\ Nj0 '38542 \** jgppwr I2XZ2Zffi ,PEMWW vmr aac N|M)4MBfllM«4» a«mm m Chfii Works,Inc.fmllW 1 ftMfc^nginw causa^#If •un KW.DST.immm o-i.ft.m»nwytum DRAINAGE STRUCTURE TABLE OA CL")i?"cpkc.\*\inv«j5.cj6 fe:et\j (VV)12"dDMC.\\ :.NV«3.C3 BOTTOM JKiV. |FEftT \I \ LEGEND c s METAL UCHT POLE GUY WIRE LmLDY POWER POLE FIRE HYDRANT WATER METER WATER VALVE ELECTRIC BOX MAIL BOX @> zbstssc ssnansr telephone box storm manhole gas valve: traffic sign catch basin drainage manhole ucht pole sewer valve ""WL S.W. **Sr3C^f^^-oc ^-l^^tZ^tfegJI 64th COURT F.F.E.*t0.4S .^tffc tn"/L POLfj/rTfJ^MA^r7r^, 5§i-«.%* ASPHAi,T~v7^^^i^ASP_t^LT,; WJM.(E 10305)ti+00 ~t-T *N02*4r2J"W 260.00* »1 WOOD FENCE (5)i?"ccsc. INV=3.94 FCtl BOTTOM INV'Aft«i ?££T const.Asphalt apron per catch basin ».*. r.I*£«#$B PAVEMENT DETAIL CONST.MANHOLE. CUT10LFOFEXIST.^ 22T DIA.CONC.PIPE.CONNEC& TO EXIST.12"CONC.PIPES CONST.33 LF OF 18* PIPE MATCH LINE STA.20+56.00 **sheet c-» ® © A C-O ELECTRICMANHOLE TELEPHONE MANHOLE GUARD POLE UNKNOWN MANHOLE INVERTS SPOT ELEVATION TEMPORARY BENCHMARK SEMAPHORE DysMETER-SPREAO-HElCHT "SSWffipr O * t o RIGHTOFWAY UNES OVERHEAD UTUTY UNES LOTCORNER TREE (SPEQES UNKNOWN) PALM TREE PINE TREE ORNAMENTAL PLANT COCONUT PALM a PUBUC WORKS NGMONMB 0M90N >H»MMH»>I»1]| PROP.STORMMANHOLE PROP.PIPE PROP.EXFIL.TRENCH PROP.INLET WITH ASPH. EXIST.SANITARY PIPE EXIST.STORMPIPE : EXIST.WATERMAN EXIST.GAS MAIN Vp WI •«*»*tfn.iMmllL -. MILL (1 IN.) RESURFACE (1IN.) \P\STATE OF /£$ *&^ LOCATION MAP RTS PLAN SHEET C-5 (-9 133KS I3S 00*06+21.'VIS 3NH HOIVW xi«Woe-b3irHncoTrrt rc-wvi tto&M &'£0:0 = v 'W m us i o 4 Mi* a l-plOWHaHuHV-l^fV*»^v««»\l«lrfu»4i<WS -•U»t\«(3*fe<<<\»k*"*«SSt-Kllfe|l03\\ V\COi>nin»-<g\tf.v»U\P,«>tuV«l<»-i*t»ttpnV'o'ttog fr/Wtrto»yvum-»nP»*0*98E: Jl o si MATCH LINE STA.30+48.00ASPH5 MATCHLINE STA.33+30.00 tZtKMUJ&JtKY COMPJftR-M.1l*»?SECSHEET C-C SEESHEET C-6 "IHTI ""MSWWKVJ fBffg TggffiPTJffT Hfc 3ZS^ MTg" PUBUC WORKS *Ml«fHbAfcON«ftMl *"*%§ <aiifi2Np TE x T —,- ^rbfll^|L&40-ojHHVBE^--^-*T|SW 63RD TE m *ffl % 91620 T?' SWURPTE si i ^5|s LOCATION MAP sre -.•--.CM/Worts,/no. PLAN SHEET C-9 ZEE nS2 iwr TTTI ^S "BHgwwr m I 0_»20 S.W.63rd TERRACE f.F.E.=10.17 /_-J .r°-.2Li i-Vl D *7 f /^sec if ^f V sec ^*SOD M?*™HAASPHALT-./EP*ASPHALT \ASPHAL.TX .g T A " ^rCmST7TB3-LT-%-~~"V"*^™^~"VS § /iff*m even -rocuru A-v © T7Tg" j****Boti prft PUBUC WORKS OGMCDtPODnM I4»&,«4WI "ygg~ '''•mit»i* CWI Civil Works.Inc. LOCATION MAP NTS PLAN SHEET C~10 3^q JHBftWfc- ZS23JT3BE 3SS3S2S PUBUC WORKS «»«|hwiiMiiia **"•.STATE OF //jig AlAf •C/w/Worte.toe W WW I MMKw.im,Miia Feet MATCH UNE STA.26+00.00 LOCATION MAP ~nTS PLAN SHEET SEE SHETTC-10 C-11 WCOUPtfFCE-tSSSyyyuyPicfrtHSW-tot,fr>MomAWy^itttHfrtcte-AUHI-PlpsMl-g ',-. o m Spiff 6gir MATCHLINESTA.43+00.00*cwtoc-n MATCHLINESTA.45+80.00atwttic-u •fl»JC»811-46:19*1*,COM»UlERfit.1»»1? ES.W.62nd JTERRACE TOTl M .flgffrewf/"''Mflr "BggflWlW PUBUC WORKS OttNEOI %%••.STATE OF '*'##•Mt»*%1 CWI CM!Works,Inc. LOCATION MAP ins PLAN SHEET C-13 r L_•'\<>:t -^s»v.'3-^r3^1^-^^L—— k or', 5 ^\T ,-.^**j *-*s'<©Q *.A'>,-*v. 1 X >y^-- >,/\_SiILBElV/No.7V; /EL£v.-7 35'P^^W ^68* wrps JlHflMPftM 3ZETJ £««**«*pyeiidtvoRks ENOMORMS OMBMM Nt p««4b MT0B»4»*» fc 38542 \*\ A1..a Civ//Works,toe W WW I M»NVLITSZ.MbNIMw.»t»(wyn-oa LOCATION MAP HSS PLAN SHEET OU "-o.f!^1.0gp?+99 VIS 3NI1HOIVIN «-a 13»S 33S OOOL+69 VIS3NI1 HOIVIN 11«t l 'OT*li(Vdft09 T*V tt n .01JWW «V .••V*••••7<v(/% iis 5 o .£*'" ^£# IS i a«»ll«au-»i|itVAP«4Wt Snw*M»Wi«iTO -tun\»i"f«'.A»i*»*$\Ci-iiirvtw»\\ I CO ^ VD ^ •LU LT1< ..vrc...*i.A kHrf —i i 61-3 133HS 33S 00'02+9S VIS 3NH H01VW ««u 'wuimcH09'ftd trwn wkm T **10 OKZPJ^Wi|P^flWcjiC^i-is-"^TTnswSlS"•jMJju^r-tk-e^^°AV OtfES «sW0HC9Jc^to8**-:*9 AYy»• :<:o o H llsi ill! i 6«P?l<<«id-«AmV*l>*4H'>f 5uf«jeM>«o-i1 •««<««-•ll*lN«iy°'A'f*"K\«i-«ll<VWft.\ H-0U3HS33S oo oi+u vx§3^n HOjVW ii»u 'W-Mitowii 'wapMm juk/m» %»»«"'»'l»»,,^**..**> •*..^ il US 5 o ft4Ptiwid-lti».V<i»ts»««nc Im^mXi^mn m«s -«"»i\«s>*?<»«AM*'^s\«i-iiirvi»»A\ S.W. r.r.=:=io^? TT~S "~^5T 62nd r.rE.*=3.85 5^ 130 PL4C ^^V^T ii '1 74+00 .^ZM-_fr j-_:3£-S \ .V.....„s:-- ft/lV- -S«I 4KT--fv **"> *k *F r r =-10 4S R*V=7.53 F££fjfr^> *Tk)~"*2"C0\C !.INV«4.00 FEET Jj <S>12"CONC. £INV*4.15 FH T ;:BOTTCw MATCH LINE STA.61+30.00 SEESHEET C-1S MATCH LINE STA.100+50.00 SEE SHOT C-2? l !*l •oc UJCNOVO<.-j^CLU1 00*02+92 VIS 3NI1 HOIVIAI U«ll 'MliatAtitflOO'Hd l»Wl SIQ9&9 ^4* liii ifiJ 5 o 0«»W»td-ftit»i\'<ai)»4»<ii«BmaJaV-**<tf"«s -•Utk\«i"fc4\»:*"«C\<»-iaifWrttt>\\ *i-o L33HS 33s 0009+09 VIS 3NI1 H01VVM •5AVs ».o»uisI*:.•si V\X;«>^/ to n sSsls I t<Mtu**-iuttV*i»w4rs t*im\>i**«v«*-B»;»iVs^,,^»»A',<Nsi-»un*«w\\ 6"(TYP.)I tt r 1.5 IN.TYPE S-1 ASPHALT SU8CRA0E u PAveyen-DBaoN 1.5 IN OFTYPE S-1 ASPHALT PAYMENT OVER PROJEO AMD TACXEO BASE. BASE -tr OF L1MEROCK PLACED M TWOEQUAL LIFTS.COMPACTTO 98% OFMAX OENSTY PERAASKTO T-180-74. SUBGRAOE-MM.C88-2S.COMPACTTO OS*OF MAX.DENSITYPER AASHTO T-180-74. £* s-o: '"'IIIUU*** LOCATION MAP kTS 9t-o 133KS 335 0003+001 VIS 3NH H01VW »<ii o$-«ainjNoo'nd*r«.ibwm lynoj Spuzg -ms & LU Z 8>i il*§ ifi 111] 6«pti<«>w-8ii»tVM|M^Mns ftuvOaV***4V"»-•U*l\*l"f«'4\H**'*S\CI~an-'Un03\\ lH 5^»$.•:?*n ,.?..;C£%*«*«••**«MM NM) |S5>T »*_.^°-g OjflgjNjgqSlTfi SESSl—"*•*-9mn£>?--3BVU-NK0NMM tBUN V3imms E 3JA1 mUXAWIB 1HOU o-4 Minims 13djul 3JU JO KUMH SMLND SNQttVMOfiEH »SOTS ON• TIT*M MOMS SY 3N 01 N0UMO1I homm •» rsnntuo shl Mm smmnoqov ni azounoo aa n» iTtfG 3ML1VMLOS Y4WWOTJ (OOM 3ML01WON JUOTWOSKL SMOffiM NPCnUJK TWJNINW *OW 01 M*B»M tOM*MOB MM MMJO <9NEVN ATOflttOIT*UNI NOJ«OW 01 NM»NIOMt MOD MM NM0« vaMMtfBuaatviQrWww NO OSiON S*Q3S0 »TWW8 fiNMlOO 9N MOL "308 *W HO »«VJ WTO 30SVH I "55UOTT Full intersection ofSW 64th Ct and SW 63rd Tr to be milled and resurfaced as shown below. Sheet C-5 shows partial restoration limits.Full extents of restoration is shown in sketch below. Theadditionalquantities are summarized as follows: Milling area =273 SY ResurfacingTypeS-1 (V)=15tons S.W.63rd F.FX.-9.86 .* --*V-\—L-+- tfy -ASeHAU wj^-wAS«4ALvF\^©-P-w -^vA^—w -qr-tf/ASPRf *^* f TERRACE F.F.E.=10.01 HEOGE I *9\ASPHALT /jfe^ASPHALT/^F ^*^ Y^P &<^/r-7#P^cV"c>s—T^0*8 fc6AS—^-CAS-——CAS—3$*as ^J^/^l^S^iV*Vu/2 S°°VlASPHAl^/S S0D * *AS 5'CA V"ASPHALT 1?^^^r^"~F.F.E.=10.03 Denotes restoration area as shown in Sheet C-5 Financial Project ID:N/A County:Miami-Dade CITY OF SOUTH MIAMI UTILITY WORK SCHEDULE FederalProject ID:N/A State Road No.:N/A Project Name:Twin Lakes Drainage Improvements Utility Agency/Owner (UAO):Miami-Dade Water &Sewer Summary of Utility Work And Execution umrrjes 1004 Paget of3 NON-CONSTRUCTION ITEMS ESTIMATED CALENDAR DAYS CONSTRUCTION ITEMS ESTIMATED CALENDAR DAYS TotalPreliminary Total Material Procurement Total Right-of-way Acquisition Total Other N/A N/A M^ N/A Total Prior to Project Construction TotalDuringtoProject Construction _0 0 Thisdocumenthasbeendevelopedasthemethod for a Utility Agency/Owner (UAO)to transmit totheCityof Miami,the Contractor, andother right-of-way users,the location,relocation,adjustment,installation,and/or protection oftheir facilities,onthisCityof Miami projectThe following dataisbasedon City of Miami plansdated 6-1-2015.Any deviation bytheCityof Miami orits contractor from the plans,asprovided,mayrenderthiswork schedule nullandvoid.Upon notification bytheCityof Miami ofsuchchange,this utility may requireadditionaldaysfor assessment andnegotiation of a new workschedule.ThisUAOisnotresponsiblefor events beyond the controlof the UAOthatcouldnotreasonablybeanticipatedbytheUAOandwhichcouldnotbeavoidedby the UAOwiththe exercise ofduediligenceatthetimeofthe occurrence.The UAO agreesto notify theCityof Miami in writing prior to starting, stopping,resuming,or completing work. During the project,the UAOshalllocatetheirfacilitieswithin48hoursofnoticetotheir Representative. Representative:Telephone Number: UAOProjectRepresentative:See sectionB Telephone Number See sectionB E-mail:SeesectaiB UAO Field Representative:See section B Telephone N umber:See sectionB E-mail:See sectionB UAO Field Representative:See sectionB Telephone Number:See sectionBE-mail:See sectionB Thisdocumentisa printout ofaCityof Miami form maintained inan electronic formatandallrevisionstheretobythe UAO in the form of additions,deletionsor substitutions are reflected onlyinanAppendix entitled "Changes to Form Document"and nochangeismadeinthetextofthedocument itself.Hand notations on affected portions ofthis document mayreferto changes reflected intheabove-namedAppendixbutare for reference purposes onlyanddonotchangethetermsofthe documentBy signing this document,the UAO hereby represents thatno change hasbeenmadetothetextof this document except throughthetermsoftheappendixentitled"ChangestoForm Document". You MUSTsignify by selectingorcheckingwhichofthe following applies: 15]'No changes to forms document CI *Appendix "Changesto Forms Document"is attached.NumberofAttachmentPages. AMtNrittfl^UQD&LAgeiyb 'Engineer of Record (EOR):Acceptance by DistrictUtilities: (Signature) Patrick Chong (PrintedName) Utility Coordination Supervisor (TKfe) (Date) (Signature) (Printed Name) (Title) (Date) (Signature) (Printed Name) (Title) (Date) ("When requestedbythe District,theEORwill attest to compatibility ofplans,specificationsand Utility WorkSchedule) 82 Project Number N/A Project Name:Twin Lakes Drainage Improvement Utility Agency/Owner (UAO):Miami-Dade Water &Sewer onroFSOUTH miami ununes UTILITY WORK SCHEDULE Rage 2 of3 B Special Conditions /Constraints City of South Miami 1-MDWASD requires thataccesstoallwater andsewervalves,sanitary sewer manholes,andother control mechanismsbe maintained throughout construction in the event of an emergency to ensure the public health and safety.Covering valve boxes and manholes can be considered unauthorized obstruction of and tamperingwithDepartmentUtilities.WASDvalveand manhole covers must be adjusted tofinalroadway elevation per standard detailWS1.0and SS 8.0, 2-Contractortolocateand proceed with caution when excavating within3feetof MDWASD facilities.Theprotection of the existing water and sewer mains throughout theconstruction process is CRITICAL totheongoingoperationof MDWASD.The City's contractor must taketheappropriate measures toprotect WASD facilities during construction.It shall bethe contractor's sole responsibility to vertically and horizontally protect all existingWASD utilities onthisproject Anydamageto WASD utilitiesshallbe immediately reportedtothe24hrWASDemergency Hot Line (305)274-8272.WASD reservestherighttoremedyany damage at the expense of the contractor. 3-The City's Contractor must contact WASD's Meter Shopat (786)268-5098 with2 weeks noticetocoordinateand schedule anyneededreplacement of water meter boxes. 4-TheCity'sContractormust contactWASD'sWater Distribution Division at (786)268-5547 with2 weeks noticetocoordinate&schedule anyneededwatermeter Relocation. 5-The City's contractor shall coordinate andworkwith WASD toadjust,relocate and install any WASD facility requiring worktobeperfomiedduring construction of the roadway project 6-ExistingWASDutilitiesaretoremainin service during construction unless otherwise approved byWASD.All existing WASDutilitiesaretoremain unless Otherwise noted. 7-This Utility Work Schedule supersedes any previously submitted UWSfor this project Contact Information:24hr WASD EMERGENCY HOTLINE:(305)274-9272. George Aguiar (786)268-5191 GLAGU01 @miamidade.gov Chief Construction Management Div. Luis Aguiar:(786)268-5401 LAGUI@miamidade.gov Chief,Water Distribution Div. RodLovett:(786)268-5025 RODLO@miamidade.gov Chief,Sewer CollectionDiv. Al Galambos:(786)268-5501 AGALA@miamidaae.gov Chief,PumpStation Maintenance Div. Isaac Gutierrez (786)268-5173 IGUTl@m1amtdade.gov PumpStation Unit-Construction. Financial Project ID:N/A County:Miami-Dade CITY OF SOUTH MIAMI UTILITY WORK SCHEDULE Federal Project ID:N/A State Road No.:N/A Project Name:Twin Lakes Drainage Improvements Utility Agency/Owner (UAO):Miami-Dade Water&Sewer UTILITY FACILITIES BY TYPBSEE/MATERIAlJOFFSErTO BASELINE FROM STATO STA 1.Existing Water mains. 2.Existingvalve box 3.Existing water meter boxes. Disposition of Facilities (List AH Existing &Proposed)on Project: DESCRIPTION OF UTBJTYWORK To remain.Possible conflictwith proposed drainage structure S-2,S-6,S-12,$-14,S-18 and 18-inch drainage pipefrom S-22 toS-23.If relocationofa WM is needed. Toremain.See note1 section B page 2. To remain. DEPENDENT ACTIVITIES M.O.T. PHASE NUMBER N/A N/A N/A UTILITIES Page3d3 CONSECUTIVE CALENDAR DAYS EXHIBIT 2 Insurance ft Indemnification Requirements 1.01 Insurance A Wrthout limiting Its BiMrty,the contractor,comurtaiftorcoiuutongnVm "FIRM"with regard to Insurance and Indemnification requirements)shall be required toprocureand maintain atitsownexpenseduringthelifeofthe Contract;Insurance ofthetypesand In the minimum amountsstatedbelowas wfll protect the FIRM,fTomctairravWiteh mayariseout of orresultfromthe contract orthe performance of thecontractwith theChyof South Miami,whethersuchclaim is against the RRM orany sub-contractor,orby anyone directly or Indirectly employed byanyofthemorby anyoneforwhoseactsanyofthemmaybe liable. B.No Insurance required bytheCITY shall be Issued orwrittenbya surplus Ines carrier unlessauthorized Inwritingby the CITYandsuch authorization shall beatthe CITTs soleandabsolutediscretion.The RRM Jhai purchase Insurance fromand shall maintain the Insurance withacompanyorcompanies lawfully authorized to sel Insurance In theStateof Florida,on forms approved bytheStateof Rortda,as will protectthe RRM,ata minimum,fromallclaims assetforth befow whichmayarte out of orresult trom the RRM^operations wider th^ such operations bebythe RRM orbya Subcontractor orby anyone dlrecdy or Indirectly employed by airy oftJiein orby anyone tor wh^claims underworkers9 compensation,disability benefitandother similar employee benefit actswhich areapplicable totheWork tobe performed;(b)claims for damages because ofbotfly injury,occupational sickness or disease,or death ofthe RRM*s employees;(c)claims for damages because ofbo<^iriJuryt sickness or disease,or deathofanypersonotherthanthe FIRM'S employees;(d)dakns for damages Insured by usual personal injury fiablRty coverage;(e)claims for carnages,other than tothe Work Itself,because of injury toor destruction of tangible property,Inducing lossofuse resulting there from;(J)claims for damages because of bodily injury,death ofa person or property damage arising outof ownership,maintenance oruseofa rrKrtorvehlde;(g)claims for bodily Injury or property damage arislr^c^it of oomp^er^op^iatfons;and (h)claims Involving contractual liability insurance applicable tothe FIRM'S obfettlons undertheContract 1.02 Rmrs Inwrai^ffl gfflrflralfy.tr»™m shall provideand maintain In forceandeffectuntil all the Work to be performed under this Contract has been completed andaccepted byCITY(or for such duration as fa]otherwise specified hereinafter),the Insurance coverage writtenon Florida approved forms and asset forth below: 1-03 Workers'C^ytrTaalton Inniranca atthe statutory amount asto ail employees In compliance with die "Workers'Compensation law"ofthe State of Fforidainduding Chapter 440,Florida Statutes,as presently written or hereafter amended,and all applicable federal laws.In addition,the policy (tes)mustinclude:Employers1 Liability atthestatutorycoverage amountThe HRM shall further insure that all of Its Subcontractor rnaintatn ap levels ofWorker's Compensation Insurance. 1.04 Commercial Cony™hftnstv»figwrd IhhiHty Insurance with broad form endorsement;aswell as automobile liability,completed operations and products liability,contractual liability,severabOhy ofinterestwith cross llabllty provision,and personal Injury and property damage liability with limits of $1,000400 combined single limit per occurrence and $2000000 aggregate,Including: •Personal Injury:$1,000,000; •Medical insurance:$5,000per person; -Property Damage:$500,000 each occurrence; 1.05 Umbrella Commercial Comprehend™General Liability insurance shall be written ona Florida approved form withthe same coverage asthe primary Insurance policy butinthe amount of $1,000,000 perdaim and $2,000,000 Annual Aggregate,Coverage mustbe am?rdedonafomnonxrere*tric^ the Comprehensive General liability policy,without restrictive endorsements,as fifed bythe Insurance Services Office,and must Include: (a)PremisesandOperation (b)IndependentContractors (c)Products and/or CompletedOperations Hazard (d)Explosion,CoHapse and Underground Hazard Coverage ss (e)Broad Form Property Damage (t)Broad Form Contractual Coverage applicable to this specific Contract Including any hold harmless and/orindemnification ayeement (a)Personal Injury Coverage with Employee andContractual Exclusions removed,with minimum limits of coverage equal tothose required for Bodily Injury UabdKy and rYoperty Damage Liability. 1.06 Bnthiftt€^»mny^|n |.^hHtpy^trt%minimum limits ofOne Million Dollars ($1,000,000.00)phis an additional One Mffllon Dollar ($l,000,000XX))umbreBa per occurrence combined single fimlt for BodBy Injury Liability and rYoperty Damage Uabiliiy.UmbreHa coverage mustbe aflbrded onaformnomore restrictive than the latest editfon ofthe Btisme^ state of Florida,and must Include: (a)Owned Vehicles. (b)Hired and Non-OwnedVehicles (c)Employers'Non-Ownership 1.07 SUBCOOTRACraTluiHRMflflrj^ subcontractshall contain thesameInsurance provision as set forth in section 5.1 aboveand 5.4 belowand substituting theword Subcontractor fortheword IWIm^ 1.08 Rre and Extended Coverapi Insurance (Builders'RttkV IF APPUCABLEr A.bi theeventthatthis contract blvolves the construction ofa structure,theCONTRACTORshall maintain,with an Insurance Company or Insurance Companies acceptable tothe CITY."Broad11 form/All RiskInsurance on buildings and structures,including VahdaBsm &Malidous Mischief coverage,while In the courseof construction.Uvdudlng foundations,additions,attachments andall permanent fixtures beloiHjng to aitdconstituting apartof taWbd Trie policy or poBdes shall ate cover machinery,ifthecostof machinery is included In the Contract,or rfthe machinery is located Ina building thatisbeingrenovatedbyreason of this cc^ttract Theamountofinsurance must at alltimes,beatleast equal to the replacement andactual cash value ofthe Insured property.The policy shall be In thenameof the CITYandtheCONTRACTOR,astheir Interestmayappear,and shall ate covertheInterestsof all Subcontractors performing Work. B.Allofthe provisions set forth In Section 5.4herein belowshall apply to thiscoverage unless it would be dearty not applicable. 1.09 MjscaBaneous; A.tfa^ifottecrfm should any Insurance have an expiration datethat win occur during the period ofthis contractthe RRM shall be responsible for securing otheracceptabfe Insuranre prior to such change,or expirationsoas to provide continuous coverage as specified In thissectionandsoas to maintain coverageduring the life ofthis Contract B.All deductibles iwm bededaredbythe RrWM^ CITY,eitherthe RRM shall eliminate orreducesuch deductible or the FIRM shall procurea Bond,In a form satisfactory to theCITYcoveringthe same, CThe poiWes shall contain waiverc^subrogation against CITYwhere applicable^ thatsuch policy or pofides are primary overanyother collectible insurance thatCITYmay have.The CITYreservesthe r^atariytlnw shall contain a "severability of Interest/'or "cross liability0 clause without obllgition (orpremium paymentoftheCITYaswellas contractual fiablRty provision covering the Contractors dutyto Indemnity the Chy asprovidedIn this Agreement D.Beforestartingthe Work,the FIRM shall deliver to theCITYandCONSULTANT certificates ofsuch InsuraiKe,acceptable to tfw CITY,asw inducing the declaration page andall applicable endorsements and provide the name,address and telephonenumber ofthe Insurance agentorbroker through whomthe policy was obtained.The insurer shall berated A.VII orbetterperAM.Best'sKey Rating Guide,latest edition and authorized to Issue insurance IntheStateof Florida.Ail Insurance polides mustbewrittenonforms approved bytheState of Florida and they must remain In tollforceand etrecttV the duration of th^ CITY.The FIRM maybe required bythe CITY,at its sole discretion,to provide a "oerthled cop/'ofthe Policy (as defined in Article I ofthis document)which shall Include the declaration page and all required endorsements.In addition,theRRM shall deliver,atthetimeof delivery ofthe Insurance certificate,the following endorsements: (I)a policy provision oranendorsementwith substantially similar provisions as follows: 84 'The City ofSouth Miami is an additional insured The insurer shall pay ail sums that the City of j South Miami becomes legtily obligated topayas damages becauseof 'bodily Injury",•property damage9,or "personal and advertising injury"andit will providetothe Qty all of the coverage that Is typically provided under the stanch Florida approved forms fo liability coverageAandcoverage B"; (2)a pdlcyprovfakmorajiendorsen^M j "This policy shall not be cancelled (including cancellation for non-payment of premium),! terminatedor materially modified withoutfirst giving the CHyofSouth Miami ten (10)days advanced written notice of the intent to materially modify the policy orto cancel orterminate j the policy for any reason.The notification shall be delivered tothe Cityby certified mall,with ; proofof delivery tothe Qty.*' IftheRRMIs providing professional services,such aswouldbe provided byanarchitect engineer, attorney,or accountant to narnea few.then In such evem I the HRM shall also provide Professional Liability Insuranre ona Roridaapproveti form j $1,000,000 with deductible per dalm If any,nottoexceed 5%ofthe liinit of liability p sumswhichtheRRM shad become legally obligated to pay as damages for claims arfoing out ofthe services orwork performed by the RRM Its agents,representatives.Subcontractors orassigpis,orby j any person employed or retained by him in connection with thisAgreement This insurance shall be I maintained for four years after completion ofthe construction and acceptance of any Project covered by \ this Agreement However,the RRM may purchase Specific Project Professional Liability Insurance.In the [ amount and under the terms specified above*which is ate acceptable.No Insurance shall be issued by a \ surplus lines carrier unless authorized m writing bythedtyatthe dt/s sole,absolute and unfettered j Indemnification Requirement AThe Cbntractor accepts and voluntarily incureaH risks of an^ ariseduring theworkoreventthatis CKXurririg onme CITTs propertydueto tf Contractororanyone acting through or onbehalfoftheCbntractor. B.The Contractor shall Indemnity,defend,save andholdCITY,its officers,affiliates,employees, successors andassigns,harmless from anyand aOdaireges,claims,ItaH^ Judgments orcost and expenses,inducing reasoiiableattorne/s fees,paralegal fe^an^ incidental thereto and incurred prior to,during or following any litigation,mediation,arbitration andat ail appellate levels,which may be suffered by,or accrued against charged toor recoverable from theCityof South Miami,its officers,affiliates,employees,successors and assigns,by reason of any causes of actions or dalm of any kind or nature,including claims for Injury to.or death ofany person or pei^oris and forthe loss or damage to property arising out ofanegligenterro^ conduct ofthe Contractor,its contractor/subcontractor or any oftheirofficers,directors,agents,representatives, employees,or assfyis,or anyone acting through or wi behalf of any of then^arising otit of this Affreemen^ Inddent to it or resulting from the performance or non-perforrnance ofthe Contractor's obligations underthis AGREEMENT. CThe Contractor shall pay all claims,losses and expenses of any kind or nature whatsoever,In connection therewith,Inducing the expense or loss ofthe CITY and/or Its affected officers,affiliates,employees, successors and assigns,Inducing their attorney's fees,in the defense of any action In law or equity brought against themand arising fromthe negligent error,omlsston,or aa ofthe Cmitractor,Its Sub-Coin^ agents,representatives,employees,or assigns,and/or arising outof,orinddentto.thisAgreementor incident to or resulting from the performance or non-performance ofthe Contractor's obligations under this AGREEMENT. D.TheContractoragreesand recognizes ttat neithertheCITYnorits officers,affi^ successors and asstyps shall be held liable or responsible for any claims,Including the costs and expenses of defending suchdalmswhichmayresultfromor arise outof actions or omissions ofthe Contractor,Its cc^itractor/subcontractor or any oftheiragents,representatives,employees,or assigns,or anyone acting through oron behalf ofthe them,and arising outofor concerning theworkor event that Is occurring onthe CITY'S property.In reviewing,approving or rejecting any submissions or acts ofthe Contractor,QTY In no way assumes or shares responsibility or liability for the acts or omissions ofthe Contractor,Its contractofysubcentractor or any of their agents,representatives,employees,or assigns,or anyone acting through oron behalf of them. 87 E.The Contractor has the duty to provide a defense with an attorney or law firm approved bythe City of South Miami,which approval will notbe unreasonably withheld F.However,asto design professional contracts,and pursuant to Section 725.08 (I),Florida Statutes, none ofthe provisions set forth herein above that are In conflict with this subparagraph shall apply and this subparagraph shall set forth the sole responsibility ofthe design professional concerning Indemnification.Thus, the design professional's obiigutons astothe Qty and Its agencies,aswell asto Its officers and employees,Is to indemnity andholdthem harmless from liabilities,damages,fosses,and costs,Including,butnot limited to, reasonable attorneys'fees,totheextent caused bythe negligence,recklessness,or Intentionally wrongful conductofthe design professional andother persons employed or utilized bythe design professional In the performance of the contract END OF SECTION CERTIFICATE OF LIABILITY INSURANCE DATgpaMwrm) 7/17/2015 THI8 CERT1RCATE 18 ISSUED A8 A HATTER OF INFORMATION ONLY AND CONFERS NO RIGHTO UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOE8 NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTENDOR ALTER THE COVERAGE AFFORDED BY THE POUCIE8 BELOW.THI8CERTIFICATE OP INSURANCE D0E8 NOTCONSTITUTEA CONTRACT BETWEENTHEISSUINGIN3URER(8),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT;Iftfta certrffcate rwldy ^H8UroO<^TION IS WAIVED,subject to the tanns and condnTene ofthe policy,certainpollcleamay lesjube an endonisinsnt A statement on this certificate does net confer rightstothe certificateholderIn lieu ofsuch endcraereenffe). Baatorn Znauraaoe Group,lac. 8570 SIT 107 Avenue Suite 104 PL 33176 Maggolc,Inc. 11020 SW 55 Straat FL 33165 David M.Lopas -^(305)585-3383 awandaGeapterninanirance.not iw.ttOS)99B-113S wmsmmmoKamaeamMOE awes WBuaiWAdOolony Insurance Company eaaaaaaatapgra Insurance Co.of Florida wawttjjcrTbraa national Company •jguwatDfluaineesFlrst Inauranca Co. aauaeaa federal Xnanranoa Coapany jBSBB^^ULih COVERAGES CERTffK^TENUMBER*aater 14-15 Auto Raw REV18ION NUMBER: TH8 IS TO CERTIFY THAT THE POUQESCF INSURANCE LISTH)BaCWHAV^ INDICATED.NOTWITHSTANDING AW REQUIREMENT,TERMORCONDITIONOFANVCONTRACT OR OTHERDOCUMENTWITH RESPECT TO WHICH THS CERTIFICATE MAYBE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED SY THS POLICIES DESCRIBED HEREIN 18 SUBJECTTOALLTHE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POUaES.UMTTS SHOWN MAYHAVE BEEN RED fig TvrewMSURANce X A X cotsaetctALOBamaLiMaajfY 9E [xj OCCUR 103OL000S301-00 9/23/2014 9/22/2015 EACH OCCURRENCE S 1,000,000 |CLMMS4IA1 DAIIABETORBnEO 1 100,000 MB>EXP (Any on»pawn)s 5,000 FERSONALS ADV04AIRY $1,000,000 GENLAGGREGATE LOUT APPLIES PER:GENQttL AGGREGATE s a,000,000 POUCYlXjSffit ||")C other: PfWOUCTS-COMWOPAGO $2,000,000 $ B AUTQttOBaJBUABttJTY 4150130009*52 7/17/SOiS 7/17/2010 fm^miim $1,000,000 X X ANYAUTO toDOYINJURY(Pvpenon)s sasr0 HWED AUTOS X SCHEDULED NOwSvMED AUTOS BCOILYWJURY{Partoddflnq s WggWcVWAoE s HftlrW8 s 1,000,000 C X UMBRELLAUAB EXCESS UAB OCCUR CLAIMS-MADE ssaaaKi40SLz 9/22/2014 9/22/201S EACH OCCURRENCE *3,000.000 AGGREGATE $3,000.000 s D 1MB mascoavENSATioN •Mill ll»W'1 H1I IIM N/A sai-ixssa 9/22/2014 9/22/2015 .IffiSh^l IS> MWPRORfeiwwwnNeajBcounvB i—i€mxMuamEHExaxioeo7 ||EJ.EACH ACCIDENT s 100.000 EJ.DtSEA&E-EAElff'lOYB s 100,000 Ei^OtSEASE-POUCYUMrr 1 300,000 B B Baated/tTsaaad Bguipnant Contractor*a Bquipaant 454(9147 45469147 11/2/2014 11/3/2014 11/2/2015 11/2/2019 |2S0,000 $254,015 DttCIWmWWOPCWmOliS/UX^TKWS/VlHiClEa (ACCTO1t1,*MRknilitara*^ Asphalt paving,conorata oonatruotion and drainage construction City of South Miami and Miami Dada County are liatad aa an additional named lnaurad and shall be provided written notion 30 daya before modifloation of this policy or cancellation for nonpayment of pramium or otherwise.Coverage aa an additional insured is provided if required by written contract. CERTIFICATE HOLDER CANCELLATION City of South Miami Building 6 Bossing Department 6130 Sunset Drive Miami,FL 33143 SHOULD ANV OFTHE ABOVE DESCRJBEO POLICIES BE CANCELLED BEFORE THEEXPIRATION DATS THEREOF,NOTICE WBJ.BEDELIVERED M ACCORDANCE WITH THE POLICY PROVISIONS. AimtCKSZei REPRESENTATIVE David Lopes/AMANDA '~_,I _^~ ACORD 25(2014/01) IN802S 001*11 •1888-2014ACORDCORPORATION.All rights reserved The ACORD name and logo are registered marks of ACORD EXHIBIT 4 Citywide Drainage Improvement Projects RFP#PWM0IM9 CONSTRUCTION BID FORM THS PROPOSAL IS SUBMITTED TO: Steven Alexander City of South Mfarnl 6130 Sunset Drive South Miami,FL 33143 1.Ifthis Proposal Is accepted,the iinderijgned Respondent aarees toenterInto a Contract with the Qty of South Miami intheform Induded In this Solicitation radcage andto perform and furnish all workas specified or Indicated Inthis Solicitation,Indudlngas setforthIn Exhibit I (Scope of Services)for the Proposed Price asset forth below,within theContractTimeandIn accordance withtheothertermsand conditions ofthe SoBdtation Package. 2.Respondent accepts all ofthetermsand conditions ofthe Solicitation and Instructions to Respondents, IndudiigvWthoutDrratation those de^This rVoposalw!UrerrahisubJetttoacceptam»f6r 180 calendar days afterthe day ofdie Proposal Opening. The Respondent;by sibling and submitting this proposal,agrees to all ofthe terms and conditions ofthe formofcontraathatIsapartofthe Solicitation package with appropriate changes to conform tothe Information contained In this Bid Form.Respondent agrees to sign and submit the Bonds,if required by this Solicitation,required Insurance documents,andother documents required bythe Solidtation, Inducing the Contract ifnotalready submitted,within ten (10)calendar days after the date ofthe City's Notice of Award 3.In submitting this Proposal,Respondentrepresents that a.Respondent has examined copies of ad the SoDdtation Documents and of the following Addencb,ifany (receiptof ail which Isherebyacknowledged) Addendum No.±0u-jmf Z"Dated:^f^^/nf **"-+*fftfft* b.Respondent tas familiarized himselfwith die natureandextent oftheContractDocuments,theproposed work;site,locafity,and ail local conditions andlawsand regulations that In anymannermayaffect cost; progress,performanceor c Subsurface conortions:If applicable to this Solicitation tn^ i.Respondenthasstudied carefully all reportsand drawings,if applicable,of subsurface conditions and drawings of physical conditions. II.Respondent has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying)all such examinations,Investigations,explorations,testsandstudiesin addition toorto supplement those referred to In this paragraph which pertain tothe subsurface or physical conditions atthe site orotherwisemayaffectthe cost;progress,peirbrmance,orthe furnishing ofthe Work at the Contract Price,within the Contraa Time a^ina of theContract Documents.The Respondent herebyacknowledges thatno additional examinations, Investigations,explorations,tests,reportsor similar Information or data are,or will,be required by Respondentforanyreason in connection withthe Proposal.The failure oftheRespondentto request a pre-bld marking ofthe construction she byanyor all utility companies shall createan irrefutable presumption that die Respondents bid,or proposal price,hastaken Into consideration all possible underground conditions and Respondent,tf awarded the contract;shall notbe entitled toa change order foranysuchcondition discovered thereafter. Hi.Respondenthas correlated theresultsof ail such observations,examinations,investigations, explorations,tests,reportsand studies withthetermsand conditions oftheContractDocuments. 91 Project Name: RFP NO. Sent South%liami THE CnY OF PLEASANT UVING APPENPUMNo.ffl CitywideDrainageImprovementProjects PW-20I5-I9 July 29.2015 Fax/EHinauTWebpage Thisaddendum submission is issued to clarify,supplement and/dr modHy the previously issued Solicitation,andisherebymade part ofthe Documents.Allrequirementsof the Documents not modified hereinshall remain in full forceandeffectas originally set forth.It shall bethe sole responsibility ofthebiddertosecure Addendums that may be issued fora specific solicitation. Canyoutellmeiftheplansforthisproject includes the installation oftype II baffle boxes? Answer to Question Ml t Both projects,SW 78*Street and Twin Lakes Drainage,will use a Type II Skimmer (baffle) according to FDOTStandard Index 241. Is there abudgetforthisproject? to Question #2; Thereisnota specific lineitemforthe construction portion oftheprojectinthe Cit/i Adopted Budget for FY 2014 -2015,Capital Improvement Program 5-Year Plan. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. Paget of 1 \k$ sfrV Sou#Miami THCCmrOfRIASANTUVlNC APPBNPUHNfftiB Project Name:Citywide Drainage ImprovementProjects RFP NO.PW-20I5-I9 Date:August 5,2015 Sent:Fax/E-mail/webpage TMs addendum submission isissued to clarify,supplementand/or modify the previously Issued Solicitation,and Is herebymade part ofthe Documents.AH requirementsofthe Documents not modified hereinshallremainin full forceandeffect as ori&nalfy set forth.Itshallbe the sole responsibility of the biddertosecure Addendums thatmaybeissuedfora specific solicitation. I.Rage 54ofthe RFP refersto additional quantities for milling and resurfacing butthose quantitiesare not includedwith the Schedule of Values.Canyou clarify? The sketchshownonpage54ofthe RFP isreferringto additional quantities for milling and resurfacing depictedinthesolid grey hatch.These quantities are not included withinthescheduleofvaluespostedwithinthe RFP. ArevisedScheduleof Values is Included withAddendumNo.2and,is apartofthis RFP bywayofthisreference.TherevisedScheduleof Values Includes the additional quantities inthe milling and resurfacing line items forsheetC-5andto clean upsome line Items forbothAreas I and2that wore repeated,with different typesof units. 2.Will the Chy acceptalternatestothe A-2000 pipe material specified? RESPONSE: Yes,the City will accepta HDPE pipeasanalternate material. IT SHALLBETHESOLE RESPONSIBILITY OFTHE BIDDER TO SECURE sQj^ ADDENDUMS THAT MAYBE ISSUED FORA SPECIFIC SOLICITATION,(-* Paget of1 pW (v.Respondent has reviewed and checked all Inforrnation and data shown or Indicated inthe Solicitation I Package orIn the Contract Documents with respect to existing Underground FadDties orconditions j at or contiguous to thesiteandassumes responsibility fortheaccuratelocationof ail Underground 3 radfities and conditions that may affect the Work.No additional examinations,Investtgttlons,\ explorations,tests,reports or similar Information or data in respect to any Underground radioes or conditions are,or will be,required by Respondent in order to perform ai^furnish the Work atthe j Contract Price,within the Contract Time and in accordance with theother terms and conditions of j theContract Documents unless the Proposal specifically statesthatthecontract price is subject to | adjustment for future discovery of underground fadlfties and/or conditions that affect the cost ofthe j Work andunlesstherespondent makes awrittenrequesttotheCityfor additional Information priorto submitting thebid or proposalasrequiredInsubsectionIIabove,; Respondent has given the Qty writtennoticeofall contacts,errors or cSscrepandes that ithas discovered in the Contract Documents and,ifany conflicts,errors or discrepancies havebeenfound andnotice ajven,the Respondent represents,by submitting itsproposaltotheChy,thatthe Respondent has received sufficient noticeofthe resolution thereof fromtheQty,thatsuchresolution Is acceptable to Respondentandthatthe Respondent waivesany dalm regardingthe conllcts,errors or a.This Proposal isgenuineandnotmadeIntheinterestoforon behalf ofany undisclosed person,firm or corporationandisnotsubmittedpursuanttoanyagreement or rulesofany group,association, organization,or corporation;Respondenthasnotdirectly or indirectly induced or soHdted any other Respondent tosubmita false orsham Proposal;Respondent hasnot solicited or induced any person, firm or corporationto retrain from responding;and Respondent hasnotsoughtby collusion or otherwiseto obtainfor itself any advarttage everanyodier Respondent or Respondentunderstandsandagrees diat theContract FVice istheamount trau ft Install all oftheWorkcompleteand In place.The Schedule of Values,if required,is provided forthe purpose of Proposal Evaluation andwhen Initiated bythe QTY,it shall formthe baste for calculating the pricing of change orders.The Contract Price shall notbe adjusted inanywaysoastoresultIna deviation fromthe Schedule of Values,excepttotheextentthatthe CITY changes theScopeofthe WorkaftertheContract Date.As such,the Respondent shall furnish all labor,rrraterrals,equipment, tools,superintendence and services necessary to provide a complete,In place,Projectforthe Proposal Price,Ifthis Solicitation requiresthe completion ofaCostand Technical Proposal,asmaybesetforthIn In anexhibitto this Solldtation,such proposal must be attached to this Bid Form and will take the place of the Lump Sum Price,otherwise,the Contract Pricefor the completed work is as follows: LUMP SUMRASEPRICE: Alternates:#1 #2 Afee breakdown foreachtask Induded Inthe lump sum contractprice,Ifapplicable,mustbe provided. Failure to provide this information shall render die proposal non-responsive. 5.The ENTIRE WORK shall be completed,in foil,within 90 calendar days fromthe commencement date setforth In the NOTICE TO PROCEED.Failure to complete theentirework during the described time period shall result In the assessment of liquidated damages as may besetforthintheContract 6.Insertthe following information for future communication with you concerning this Proposal: RESPONDENT:AfgCLpfrLe,*£Uc *f Telephone:^jflg-Mf-?^*<*J ContactPerson AJaW*G»A>**Je.<iS w r f 7.The terms used in this Proposal which are defined In the Contract shall have the same meaning as Is \ assigned to them in the Contract Documents,unless specifically defined In this Solicitation Package.\ &ifa cost &technical proposal Is required bythe Solicitation,Respondent hereby certifies that all ofthe facts and responses tothe questions posed In the cost cctechnicalproposal,Ifsuch an exhibit Is made apartofthe Solicitation,aretrueandcorrectandare hereby adopted aspartof this BidForm,andare madeapartof this proposal,by reference. 9.d>submitting this proposal,I,on behalf ofthe business that I represent,hereby agree tothe terms ofthe form of contract contained In the Solicitation package and I agree to be bound by those terms,with any appropriate blank boxes,If any,checked and any blank lines filled In with the appropriate Information contained In the Solicitation Documents andthis Proposal,or such information thattheChyand I have agreed uponinthe course ofcontract negotiations and which have bean confirmed bythe Qty Inwriting Inducing e-mail confirmation,If any.I hereby certify under penalty of perjury that I amthe lawful representative ofthe business entity referenced In this Bid Form and that I have authority tobidthat entity. SUBMITTED THIS /3 DAY OF AiJfO&-P 20 fS[ /)TelephoneNumber >%m*ue.ittu«.c^ TTtta fasjJL^ END OF SECTION M EXHIBIT 5 RESPONDENTS COST ft TECHNICAL PROPOSAL Citywide Drainage improvement Projects RFP WW-2015-19 Respondents shall quote both Projects -"SW 78 Street ft63 Avenue,"and Twin Lakes.The CHy,at its discretion,may award both projects to a single contractor or,each project to separate contractors. LUMP SUM BASE PRICE FOR EACH PROJECT ISIN ACCORDANCE WITH EXHIBIT I "SCOPE OF SERVICES,'ATTACHMENT A,B,C,ftD: SUBMITTED THIS SW 78 Street ft 63 Avenue *B8f 634.°* TWIN LAKES AREAI %«S,W AREA2 $/£^£30,~ /•3 DAY OF ./fu~fQ<£ufl~20 /f PROHMAL SUBMITTEDBY: Telephone I £bu&k& hone Number Fax Number fkssJuJ- raxiNumDer / END OF SECTION »4 EXHIBIT 6 CONSTRUCTION CONTRACT Citywide Drainage Improvement Projects RFP#PW~2QI5-I9 THIS CONTRACT was made and entered into on this /&**day of <>44skjf, rveen AM*gft&rZ**~(hereafter referred t ictoO,and thtftety ofSouth Miami (hereafter referred to as "Owner"),through its City Mar m _,20/^TpyandbetweenAMj^tCL^n^(hereafter referred to as XontractcO,and thtftety ofSouth Miami (hereafter referred to as "Owner"),through its Qty Manager (hereafter referred to as "City"). WITNESETH: That,the Contractor,for the consideration hereinafter fully setout,hereby agrees with die Owner as follows: 1.The Comractor shall furnish all labor,materials,equipment,machinery,tools,apparatus,transportation and any otheritems necessary to perform all of die workshownon and described intheContract Documents and shafl do everything required by this Contract and theother Contract Documents hereinafter referred to as the Woric 2.The Contract Documents shall Indude this Contract,General Conditions tothe Contract;if any,die drawings,plans,specifications and project manual,if any,any supplementary or special conditions,other documents referring to this contraa and signed by die parties,the solicitation documents (4ibere*inafter referred to as "Bid Documents")and any documents to which those documents refer which are used by the Owner as weH as any attachments or exhibits that are made a part of any ofthe documents described herein. 3.The Contractor shall commence the Work to be performed under this Contraa ona date tobe specified in a Notice to Proceed and shall complete all Work hereunder within the length of time set forth inthe Contraa Documents. 4.The Owner hereby agrees to pay to the Comractor for the fcithfol pe* to additions and deductions as provided in the Contraa Documents and any properly approved,written change orders.In lawful money of the United States,the amount of:&*tw *»«« *»)3*fl far ndifld /gjg/ury 3*/»vi 4«x«**A*A fui^Dollar*($/&jfco M ,.Lump Sum ("Contraa rVtee"). 5.The expenses of performing Work after regular working hours,and on Sunday and legal holidays shall be Induced In the Contraa Price.The City may demand,at any point in time,that any part,or all,of die Work be performed after regular working hours.In such event,the Respondent shall have no rfeht to additional compensation for such work.However,nothing contained herein shall authorize work on days and during hours that are otherwise prohibited by ordinance unless specifically authorized or Instructed m writingbythe Oty. o.If the Work is expected to require more than one month,the Owner shall make monthly partial payments tothe Contractor on the basis ofaduly certified and approved schedule ofvalues for the Work performed during each calendar month by the Contractor,less the retainage (all as provided for in the Contraa Documents),which is to be withheld by the Owner until completion and acceptance ofthe complete projeain accordance with this Contraa and the other Contraa Documents and until such Work has beenaccepted bythe City. 7.Upon submission by the Contractor of evidence satisfactory to the Owner that all labor,material,and other costs incurred by the Contractor in connection with the construction ofthe Work have been paid in full and after compliance with the terms for payment provided for in the Contraa Documents,final payment on account ofthis Contraa shall be made within sixty (60)calendar days after the completion by ro^"*^0**11 Work covered by this Contraa ami the acceptance of such Work by the Owner. \~1 **&*T CTmpkteJ m ?Q calendar days.In the event that the Contractor shall fail to complete theWork within the time limit stipulated in the Contraa Documents,orthe extended time limit a^etiupon.In accordance with the procedure as more particularly set forth in die Contraa Documents, r Sl^!?da,r^S«B sllaI,*»P^^by the Contractor at the rate of,in accordance with ^Exhibit l»"Scope °1I-.'*—da,tors **r **•P,u$*nX "»•*«*P»W by the Owner to the Consultant,if any,foradditionalengineeringandinspectionservices,ifany,associated with such delay. VS «M««»d aaoWikT the ftSSlS*^ •ceouminf for the other cocnttrpwt,be deemed an orbjml the da/and datamfonh ^daft wfthow proof or EXHIBIT 7 CONSTRUCTION CONTRACT GENERAL CONDITIONS Citywide Drainage Improvement Projects RFP#PW»20I5~I9 ARTICLE I -DEFINITIONS Whenever used In these General Conditions orinthe other Contraa Documents,the following terms shall have the meaning indicated These definitions shall always apply when the section oftheContraa spedfkaOy refers to this Artide for the purpose of interpreting awordor group of words in that section oftheContraa Document. However,whenthe section ofthe Contract,where the word tobe defined is used,doesnot specifically refers to this Artide to define the word or group of words,the definitions contained in this Article shall not apply unless thewordor group of words,inthe context ofitor their use in theContraaDocument in question,is/are ambiguous andopen for interpretation.In addition,these definitions shall also not apply to interpret termsina specific provision ofa Contraa Document Ifthat specific provision contains a definition ofthese terms: Addenda;Writtenor graphic documents issued prior tothe Bid Opening which modifyor interpret theContraa Documents,Drawings and Specifications,by addition,deletions,clarifications orcorrection. Application for Payment:Aform approved bythe CONSULTANT,if any,orthe Chy Manager whichistobeused bytheCONTRACTOR In requesting progress payments. Bid;Theofferor proposal ofthe Bidder subrrritted onthe prescribed fon termsforthe Work tobeperformed. Bidden Any person,firm or corporation submitting a response tothe Owner's solicitation for proposals or bids for Work. Bid Documents The solicitation for bids or proposals and all documents that make up the solicitation induding the instructions,form of documents and affidavits. Bondsi Bid bond,performance and payment bonds and other instruments of security,furnished bythe CONTRACTOR andItssuretyin accordance withtheContraaDocumentsandinaccordancewitfi die lawsof die State of Florida. Change Order;A written order u the COrTOACTORsIgr^ deletion or revision In the Work,oran adjustment in die Contraa Price orthe Contraa Time issued after execution ofthe Contract Work Order ftoopab:Written proposals from the COhTTRACTOR in response to or^ based onthe Scope oftheWork provided bythe City to the CONTRACTOR.The proposal induces line Item pricing where there are multiple locations,and the timeframe for completing the work. QLTL The City Manager fortheCityof South Miami,6130 Sunset Drive,South Miami,ft 33143,unless the context wherein thewordis used should moreappropriately mean the City of South Miami. Construct Qbayyer;An authorized representative of the CONSULTANT,ifany,or otherwise a representative oftheChyassigned to observe theWork performed and materials furnished bythe CONTRACTOR.The CONTRACTOR shall benotified in writing ofthe identity of this representative. ComTaffl PofiatoaBBtc TheContraa Documents shall indude theContraabetweentheOwnerandthe Contractor,other documents listed In theContraa and modifications issued afterexecution oftheContraa as well asall Bid Docwnems induing b^ Insurance endorsements,Insurance Certificates and poBcies,the Notice of Award,the Notice to Proceed,the General Conditions,Special Conditions,ifany,any Supplementary Conditions,theTechnical Specifications, Drawings,induding any Incorporated specifications,addenda to the drawings Issued prior to execution ofthe Contract.Change Orders,C^nstniction Change DirectX Work,and written modifications to any ofthe Contraa Documents, CojttrjcjJHcg;The total moneys payable to the CONTACTOR pursuant to the terTra ofti>eCcmtraa Documents. CojlOTttTIraBl The number of calendar days stated in the Contraa for thecompletion oftheWork. Contract QBcec The individual who is authorized to sign the contraa documents on behalf ofthe OWNER. CONTRACTOR;The person,firm or corporation with whom the OWNl^has execut*^the Contract. TONSULTANTLThe person identified as the CONSULTANT in the Suppiementary Conditions or,ifnone,then OTTs designated representative as identified in the Supplementary Conditions. 97 Ba*A period oftwenty-four hours meuured from the begMn^ to be acalendar day unless specifically designated as abusiness day. Cays;Thenumberoftwemy4Dur(24)h afowed bydieContraa Doctnnents,thec^yoftheact.evemordefauk begins to run shall not beinduded.The last day ofthe period so computed shall beincluded unless it is a Saturday.Sunday orlegai holiday,inwhich event die perk*shdl run uittil the end tf^ nota Saturday,Sunday or legal holiday. PetoftftWorfr;Work that is unsatisfactory,faulty,or defictot In that it does i^Do©jrriems,Q^ r*rred to in the Contract Documents,c^rias been dairoged pr^^ final payment (unlessre*pc*sibi!ityfertile^ arenot|iroperiyapprovedandau^^ ec^pment rurrthhed under theCbntraadiat are not good quality and new unless permitted by the Contraa Documents. Dmwjne;Tliedrawinpwhlchshowte prepared ^approved by the CONSULTANT,or if rtcme,then by an « are referred to In the Contraa Documents. EieJilQ^Awritten orderlssued by the COWULTANT which darifies or interpret M^^MA^*WW0^^^,n^W^ta>W^I&2.ttofflc^on;(a)AwrfttenamendrnentoftheCc^^ signed by both parties,(c )a written darification or Interpretation (f issued by theCONSULTANT in accordance OTrWLTANTpursuaiittoR A modification may only be issued after executwn oftr*Corttrmct,kJ™**^wr^^ Etoi^nfeni^^ uiisa&teoiy.^,or defidem or t^ **»«&test,orthat does notmeet ariyapprovd required by.o work that has been damaged prior to CONSULTANTS recommendation offinal payment (unless responsibtrrtyfor the protection thereof has been assumed in writing by CITY). NotfttOf Award;Th«wrro*nr*>ticebyCIT^ the coikIWwis precede to him. r^fietOPrQCfigfc AwrittennotkeglvenbyCITYtDCOW tteon which the Contract Time shall commence to run and ot which CONTRACTOR s^^ obtqptions under the Contraa Documents. Bason:An individual or legal entity. |b*ttThe entire construction operatkm being pe^ EQffi&The term "policy"as used in the Contraa Documents shall mean the insurance binder,ifit is issued,the ™ao"on page ofthe policy and the body c^the policy,Induding aHeiulomments. BB6 Request for Proposal. fcepetf&rYteeA.TWs phrase refers to die scope of the services or worktobeperfonnedafidithasthesamejrarij^Scoi*^ aaTtaMte AHdrawiru^ the CONTRACTOR,aSubcontractor,manufacturer,supplier,or distributor,and which illustrate the equipment, material or some portion ofthe work and as required by the Contraa Documents. Smfe&rtysfcal examples which illustrate materials,equipment or workmanship and establish standards by which theWork wiy be judged. SjXjcjfieaitaiK Those portions ofthe Contrm Document condsdr^ ™»»s>equipment;construction systems,standards and workmanship as applied to the Work.gwCO^fflrr;Anlndh^tiaJ,tVmc^coiporafo^ other Subcontractor for the rjerfbrmance ofa part ofdie Work atthe construction site. Svlmn^irpmpJeApi Thedate,as certified by the CONSULTAr^.whentr^c^stnH^onoftherroleaora cerdW part thereof issufficiently completed,in accordance with the Contra a substantial part,can be utilized for the purpc^es for which tt was Intended wn^ any degree,cdier than for die repair of minor >unch 1^^ when final payment Is due in accordance with parapaph 14.9.However,in no event shall the projea or portion 98 thereof,be deemed to be substantially completed until a certificate ofoccupancy or certificate ofuse is lawfully issued by the applicable governmental agency.A certificate ofSubstantial Completion.Issued by the CONSULTANT,shall be null and void ifit is based on false,misleading or inaccurate Information,from any source, or when it would not have been issue butfor die consideration of Work thatis thereafter found tobe defective to a degree greater than that which would normally tobeconsidered by the City tobe minor "punch list"work. Supplier;Any person or organization who supplies materials or equipment for dieWork,induding the fabrication ofan item,butwhodoesnotperformlaboratthesiteofthe Work. &DBSG The individual orentitywhoisan obligor ona Bond and who b bound withthe CONTRACTOR forthe full and faithful performance of the Contraa and forthe payment of afl labor,services and materials used onthe projea Work;Any and all obligations,duties and responsibilities necessary for die successful performance and completion of the Contraa Ncticei Theterm "Notice**as used herein shall mean and indude all written notices,demands,instructions, claims,approvals and disapprovals required to obtain compliance with Contraa requirements.Written notice shall be deemed to have been duly served ifdelivered in person tothe Individual ortoa member ofthe firm or to an officer ofdie corporation for whom it is intended,orto an authorized representative ofsuch individual,firm,or corporation,or if delivered at or sentbyregistered mail tothelast known business address.Unlessotherwise stated in writing,any notice toor demand upon die OWNER under this Contraashall be delivered tothe City ManagerandtheCONSULTANT. ARTICTtE 2 -PREMMINAWY MATTERS Award; II Trie CITY reservestrie rfgfrt to reject by the CITY to die lowest responsive and responsible Bidder.No Notice ofAward shall begiven until the CITY has concluded its investigation,as it deems necessary,to establish,tothe satisfaction ofthe CITY, which Bidder is the most responsive and responsible ofall the Bidders to complete the Work within the time prescribed and in accordance with the Contraa Documents.The CITY reserves the right to rejea the Bid ofany Bidder who is notbelieved to be,in the sole discretion and satisfaction oftheChy,tobe suffidendy responsible,qualified and financial able to perform the work.In analyzing a Bid,the CITY may also take into consideration alternate and unit prices,ifi^uested by the Bid fonm^ awarded^the CITY shall issue the Notice of Award and give the successful Bidder aContraafor execution within ninety (90)day after opening of Bids. tyecutionQfCOTracC 23 At least four counterparts ofthe Contract,the Performance and Payment Bond dieCertificates of Insurance,the Binder ofInsurance if issued,the Insurance Declaration Page if not induded in the Policy of Insurance,the Policy ofInsurance required by the Contraa Documents,the written notice of designated supervisor or superintendentas provided in Section 6.1 oftheGeneralConditionsandsuchother Documents asrequiredbythe Contraa Documents shdl beexecutedand c^ tothe CITY within ten (10)calendar days of receipt ofthe Ncdce ofAward.AContraaDocument that rtq^r&the sigriature ofa party may be executed in counterparts separately by each ofthe parties and,In such event,each counterpart separately executed shall,without proof or accounting for the other counterpart be deemed an original Contraa Document fQ$!My^Stmrl^and Rivment Bond.If anv are required by th*apptohte RFft 2.3 Within ten (10)calendar days of being notified ofthe Award,CONTRACTOR shall furnish a Performance Bond and a Payment Bond containing all the provisions of the Performance Bond and Payment Bond attached. 23.1 Each Bond shall be in the amount of one hundred percent (100%)of the Contraa Price guaranteeing to OWNER the completion and performance oftheWorkcovered In such Contraa as well as full payment ofall suppliers,material man,laborers,orSubcontractor employed pursuant to this Projea.Each Bond shall bewith a Surety company whose qualifications meet the requirementsofSections 2J.4,Z3.5,and 13.6. 2.3.2 Each Bond shall continue in effea for five year after final completion and acceptance of the Work with the liability equal to one hundred percent (100%)of the Contraa Sum. 99 13.«J^^^^edtoacc^• ^aretheZS^,^™^ Contractor's Pr*-^Rf pre^fi^Qr,. perferma^oftteWorinSrepr^^requirement,of the CoW^dSZS OT^?r^tal^"dobsenatl^wf*«h« ^"^sudiaddr^surveva^d^^W«*«^mtheC«^r^,^^tterBquawe^oftheO^SSe^dd*ttetec^ted the results rf all sudictevrf* 15 tarj 2.6 17 18 19 ofCfflwrwfnmfi?The Contraa Tune shall commence to am on the date sated in the Notice to Proceed. •"""""^andcomlW^^ involved mthe Pr^d?j2L^^Sub,^tf*^h'««^oi»CONTRACTOR Applications ^Znta^to^Tw^^S0P DT",*t md «her*«*'"»«tow.and for processing"w siorravmentand to establish aworking understanding between the parties as to &Project tw Presentattheconference will bethe CITTS representative,CONSULTANT.ResidentProjea *Representatives,CONTRACTORanditsSuperintendent Qualifications of Subcontractors.Material menand&ippfo>re 2.10 Within five (5)business days after bid opening,die apparentlowest responsive and responsible Bidder shall submittothe CITY andthe CONSULTANT for acceptance alistofthenamesof Subcontractors and such other persons and organizations (including those whoareto furnish principal items of materials or equipment)proposed forthose portions ofthe Work asto which the identity of Subcontractors and other persons and organizations mustbe submitted as specified inthe Contraa Documents.Within thirty (30)calendar days after receiving the list,the CONSULTANT will notify the CONTRACTOR in writing ifeither the CITY orthe CONSULTANT has reasonable objection to any Subcontractor,person, or organization on such list.The failure ofthe CITY orthe CONSULTANT to make objection toany Subcontractor,person,or organization onthe list within thirty (30)calendar days ofthe receipt shall constitute an acceptance of such Subcontractor,person or organization.Acceptance of any such Subcontractor,person or organization shall not constitute a waiver of any right ofthe CITY orthe CONSULTANT to rejea defective Work,material or equipment,or any Work,material or equipment notinconformancewiththerequirementsofthe Contraa Documents. Ill Itprlor to the Notice ofAward,the CITY or the CONSULTANT has reasonaWe (objection to any Subcontractor,person or organization listed,the apparent low Bidder may,prior to Notice ofAward, submit an acceptable substitute without an increase in Itsbid price. 2.12 The apparent silence ofthe Contraa Documents as to any detail,orthe apparent omission from them of a detailed description concerning any Work to be done and materials tobefurnished,shall be regarded as meaning thatonly best practices are to prevail and only materials and workmanship ofdiebest quality are tobeusedintheperformanceofthe Work. ArVTIClf ^CQBHELATION,INTERPRETATION AND INTENT OF CONTRACT DOCUMENTS 3.1 It Is the Intent oftheSpecifications and Drawings to describe a complete Projea tobeconstructed in accordance with theContraaDocuments.The Contraa Documents comprise the entire Contraa between the OWNER and the CONTRACTOR.They may be altered only by a rnodification as defined in Artide I. 3.2 The Contraa Documents are complementary;what is called for by one Is as binding as if called for by all the documents.IfCONTRACTOR finds a conflict,error or discrepancy in the Contraa Documents,it shall,before proceeding with the Work affected thereby.immecOateiy call ittothe CONSULTANTS attention In writing.The various Contraa Documents are complementary;In case of conflict,erroror discrepancy,the more stringent Interpretation and requirement diat shafl provide die maximum benefit to theOwnershall apply 3.3 The words "furnish-and lurnish and install","install",and "provide"or words with similar meaning shall be interpreted,unless otherwise specifically stated,to mean 'furnish and install complete in place and readyfor serviced 3.4 Miscellaneous items and accessories which are not specifically mentioned,but which are essential to produce a complete and properly operating installation,or usable structure,providing die indicated fanctions,shaB be furnished and installed without change In the Contraa Price.Such miscellaneous items and accessories shall be of the same quality standards,induding material style,finish,strength,dass, weight and other applicable characteristics,as specified for the major component ofwhich die miscellaneous Item or accessory is an essential part,and shall be approved by the CONSULTANT before installation.The above requirement is not intended to indude major components not covered by or inferable from the Drawings and Specifications. 35 The Work ofall trades under this Contraa shall be coordinated by the CONTRACTOR in such a rrminer as obtain the best workmanship possible for the entire Project,and art components of the Work shall Deinstalled or erected in accordance with the best practices ofthe particular trade. 3.6 The CONTRACTOR shall be responsible for making the construction ofhabitable structures under this Contraa rain proof,and for making equipment and utility installations property perform the specified function.If the CONTRACTOR is prevented from complying with this provision due to the Drawings or Specifications,the CONTRACTOR shall Immediately notify the CONSULTANT in writing of such Bmhations before proceeding with construction in the area where the problem exists. 3.7 r^mifacturer's literature,when referenced,shall be dated and numbered and is intended to establish the minimum requirements acceptable.Whenever reference is given to codes,or standard specifications or 101 other data published by regulating agendes or accepted organizations,including but not limited to htotiorai BectrkaJ Code,applicable State Building Code,Florioa Butkfing Code,Federal Specifications, ASTM Specifications,various institute specifications,and the like,Itshall be understood that such reference istothe latest edition induding adders ineffeaonthedateofdie Bid. 3.8 Brand riarnes whereusedinthe tecto required for the particular material or produa The term "equal"or ^equivalent9,when used In connection with brand names,shall be interpreted to rnean a material c^produat^ in type,quality,size,capacity,composition,finish,color and other applicable characteristics to the material or produa specified by trade name,and that Usuitable for the sarne use capao^ function,in the opinion of the CONSULTANT,as the material orprodua so spedfted.Proposed eojirvafent items rnust beapproved by CONSULTArfTb^ Work.(When a brand name,catalog number,model number,or other Identification,Is used without the phrase "orequal",the CONTRACTOR shaR use the braml make and rn^ 3.9 Throughout this agreement the male pronoun may besubstituted for female and neuter and vice versa and die singular words substituted for plural and plural words substituted for singular wherever applicable. 3.10 Afl technical Interpretations shafl be made by the CONSULTANT as set forth In Section 9.3 below. 3.11 The CONTRACTOR shall advised the CONSULTANT,prior to performing any work involving a conflict inthe Contraa Documents arid the CONSULTANT sl^iriake thefind documents shall take precedence.Inthe evemthatthereisa confix Documents,onry the latest version shatt apply and the btestwjr^The CONSULTANT shall use diefollowing list ofContraa Documents asa guide.These documents are set forth below Intheorderoftheir precedence sothat al!the dc^rr^ should have precedence over afl the documents listed below it (a)Change Orders (b)Atnendmems/aooteda to Contraa (c)Sitpplementary Conditions,If any (d)Contraa with ail Exhibits thereto (e)GeneralConditions (f)Written or figured dimensions (g)Scaleddimensions (h)Drawings ofalargerscale 0)Drawings of a,smallerscale Q)Swings andSpecifications are tobe cona ARTICLE 4-AYAILAWi ITYOF LANDS SUBSURFACE CONDITIONS REFERENCE POINTS Avail^ftayofbuinV 4.1 The OWNER shall furnish,as Indicated inthe Coritraa Documents,tfo ^ be done,r$its-of-way for access thereto,ami such cxher lands whto CONTRACTOR.Easements for perrnanentstractures or permanent c^ obtained and paid forbythe OWNER,unless otherwise specified in tto Other access to such lands or rights-of-way for the CONTRACTOR'S convenience shafl bethe responsibility of the CONTRACTOR. TheCONTRACTOR shaO provide for a^ temporary obstruction fadfrties or storage of material and equipment. 42 The CITY will,upon request furnish to dieBidders,copies ofall available boundary survei/s and subsurface tests at no cost Subsurface Conditions 43TheCONTRACTOR acknowledges thathe has irivestl^ed prior to Nddl^ the oortffitions affecting the Work,Induding butnot limited to those bearing upon transportation, disposal,handling andstorage of materials,availability of labor,water,electric power,roadsand uncertainties of weather,riverstages,tides,water tables or sunfrphydc^ conformation and conditions ofthe ground,the character ofequipment and facilities needed prefiminary to and during prosecution ofthe Work.The CONTRACTOR further acknowledges thathe has satisfied himself astothe character;quality and quantity ofsurface and subsurface materials or obstades tobe encountered Insofar as this Information is reasonably ascertainable froman inspection ofthesite, 102 including all exploratory workdone by the OWNER/CONSULTANT onthe siteor any contiguous site, as well as from information presented by the Drawings and Specifications made partof this Contraa,or any other information made available toit prior to receipt of bids.Any failure by the CONTRACTOR to acquaint itself withthe available information shall not relieve it from responsibility for estimating property the difficulty orcostof successfully performing Work.TheOWNER assumes no responstbffity forany conclusions or interpretations made by the CONTRACTOR onthe basis of die Information made available bytheOWNER/CONSULTANT. Differing SheConditions: 4.4The CONTRACTOR shall within forty eight (48)hours ofits discovery,and before such conditions are disturbed,notify the CITYinwritingof: 4.4.1 Subsurface or latent physical conditions atthesite differing materially fromthose indicated in die Contraa Documents,and 4.4.2 Unknown physical conditions atthe site,ofan unusual nature,differing materially from diose ordinarily encounteredand generally inherentinWorkof die characterprovidedforin this Contraa.The CITY shall promptly Investigate die conditions,andif it finds thatsuch conditions do materially differtotheextentastocausean increase or decreasein die CONTRACTOR'S cost of,or the timerequiredfor,performance ofanypartofthe Work undertills Contract an equitable adjustment shall be made andthe Contraa modified in writing accordingly. 4.5Nodaimof die CONTRACTORunderthisclause shall beallowedunlesstheCONTRACTORhasgiven thenoticerequiredin4.4 above;provided,however,thetimeprescribed therefore maybeextendedby the CITY,butonly If doneinwritingsigned by die Qty Manager or the CONSULTANT. ARTICLE 5 -INSURANCE Contractor shallcomplywith theinsurancerequirements set forthintheRFPand as set forthin die SupplementaryConditionsto die Contract Ifany.Ifbothhaveinsurancerequirementsandif there isa conflitt between die two,the insurance requirementsinthe Supplemental Cofxfitions shalltake precedent ARTICLE 6 -CONTRACTOR'S RESPONSIBILITIES Supervision and Surjerirrteridencg 6.1 The CONTRACTOR shall supervise anddirectthe Work.It shall besolelyresponsible forthe means, methods,techniques,sequences and procedures of construction.The CONTRACTOR shall employ and maintain a qualified supervisororsuperintendent(hereirtafter referred to as "Supervisor"at die Work sitewhoshallbedesignatedinwritingbythe CONTRACTOR,before the CONTRACTOR commences theWorkandwithindie timerequiredbydie Conn-actasthe CONTRACTOR'S representative atthe site.TheSupervisor orso designated shall have full authority to aa on behaHof die CONTRACTOR and all contmufiications given to die Supervisor shall beas binding asifgiven tothe CONTRACTOR.The Supervisor^)shall bepresentateachsiteatalltimesas required toperformadequatesupervision and coordination of the Work (Copies of written communications gven tothe Supervisor shafl be mailed to the CONTRACTOR'S riome office). 6.1.1 TheCONTRACTOR shall keep one record copy of all Specifications,Drawings,Addenda, Modifications and 9iop Drawings atthesiteat all times and ingoodorderand annotated to show ail changes made during the construction process.Theseshall be available tothe CONSULTANT aftd any CITY Represematrve at all reasonable times.Asetof "As-Built"drawings,as well as die original Specifications,Drawings,Addenda,Modifications and 9iop Drawings with annotations, shall be made available tothe City at all times and it shall be delivered tothe CITY upon completionof die Project. labor.Materials and Eqtripmefrc 6.2 The CONTRACTOR shall provide competent suitably qualified personnel to lay outthe Work and perform construction as required bytheContraa Documents.It shall at all times maintain good discipline and order at the site. 6.3 The CONTRACTOR shaH furnish all materials,equipment labor,transportation,construction equipment and machinery,tools,appliances,fuel,power,light heat local telephone,water and sanitary fatilitles and all other facilities and incidentals necessary for die execution,testing,initial operation and completion of theWork. 103 64 2Ii^,and?*""***.«*•**except as otherwise provided in the Contra*Documents.™*»*j*w "n*"orjjatte of material which are norri^ypacte^ly the supplier or mamrfacturer are SDecmed or annrnwvl en^k MMte^.u .L.II i i_if._„a ^_.../•...-T ."w-MMsoiarespedfiedorapproved,such materiab shdl be ddivei^to the site In thw comainwwithsedsimbrofcw v ^^^ l!!^^—015 *^^^Jns^ucelons c>f the appttcabie nrtautufocturer.faubHcator,or proossssor^except:as odierwise provided in the Coittraa Documents.^ Work,Materials,r^forrtPnt.Prod..™p^Supstfeutionf; 6.6 to^s^pmerit^ P^rdias^bytheCOrmACrOR.The CONTRACTOR shall submit to the CONSULTANT afistof!£****«materials,equipment or products,together with ^ c*termine their acceptability andobtain^ Contraa unless cdu^vdse stipulated in trie S^r^request fi^payment for "or eoual"eojijpmertt will be ajipiwed until this fist has been r^^ 6.6.1 Whenever a material,article or piece ofequijmiem is kkm^ preferenceto brand name or catalog number,rtshdl be tmderstoodtta the purpose ofdefining the peifortnance or other sdient require ^S^t^qU^^fa^MsMtew^*r^-The CONTRACTOR may recommendthesubstitutionofamaterial,artide.orpiece ofequipi^ thosereferred to in theContraa Docurnems by refereiice t^ if,in the opinion ofthe CONSULTANT,such material,article,or piece ofequipment Is ofequal substance and function to dat specified,tlieCONSULTANT by the CONTRACTOR,inridental changes or extra component pam n^utred to accorrmxxfate die substitute will be made by the CONTRACTOR without a change In the Coii^ ComraaTifne. 6.62 No substitute shall be ordered or Installed without the written approval ofthe CONSULTANT who shall be die judge of quaffty. 6.63 Delay caiisedlyobtainlt^approve groundsforanextension of construction time. 6A4 Should any Work or materials,equipment or products not conform to requirements ofdie Drawings arriSpedfjcat^ materiab shall beremoved and recced,together whhaiw Workd atany time before cornptecton and acceptance ofthe FYojea All such Work shall bedone atthe expense ofthe CONTRACTOR. 6.65 NoinwerWscrsui^ Subcontractor subjea to any chattel mortgage or under acomfofonal sde or other agreement by v^ichanirrterestlsrminedbytheSdler.The CONTRACTOR warrants that they have good title to all materials and supplies used bythem tn theWork 6.6.6 Norr<oirfonritagWork:The City ofSouth Miami may witiihdd acceptance^or rejea Items which are found uponexamination^ plans and drawings.Upon wrtaen notification of reject within five (5)business days by theCONTIOXCTOR athis own expense and ra reinstalled at his expense.Rejected goods left longer diantNrty(30)calefidardayssfiafilM regarded as abandoned and the CITY shall ravetherighttodts^tftnemaste and the CONTRACTOR thereby waives any dalm tothe good or to compensation ofany land for said goods.Rejection for nonconformance or faBure to meet delivery schedules may result in the CONTRACTOR being found In default 6.67 In case of default bytheCONTRACTOR,the Chy ofSouth Miami may procure the arddes or services from othersources and hold theCOl^^^(ACTOR respor«b4e fcrr any i^xcess costs occasioned or Incurred thereby. 6.6.8 TheCITY reserves the right In the event the CONTTIACFOR canrKrt f^rovide an rte*n(s)or services)ina timely manner as requested,to obtain the good and/or services from other sources and deducting thecost from the Contraa Price without violating die Intent oftheContraa Concerning »bcomnigora 6.5 104 6.7The CONTRACTOR shall notemployanySubcontxaaor,against whom theCITYorthe CONSULTANT mayhave reasonable objection,nor will die CONTRACTORbe required toemployany Subcontractor who hasbeenacceptedbytheCITYand the CONSULTANT,unless the CONSULTANT determinesthat there isgoodcausefordoingso. 6.8The CONTRACTOR shall be fully responsible for all actsandomissionsof itsSubcontractorsandof personsand organizations directlyor Indirectly employedbyitand of personsand organizations for whoseactsanyofthemmaybe liable to die sameextentthattheyare responsible for die actsand omissions ofpersons cDrecdy employed by diem.Nothing intheContraaDocuments shall createany contractual relationship betweenOWNERorCONSULTANT and anySubcontractororotherpersonor organization having adirectcontraawith CONTRACTOR,nor shall itcreateany obligation onthepart ofOWNERor CONSULTANT to pay ortoseeto payment of any persons due subcontractor orother personor organization,exceptasmay otherwise be required by (aw.CITYorCONSULTANTmay furnish toanySubcontractor or otiier person or organization,totheextent practicable,evidence of amounts paid totheCONTRACTORon account of specified Workdonein accordance withthe schedule values. 6.9The divisions and sections ofthe Specifications and the identifications of any Drawings shafl not control the CONTRACTOR in dividing theWork among Subcontractors or delineating theWork performed by anyspecific trade. 6.10 The CONTRACTOR agrees to bind specifically every Subcontractor tothe applicable terms and conditions of the Contraa Documents for die benefit of the OWNER. 6.11 All Work performed for the CONTRACTOR by a Subcontractor shall be pursuant to an appropriate agreement between the CONTRACTOR andthe Subcontractor. 6.12 TheCONTRACTOR shall be responsible forthe coordination ofthetrades.Subcontractors material and menengagedupon their Work. 6.12.1 The CONTRACTOR shall cause appropriate provisions tobe inserted in all subcontracts relative totheWorkto bind Subcontractors tothe CONTRACTOR by die termsof tiiese General Conditions and other Contraa Documents insofar as applicable totheWorkof Subcontractors, and pve the CONTRACTOR die same power as regards to terminating any subcontract that the OWNER may exerdse over the CONTRACTOR under any provisions ofthe Contraa Documents. 6.112 The CITY or CONSULTANT will not undertake to settie any differences between the CONTRACTORandtheir Subcontractors orbetween Subcontractors. 6.113 If in the opinion ofthe CONSULTANT,any Subcontractor onthe Projea proves tobe incompetent or otherwise unsatisfactory,they shall be promptly replaced bythe CONTRACTOR ifand when directed bythe CONSULTANT in writing. 6.I2A Discrimination:No action shall betaken by the any subcontractor with regard to the fulfillment ofthe terms ofthe subcontract Induding the hiring and retention of employees for the performance ofWork that would discriminate against any person on the basis ofrace,color,creed,religion,national origin,sex, age,sexud oriematioii,familid a This parcigraph shall be made a part ofthe subcontraaor's contraa withtheContractor. Patent Fees and Royalties; 6.13 The CONTRACTOR shall pay all license fees and royalties and assume all costs Inddent to the use of any Invention,design,process or device which is the subjea ofpatent rights or copyrights held by others.He shall indemnify and hold harmless the OWNER and the CONSULTANT and anyone directly or Indirectly employed by either of them from against all dalms,damages,losses and expenses (induding attorney's 7$Tf*?*°f any in,rtn*ement <*«**rights during or after die completion of the Work,and shalldefendallsuchclaimsinconnectionwithanyallegedinfringementofsuchrights. 6.14 The CONTRACTOR shall be respondWefordetennlningtheap^ rnatenals,appliances,articles or systems prior to bidding.However,he shall not be responsible for such determination on systems which do not involve purchase by them of materials,appliances and artides. 6.15 The COhfTRACTOR shall secure and pay for all construction permits and licenses and shall pay for all governn^l charges and inspection fees necessary for the prosecution ofthe Work,which are W1******•time ofhis Bid.Wiien such chargw are normally im^ in the Special Conditions,there will be no charges totheCONTRACTOR.The CITY shafl assist the I OS CONTRACTOR,when necessary,in obtaining such permits and licenses.The CONTRACTOR shall also pay all public utility charges. QeciricalPovveraridllghtinir 6.16 Bectrkal power required during construction shall be provided by each prime CONTRACTOR as required byit This service shall be Installed by aquitted dectrfcal Q>^ CONSULTANT.Lighting shall be provided by the CONTRACTOR in all spaces at all times where rtecessary for good and proper workmanship,for inspection or for safety.No tenrpcrary power shall be used extemporary fighting lines without specific approval ofthe CONTRACTOR. LawsaradRefjAtiony 6.17 The CONTRACTOR shall comply with dl notices,laws,ordinances,rules and regulations applicable to the Work.If the CONTRACTOR observes that the Specification w Drawings are at v^ ft shall #ve the CONSULTANT prompt written notice thereof,and any necessary changes shall be adjusted by an appropriate inodification.If the CONTRACTOR performs any Work knowing It to be contrary to such laws,ordinances,rules and regulations,and without such notice to die CONSULTANT, it shall bear ail costs arising there from;hovvever,h:shall notbe res prima^ that the Drawings and Specifications are in accordance with such laws,ordinances,rules and regulations. Discrimination: 6.17A No action snail betaken bythe Contractor with regart^ induding the hiring and retention of employees for the performance ofWork that would discriminate against any person onthe basis of race,color,creed,religion,national odpn,sex.age,sexual orientation, familial statusor disability. 6.18 Costof all applicable sales,cc^mer use,and othertaxesfor whto the Contraa shall be Induded in the Contraa Price stated by the CONTRACTOR. Safety ami Protection: 6.19 The CONTRACTOR shall beresfXHidbte for initiating afKffiropaimmcofi^^They shaH take all necessary precautions for the safety of, and shall provide the necessary protection to pivvent damage,inj^ 6.19.1 All employees and other persons,whomay beeffected thereby, 6.19.2 All theWork and all materials or eqw^ off die she,and 6.193 Odier property atthe sfteccadjaoem roadways,structures and utilities not designated for removal,relocation or replacement In the course of construction. 6.20 The CONTRACTOR shall designate a responsible iriemlxy of the^ shall bethe prevention of accidertts.This person shall bethe CONTRACTOR'S Superintendent unless otherwise designated in writing bythe CONTRACTOR tothe CITY. Emergencies: 6u2t b emergences affecting the safety c^persomortheWorkor property at die sitt or the CONTRACTOR,without special Instruction or authorization from the CONSULTANT or CITY.Is obligated to act at hisdiscretion,to prevent threatened darrage,Injury or loss.He shall #ve the CONSULTANT prompt written notice of any sfenfikmchanges In theWork ^^ ContraaDocuments caused thereby.Ifthe CONTRACTOR bdleves that adc5tional Work doneby him inanemergency which arose from causes beyond his control entitles himtoanIncrease intheContraa Price oranextensionoftheContraa Time,he rray rnake a dalmthereforeas provided inArtidesII and II ShopDiTnYlnffWdSan^^ 622 After checking and verifying all field rneasuremertts,the CONTrUCTOR shdl subn^to the CONSULTANTfor review,in accordance withthe accepted schedule of shop drawing submissions,six (6)copies (oratthe CONSULTANT option,onereproducible copy)of afl Shop Drawings,which shall have been checked byand stamped withthe approvd ofthe CONTRACTOR.TheShop Drawings shall 106 be numbered and identified as the CONSULTANT may require The data shown onthe Shop Drawings shall becompletewith respea to dimensions,design criteria,materials of construction anddie like to enable the CONSULTANT to review the iriformation without any unnecessary investigation. 6.23 The CONTRACTOR shdldsosubmfr to cause no delay in Work,all samples required bytheContraa Documents. All samples shall have been checked byand stamped with the approval ofthe CONTRACTOR,identified dearly asto material,manufacturer,any pertinent catalog numbers and the use for which iritended. 6.24 At the time of each submission,the CONTRACTOR shall notify the CONSULTANT,in writing of any deviations between die Shop Drawings or samples and the requirements oftheContraaDocuments. 6.25 The CONSULTANT shall review with responsible promptness Shop Drawings and Samples,but his review shall be only for conformance with the design concept of the Project and for compliance with the infornution pven inthe Contraa Documents.The review ofa separate item as such will notIndicate review oftheassembly Hi which theitems functions.The CONTRACTOR shaH make any corrections required by the CONSULTANT and shall return the required number of corrected copies ofShop Drawings and resubmit new samples until the review is satisfactory tothe CONSULTANT.The CONTRACTOR shafl notify the CONSULTANT,in writing of any prior Shop Drawing or revisions to Shop Drawings that are in conflirt with each submission or re-submission.The CONTRACTOR'S stamp of approval on any Shop Drawings orsample shall coristitute representation tothe CITY and the CONSULTANT that the CONTRACTOR has either determined and/or verified ail quantities,dimension, field construction criteria,materials,catalog numbers and similar data or they assume full responsibility for doing so,and that diey have reviewed or coordinated each Shop Drawing or sample with the requirements of the Work and the Contraa Documents. 6.26 No Work requiring a submittal ofaShop Drawing orsample shafl be commenced until the submission has been reviewed and approved in wrttmg by the CONSULTANT.A cc^ approved sample shall be kept In good order,in a book orbinder,in chronological order orIn such other order required by the CONSULTANT in writing,by the CONTRACTOR atthe site and shall be available to the CONSULTANT. 6.27 The CONSULTANTS review ofShop Drawings orsamples shall not relieve the CONTRACTOR from his responsibility for any deviations from the requirements oftheContraa Documents unless the CONTRACTOR has Informed the CONSULTANT,to writii*^ submlsslc^and tf»CONSULTANT has gfvm review by the CONSULTANT relieve the CONTRACTOR from responsibility for errors or omissions in the Shop Drawings or samples. 6.27A The CONTRACTOR shall be liable tothe OWNER for any addrtio^ failure to notify the CONSULTANT of any of said devfatlons or conflict between Snop Drawing to errors inthe Shop Drawings or samples. Cleaning Up; 638 TlieTONTlttCTORsh^^ ^TS!*CC™TRACTOR shaH remove aU his surplus and discarded materials,excavated^rial and rubbish as well as dl other material and ec^^ S5m^^In addition,the ZSl^tT^-!?dean hts t™*0"of w^Solved in any building under this Coh^ refVredtoinpareg^f!na,$ Public Conveniens ao<J fofay. Wobfe obstruction to public travd.Tr^cc^venlenre of the general public and ofto operaoon and local conditions."Street Closed"signs shall be placed immediately adjacent to to Work,in ooseo.tne cumKACTOR shall notify law enforcement agencies and in particular,the City of South 107 EE^Accesstofirenytlrantsandodierfireextirigu^ SanfarvltawitfAn* 631 U?6 ^NTR^CT0R#SWI provide on-site office,and necessary toilet faculties,seduded from public ™f™-^They shafl be kept ^orWttr^iurisdl^They shall commit no public nuisance.Temporary field office and sanitarytadOtiesshallberemoveduponcompletionoftoWorkarxito^7 6.32 ^nowor shall comply with to indemnification requirements set forth In to RFP and as set forth in the i P^f"tfy CondWon$">*•Contract if any.ifboth have indemnification requirements and if there is a confix*between to two,to indemnification requirements In the Supplemental Conditions shall take precedent 6.33 In to event that any action or proceeding is brought against OWNER or CONSULTANT by reason of any such claim or demand,CONTRACTOR,upon written notire firom Cl^ XSS™**^COUfWC,$ad$fectory to cmr-T"e indemnification provided above shall obligateCONTRACTORdefendatItsownexpenseorto|»widefe^ ™u™£wwwwV and all suits and actions ofevery name and descrifric*that may be b^ OWNER orCONSULTANT,exduding only those claims that allege that the injuries arose out ofto sole negligence ofOWNERor CONSULTANT. CONSULTANT.Its agents or employees aris^o*erf « opinions,reports,surveys,Change Ortairs,design orspecifications give directions or Instructions by to CONSULTANT,its agentt or ernptoyw omission Is the primary cause of Injury or damage. 634A All of to forgoing Memnfficatfon previsk^ General Cowfitions areapart Imfemnifkation s^ insurance coverage reeled ty Sectkm ^ in whofo orin pm byaiy act on^sdon^ sub-subcontractors,materialmen,wagenc ofany tier ortr^ra by the negjgence,recklessness,or intentional wrongful misconduct ofto Indemnttytng party and persons employed or utilized by the indemnifying party in the performance oftheconstruction contract ReStXMlsftfflty for Connexion to Existing Warlr 6.35 It shall beto responsibility ofto CONTRACTOR to connea its Work to each part of the existing Work,existing bu&fing or structure orWork previously installed as required by to Drawings and Specifications to provide a complete installation. 636 Excavations,9adin£fi&storm ways of streets,highways,public carrier lines,iitilty fines, dortemaccotdaiicewithre^The OWNER will be responsible for obomlng all permits necessary for theWorkdescribed in ti^paragraph 636.Upon ccrnipletion ofthe Work,CONTRACTOR shall present to CONSULTANT certificates,In triplicate,from the proper authorities,stating that theWork has been done In accordance with their requirements, 636.1 The OTY wHi cooperate with the CONTRACTOR in obtaining actton from any utflr^ autorities involved m to above requirements, 636.2 The CONSULTANT shall be responsible for obtaining elevations of curbs and gutters,pavement storm drainage structures,and other hemswhich mustbe established by governmental departments assoon asgrading operations are begun onto sheand,In any case,sufficiently early In the construction period topreventanyadverse effea ontheProject Cooperation with Governmental D^rrn^nty PuMic Utilities,Ete^ 637The CONTRACTOR shafl be responsible for making aU necessary airarigemeritt with governs departments,public utilities,public carriers,service companies and corporations (ttereirtafter referred to as*third parties")owning or controUng roadways,railways,water,sewer,gas,electrical conduks, telephone,and telegraph facilities such as pavements,tracks,piping wires,cables,conduits,poles,guys, 108 etc including Incidental structures conneaed therewith,thatare encountered inthe Work in order that suchitemsareproperfy shored,supportedandprotected,thattheirlocation is identified andtoobtain authority from these third parties forrelocationifthe CONTRACTOR desires to relocate the Item.The CONTRACTOR shallgiveallproper notices,shall comply with ail requirementsofsuchthirdparties In die performance ofhis Work,shall permitentranceofsuchthirdpartieson die Projea in order dot they mayperform their necessary work,and shall pay all chargesandfeesmadebysuchthirdpartiesfortheir work. 637.1 TheCONTRACTOR'Sattentionis called tothe faa that there maybe ddays on the Projea due to work to bedonebygovernmentaldepartments,publicutilities,and others inrepairing or movingpoles,conduits,etc The CONTRACTOR shall cooperate withtheabovepartiesinevery way possible,so that to constructioncanbecompletedin to leastpossible time. 637.2 The CONTRACTOR shall have made itself familiar with all codes,laws,ordinances,and I regulations which in any manner aftea thoseengaged or employed in to Work,or materials and [equipment useinor upon to Work,or in any way affeatheconduaofthe Work,andno plea of !misunderstanding will be considered on account of damage or delay caused by his Ignorance j thereof. |U«Prgm*5fi& 638 CONTRACTOR shallconfineits apparatus,storageof materfels,ami operatfons of te limits indicated by law,ordinances,permitsand directions of CONSULTANT and CITY,and shall not unnecessarily encumber any part of to site oranyareasoff site. 638.1 CONTRACTORshallnotoverloadorpermitanypartof airystnictore tobeloadedwithsuch weightas will endangerIts safety,nor shall itsubjeaany worktostressesorpressuresthat will endanger it 6382 CONTRACTORshallenforce to rulesand reguUtion prc^nulgated by die CONSULTANT and OWNERaswellastheir instructions with regard to sigfis,advertisements,firesand smoking, 6383 CONTRACTORshallarrangeandcooperatewith CITY inroutingand parking ofautomobilesof its employees,subcontraaors andother personnel,as wdl asthatof to material delivery trucks and other vehides that cometo die Projea site. 638.4 TheCitywilldesignate specific areason to sitefor storage parkirr^etc and to jobsite shdl be fenced to protea thejobsiteand to generalpublic 638.5 The CONTRACTOR shallfurnish,install andmaintainadequate construction officefacilities forall workersemployedby it orbyits Subcontractors.Temporary offices shaH beproddedand locatedwheredirectedand approved bythe CONSULTANT.All such facilities shall be furnished in stria accordancewith existing governing regulations.Reld offices shall Indude telephone farifities. Protectionof Existing Property Improvements: 638 Any existing surface or subsurfaceImprovements,suchaspavements,curbs,sidewalks,pipes or utilities, footings,orstructures (induding portions thereof),treesand shrubbery,not Indicated on die Drawings ornoted In the Specifications as being removed oraltered shall beprotectedfrom damage during constructionof the Projea Anysuch Improvements damaged duringconstructionof the Projea shafl berestoredat the expenseofthe CONTRACTOR toaconditionequal to that existing at to timeof award of Contract ARTICLE 7 -WORK BY OTHERS. 7.1 The CITY mayperform additional Work related totheProjeaor may letother direa contractstherefor which shall contain General Conditions similar to these.The CONTRACTOR shall afford the other contraaors whoarepartiestosuch direa contracts (orthe OWNER,if it is performing die additional Work Itself),reasonableopportunityfor to introduction andstorageof materrals andequipmentand to execution of Work,and shall properly connea and coordinate itsWorkwiththeirs. 7.2 Ifanypartofthe CONTRACTOR'S Work depends upon proper execution or results of die Workofany odier contractor or the OWNER,the CONTRACTOR shallpromptly report to the CONSULTANT in writingany defects or deficiencies in such Work that render it unsuitable for die CONTRACTORS Work, 73TheCONTRACTOR shall do all cutting,fitting and patching oftheWorkthat may be required to make itsseveralpartscometogetherproperlyandfitto receive orbe received bysuchother Work.The CONTRACTOR shall not endanger anyWorkofothersbycutting excavating orotherwise altering thdr 109 Work and shall only cut or alter their Work with to written corisent ofto CONSULTANT and ofthe otr^contractusrwrwseworkwinbean^cted. 7.4 If the |>erforrnance ofadditional Work by other contractors orthe OWNER is not noted in to Contraa Documents prior to to execution of to Contractwrittennc^cetiierecrfsT^te^en toto CONTRACTOR prior to starting any such additional Work.If the CONTRACTOR believes that to performance ofsuch additional Work by to OWNER or others will caiise to COrfiTUVCTOR additional expense orentitles him to an extension of the Contraa Time,he may make a dalm therefore asprovided In Articles 11 and 11 7.5 Where practicable,to CONTRACTOR sridl build around to wo^sl^leave chases,dots and bote Work the work ofsuch otor separate comractore as directed by them.Where such chases,slots,etc. are impracticable,theWork shall require specific approval ofto CONSULTANT. 7.6 Necessary chases,slots,and holes not bulk or left by to CONTRACTOR shafl be cut by to separate conwa^rec^lrfng such alterations after approval of to CONTRACTOR.The CONTRACTOR shall do^afi patching and finishing of to work of other extractors where fcb cut by tr^ and finishing shafl beat to expense of CONTRACTOR 7.7 Cooperation is required In to use of site facilities and In to detailed execution of the Work,each fotnractor shall coordinate their operation with tose of to other Contractors for to r^ theWorkinorderto prevent delay into execution thereof. ™S^?!^the Projea Site shall keep themselves informed erf the progress of the work of other contractors.Should lack of progress ordefective workmar^pon topaaofotheroottt^rs Interfere CONSULTANT Immediately and in writing.Lack ofsuch notice tothe CONSULTANT shall be construed asacceptance by to CONTRACTOR ofto statos ofto work ofou^ satisfactory for proper ccwc^iatkm ofCONTRACTORS own Work. 7.9 Tte cost ofextra Work resiil»^ Defective Work or rack of coordination shall bethe CONTRACTOR'S cost 7.10 TheCmreservestorightinto timerjrmanner as requested,toobtain the good andfor services from cntor sources and ded^ cost from theContraa Price withoutdoratingto Intent ofto Contract CafaMaEJyBBiTJLfeiPfci*.^fc^.^.jataLJ •RiCaS* 8.1 The OTY will issue all commtmicatfons to to CONTRACTOR through the CONSULTANT. B2 »casesof terminal ofe whose status under to ContraaDocuments shdl betfiat ofto forn^ 83 The CITY shall promptly furnish to data required ofthem under to Contraa Documents, ec -H!f ^52^^!^?*Ifl•^^P^ct^o fMxyvicfinsiauidsauMfleas^Yaefitt3r^saatft^eti in Rauraisrai^hs-#•!and^.^. 83 The CITY shall have the right to take possession of and use iirry completed w Pardons ofto Work,notwithstaiidingtofaatriatto portion thereof may not have exfrfred;lw such talcing acceptance Saiw Worknot cwnple^ ART1GM-1 -CONSULTANTS'status durhmc ^wstructiqm Cay's Representative; 9.1 The CONSULTANT shall be to CTiTS representative during the construction period.The duties and responsibaroes and to limitations of authority of the CONSULTANT as the CITY'S representative during coiwnictton are set forth fo An^ without written consent of to OTYand the CONSULTANT. 9.1.1 TheCONSULTANTS decision,In matters reiatingto aesthetics,shall be teal,ifwithin to terms of the Contraa Documents. 9A2 Except as may be otherwise provided In this contract all dalms,counterclaims,disputes and otor matters in question between to CITY and theCONSULTANT arising outerf or relating to this Contraa or the breach thereof,shall be dedded in a court ofcompetent jurisdiction within the State of Florida. Visits to Stag MO 9.2The CONSULTANT shallprovideaninspector to makeperiodicvisits to thesiteateachphase of constructiontoobservethe progress and quality of die executed Work andtodetermineifthe Work is proceeding In accordance with die Contraa Documents.Hisefforts shall bedirectedtowardproviding assurancefor the OWNER anddl applicable regulatoryagendesthatconstructionisincompliance with theConstructionDocumentsand appficable raws,rulesand regulations.On to basis of theseon site- observationsasanexperiencedand qualified design professional,he shdl keep to CITY informed of die progressof to Work and shall guard to OWNER against defectsand deficiencies in the Work of CONTRACTOR. Clarifications andInterpretations: 93 The CONSULTANT shad issue,with reasonable promptness,such written clarifications orinterpretations of the Contraa Documents(intheformof Drawings orotherwise)asitmaydeterminenecessary,which shall beconsistentwith,or reasonably inferable from,the overall Intent of to Contraa Documents.If the CONTRACTOR seeks anIncreasein to Contraa Price or extension of Contraa Time based on a written clarification and/orinterpretation it shall be required to submit atimely claim as provided in Articles 11 and II M^Mrerrrcm of Quajirttfesi 9.4AllWork completed under to Contraa shall be measured bythe CONSULTANT according to to UnitedStatesStandardMeasures.All linear surfacemeasurementsshallbemadehorizontallyorvertically asrequiredby the Item measured. Rejecting Detective Work: 9S TheCONSULTANT shall have authority to disapprove or rejea Work thatis"Detective Work"as definedin Artide I.It shafl alsohave authority torequirespecial inspectionortestingof to Work indudingWork fabricated onoroff site,installed orcompletedasprovided.In to event that to CONSULTANTrequirestestingofcompletedWork,to costofsuch inspections and/or testing shall be approved In writing bythe CITY.All consequential costof such inspections and testing,induding butnot limitedto the cost of testingand Inspection to cost of repairing any thecosttomove furnrture and equipment and/orto costto provide alternative facilities untilto repair work can becompleted,shall paid bytheCONTRACTORif to Work is found tobeDefectiveWork. Shop Drawings.Change Orders and l^ymentg 9.6 In connectionwiththeCONSULTANT responsibility astoShop Drawings and samples,see paragraphs 6.25through 6.28,indusrve. 9.7 In connectionwiththeCONSULTANTS responsibility for Change OrdersseeArticles 10,11,and 12. 9.8 In connection withtheCONSULTANT responsibilities withrespeato to Application forPayment etc, see Artide 14. Pensions,on PjaWfifflrcntt; 9.10 TheCONSULTANT shall be die initial Interpreter of die Construction Documents. Urnitations onConsultant's ResponsibilrtJei: 9.11 TheCONSULTANTwill notbe responsible for to construction means,methods,techniques,sequences or procedures,orthesafety precautions and programs inddent thereto. 9.12 The CONSULTANT will notbe responsible forthe acts or omissions of to CONTRACTOR,orany Subcontractors,oranyoftheiragent servants or employees,or any other person performing any ofthe Work underorthrough them. ARTICM;Ht -CHANCES IN THE WORK, 10.1 Without invalidating theContractthe CITY may,at any timeor from timeto time,order additions, deletions or revisions In orto die Work which shall onlybe authorized byawritten Change Orders. Upon receipt ofa Change Order,the CONTRACTOR shafl proceed withtheWork involved.All such Work shall be performed under the applicable conditions of die Contraa Documents.Ifany authorized writtenChangeOrdercausesan increase or deaease inthe Contraa Priceoranextension or shortening of to Contraa Time,an equitable adjustment will be made as provided inArtide 11 or Artide 12.Awritten Change Order signed by to QTY and to CONTRACTOR Indicates their in agreement to to terTns ofto C^an^Order.Ail Change Orders shall becertified by to CONSULTANT as tothe appropriateness ai^dvaliieoftocriangeintiieWc^as wdlastoanychange in the time to complete the Workunder to drcumstances.The failure to indude a time extension in the Change Order or in the request for a change order sfiaflresuk in a waiver ofaityextensto dueto to change in to workas reflected™to 103 The CONSULTANT may authorize minor changes oralterations in to Work not involving extra cost and notinconsistent with theoverall intent oftheContraa Documents without to need for a formal written Change Order provided the CONTRACTOR does not request additional time or additional compensation.These may be accomplished bya written Field Order.Ifthe CONTRACTOR believes thatany change or alteration authorized by to CONSULTANTS Field Order would entities to CONTRACTOR toan increate in to Contra^ wrtttennotteeofimemtoctemandaOiaiTg^ RddjOrder and submit a written proposd for Otaiige Order withfo the CONTRACTOR shallbe deemed tohavewaived such claim. 103 AdditioiidWorkperforrnedbyto shall not entitle ittoan increase in to Cotroaa Mre c>r anextenston ofto to case ofan emergency as provided In paragraph 632 and except as provided in paragraph 103. 10.4 The CITY will execute appropriate Change Orders prepared by the CONSULTANT covering changes in the Work,tobeperformed as provided in paragraph 4.4,and Work pertc*r^ provided in paragraph 6.22 andany other dalm ofto CONTRACTOR for a charige In to CbriM or to ContraaPrice which isapproved by the CONSULTANT. 103 It is the CONTRACTOR'S responsibility to notify its Surety of any changes affecting to general Scope of to Workor change In theContraa Price or Contraa Tlrne and to amoiim of to be adjusted according.The CONTRACTOR shdl furnish proof of such an adjustment to to CRY before conirnencement ofto Change Order Work.The Work shdl be stopped until to CONTRACTOR provides such proof of adjustment in the bond amount and any such delay shdl be charged to the CONTRACTOR. WTIGIE 11 -CHANGE OFCONTRACT PBIfP, M.I TrreCorrtraarTfceccwsth^ to Work,All duties,responsibilities and obligations assigned toor undertaken by the CONTRACTOR shdlbeatitsexpense without changing to ContraaPrice. 113 TrteCrTYrmy,at any tinie,without written mrfceto to indicated tobea Change Order,rr^^ induding butnot limited to changes toor In: 113.1 Specifications (Induding drawings and designs); 1133 Method or manner of perfwinanre^ 1123 CITY-furnished fadlrtJes,equipment materials,services,or site;or 113.4 AccderationintoperfornraeoftoWorit 113 Except as provided in this section,or sections referred to In this section,noenter,statement or condua ofthe CITY shall be treated as a Change Order ch*entitle to CONTRACTCMA to an equtoWe adjustment unless and until the change In to Work is spechlcally and expressly provx^^ Change Order,oras otherwise provided In another section of to Contraa Documents. 11.4 When a Change Order isissued by the CONSULTANT and signed by to Cl^ writing to CONTRACTOR shall perform to Workeven tfto CONT^^ to doHar amount ofthe Change Order.If any Change Order causes anincrease or decrease mthe CONTRACTOR?costof,orthe time required for,to performanre Contract for which to CITY and to CONTRACTOR canrwt reach a tinwfy ay^rroiTt an editable adjustmentbasedon to cost of the Work shdlbemadeand to Contraa modifiedacco 11.5 Ifto CONTRACTOR intends to assert a dahn for an equitable adjustinem ot contett to adjustment made bythe CONSULTANT,it shall,within ten (10)calendar days att^receipted ChangeOrder,submitto the CITY and CONSULTACT awrittennotice i^ forth the general nature and monetary extent ofsuch dalm for equitable adjustment time extension requested and supporting data.In determining to costofthe Change Order,to costsshdl be limited to those listedin section 11.7 and IIJ. 11.6 No dalm byto CONTRACTOR foranequitable adjustment hereunder shall be allowed ifnot submitted In accordance with this section or Ifasserted after final payment under this Contract 112 I 11.7 The value ofanyWork coveredbya Change Orderorofany claim foran increase or decrease inthe Contraa Price shdl bedeterminedinoneofthe following ways: 11.7.1 Bynegotiatedlump sum |11.73 On to basis ofthe reasonable cost and savings that results from thechange in theWork plus a |mutually agreed upon tee to to CONTRACTOR tocover oveinead and profit not toexceed I 15%.If the CONTRACTOR disagrees withtheCONSULTANTS determination of reasonable costs,die CONTRACT shdl provide alistofdlcoststogetherwithbackup documentation |11.8 The term cost of to Work means diesum ofdl direa extra costs necessarily Incurred and paid bythe t CONTRACTOR in to proper performance of to Change Order.Exceptasotherwisemaybeagreed toinwritingby CITY,suchcosts shall bein amounts no higher thanthose prevailing in Mlaml-Dade Countyandshdlindudeonlythe following items: 11.8.1 Payroll costsfor employees in die direaemployofCONTRACTORin to performance of die Work described In the Change Orderunder schedules ofjob classifications agreeduponbyCITY and CONTRACTOR.Payroll costsforemployeesnotemployed full timeon to Work shall be apportionedon die basisoftheirtimespenton to Work.Payroll costsshdlbe fimited to: salariesand wages,plus to costs of fringe benefitswhichshdl indude socid security contributions,unemploymentexciseand payroll taxes,workers'cornpensation,health and retirement benefits,sick leave,vacation and holiday pay applicable thereto.Suchemployeesshall indudesuperintendentsand foremen at die site.Theexpensesof performing Work after regular working hours,on Sunday or legal holidays shdlbeinduded in die aboveonlyIf authorized by CITYandprovideditwasnotinanyway,whetherinwholeor In part to resultof to fault of to CONTRACTOR dueto negligence of to CONTRACTORorthose acting byor tiirough h'rm or due In wholeor In parttoDefectiveWork of the CONTRACTOR. 114L2 Cost of afl materials and equipment furnished and incorporated in to Work,indudingcostsof transportationand storage,and manufacturers'fiddservicesrequiredinconnection torewrth. The CONTRACTOR shall notifyto CITYof afl cashdiscountsthatare available andoffer to CITY to opportunityto deposit funds with to CONTRACTORfor to paymentforitems tot offer a discount Cash discounts shdl accrue to CONTRACTOR unless to CONTRACTOR fails to ttrndy notify the CITYofthe discounts orif to OWNER depositsfundswith CONTRACTOR withwhichtomake payments inwhichcases to cashdiscountsshdlaccrueto the OWNER.All tradediscounts,rebatesand refunds,and all returnsfromsdeof surplus materials andequipment shadaccrueto OWNER,andCONTRACTORshdlmakeprovisionssothattheymaybe obtained. 11.83 Payments madebyCONTRACTORtothe Subcontractors for Work performedby Subcontractors.If requiredbyCITY,CONTRACTOR shad obtain cornpetJtive bids from Subcontractors acceptable to himandshdl deliver suchbidstoCITYwhowillthen determine, with to advice ofthe CONSULTANT,which Bids will be accepted.Nosubcontraa shall bea cost plus contraa unless approved In writing by to CfTY.If a Subcontraa provides that to Subcontractor istobe paid on die basis ofCostof Work plus a fee,die costof to Work shall be determined in accordance this section 11.8 and In such case to word Subcontractor**shafl be substituted for to word "CONTRACTOR". 11.8.4 Rentals ofdl construction equipment and machinery,except hand tools,anddie parts thereof whetherrentedfrom CONTRACTOR orothers in accordance with rentd agreements approved byCITYwith die advice of CONSULTANT,andto costsof transportation,loading unloading,installation,dismantling and removal thereof -all in accordance withtermsof said rental agreements.Trie remd of any such equipment iracWnery or parts startl cease whento usethereofisno longer necessary for to Work. 11.83 Sates,vse «rsirniiar taxes related to to Work,and for wWch CONTRACTOR te liable,Irn^ byany governmental authority. 11.8.6 Payments and fees for permits and licenses.Com for permits and licenses must be shown as a separate Item. 11.8.7 Thecostof utilities,fuel and sanitary facilities at die site. 11.8A Minor expenses such as telegrams,long distance telephone calls,telephone service atthe she, expressage andsimilarpettycash herns inconnection with the Work. 11.8.9 Cost of premiums for addtiond Bonds and insurance required solely because of changes in the Work,notto exceed two percent (2%)ofthe increase in to Costof to Work. 11.9 The term Cost oftheWork shdl NOT include any ofthe following 113 11.9.1 Payroll costs and otor compensation of CONTRACTOR'S officers,executives,principals (of partnership and sole proprietorships),general managers,engineers,architects,estimators,lawyers, agents,expediters,timekeepers,derks and other personnel employed by CONTRACTOR whether at to site ormits principal ora liranchc^ceforger^ac^mstrBtic^of the Wor^ and not spedficdiy induded In to schedule referred torn Subparagraph 115. 11.93 BcpensestfCOrinWCTORS 11.93 Any part ofCONTRACTOR'S captad expenses,IncW^ employed for to Work and criar^agdrm CONTRACTOR for ddinq^ 11.9.4 Cost ofpremiums for dl bonds and for dl insurance policies whether ornotCONTRACTOR Is required by the Contraa Documents to purchase and maintain the same (except as otherwise provided in Subparapaph 11.8.9). 11.9.5 <^duetotoneg)lgiirK:eofCONTRACTOK Indirectly employed by any of them or for whose acts any of torn may be liable,induding but not limited to,the correction ofdefective work,disposal of materials or equipment wrongly supplied and making good any damage to property. 11.9.6 Other overhead or general expense costs of any kind and the costs ofany item not specitlcally and expressly Induded bt Paragraph 11.8. 11.10 The CONTRACTOR'S fee which shdl be dlowed to CONTACTOR forte overhead ami p determined asfollows: 11.10.1 Amutually acceptable firm fixed pricey ch-if rione can be su^eed upon. 11.103 Amutually acceptable fixed percentage (not toexceed 15%). 11.11 TheaiiK*intofcrec3ttobe^ anetdecrease in costwill be to amount ofto actual netdecrease mcosts calculated in to same n^ner as provided in Il.a When both additions and credits are involved in any wie diange.to net shall be computed to indude overhead and profit identified separately,torboth a^ provided however,to CONTRACTOR shdl n«be entftiW to ddm loa profits for any Work r»^ performed. fff"""-Tiff FQR WW"«T1QIIL UOUIPATEP DAMAGES AMD CHANGE OP THE CONTRACT TIME, 12.1 Tlrneisoftoessencetothisc* are^sttitid conditions of to Contract Therefore,to Woric sha»l*cominenc^ .->->^"^^^^aoe«>ffVoc»eciaandczompl^DBciwtcfiltidieeJmesg>«ci6«cf«mtcxsrvipleeJoiioTeJieworic 123 The CONTRACTOR shafl proceed with to wi^toContiraaTime,It is expressly understood and agreed,by and between the CONTrUCTOR and to OWNER,that the Contraa Time for the corr^etioncrfto Work described herein is a reasonable time,taking Into condderation to average dlmatic and econornte lirevdltngrn to locality ofto Work.No extension of time shaH be gamed due m Corrtraoorkrrewoforshotild^ except asprovidedinsection 12.7. 123 Ifthe CONTRACTOR shdl fall to cornplete granted by to CITY,then the CONTRACTOR shafl pay te to OWNER to amount oflk|uk^ damages as specified in to Contraa Dcx:uments for each calendar day a completion asadjusted by written QiangeOrdrntiiatextefideo^ 123.1 These amounts are not penalties but are liquidated dann^incurred by to ^ faiaWRty to orjtamfofl use ofthe Projea liquidate damaj^are hei^fixed ar^ between the parties,recognizing the impossrblfity of predsdy ascertaining to amount ofdamages that will be sustained as a consequence ofsuch defy,aidboA parties dedrirg^ question or dispute concerning the arruum ofsdddamages and to cc^ ofCONTRACTOR to complete to Contraa on time.The above-stated liquidated damages shafl apply separately to each phase oftheProjeaforwhichatimeforcc^npletionistfven. 1233 OTY Is authorized to dedua to liquidated damages from monies due to CONTRACTOR for to Work under this Contract 1X4 The Contraa Time may only be.changed by awrittenOiange Order.Any ddmforan extension in to CONTRACTTIME sridl bebasedon w^ five (5)business days ofto occurrence ofto event gving rise to to dalm and stating to general nature ofthe dalm Induding supporting data.AH dalms for adjustment In theContraa Time shdl be evaluated 114 and rerommended bythe CONSULTANT,with find approvd bythe CITY'S representative,Any change In to ContraaTime resulting from any such ddm shdl be incorporated ina written Change Order. 123 All time limits stated in the Contraa Documents are of to essence of the Contraa 12.6 No ddm for delay shall be allowed because of failure to furnish Drawings before the expiration of fourteen (14)calendar days after demand has been made In writing tothe CONSULTANT for such Drawings.Furthermore,there shall beno monetary compensation forsuchddayandthe CONTRACTOR'S sole remedy shdlbeanextension oftimefortheperiodofdday. 12.7 Extensions to die Contraa Time for delays caused bythe effects of inclement weather shall notbe granted unless to weather was unusual for South Florida and could not have been arrtidpated,die abnormd weather is documented by records from the national weather service and the abnormal weather Is documented to havehadasubstantial affected on to construction schedule. 118 No Damages for Delay:The CONTACTOR agrees thatheshdlnot have any cfalm for dar^ delay unless the delay exceeds 6 months,whether individually or cumulatively,and thenthe damages shall be limited to increased costof materials thatwere unanticipated and thatwouldnothavebeen incurred butforto delay.Other than asset forth above,to only remedy for any dday shdlbe limited toan extension erf timeas provided for in Section 114which shall be to sole and exclusive remedy for such resulting delay.Otherthanasset forth above,CONTRACTOR shdlnotbe entitled toan increase In the Contraa Price or paymentor compensation ofany kind from OWNER fordirectindirect consequential, impaaorotiier costs,expensesor damages,induding butnot limited to,costsof acceleration or ineffidency,overhead orlost profits,arising because of delay,disruption,interference or hindrance from anycause whatsoever,whether such delay,disruption,interference or hindrance be reasonable or unreasonable,foreseeable or unforeseeable,oravoidable or unavoidable 119 The CONTRACTOR waives dl chums that are not presented to to Cityin writing onor before the 21 st day following the dateof to eventuponwhichto dalm is based. 12.10 Dispute Resolution:ifanydispute concerning a question offaa arises underto Contractotherthan termination fordefaultor convenience,to CONTRACTORandthecitydepartment responsible forthe administration of the Contraashdl make a good faith efforttoresolvethe dispute,if to dispute cannot be resolved byagreementthen die department withthe advice ofthe Qty Attorneyandthe CONSULTANT shall ruleon to disputed issue andsendawrittencopyof its decision to to CONTRACTOR.CONTRACTOR shdl comply with such decision and shafl not delay the projea AHT1CM;13 -GUARANTEE, 13.1 TheCONTRACTOR shafl guarantee and unconditionally warrant througheither to manufacturer orthe CONTRACTOR directly,all materidsand equipment furnished andWork performedforpatent Defective Work fora period ofone(I)year from to dateof Find Acceptanceas Indicated into CONSULTANT Letter of Recommendation ofAcceptanceorfrom the datewhen the defect wasfirst observable,whicheveris rater.Thesame guarantee and unconditional warrantyshdlbeextendfor five (5)yearsfrom the dateof Find Acceptanceas Indicated in to CONSULTANTLetter of Recommendation of AcceptanceforlatentDefectiveWork.TheCITY will givenotice of observed defectswithreasonablepromptness.In theeventthatthe CONTRACTOR should tail to commenceto corneasuchDefective Work withinten (10)calendar days after having received writtennoticeof to defect orshouldtheCONTRACTOR commence the corrective work,but fall toprosecuteto correctivework continuously and diligently and In accordance with the Contraa Documents,applicable raw,rules andregulations,to OTY may declare aneventof default terminateto Contraainwholeor in portandcausethe Defective Work tobe removed or corrected and to completethe Work at to CONTRACTOR'S expense,and theCITYshdl charge theCONTRACTORthecostthereby incurred. The Performance Bond shall remain in full force and effea through the guarantee period 133 The specific warranty periods listed In to Contraa Documents,if different from the period oftime fisted in Section 13.1,shall take precedence over Section 13.1. 133 CONTRACTOR shdlaa as agent ona limited basis for to OWNER,atthe CITY'S option,solely for die follow-up concerning warranty compliance for all hems under manufacturer's Warranty/Guarantee andfor die purpose of completing dl forms for Warranty/Guarantee coverage underthisContraa 13.4 In case of default bythe CONTRACTOR,the City of South Miami may procure to articles or services from othersources and hold die CONTRACTOR responsible for any excess costs occasioned or incurred thereby. 13.5 The CITY may withhold acceptance of,orrejeaitems which are found upon examination,nottomeet the specification requirements.Upon written notification of rejection,itemsshdlbe removed within five lis (5)business days by to CONTRACTOR at hU own ex|>eme and reddrvered at Ills expense.Rejected goods left longer than thirty (30)calendar days shdl I*regard fight todispose ofdiem as its own property and to CONTRACTOR thereby wdves any dalm tothe gcxxlortocorripensadonofanykind.Rejection for Nornroiifbrming Work or failure to rneet defivery schedules may result in the Contraa being found indefault ARTICLE 14 -PAYMENTS AMD CQMPIPTIHM fryrnffltt to Gontraffioc 14.1 The Contractor shafl notbeentitled to any money for any work performed b^ Notice to Proceed on to form described tti to ContraaDocurnemsandtoissuanrebytoOty ofa "purchase order",or any otherdocument does not and shall not authorize to commencement ofthe Work.At least ten (10)calendar days before each progress payment falls due (|b^ once amonth),the CONTRACTOR shall submit to the CONSULTANT a partial payment estimate filled outand signed byto CONTRACTOR covering the Work f>erfc^rrned during to period covered byto partialI payment estimate and supported by such data as to CONSULTANT may reasonably require.All progress payment applications afr^to fim progress payn^ Hen executed by all persons,firms and corporations who have furnished labor,services or materials incorporated into to work during the period oftime for which the previous progress payment was made, releasing such dalms and lien rights,ifany,ofthose persons.If payment is requested on thebasis of materials and equipment not incorporated into Work but ddlv^ to partid payment estimate shall also be accomrxmled Ijy such w which establishes the OWNER'S tide to to materidandec^menttt providing coverage for 100%ofthevalue of said material and equipment covering to material and equlrjrnent from all casualties as well as thefts vandalism,fire aiidfiood The CONTRACTOR shall replace atto expense anystored rnaterids paid for which areeither daniagedc4»s The COyULTANTvvillwhiimten(l0)cdefK^ certifying inwriting its approvd of payment and present to partid paymem estimate to to OWNER,or returnthepartidpaymentestimateto to CONTMCTORJr^ to approve payment In the latter case,to COhTTRACTORrntymaketontttessat^ resubirit to partid payment estimate.The OWNER,will within thirty 00)calendar days erf r^esentation toitof any approved partid payment estimate,pay to CONTRACTOR a progress payment onto basis of to approved partial paymerit estimate,The OWNER shdl retain ten (10%)percent of to amount of each payment until find Completion and Acceptance ofdlWork covered bythe Contraa Documents. Any interest earned on to retainage shafl accree to to benefit of to OWhIER. 14.2 Tlte CONTRACTOR,before itshaflreceto r^ymem Affidavitas set forth In the Florida ConstructionUenStatuteaswellasfindreleasesoflien executedby afl personswhohave r^rformed or furnished labor,servkes or material^ Indirectly,which wasincorporated intotheWork.Ifany person refuses to provide such a release or provides a comlrticuul release,to CriY shall rave to i^t to CONTRACTOR and such person. Contractor's Warrantyof Tfrfc 143 The CONTRACTOR warrants and guarantees diat tide todl Work,materials and equipment covered by an Apf>!ication for Payment whetherto Work,materid or equipment Is incorporated in to Projea or not shall havepassed to to OWNER prior to to making of to Appficatton for Payrr>ent free ami dear of afl liens,cfaims,security interest and encumbrances (hereafter inthese General Conditions referred to asliens");and thatnoWork,materials or equipment covered byanApprtcatim been acquired by to CONTRACTOR orbyany otherpei^onperiormingtoWcHicatthesrteor furnishing materials andequipment forthe Project underor pursuant toan ayeement underwhich an interestthereinor encumbrance thereon Is retained by to seller or otherwise imposed bythe CONTRACTOR orsuchother person. ApproYiM of Paymfflt 14.4 The CONSULTANTS approvd of any payment requested In anApplication for Payment shdl constitute a representation byhimto to CITY,based on to CONSULTANTSonsite observations oftheWorkin progress asanexperienced professional andonhisreviewof to Application for Payment and supporting data,thatthe Work has progressed tothepointindicated In to Application for Payment;thatto to 116 best his knowledge,information andbdief,the quality of die Work isin accordance withthe Contraa Documents (subjeatoan evduation of to Workasa functioning Projeaupon substantial completionas defined In Article I,to theresultsofany subsequent tests called forin to Contraa Documentsandany qudrfications statedinhis approval);andthat die CONTRACTORisentitledto payment of die amount approved.However,by approving any such payment to CONSULTANT shdlnottherebybedeemed tohaverepresented thathemadeexhaustive or continuous on-site observations tocheck die qudrty or die quantity of to Work,orthathe has reviewed to means,methods,techniques,sequences and procedures ofconstructionorthathehadmadeanyexamination to ascertain how orforwhatpurpose the CONTRACTOR hasused to moneys paid ortobe paid tohimon account of to Contraa Price,or tot tideto any Work,materials,or equipment has passed to to OWNER free and dearof any liens. 14.5 The CONTRACTOR shdlmake die following certification oneach request for payment: "Iherebycertify that die laborand materials listed on this requestfor payment havebeenusedin die construction of this Work and tot dlmaterialsindudedinthis request for payment and not yet incorporated Into to construction are nowon to siteorstoredatan approved location,and payment received from to fast request for payment has been used to make payments todl his Subcontractors and suppliers,exceptforthe amounts listed below beside to names of to persons who performed work or supplied materials". Intheeventthat to CONTRACTOR withholds payment froma Subcontractor or Supplier,thesame amountofmoneyshdlbe withheld from the CONTRACTOR'S payment until the issue Is resolved by written agreement between torn andthenajointcheck shaH bemade payable to to person In question andtheCONTRACTOR in accordance wfth to setdementagreementotherwisethemoneyshdlbe heldby die OWNERuntila judgment is entered in favor ofthe CONTRACTOR orthe person,in which case themoney shall be paid according with said judgment Nothing contained herein shdl indicate an intent to benefitanythirdpersonswhoarenot signatories to to Contraa 14.6 TheCONSULTANTmayrefuseto approve thewholeoranypartofany payment if.In its opinion,it is unabfetomakesuchrepresentetkmstotoOWNERasrequ^14.It mayalso refuse to approve anypaymentor h mayvoidanypriorpayment application certification because of subsequently discoveredevidenceor the resultsofsubsequent inspection orteststosuch extent asmaybenecessary initsopinion to protea the OWNER fromloss because: 14.6.1 ofDefectiveWork,orcompleted Work hasbeen damaged requiring correctionorreplacement 14.63 to Work forwhichpaymentisrequestedcannotbe verified, 14.6.3 cfaimsof Lienshavebeen filed orreceived,orthereisreasonableevidence indicating to probable filing orreceipt thereof, 14.6.4 the Contraa Price has been reduced because of modifications, 14.6.5 to CITYhas correa Defective Work or completed the Work in accordance withArticle13. 14.6.6 of unsatisfactory prosecutionof to Work,induding failure to deanupasrequiredby paragraphs 6.29 and 630, 14.6.7 ofpersistent failure tocooperatewith otor contractors on the Projeaandpersistentfailure to carry out to Work in accordancewith to Contraa Documents, 14.6.8 of liquidated damages payable bythe CONTRACTOR,or 14.6.9 ofanyother violation of,or failure to comply with provisions oftheContraa Documents. 14.7 Prior toRnd Acceptance to OWNER,withto approvd ofthe CONSULTANT,may use any completed V substantially completed portions ofdie Work provided such use does not Interfere with to CONTRACTOR'S completion of to Work.Such useshdl not constitute an acceptance of such portions of the Work. 14.8 The CITY shdl have the right toenterthe premises for to purpose of doing Worknot covered bythe ContraaDocuments.This provision shdl notbe construed as relieving the CONTRACTOR of to sole responsibility for to care and protection of to Work,orthe restoration of any damaged Work except such asmaybe caused by agents or employees of to OWNER. 14.9 Upon completion andacceptance of to Workthe CONSULTANT shdl issue a Certificate attached to the Find Application for Payment thatto Work has been accepted byitunderdie conditions of die Contraa Documents.The entire balance found tobe due the CONTRACTOR,inducing to retained percentages,butexceptsuchsumsas may be lavvtuliy retained by to OWNER,shdl r^paid tothe CONTRACTOR within thirty (30)calendar days of completion and acceptance of to Work. 117 14.10 Upon The awarded CONTRACTOR will be strong^encouraged to register as an ePayables Vendor with the Owner.The Bank ofAmerica ePayabfes Solution Is an automated card payment process that shifts accounts payable disbursements to corporate purchasing cards.ePayables,streamline the process of making payments to your organization goirig forward,to City credit card account number to keep on file.This card has urtiquesecurty funds until an invoice is approved for payment After an invoice has received proper and complete approvd.an electronic remittance advire win besemviae-mail,orfa* CONTRACTOR that to fends have been trar^erred In toto account nnked toto ord for to annnint listed on to Invoice and/or remittance email.Please refer toto ePayables Questions *Answers Form contained in this RFP or contaa to OWNER'S Rrianre department Acceptance of Rnal Payngpt as fUl^e 14-11 Jl£l2P"m^^a^^O^ERandawaiverofallddmsanddlfiabflitytotofiled^and unresolved.The waiver shdl Include all things done or furnished in connection with to Woric and for every aa and neglea of to OWNER and others reiatingto or arising out ofthis Work,Any payment however,final orotherwise,shall not release to CONTRACTOR or its sureties from any ,4J2 ^CONSULTANT may void any certification erfSubstain^ Work as may benecessary in his opinion to protea to OWNER from loss ff hedetermines,Ix^ause of subsequently discovered evidence or the resulo ofsubsequent irispeoion or tests,that 14.111 theWc4fckdetectrve.orthatto CONTRACTOR orany individual or entity operating under or through It requiring correction orreplacement to to extent that to projea is no lor«erSubstanti%Completed,orin the case of Rial Completion certification,is no longer Rnalry Competed 14.123 to Work necessary to be completed for to purpose ofcertiryingthe woric as being Substantially Completed or finally Completed cannot beverified. 14.123 claims or Liens have been filed or received,or mere is reasorobte evidence Indicating the probable filing or receipt dtereof that rfvdld and paks\would redim CONTRACTOR BY 20%in to case ofSubstantial Con^etion and 5%In the case of Rnd Completion. 14.114 tore is Defective Woric to value of which,ifdeducted from to conr^ to amount owing to to CONTRACTOR BY 20%in to case ofSubstantial Completion and 5% in to case of Rnal Completion. 14.13 Ifto CONSULTANT de-certifies any poirtionoftoWorkthatwascerin^ to CONSULTANT,to CONTRACTOR shdl repay toto City erf Soutii Miami any rr^r^y paid as a result ofsdd Initial Certification being issued which shdl be paid only when to decertified work is re- certified. ARTICLE 15 -SUSPFMSIOM OF WORK AMQ TERMINATION 15.1 The CITY may,at any time and without cause,suspem!to Work orany p>rtfon there not more than ninety (90)calendar days bynotice In writing to to COriTIUVCTOR arid to CONSULTANT,which shall fix to date on which Workshdlbe resumed.The CONTRACTOR shall be aikmed anincreasein to Contraa Price attributable to any suspension and ifaddmis timely made and ffh isaflowed under to terms of Aitides II or Artide II City May Terminate 153 Ifthe CONTRACTOR isadjudged bankrupt or insolvent or ifhemakes ageneral assignment for to benefit ofits creditors,or rf atrustee or receiver isappointed for the CONTRACTOR or for any its property,or Ifhe files a petition totake advantage of any debtor's actorto reorganize under bankruptcy or similar laws,or if he repeatedly falls to supply sufficient skilled workmen or suitable materiab or equipment orifhe repeatedly fails to make prompt payments to Subcontractors or for labor,materiab or equipment orhe disregards laws,ordinances,rules,regulations or orders of any public body having jurisdiction,orifhe disregards the authority of to CONSULTANT,or if he otherwise violates any provision of,theContraa Documents,ton to CITY may,without prejudice to any other right or remedy and aftergiving the CONTRACTOR and to Surety seven (7)cdendar days written notice. MS terminate the services ofthe CONTRACTOR andtakepossession of the Projea andofdl materials, equipment,tools,constructionequipment and machinery thereonownedbytheCONTRACTOR,and finish the Work bywhatevermethoditmaydeemexpedient In suchcasetheCONTRACTORshdl not beentitledtoreceiveanyfurtherpaymentuntilto Work is finished.Iftheunpaid balance ofto Contraa Price exceedsthedireaandindireacosts of completing the Projectinducingcompensation for additional professional services,suchexcess shall be paid to to CONTRACTOR,ff suchcosts exceedsuch unpaid balance,to CONTRACTORor the Suretyon the Performance Bondshdlpay the differenceto to OWNER.Suchcostsincurredbythe OWNER shdlbedeterminedbythe CONSULTANT andincorporatedinaChangeOrder. If aftertermination of the CONTRACTOR underthisSection,it isdeterminedbyacourtof competent jurisdictionforanyreasonthat the CONTRACTOR was not indefault the rightsand oblations of die OWNER and the CONTRACTOR shdlbe the sameasif the termination had been issued pursuant to Section 153 153 Where to CONTRACTOR'S serviceshavebeensoterminatedby die CITYsaidterminationshdl not aftea any rights oftheOWNER against theCONTRACTORthenexistingorwhichmaythereafter accrueAnyretentionor payment ofmoneysbytheOWNERdue die CONTRACTORshdlnotrelease the CONTRACTOR from liability. 15.4 Uponseven(7)calendardayswrittennotice to to CONTRACTOR and the CONSULTANT,theCITY may,withoutcauseandwithout prejudice toanyotherrightor remedy,efea toterminateto Contraa tor the convenience of the OWNER.In such case,the CONTRACTOR shdlbepaidforallWork executed andacceptedby to CITYasof to dateofthetermination,minusanydeductionfor damage or Defective Work.Nopaymentshdlbemadeforprofitfor Work whichhas rxHbeen performed. I5.4A TheCITYreserves die rightintheevent to CONTRACTORcannotprovidean rtem(s)or services)ina timelymannerasrequested,to obtain the good and/or servicesfrom other sourcesanddeductingthe costfrom to Contraa Price without violating to intentoftheContract Removal of Equipment 153 inthecaseerf termination ofthisContraabeforecompletion foranycausewhatever,to CONTRACTOR,ifnotifiedto dosoby to CITY,shall promptlyremoveanypartordlofitsequipment andsuppliesfrom to property ofthe OWNER.Should tfie CONTRACTOR not removesuch equipmentand supplies,theCITYshall haveto right toremovethemattheexpenseof to CONTRACTORand to CONTRACTOR agrees that to tosuchequipmentor supplies.Equipment and supplies shaH notbeconstruedtoIndudesuch herns for which to CONTRACTORhas been paid in whole or In part Comractor Mqr Stop Work or Terminate, 15.6 tf,through noaaor fault of to CONTRACTOR,theWorkis suspended for a period of more than ninety (90)calendar days bytheCITYorby order ofother public authority,or under anorderofcourt or to CONSULTANT falls toaaon any Application for fryment within thir^ b submitted,ortheOWNER falls to pay the CONTRACTOR any sum approved by the CONSULTANT, within thirty(30)calendar days ofits approvd,and presentation,thenthe CONTRACTOR may,upon twenty (20)calendar dayswrittennoticeto to CITYandtheCONSULTANT,terminate to Contract The CITY may remedy to deby or n^ remedied byto CITY the Contraa shdl notbe considered terminated,in lieu of terminating to Contract if the CONSULTANT has failed toaaon an Application for Payment or to OWNER has failed to make any payment asafore said,to CONTRACTOR may upon ten (10)calendar days'notice to to OTY and the CONSULTANT stop to Work until It has been paid all amounts ton due. Indemnification of Independent Contirtranf 15.7 The CONTRACTOR and the CITY hereby acknowledges that If to CONSULTANT isan Independent contractor ofthe OWNER,the CONSULTANT may be reluctant to rule on any disputes concerning the Contraa Documents oronthe performance ofto CONTRACTOR orthe OWNER pursuant tothe terms ofthe Contraa Documents.Therefore,to OWNER,atthe CONSULTANTS request agrees to provide the CONSULTANT with a written indemnification and hold harmless agreement to indemnify and hold to CONSULTANT harmless as to any decision in this regard before the CONSULTANT makes 119 ?IIIS!!^13110^de-certlfte$aPayment application,decertifies Substantial Completion,decertifies Rnal Cofnpteoon,certifies an event of default or approves any action which requires to approvd ofto CONSULTANT. artici p is-Mi^i f ftHRfrV? 16.1 Wherteverany provision of the Omtraa Documents requires to giving erf written notice itshdl be o^emedtohawj been validly given tfdelivered in person to to mdiv^ to an officer ofthe corporation for whom rtUiirterrded,orrfdelrvere^atorsentbyr^stei^or certified mall,postage prepaid,to to fast known business address. 162 VO^*™™*Doctim8nt5 ^remaln *e property of to OWNER.The CONTRACTOR and to of the Project163T^iriesandobfi^tioro^ Conditions,ifany,and the rights and remedies avdtabte hereurufer,ait4 ^ firntaticn,die warranties,guarantees and obligations imposed upon CONTRACTOR by to Contraa laments and to rights and remedies available to to OWNER and CONSULTANT thereunder,shall be in addition to,and shdl not be construed in any way as alirnitatwn of,any rights and remedies available bylaw,by special guarantee orbyother provisions erf to C^nUM Dooimemx 16.4 SiKHildtoOWNERortoCONTRACTORsufferinjUtyo^ any error,omission,oraaoftheother cjt ofany ofthdr employees or agents orotherat^ toy arelegaily liable,dalm shdl be rmde in writirig toto odier party within t^ days ofthe first observance of such injury ordamage. ARTICLE 17.WAIVER Of |URYTfW.f., 17.1 OWNER and CONTRACTOR 1^ t^have to atrid by jury In State w FedOT lawsuit orcounterdaim arising outofto Contraa Documents orto perfonrance ofthe Work thereunder. ARTICLE 18 -ATTORNEYS FCFS lURiSDimnN,venue /horning law. 18.1 The Contraa diafl be coiistnie^ 18.2 The parties submit to to jurisdiction ofaiiyccwrtofcompetem^^ oractxmartdftgoutoforrelatingtoto Venue of any action to enforce the Contraa shall bein Mlaml-Dade County,Rorlda. 183 k^ce|rtasintybecdierwlseprcn<ded other matters in question between to OWNER and to CONTRACTOR arcing out erf or refating to this Contraa orto breach toreof,shall be decided in acourt ofcompetent jurisdiction within the State of Florida. ARTICLE 19 .PROIECT RErappfi, 19.1 The CITY shdl have right to ins|x»arid copy during regular books and records and accounts ofCONTRACTOR which relate In any way to to Pr^ cfalm for additional compensation made by CONTRACTORS to condua an audit of to fi accounting records of CONTRACTOR which relate to to Project CONTRACTOR shall retain and make available to CITY afl such booksand records and actounts,firiancbl or odier^ the rVojea and to any dalm for a period crfthree (3)yeare following find co During to rVofea and to three 0)year perM CONTRACTOR shdl provide CITY access to Its books and records upon five (5)business da/s written notice. 193 CONTRACTOR and all of its subcontractors are required toamply wioS to public records law (s.119.0701)while providing serviceson behalf of to OWNER and the CONTRACTOR,under such conditions,shall Incorporate this paragraph in dlof its subcontracts for this Protect CONTRACTOR and its surjcontraoors are spectficafly required to:(a)Keep and maintain public records thatordinarily and necessarily would be required byto public agency in order to perform to service;(b)Provide to public with access to public records onto same terms and conditions that to public agency would provide to records and atacostthat does not exceed to cost provided In this chapter oras otherwise 120 proddedbylawr(c)Ensurethatpubotrecordithatareexemptorcorrnc^ritialandexemptfrompubte records&sdosureroquirerr^ requ&wnerrtsforretailingpublfc Inpossessionofthecontractoruponteiiiiiiiilonofthecontractanddestroyanyduplicatepubficrecords thatareexemptorconfldentlilandexemptfromtwinerecordsdiidoimeregtaVemenfiAHrecords •storedetecoionlceuyroustbeproddedtothepublicagencyInafenneltnatbtvwnpetlbiewfththe iffumiiawonueuuxHsaylysteiiBororepirnx.agency, 193rfCONTRACCTORretasubuxiutiaor naveuieiiputoeniorxeuTJSContriauiovu^cuiDyspecnKueitUfrnarK&aixitnepe urovtikxishaBbeaabfetoOWN^fb^ bicurredinanfwootegnsjtwhetheradhifcifatialiveordvucourtandbiani ^ffTlfflFal-l 20LInanyprovisionoftheContraaorthoeppnriilonthereoftoanypersonorsltuatioflshdltoaiwcuuertt beheldInvalidoruneiroroeabie,theternalfederoftheContractaiiddteapplicationofsuchprovisionsto personsorsituationsotherthanthoseastowhichItshaflhavebeenheldInvalidoruitonforoeibleshafl notbearwictndthereby,andshaflcontinueInftrflforceandeffectandbeenforcedtodiefuHettextent permittedbylaw. 21.1TheCONTOACTORbanlndi^^ CONTRACTORshaflbebyemptaymoftoCONTRACTORS CONTRACTOR,andnotasofficers,eniphipeai,y ,sodalsecurityandhealthIrtsurince,employeebenefitedpsnxhasliujpoidesandother ftSijtfMBB^fttahJnVaflMaaaV«mAflhSV^BBmsValWettam.•*^gaS1^fcJ^^B^fc^8ftaBBBm^B^BBatmaSkWaaUaf^^BBmaBBBBBBBBBBBBBBfe^BBBB*aBBBe^amllftV^a*aViBBB*tMb^ekST iprooooures,appnrtnietoservicesrerusereawidertne\jontraccsnailoeinoseor toCONTRACTOR. AfrnnriintmiitmrTiT 22.1TrwCONTRACTORshdlrxtttrv^ adshiisndertoterii^ooiuan^ ChyMartager,TrieCriYwuIn CONTRACTOR'Srights.TlteCCTmty,inltssc4eaiids£s^ CONTRACTORtoasafeitodirties,obafcatimInanyeventtheOTYshaflnot consorttosuchasajsjimett toAereensentIn/toaasls^ee,to satisfactionandtheassfeneoexeeuottaflerftoContraaDocumentso^ bytoCONTRACTOR INnortave_execut©d^GeneralOxxfitionstoacknowtedgitheir aspertoftoContraai>«umentso^ Slgnanire: ill rrrfttSuymivythhnie:wM^tT^dt^^^^A^^0^ ThfoofSteiatorv!^K^jUb' OWNER:CXTh(Sf%0\JTH\ EXHIBIT 8 Supplementary Conditions cnqreUe t>r*IiunjoIreproventant Piuletti MFPtpw.aeis.it parawHendBad a,dieCONSULTANT to the SupplementaiyCondtoM org none,then OTT, *>«BicdrB|«BBne^Tr*CONSULTANT.,If any.JJ^Caya DeMpa^IUs«miiwI»',nan^ Cm»*»»*T.Y.LyrailiitenwtlomVmRon 201 ABuvnbraQrato,Suite900 Coral Gafatet.FI 33134 FhameSOSSCMSSB Foe 305067-1771 OtflWariBvInc 8941 N.W.l7&f*t.S**e I0B Doral,Ft 33126 Phonee 30S/59I-4323 *"'^S!T!^9*0^MkmttCamil,m'b Nod^hwtoriaapnwwth.CITYfromu.riimltntthe«f>^«tt*CONSULTANT oHromaubiftittl^^ C HtrafarCoaitrualen:Theeuc^ ^•""^iJ^*"^^«*>*^««|tereo^B^wfflbelufriBkedt»theCON^coataa the CONTRACTOR equal tothe reproduction coat D.Tiie Scope of Sewtcaa,alwpea»i^to a,ftaWaffctadia contra^ and tothe attached EXHttlT I awdlf«faii»h««^«ift^^tffi,^fttf^^ E <*ntrtctcT«haB,coriB*y»»fditholMu^^ fc^he attached EXWOTla^If therebacot^ much event the Omraasna»takeprecettmm^^ to the Cwwritt that may bete dieoomrary.. INWITNESS WHEREOF,the pantet hereto ha&tncutedthe$tac4ementawConddBnatD acfaiowrtBuptl«*tnc*iBlonaap«rtof^.20/}. Read and CONTRACTOjfe /jffifeffiffitf^d3/L.C* Hint 5ytttor)fs TbJo ofSanatory;iy '<&*&.. ATTBTHfc "\S\s\OWNERtOTY OF SOUTH MIAMI Maria Menendez V StevenAJenndtr OKfOmk y^s OtyMwagor CTQBConstructionTradesQualifying Board BUSINESS CERTIFICATE OF COMPETENCY) E251302 MAGGOLC INC ?D.BA: GONZALEZ MARIO Is certified under the provisions of Chapter toofMfonl-PafeCpur^ Local Business Tax Receipt Miami-Dade County,State ofFlorida -THIS IS NOT A BILL -DONOT PAY 5664064 BUSINESS NAME/LOCATION MAGGOLCINC 11020 SW 55 ST MIAMI Fl 33165 OWNER MAGGOLC INC Workers)J RECEIPT NO. RENEWAL 5928487 EXPIRES SEPTEMBER 30,2016 Must be displayed atplace of business Pursuant lo County Code Chapter SA-Art 9&10 SEC.TYPE OF BUSINESS 196 SPECIALTY ENGINEERING CONTRACT£A™?!£?f^™,?E251302 BY TAX COLLECTOR $75.00 07/18/2015 ECHECK-15-158260 This Ucal Business Tax Recent only confirms payment efthe Local Business Tax.The Receipt Unot alicense, permit ora certification of ihetafdei'i Qualifications,todo business.Holder must comply vvftb anygovernmentalornongovernmentalregalalojyUVtxandrequiremeatewhichapplytothebusiness. The RECEIPT NO.above must bedisplayed on all cttnojerciaf vehicles -MiamWJade Coda Sac8e-276. Formoreinformation,visitWww imnmidarfe.povftajtcfilfflctor STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION ?o^SJ^Jl?N 'NDUSTRY LICENSING BOARD 1940 NORTHMONROE STREET TALLAHASSEE FL 32399-0783 GONZALEZ,MARIO H MAGGOLC INC 11020 SW55TH STREET MIAMIFL 33165 Congratulations]With this license you become oneofthenearly one million Fioridians licensed bythe Department of Business and Professional Regulation.Our professionals and businesses range from architects to yacht brokers,from boxers to barbeque restaurants andtheykeep Florida's economystrong. Everydayweworkto improve thewaywedobusinessinorderto serveyou better.For Information aboutourservices,please log onto www,rnyfloridalicense.com.Thereyoucan fmd more information aboutour divisions andthe regulations that Impact you,subscribe to department newsletters and learn more aboutthe Department's initiatives. Our mission atthe Department is:Lioense Efficiently,Regulate Fairly We constantly strive to serve you belter sothat you can serve your customers.Thankyoufordoingbusinessin Florida, and congratulations on your newlicense! DETACH HERE RICKSCOTT,GOVERNOR (850)487-^1395 STATEOF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSiONAi/REGULATION CUC1224868 ISSUED:.06/15/2014 CERT UNDERGROUND &EXGAV QNTR GONZALEZ,MARK)H KMGGOLCINCU;-..y..~"•- IS CERTIFIED under trie provisions of Ch.469 FS. Expiration date :AUG 31.2016 L14061S0001743 KEN LAWSON.SECRETARY STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD The UNDERGROUND UTILITY &EXCAVATION CO Named below IS CERTIFIED Under the provisions of Chapter 489 FS.• Expiration date:AUG 31,2016 GONZALEZ,MARIOH MAGGOLC INC 11020 SW55TH STREET •MIAMI FL 33165 STATE OF FLORIDA DEPARTMENT OFBUSINESSAND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD 1940 NORW MONROE STREET TALLAHASSEE FL 32399-0783 GONZALEZ,MARIO H MAGGOLC INQ 11020 SWS5TH STREET MIAMI FL 33165 Congratulations!With thislicenseyou become oneofthe nearly prte^SBoqFWiolahs Jioen^ferine Department of Business and Frotessfori|)§egAi^otv OUr protessionals and businesses rangefrorharcritlbstoyachtbrokers,from boxers to barbeque restaurants,and they It^Florifia'I e^rwrriy stong; Ever#|fcw*^thjeiWQpe |di business in order to serviySU biit%-F6rpTOnnatfon aboutour services,please log ontoww^ft^fllWiMTOii^m,There you can find more information aboutowf dvSsiohs andthe regulations thatimpactyou,subscribe to-department newslettersand learn moreaboutthe Department's OurmteBlon attheDepartmentis:license Efficiently,Regulate Fairly. We constarrtiy strivetoserveyoubetter so thatyoucanserveyour customers.Thankyoufor doing businessin Florida, ana"congratulationsonyournew license! DETACH HERE JSPS scofr;GovpNpR ISSUED:08/02^015 DISPLAYAS REQUIRED BY LAW (850)487-1395 KEN LAWSON,SECRETARY SEQ#U 508020001221