Loading...
13-96 (2)-10814. CONTRACTOR SHALL KEEP ALL AREAS IN WHICH WORK IS BEING PERFORMED, FREE FROM DEBRIS AT ALL TIMES AND SAID AREAS SHALL BE LEFT BROOM CLEAN AT THE END OF EACH WORKING DAY. 15. CONTRACTOR SHUT PAY FOR ALL PERMITS. FEES. INSPECTIONS. AND TESTING COSTS. 16. COORDINATE ALL ELECTRICAL SITE WORK WITH ALL OTHER TRADES CONTRACTORS. 17. IT SHALL BE THE RESPONSIBILITY OF THE ELECTRICAL CONTRACTOR FOR THE ADVANCE ORDERING OF LONG LEAD ITEMS. AS TO NOT INTERFERE WITH THE PRODUCTION OF OTHER TRADES RESULTING IN ANY DOWN OR LAG TIME THE CONTRACTOR SHALL NOT ORDER ANY ITEMS UNTIL APPROVED SHOP DRAWINGS ARE RETURNED TO HIM. 18. ELECTRICAL CONTRACTOR SHALL SUBMIT (6 COPIES) EQUIPMENT LAYOUT OF ALL ELECTRICAL SPACES. ROOMS, ETC., TO ENGINEER FOR APPROVAL PRIOR TO ORDERING EQUIPMENT OR INSTALLING CONDUITS. ETU. LAYOUT SHALL CONSIST OF PLAN VIEWS (SCALED AS REQUIRED) AND ELEVATKONS (DIMENSIONED) FOR EACH SUCH SPACE. ROOM. ETC. 19. CONTRACTOR SHALL SUBMIT AT ONE TIME. SIX (6) SETS OF LOOSE -LEAF BOUND BOOKS. INDEXED WITH ALL PRODUCTS. MATERIALS, LIGHTING FIXTURES, LAMPS, WIRING DEVICES, SWT CHIGEAR. ETC. CLEARLY HIGHLIGHTING ALL EQUIPMENT QUANTITIES AND DETAILS. ALL EQUIPMENT SHALL BE AS SPECIFIED ON PLANS: THE RESPONSIBILITY TO ACCEPT OR REJECT ANY PROPOSED SUBSTITUTION REMAINS WITH THE PROJECT ENGINEER. THE CONTRACTOR MAY AT HIS JUDGMENT USE ANY /ARTICLE. DEVICE. PRODUCT, OR MATERIAL WHICH IN THE JUDGMENT OF THE ENGINEER EXPRESSED IN WRITING ARE EQUAL TO THAT SPECIFIED. 20. ALL CONDUCTORS SHALL BE COPPER, TYPE THHN/THWN EXCEPT WHERE OTHERWISE REQUIRED BY U.L OR CODES. MINIMUM WIRE SIZE SHALL BE #12 AWG, EXCLUDING CONTROL WIRING. ALUMINUM CONDUCTORS ARE NOT PERMITTED. 21. ALL CONDUCTORS SHALL BE IN CONDUITS. ALL CONDUITS SHALL BE GALVANIZED RIGID STEEL (GRS) EXCEPT THAT: (a) PVC CONDUITS MAY BE USED UNDERGROUND PROVIDED ELBOWS AND RISERS ARE GALVANIZED RIGID STEEL OR SCHEDULE 80 PVC, WHERE SUBJECT TO PHYSICAL DAMAGE (b) ELECTRICAL METALLIC TUBING (EMT) MAY BE USED IN OR ON WALLS OR CEILINGS WHERE NOT SUBJECT TO MECHANICAL DAMAGE, DAMP OR CORROSIVE CONDITIONS. (C) LIQUID 71GHT FLEXIBLE CONDUIT WHERE REQUIRED. (d) FLEXIBLE METALLIC CONDUIT WHERE REQUIRED IN DRY LOCATIONS ONLY. (e) MC CABLE WITH DEDICATED GREEN GROUNDING CONDUCTOR WHERE PERMITTED. ALL CONDUITS IN HAZARDOUS AREAS (PER NEC) SHALL MEET THE REQUIREMENTS OF NEC CHAPTER 5. 22. FOR UNDERGROUND ELECTRICAL CONDUITS, PROVIDE PULL BOXES. SUCH THAT NO SINGLE CONDUIT RUN HAS BENDS IN EXCESS OF 360. PULL BOXES SHALL BE SUITABLE AND APPROVED FOR THE INTENDED USE WARNING TAPE WHICH SAYS 'WARNING BURIED ELECTRIC' SHALL BE PLACED IN TRENCHES ABOVE ALL UNDERGROUND ELECTRIC CONDUITS. WHERE CONDUITS PASS UNDERNEATH PAVED AREAS. THEY SHALL BE PVC. WHERE UNDERGROUND CONDUITS ARE NOT EXPOSED TO MECHANICAL DAMAGE OR ARE NOT UNDER PAVED AREAS, THEY SHALL BE SCHEDULE 40 PVC. 23. ALL CONDUIT RUNS ARE SHOWN DIAGRAMMATIC. EXACT ROUTING SHALL BE DETERMINED IN THE FIELD, UNLESS OTHERWISE NOTED. 24. WIREWAYS SHALL BE SIZED AS REQUIRED, PER NEC. UNLESS OTHERWISE NOTED (LION). 25. WHERE CORE DRILLING OF FLOOR/WALLS IS REQUIRED. CONTRACTOR SHALL SEAL OPENINGS WATERTIGHT AFTER UTILITIES HAVE BEEN INSTALLED. LOCATION OF CORED HOLES SHALL COORDINATE WITH LOCATION OF EQUIPMENT IN A MANNER TO BE CLEAN AND FUNCTIONAL THE CONTRACTOR SHALL INSTALL ONLY ONE CONDUIT PER HOLE AND SEAL THE OPENING AROUND THE CONDUIT AS SPECIFIED. 28. PROVIDE FIRE RETARDANT U.L APPROVED SEALANT ON ALL PENEMA71ONS OF FIRE RATED PARTITIONS. WALLS AND STRUCTURAL SLABS. CONTRACTOR TO VERIFY. PRIOR TO SUBMITTING BID, LOCATIONS OF ALL SUCH FIE RATED PARTITIONS. WALL AND STRUCTURAL SLABS. 27. UNLESS NOTED AS EXISTING, ALL EQUIPMENT. WIRING, DEVICES. ETC. SHALL BE NEW. 41. A. WORKING CLEARANCES FOR ELECTRICAL EQUIPMENT SWILL BE IN COMPLIANCE WITH NEC 110.28 B. THE EXCLUSIVELY DEDICATED SPACE EXTENDING FROM FLOOR TO STRUCTURAL CEILING WITH A WIDTH AND DEPTH OF THE PANELBOARD OR SWITCHBOARD MUST BE CLEAR OF ALL PIPING. DUCTS, EQUIPMENT FOREIGN TO THE ELECTRICAL EQUIPMENT OR ARCHITECTURAL APPURTENANCES IN ACCORDANCE WITH NEC 408. 42. METER CANS. HUBS. & LUGS FOR SAME ARE TO BE FURNISHED & INSTALLED BY CONTRACTOR. CONTRACTOR TO VERIFY SPECIFIC TYPE OF METER CAN TO BE USED WITH F.P.L. PRIOR TO BID. 43. A. PROVIDE A PERMANENT SIGN ON THE MAIN ELECTRICAL ROOM DOOR TO THE BLDG. STATING THAT THE SERVICE DISCONNECTS ARE LOCATED INSIDE B. SIGNS SHALL BE PLACED AT THE MAIN DISCONNECT EQUIPMENT INDICATING TYPE AND LOCATION OF ON -SITE EMERGENCY POWER SOURCES. 44. THE EQUIPMENT GROUNDING TERMINAL BARS OF THE NORMAL. AND EMERGENCY ELECTRICAL SYSTEM PANELBOARDS SERVING THE SAME BUILDING SHALL BE BONDED TOGETHER WITH AN INSULATED. CONTINUOUS, COPPER CONDUCTOR NOT SMALLER THAN NUMBER 6. 45. THE ELECTRICAL. CONTRACTOR SHALL FURNISH A COMPLETE SET OF AS -BUILT DRAWINGS. SHOWING ALL CHANGES AND DEVIATIONS TO THE ARCHITECT /ENGINEER PRIOR TO COMPLETION OF THE PROJECT. 48. ARCHITECTURAL AND OR ENGINEERING EXPENSES THAT ARE INCURRED DUE TO REVISIONS OR SU NS REQUESTED BY THE CONTRACTOR SHALL BE PAID FOR BY THAT CONTRACTOR. 47. FOR TELEPHONE SYSTEMS: A. PROVIDE GROUNDING FOR ALL TELEPHONE OUTLETS AND EQUIPMENT PER REQUIREMENTS OF THE TELEPHONE COMPANY. B. COORDINATE INSTALLATION OF ALL TELEPHONE OUTLETS. RACEWAYS. ENCLOSURES AND BACKBOARDS WITH TELL CO. C. VERIFY LOCATION OF TELEPHONE SERVICE WITH TELEPHONE COMPANY. PROVIDE SERVICE CONDUIT TO BLDG. FROM SERVICE POINT PER TELCO. INSTRUCTIONS, INCLUDE ALL ASSOCIATED COSTS IN BID. D. MARK TERMINATIONS OF TELEPHONE CONDUIT AS DIRECTED BY THE TELEPHONE COMPANY. E VERIFY LOCATION OF TELEPHONE SERVICE WITH TELEPHONE COMPANY PRIOR TO SUBMITTING BID, INCLUDE ALL ASSOCIATED COSTS IN BID. F. USE EXTERIOR GRADE 3/4' PLYWOOD BACKBOARDS FOR MOUNTING TELEPHONE EQUIPMENT AND TERMINAL STRIPS. PAINT BOARD ON ALL SIDES AND EDGES WITH TWO COATS OF FLAT BLACK FIRE RETARDANT PAINT. 48. INDUSTRIAL CONTROL TYPE TRANSFORMERS SHALL BE PROVIDED WITH FlNGERSAFE COVERS AND PRIMARY FUSE PROTECTION AS REQUIRED PER NEC 450 -3. MOUNT TRANSFORMERS ON 40X4' JUNCTION BOX ABOVE ACCESSIBLE CEILINGS OR ELECTRICAL ROOMS. 49. FOR RESIDENTIAL WORK PROVIDE COMBINATION TYPE ARC -FAULT CIRCUIT INTERRUPTER PROTECTION THROUGHOUT THE DWELLING UNIT, EXCEPT IN KITCHEN BATHROOM, GARAGES AND OUTDOORS. ALL DWELLING UNIT RECEPTACLE OUTLETS MUST BE LISTED TAMPER- RESISTANT. 50. PROVIDE U.L LISTED COMPOUND APPLIED TO BACK OF 'BACK TO BACK' BOXES IN RATED WALLS WHERE THE BOXES ARE LESS THAN 609.6MM (24 INCHES) APART MEASURED HORIZONTALLY. 51. CONTRACTOR SHUT PROVIDE TYPED - WRITTEN. UPDATED PANEL DIRECTORIES ON ALL PANELS THAT ARE /AFFECTED AT THE COMPLETION OF THE JOB. 52. FOR RECEPTACLES IN DAMP AND WET LOCATIONS THE CONTRACTOR SWILL PROVIDE ALL 125V. AND 250V.. 151. AND 20A. RECEPTACLES THAT ARE LISTED AS WEATHER RESISTANT TYPE TO MUPLY WRTFI We ARM F LIRA_ GENERAL LIGHTING NOTES: 1. REFER TO ARCHITECTURAL REFLECTED CEILING PUN FOR EXACT LOCATION OF LIGHT FIXTURES. 2. COORDINATE TYPE OF CEILING FOR EACH FIXTURE WITH ARCHITECTURAL REFLECTED CEILING PLANS AND PROVIDE FIXTURE TRIM AS REQUIRED. 3. ALL COMPACT FLUORESCENT DOWNLIGHTS SHALL USE LAMPS WITH 35WK TEMPERATURE. MINIMUM 10.000 HOUR LIFE: ELECTRONIC BALLAST. UNLESS OTHERWISE NOTED. 4. PROVIDE APPROVED FIRE RATED ENCLOSURES FOR ALL LIGHT FIXTURES LOCATED IN FIRE RATED CEILINGS. 5. FIXTURES IN AREAS WITHOUT CEILINGS. OR IN MECHANICAL. AND ELECTRICAL ROOMS SHALL BE MOUNTED WITH 1 7¢'X1 X"KINDOIRF CHANNEL SUPPORT SUSPENDED FROM ROOF STRUCTURE WITH THREAD RODS. FIXTURES SHALL BE MOUNTED 10' -0' A.F.F. S. ALL ACRYLIC LENSED FIXTURES SHALL HAVE A LENS THICKNESS OF .125 INCHES MINIMUM. 7. HALF SHADED FIXTURES DENOTE EMERGENCY FIXTURES EITHER WITH 1100 LUMEN EMERGENCY BATTERY PACK OR ON LIFE SAFETY CIRCUIT. S. LIGHTING FIXTURE SCHEDULE IS PREDICTED ON PERFORMANCE AND IS DESIGNED TO MEET CERTAIN AESTHETIC CRITERIA. ALL ALTERNATIVE SELECTIONS MUST BE SUBMITTED FOR PRIOR APPROVAL TEN (10) DAYS PRIOR TO BID DATE 9. ALL BALLASTS SHALL HAVE MINIMUM POWER FACTOR OF 0.90. ALL BALLASTS FOR METAL HALIDE AND HIGH PRESSURE SODIUM FIXTURES SHALL BE CONSTANT WATTAGE TYPE WITH + / -5X LAMP WATTS FOR + / -IOX NOMINAL LINE VOLTAGE VARIATION. 10. PROVIDE LAMPS WITH FIXTURES, VERIFY LAMP TYPE WITH MANUFACTURER. 11. FLUORESCENT LUMINAIRES THAT UTILIZE DOUBLE -ENDED LAMPS AND CONTAIN BALLAST(S) OR MULTIWARE BALLASTED LUMINAIRES SWILL CONTAIN AN INTEGRATED INTERNAL DISCONNECT AND TO BE COMPLIED WITH NEC 410.130(G). 12. ALL OPENINGS FOR LIGHT FIXTURES IN CEILINGS SHALL BE PROTECTED IN A MANNER (PER ALL GOVERNING CODES) THAT WILL PROVIDE THE SAME RATING AS THE CEILING. (THIS APPLIES TO ALL FIE RATED CEILINGS). 13. FOR EMERGENCY EXIT SKIS AND EMERGENCY BATTERY PACKS MAKE CONNECTION AHEAD OF ALL SWITCHES AND CONTROLS. 14. PROVIDE A FUSE HOLDER AND FUSE (BUSSMAN HEB AND FNQ OR EQUAL). IN THE PRIMARY SIDE OF EACH UNGROUNDED CONDUCTOR FOR ALL BALLASTS AT THE HAND HOLE OF EACH EXTERIOR POLE MOUNTED LIGHTING FIXTURE OR J -BOX FOR WALL OR GROUND MOUNTED FIXTURE 15. PROVIDE WIND LOAD RATED LIGHT POLES WITH 145 MPH MINIMUM WIND SPEED (ASCE EXPOSURE C WITH IMPORTANCE FACTOR OF I.O. AND PROVIDE PHOTOMETRICS WITH FIXTURE SUBMITTALS. CONTRACTOR TO VERIFY VOLTAGES OF ALL LIGHT FIXTURES PRIOR TO BIDDING. I& PHOTOMETRICS ARE BASED ON MANUFACTURER'S INFORMATION AND CATALOG NUMBERS. ALTERNATIVE MANUFACTURERS MUST PROVIDE THE IESNA FORMAT ELECTRONIC FILES OF THE INDEPENDENT TEST LAB REPORTS FOR THE PROPOSED FIXTURES ON CD OR FLOPPY DISKETTE 10 WORKING DAYS PRIOR TO BID. (SPECIFIER) WILL CONFIRM THAT THE PHOTOMETRIC CRITERIA HAS BEEN MET. AND IF ALTERNATE IS APPROVED WILL ISSUE AN ADDENDUM. MANUFACTURERS NOT LISTED ON THE PLANS OR IN AN ADDENDUM WILL NOT BE ACCEPTED. 17 TO CONFIRM THAT THE SPECIFIED PHOTOMETRIC CRITERIA HAS BEEN MET, A COMPUTER DISK CONTAINING AN IES FILE FOR THE PROPOSED ALTERNATE MUST BE SUBMITTED TO (SPECIFIER) FOR EVALUATION NO LESS THAT 10 DAYS PRIOR TO BID. ANY ACCEPTABLE ALTERNATE MUST BE APPROVED IN WRITING PRIOR TO BID DATE 18. CONTRACTOR MUST BID PROJECT USING SPECIFIED LIGHTING FIXTURES AS BASE BID (NO EXCEPTK)NS). IF ALTERNATE FIXTURES ARE PROPOSED, THEY MUST BE BID AS AN ALTERNATE BID MUST INCLUDE- A) TOTAL DOLLAR CREDIT TO OWNER IF ALTERNATE IS ACCEPTED. B LINE ITEM CREDIT FOR EACH ALTERNATE FIXTURE PROPOSED. C) CATALOG SUBMITTAL DATA FOR EACH ALTERNATE FIXTURE PROPOSED. 19. IF THERE IS A DISCREPANCY BETWEEN A FIXTURE DESCRIPTION AND GENERAL NOTES. AND THE CATALOG NUMBER LISTED, THE FIXTURE DESCRIPTION AND GENERAL NOTES SAW. GOVERN. 20. COORDINATE FIXTURE TYPES WITH ARCHITECTURAL DRAWINGS. ELECTRICAL SYMBOL LEGEND GENERAL ELECTRICAL NOTES DESCRIPTION (GENERAL NOTES ARE PROVIDED AS A BASIC DESCRIPTION OF THE EXTENT AND QUALITY EXPECTED IN THIS PROJECT. IF A CONFLICT EXISTS LIGHTING (REFER TO LiG ITING FIXTURE SCHEDULE) I BETWEEN THESE GENERAL NOTES AND THE REMAINDER OF THE CONTRACT DOCUMENTS THE SPECIFICATIONS. PLANS AND DETAILS WILL GOVERN.) 1. THE ENTIRE IMALLAlION SWILL BE N ACCOROANM WITH THE FOLLOWING CODES OF THE LIGHT FIXTURE RURE WITH ' SUFFIX DESIGNATION INDICATES EMERGENCY EC BATTERY BACK -UP FOR A MINIMUM OF 90 MINUTES. NATIONAL FIRE PROTECTION ASSOCIATION 28. ALL CIRCUIT BREAKERS SHALL BE INVERSE TIME TYPE (THERMAL MAGNETIC OR SOLID LIGHTING FIXTURE (HID. FLUORESCENT OR INCANDESCENT). RECESSED MTD. A WFA 70' NATIONAL ELECTRICAL CODE (2006 EDITION) LIGHTING FIXTURE, WALL MOUNTED STATE AS REQUIRED BY SPECIFICATION). TWO AND THREE POLE CIRCUIT BREAKERS EXIT LIGHT FIXTURE DIRECTION ARROWS AS SHOWN EL NFPA 72: NATIONAL FIRE ALARM CODE (2007 EOITDO MOUNTED EXIT LIGHT FIXTURE SHALL BE COMMON TRIP. NO TIE HANDLES PERMITTED. (SHADED QUADRANT INDICATES FACE(S) OF FIXTURE) N ADDITION, THE DISTALLA70 Stall ALSO BE N ACCORDANCE WITH THE FOLLOWIM 29. ALL FUSES SHALL BE CURRENT LIMITING. PER U.L. RATED 60OV., LION. A. NON -TIME DELAY FUSES IN MAIN SWITCHES AND SWITCHES FEEDING PANELS. 2 X 4 FLUORESCENT LIGHT FIXTURE C. 2010 FLORIDA BULDWG 000E 1/2 SHADED FIXTURE INDICATES FIXTURE TO BE PROVIDED WITH 90 MINUTE 1100 LUMEN BATTERY BACK -UP FOR LINEAR FLUORESCENT FIXTURES AND 700 LUMEN B. TIME DELAY FUSES FOR MOTOR AND A/C CIRCUITS. BATTERY BACK -UP FOR COMPACT FLUORESCENT FIXTURES. D. FIARIDA FIRE PREVENTION CODE (2007 EDITION) 30. ALL DISCONNECT SWITCHES SHALL BE SIZED BY NEC REQUIREMENTS TO ACCOMMODATE 2. AS A MINIMUM, ALL EQUIPMENT SHALL MEET APPLICABLE STANDARDS. FOR THE TYPE OF FLUORESCENT STRIP FIXTURE EQUIPMENT SERVED. INCLUDING REQUIRED FUSES U.O.N. SNITCHES SHALL BE DIAGONAL SHADING DENOTES LIGHT FIXTURE CONNECTED TO EMERGENCY EQUIPMENT AND INTENDED USE. OF THE FOLLOWING: BRANCH CIRCUIT OR. W /EMERG. BATTERY PACK. HORSEPOWER RATED FOR MAX. HORSEPOWER. HEAVY DUTY TYPE EXTERIOR LIGHT FIXTURE WITH ARMS AS SHOWN ON DRAWINGS A. AMERICAN NATIONAL STANDARDS INSTITUTE (ANSI) 31. CONTRACTOR SHALL VERIFY CIRCUIT PROTECTIVE DEVICE RATING FOR EQUIPMENT PRIOR TOGGLE SWITCH 120/277V. 20 AMP. ,(M.H. - 48' A.F.F.) , 3 -WAY B. ILLUMINATING ENGINEERS SOCIETY (TES) TOGGLE SWITCH 120/277V. 20 AMP.. (M.H. - 48' A.F.F.). 4 -WAY TO INSTALLATION. TOGGLE SWITCH 120/277V. 20 AMP. KEYSWITCH, (M.H. - 48- A.F.F.) C. AMERICAN SOCIETY FOR TESTING AND MATERIALS (ASTM) 32. FURNISH AND INSTALL DISCONNECT SWITCHES AND WIRING FOR AIR CONDITIONING 30- MINUTE ROTATABLE TIMER SWITCH (M.H. - 48' A.F.F.) D. NATIONAL ELECTRICAL MANUFACTURER'S ASSOCIATES.(NEMA) TOGGLE SWITCH 120/277V. 20 AMP., WITH PILOT LIGHT, SYSTEM AS PER MANUFACTURER RECOMMENDATIONS CONTROLS ARE TO BE SUPPLIED (M.H.- 48'A.F.F.) E NOTE THESE STANDARDS ARE SUBORDINATE TO CODES AND STANDARDS SET BY U.L 7V TOGGLE SWITCH 120/27. 20 AMP. EXPLOSION- PROOF, BY AIR CONDITIONING CONTRACTOR AND CONNECTED. PROVIDE ALL CONTROL WIRING FOR (M.H.- 48- A.F.F.) ALL ELECTRICAL EQUIPMENT. DEVICES. WIRE. ETC., SHALL BE LISTED, FOR INTENDED USE, WITH UNDERWRITER'S LABORATORIES INC. (U.L). WHERE STANDARDS HAVE BEEN SPEED SWITCH 120/277V. 20 AMP. U.O.N. .(M.H. - 48- A.F.F.) A/C SENSORING AND CONTROL UNITS, COORDINATE WITH A/C CONTRACTOR FOR WIRING SINGLE PHASE MANUAL MOTOR STARTER. (M.H. -48' A.F.F.) ESTABLISHED BY U.L DIMMER SWATCH 120/277V. 20 AMP.. (M.H. -48- A.F.F.) (1500 WATTS NAGRAMS AND EXACT MOUNTING LOCATIONS. 3. CONTRACTOR TO PROVIDE ALL LABOR, MATERIALS AND SUPERVISION NECESSARY TO 33. ALL ELECTRICAL EQUIPMENT SHALL BE RAINT1GHR WHERE EXPOSED TO THE WEATHER. ALL FLEX CONDUITS CONNECTED TO SUCH EQUIPMENT SHALL BE LIQUID TIGHT. S I SWITCH (48' A.F.F.) (SUBSCRIPT INDICATES ITEM ACCOMPLISH THE WORK AS SHOWN AND /OR NOTED ON THE DRAWINGS. ) 0 PANIC SWITCH. MUSHROOM TYPE. (M.H. -48' A.F.F.) a.b 34, EQUIPMENT SHALL BE OF MATERIALS SUITABLE FOR AND NEMA RATED FOR THE 4. THE CONTRACTOR SHALL VISIT THE JOB SITE AND VERIFY ALL CONDITIONS, LOCATIONS, (a. b) OR (2) INDICATES TWO POLE SWITCH - WSD- PDT -2P ENVIRONMENT IN WHICH THEY ARE TO BE INSTALLED. D INDICATES DIMMABLE DIMENSIONS AND COUNTS AS SHOWN OR NOTED ON THE DRAWINGS, PRIOR TO 35. ALL CONNECTIONS TO GROUND RODS SHALL BE MADE WITH U.L APPROVED WELDED MFGR./MODEL# (SENSOR SWITCH /#CM -PDT) SUBMITTING BID. CEILING MOUNTED DUAL TECHNOLOGY EXTENDED RANGE OCCUPANCY CONNECTIONS, UNLESS NOTED OTHERWISE THE CONTRACTOR SHALL. FORM A 5. IT SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR TO PROVIDE ALL LABOR. WALL MOUNTED - OCCUPANCY SENSOR (M.H. -967A.F.F.) GROUNDING ELECTRODE SYSTEM AS PER NEC 25D -50. MFGR. /MODEL#WN -PDT MATERIALS AND SUPERVISION NECESSARY TO ACCOMPLISH THE WORK AS SHOWN MID /OR NOTED ON THE PLANS. 3a, OUTLET IN DRY LOCATIONS BOXES SWILL BE PRESSED STEE=L. IN WET OR DAMP SECURRY SYSTEM KNOX BOX NOTE SOME SYMBOLS SHOWN ON THIS LEGEND MAY NOT PERTAIN TO THIS PROJECT ABBREVIATIONS LOCATIONS SHALL BE CAST ALLOY WEATHER - RESISTANT OUTLET WITH THREADED HUBS 6. ELECTRICAL CONTRACTOR SHALL NOT SCALE DRAWINGS. CONTRACTOR SHALL REFER TO REFER CALL EXISTING AND IN OTHER CLASSIFIED AREAS IT SHALL BE IN A SPECIAL ENCLOSURE PROPER PLASTER RINGS SWILL BE USED WITH OUTLET BOXES. PROPER COORDINATION BETWEEN IT IS THE SOLE RESPONSIBILITY OF THE CONTRACTOR TO PROVIDE TALL ARCHITECTURAL PUNS AND ELEVATIONS FOR EXACT LOCATIONS UNLESS NOTED OTHERWISE EXISTING RELOCATED I ELECTRICAL SUBCONTRACTOR AND GENERAL CONTRACTOR FOR PLASTER RING INITIATION ABOVE FINISHED FLOOR G.F.I. SYSTEM IN ACCORDANCE WITH THE PLANS. DETAILS. INTENT OF THE DILL BE REQUIRED. NO "GOOF' RINGS SHALL BE ALLOWED. ALL OUTLET BOXES SHALL 7. IT SHALL BE UNDERSTOOD THAT ALL WORK PERFORMED SHALL BE DONE BY A LICENSED LOCKABLE COVER BE SECURELY FASTENED. BELOW FINISHED CEILING CONTRACTOR AND IN A FIRST -CLASS WORKMANLIKE MANNER. SAID CONTRACTOR SHALL 37, WHEN N EILECTRICAL 80XES ARE LOCATED IN VERTICAL FIE RESISTIVE ASSEMBLIES, TO OR DESIGNATED AS EMERGENCY BY THE LETTER "F'. INCASE OF EMERGENCY MEET ALL REQUIREMENTS SET FORTH BY ANY LOCAL ORDINANCE AND GOVERNING POWER, THE RECEPTACLES SHALL BE HOSPITAL GRADE AND HAVE THE COLOR (CLASSIFIED AS FIRE /SMOKE AND SMOKE PARTITIONS), THEY SHALL BE INSTALLED RED. THE COVERPLATE SHALL BE RED AND ENGRAVED WITH 1 /4" HIGH LETTERS AUTHORITIES. AND SHOWN IN WHITE ON RED. (NO EVGRAVING REQUIRED FOR NORMAL POWER). WITHOUT AFFECTING THE FIRE CLASSIFICATION. ALL OF THE FOLLOWING CONDITIONS 8. THE CONTRACTOR SHALL PROVIDE ALL REQUIRED INSURANCE FOR PROTECTION AGAINST E - DENOTES EMERGENCY POWER CONNECTION. HOSPITAL GRADE RED WITH SHALL BE MET: RED COVIUMATE ENGRAVED WITH WHITE CIRCUIT NUMBER. PUBLIC LABILITY AND PROPERTY DAMAGE FOR THE DURATION OF THE WORK FLOOR OUTLET BOX AND DUPLEX RECEPTACLE 20 AMP., 125V.. WITH A. ALL ELECTRICAL BOXES SHUT BE METALLIC. 9. CONTRACTOR SHUT GUARANTEE ALL MATERIALS AND WORKMANSHIP FREE FROM DEFECTS CEILING OUTLET BOX AND DUPLEX RECEPTACLE 2011. 125V. B. BOX OPENING SHALL OCCUR ONLY ON ONE SIDE OF FRAMING SPACE. DUPLEX RECEPTACLE. 20 AMP., 125V., TOP HALF SWITCHED. M.H. - FOR A PERIOD OF NOT LESS THAN ONE YEAR FROM DATE OF ACCEPTANCE, UNLESS 18- A.F.F. UNLESS OTHERWISE NOTED C. BOX OPENING SHALL NOT EXCEED 10322.58 SQUARE MM (16SQUARE INCHES). DUPLEX RECEPTACLE. 20 AMP.. 125V.. ISOLATED GROUND AND SURGE INDICATED OR SPECIFIED OTHERWISE PROTECTED. (M.H. -18- A.F.F.) D. ALL CLEARANCES BETWEEN OUTLET BOX AND GYPSUM BOARD SHWl BE 10. T SHALL NOT BE THE INTENT OF THESE PLANS MID /OR SPECIFICATIONS TO SHOW EQUIPMENT. COMPLETELY FILLED WITH JOINT COMPOUND (OR OTHER APPROVED MATERAL). E PROVIDE A WALL AROUND OUTLETS LARGER THAT 10322.56 SQUARE MM (16 SIMPLEX RECEPTACLE (16- A.F.F.) (EWC DENOTES ELECTRIC WATER EVERY MINOR DETAIL OF CONSTRUCTION. THE CONTRACTOR SHALL BE EXPECTED TO COOLER. COORDINATE WITH EWC INSTALLER FOR MOUNTING HEIGHT) SQUARE INCHES). THE INTEGRITY OF THE WALL RATING SHALL BE MAINTAINED. TWO DUPLEX RECEPTACLES WITH COMMON COVER 20A., 125V.,(18- FURNISH AND INSTALL ALL TEMS FOR A COMPLETE ELECTRICAL SYSTEM AND PROVIDE A.F.F.) ® T SPECIAL PURPOSE OUTLET e.g. RANGE OUTLET, COORD. W/ EQUIPT. FOR ALL REQUIREMENTS NECESSARY FOR EQUIPMENT TO BE PLACED IN PROPER DUPLEX RECEPTACLE. 20 AMP., 125V., MOUNT /ABOVE COUNTER 0440AFF. F. THE TOTAL AGGREGATE SURFACE AREA OF THE BOXES SHALL NOT EXCEED 64516 OR +42' AFF FOR EXAM ROOMS (REFER TO ARCHITECURAL DRAWINGS AND WORKING ORDER. ELEVATIONS FOR EXACT MOUNTING HEIGHT, ORIENTATION AND LOCATIONS. INCHES) METERS (100 SQUARE GFCI DUPLEX RECEPTACLE. 20 AMP.. 125V., (M.H.-18-A.F.F.) WP. GFCI DUPLEX RECEPTACLE. 20 AMP.. 125V., MID. ABOVE COUNTER OR OUTLET LOCATED ONOPPOSITE SIDES OF FIE RESISTIVE ASSEMBUES SHALL 11. THE CONTRACTOR SHALL BE RESPONSIBLE FOR REPAIRING TO ORIGINAL CONDITIONS. TWO DUPLEX GFCI RECEPTACLES WITH COMMON COVER 20A.. 125V.. BE SEPARATED BY A MINIMUM HORIZONTAL DISTANCE OF 609.5MM (24 INCHES). MID. ABOVE COUNTER OR MOUNTED HIGH. VERIFY HEIGHT BEFORE ANY AND ALL DAMAGES TO BUILDING SURFACES, EQUIPMENT, ETC. CAUSED DURING THE ROUGH IN. H. OUTLET BOXES SHALL BE SECURELY FASTENED TO WALL FRAMING MEMBERS. 30 AMP., 125V.. TWIST LOCK RECEPTACLE FOR FLOOR POLISHING MACHINE PERFORMANCE OF WORK. JUNCTION BOX. MOUNTING AS SHOWN I. THE OPENING IN THE GYPSUM BOARD FACING SHALL BE CUT NOT TO EXCEED 12. CORRECTION OF ANY DEFECTS SHALL BE COMPLETED WITHOUT ADDITIONAL CHARGE OR 3.175MM (1/8 INCH) BETWEEN THE EDGES OF THE OUTLET BOX AND THE EDGES OF ELECTRIC MOTOR. NUMBER INDICATES HORSEPOWER DELAYS AND SHALL INCLUDE REPLACEMENT OR REPAIR OF ANY OTHER PHASE OF THE MAGNETIC MOTOR STARTER OR CONTACTOR, THE OPENING. COMBINATION MAGNETIC MOTOR STARTER, SIZE AS NOTED INSTALLATION WHICH MAY HAVE BEEN DAMAGED THEREBY. 38. SMOKE DETECTORS SHALL BE PROVIDED NO CLOSER THAN 36' FROM SUPPLY AIR 13. FOR ELECTRIC POWER SYSTEM, COORDINATE POWER SERVICE WITH POWER COMPANY; AMP RATING /FRAME NEMA 3R- FOR EXTERIOR DIFFUSERS. NEMA 1- FOR INTERIOR A. VERIFY LOCATION OF POWER SERVICE TERMINATION WITH POWER COMPANY, PRIOR 39. CONTRACTOR SWILL PROVIDE A TYPE WRITTEN DIRECTORY OF EACH PANELBOARD. HAND LIGHTING CONTROL TIME CLOCK TO SUBMITTING BID. CONTRACTOR TO VERIFY AVAILABLE SERVICE VOLTAGE AND PHASES PHOTOCELL. MOUNTED ON ROOF FACING NORTH WRITTEN DIRECTORY IS NOT ACCEPTABLE. EXCEPT SPARE AND SPACES SHALL BE SHUNT -TRIP BUTTON - FLUSH MOUNTED UNLESS OTHERWISE NOTED WITH POWER COMPANY PRIOR M BID AND PROVIDE BD ALLOWANCE FOR ALTERNATES. PLUG -IN STRIP WITH RECEPTACLES. 18' O.C. UNLESS OTHERWISE INDICATED HANDWRITTEN IN PENCIL CABLE TRAY (ROUTING TO BE COORDINATED WITH ALL TRADES) B. PROVIDE TEMPORARY ELECTRICAL SERVICE FOR USE BY ALL TRADES DURING GROUND OR GROUND ROD AS NOTED 0 CONDUIT TURNING UP CONSTRUCTION AND REMOVE SAME AT COMPLETION OF PROJECT, 40. PRIDE A OV 4' STEEL REINFORCED CONCRETE HOUSEKEEPING PAD UNDER ALL FLOOR _ _ _ _ 14. CONTRACTOR SHALL KEEP ALL AREAS IN WHICH WORK IS BEING PERFORMED, FREE FROM DEBRIS AT ALL TIMES AND SAID AREAS SHALL BE LEFT BROOM CLEAN AT THE END OF EACH WORKING DAY. 15. CONTRACTOR SHUT PAY FOR ALL PERMITS. FEES. INSPECTIONS. AND TESTING COSTS. 16. COORDINATE ALL ELECTRICAL SITE WORK WITH ALL OTHER TRADES CONTRACTORS. 17. IT SHALL BE THE RESPONSIBILITY OF THE ELECTRICAL CONTRACTOR FOR THE ADVANCE ORDERING OF LONG LEAD ITEMS. AS TO NOT INTERFERE WITH THE PRODUCTION OF OTHER TRADES RESULTING IN ANY DOWN OR LAG TIME THE CONTRACTOR SHALL NOT ORDER ANY ITEMS UNTIL APPROVED SHOP DRAWINGS ARE RETURNED TO HIM. 18. ELECTRICAL CONTRACTOR SHALL SUBMIT (6 COPIES) EQUIPMENT LAYOUT OF ALL ELECTRICAL SPACES. ROOMS, ETC., TO ENGINEER FOR APPROVAL PRIOR TO ORDERING EQUIPMENT OR INSTALLING CONDUITS. ETU. LAYOUT SHALL CONSIST OF PLAN VIEWS (SCALED AS REQUIRED) AND ELEVATKONS (DIMENSIONED) FOR EACH SUCH SPACE. ROOM. ETC. 19. CONTRACTOR SHALL SUBMIT AT ONE TIME. SIX (6) SETS OF LOOSE -LEAF BOUND BOOKS. INDEXED WITH ALL PRODUCTS. MATERIALS, LIGHTING FIXTURES, LAMPS, WIRING DEVICES, SWT CHIGEAR. ETC. CLEARLY HIGHLIGHTING ALL EQUIPMENT QUANTITIES AND DETAILS. ALL EQUIPMENT SHALL BE AS SPECIFIED ON PLANS: THE RESPONSIBILITY TO ACCEPT OR REJECT ANY PROPOSED SUBSTITUTION REMAINS WITH THE PROJECT ENGINEER. THE CONTRACTOR MAY AT HIS JUDGMENT USE ANY /ARTICLE. DEVICE. PRODUCT, OR MATERIAL WHICH IN THE JUDGMENT OF THE ENGINEER EXPRESSED IN WRITING ARE EQUAL TO THAT SPECIFIED. 20. ALL CONDUCTORS SHALL BE COPPER, TYPE THHN/THWN EXCEPT WHERE OTHERWISE REQUIRED BY U.L OR CODES. MINIMUM WIRE SIZE SHALL BE #12 AWG, EXCLUDING CONTROL WIRING. ALUMINUM CONDUCTORS ARE NOT PERMITTED. 21. ALL CONDUCTORS SHALL BE IN CONDUITS. ALL CONDUITS SHALL BE GALVANIZED RIGID STEEL (GRS) EXCEPT THAT: (a) PVC CONDUITS MAY BE USED UNDERGROUND PROVIDED ELBOWS AND RISERS ARE GALVANIZED RIGID STEEL OR SCHEDULE 80 PVC, WHERE SUBJECT TO PHYSICAL DAMAGE (b) ELECTRICAL METALLIC TUBING (EMT) MAY BE USED IN OR ON WALLS OR CEILINGS WHERE NOT SUBJECT TO MECHANICAL DAMAGE, DAMP OR CORROSIVE CONDITIONS. (C) LIQUID 71GHT FLEXIBLE CONDUIT WHERE REQUIRED. (d) FLEXIBLE METALLIC CONDUIT WHERE REQUIRED IN DRY LOCATIONS ONLY. (e) MC CABLE WITH DEDICATED GREEN GROUNDING CONDUCTOR WHERE PERMITTED. ALL CONDUITS IN HAZARDOUS AREAS (PER NEC) SHALL MEET THE REQUIREMENTS OF NEC CHAPTER 5. 22. FOR UNDERGROUND ELECTRICAL CONDUITS, PROVIDE PULL BOXES. SUCH THAT NO SINGLE CONDUIT RUN HAS BENDS IN EXCESS OF 360. PULL BOXES SHALL BE SUITABLE AND APPROVED FOR THE INTENDED USE WARNING TAPE WHICH SAYS 'WARNING BURIED ELECTRIC' SHALL BE PLACED IN TRENCHES ABOVE ALL UNDERGROUND ELECTRIC CONDUITS. WHERE CONDUITS PASS UNDERNEATH PAVED AREAS. THEY SHALL BE PVC. WHERE UNDERGROUND CONDUITS ARE NOT EXPOSED TO MECHANICAL DAMAGE OR ARE NOT UNDER PAVED AREAS, THEY SHALL BE SCHEDULE 40 PVC. 23. ALL CONDUIT RUNS ARE SHOWN DIAGRAMMATIC. EXACT ROUTING SHALL BE DETERMINED IN THE FIELD, UNLESS OTHERWISE NOTED. 24. WIREWAYS SHALL BE SIZED AS REQUIRED, PER NEC. UNLESS OTHERWISE NOTED (LION). 25. WHERE CORE DRILLING OF FLOOR/WALLS IS REQUIRED. CONTRACTOR SHALL SEAL OPENINGS WATERTIGHT AFTER UTILITIES HAVE BEEN INSTALLED. LOCATION OF CORED HOLES SHALL COORDINATE WITH LOCATION OF EQUIPMENT IN A MANNER TO BE CLEAN AND FUNCTIONAL THE CONTRACTOR SHALL INSTALL ONLY ONE CONDUIT PER HOLE AND SEAL THE OPENING AROUND THE CONDUIT AS SPECIFIED. 28. PROVIDE FIRE RETARDANT U.L APPROVED SEALANT ON ALL PENEMA71ONS OF FIRE RATED PARTITIONS. WALLS AND STRUCTURAL SLABS. CONTRACTOR TO VERIFY. PRIOR TO SUBMITTING BID, LOCATIONS OF ALL SUCH FIE RATED PARTITIONS. WALL AND STRUCTURAL SLABS. 27. UNLESS NOTED AS EXISTING, ALL EQUIPMENT. WIRING, DEVICES. ETC. SHALL BE NEW. 41. A. WORKING CLEARANCES FOR ELECTRICAL EQUIPMENT SWILL BE IN COMPLIANCE WITH NEC 110.28 B. THE EXCLUSIVELY DEDICATED SPACE EXTENDING FROM FLOOR TO STRUCTURAL CEILING WITH A WIDTH AND DEPTH OF THE PANELBOARD OR SWITCHBOARD MUST BE CLEAR OF ALL PIPING. DUCTS, EQUIPMENT FOREIGN TO THE ELECTRICAL EQUIPMENT OR ARCHITECTURAL APPURTENANCES IN ACCORDANCE WITH NEC 408. 42. METER CANS. HUBS. & LUGS FOR SAME ARE TO BE FURNISHED & INSTALLED BY CONTRACTOR. CONTRACTOR TO VERIFY SPECIFIC TYPE OF METER CAN TO BE USED WITH F.P.L. PRIOR TO BID. 43. A. PROVIDE A PERMANENT SIGN ON THE MAIN ELECTRICAL ROOM DOOR TO THE BLDG. STATING THAT THE SERVICE DISCONNECTS ARE LOCATED INSIDE B. SIGNS SHALL BE PLACED AT THE MAIN DISCONNECT EQUIPMENT INDICATING TYPE AND LOCATION OF ON -SITE EMERGENCY POWER SOURCES. 44. THE EQUIPMENT GROUNDING TERMINAL BARS OF THE NORMAL. AND EMERGENCY ELECTRICAL SYSTEM PANELBOARDS SERVING THE SAME BUILDING SHALL BE BONDED TOGETHER WITH AN INSULATED. CONTINUOUS, COPPER CONDUCTOR NOT SMALLER THAN NUMBER 6. 45. THE ELECTRICAL. CONTRACTOR SHALL FURNISH A COMPLETE SET OF AS -BUILT DRAWINGS. SHOWING ALL CHANGES AND DEVIATIONS TO THE ARCHITECT /ENGINEER PRIOR TO COMPLETION OF THE PROJECT. 48. ARCHITECTURAL AND OR ENGINEERING EXPENSES THAT ARE INCURRED DUE TO REVISIONS OR SU NS REQUESTED BY THE CONTRACTOR SHALL BE PAID FOR BY THAT CONTRACTOR. 47. FOR TELEPHONE SYSTEMS: A. PROVIDE GROUNDING FOR ALL TELEPHONE OUTLETS AND EQUIPMENT PER REQUIREMENTS OF THE TELEPHONE COMPANY. B. COORDINATE INSTALLATION OF ALL TELEPHONE OUTLETS. RACEWAYS. ENCLOSURES AND BACKBOARDS WITH TELL CO. C. VERIFY LOCATION OF TELEPHONE SERVICE WITH TELEPHONE COMPANY. PROVIDE SERVICE CONDUIT TO BLDG. FROM SERVICE POINT PER TELCO. INSTRUCTIONS, INCLUDE ALL ASSOCIATED COSTS IN BID. D. MARK TERMINATIONS OF TELEPHONE CONDUIT AS DIRECTED BY THE TELEPHONE COMPANY. E VERIFY LOCATION OF TELEPHONE SERVICE WITH TELEPHONE COMPANY PRIOR TO SUBMITTING BID, INCLUDE ALL ASSOCIATED COSTS IN BID. F. USE EXTERIOR GRADE 3/4' PLYWOOD BACKBOARDS FOR MOUNTING TELEPHONE EQUIPMENT AND TERMINAL STRIPS. PAINT BOARD ON ALL SIDES AND EDGES WITH TWO COATS OF FLAT BLACK FIRE RETARDANT PAINT. 48. INDUSTRIAL CONTROL TYPE TRANSFORMERS SHALL BE PROVIDED WITH FlNGERSAFE COVERS AND PRIMARY FUSE PROTECTION AS REQUIRED PER NEC 450 -3. MOUNT TRANSFORMERS ON 40X4' JUNCTION BOX ABOVE ACCESSIBLE CEILINGS OR ELECTRICAL ROOMS. 49. FOR RESIDENTIAL WORK PROVIDE COMBINATION TYPE ARC -FAULT CIRCUIT INTERRUPTER PROTECTION THROUGHOUT THE DWELLING UNIT, EXCEPT IN KITCHEN BATHROOM, GARAGES AND OUTDOORS. ALL DWELLING UNIT RECEPTACLE OUTLETS MUST BE LISTED TAMPER- RESISTANT. 50. PROVIDE U.L LISTED COMPOUND APPLIED TO BACK OF 'BACK TO BACK' BOXES IN RATED WALLS WHERE THE BOXES ARE LESS THAN 609.6MM (24 INCHES) APART MEASURED HORIZONTALLY. 51. CONTRACTOR SHUT PROVIDE TYPED - WRITTEN. UPDATED PANEL DIRECTORIES ON ALL PANELS THAT ARE /AFFECTED AT THE COMPLETION OF THE JOB. 52. FOR RECEPTACLES IN DAMP AND WET LOCATIONS THE CONTRACTOR SWILL PROVIDE ALL 125V. AND 250V.. 151. AND 20A. RECEPTACLES THAT ARE LISTED AS WEATHER RESISTANT TYPE TO MUPLY WRTFI We ARM F LIRA_ GENERAL LIGHTING NOTES: 1. REFER TO ARCHITECTURAL REFLECTED CEILING PUN FOR EXACT LOCATION OF LIGHT FIXTURES. 2. COORDINATE TYPE OF CEILING FOR EACH FIXTURE WITH ARCHITECTURAL REFLECTED CEILING PLANS AND PROVIDE FIXTURE TRIM AS REQUIRED. 3. ALL COMPACT FLUORESCENT DOWNLIGHTS SHALL USE LAMPS WITH 35WK TEMPERATURE. MINIMUM 10.000 HOUR LIFE: ELECTRONIC BALLAST. UNLESS OTHERWISE NOTED. 4. PROVIDE APPROVED FIRE RATED ENCLOSURES FOR ALL LIGHT FIXTURES LOCATED IN FIRE RATED CEILINGS. 5. FIXTURES IN AREAS WITHOUT CEILINGS. OR IN MECHANICAL. AND ELECTRICAL ROOMS SHALL BE MOUNTED WITH 1 7¢'X1 X"KINDOIRF CHANNEL SUPPORT SUSPENDED FROM ROOF STRUCTURE WITH THREAD RODS. FIXTURES SHALL BE MOUNTED 10' -0' A.F.F. S. ALL ACRYLIC LENSED FIXTURES SHALL HAVE A LENS THICKNESS OF .125 INCHES MINIMUM. 7. HALF SHADED FIXTURES DENOTE EMERGENCY FIXTURES EITHER WITH 1100 LUMEN EMERGENCY BATTERY PACK OR ON LIFE SAFETY CIRCUIT. S. LIGHTING FIXTURE SCHEDULE IS PREDICTED ON PERFORMANCE AND IS DESIGNED TO MEET CERTAIN AESTHETIC CRITERIA. ALL ALTERNATIVE SELECTIONS MUST BE SUBMITTED FOR PRIOR APPROVAL TEN (10) DAYS PRIOR TO BID DATE 9. ALL BALLASTS SHALL HAVE MINIMUM POWER FACTOR OF 0.90. ALL BALLASTS FOR METAL HALIDE AND HIGH PRESSURE SODIUM FIXTURES SHALL BE CONSTANT WATTAGE TYPE WITH + / -5X LAMP WATTS FOR + / -IOX NOMINAL LINE VOLTAGE VARIATION. 10. PROVIDE LAMPS WITH FIXTURES, VERIFY LAMP TYPE WITH MANUFACTURER. 11. FLUORESCENT LUMINAIRES THAT UTILIZE DOUBLE -ENDED LAMPS AND CONTAIN BALLAST(S) OR MULTIWARE BALLASTED LUMINAIRES SWILL CONTAIN AN INTEGRATED INTERNAL DISCONNECT AND TO BE COMPLIED WITH NEC 410.130(G). 12. ALL OPENINGS FOR LIGHT FIXTURES IN CEILINGS SHALL BE PROTECTED IN A MANNER (PER ALL GOVERNING CODES) THAT WILL PROVIDE THE SAME RATING AS THE CEILING. (THIS APPLIES TO ALL FIE RATED CEILINGS). 13. FOR EMERGENCY EXIT SKIS AND EMERGENCY BATTERY PACKS MAKE CONNECTION AHEAD OF ALL SWITCHES AND CONTROLS. 14. PROVIDE A FUSE HOLDER AND FUSE (BUSSMAN HEB AND FNQ OR EQUAL). IN THE PRIMARY SIDE OF EACH UNGROUNDED CONDUCTOR FOR ALL BALLASTS AT THE HAND HOLE OF EACH EXTERIOR POLE MOUNTED LIGHTING FIXTURE OR J -BOX FOR WALL OR GROUND MOUNTED FIXTURE 15. PROVIDE WIND LOAD RATED LIGHT POLES WITH 145 MPH MINIMUM WIND SPEED (ASCE EXPOSURE C WITH IMPORTANCE FACTOR OF I.O. AND PROVIDE PHOTOMETRICS WITH FIXTURE SUBMITTALS. CONTRACTOR TO VERIFY VOLTAGES OF ALL LIGHT FIXTURES PRIOR TO BIDDING. I& PHOTOMETRICS ARE BASED ON MANUFACTURER'S INFORMATION AND CATALOG NUMBERS. ALTERNATIVE MANUFACTURERS MUST PROVIDE THE IESNA FORMAT ELECTRONIC FILES OF THE INDEPENDENT TEST LAB REPORTS FOR THE PROPOSED FIXTURES ON CD OR FLOPPY DISKETTE 10 WORKING DAYS PRIOR TO BID. (SPECIFIER) WILL CONFIRM THAT THE PHOTOMETRIC CRITERIA HAS BEEN MET. AND IF ALTERNATE IS APPROVED WILL ISSUE AN ADDENDUM. MANUFACTURERS NOT LISTED ON THE PLANS OR IN AN ADDENDUM WILL NOT BE ACCEPTED. 17 TO CONFIRM THAT THE SPECIFIED PHOTOMETRIC CRITERIA HAS BEEN MET, A COMPUTER DISK CONTAINING AN IES FILE FOR THE PROPOSED ALTERNATE MUST BE SUBMITTED TO (SPECIFIER) FOR EVALUATION NO LESS THAT 10 DAYS PRIOR TO BID. ANY ACCEPTABLE ALTERNATE MUST BE APPROVED IN WRITING PRIOR TO BID DATE 18. CONTRACTOR MUST BID PROJECT USING SPECIFIED LIGHTING FIXTURES AS BASE BID (NO EXCEPTK)NS). IF ALTERNATE FIXTURES ARE PROPOSED, THEY MUST BE BID AS AN ALTERNATE BID MUST INCLUDE- A) TOTAL DOLLAR CREDIT TO OWNER IF ALTERNATE IS ACCEPTED. B LINE ITEM CREDIT FOR EACH ALTERNATE FIXTURE PROPOSED. C) CATALOG SUBMITTAL DATA FOR EACH ALTERNATE FIXTURE PROPOSED. 19. IF THERE IS A DISCREPANCY BETWEEN A FIXTURE DESCRIPTION AND GENERAL NOTES. AND THE CATALOG NUMBER LISTED, THE FIXTURE DESCRIPTION AND GENERAL NOTES SAW. GOVERN. 20. COORDINATE FIXTURE TYPES WITH ARCHITECTURAL DRAWINGS. ELECTRICAL SYMBOL LEGEND SYMBOL DESCRIPTION Ee LIGHTING (REFER TO LiG ITING FIXTURE SCHEDULE) I A LIGHT FIXTURE DESIGNATION. AE LIGHT FIXTURE RURE WITH ' SUFFIX DESIGNATION INDICATES EMERGENCY EC BATTERY BACK -UP FOR A MINIMUM OF 90 MINUTES. 0 LIGHTING FIXTURE, SURFACE MOUNTED O LIGHTING FIXTURE (HID. FLUORESCENT OR INCANDESCENT). RECESSED MTD. O LIGHTING FIXTURE, WALL MOUNTED O EXIT LIGHT FIXTURE DIRECTION ARROWS AS SHOWN (®WALL MOUNTED EXIT LIGHT FIXTURE _� (SHADED QUADRANT INDICATES FACE(S) OF FIXTURE) E� LL_ 2 X 2 FLUORESCENT LIGHT FIXTURE ® 2 X 4 FLUORESCENT LIGHT FIXTURE ® 1/2 SHADED FIXTURE INDICATES FIXTURE TO BE PROVIDED WITH 90 MINUTE 1100 LUMEN BATTERY BACK -UP FOR LINEAR FLUORESCENT FIXTURES AND 700 LUMEN [r] BATTERY BACK -UP FOR COMPACT FLUORESCENT FIXTURES. ® 1 X 4 FLUORESCENT LIGHT FIXTURE - - - - - - - - FLUORESCENT WALL MOUNTED FIXTURE WITH WALL OUTLET BOX I-o--i FLUORESCENT STRIP FIXTURE I 0 DIAGONAL SHADING DENOTES LIGHT FIXTURE CONNECTED TO EMERGENCY ® BRANCH CIRCUIT OR. W /EMERG. BATTERY PACK. 0-0-0 EXTERIOR LIGHT FIXTURE WITH ARMS AS SHOWN ON DRAWINGS $ TOGGLE SWITCH 120/277V. 20 AMP,(M.H. - 48' A.F.F.) $3 TOGGLE SWITCH 120/277V. 20 AMP. ,(M.H. - 48' A.F.F.) , 3 -WAY $4 TOGGLE SWITCH 120/277V. 20 AMP.. (M.H. - 48' A.F.F.). 4 -WAY $ K TOGGLE SWITCH 120/277V. 20 AMP. KEYSWITCH, (M.H. - 48- A.F.F.) $F FAN SWITCH 120/277V. 20 AMP. (HORSEPOWER RATED) $T 30- MINUTE ROTATABLE TIMER SWITCH (M.H. - 48' A.F.F.) $ TOGGLE SWITCH 120/277V. 20 AMP., WITH PILOT LIGHT, P (M.H.- 48'A.F.F.) Ex 7V TOGGLE SWITCH 120/27. 20 AMP. EXPLOSION- PROOF, 12 (M.H.- 48- A.F.F.) $S SPEED SWITCH 120/277V. 20 AMP. U.O.N. .(M.H. - 48- A.F.F.) $ M SINGLE PHASE MANUAL MOTOR STARTER. (M.H. -48' A.F.F.) D DIMMER SWATCH 120/277V. 20 AMP.. (M.H. -48- A.F.F.) (1500 WATTS ® UNLESS INDICATED) $3D THREE -WAY DIMMER ER SSWITCH (48' A.F.F.) $ a S I SWITCH (48' A.F.F.) (SUBSCRIPT INDICATES ITEM E4 ) 0 PANIC SWITCH. MUSHROOM TYPE. (M.H. -48' A.F.F.) a.b WALL MOUNTED - OCCUPANCY SENSOR SWTCH,(M.H.- 481A.F.F.) MFGR./MO is SENSOR SWITCH /#WSD -PDT (a. b) OR (2) INDICATES TWO POLE SWITCH - WSD- PDT -2P O D INDICATES DIMMABLE OS CEILING MOUNTED OCCUPANCY SENSOR - LIGHTING CIRCUIT CONTROLLER. • .n' MFGR./MODEL# (SENSOR SWITCH /#CM -PDT) OSE CEILING MOUNTED DUAL TECHNOLOGY EXTENDED RANGE OCCUPANCY SENSOR - LK*MNG CIRCUIT CONTROLLER. SENSOR SWITCH / #CM- PDT -10. El WALL MOUNTED - OCCUPANCY SENSOR (M.H. -967A.F.F.) E4.3 LIGHT FIXTURE SCHEDULE MFGR. /MODEL#WN -PDT PP POWER PACK OCCUPANCY SENSOR NOTE CONTRACTOR SHALL PROVIDE ALL SWITCHPACKS AND CONDUCTORS AS SECURRY SYSTEM KNOX BOX NOTE SOME SYMBOLS SHOWN ON THIS LEGEND MAY NOT PERTAIN TO THIS PROJECT ABBREVIATIONS REQUIRED FOR LAYOUTS AND CONTROLS SHOWN ON PLANS. ABOVE COUNTER EX EXISTING A.F. IT IS THE SOLE RESPONSIBILITY OF THE CONTRACTOR TO PROVIDE ER EXISTING RELOCATED I AND INSTALL A COMPLETE AND FULLY FUNCTIONAL. LIGHTING CONTROL ABOVE FINISHED FLOOR G.F.I. SYSTEM IN ACCORDANCE WITH THE PLANS. DETAILS. INTENT OF THE A.S.W. ABOVE SHOW WINDOW RCPT. DESIGN AND SPECIFICATIONS SHOWN ON THESE PLANS. LOCKABLE COVER BASIC MATERIALS BELOW FINISHED CEILING M.H. ALL RECEPTACLES TO BE COMMERCIAL GRADE EXCEPT FOR THOSE CONNECTED B.F.G TO OR DESIGNATED AS EMERGENCY BY THE LETTER "F'. INCASE OF EMERGENCY N POWER, THE RECEPTACLES SHALL BE HOSPITAL GRADE AND HAVE THE COLOR C.B. RED. THE COVERPLATE SHALL BE RED AND ENGRAVED WITH 1 /4" HIGH LETTERS N.F. AND SHOWN IN WHITE ON RED. (NO EVGRAVING REQUIRED FOR NORMAL POWER). E COMMERCIAL GRADE DUPLEX RECEPTACLE. 20 AMP.. 125V.. (M.H.- 180A.F.F.) 1T E - DENOTES EMERGENCY POWER CONNECTION. HOSPITAL GRADE RED WITH D RED COVIUMATE ENGRAVED WITH WHITE CIRCUIT NUMBER. ® FLOOR OUTLET BOX AND DUPLEX RECEPTACLE 20 AMP., 125V.. WITH APPROPRIATE FLANGE. irmh ( CEILING OUTLET BOX AND DUPLEX RECEPTACLE 2011. 125V. 9 DUPLEX RECEPTACLE. 20 AMP., 125V., TOP HALF SWITCHED. M.H. - T.C. 18- A.F.F. UNLESS OTHERWISE NOTED If DUPLEX RECEPTACLE. 20 AMP.. 125V.. ISOLATED GROUND AND SURGE T.S. PROTECTED. (M.H. -18- A.F.F.) q) SINGLE RECEPTACLE. 20 AMP., 125V., COORDINATE M.H. WITH TT EQUIPMENT. `YEWC SIMPLEX RECEPTACLE (16- A.F.F.) (EWC DENOTES ELECTRIC WATER U.O.N. COOLER. COORDINATE WITH EWC INSTALLER FOR MOUNTING HEIGHT) It TWO DUPLEX RECEPTACLES WITH COMMON COVER 20A., 125V.,(18- A.F.F.) ® T SPECIAL PURPOSE OUTLET e.g. RANGE OUTLET, COORD. W/ EQUIPT. Ah. DUPLEX RECEPTACLE. 20 AMP., 125V., MOUNT /ABOVE COUNTER 0440AFF. OR +42' AFF FOR EXAM ROOMS (REFER TO ARCHITECURAL DRAWINGS AND XFMR. ELEVATIONS FOR EXACT MOUNTING HEIGHT, ORIENTATION AND LOCATIONS. GFCI DUPLEX RECEPTACLE. 20 AMP.. 125V., (M.H.-18-A.F.F.) WP. GFCI DUPLEX RECEPTACLE. 20 AMP.. 125V., MID. ABOVE COUNTER OR RR MOUNTED HIGH. VERIFY HEIGHT BEFORE ROUGH IN. . TWO DUPLEX GFCI RECEPTACLES WITH COMMON COVER 20A.. 125V.. MID. ABOVE COUNTER OR MOUNTED HIGH. VERIFY HEIGHT BEFORE - ( - ROUGH IN. 0 30 AMP., 125V.. TWIST LOCK RECEPTACLE FOR FLOOR POLISHING MACHINE Q JUNCTION BOX. MOUNTING AS SHOWN I[] POWER POLE � , ' ELECTRIC MOTOR. NUMBER INDICATES HORSEPOWER ® MAGNETIC MOTOR STARTER OR CONTACTOR, COMBINATION MAGNETIC MOTOR STARTER, SIZE AS NOTED DISCONNECT SWITCH. SIZE AS NOTED OF POLES ENCLOSURE TYPE: AMP RATING /FRAME NEMA 3R- FOR EXTERIOR D 3;Q NEMA 1- FOR INTERIOR FUSE SIZE ( * DENOTES AS PER MANUFACTURER) LIGHTING CONTROL TIME CLOCK ® PHOTOCELL. MOUNTED ON ROOF FACING NORTH Q SHUNT -TRIP BUTTON - FLUSH MOUNTED UNLESS OTHERWISE NOTED ® PLUG -IN STRIP WITH RECEPTACLES. 18' O.C. UNLESS OTHERWISE INDICATED ® CABLE TRAY (ROUTING TO BE COORDINATED WITH ALL TRADES) +- GROUND OR GROUND ROD AS NOTED 0 CONDUIT TURNING UP -0 CONDUIT TURNING DOWN CONDUIT STUB -� CONDUIT CONTINUED NOTE: SOME SYMBOLS SHOWN ON THIS LEGEND MAY NOT PERTAIN TO THIS PROJECT. SYSTEMS SYMBOL LEGEND SYMBOL DESCRIPTION Ee CALL BACK PUSH BUTTON m CIRCUIT BREAKER, TYPE AND SIZE AS PER DRAWINGS 2 SECURITY SYSTEM KEYPAD EC CLOCK El BELL 1lI %1.% ° Cr Q 0 O AIR HANDUNG UNIT SHUT -DOWN RELAY O POWER ON INDICATOR WITH KEYED RESET SERVICE AND DISTRIBUTION _� ELECTRK'.AL BRANCH CIRCUIT PANELBOARD, RECESS MOUNTED. E� LL_ (SEE PANEL SCHEDULE FOR DETAILS) O •�__ ELECTRICAL BRANCH CIRCUIT PANELBOARD. SURFACE MOUNTED. E2.3 THIRD FLOOR PLAN NEW CONSTRUCTION ELECTRICAL PLAN (SEE PANEL SCHEDULE FOR DETAILS) [r] TRANSFORMER, SIZE AS NOTED OEM AUTOMATIC TRANSFER SWITCH - - - - - - - - EXISTING EQUIPMENT TO REMAIN U-) NEW EQUIPMENT OR WORK OF THIS PROJECT E3.1 a PARTIAL FIRST FLOOR NEW CONSTRUCTION POWER PLAN TELEPHONE /COMPUTER RACEWAY SYSTEM ® TELEPHONE /COMPUTER TERMINAL BOARD 'TTB- © SECURITY CAMERA J -BOX PROVIDE CONNECTION TO SECURITY POWER SUPPLY AND VIDEO SUPPLY. SO INTERCOM SYSTEM SPEAKER N COMPUTER/TELEPHONE OUTLET WITH (2) 8- CONDUCTOR RJ -45 JACKS IN A 4X4 GANG BOX WITH 2X4 MUD RING MOUNTED AT 10 18' A.F.F. PROVIDE 1- CONDUIT STUBBED 6' ABOVE ACCESSIBLE CEILING SPACE C - ABOVE THE COUNTER (VERIFY WITH ARCH DRAWINGS) E3.1 s PARTIAL FIRST FLOOR NEW CONSTRUCTION LIGHTING PLAN W - WALL MOUNTED (48' A.F.F. /VERIFY WITH ARCH DWG) TV - COMBINATION RECESSED AND DATA RECEPTACLE 12 WALL BOX FOR CONNECTION TO TV USING CLOSED CIRCUIT DATA CABLE MOUNTING HEIGHT IS +720 A.F.F UNLESS OTHERWISE NOTED. ® DATIA/TELEPHONE PORT - CEILING MOUNTED ® DATA/TELEPHONE PORT - FLOOR MOUNTED 14 SPECIALTY DEVICES - SYSTEMS Q EMERGENCY PULLSTRING BOX E4 EMERGENCY SOUNDER /STROBE LIGHT. Q-•i NURSE GALL DOME LIGHT SECURITY SYSTEM is SECURITY SYSTEM CAMERA. PROVIDE POWER AND SIGNAL CONNECTION. SEE SPECS. O SECURITY SYSTEM MONITORS AND RECORDERS, SEE SPECS. 0 SECURITY SYSTEM CARD READER. SEE SPECS • .n' SECURITY SYSTEM GABLES IN CONDUIT. SEE SPECS. vS SECURITY SYSTEM JUNCTION BOX AT ACCESSIBLE LOCATION. SECURITY SYSTEM HIDDEN PUSH BUTTON FOR DOOR STRIKE El RELEASE. COORDINATE INSTALLATION WITH FURNITURE OR E4.3 LIGHT FIXTURE SCHEDULE EQUIPMENT. ® SECURITY SYSTEM SPEAKER WITH INTEGRAL MICROPHONE ❑Ka SECURRY SYSTEM KNOX BOX NOTE SOME SYMBOLS SHOWN ON THIS LEGEND MAY NOT PERTAIN TO THIS PROJECT ABBREVIATIONS A.C. ABOVE COUNTER EX EXISTING A.F. ARC FAULT I ER EXISTING RELOCATED I A.F.F. ABOVE FINISHED FLOOR G.F.I. GROUND FAULT INTERRUPTER A.S.W. ABOVE SHOW WINDOW RCPT. LC. LOCKABLE COVER B.F.C. BELOW FINISHED CEILING M.H. MOUNTING HEIGHT B.F.G BELOW FINISHED GRADE N NEW DEVICE C.B. CIRCUIT BREAKER I N.F. NON FUSED CL CENTER LINE NL NIGHT LIGHT D DEDICATED FOR COMPUTER, R EXISTING TO BE REMOVED PROVIDE DEDICATED GROUND AND NEUTRAL T.C. TERMINAL CABINET D ISOLATED GROUND (ORANGE T.S. TIME SWITCH DEVICE) U.O.N. UNLESS OTHERWISE NOTED EM PROVIDE EMERGENCY BATTERY PACK W /FIX TURE. WR. � WATER RESISTANCE TAC1E CONNECT AHEAD OF ALL SWITCHES XFMR. TRANSFORMER. WP. WEATHER PROOF ENCLOSSURE RR REMOVE AND RELOCATE DETAIL � - ( - SHEET NUMBER NOTE: SOME SYMBOLS SHOWN ON THIS LEGEND MAY NOT PERTAIN TO THIS P MM- MULTNWIRE BRANCH CIRCUITS REQUIRE DISCONNECTING MEANS AS PER NEC 219.4d 11.Qg: RECEP'M IN ALL EXAM ROOMS AND TREATMENT ROOMS ARE TO BE HOSPITAL QUALITY WITH REDUNDANT GROUND SYSTEM AS MANDATED BY N.E.C. 517, LOW VOLTAGE SYSTEM NOTES 1. WORKSTATION DATA CABLES TO BE CATEGORY 8 AND PLENUM RATED. 2. WIRES. BACK BOXES. AND DEVICES FOR TELEPHONE/DATA OUTLETS ARE PROVIDED BY CONTRACTOR - COORDINATE EXACT REQUIREMENTS WITH OWNER'S IT VENDOR. SERVER EQUIPMENT TO BE PROVIDED BY OWNER. 3. WIRES, BACK BOXES. AND DEVICES FOR TV OUTLETS ARE PROVIDED BY CONTRACTOR. TV EQUIPMENT TO BE PROVIDED BY OWNER /COMCAST. 4. PAGING SYSTEM IS NOT IN SCOPE OF WORK 5. NURSE CALL SYSTEM WITH PULL CORD STATIONS AND DOME LIGHTS ARE NOT IN SCOPE OF WORK I I I I I ELECTRICAL INDEX CERT. NO. AAP000034 /CA3806 a 1B26000797/LC26000381 m 1 E1.1 ELECTRICAL INDEX. SYMBOL LEGEND AND NOTES. . DELTA . @'' ' ' dd TING EN 1 707: NC11. = lr, ERD - `.. . 27- ' - Ijfj00 81 1 • - �- PJT. MGR: )BC 'H00 .. PROJECT UA: 12 717 A • 5 •,x'40 2 E2.0 SITE PLAN NEW CONSTRUCTION ELECTRICAL PLAN 1lI %1.% ° Cr Q 0 4Z 3 E2.1 FIRST FLOOR PLAN NEW CONSTRUCTION ELECTRICAL PUN z 4 O 4 E2.2 SECOND FLOOR PLAN NEW CONSTRUCTION ELECTRICAL. PLAN E� LL_ av� O •�__ 5 E2.3 THIRD FLOOR PLAN NEW CONSTRUCTION ELECTRICAL PLAN Lo :E Q T 6 E2.4 FOURTH FLOOR PLAN NEW CONSTRUCTION ELECTRICAL PLAN U-) 7 E3.1 a PARTIAL FIRST FLOOR NEW CONSTRUCTION POWER PLAN O IS 8 1 E3.1 b PARTIAL FIRST FLOOR NEW CONSTRUCTION POWER PLAN 9 E3.1 c PARTIAL FIRST FLOOR NEW CONSTRUCTION POWER PLAN 10 E3.1d PARTIAL FRST FLOOR NEW CONSTRUCTION LIGHTING PLAN 11 E3.1 s PARTIAL FIRST FLOOR NEW CONSTRUCTION LIGHTING PLAN 12 E3.4o PARTIAL FOURTH FLOOR ENLARGED POWER PLAN 13 E3.4b PARTIAL FOURTH FLOOR ENLARGED POWER PLAN 14 E3.4c PARTIAL FOURTH FLOOR ENLARGED LIGHTING PLAN 15 E3.4d PARTIAL FOURTH FLOOR ENLARGED LIGHTING PLAN is E3.5 ROOF LEVEL PLAN NEW CONSTRUCTION ELECTRICAL PLAN 17 E4.1 ELECTRICAL RISER DIAGRAM 18 E4.2 ELECTRICAL PANELS 19 E4.3 LIGHT FIXTURE SCHEDULE 21 PH2.1 FIRST FLOOR PLAN - GARAGE PHOTOMETRICS PLAN 22 PH2.2 SECOND FLOOR PLAN - GARAGE PHOTOMETRICS PLAN 23 1 PH2.3 THIRD FLOOR PLAN - GARAGE PHOTOMETRICS PLAN 24 PH2.4 FOURTH FLOOR PLAN - PARKING PHOTOMETRICS PLAN SHOP DRAWING REQUIREMENTS I. CONTRACTOR SHALL SUBMIT B COPIES OF COMPLETED SHOP DRAWINGS, TOGETHER AT ONE TIME AND MUST COME THROUGH THE ARCHITECT. ALL SUBMITTALS SHALL BE MADE WITHIN 30 DAYS OF NOTICE TO PROCEED. 2. ALL SUBMITTALS MUST CLEARLY INDICATE EXACTLY WHICH ITEMS ARE BEING PROPOSED FOR USE IF NOT, THE SUBMITTAL SHALL BE REJECTED. 3• SUBSTITUTIONS SHALL BE LIMITED TO ONE OF THE ALTERNATES LISTED IN THE CONSTRUCTION DOCUMENTS. PRODUCTS CONSIDERED TO BE EQUAL SHALL BE REVIEWED AND ACCEPTED BY THE ENGINEER, ARCHITECT AND OWNER (10) DAYS PRIOR TO BID DATE 4. THE CONTRACTOR ASSUMES ALL DESIGN RESPONSIBILITY AND ALL FINANCIAL RISKS FOR PROCEEDING PRIOR TO SHOP DRAWINGS PROCESSING, AND ON ANY REM OR WORK THAT IS AT VARIANCE TO THE CONSTRUCTION DOCUMENTS. 5. SHOP DRAWINGS AND SUBMITTALS FOR EACH ITEM SHALL BE REVIEWED NO MORE THAN TWICE A THIRD SUBMITTAL ON AN ITEM MUST BE ACCOMPANIED BY A PURCHASE ORDER FROM THE CONTRACTOR OR IT SHALL BE REJECTED. 6. CIRCUMSTANCES NECESSITATING A REVISION TO THE PERMITTED DOCUMENTS NOT PROCESSED PRIOR TO INSTALLATION MAY NOT BE ACCEPTED. IF ACCEPTED IT MUST BE LEGIBLE. ACCURATE AND ACCOMPANIED BY A PURCHASE ORDER ORDER FROM THE CONTRACTOR. THE REVISION SHALL BE CHARGED TO THE CONTRACTOR AND DELIVERED TO HIM ON A C.O.D. BASIS. 7. SUBSTITUTIONS FROM THE BASE DESIGN OR VARIATIONS TO THE PERMITTED CONTRACT DOCUMENTS. WHETHER RESULTING FROM PROCESSED SHOP DRAWINGS OR NOT. THAT RESULT IN REQUIREMENTS IN LETTERS OF AUTHORIZATION AID /OR PERMIT CONTRACT DOCUMENT CHANGES MANDATED BY THE AUTHORITY HUIVING JURISDICTION DILL NOT BE MADE BY THIS OFFICE UNLESS ACCOMPANIED BY A PURCHASE ORDER FROM THE CONTRACTOR. AND RELEASED ON A C.O.D. BASIS. 8. CONTRACTOR SHALL SUBMIT 5 COPIES OF EQUIPMENT LAYOUIS OF ALL ELECTRICAL SPACES, ROOMS, ETC. TO THE ENGINEER FOR APPROVAL PRIOR TO ORDERING EQUIPMENT OR INSTALLING CONDUITS. ETC. THE LAYOUTS SWILL CONSIST OF PLAN VIEWS AT A SCALE OF 1/2- - 1'0' AND ELEVATIONS FOR EACH SUCH SPACE OR ROOM, ETC. NOTE: ALL MATERIALS USED IN CEILING SPACE SHALL BE PLENUM APPROVED TYPE. OF REQUIRED). ALL ELECTRICAL RECEPTACLES AND SWITCHES ARE TO BE LABELED MECHANICALLY WITH PANEL CIRCUIT NUMBER, ALL CONSTRUCTION SHALL COMPLY WITH THE FOLLOWING CODES AND STANDARDS: FLORIDA STATE FIE MARSHALL'S RULE 69A -3.012 FAC AND RULE CHAPTER 69A -60 FLORIDA ADMINISTRATIVE CODE (FAC) AND FLORIDA STATUTE SECTION 633.022. THE 2010 FLORIDA BUILDING CODE THE GUIDELINES FOR DESIGN D CONSTRUCTION OF HEALTH CAE FACILITIES (AIA GUDEUNES. FGI GUIDELINES. 2005 EDITIONS) THE NATIONAL FIE PROTECTION ASSOCIATION (NFPA) CODE 99 (2)05 EDITION) THE NATIONAL FIRE PROTECTION ASSOCIATION (NFPA) CODE 7 0 THE NATIONAL FIE PROTECTION ASSOCIATION NFPA) CODE 110 tZO5 =ON� THE NATIONAL FIE PROTECTION ASSOCIATION NFPA) CODE 72 (2X)7 EDITION THE NATIONAL FIE PROTECTION ASSOCIATION NFPA) CODE 780 (2)11 EDITION THE NATIONAL FIE PROTECTION ASSOCIATION (NFPA) CODE 101 (2109 EDITION) bm • ELECTRICAL SYMBOLS SHOWN ARE DIAGRAMATIC. • DO NOT SCALE PLANS. • COORDINATE EXACT LOCATIONS OF OUTLETS WITH FURNITURE COMPANY SHOP DRAWINGS • COORDINATE EXACT HEIGHT OF OUTLETS WITH ARCHITECTURAL INITRIOR ELEVATIONS AND CABINET SHOP DRAWINGS. DEMOLITION NOTES __�i L It shall be the responsiblilty of the contractor to rerove existhg equipment as required to accomptish new work. 2• When removing electrical equipment and systems, all prrautlons shall be taken 3 The contractor shall exercise care so that only that onstructlon hdkated or reasonably Lmplled to be removed shall be demoUshed 4. The contractor shall be responsible for the removal of all demoUtlon and constructbn debris generated from work. 5. The contractor shall coordhate all power Interruptlonswith owner. 6. Remove all miscellaneous fbctures and equlpment retalr*K Items to be Identified for salvage and storage at the drectlon of the owner 7. The contractor shall be re s�le f the r v l fall fluore n and HID ty� lnmp and proper dlsp0).al of sal lamps and shA rovlde ver sa 2 o amp sposal to the owner upon request. &I - - ____ ,AAM ­ I %' _�r '1041001 , - . ----------------- --- ______ 0 Design Services For The Built Environment N Atlanta Birmingham Cincinnati Columbus Dallas Fort Lauderdale Knoxville Jackson Jacksonville Louisville Memphis Nashville Richmond Tampa G R E S H A M SMITH AND P A R T N E R S 6030 Hollywood Blvd. Suite 210 Hollywood, Florida 33024 954.981.9100 FIRM'S FLORIDA CERT. NO. AAP000034 /CA3806 a 1B26000797/LC26000381 m a� C . DELTA . @'' ' ' dd TING EN 1 707: NC11. = lr, ERD - `.. . 27- ' - Ijfj00 81 1 • - �- PJT. MGR: )BC 'H00 .. PROJECT UA: 12 717 A • 5 •,x'40 •.. .', S TF} 200 - . , L. 33q0,X �; I W : U.1 '� O< : Zq O; L �� -* �-� , .' P v °e ,%, l>>))1 1lI %1.% ° (D No. - Date - Revision a Q03/15/13 3Q m a� C d4 I__ m LU M Lit ® .-Z Cr Q 0 4Z - z 4 O L /9 4) fi C E� LL_ av� O •�__ . Lo :E Q T M Q M H U-) CZ LL] O IS N GEORGE SANJUAN, P.E. FLORIDA LICENSE #46100 DATE: 03/29/13 REVISION No. - Date - Revision I i i City Comments Response 03/29/13 City Comments Respon Q03/15/13 3Q - -- - I--------- ELECTRICAL INDEX, SYMBOL LEGEND AND NOTES E1.1 FILE: PROJECT: 29080.00 DATE: 11/29/2012 23�