Loading...
7T H E C IT Y OF PLEASANT LI V ING CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM To : The Honorable Mayor & Members of the City Commission FROM: Steven Alexander, City Manager Agenda Item NO ':~ DATE: September 1, 2015 SUBJECT: A Resolution authorizing the City Manager to negotiate and enter into a contract with Coreland Construction Corp . for the construction of the Mango Terrace Neighborhood Traffic Calming Improvements. BACKGROUND : The project consists of the construction of eleven traffic calming speed tables within the Mango Terrace Neighborhood, as per plans developed by T. y. Lin International. This includes, but is not limited to, the furnishing of all labor, material, tools, equipment, machinery, disposal of all materials, superintendence and services necessary for the completion of the construction of the project. AMOUNT: ACCOUNT: The City received five bids in response to a solicitation . Below are the proposals received : Contractor Bid Price Florida Construction & Engineering $40,188.86 Coreland Construction $40,342.00 Maggolc, Inc. $65,679.00 H. A. Contracting Corp $111,941.88 Sanchez Arango $177,000.00 The two lowest bids have a difference of approximately $154 . Based on past experience in similar construction projects that included installing of traffic calming devices within the City of South Miami, Coreland Construction Corp is being recommended for the installation of the Mango Terrace Traffic Calming Improvements. Pursuant to further review, it was determined that Coreland Construction Corp. is a responsive and responsible bidder for this proposal. A contingency amount of $19 ,658 will be included over the proposal amount to address for unknown factors that may arise during the work . The total amount of the contract, including the contingency, will be $60,000. Amount not to exceed $60,000 The expenditure shall be charged $60,000 to Local Option Gas Trust Fund account number 112-1730-541-6210, which has a balance of $274,305 before this request was made. AnAcHMENTs: Resolution Bid Opening Report Coreland Construction Corp. Bid Contract RFP Intergovernmental Agreement with Miami Dade County t • , 1 RESOLUTION NO.: _____ _ 2 3 A Resolution authorizing the City Manager to negotiate and enter into a contract with 4 Coreland Construction Corp. for the construction of the Mango Terrace Neighborhood 5 Traffic Calming Improvements. 6 7 WHEREAS, the Mayor and City Commission wish to provide traffic calming 8 improvements to the area known as Mango Terrace, and 9 10 WHEREAS, pursuant to a competitive selection process in accordance with the City 11 Charter, it was determined that Coreland Construction Corp. submitted a bid in the amount of 12 $40,342 that was the most comprehensive and cost effective in its construction approach; and 13 14 WHEREAS, the City desires to provide a contingency of $19,658 over the bid amount for 15 unknown factors that may arise during the work; and 16 17 WHEREAS, the total expenditure, including the contingency amount, is not to exceed 18 $60,000; and 19 20 WHEREAS, the Mayor and City Commission desire to authorize the City Manager to 21 negotiate and enter into a contract with Coreland Construction Corp. for the construction of 22 the Mango Terrace Neighborhood Traffic Calming Improvements for a total amount not to 23 exceed $60,000 24 25 NOW, THEREFORE, BE IT RESOLVED BY THE MAYOR AND CITY COMMISSION OF THE CITY OF 26 SOUTH MIAMI, FLORIDA THAT: 27 28 Section 1: The City Manager is authorized to negotiate the price, terms and conditions 29 and to execute a contract with Coreland Construction Corp. for Mango Terrace Neighborhood 30 Traffic Calming Improvements for an amount not to exceed $40,342, and he is authorized to 31 expend up to $19,658 for unforeseen conditions. A copy of the approved form of contract is 32 attached and the City Manager may negotiate a lower price and more advantageous terms and 33 conditions if approved by the City Attorney. 34 35 Section 2: The expenditure shall be charged $60,000 to the Local Option Gas Trust Fund 36 account number 112-1730-541-6210, which has a balance of $274,305 before this request was 37 made. 38 39 Section 3: If any section clause, sentence, or phrase of this resolution is for any reason held 40 invalid or unconstitutional by a court of competent jurisdiction, the holding shall not affect the validity 41 ofthe remaining portions ofthis resolution. 42 43 44 45 46 47 48 49 50 51 52 53 54 55 56 Section 4. This resolution shall take effect immediately upon adoption. PASSED AND ADOPTED this ___ day of _____ -', 2015. ATTEST: CITY CLERK READ AND APPROVED AS TO FORM LANGUAGE, LEGAlITY AND EXECUTION THEREOF APPROVED: MAYOR COMMISSION VOTE: Mayor Stoddard Vice Mayor Harris Commissioner Welsh Commissioner Liebman Commissioner Edmond 57 CITY ATTORNEY 58 59 Mango Terrace Traffic Calming Speed Table Locations 7144 71'5 III '" '" '" J '---L-I--L-____ IL-__ -----') L 8 N8ET DR 8W 72ND 8T ~ c"r----1I---,------, 6970 6800 6880 7220 6900 6896 7722 7280 7250 7300 6795 7330 7335 7300 7350 8 741H::;T 7355 7400 6700 6790 7441 6871 .__L-------' 7440 ~ W f':J I t rs:f 7400 ~ !-----1 7401 6851 7420 7440 7441 - - 7500 6900 6870 7461 7520 7525 6881 7630 - - 7700 ;1, I-------{l ~ i i Ii ~ i ~ I ~ i ~ 6785 ~~~~1 ~8hW~7~T~H.~TE~R.-~~~L--~~ 1-----{ICl 7721 iil 0 :n~1 1 g !<l 8 N ~ ~I !<!b l :l g ~ ~ 7750 ~ f8 ~ !8 $11 f8 f8 $ ~ ~ <0 IfDF Jto t5 CD 7l3() 7741 t.n.-en,.... f-1-_--,-lt---,-l_~L~-+..1~+~-r-oO-j 7 i8 lB i~~ &§ ~ ~~ ia f5~;e . .. '- 7740 7790 7710 ~~ ~~~~~~~ ~II ~S~ ~I ~~r-:-~"i III! 7681 1 7850 J--78_51 -'-r_7_85_0 --.,,-1 7841 7850 ~ ~ "" 1 "'1~ ~ ~ .. " .. ~ 01" 1----,----I'tWr9 8 ~ \0 7862 7861 7862 .L. 7861 7862 Po :;- III III 7002 7901 7902 ':::0 7001 7902 "- 6925 ~ ~ I I 6811 6791 6761 > 6741 6711 ~ in '- 7800 7850 Legend • Speed Table Location BID OPENING REPORT Bids were opened on: Fridav. AUI!Ust 14.2015 after: 12:00 pm For: RFP # PW 2015-20 Mango Terrace Neighborhood Traffic Calm Improv COMPANIES THAT SUBMITTED PROPOSALS' . AMOUNT' . ENTIRE PROJECT W/OTRAFFIC > CIRCLES I. CORELAND CONSTRUCTION ............................. J (d1,Q 7 3.QJ .t4D) t3lta.CX) 2. FLORIDA CONSTRUCTION & ENGINEERING, INC tl;C)5 ,DtD 1.-"15 i YO, (g'UlD 3. H. A. CONTRACTING CORP .............................. It 135 t5C>l. ~'<I 1!III,G41.'61i" 4. MAGGOLC INC ................................................ ftt IDb,DSO.OO t 105,10"1(}. CX:l 3. SANCHEZ ARANGO .......................................... 11.1 q d ,I 'i!3. (J.) ~nl,a::o.CO THE ABOVE BIDS HAVE NOT BEEN CHECKED. THE BIDS ARE SUBJECT TO CORRECTION AFTER THE BIDS HAVE BEEN COMPLETELY REVIEWED. C"C." m. ~J Witness: $f-f.V?-... i PrmtName Witness: l2tr<ocrL A. Ay<-ic Print Name CORELAND CONSTRUCTION -W-OIl-/aI-'.(-}"-'fIe-d-HI-/sH-,e.-~----------------------====-------------------------------­ SIJA ('eff!!i!'d Small Disac/wI/lIClNet/ Business S'/ale of Flom/a ,\tinorl'Y Business Eme/'prise (JIBE) .1Iiami-nade ('011111)' COmlll1m/f)' Smull Hu.5ille.~s l:nteI1wl:5(' (C:"\BU Project Name: Due Date: Submitted By: Point of Contact: Address: Phone Number: Submitted to: SEALED BID MANGO TERRACE NEIGHBORHOOD TRAFFIC CALMING IMPROVEMENTS RFP# PW-2015-20 Friday, August 14,2015/12:00 p.m. CORELAND CONSTRUCTION CORP. Monica Hernandez 12301 SW 128 TH Court, #107 Miami, FL 33186 305-233-1709 CITY OF SOUTH MIAMI CITY CLERK'S OFFICE 6130 Sunset Drive Miami, FL 33143 1230 I s.w. 128~ Court, Suile 107 • Miami, FL 33186 • 305·233·1709 Office. 305·233·1809 Fax www.corelandconstruction.com --------- ... ~""<':-"~" . • ,F .,\ sou~hlMiami TIl!. (IIY 01 J'l! i\SA~T IIVt~C CITY OF SOUTH MIAMI Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW·20IS·20 Submittal Due Date: August 14,2015 at 12:00 PM (Noon) Solicitation Cover Letter The City of South Miami, Florida (hereinafter referred to as "CSM") through its chief executive officer (City Manager) hereby solicits sealed proposals responsive to the City's request (hereinafter referred to as "Request for Proposals" or "RFP"). All references in this Solicitation (also referred to as an "Invitation for Proposals" or "Invitation to Bid") to "City" shall be a reference to the City Manager. or the manager's designee. for the City of South Miami unless otherwise specifically defined. The City is hereby requesting sealed proposals in response to this RFP #PW·20IS·20 "Mango Terrace Neighborhood Traffic Calming Improvements," The purpose of this Solicitation is to contract for the services necessary for the completion of the project in accordance with the Scope of Services" (Exhibit I, Attachment A) and Respondents Cost and Technical Proposal or the plans andlor specifications, if any, (Exhibit I; Attachment 8) described in this Solicitation (hereinafter referred to as "the Proiect" or "Proiect") Interested persons who wish to respond to this Solicitation can obtain the complete Solicitation package at the City Clerk's office Monday through Friday from 9:00 AM. to 4:00 P.M. or by accessing the following webpage: http://www.southmlamifl.gov/ which is the City of South Miami's web address for solicitation information. Proposals are subject to the Standard Terms and Conditions contained in the complete Solicitation Package, including all documents listed in the Solicitation. The Proposal Package shall consist of one (I) original unbound proposal, three ( 3 ) additional copies and one (I) digital (or comparable medium including Flash Drive, DVD or CD) copy all of which shall be delivered to the Office of the City Clerk located at South Miami City Hall, 6130 Sunset Drive, South Miami, Florida 33143. The entire Proposal Package shall be enclosed in a sealed envelope or container and shall have the following Envelope Information clearly printed or written on the exterior ofthe envelope or container in which the sealed proposal is delivered: "Mango Terrace Neighborhood Traffic Calming Improvements," RFP #PW·10 l5~lO and the name of the Respondent (person or entity responding to the Solicitation. Special envelopes such as those provided by UPS or Federal Express will not be opened unless they contain the required Envelope Information on the front or back of the envelope. Sealed Proposals must be received by Office of the City Clerk, either by mail or hand delivery, no later than 12:00 PM local time on August 14, 2015. Hand delivery must be made during normal business days and hours of the office of City Clerk. A public opening will take place at 10 A.M. on the same date in the City Commission Chambers located at City Hall, 6130 Sunset Drive, South Miami 33143. Any Proposal received after 10 AM. local time on said date will not be accepted under any circumstances. Any uncertainty regarding the time a Proposal is received will be resolved against the person submitting the proposal and in favor of the Clerk's receipt stamp. A Non.Mandatory Pre.Proposal Meeting will be conducted at City Hall in the Commission Chambers located at 6130 Sunset Drive, South Miami, FI 33143 on, August 3, 2015 at II :00 A,M. The conference shall be held regardless of weather conditions. Proposals are subject to the terms, conditions and provisions of this letter as well as to those provisions. terms. conditions, affidavits and documents contained in this Solicitation Package. The City reserves the right to award the Project to the person with the lowest, most responsive, responsible Proposal, as determined by the City, subject to the right of the City, or the City Commission. to reject any and all proposals, and the right of the City to waive any irregularity in the Proposals or Solicitation procedure and subject also to the right of the City to award the Project, and execute a contract with a Respondent or Respondents. other than to one who provided the lowest Proposal Price or, if the Scope of the Work is divided into distinct subdivisions, to award each subdivision to a separate Respondent .. Maria M. Menendez, CMC, City Clerk, City of South Miami INSTRUCTIONS for RESPONDENT Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW.20 15.20 IT IS THE RESPONSIBILITY OF THE RESPONDENT TO THE SOLICITATION TO ENSURE THAT THE RESPONSE TO THE SOLICITATION (HEREINAFTER ALSO REFERRED TO AS THE "PROPOSAL" THROUGHOUT THE CONTRACT DOCUMENTS) REACHES THE CITY CLERK ON OR BEFORE THE CLOSING HOUR AND DATE STATED ON THE SOLICITATION FORM. I. Purpose of Solicitation. The City of South Miami is requesting proposals for the lowest and most responsive price for the Project. The City reserves the right to award the contract to the Respondent whose proposal is found to be in the best Interests olthe City. 2. Qualification of Proposing Firm. Response submittals to this Solicitation will be considered from firms normally engaged in providing the services requested. The proposing firm must demonstrate adequate experience, organization, offices, equipment and personnel to ensure prompt and efficient service to the City of South MiamI. The City reserves the right, before recommending any award, to inspect the offices and organization or to take any other action necessary to determine ability to perform In accordance with the specifications, terms and conditions. The City of South Miami will determine whether the evidence of ability to perform is satisfactory and reserves the right to reject all response submittals to this Solicitation where evidence submitted, or investigation and evaluation, indicates inability of a firm to perform. 3. Deviations from Specifications. The awarded firm shall dearly indicate, as applicable, all areas in which the services proposed do not fully comply with the requirements of this Solicitation. The decision as to whether an item fully complies with the stated requirements rests solely with the City of South Miami. 4. DeSignated Contact. The awarded firm shall appoint a person to act as a primary contact with the City of South Miami. This person or back~up shall be readily available during normal work hours by phone, email, or in person, and shall be knowledgeable of the terms of the contract. S. Precedence of Conditions. The proposing firm, by virtue of submitting a response, agrees that City's General Provisions, Terms and Conditions herein will take precedence over any terms and conditions submitted with the response, either appearing separately as an attachment or included within the Proposal. The Contract Documents have been listed below in order of precedence. with the one haVing the most precedence being at the top of the list and the remaining documents in descending order of precedence. This order of precedence shall apply" unless clearly contrary to the specific terms of the Contract or General Conditions to the Contract a) Addenda to Solicitation b) Attachments/Exhibits to c) Solicitation d) Attachment/Exhibits to Supplementary Conditions e) Supplementary Conditions to Contract, if any f) Attachment/Exhibits to Contract g) Contract h) General Conditions to Contract, if any i) Respondent's Proposal 6. Response Withdrawal. After Proposals are opened, corrections or modifications to Proposals are not permitted, but the City may allow the proposing firm to withdraw an erroneous Proposal prior to the' confirmation of the proposal award by City Commission, if all of the following is established: a) The proposing firm acted in good faith in submitting the response; b) The error was not the result of gross negligence or willful Inattention on the part of the firm; c) The error was discovered and communicated to the City within twenty-four (24) hours (not including Saturday, Sunday or a legal holiday) of opening the proposals received, along with a request for permission to withdraw the firm's Proposal: and d) The firm submits an explanation in writing. signed under penalty of perjury, stating how the error was made and delivers adequate documentation to the CIty to support the explanation and to show that the error was not the result of gross negligence or willful inattention nor made in bad faith. 7. The terms, provisions, conditions and definitions contained in the Solicitation Cover Letter shall apply to these instructions to Respondents and they are hereby adopted and made a part hereof by reference. If there is a conflict between the Cover Letter and these instructions, or any other provision of this Solicitation, the Cover Letter shall govern and take precedence over the conflicting provision(s) in the Solicitation. 2 8. Any questions concerning the Solicitation or any required need for clarification must be made in writing, by 10 AM, August 6, 20 I 5 to the attention of Steven P. Kulide at sklllick@sQuthmiamif1.eov or via facsimile at (305) 663·6346. 9. The issuance of a written addendum is the only official method whereby interpretation and/or clarification of information can be given. Interpretations or clarifications, considered necessary by the City in response to such questions, shall be Issued by a written addendum to the Solicitation Package (also known as "Solicitation Specifications" or "Solicitation") by U.S. mail, e-mail or other delivery method convenient to the City and the City will notify all prospective firms via the City's website. 10. Verbal interpretations or clarifications shall be without legal effect. No plea by a Respondent of Ignorance or the need for additional information shall exempt a Respondent from submitting the Proposal on the reqUired date and time as set forth in the public notice. II. Cone of Silence: You are hereby advised that this Request for Proposals is subject to the "Cone of Silence." in accordance with Miami-Dade County Ordinance Nos. 98106 and 99-1. From the time of advertising until the City Manager issues his recommendation, there is a prohibition on verbal communication with the City'S profeSSional staff, including the City Manager and his staff. All written communication must comply with the requirements of the Cone of Silence. The Cone of Silence does not apply to verbal communications at pre- proposal conferences. verbal presentations before evaluation committees, contract discussions during any duly noticed pUblic meeting. public presentations made to the City Commission during any duly notice public meeting. contract negotiations with the staff following the City Manager's written recommendation for the award of the contract, or communications in writing at any time with any City employee. official or member of the City Commission unless specifically prohibited. A copy of all written communications must be contemporaneously flied with the City Manager and City Clerk. In addition, you are reqUired to comply with the City Manager's Administrative Order AO I-I S. If a copy is not attached, please request a copy from the City's Procurement Division. WITH REGARD TO THE COUNTY'S CONE OF SILENCE EXCEPTION FOR WRITTEN COMMUNICATION, PLEASE BE ADVISED THAT, NOTWITHSTANDING THE MIAMI· DADE COUNTY EXCEPTION FOR WRITTEN COMMUNICATION THE COUNTY'S RULES PROHIBITING VERBAL COMMUNICATION DURING AN ESTABLISHED CONE OF SILENCE SHALL, WITH REGARD TO THIS SOLICITATION, ALSO APPLY TO ALL WRITTEN COMMUNICATION UNLESS PROVIDED OTHERWISE BELOW. THEREFORE, WHERE THE CITY OF SOUTH MAIMI CONE OF SILENCE PROHIBITS COMMUNICATION, SUCH PROHIBITION SHALL APPLY TO BOTH VERBAL AND WRITTEN COMMUNICATION. Notwithstanding the foregoing, the Cone of Silence shall not apply to ... (I) Duly noticed site visits to determine the competency of bidders regarding a particular bid during the time period between the opening of bids and the time that the City Manager makes his or her written recommendation: (2) Any emergency procurement of goods or services pursuant to the Miami-Dade County Administrative Order 3.2; (3) Communications regarding a particular solicitation between any person and the procurement agent or contracting officer responsible for administering the procurement process for such solicitation, provided the communication is limited strictly to matters of process or procedure already contained In the corresponding solicitation document; and (4) Communications regarding a particular solicitation between the procurement agent or contracting officer, or their designated secretarlall clerical staff responsible for administering the procurement process for such solicitation and a member of the selection committee provided the communication is limited strictly to matters of process or procedure already contained in the corresponding solicitation document." 12. Violation of these provisions by any particular Respondent or proposer shall render any recommendation for the award of the contract or the contract awarded to said Respondent or proposer voidable, and, in such event, said Respondent or proposer shall not be considered for any Solicitation including but not limited to one that requests any of the follOWing a proposal, qualifications. a letter of Interest or a bid concerning any contract for the provision of goods or services for a period of one year. Contact shall only be made through regularly scheduled Commission meetings, or meetings scheduled through the PurchaSing Division. which are for the purposes of obtaining additional or clarifying information. 3 13. Lobbying. All firms and their agents who Intend to submit, or who submitted, bids or responses for this Solicitation, are hereby placed on formal notice that neither City Commissioners, candidates for City Commissioner or any employee of the City of South Miami are to be lobbied either individually or collectively concerning this Solicitation. Contact shall only be made through regularly scheduled Commission meetings, or meetings scheduled through the Purchasing Division, which are for the purposes of obtaining additional or clarifying information. 14. Reservation of Right. The City anticipates awarding one contract for services as a result of this Solicitation and the successful firm will be requested to enter into negotiations to produce a contract for the Project. The City, however, reserves the right, In Its sole discretion, to do any of the following: a) to reject any and all submitted Responses and to further define or limit the scope of the award. b) to waive minor irregularities in the responses or in the procedure required by the Solicitation documents. c} to request additional information from firms as deemed necessary. d) to make an award without discussion or after limited negotiations. It is, therefore. important that all the parts of the Request for Proposal be completed In all respects. e} to negotiate modifications to the Proposal that It deems acceptable. f} to terminate negotiations in the event the City deems progress towards a contract to be insufficient and to proceed to negotiate with the Respondent who made the next best Proposal. The City reserves the right to proceed in this manner until it has negotiated a contract that is satisfactory to th~ City. g) To modify the Contract Documents. The terms of the Contract Documents are general and not necessarlly specific to the Solicitation. It is therefore anticipated that the City may modify these documents to fit the specific project or work in question and the Respondent, by making a Proposal, agrees to such modifications and to be bound by such modified documents. h) to cancel, In whole or part, any invitation for Proposals when it is in the best interest of the City. i) to award the Project to the person with the lowest, most responsive, responsible Proposal, as d~t~rmined by the City. j} to award the ProJecr. and execute a contract with a Respondent or Respondents, other than to one who provided the lowest Proposal Price. k} if the Scope of the Work is divided into distinct subdivisions, to award each subdivision to a separate Respondent. 15. Contingent Fees Prohibited. The proposing firm, by submitting a proposal, warrants that it has not employed or retained a company or person, other than a bona fide employee, contractor or subcontractor. working in its employ, to solicit or secure a contract with the City, and that it has not paid or agreed to pay any person, company. corporation, individual or firm other than a bona fide employee, contractor or sub-consultant, working in its employ, any fee, commission, percentage, gift or other consideration contingent upon or resulting from the award or making of a contract with the City. 16. Public Entity Crimes. A person or affiliate of the Respondent who has been placed on the convicted vendor list pursuant to Chapter 287 follOWing a conviction for a public entity crime may not submit a Proposal on a contract to provide any goods or services, or a contract for construction or repair of a public building. may not submit proposals on leases of real property to or with the City of South Miami, may not be awarded a contract to perform work as a CONTRACTOR, sub-contractor. supplier. sub-consultant, or consultant under a contract with the City of South Miami, and may not transact business with the City of South Miami for a period of 36 months from the date of being placed on the convicted vendor list. 17. Respondents shall use the Proposal Form(s) furnished by the City. All erasures and corrections must have the initials of the Respondent's authorized representative in blue ink at the location of each and every erasure and correction. Proposals shall be signed using blue ink; all quotations shall be typewritten. or printed with blue ink. All spaces shall be filled in with the reguested information or the phrase "not applicable" or "NA". The proposal shall be delivered on or before the date and time, and at the place and in such manner as set forth in the Solicitation Cover Letter. Failure to do so may cause the Proposal to be rejected. Failure to include any of the Proposal Forms may invalidate the Proposal. Respondent shall deliver to the City. as part of its Proposal. the (ollowing documents: a) The Invitation for Proposal and Instructions to Respondents. b) A copy of all Issued addenda. c) The completed Proposal Form fully executed. d) Proposal/Bid Bond, (Bond or cashier's check), if required, attached to the Proposal Form. 4 e) Certificates of Competency as well as all applicable State, County and City licenses held by Q 18. Goods: a) Respondent Certificate of Insurance and/or Letter of Insurability. If goods are to be provided pursuant to this Solicitation the following applies: Brand Names: If a brand name, make, manufacturer's trade name, or vendor catalog number is mentioned in this Solicitation, whether or not followed by the words "approved equal", it is for the purpose of establishing a grade or quality of material only. Respondent may offer goods that are equal to the goods described in this Solicitation with appropriate identification, samples and/or specifications for such item(s). The City shall be the sole judge concerning the merits of Items proposed as equals. b) Pricing; Prices should be stated in units of quantity specified in the Proposal Form. In case of a c) discrepancy. the City reserves the right to make the final determination at the lowest net cost to the City. Mistake: In the event that unit prices are part of the Proposal and if there is a discrepancy between the unit price(s) and the extended price(s), the unit prlce(s) shall prevail and the extended prlce(s) shall be adJusted to coincide. Respondents are responsible for checking their calculations. Failure to do so shall be at the Respondent's risk, and errors shall not release the Respondent from his/her or Its responsibility as noted herein. d) Samples: Samples of items, when required. must be furnished by the Respondent free of charge to the City. Each individual sample must be labeled with the Respondent's name and manufacturer's brand name and delivered by it within ten (10) calendar days of the Proposal opening unless schedule indicates a different time. If samples are requested subsequent to the Proposal opening, they shall be delivered within ten (10) calendar days of the request. The City shall not be responsible for the return of samples. e) Respondent warrants by signature on the Proposal Form that prices quoted therein are in conformity with the latest Federal Price Guidelines. Q Governmental Restrictions: In the event any governmental restrictions may be imposed which would necessitate alteration of the material quality, workmanship, or performance of the items offered on this Proposal prior to their delivery. it shall be the responsibility of the successful Respondent to notify the City at once, indicating in its letter the specific regulation which required an alteration. The City of South Miami reserves the right to accept any such alteration, including any price adjustments occasioned thereby, or to cancel all or any portion of the Contract, at the sole discretion of the City and at no further expense to the City with thirty (30) days advanced notice. g) Respondent warrants that the prices, terms and conditions quoted in the Proposal shall be firm for a period of one hundred eighty (180) calendar days from the date of the Proposal opening unless otherwise stated in the Proposal Form. Incomplete, unresponsive, irresponsible, vague, or ambiguous responses to the Solicitation shall be cause for rejection, as determined by the .City. h) Safety Standards: The Respondent warrants that the product(s) to be supplied to the City conform in all respects to the standards set forth in the Occupational Safety and Health Act (OSHA) and Its amendments. Proposals must be accompanied by a Materials Data Safety Sheet (M.S.D.S) when applicable. 19. Liability, licenses & Permits: The successful Respondent shall assume the full duty, obligation, and expense of obtaining all necessary licenses, permits, and inspections reqUired by this Solicitation and as reqUired by law. The Respondent shall be liable for any damages or loss to the City occasioned by the negligence of the Respondent (or its agent or employees) or any person acting for or through the Respondent. Respondents shall furnish a certified copy of all licenses, Certificates of Competency or other licensing requirement necessary to practice their profession and applicable to the work to be performed as required by Florida Statutes, the Florida Building Code, Miami-Dade County Code or City of South Miami Code. These documents shall be furnished to the City as part of the Proposal. Failure to have obtained the reqUired licenses and certifications or to furnish these documents shall be grounds for rejecting the Proposal and forfeiture of the ProposalfBid Bond, if required for this Project. 20. Respondent shall comply with the City's insurance reqUirements as set forth in the attached EXHIBIT 2, prior to issuance of any Contract(s) or Award(s) If a recommendation for award of the contract, or an award of the contract is made before compliance with this provision. the failure to fully and satisfactorily comply with the City's bonding, 'If required for this project, and insurance reqUirements as set forth herein shall authorize the City to Implement a rescission of the Proposal Award or rescission of the recommendation for award of 5 contract without further City action. The Respondent. by submitting a Proposal. thereby agrees to hold the City harmless and agrees to Indemnify the City and covenants not to sue the City by virtue of such rescission. 21. Copyrights and/or Patent Rights: Respondent warrants that as to the manufacturing, producing or selling of goods intended to be shipped or ordered by the Respondent pursuant to this Proposal, there has not been, nor will there be, any infringement of copyrights or patent rights. The Respondent agrees to indemnify City from any and all liability. loss or expense occasioned by any such violation or infringement. 22. Execution of Contract: A response to this Solicitation shall not be responsive unless the Respondent signs the form of contract that is a part of the Solicitation package. The Respondent to this Solicitation acknowledges that by submitting a response or a proposal, Respondent agrees to the terms of the form contract and to the terms of the general conditions to the contract, both of which are part of this Solicitation package. The Respondent agrees that Respondent's signature on the Bid Form and/or the form of contract that is a part of the Solicitation package and/or response to this Solicitation. grants to the City the authority, on the Respondent's behalf, to inserted. into any blank spaces in the contract documents, information obtained from the proposal and, at the City's sale and absolute discretion, the City may treat the Respondent's signature on any of those documents, as the Respondent's Signature on the contract:, after the appropriate information has been inserted, as well as for any and all purposes, including the enforcement of all of the terms and conditions of the contract. 23. Evaluation of Proposals: The City. at its sale discretion, reserves the right to inspect the facilities of any or all Respondents to determine its capability to meet the requirements of the Contract. In addition, the price, responsibility and responsiveness of the Respondent, the financial pOSition, experience, staffing, equ·tpment. materials, references, and past history of service to the City and/or with other units of state, and/or local governments in Florida, or comparable private entities, will be taken into consideration in the Award of the Contract. 24. Drug Free Workplace: Failure to prOVide proof of compliance with Florida Statute Section 287.087, as amended, when requested shall be cause for rejection of the Proposal as determined by the City. 25. Public Entity Crimes: A person or affiliate who was placed on the Convicted Vendors List follOWing a conviction for a pUblic entity crime may not submit a response on a contract to provide any services to a public entity, may not submit Solicitation on leases of real property to a public entity, and may not transact business with any public entity In excess of the threshold amount provided in Section 287.017, for a period of 36 months from the date of being placed on the Convicted Vendors list. 26. Contingent Fees Prohibited: The proposing firm must warrant that it has not employed or retained a company or person, other than a bona fide employee, contractor or subcontractor, working in its employ, to solicit or secure a contract with the City, and that it has not paid or agreed to pay any person, company, corporation, individual or firm other than a bona fide employee. contractor or sub-consultant, working in its employ, any fee. commission. percentage. gift or other consideration contingent upon or resulting from the award or making of a contract with the City. 27. Hold Harmless: All Respondents shall hold the City, its officials and employees harmless and covenant not to sue the City. its officials and employees in reference to its decisions to reject, award, or not award a contract, as applicable, unless the claim is based solely on allegations of fraud and/or collusion. The submission of a proposal shall act as an agreement by the Respondent that the Proposal/Bid Bond, if required for this project:, shall not be released until and unless the Respondent waives any and all claims that the Respondent may have against the City that arise out of this Solicitation process or until a judgment is entered in the Respondent's favor in any suit filed wh1ch concerns this proposal process. In any such suit, the prevailing party shall recover its attorney's fees. court costs as well as expenses associated with the litigation. In the event that fees, court costs and expenses associated with the litigation are awarded to the City, the Proposal/Bid Bond. if reqUired for this project, shall be applied to the payment of those costs and any balance shall be paid by the Respondent. 28. Cancellation: Failure on the part of the Respondent to comply with the conditions, speCifications. requirements, and terms as determined by the City, shall be just cause for cancellation of the Award or termination of the contract. 29. Bonding ReqUirements: The Respondent, when submitting the Proposal. shall include a Proposal/Bid Bond, if required for this project:, in the amount of 5% of the total amount of the base Proposal on the Proposal/Bid Bond Form Included herein. A company or personal check shall not be deemed a valid Proposal Security. 30. Performance and Payment Bond: The City of South Miami may reguire the successful Respondent to furnish a Performance Bond and Payment Bond. each in the amount of 100% of the total Proposal Price, including Alternates if any, naming the City of South Miami, and the entity that may be prOViding a source of funding for the Work. as the obligee. as security for the faithful performance of the Contract and for the payment of all 6 persons or entities performing labor. services and/or furnishing materials in connection herewith. In addition, if the Respondent's employees will be working in secure and sensitive areas of the City the City may require that the Respondent provides employee bonding, naming the City of South Miami as the obligee on the bond. The bonds shall be with a surety company authorized to do business in the State of Florida. 30.1. Each Performance Bond shall be in the amount of one hundred percent (100%) of the Contract Price guaranteeing to City the completion and performance of the Work covered in the Contract Documents. 30.2. Each Performance Bond shall continue in effect for five year after final completion and acceptance of the Work with the liability equal to one hundred percent (100%) of the Contract Sum. 30.3. Each Payment bond shall guarantee the full payment of all suppliers, material man, laborers, or subcontractor employed pursuant to this Project. 3004. Each Bond shall be with a Surety company whose qualifications meet the requirements of insurance companies as set forth In the Insurance requirements of this solicitation. 30.5. Pursuant to the requirements of Section 255.05, Florida Statutes, Respondent shall ensure that the Bond(s) referenced above shall be recorded in the pUblic records of Miami·Dade County and provide CITY with evidence of such recording. 30.6. The surety company shall hold a current certificate of authority as acceptable surety on federal bonds in accordance with the United States Department of Treasury Circular 570. current revisions. 31. Proposal Guarantee: Notwithstanding the fact that the Respondent, in submitting a proposal, agrees to the terms contained In the form of contract that is part of this Solicitation package, the successful Respondent, within ten (10) calendar days of Notice of Award by the City, shall deliver, to the City, the executed Contract and other Contract Documents that provide for the Respondent'S signature. and deliver to the City the required insurance documentation as well as a Performance and Payment Bond if these bonds are reqUired. The Respondent who has the Contract awarded to it and who fails to execute the Contract and furnish the required Bonds and Insurance Documents within the specified time shall, at the City's option, forfeit the Proposal/Bid Bond/Security that accompanied the Proposal, and the Proposal/Bid Bond/Security shall be retained as liqUidated damages by the City. It is agreed that if the City accepts payment from the Proposal/Bid Bond, that this'sum is a fair estimate of the amount of damages the City will sustain in case the Respondent fails to sign the Contract Documents or fails to furnish the required Bonds and Insurance documentation. If the City does not accept the Proposal/Bid Bond, the City may proceed to sue for breach of contract if the Respondent fails to perform in accordance with the Contract Documents. Proposal/Bid Bond/Security deposited in the form of a cashier's check drawn on a local bank in good standing shall be subject to the same requirements as a Proposal/Bid Bond. 32. Pre· proposal Conference Site Visits: If a Mandatory Pre·proposal conference is scheduled for this project, all Respondents shall attend the conference and tour all areas referenced in the Solicitation Documents. It shall be grounds for rejecting a Proposal (rom a Respondent who did not attend the mandatory pre.proposal conference. No pleas of Ignorance by the Respondent of conditions that exist, or that may hereinafter exist, as a Solicitation result of failure to make the necessary examinations or investigations, or failure to complete any part of the Solicitation Package, will be accepted as basis for varying the requirements of the Contract with the City of South Miami or the compensation of the Respondent. The Respondent, following receipt of a survey of the property, if applicable, is bound by knowledge that can be seen or surmised from the survey and will not be entitled to any change order due to any such condition. If the survey is provided before the proposal is submitted, the contract price shall Include the Work necessitated by those conditions. If the survey is prOVided subsequent to the submission of the proposal, the R.espondent shall have five calendar days to notify the City of any additional costs required by such conditions and the City shall have the right to reject the proposal and award the contract to the second most responsive, responsible bidder with the lowest price or to reject all bids. 33. Time of Completion: The time is of the essence with regard to the completion of the Work to be performed under the Contract to be awarded. Delays and extensions of time may be allowed only in accordance with the provisions stated in the appropriate section of the Contract Documents, in~luding the Proposal Form. No change orders shall be allowed for delays caused by the City, other than for extensions of time to complete the Work. 34. Submittal Requirements: All Proposals shall comply with the requirements set forth herein and shall include a fully completed Bid Form found on EXHIBIT 4 which is a part of this Solicitation Package. 3S. Cancellation of Bid Solicitation: The City reserves the right to cancel, in whole or part, any request for proposal when it is in the best interest of the City. 7 36. Respondent shall not discriminate with regard to its hiring of employees or subcontractors or in its purchase of materials or in any way in the performance of its contract, if one is awarded, based on race, color, religion, national origin, sex, age, sexual orientation, disability, or familial status. 37. All respondents, at the time of bid opening. must have fulfilled all prior obligations and commitments to the City in order to have their bid considered, including all financial obligations. Prior to the acceptance of any bid proposal or quotation, the City's Finance Department shall certify that there are no outstanding fines, monies, fees, taxes, liens or other charges owed to the City by the Respondent, any of the Respondent's principal, partners, members or stockholders (collectively referred to as "Respondent Debtors"). A bid. proposal or quotation will not be accepted until all outstanding debts of all Respondent Debtors owed to the city are paid in full. No bidder who is in default of any prior contract with the City may have their bid considered until the default is cured to the satisfaction of the City Manager. 38. Bid Protest Procedure. See attached EXHIBIT 3. 39. Evaluation Criteria: If this project is to be evaluated by an Evaluation Committee, the evaluation criteria is attached as NfA. END OF SECTION 8 Proposal Submittal Checklist Form Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW-IOI5-10 This checklist indicates the forms and documents required to be submitted for this solicitation and to be presented by the deadline set for within the solicitation. Fulfillment of all solicitation requirements listed is mandatory for consideration of response to the solicitation. Additional documents may be required and, if so, they will be identified in an addendum to this Solicitation. The response shall include the following items: Attachnlents and Other Documents described below Ch~cI{ to be Completed IF MARKED WITH AN "X": Completed. X Indemnification and Insurance Documents EXHIBIT 2 X X Bid Form EXHIBIT 4 X X Signed Contract Documents (All -including General Conditions and Supplementary Conditions if attached) EXHIBIT 5; 6 & 7 X Performance and Payment Bonds (As a Condition Award. Not required with Submittal.) EXHIBIT 8 & 9 X X Respondents Qualification Statement X X List of Proposed Subcontractors and Principal Suppliers X X Non-Collusion Affidavit X X Public Entity Crimes and Conflicts of Interest X X Drug Free Workplace X X Acknowledgement of Conformance with OSHA Standards X X Affidavit Concerning Federal & State Vendor listings X X R.elated Party Transaction Verification Form X X Presentation Team Declaration/Affidavit of Representation X Submit this checklist along with your proposal indicating the completion and submission of each required forms and/or documents. END OF SECTION 9 RESPONDENT QUALIFICATION STATEMENT Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW·20 15·20 The response to this questionnaire shall be utilized as part of the CITY'S overall Proposal Evaluation and RESPONDENT selection. I. Number of similar projects completed, a) In the past 5 years 7 In the past 5 years On Schedule 7 b) In the past 10 years 10 In the past 10 years On Schedule 10 2. list the last three (3) completed similar projects. See attached chart a) Project Name: Owner Name: Owner Address: Owner Telephone: Original Contract Completion Time (Days): Original Contract Completion Date: Actual Final Contract Completion Date: Original Contract Price: Actual Final Contract Price: b) Project Name: Owner Name: Owner Address: Owner Telephone: Original Contract Completion Time (Days): Original Contract Completion Date: Actual Final Contract Completion Date: Original Contract Price: Actual Final Contract Price 10 c) Project Name: Owner Name: Owner Address: Owner Telephone: Original Contract Completion Time (Days): Original Contract Completion Date: Actual Final Contract Completion Date: Original Contract Price: Actual Final Contract Price: 3. Current workload Project Name Owner Name Telephone Number FY2014 Sidewalk Const. City of Hollywood 954-924-2985 Frank Leon, PE Supply & Install Conc. City of Lauderhill 954-730-4230 Sidewalks, Pads & Curbs Charlie Cuyler, PM 4, The following information shall be attached to the proposal. a) RESPONDENT's home office organization chart. See attached Contract Price $ 399,805 $ 62,340 b) RESPONDENT's proposed project organizational chart. See attached c) Resumes of proposed key project personnel, including on-site Superintendent. See attached S. List and describe any: II a) Bankruptcy petitions filed by or against the Respondent or any predecessor organizations, N/A b) Any arbitration or civil or criminal proceedings, or N/A Suspension of contracts or debarring from Bidding or Responding by any public agency brought c) against the Respondent in the last five (5) years N/A 6. Government References: See attached list other Government Agencies or Quasi-government Agencies for which you have done business within the past five (5) years. Name of Agency: Address: Telephone No.: Contact Person: Type of Project: Name of Agency: Address: Telephone No.: Contact Person: Type of Project: Name of Agency: Address: Telephone No.: Contact Person: Type of Project: 12 LIST OF PROPOSED SUBCONTRACTORS AND PRINCIPAL SUPPLIERS Mango Terraee Neighborhood Traffie Calming Improvements RFP #PW-20 15-20 Respondent shall list all proposed subcontractors, if subcontractors are allowed by the terms of this Solicitation to b d h fh ddhC Classification of Worl< Subcontractor Name Address Telephone, Fax & Email landscape NIA Sodding and Turf Work NIA Electrical NIA Irrigation NIA Paving NIA Park Amenities NIA Graphics NIA Utilities NIA Excavation NIA Building NIA Structures NIA Plumbing NIA Painting NIA Testing Laboratory N/A Soil Fumigator NIA Signs N/A Other: N/A This list shall be rovided to the Ci of South Miami b the a p ~ y W arent lowest res onsive and res on sible Bidder p p within five (5) business days after Bid Opening. END OF SECTION I] NON COLLUSION AFFIDAVIT STATE OF FLORIDA COUNTY OF MIAMI-DADE Monica Hernandez _____________________ being first duly sworn, deposes and states that: ( I ) He/Sh!ifhey islare the ---,,.--'-P-'-re"'s"'id"'e"'n"-t_-,_--,---,-____________ _ (Owner, Partner, Officer, Representative or Agent) of Coreland Construction Corp. the Respondent that has submitted the attached Proposal; (2) He/ShefThey islare fully informed concerning the preparation and contents of the attached Proposal and of all pertinent circumstances concerning such Proposal; (3) Such Proposal is genuine and is not a collusive or sham Proposal; (4) Neither the said Respondent nor any of its officers, partners, owners, agents, representatives, employees or parties in interest, including this affiant, have In any way colluded, conspired, connived or agreed. directly or indirectly. with any other Respondent, firm, or person to submit a collusive or sham Proposal in connection with the Work for which the attached Proposal has been submitted; or to refrain from Bidding or proposing in connection with such Work; or have in any manner, directly or indirectly, sought by agreement or collusion. or communication, or conference with any Respondent, firm, or person to fix any overhead, profit, or cost elements of the Proposal or of any other Respondent, or to fix any overhead, profit, or cost elements of the Proposal Price or the Proposal Price of any other Responden~ or to secure through any collusion, conspiracy, connivance, or unlawful agreement any advantage against (Recipient), or any person interested in the proposed Work; (5) The price or prices quoted in the attached Proposal are fair and proper and are not tainted by any collusion, conspiracy, connivance, or unlawful agreement on the part of the Respondent or any other of its agents, representatives, owners, employees or parties of interest. including this affiant. STATE OF FLORIDA COUNTY OF MIAMI-DADE resence of: t Name and Title Monica Hernandez, President .-.-r- 8/13/15 Date ACKNOWLEDGEMENT ) ) ) On this the 13th day of August , 20--.1L before me, the undersigned Notary Public of the State of Florida, personally appeared (Name(s) of individual(s) who appeared before 14 notary) Monica Hernandez and within instrument, and he/shelthey acknowledge that he/she/they exe WITNESS my hand and official seal. NOTARY PUBLIC: SEAL OF OFFICE: --L Personally known to me, or Personal identification: Type of Identification Produced Did take an oath. or Did Not take an oath. 15 PUBLIC ENTITY CRIMES AND CONFLICTS OF INTEREST Pursuant to the provisions of Paragraph (2) (a) of Section 287.133, Florida State Statutes -"A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a Proposal or bid on a Contract to provide any goods or services to a public entity, may not submit a Bid or proposal for a Contract with a public entity for the construction of repair of a public building or public work, may not submit bids or proposals on leases or real property to a public entity, may not be awarded to perform Work as a RESPONDENT, Sub-contractor, supplier, Sub-consultant, or Consultant under a Contract with any public entity, and may not transact business with any public entity in excess of the threshold amount Category Two of Section 287.017, Florida Statutes, for thirty six (36) months from the date of being placed on the convicted vendor list", The award of any contract hereunder is subject to the provisions of Chapter 112, Florida State Statutes. Respondents must disclose with their Proposals, the name of any officer, director, partner, associate or agent who is also an officer or employee of the City of South Miami or its agencies. SWORN STATEMENT PURSUANT TO SECTION 287.133 (3) (a), FLORIDA STATUTES, ON PUBUC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBUC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. I. This sworn statement is submitted to City of South Miami [print name of the public entity] by Monica Hernandez, President [print individual's name and title] for Coreland Construction Corp. [print name of entity submitting sworn statement) whose business address is 12301 SW 128 Court. #107 Miami, FL 33186 and (if applicable) its Federal Employer Identification Number (FEIN) is 65-0073665 (If the entity has no FEIN) include the Social Security Number of the individual signing this sworn statement: ------------------'.) 2. I understand that a "public entity crime" as defined in Paragraph 287.133 (I )(g), Florida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including. but not limited to , any bid, proposal or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud, theft, bribery. collusion, racketeering, conspiracy, or material misrepresentation. 3. I understand that "convicted" or "conviction" as defined in Paragraph 287.133 (I) (b), Florida Statutes, means a finding of guilt or a conviction of a pUblic entity crime, with or without an adjudication of guilt, in any federal or state trial court of record relating to charges brought by indictment or information after July I, 1989, as a result of a jury verdiCt, non-jury trial, or entry of a plea of guilty or nolo contendere. 4. I understand that an "affiliate" as defined in Paragraph 287.133 (I) (a), Florida Statutes, means: (a) A predecessor or successor of a person convicted of a public entity crime; or (b) An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers, 16 ----------------- directors. executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in any person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. S. I understand that a "person" as defined in Paragraph 287.133 (I) (e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or proposal or applies to bid or proposal on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. 6, Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this sworn statement. [Indicate which statement applies.] _X_ Neither the entity submitting this sworn statement. nor any of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July I, 1989. __ The entity submitting this sworn statement. or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity. or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1,1989. __ The entity submItting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders. employees, members, or agents who are active in the management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent of July I, 1989. However. there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that It was not in the public interest to place the entity submitting this sworn statement on the convicted vendor list. [attach a copy of the final order.] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FOR THE PUBLIC ENTITY INDENTIFIED IN PARAGRAPH I (ONE) ABOVE IS FOR THAT PUBLIC ENTITY ONLY, AND THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017, F ORIDA S TES, CATEG Y TWO OF AN CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. Sworn to and subscribed before me this __ 1_3_th __ Personally known __ -'X--'--_______ _ OR Produced identification _______ _ (Type of Identification) Form PUR 7068 (Rev.06/11/92) 17 Notary Public -State of _'--F::.L ____ _ My commission expires (Printed, name 0 !nlrtJb~ryPubIlCSI.te of Florlda • • RiCk Hamish ~ ~.# My Commission FF 170461 • . :'" Expire, 10/2112018 DRUG FREE WORKPLACE Whenever two or more Bids or Proposals which are equal with respect to price, quality and service are received by the State or by any political subdivisions for the procurement of commodities or contractual services. a Bid or Proposal received from a business that certifies that it has implemented a drug-free workplace program shall be given preference in the award process. Established procedures for processing tie Bids or Proposals shall be followed if none of the tied vendors have a drug-free workplace program. In order to have a drug-free workplace program, a business shall: I) Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that shall be taken against employees for violations of such prohibition. 2) Inform employees about the dangers of drug abuse in the workplace, the business' policy of maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be Imposed upon employees for drug abuse violations. 3) Give each employee engaged in providing the commodities or contractual services that are under Bid a copy of the statement specified in Subsection (I). 4) In the statement specified in Subsection (I), notify the employees, that, as a condition of working of the commodities or contractual services that are under Bid, he employee shall abide by the terms of the statement and shall notify the employee of any conviction of, or plea of guilty or nolo contendere to. any violation of Chapter 893 or of any controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5) business days after such conviction. S) Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or rehabilitation program, if such is available in the employee's community, by any employee who Is so convicted. 6) Make a good faith effort to continue to maintain a drug-free workplace through implementation of this section. As the person authorized to sign fully with the above requirements, RESPONDENT's Signa re~·s"2.~lt.~~~~i;Z~~~t!::.~~~ Print Name: __ M_D_n_ica---''''-e_rn_a_n_d_e_z-',_P_r_e_s_id_e_n_t ______ _ Date: 8/13/15 18 ACKNOWLEDGEMENT OF CONFORMANCE WITH OSHA STANDARDS Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW-20 15-20 TO THE CITY OF SOUTH MIAMI We. Coreland Construction Corp. • (Name of CONTRACTOR). hereby acknowledge and agree that as CONTRACTOR for the Mango Terrace Neighborhood Traffic Calming Improvements project as specified have the sole responsibility for compliance with all the requirements of the Federal Occupational Safety and Health Act of 1970. and all State and local safety and health regulations. and agree to indemnify and hold harmless the City of South Miami and TY Linn/H.J. Ross (Consultants) against any and all liability. claims. damages, losses and expenses they may incur due to the failure of (Sub.contractor's names): N/A to comply with such act or regulation. CONTRACTOR President Title 19 AFFIDAVIT CONCERNING FEDERAL AND STATE VENDOR LISTINGS The person, or entity, who is responding to the City's solicitation, hereinafter referred to as "Respondent", must certify that the Respondenes name Does Not appear on the State of Florida, Department of Management Services, "CONVICTED, SUSPENDED, DISCRIMINATORY FEDERAL EXCLUDED PARTIES and COMPLAINTS VENDOR LISTINGS". If the Respondent's name Does appear on one or all the "Listings" summarized below, Respondents must "Check if Applies" next to the applicable "listing." The "listings" can be accessed through the following link to the Florida Department of Management Services website: http://www.dms.myflorida.com/business operations/state purchasing/vendor information/convicted susp ended discriminatory complaints vendor lists DECLARATION UNDER PENALTY OF PERJURY I, Monica Hernandez (hereinafter referred to as the "Declarant") state, under penalty of perjury, that the following statements are true and correct: (I) I represent the Respondent whose name is Coreland Construction Corp. (2) I have the following relationship with the Respondent president (Owner (if Respondent is a sole proprietor), President (if Respondent is a corporation) Partner (if Respondent is a partnership), General Partner (if Respondent is a limited Partnership) or Managing Member>(if Respondent is a limited liability Company). (3) I have reviewed the Florida Department of Management Services website at the follOWing URL address: http://www.dms.myflorida.comlbusiness_ operations/state--purchasing/vendor _information/convicted_suspended _ di scriminatory_complaints_vendor Jists (4) I have entered an "x" or a check mark beside each listing/category set forth below if the Respondent's name appears in the list found on the Florida Department of Management Services website for that category or listing. if I did not enter a mark beside a listing/category it means that I am attesting to the fact that the Respondent's name does not appear on the listing for that category in the Florida Department of Management Services website as of the date of this affidavit. Check if Applicable Convicted Vendor list Suspended Vendor list Discriminatory Vendor list Federal Excluded Parties list Vendor Compiaint List FURTHER DECLARANT SAYETH NOT. ACKNOWLE STATE OF FLORIDA ) COUNTY OF MIAMI-DADE ) Monica Herna On this the 13th day of-'-AO::uSlg"'us;ct'----__ ~, 20~ before me, the undersigned authority, personally appeared Monica Hernandez who is ersonall know to me or who provided the following identification and who took an oath or affir t t that he/she/they executed the foregoing Affidavit as the Declarant. WITNESS my hand and official seal. NOTARY PUBLIC, SEAL 20 RELATED PARTY TRANSACTION VERIFICATION FORM Monica Hernandez • individually and on behalf of Coreland Construction Corp. ("Firm")have Name o(Representative CompanylVendorlEntity read the City of South Miami ("City")'s Code of Ethics. Section SA-I of the City's Code of Ordinances and I hereby certify. under penalty of perjury that to the best of my knowledge. information and belief: (I) neither I nor the Firm have any connict of interest (as defined In section SA-I) with regard to the contract or business that I. and/or the Firm. am (are) about to perform for. or to transact with. the City. and (2) neither I nor any employees, officers, directors of the Firm, nor anyone who has a financial interest greater than 5% in the Firm. has any relative(s). as defined in section SA-I. who Is an employee of the City or who is(are) an appointed or elected official of the City. or who is(are) a member of any public body created by the City Commission. i.e .• a board or committee of the City. [while the ethics code still applies. if the person executing this form is doing so on behalf of a firm whose stock is publicly traded. the statement In this section (2) shall be based solely on the signatory's personal knowledge and he/she is not required to make an independent investigation as to the relationship of employees or those who have a financial interest in the Firm.]: and (3) neither I nor the Firm, nor anyone who has a financial interest greater than 5% in the Firm, nor any member of those persons' immediate family (Le" spouse, parents, children, brothers and sisters) has transacted or entered into any contract(s) with the City or has a financial interest, direct or indirect, in any business being transacted with the city, or with any person or agency acting for the City, other than as follows: N/A _(use (if necessary. use a separate sheet to supply additional information that will not fit on this line; however. you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies. if the person executing this form is doing so on behalf of a firm whose stock is publicly traded. the statement in this section (3) shall be based solely on the signatory's personal knowledge and he/she is not required to make an independent investigation as to the relationship of those who have a financial interest In the Firm.]; and (4) no elected and/or appointed official or employee of the City of South Miami. or any of their immediate family members (i.e., spouse. parents, children, brothers and sisters) has a financial interest. directly or indirectly, in the contract between you and/or your Firm and the City other than the following individuals whose interest is set forth following their use a separate names! ._-:-:,.,--..JNl.!!£/A"-::-_-:_--:-_--.c_-::-__ '"'""-::---: ___ _ (if necessary. use a separate sheet to supply additional information that will not fit on this line; however, yau must make reference, on the abave line. to the additional sheet and the additional sheet must be signed under oath). The names of all City employees and that of all elected and/or appointed city officials or board members, who own, directly or indirectly, an interest of five percent (5%) or more of the total assets of capital stock in the firm are as follows: N/A (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded. the statement in this section (4) shall be based solely on the signatory's personal knowledge and he/she is not required to make an independent investigation as to the financial interest in the Firm of city employees, appointed officials or the immediate family members of elected and/or appointed official or employee.] (5) I and the Firm further agree not to use or attempt to use any knowledge. property or resource which may come to us through our position of trust, or through our performance of our duties under the terms of the contract with the City, to secure a special privilege, benefit, or exemption for ourselves, or others. We agree that we may not disclose or use Information, not available to members of the general pUblic, for our personal gain or benefit or for the personal gain or benefit of any other person or business entity, outside of the normal gain or benefit anticipated through the performance of the contract. (6) I and the Firm hereby acknowledge that we have not contracted or transacted any business with the City or any person or agency acting far the City, and that we have not appeared in representation of any third party 21 --~~--------~ ---~~~ before any board, commission or agency of the City within the past two years other than as follows: N/A (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). X:lPurchasinglVendor RegistrationIl2.28.12 RELATED PARTY TRANSACTION VERIFICATION FORM [3].docx (7) Neither I nor any employees. officers, or directors af the Firm, nor any of their immediate family (i.e., as a spouse, son, daughter, parent, brother or sister) is related by blood or marriage to: (i) any member of the City Commission; (ii) any City employee; or (iii) any member of any board or agency of the City other than as follows: N/A (if necessary, use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above 1·lne, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (7) shall be based solely on the Signatory's personal knowledge and helshe is not required to make an independent investigation as to the relationship by blood or marriage of employees, officers, or directors of the Firm, or of any of their immediate family to any appointed or elected officials of the City, or to their immediate family members]. (8) No Other Firm, nor any officers or directors of that Other Firm or anyone who has a financial interest greater than 5% In that Other Firm, nor any member of those persons' immediate family (I.e .• spouse, parents. children, brothers and sisters) nor any of my immediate family members (hereinafter referred ta as "Related Parties") has responded to a solicitation by the City in which I or the Firm that I represent or anyone who has a financial interest greater than 5% in the Firm. or any member of those persons' immediate family (i.e. spouse, parents. children, brothers and sisters) have also responded, other than the following: ~ ~ necessary. use a separate sheet to supply additional information that will not fit on this line; however, you must make reference, on the above line, to the additional sheet and the additional sheet must be signed under oath). [while the ethics code stiil applies, if the person executing this form Is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (8) shall be based solely on the signatory's personal knowledge and he/she is not required to make an independent investigation into the Other Firm, or the Firm he/she represents. as to their officers, directors or anyone having a financial interest in those Firms or any of their any member of those persons' immediate family.] (9) I and the Firm agree that we are obligated to supplement this Verification Form and inform the City of any change in circumstances that would change our answers to this document. Specifically, after the opening of any responses to a solicitation. I and the Firm have an obligation to supplement this Verification Form with the name of all Related Parties who have also responded to the same solicitation and to disclose the relationship of those parties to me and the Firm. (10) A violation of the City's Ethics Code, the giving of any false information or the failure to supplement this Verification Form, may subject me or the Firm to immediate termination of any agreement with the City, and the impOSition of the maximum fine and/or any penalties allowed by law. Additionally. Violations may be considered by and subject to action by the Miami-Dade County Commission on Ethics. Under penalty of perjury, I declare that I have made a diligent e to investigate the matters to which I am attesting hereinabove and that the statements made here rue.. a d carr 0 the best of m owledge, information and belief. Print me & Title: Monica Hernandez, President Date: 8113115 22 PRESENTATION TEAM DECLARATION/AFFIDVAIT OF REPRESENTATION This affidavit is not required for compliance with the City's Solicitation; however, it may be used to avoid the need to register members of your presentation team as lobbyists. Pursuant to City Ordinance 28-14- 2206 (c)(9), any person who appears as a representative for an Individual or firm for an oral presentation before a City certification, evaluation, selection, technical review or similar committee, shall list on an affidavit provided by the City staff, all individuals who may make a presentation. The affidavit shall be filed by staff with the Clerk's office at the time the committee's proposal is submitted to the City Manager. For the purpose of this subsection only, the listed members of the presentation team, with the exception of any person otherwise required to register as a lobbyist, shall not be required to pay any registration fees. No person shall appear before any committee on behalf of an anyone unless he or she has been listed as part of the firm's presentation team pursuant to this paragraph or unless he or she is registered with the City Clerk's office as a lobbyist and has paid all applicable lobbyist registration fees. Pursuant to '92.525(2), Florida Statutes, the undersigned, Monica Hernandez, makes the following declaration under penalty of perjury: Listed below are all individuals who may make a presentation on behalf of the entity that the affiant represents. Please note; No person shall appear before any committee on behalf of anyone unless he or she has been listed as part of the firm's presentation team pursuant to this paragraph or unless he or she 15 registered with the Clerk's office as a lobbyist and has paid all applicable lobbyist registration fees. Monica Hernandez President Nestor Hernandez Vice President For the purpose of this Affidavit of Representation only, the listed members of the presentation team, with the exception of any person otherwise required to register as a lobbyist, shall not be required to pay any registration fees. The Affidavit of Representation shall be filed with the City Clerk's office at the time the committee's proposal is submitted to the City as part of the procurement process. Under penalties of perjury, I declare that I have read the foregoing declaration and that the facts stated in it are true and specifically that the persons listed above are the members of the presentation team of the entity listed below nature of Representative Monica Hernandez, President Print Name and Title August 23 Coreland Construction Corp. Print name of entity being represented 1.01 A B. EXHIBIT 2 Insurance & Indemnification Requirements Insurance Without limiting its liability, the contractor. consultant or consulting firm (hereinafter referred to as "FIRM" with regard to Insurance and Indemnification requirements) shall be required to procure and maintain at its own expense during the life of the Contract, insurance of the types and in the minimum amounts stated below as will protect the FIRM, (rom claims which may arise out of or result from the contract or the performance of the contract with the City of South Miami, whether such claim is against the FIRM or any sub-contractor, or by anyone directly or Indirectly employed by any of them or by anyone for whose acts any of them may be liable. No insurance reqUired by the CITY shall be issued or written by a surplus lines carrier unless authorized in writing by the CITY and such authorization shall be at the CITY's sole and absolute discretion, The FIRM shall purchase insurance from and shall maintain the insurance with a company or companies lawfully authorized to sell insurance in the State of Florida, on forms approved by the State of Florida, as will protect the FIRM, at a minimum, from all claims as set forth below which may arise out of or result from the FIRM's operations under the Contract and for which the FIRM may be legally liable, whether such operations be by the FIRM or by a Subcontractor or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable: (a) claims under workers' compensation. disability benefit and other similar employee benefit acts which are applicable to the Work to be performed; (b) claims for damages because of bodily injury, occupational sickness or disease, or death of the FIRM's employees; (c) claims (or damages because of bodily injury, sickness or disease, or death of any person other than the FIRM's employees; (d) claims for damages insured by usual personal injury liability coverage; (e) claims for damages, other than to the Work Itself, because of injury to or destruction of tangible property. including loss of use resulting there from; (f) claims for damages because of bodily injury. death of a person or property damage ariSing out of ownership. maintenance or use of a motor vehicle; (g) claims for bodily Injury or property damage arising out of completed operations; and (h) claims involVing contractual liability insurance applicable to the FIRM's obligations under the Contract. 1,02 Firm's Insurance Generally" The FIRM shall provide and maintain in force and effect until all the Work to be performed under this Contract has been completed and accepted by CITY (or for such duration as is otherwise specified hereinafter), the insurance coverage written on Florida approved forms and as set forth below: 1.03 Workers' Compensation Insurance at the statutory amount as to all employees in compliance with the 'Workers' Compensation Law" of the State of Florida including Chapter 440, Florida Statutes, as presently written or hereafter amended, and all applicable federal laws, In addition, the policy (ies) must include: Employers' liability at the statutory coverage amount, The FIRM shall further insure that all of its Subcontractors maintain appropriate levels of Worker's Compensation Insurance, 1,04 Commercial Comprehensive General liability insurance with broad form endorsement, as well as automobile liability, completed operations and products liability, contractual liability, severability of interest with cross liability provision, and personal injury and property damage liability with limits of $1 ,000,000 comb"lOed single limit per occurrence and $2,000,000 aggregate, including: • Personal Injury: $1,000,000; • Medical Insurance: $5,000 per person; • Property Damage: $500,000 each occurrence; 1,05 Umbrella Commercial Comprehensive General liability insurance shall be written on a Florida approved form with the same coverage as the primary insurance policy but in the amount of $1 ,000,000 per claim and $2,000,000 Annual Aggregate, Coverage must be afforded on a form no more restrictive than the latest edition of the Comprehensive General Liability policy, without restrictiVe endorsements, as filed by the Insurance Services Office, and must Include: (a) Premises and Operation (b) Independent Contractors 24 (c) Products andlor Completed Operations Hazard (d) Explosion, Collapse and Underground Hazard Coverage (e) Broad Form Property Damage (f) Broad Form Contractual Coverage applicable to this specific Contract, including any hold harmless and/or indemnification agreement. (g) Personal Injury Coverage with Employee and Contractual Exclusions removed, with minimum limits of coverage equal to those required for Bodily Injury liability and Property Damage liability. 1.06 Bysiness Automobile Liability with minimum limits of One Million Dollars ($1,000,000.00) plus an additional One Million Dollar ($1,000,000.00) umbrella per occurrence combined single limit for Bodily Injury liability and Property Damage Uability. Umbrella coverage must be afforded on a form no more restrictive than the latest edition of the Business Automobile L1ability policy, without restrictive endorsements, as filed by with the state of Florida. and must include: (a) Owned Vehicles. (b) Hired and Non-Owned Vehicles (c) Employers' Non-Ownership 1.07 SUBCONTRACTS' The FIRM agrees that if any part of the Work under the Contract is sublet, the subcontract shall contain the same insurance provision as set forth in section 5.1 above and SA below and substituting the word Subcontractor for the word FIRM and substituting the word FIRM for CITY where applicable. 1.08 Fire and Extended Coverage Insurance (Byilders' Risk), IF APPLICABLE: A. In the event that this contract involves the construction of a structure, the CONTRACTOR shall maintain. with an Insurance Company or Insurance Companies acceptable to the CITY, "Broad" form/All Risk Insurance on buildings and structures, Including Vandalism & Malicious Mischief coverage. while in the course of construction, Including foundations, additions, attachments and all permanent fixtures belonging to and constituting a part of said buildings or structures. The policy or policies shall also cover machinery, if the cost of machinery is included in the Contract, or if the machinery is located in a building that is being renovated by reason of this contract. The amount of insurance must, at all times, be at least equal to the replacement and actual cash value of the insured property. The policy shall be in the name of the CITY and the CONTRACTOR, as their interest may appear, and shall also cover the interests of all Subcontractors performing Work. B. All of the provisions set forth in Section 5.4 herein below shall apply to this coverage unless it would be clearly not applicable. 1.09 Miscellaneous: A. If any notke of cancellation of insurance or change in coverage is issued by the insurance company or should any insurance have an expiration date that will occur during the period of this contract, the FIRM shall be responsible for securing other acceptable insurance prior to such cancellation, change, or expiration so as to provide continuous coverage as specified in this section and so as to maintain coverage during the life of this Contract. B. All deductlbles must be declared by the FIRM and must be approved by the CITY. At the option of the CITY, either the FIRM shall eliminate or reduce such deductible or the FIRM shall procure a Bond, in a form satisfactory to the CITY covering the same. C. The policies shall contain waiver of subrogation against CITY where applicable, shall expressly provide that such policy or policies are primary over any other collectible insurance that CITY may have. The CITY reserves the right at any time to request a copy of the reqUired policies for review. All policies shall contain a "severability of interest" or "cross liability" clause without obligation for premium payment of the CITY as well as contractual liability provision covering the Contractors duty to indemnify the City as prOVided in this Agreement, D. Before starting the Work, the FIRM shall deliver to the CITY and CONSULTANT certificates of such insurance, acceptable to the CITY, as well as the insurance binder, if one is issued, the insurance policy, including the declaration page and all applicable endorsements and provide the name, address and telephone number of the insurance agent or broker through whom the policy was obtained. The insurer shall be rated A.VII or better per AM. Best's Key Rating Guide, latest edition and authorized to issue insurance in the State of Florida. All insurance polides must be written on forms approved by the State of Florida and they must remain in full force and effect for the duration of the contract period with the CITY. The FIRM may be required by the CITY, at its sole discretion, to provide a "certified copy" 01 the Policy (as defined in Article I of this document) which shall include the declaration page and all reqUired 25 endorsements, In addition, the FIRM shall deliver, at the time of delivery of the insurance certificate, the following endorsements: (I) a policy provision or an endorsement with substantially similar provisions as follows: "The City of South Miami is an additional insured. The insurer shall pay all sums that the City of South Miami becomes legally obligated to pay as damages because of lbodily injury", lproperty damage' • or "personal and advertising Injury" and it will provide to the City all of the coverage that is typically provided under the standard Florida approved forms for commercial general liability coverage A and coverage B"j (2) a polley provision or an endorsement with substantially similar provisions as follows: "This policy shall not be cancelled (including cancellation for non-payment of premium), terminated or materially modified without first giving the City of South Miami ten (10) days advanced written notice of the intent to materially modify the policy or to cancel or terminate the policy for any reason. The notification shall be delivered to the City by certified mail, with proof of delivery to the City." E. If the FIRM is providing professional services, such as would be prOVided by an architect. engineer. attorney, or accountant, to name a few, then in such event and in addition to the above requirements, the FIRM shall also provide Professional liability Insurance on a Florida approved form in the amount of $1,000,000 with deductible per claim if any, not to exceed 5% of the limit of liability providing for all sums which the FIRM shall become legally obligated to pay as damages for claims ariSing out of the services or work performed by the FIRM its agents, representatives, Sub Contractors or assigns, or by any person employed or retained by him in connection with this Agreement. This insurance shall be maintained for four years after completion of the construction and acceptance of any Project covered by this Agreement. However, the FIRM may purchase Specific Project Professional liability Insurance, in the amount and under the terms speCified above, which is also acceptable. No insurance shall be issued by a surplus lines carrier unless authorized in writing by the city at the city's sole, absolute and unfettered discretion. Indemnification Requirement A The Contractor accepts and voluntarily incurs all risks of any injuries, damages, or harm which might arise during the work or event that is occurring on the CITY's property due to the negligence or other fault of the Contractor or anyone acting through or on behalf of the Contractor. B. The Contractor shall indemnify, defend, save and hold CITY, its officers, affiliates, employees, successors and assigns, harmless (rom any and all damages, claims, liability. losses. claIms, demands. suits, fines, judgments or cost and expenses, including reasonable attorney's fees, paralegal fees and investigative costs incidental there to and incurred prior to, during or following any litigation, mediation, arbitration and at all appellate levels. which may be suffered by. or accrued against. charged to or recoverable from the City of South Miami, its officers, affiliates. employees, successors and assigns, by reason of any causes of actions or claim of any kind or nature, including claims for injury to, or death of any person or persons and for the loss or damage to any property arising out of a negligent error, omission, misconduct, or any gross negligence, intentional act or harmful conduct of the Contractor. its contractor/subcontractor or any of their officers, directors, agents, representatives, employees, or assigns, or anyone acting through or on behalf of any of them, arising out of this Agreement, incident to it, or resulting from the performance or non~performance of the Contractor's obligations under this AGR.EEMENT. c. The Contractor shall pay all claims, losses and expenses of any kind or nature whatsoever, in connection therewith, including the expense or loss of the CITY and/or its affected officers, affiliates, employees. successors and assigns, including their attorney's fees, in the defense of any action in law or eqUity brought against them and arising from the negligent error, omission, or act of the Contractor, its Sub-Contractor or any of their agents, representatives. employees. or assigns, and/or arising out of, or incident to, this Agreement. or incident to or resulting from the performance or non-performance of the Contractor's obligations under this AGREEMENT. D. The Contractor agrees and recognizes that neither the CITY nor its officers, affiliates, employees, successors and assigns shall be held liable or responsible for any claims, Including the costs and expenses of defending such claims which may result from or arise out of actions or omissions of the Contractor, its contractor/subcontractor or any of their agents, representatives, employees, or assigns, or anyone acting through or on behalr of the them, and ariSing out of or concerning the work or event that is occurring on the CITY's 26 property. In reviewing, approving or rejecting any submissions or acts of the Contractor. CITY in no way assumes or shares responsibility or liability for the acts or omissions of the Contractor. its contractor/subcontractor or any of their agents, representatives, employees, or assigns, or anyone acting through or on behalf of them. E. The Contractor has the duty to provide a defense with an attorney or law firm approved by the City of South Miami, which approval will not be unreasonably withheld. F. However, as to design professional contracts, and pursuant to Section 725.08 (I), Florida Statutes, none of the provisions set forth herein above that are in conflict with this subparagraph shall apply and this subparagraph shall set forth the sale responsibility of the design professional concerning indemnification. Thus, the design professional's obligations as to the City and its agencies, as well as to its officers and employees, is to indemnify and hold them harmless from liabilities, damages, losses, and costs, including. but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the design professional and other persons employed or utilized by the design professional in the performance of the contract. END OF SECTION 27 Addendum No.2 REVISED: July 30, 2015 EXHIBIT 4 Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW·20 I 5·20 THIS PROPOSAL IS SUBMITTED TO: Steven Alexander City Manager City of South Miami 6130 Sunset Drive South Miami, FL 33143 CONSTRUCTION BID FORM I. If this Proposal is accepted, the undersigned Respondent agrees to enter into a Contract with the City of South Miami in the form Included in this Solicitation Package and to perform and furnish all work as specified or indicated in this Solicitation, including as set forth in Exhibit I (Scope of Services) for the Proposed Price as set forth below, within the Contract Time and in accordance with the other terms and conditions of the Solicitation Package. 2. Respondent accepts all of the terms and conditions of the Solicitation and Instructions to Respondents, including without limitation those dealing with the disposition of Proposal/Bid Bond, if required. This Proposal will remain subject to acceptance for 180 calendar days after the day of the Proposal Opening. The Respondent, by signing and submitting this proposal, agrees to all of the terms and conditions of the form of contract that is a part of the Solicitation package with appropriate changes to conform to the information contained in this Bid Form. Respondent agrees to sign and submit the Bonds, If required by this Solicitation, required Insurance documents, and other documents required by the Solicitation, including the Contract if not already submitted, within ten (10) calendar days after the date of the City's Notice of Award. 3. In submitting this Proposal, Respondent represents that: a. Respondent has examined copies of all the Solicitation Documents and of the folloWing Addenda. If any (receipt of all which is hereby acknowledged.) 01 7/28/15 Addendum No. 02 Dated: 7/30/15 03 8104715 b. Respondent has familiarized himself with the nature and extent of the Contract Documents, the proposed work, site, locality, and all local conditions and laws and regulations that in any manner may affect cost, progress, performance or furnishing of the Work. c. Subsurface conditions: If applicable to this Solicitation, the Respondent represents that: i. Respondent has studied carefully all reports and drawings, if applicable, of subsurface conditions and drawings of physical conditions. ii. Respondent has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying) all such examinations, investigations, explorations, tests and studies in addition to or to supplement those referred to in this paragraph which pertain to the subsurface or physical conditions at the site or otherwise may affect the cost, progress, performance, or the furnishing of the Work at the Contract Price, within the Contract Time and In accordance with the other terms and conditions of the Contract Documents. The Respondent hereby acknowledges that no additional examinations, investigations, explorations. tests, reports or similar information or data are, or will, be required by Respondent for any reason in connection with the Proposal. The failure Page2of4 28 of the Respondent to request a pre-bid marking of the construction site by any or all utility companies shall create an irrefutable presumption that. the Respondent's bid, or proposal price, has taken into consideration all possible underground conditions and Respondent, if awarded the contract, shall not be entitled to a change order for any such condition discovered thereafter. iii. Respondent has correlated the results of all such observations, examinations, investigations, explorations, tests, reports and studies with the terms and conditions of the Contract Documents. iv. Respondent has reviewed and checked all information and data shown or indicated in the Solicitation Package or In the Contract Documents with respect to existing Underground Facilities or conditions at or contiguous to the site and assumes responsibility for the accurate location of all Underground Facilities and conditions that may affect the Work. No additional examinations, investigations, explorations, tests, reports or simliar information or data in respect to any Underground Facillties or conditions are, or will be, required by Respondent in order to perform and furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents unless the Proposal specifically states that the contract price is subject to adjustment for future discovery of underground facilities and/or conditions that affect the cost of the Work and unless the respondent makes a written request to the City for additional information prior to submitting the bid or proposal as required in subsection ii above, d. Respondent has given the City written notice of all conflicts, errors or discrepancies that it has discovered in the Contract Documents and, if any conflicts, errors or discrepancies have been found and natice given, the Respondent represents, by submitting its proposal ta the City, that the Respondent has received sufficient notice of the resolution thereof from the City. that such resolution is acceptable to Respondent and that the Respondent waives any claim regarding the conflicts, errors or discrepancies. e. This Proposal is genuine and not made in the interest of or on behalf of any undisclosed person, firm or corporation and is not submitted pursuant to any agreement or rules of any group, association, organization. or corporation; Respondent has not directly or indirectly induced or solicited any other Respondent to submit a false or sham Proposal; Respondent has not solicited or induced any person, firm or corporation to refrain from responding: and Respondent has not sought by collusion or otherwise to obtain for itself any advantage over any other Respondent or over the CITY, 4. Respondent understands and agrees that the Contract Price is the amount that it needs to furnish and install all of the Work complete and in place. The Schedule of Values, if required, is provided for the purpose of Proposal Evaluation and when initiated by the CITY, it shall form the basis for calculating the pricing of change orders. The Contract Price shall not be adjusted in any way so as to result in a deviation from the Schedule of Values, except to the extent that the CITY changes the Scope of the Work after the Contract Date. As such, the Respondent shall furnish all labor, materials, equipment, tools, superintendence and services necessary to provide a complete, in place, Project for the Proposal Price. If this Solicitation requires the completion of a Cost and Technical Proposal, as may be set forth in S. +an exhibit to this Solicitation, such proposal must be attached to this Bid Form and will take the place of the Lump Sum Price, otherwise, the Contract Price for the completed work is as follows: (I) LUMP SUM BASE PRICE (Entire Project): $----"6"'9"',9:...:7.;;3"'.0"-'0<--______ _ Alternates: #1 _______ #2 __________ _ (2) LUMP SUM BASE PRICE (Without Traffic Calming Cirde): $ ........:4.::0'-',3:...4:.:2:.:..0=-0=---___ _ Alternates: #1 _______ #2 __________ _ Page 3 of4 29 A fee breakdown for each task included in the lump sum contract price, if applicable, must be provided, Failure to provide this information shall render the proposal non-responsive, 6, The ENTIRE WORK shall be completed, in full, within 75 calendar days from the commencement date set forth in the NOTICE TO PROCEED, Failure to complete the entire work during the described time period shall result in the assessment of liquidated damages as may be set forth in the Contract. 7. Insert the following information for future communication with you concerning this Proposal: RESPONDENT: Coreland Construction Corp, Address: 12301 SW 128 Court, #107 I Miami, FL 33186 Telephone: 305-233-1709 Facsimile: 305-233-1809 Contact Person Monica Hernandez 8. The terms used in this Proposal which are defined in the Contract shall have the same meaning as is assigned to them in the Contract Documents, unless specifically defined In this Solicitation Package. 9, If a cost & technical proposal is required by the Solicitation, Respondent hereby certifies that all of the facts and responses to the questions posed in the cost & technical proposal, if such an exhibit is made a part of the Solicitation, are true and correct and are hereby adopted as part of this Bid Form, and are made a part of this proposal, by reference. 10., By submitting this proposal, I, on behalf of the business that I represent, hereby agree to the terms of the form of contract contained In the Solicitation package and I agree to be bound by those terms, with any appropriate blank boxes, if any, checked and any blank lines filled in with the appropriate information contained in the Solicitation Documents and this Proposal, or such information that the City and 1 have agreed upon in the course of contract negotiations and which have been confirmed by the City in writing, including e-mail confirmation, if any, I hereby certify under penalty of perjury that I am the lawful representative of the business entity referenced in this Bid Form that I have authority to bid that entity and that all of the information and representations contained herein are true and correct to the best of my information and belief, SUBMITTED THIS 13th DAY OF --- PROPOSAL SUBMITTED BY: Coreland Construction Corp, Company Monica Hernandez horized to Submit _A---,U9,--u_s_t ______ 20lL, 305-233-1709 Telephone Number 305-233-1809 Fax Number mh@corelandconstruction,com Email Address Page 4 of4 30 City of South Miami Mango Terrace Neighbourhood Traffic Calming Improvements - Schedule of Values Entire Project PAY ITEM PAY ITEM DESCRIPTION Ie 01-1 102-1 110-1'::;- 210-: 285-~ 327-70-1 334-1-13 164-4 520-2- lr1<ing Base (8'? new driveway 1(12" Limerock LBR 100, new drivewa :>AVEMENT (0.5" AVERAGE) ,TRAFFIC C (11C 520-2· 57Q.1-, 0526-1- )NCRETE • ............ FORMAr :) (RaiSe( Y Bricks 1.6" d SO!=Ia~) "8" "0" :00 d IslandS) 0700-20-12 ::. POST SIGN:FS'I, 12-20 SF-:-Traffic Circle •. NGLE POST SIGN, F&I, 12-20 SF- 0700-48-48 SIGN PANELS RELQ( 0706-3 RETRO-REFLECnVE 6" SOLID TRAFFIC Sl )UD TRAFFIC STRIPE (WHITE) H-6131 6-~KJP 4 TRAFFIC STRIPE ITEl 1-1-1180 STANDARD, WHITE, YIELD LINE 1-1-6211 6" SOUD TRAFFIC STRIPE _>'>'4 "" ","ULll.I , ......... FIC Sl 1-11_224 18" SOLID TRAFr-u ... .::> I n.1 .... e' ,.J (~ ~bles 3.S' Avg and, I y-~: UNIT Inl~-~- LS LS -1§ SY SY SY TN Tv 'M _ 1 E- 298 178 UNIT PRICE . 2,000.00 1,500.00 12.00 6 225. 200 . 100 5.0( COST Me 10_00 i5:OO o!? nn ____ TOTAL I $ 69,97:3.00 31 EXHIBIT 5 CONSTRUCTION CONTRACT Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW-20 15-20 THIS CONTRACT was made and entered into on this day of • 20 __ • by and between Coreland Construction Corp. (hereafter referred to as "Contractor"). and the City of South Miami (hereafter referred to as "Owner"). through its City Manager (hereafter referred to as "City"). WITNESETH: That, the Contractor, for the consideration hereinafter fully set out, hereby agrees with the Owner as follows: I. The Contractor shall furnish all labor, materials, equipment. machinery, tools, apparatus, transportation and any other items necessary to perform all of the work shown on and described in the Contract Documents and shall do everything required by this Contract and the other Contract Documents hereinafter referred to as the Work. 2. The Contract Documents shall include this Contract, General Conditions to the Contract. if any. the drawings, plans, specifications and project manual, if any, any supplementary or special conditions, other documents referring to this contract and signed by the parties, the solicitation documents ("hereinafter referred to as "Bid Documents") and any documents to which those documents refer which are used by the Owner as well as any attachments or exhibits that are made a part of any of the documents described herein. 3. The Contractor shall commence the Work to be performed under this Contract on a date to be specified in a Notice to Proceed and shall complete all Work hereunder within the length of time set forth in the Contract Documents. 4. The Owner hereby agrees to pay to the Contractor for the faithful performance of this Contract, subject to additions and deductions as provided in the Contract Documents and any properly approved, written change orders, in lawful money of the United States, the amount of: (Spell Dollar Amount h&.) Dollars ($ .OO~. Lump Sum ("Contract Price"). 5. The expenses of performing Work after regular working hours. and on Sunday and legal holidays shall be included in the Contract Price. The City may demand. at any point in time. that any part. or all. of the Work be performed after regular working hours. In such event, the Respondent shall have no right to additional compensation for such work. However, nothing contained herein shall authorize work on days and during hours that are otherwise prohibited by ordinance unless specifically authorized or instructed in writing by the City. 6. If the Work is expected to require more than one month, the Owner shall make monthly partial payments to the Contractor on the basis of a duly certified and approved schedule of values for the Work performed during each calendar month by the Contractor. less the retainage (all as provided for In the Contract Documents), which is to be withheld by the Owner until completion and acceptance of the complete project in accordance with this Contract and the other Contract Documents and until such Work has been accepted by the City. 7. Upon submission by the Contractor of evidence satisfactory to the Owner that all labor. material. and other costs incurred by the Contractor in connection with the construction of the Work have been paid in full, and after compliance with the terms for payment provided for in the Contract Documents, final payment on account of this Contract shall be made within sixty (60) calendar days after the completion by the Contractor of all Work covered by this Contract and the acceptance of such Work by the Owner. 8. The Work shall be completed in 75 calendar days. In the event that the Contractor shall fall to complete the Work within the time limit stipulated in the Contract Documents, or the extended time limit agreed upon, in accordance with the procedure as more particularly set forth in the Contract Documents, liquidated damages shall be paid by the Contractor at the rate of $ dollars per day. plus any monies paid by the Owner to the Consultant, if any, for additional engineering and inspection services. if any, associated with such delay. 32 9. It is further mutually agreed between the parties hereto that if a Payment andlor Performance Bond ("Bond") is required and if, at any time after the execution of this Contract and the Bond for its faithful performance and payment, the City shall deem the Surety or Sureties upon such bond(s) to be unsatisfactory, or if, for any reason such bond ceases to be adequate to cover the performance of the Work or payment to subcontractors and suppliers, the Contractor shall, at its expense within five (5) business days after the receipt of notice from the City so to do, furnish an additional bond or bonds in such form and amount and with such Surety or Sureties as shall be satisfactory to the City. In such event. no further payment to the Contractor shall be deemed to be due under this Contract until such new or additional security for the faithful performance of the Work is furnished in the manner and in the form satisfactory to the City. 10. No additional Work or extras shall be done unless the same is duly authorized in writing, and in advance of the work, by appropriate action by the City and in accordance with the Contract Documents. I I. The date that this contract was "made and entered into" and its effective date is the date that the contract is the signed by the City or, if the contract is required to be approved by resolution of the City Commission, then the Effective Date is the date of the resolution approving the Contract whichever is the later date. IN WITNESS WHEREOF, the parties hereto have executed this Contract on the day and date set forth next to their name below and may be signed in one or more counterparts, each of which shall, without proof or accounting for the other counterpart, be deemed an original Contract. ATIESTED: Signature: __________ _ Maria Menendez City Clerk Read and Approved as to Form, Language, Legality, and Execution Thereof: Signature: ---::::--:-________ _ City Attorney 33 OWNER: CITY OF SOUTH MIAMI Signature: Steven Alexander City Manager EXHIBIT 7 CONSTRUCTION CONTRACT GENERAL CONDITIONS Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW-20 I 5-20 ARTICLE I -DEFINITIONS Whenever used in these General Conditions or in the other Contract Documents, the following terms shall have the meaning indicated. These definitions shall always apply when the section of the Contract specifically refers to this Article for the purpose of interpreting a word or group of words in that section of the Contract Document. However, when the section of the Contract, where the word to be deflned is used, does not specifically refers to this Article to define the word or group of words, the definitions contained in this Article shall not apply unless the word or group of words, in the context of it or their use in the Contract Document in question, is/are ambiguous and open for interpretation. In addition, these definitions shall also not apply to interpret terms in a specific provision of a Contract Document if that specific provision contains a definition of these terms: Addenda: Written or graphic documents issued prior to the Bid Opening which modify or interpret the Contract Documents, Drawings and Specifications, by addition, deletions, clarifications or correction. Application for Payment: A form approved by the CONSULTANT. if any, or the City Manager which is to be used by the CONTRACTOR in requesting progress payments. IDQ.;. The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices and other terms for the Work to be performed. ~ Any person, firm or corporation submitting a response to the Owner's solicitation for proposals or bids for Work. Bid Documents: The solicitation for bids or proposals and all documents that make up the solicitation including the instructions. form of documents and affidavits. ~ Bid bond, performance and payment bonds and other Instruments of security, furnished by the CONTRACTOR and its surety in accordance with the Contract Documents and in accordance with the laws of the State of Florida. Change Order: A written order to the CONTRACTOR signed by the City Manager authorizing an addition, deletion or revision in the Work, or an adjustment in the Contract Price or the Contract Time issued after execution of the Contract. Work Order Proposals: Written proposals from the CONTRACTOR in response to orders or request for work based on the Scope of the Work prOVided by the City to the CONTRACTOR. The proposal Includes line item pricing, where there are multiple locations, and the timeframe for completing the work. QIY; The City Manager for the City of South Miami, 6130 Sunset Drive, South Miami, FL 33143. unless the context wherein the word Is used should more appropriately mean the City of South Miami. Construction Observer: An authorized representative of the CONSULTANT. if any, or otherwise a representative of the City assigned to observe the Work performed and materials furnished by the CONTRACTOR. The CONTRACTOR shall be notified in writing of the identity of this representative. Contract Documents: The Contract Documents shall include the Contract between the Owner and the Contractor, other documents listed in the Contract and modifications issued after execution of the Contract as well as all Bid Documents Including but not limited to the solicitation for Bid, CONTRACTOR'S Bid, the Bonds, Insurance endorsements. Insurance Certificates and policies, the Notice of Award, the Notice to Proceed, the General Conditions, Special Conditions, If any, any Supplementary Conditions, the Technical Specifications, DraWings. including any incorporated specifications, addenda to the drawings issued prior to execution of the Contract, Change Orders. Construction Change Directives and any written order for a minor change in the Work. and written modifications to any olthe Contract Documents. Contract Price: The total moneys payable to the CONTRACTOR pursuant to the terms of the Contract Documents. Contract Time: The number of calendar days stated in the Contract for the completion of the Work. Contracting Officer: The individual who is authorized to sign the contract documents on behalf of the OWNER. CONTRACTOR: The person, firm or corporation with whom the OWNER has executed the Contract. CONSULTANT: The person identified as the CONSULTANT in the Supplementary Conditions or, if none, then CITY's designated representative as identified in the Supplementary Conditions. 34 ~ A period of twenty-four hours measured from the beginning of the day at 12:01 a.m. and it shall be presumed to be a calendar day unless specifically designated as a business day. Days: The number of twenty-four (24) hour periods following the event to which the word "days" refers commencing at 12:01 a.m. at the start of the next day. Therefore, in computing any period of time prescribed or allowed by the Contract Documents, the day of the act, event or default from which the designated period of time begins to run shall not be included. The last day of the period so computed shall be included unless it is a Saturday, Sunday or legal holiday, in which event the period shall run until the end of the next business day that is not a Saturday, Sunday or legal holiday. Defectjye Work: Work that is unsatisfactory. fautty. or deficient in that it does not conform to the Contract Documents, or does not meet the reqUirements of any applicable inspection, reference standard, test. or approval referred to in the Contract Documents, or has been damaged prior to the CONSULTANTS recommendation of final payment (unless responsibility for the protection thereof has been delegated to the Owner); substitutions that are not properly approved and authorized, any deficiency in the Work, materials and equipment: materials and equipment furnished under the Contract that are not good quality and new unless otherwise required or permitted by the Contract Documents. Drawings: The drawings which show the character and Scope of the Work to be performed and which have been prepared or approved by the CONSULTANT, or if none, then by an architect or engineer hired by the City and are referred to in the Contract Documents. Field Order: A written order issued by the CONSULTANT which clarifies or interprets the Contract Documents in accordance with Paragraph 9.3 or orders minor changes in the Work in accordance with paragraph 10.2. Modification: (a) A written amendment of the Contract Documents signed by both parties, (b) a Change Order signed by both parties. (c) a written clarification or interpretation if issued by the CONSULTANT in accordance with paragraph 9.3 or (d) a written order for minor change or alteration in the Work issued by the CONSULTANT pursuant to Paragraph 10.2. A modification may only be issued after execut'lon of the Contract, it must be in writing and signed by the party against whom the modification is sought to be enforced. Non-conforming Work means work that does not conform to the Contract Documents and includes work that is unsatisfactory. faulty, or deficient or that does not meet the requirements of any applicable Inspection, reference standard, test, or that does not meet any approval reqUired by. or referred to in, the Contract Documents, or work that has been damaged prior to CONSULTANT's recommendation of final payment (unless responsibility for the protection thereof has been assumed in writing by CITY). Notice of Award: The written notice by CITY to the apparent successful Bidder stating that upon compliance with the conditions precedent to be fulfilled by it within the time speclfied, CITY will execute and deliver the Contract to him. Notice to Proceed: A written notice given by CITY to CONTRACTOR (with copy to CONSULTANT) fixing the date on which the Contract Time shall commence to run and on which CONTRACTOR shall start to perform its obligations under the Contract Documents. Person: An individual or legal entity. Project: The entire construction operation being performed as delineated in the Contract Documents. ~ The term "policy" as used in the Contract Documents shall mean the insurance binder, if it is issued. the declaration page of the policy and the body of the policy, including all endorsements. REf: Request for Proposal. Scope of Services .. This phrase refers to the scope of the services or work to be performed and it has the same meaning as Scope of the Work unless the context in which the phase is used dearly means otherwise. Shop Drawings: All drawings, diagrams, Illustrations, brochures, schedules and other data which are prepared by the CONTRACTOR, a Subcontractor, manufacturer, supplier, or distributor, and which illustrate the equipment, material or some portion of the work and as required by the Contract Documents. Samples: Physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be Judged. Specifications: Those portions of the Contract Documents consisting of written technical descriptions of materials, equipment, construction systems, standards and workmanship as applied to the Work. Subcontractor: An individual, firm or corporation having a direct contract with CONTRACTOR or with any other Subcontractor for the performance of a part of the Work at the construction site. Substantial Completion: The date, as certified by the CONSULTANT. when the construction of the Project or a certified part thereof is sufficiently completed, in accordance with the Contract Documents, so that the Project. or a substantial part. can be utilized for the purposes for which it was intended without restriction or limitation to any degree. other than for the repair of minor "punch list" items; or if there be no such certification. the date when final payment Is due in accordance with paragraph 14.9. However, in no event shall the project or portion 35 thereof, be deemed to be substantially completed until a certificate of occupancy or certificate of use Is lawfully issued by the applicable governmental agency. A certificate of Substantial Completion, issued by the CONSULTANT, shall be null and void if it is based on false, misleading or inaccurate information. from any source, or when it would not have been issue but for the consideration of Work that is thereafter found to be defective to a degree greater than that which would normally to be considered by the City to be minor "punch list" work. Supplier: Any person or organization who supplies materials or equipment for the Work, including the fabrication of an item, but who does not perform labor at the s1te of the Work. ~ The individual or entity who is an obligor on a Bond and who is bound with the CONTRACTOR for the full and faithful performance of the Contract and for the payment of all labor, services and materials used on the project. Work: Any and all obligations, duties and responsibilities necessary for the successful performance and completion of the Contract. Notice: The term "Notice" as used herein shall mean and include all written notices, demands, instructions, claims, approvals and disapprovals required to obtain compliance with Contract requirements. Written notice shall be deemed to have been duly served if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it Is Intended, or to an authorized representative of such individual, firm, or corporation, or if delivered at or sent by registered mail to the last known business address. Unless otherwise stated in writing, any notice to or demand upon the OWNER under this Contract shall be delivered to the City Manager and the CONSULTANT. ARTICLE 2 -PRELIMINARY MATTERS AYIwt 2.1 The CITY reserves the right to reject any and all Bids, at its sole discretion. Bids shall be awarded by the CITY to the lowest responsive and responsible Bidder. No Notice of Award shall be given until the CiTY has concluded its Investigation, as it deems necessary. to establish, to the satisfaction of the CITY, which Bidder is the most responsive and responsible of all the Bidders to complete the Work within the time prescribed and in accordance with the Contract Documents. The CITY reserves the right to reject the Bid of any Bidder who Is not believed to be, in the sole discretion and satisfaction of the City. to be sufficiently responsible. qualified and financial able to perform the work. In analyzing a Bid, the CITY may also take into consideration alternate and unit prices, if requested by the Bid forms. If the Contract is awarded, the CITY shall issue the Notice of Award and give the successful Bidder a Contract for execution within ninety (90) day after opening of Bids. Execution of Contract: 2.2 At least four counterparts of the Contract, the Performance and Payment Bond, the Certificates of Insurance. the Binder of Insurance If Issued, the Insurance Declaration Page if not included in the Policy of Insurance, the Pollcy of Insurance required by the Contract Documents. the written notice of designated supervisor or superintendent as prOVided in Section 6.1 of the General Conditions and such other Documents as required by the Contract Documents shall be executed and delivered by CONTRACTOR to the CITY within ten (10) calendar days of receipt of the Notice of Award. A Contract Document that requIres the SIgnature of a party may be executed In counterparts separately by each of the parties and. in such event, each counterpart separately executed shall, without proof or accounting for the other counterpart be deemed an original Contract Document. Forfeiture of Bid Security/Performance and Payment Bond if any are reqUired by the applicable RFP: 2.3 Within ten (10) calendar days of being notified of the Award, CONTRACTOR shall furnish a Performance Bond and a Payment Bond containing all the provisions of the Performance Bond and Payment Bond attached. 2.3. I Each Bond shall be in the amount of one hundred percent (100%) of the Contract Price guaranteeing to OWNER the completion and performance of the Work covered in such Contract as well as full payment of all suppliers, material man, laborers, or Subcontractor employed pursuant to this Project. Each Bond shall be with a Surety company whose qualifications meet the reqUirements of Sections 2.3.4, 2.3.5, and 2.3.6. 2.3.2 Each Bond shall continue In effect for five year after final completion and acceptance of the Work with the liability equal to one hundred percent (100%) of the Contract Sum. 36 2.3.3 Pursuant to the requirements of Section 255.05( I), Florida Statutes, CONTRACTOR shall ensure tnat the Bond(s) referenced above shall be recorded in the public records of Miami-Dade County and provide CITY with evidence of such recording. 2.3,4 Each Bond must be executed by a surety company authorized to do business in the State of Florida as a surety, haVing a resident agent In the State of Florida and having been in business with a record of successful continuous operation for a least five (5) years. 2.3.5 The surety company shall hold a current certiftcate of authority as acceptable surety on federal bonds in accordance with the United States Department of Treasury Circular 570, current revisions. 2.3.6 The CITY shall only be required to accept a surety bond from a company with a rating A. VII or better. 2.3.7 Failure of the successful Bidder to execute and deliver the Contract, and deliver the required bonds and Insurance documents shall be cause for the CITY to annul the Notice of Award and declare the Bid and any security therefore forfeited. Contractor's Pre-Start Representation; 2.4 CONTRACTOR represents that it has familiarized itself with. and assumes full responsibility for having familiarized itself with the nature and extent of the Contract Documents, Work, locality, and with all local conditions and federal, state and local laws, ordinance, rules and regulations that may in any manner affect performance of the Work. and represents that it has correlated its study and observations with the requirements of the Contract Documents. CONTRACTOR also represents that it has studied all surveys and investigations, reports of subsurface and latent physical conditions referred to in the specifications and made such additional surveys and Investigations as it deems necessary for the performance of the Work reflected in the Contract Documents and that he has correlated the results of all such data with the reqUirements of the Contract Documents. Commencement of Contract Time: 2.S The Contract Time shall commence to run on the date stated in the Notice to Proceed. Starting the Profect; 2.6 CONTRACTOR shall start to perform its obligations under the Contract Documents on the date the Contract Time commences to run. No Work shall be done at the site (as defined in Article I), prior to the date on which the Contract Time commences to run, except with the written consent of the CITY. Before Starting Construction: 2.7 Before undertaking each part of the Work, CONTRACTOR shall ca.refully study and compare the Contract Documents and check and verify pertinent figures shown thereon and all appUcable field measurements and conditions. It shall at once report in Writing to CONSULTANT any conflict, error, or discrepancy which it may discover. Neither the OWNER nor the CONSULTANT shall be liable for any harm, damage or loss suffered by CONTRACTOR as a result of its failure to discover any conflict, error, or discrepancy in the Drawings or Specifications nor shall the CONTRACTOR be entitle to any compensation (or any harm. damage or loss suffered by the CONTRACTOR due to any conflict, error, or discrepancy in the Contract Documents. Schedule of Completjon: 2.8 Within Five (5) business days after delivery of the Notice to Proceed by CITY to CONTRACTOR, CONTRACTOR shall submit to CONSULTANT for approval, an estimated construction schedule indicating the starting and completion dates of the various stages of the Work. and a preliminary schedule of Shop Drawing submissions. The CONSULTANT shall approve this schedule or reqUire revisions thereto within seven (7) calendar days of Its submittal. If there is more than one CONTRACTOR involved in the Project, the responsibility for coordinating the Work of all CONTRACTORS shall be prOVided in the Special Conditions. 2.9 Within five (5) business days after delivery of the executed Contract by CiTY to CONTRACTOR, but before starting the Work at the site, a pre-construction conference shall be held to review the above schedules, to establish procedures for handling Shop Drawings and other submissions, and for processing Applications for Payment, and to establish a working understanding between the parties as to the Project. 37 Present at the conference will be the CITY'S representative, CONSULTANT, Resident Project Representatives, CONTRACTOR and its Superintendent. Qualifications of Subcontractors Material men and Suppliers: 2.10 Within five (5) business days after bid opening, the apparent lowest responsive and responsible Bidder shall submit to the CITY and the CONSULTANT for acceptance a list of the names of Subcontractors and such other persons and organizations (including those who are to furnish principal items of materials or equipment) proposed for those portions of the Work as to which the identity of Subcontractors and other persons and organizations must be submitted as specified in the Contract Documents. Within thirty (30) calendar days after receiving the list, the CONSULTANT will notify the CONTRACTOR In writing If either the CITY or the CONSULTANT has reasonable objection to any Subcontractor, person, or organization on such list. The failure of the CITY or the CONSULTANT to make objection to any Subcontractor, person, or organization on the list within thirty (30) calendar days of the receipt shall constitute an acceptance of such Subcontractor, person or organization. Acceptance of any such Subcontractor, person or organization shall not constitute a waiver of any right of the CITY or the CONSULTANT to reject defective Work, material or equipment, or any Work, material or equipment not in conformance with the requirements of the Contract Documents. 2.11 If, prior to the Notice of Award, the CITY or the CONSULTANT has reasonable objection to any Subcontractor, person or organization listed, the apparent low Bidder may, prior to Notice of Award, submit an acceptable substitute without an increase in its bid price. 2.12 The apparent silence of the Contract Documents as to any detail, or the apparent omission from them of a detailed description concerning any Work to be done and materials to be furnished, shall be regarded as meaning that only best practices are to prevail and only materials and workmanship of the best quality are to be used in the performance of the Work. ARTICLE l-CORRELATION. INTERPRETATION AND INTENT OF CONTRACT POCUMENTS 3.1 It is the intent of the Specifications and Drawings to describe a complete Project to be constructed in accordance with the Contract Documents. The Contract Documents comprise the entire Contract between the OWNER and the CONTRACTOR. They may be altered only by a modification as defined in Article I. 3.2 The Contract Documents are complementary; what is called for by one is as binding as if called for by all the documents, If CONTRACTOR finds a conflict, error or discrepancy in the Contract Documents, it shall, before proceeding with the Work affected thereby, immediately call it to the CONSULTANT's attention in writing. The various Contract Documents are complementary; in case of conflict, error or discrepancy, the more stringent interpretation and requirement that shall provide the maximum benefit to the Owner shall apply 3.3 The words "furnish" and "furnish and install", "install", and "provide" or words with similar meaning shall be interpreted, unless otherwise specifically stated, to mean "furnish and install compiete in place and ready for service", 3.4 Miscellaneous items and accessories which are not specifically mentioned, but which are essential to produce a complete and properly operating installation, or usable structure, prOViding the indicated functions, shall be furnished and installed without change In the Contract Price. Such miscellaneous items and accessories shall be of the same quality standards, including material, style, finish, strength, class, weight and other applicable characteristics, as specified for the malor component of which the miscellaneous Item or accessory is an essential part, and shall be approved by the CONSULTANT before installation. The above requirement is not intended to in dude major components not covered by or inferable from the Drawings and Specifications. 3.S The Work of ali trades under this Contract shall be coordinated by the CONTRACTOR In such a manner as obtain the best workmanship possible for the entire Project, and all components of the Work shall be installed or erected In accordance with the best practices of the particular trade. 3,6 The CONTRACTOR shall be responsible for making the construction of habitable structures under this Contract rain proof, and for making equipment and utility installations properly perform the specified function. If the CONTRACTOR Is prevented from complying with this provision due to the Drawings or Specifications, the CONTRACTOR shall Immediately notify the CONSULTANT in writing of such limitations before proceeding with construction in the area where the problem exists. 3,7 Manufacturer's literature, when referenced, shall be dated and numbered and is intended to establish the minimum requirements acceptable. Whenever reference is given to codes. or standard specifications or 38 other data published by regulating agencies or accepted organizations. including but not limited to National Electrical Code, applicable State Building Code, Florida Building Code, Federal Specifications, ASTM Specifications, various institute specifications, and the like, it shall be understood that such reference is to the latest edition including addenda in effect on the date of the Bid. 3.8 Brand names where used in the technical specifications, are intended to denote the standard or quality required for the particular material or product The term "equal l1 or "equivalent", when used in connection with brand names, shall be interpreted to mean a material or product that is similar and equal in type. quality, size, capacity, composition, finish. color and other applicable characteristics to the material or product specified by trade name. and that is suitable for the same use capable of performing the same function, in the opinion of the CONSULTANT. as the material or product so specified, Proposed equivalent items must be approved by CONSULTANT before they are purchased or incorporated in the Work. (When a brand name, catalog number, model number, or other identification. is used without the phrase "or equal", the CONT['.ACTOR shall use the brand, make and model specified). 3.9 Throughout this agreement the male pronoun may be substituted for female and neuter and vice versa and the singular words substituted for plural and plural words substituted for Singular wherever applicable. 3.10 All technical interpretations sh~1I be made by the CONSULTANT as set forth in Section 9.3 below. 3.11 The CONTRACTOR shall advised the CONSULTANT, prior to performing any work involving a conflict in the Contract Documents and the CONSULTANT shall make the final decision as to which of the documents shall take precedence, In the event that there is a conflict between or among the Contract Documents, only the latest version shall apply and the latest version of the Contract Documents. The CONSULTANT shall use the following list of Contract Documents as a guide. These documents are set forth below in the order of their precedence so that all the documents listed above a given document should have precedence over all the documents listed below it. (a) Change Orders (b) Amendments/addenda to Contract (c) Supplementary Conditions, if any (d) Contract with all Exhibits thereto (e) General Conditions Written or figured dimensions Scaled dimensions DraWings of a larger scale Drawings of a smaller scale (Q (g) (h) (i) OJ Drawings and Specifications are to be considered complementary to each other ARTICLE 4 -AVAILABILITY OF LANDS SUBSURFACE CONDITIONS REFERENCE POINTS Availability of Lands: 4.1 The OWNER shall rurnlsh, as indicated In the Contract Documents, the lands upon which the Work is to be done, rights-of-way for access thereto, and such other lands which are designed for the use of the CONTRACTOR. Easements for permanent structures or permanent changes in existing facilities will be obtained and paid ror by the OWNER, unless otherwise specified in the Contract Documents. Other access to such lands or rights-af-way for the CONTRACTOR'S convenience shall be the respons'tbility of the CONTRACTOR. The CONTRACTOR shall provide (or all additional lands and access thereto that may be required for temporary construction facilities or storage of material and eqUipment. 4.2 The CITY will, upon request. furnish to the Bidders. caples of all available boundary surveys and subsurface tests at no cost. Sybsurface Conditions: 4.3 The CONTRACTOR acknowledges that he has investigated prior to bidding and satisfied himself as to the conditions affecting the Work, including but not limited to those bearing upon transportation. disposal. handling and storage of materials, availability of labor, water, electric power, roads and uncertainties of weather. river stages, tides, water tables or similar physical conditions at the site. the conformation and conditions of the ground, the character of eqUipment and facilities needed preliminary to and during prosecution of the Work. The CONTRACTOR further acknowledges that he has satisfied himself as to the character, quality and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, 39 Including all exploratory work done by the OWNER! CONSULTANT on the site or any contiguous site, as well as from information presented by the Drawings and Specifications made part of this Contract, or any other information made available to It prior to receipt of bids. Any failure by the CONTRACTOR to acquaint itself with the available information shall not relieve it from responsibility for estimating properly the difficulty or cost of successfully performing Work. The OWNER assumes no responsibility for any conclusions or interpretations made by the CONTRACTOR on the basis of the Information made available by the OWNER! CONSULTANT. Differing Site Conditions; 4.4 The CONTRACTOR shall within forty eight (48) hours of its discovery, and before such conditions are disturbed, notify the CITY In writing, of: 4.4. I Subsurface or latent physical conditions at the site differing materially from those indicated in the Contract Documents, and 4.4.2 Unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally inherent in Work of the character prOVided for in this Contract. The CITY shall promptly Investigate the conditions, and if it finds that such conditions do materially differ to the extent as to cause an increase or decrease in the CONTRACTOR'S cost of, or the time required for. performance of any part of the Work under this Contract. an equitable adjustment shall be made and the Contract modified in writing accordingly. 4.5 No claim of the CONTRACTOR under this clause shall be allowed unless the CONTRACTOR has given the notice required in 4.4 above; provided. however, the time prescribed therefore may be extended by the CITY, but only if done in writing signed by the City Manager or the CONSULTANT. ARTICLE 5 -INSURANCE Contractor shall comply with the insurance reqUirements set forth in the R.FP and as set forth In the Supplementary Conditions to the Contract. if any. If both have insurance requirements and if there is a conflict between the two, the insurance requirements in the Supplemental Conditions shall take precedent. ARTICLE 6. CONTRACTOR'S RESPONSIBILITIES Supervision and Superintendence: 6.1 The CONTRACTOR shall supervise and direct the Work. It shall be solely responsible for the means, methods, techniques, sequences and procedures of construction. The CONTRACTOR shall employ and maintain a qualified supervisor or superintendent (hereinafter referred to as "Supervisor" at the Work site who shall be designated In writing by the CONTRACTOR, before the CONTRACTOR commences the Work and within the time required by the Contract, as the CONTRACTOR'S representative at the site. The Supervisor or so deSignated shall have full authority to act on behalf of the CONTRACTOR and all communications given to the Supervisor shall be as binding as if given to the CONTRACTOR. The Supervisor(s) shall be present at each site at all times as required to perform adequate supervision and coordination of the Work. (Cop'les of written communications given to the Super,tisor shall be mailed to the CONTRACTOR'S home office). 6.1.1 The CONTRACTOR shall keep one record copy of all SpeCifications, Drawings, Addenda, Modifications and Shop Drawings at the site at all times and in good order and annotated to show all changes made during the construction process. These shall be available to the CONSULTANT and any CITY Representative at all reasonable times. A set of "As-Built" drawings. as well as the original Specifications, Drawings, Addenda, Modifications and Shop Drawings with annotations, shall be made available to the City at all rimes and it shall be delivered to the CITY upon completion of the Project. Labor, Materials and EqUipment: 6.2 The CONTRACTOR shall provide competen~ SUitably qualified personnel to layout the Work and perform construction as reqUired by the Contract Documents. It shall at all times maintain good discipline and order at the site. 6.3 The CONTRACTOR shall furnish all materials, eqUipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel. power, light, heat, local telephone, water and sanitary facilities and all other facilities and incidentals necessary for the execution, testing. Initial operation and completion of the Work. 40 6.4 All materials and equipment shall be new, except as otherwise provided in the Contract Documents. When special makes or grades of material which are normally packaged by the supplier or manufacturer are specified or approved. such materials shall be delivered to the site in their original packages or containers with seals unbroken and labels intact. 6.5 All materials and equipment shall be applied. installed. connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturer, fabricator, or processors, except as otherwise provided in the Contract Documents. Work Materials. Equipment. Products and Substitutions: 6.6 Materials. eqUipment and products incorporated in the Work must be approved for use before being purchased by the CONTRACTOR. The CONTRACTOR shall submit to the CONSULTANT a list of proposed materials, eqUipment or products, together with such samples as may be necessary for them to determine their acceptability and obtain their approval, within ninety (90) calendar days after award of Contract unless otherwise stipulated in the Special Conditions. No request for payment for "or equal" equipment will be approved until this list has been received and approved by the CONSULTANT. 6.6.1 Whenever a material, article or piece of eqUipment Is identified on the Drawings or SpeCifications by reference to brand name or catalog number, it shall be understood that this is referenced (or the purpose of defining the performance or other salient reqUirements and that other products o( equal capacities, quality and (unction shall be considered. The CONTRACTOR may recommend the subsdtution of a material, article, or piece o( eqUipment of equal substance and function (or those referred to in the Contract Documents by reference to brand name or catalog number, and if, in the opinion o( the CONSULTANT, such material, article, or piece of eqUipment is of equal substance and function to that specified, the CONSULTANT may approve Its substitution and use by the CONTRACTOR. Incidental changes or extra component parts required to accommodate the substitute will be made by the CONTRACTOR without a change in the Contract Price or the Contract Time. 6.6,2 No substitute shall be ordered or installed without the written approval of the CONSULTANT who shall be the judge of quality. 6.6.3 Delay caused by obtaining approvals for substitute materials shall not be considered justifiable grounds for an extension of construction time. 6.6.4 Should any Work or materials, equipment or products not conform to requirements of the DraWings and Specifications or become damaged during the progress o( the Work, such Work or materials shall be removed and replaced, together with any Work disarranged by such alterations, at any time before completion and acceptance o( the Project. All such Work shall be done at the expense of the CONTRACTOR. 6.6.5 No materials or supplies for the Work shall be purchased by the CONTRACTOR or any Subcontractor subject to any chattel mortgage or under a conditional sale or other agreement by which an interest is retained by the Seller. The CONTRACTOR warrants that they have good title to all materials and supplies used by them in the Work. 6.6.6 Non¥con(orming Work: The City of South Miami may withhold acceptance of. or reject items which are found upon examination, not to meet the specification requirements or conform to the plans and drawings. Upon written notification of rejection, items shall be removed or uninstalled within five (5) business days by the CONTRACTOR at his own expense and redelivered andlor reinstalled at his expense. Rejected goods left longer than thirty (30) calendar days shall be regarded as abandoned and the CITY shall have the right to dispose o( them as its own property and the CONTRACTOR thereby waives any claim to the good or to compensation o( any kind (or said goods. Rejection for non·conformance or failure to meet delivery schedules may result in the CONTRACTOR being found in default. 6.6.7 In case of default by the CONTRACTOR, the City of South Miami may procure the articles or services (rom other sources and hold the CONTRACTOR responsible (or any excess costs occasioned or incurred thereby. 6.6.8 The CITY reserves the right, in the event the CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested, to obtain the good and/or services from other sources and deducting the cost (rom the Contract Price without violating the intent of the Contract. Concerning Subcontractors: 41 6.7 The CONTRACTOR shall not employ any Subcontractor, against whom the CITY or the CONSULTANT may have reasonable objection, nor will the CONTRACTOR be required to employ any Subcontractor who has been accepted by the CITY and the CONSULTANT, unless the CONSULTANT determines that there is good cause for doing so. 6.8 The CONTRACTOR shall be fully responsible for all acts and omissions of its Subcontractors and of persons and organizations directly or indirectly empl_oyed by it and of persons and organizations for whose acts any of them may be liable to the same extent that they are responsible for the acts and om'lssions of persons directly employed by them. Nothing in the Contract Documents shall create any contractual relationship between OWNER or CONSULTANT and any Subcontractor or other person or organization having a direct contract with CONTRACTOR, nor shall it create any obligation on the part of OWNER or CONSULTANT to payor to see to payment of any persons due subcontractor or other person or organization, except as may otherwise be required by law. CITY or CONSULTANT may furnish to any Subcontractor or other person or organization. to the extent practicable, evidence of amounts paid to the CONTRACTOR on account of specified Work done In accordance with the schedule values. 6.9 The divisions and sections of the Specifications and the identifications of any DraWings shall not control the CONTRACTOR in dividing the Work among Subcontractors or delineating the Work performed by any specific trade. 6.10 The CONTRACTOR agrees to bind specifically every Subcontractor to the applicable terms and conditions of the Contract Documents for the benefit of the OWNER. 6.11 All Work performed for the CONTRACTOR by a Subcontractor shall be pursuant to an appropriate agreement between the CONTRACTOR and the Subcontractor. 6.12 The CONTRACTOR shall be responsible for the coordination of the trades, Subcontractors material and men engaged upon their Work. 6,12,1 The CONTRACTOR shall cause appropriate prOVisions to be inserted in all subcontracts relative to the Work to bind Subcontractors to the CONTRACTOR by the terms of these General Conditions and other Contract Documents insofar as applicable to the Work of Subcontractors, and give the CONTRACTOR the same power as regards to terminating any subcontract that the OWNER may exercise over the CONTRACTOR under any provisions of the Contract Documents. 6.12.2 The CITY or CONSULTANT will not undertake to settle any differences between the CONTRACTOR and their Subcontractors or between Subcontractors, 6.12.3 Ifin the opinion ofthe CONSULTANT, any Subcontractor on the Project proves to be Incompetent or otherwise unsatisfactory, they shall be promptly replaced by the CONTRACTOR if and when directed by the CONSULTANT in writing. 6.12A Discrimination: No action shall be taken by the any subcontractor with regard to the fulfillment of the terms of the subcontract, including the hiring and retention of employees for the performance of Work that would discriminate against any person on the basis of race, color, creed, religion, national origin, sex, age. sexual orientation, familial status or disability. This paragraph shall be made a part of the subcontractor's contract with the Contractor. Patent Fees and Royalties: 6./3 The CONTRACTOR shall pay all license fees and royalties and assume all costs incident to the use of any invention. design, process or deVice which is the subject of patent rights or copyrights held by others. He shall indemnify and hold harmless the OWNER and the CONSULTANT and anyone directly or indirectly employed by either of them from against all da"lms, damages, losses and expenses (including attorney's fees) arising out of any infringement of such rights during or after the completion of the Work. and shall defend all such claims in connection with any alleged infringement of such rights. 6.14 The CONTRACTOR shall be responsible for determining the application of patent rights and royalties materials, appliances. articles or systems prior to bidding. However, he shall not be responsible for such determination on systems which do not involve purchase by them of materials, appliances and articles. Permits: 6.15 The CONTRACTOR shall secure and pay for all construction permits and licenses and shall pay for all governmental charges and Inspection fees necessary for the prosecution of the Work, which are applicable at the time of his Bid. When such charges are normally made by the CITY and when so stated in the Special Conditions, there will be no charges to the CONTRACTOR. The CITY shall assist the 42 CONTRACTOR, when necessary, in obtaining such permits and licenses. The CONTRACTOR shall also pay all public utility charges. Electrical power and lighting: 6.16 Electrical power required during construction shall be provided by each prime CONTRACTOR as required by it. This service shall be installed by a qualified electrical Contractor approved by the CONSULTANT. Lighting shall be provided by the CONTRACTOR in all spaces at all times where necessary for good and proper workmanship, for inspection or (or safety. No temporary power shall be used off temporary lighting lines without specific approval of the CONTRACTOR. Laws and Regulations: 6.17 The CONTRACTOR shall comply with all notices. laws. ordinances, rules and regulations applicable to the Work If the CONTRACTOR observes that the Specifications or Drawings are at variance therewith, it shall give the CONSULTANT prompt written notice thereof, and any necessary changes shall be adjusted by an appropriate modification. If the CONTRACTOR performs .ny Work knowing It to be contrary to such laws, ordinances, rules and regulations, and without such notj~e to the CONSULTANT, it shall bear all costs arising there from; however, it shall not be its primary responsibillty to make certa'in that the Drawings and Specifications are in accordance with such laws, ordinances, rules and regulations. Discrimjnatlon: 6.17 A No action shall be taken by the Contractor with regard to the fulfillment of the terms of the Contract, including the hiring and retention of employees for the performance of Work that would discriminate against any person on the basis of race, color, creed. religion. national origin, sex, age, sexual orientation, familial status or disability. ill= 6.18 Cost of all applicable sales, consumer use, and other taxes for which the CONTRACTOR is liable under the Contract shall be included in the Contract Price stated by the CONTRACTOR, Safety and Protection; 6.19 The CONTRACTOR shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work, They shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 6.19.1 All employees and other persons, who may be affected thereby, 6.19.2 All the Work and all'materials or eqUipment to be incorporated therein, whether in storage on or off the site, and 6.19.3 Other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated (or removal, relocation or replacement in the course of construction. 6.20 The CONTRACTOR shall designate a responsible member of their organization at the site whose duty shall be the prevention of accidents. This person shall be the CONTRACTOR'S Superintendent unless otherwise designated in writing by the CONTRACTOR to the CITY. Emergencies; 6.21 In emergencies affecting the safety of persons or the Work or property at the site or adjacent thereto, the CONTRACTOR, without special Instruction or authorization (rom the CONSULTANT or CITY, is obligated to act, at his discretion, to prevent threatened damage, injury or loss. He shall give the CONSULTANT prompt written notice of any significant changes In the Work or deviations from the Contract Documents caused thereby. If the CONTRACTOR believes that additional Work done by him in an emergency which arose (rom causes beyond his control entitles him to an increase in the Contract Price or an extension of the Contract Time, he may make a claim therefore as provided in Articles II and 12. Shop Drawings and Samples: 6.22 After checking and verifying all field measurements, the CONTRACTOR shall submit to the CONSULTANT for review, in accordance with the accepted schedule of shop drawing submissions. six (6) copies (or at the CONSULTANT option, one reproducible copy) of all Shop Drawings, which shall have been checked by and stamped with the approval of the CONTRACTOR. The Shop Drawings shall 43 be numbered and identified as the CONSULTANT may require, The data shown on the Shop Drawings shall be complete with respect to dimensions, design criteria, materials of construction and the like to enable the CONSULTANT to review the information without any unnecessary investigation, 6.23 The CONTRACTOR shall also submit to the CONSULTANT for review, with such promptness as to cause no delay in Work, all samples requIred by the Contract Documents. All samples shall have been checked by and stamped with the approval of the CONTRACTOR, identified clearly as to material, manufacturer, any pertinent catalog numbers and the use for which intended, 6.24 At the time of each submission, the CONTRACTOR shall notify the CONSULTANT, In writing, of any deviations between the Shop Drawings or samples and the requirements of the Contract Documents. 6.25 The CONSULTANT shall review with responsible promptness Shop Drawings and Samples, but his review shall be only for conformance with the design concept of the Project and for compliance with the information given in the Contract Documents. The review of a separate item as such will not indicate review of the assembly in which the items functions. The CONTRACTOR shall make any corrections required by the CONSULTANT and shall return the required number of corrected copies of Shop DraWings and resubmit new samples until the review is satisfactory to the CONSULTANT. The CONTRACTOR shall notify the CONSULTANT, in writing, of any prior Shop Drawing or revisions to Shop Drawings that are in conflict with each submission or re-submission. The CONTRACTOR'S stamp of approval on any Shop Drawings or sample shall constitute representation to the CITY and the CONSULTANT that the CONTRACTOR has either determined andlor verified all quantities, dimension, field construction criteria, materials, catalog numbers and similar data or they assume full responsibility for doing so, and that they have reviewed or coordinated each Shop Drawing or sample with the requirements of the Work and the Contract Documents, 6.26 No Work requiring a submittal of a Shop Drawing or sample shall be commenced until the submission has been reviewed and approved In writing by the CONSULTANT. A copy of each Shop DraWing and each approved sample shalt be kept in good order, in a book or binder, in chronological order or in such other order required by the CONSULTANT in writing, by the CONTRACTOR at the site and shall be available to the CONSULTANT. 6.27 The CONSULTANT's review of Shop Drawings or samples shall not relieve the CONTRACTOR from his responsibility for any deviations from the reqUirements of the Contract Documents unless the CONTRACTOR has informed the CONSULTANT, in writing, to each deviation at the time of submission and the CONSULTANT has given written approval to the specific deviation, nor shall any review by the CONSULTANT relieve the CONTRACTOR from responsibility for errors or omissions in the Shop Drawings or samples, 6.27A The CONTRACTOR shall be liable to the OWNER for any additional cost or delay that is caused by its failure to notify the CONSULTANT of any of said deviations or conflicts between Shop Drawings or due to errors in the Shop Drawings or samples. Cleaning Up' 6.28 The CONTRACTOR shall clean up behind the Work as much as is reasonably possible as the Work progresses. Upon completion of the Work, and before acceptance of final payment for the Project by the OWNER. the CONTRACTOR shall remove all his surplus and discarded materials, excavated material and rubbish as well as all other material and eqUipment that does not form a part of the Work, from the property, roadways, sidewalks, parking areas, lawn and all adjacent property. In addition, the CONTRACTOR shall clean his portion of Work involved in any building under this Contract, so that no further cleaning by the OWNER is necessary prior to its occupancy and he shalt restore all property. both public and private, which has been disturbed or damaged during the prosecution of the Work so as to leave the whole Work and Work Site in a neat and presentable condition. 6.29 If the CONTRACTOR does not clean the Work site, the CITY may clean the Work Site of the materials referred to in paragraph 6.28 and charge the cost to the CONTRACTOR. Public Convenience and Safety: 6.30 The CONTRACTOR shall, at at! times, conduct the Work In such a manner as to insure the least practicable obstruction to public travel. The convenience of the general public and of the residents along and adjacent to the area of Work shalt be provided for in a satisfactory manner, consistent with the operation and local conditions. "Street Closed" signs shall be placed immediately adjacent to the Work, in a conspicuous position, at such locations as traffic demands. At any time that streets are required to be dosed, the CONTRACTOR shall notify law enforcement agencies and in particular, the City of South 44 Miami Police Department, before the street Is closed and again as soon as it is opened. Access to fire hydrants and other fire extinguishing equipment shall be provided and maintained at all times. Sanitary Provisions' 6.31 The CONTRACTOR shall provide on-site office, and necessary toilet facilities, secluded from public observation, for use of all personnel on the Work Site, whether or not in his employ. They shall be kept In a clean and sanitary condition and shall comply with the requirements and regulations of the Public Authorities haVing jurisdiction. They shall commit no pUblic nuisance, Temporary field office and sanitary facilities shall be removed upon completion of the Work and the premises shall be left clean. Indemnification: 6.32 Contractor shall comply with the indemnification requirements set forth in the RFP and as set forth in the Supplementary Conditions to the Contract, if any. If both have Indemnification reqUirements and if there is a conflict between the two, the indemnification requirements in the Supplemental Conditions shall take precedent. 6,33 In the event that any action or proceeding [s brought against OWNER or CONSULTANT by reason of any such claim or demand, CONTRACTOR, upon written notice from CITY shall defend such action or proceeding by counsel satisfactory to CITY. The indemnification provided above shall obligate CONTRACTOR to defend at its own expense or to provide for such defense, at CITY'S option, any and all claims of liability and all suits and actions of every name and description that may be brought against OWNER or CONSULTANT. excluding only those claims that allege that the injuries arose out of the sole negligence of OWNER or CONSULTANT. 6.34 The obligations of the CONTRACTOR under paragraph 6.33 shall not extend to the liability of the CONSULTANT, its agents or employees arising out of (a) the preparation or approval of maps, drawings, opinions, reports, surveys, Change Orders, designs or specifications or (b) the giving of or the failure to give directions or instructions by the CONSULTANT, its agents or employees prOVided such act or omission is the primary cause of injury or damage. 6.34A All of the forgoing Indemnification prOVisions shall surv'lve the term of the Contract to which these General Conditions are a part. Indemnification shall not exceed an amount equal to the total value of all insurance coverage required by Section 5.1 of this document. Indemnification is limited to damages caused in whole or in part by any act, omission, or default of the Contractor, the Contractor's subcontractors, sub-subcontractors, materialmen, or agents of any tier or their respective employees to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of the indemnifying party and persons employed or utilized by the indemnifying party in the performance of the construction contract. Responsibility for Connection to Existing Work' 6.35 It shall be the responsibility of the CONTRACTOR to connect its Work to each part of the eXisting Work, existing bUilding or structure or Work previously installed as reqUired by the Drawings and Specifications to prOVide a complete installation. 6.36 Excavations, grading, fill, storm drainage, paving and any other construction or installations in rights-of- ways of streets, highways, public carrier lines, utility lines, either aerial, surface or subsurface, etc., shall be done in accordance with requirements of the special conditions. The OWNER will be responsible for obtaining all permits necessary for the Work described In this paragraph 6.36. Upon completion of the Work. CONTRACTOR shall present to CONSULTANT certificates. in triplicate. from the proper authorities, stating that the Work has been done In accordance with their requirements. 6.36. I The CITY will cooperate with the CONTRACTOR in obtaining action from any utilities or public authorities Involved in the above reqUirements. 6.36.2 The CONSULTANT shall be responsible for obtaining elevations of curbs and gutters, pavement, storm drainage structures, and other items which must be established by governmental departments as soon as grading operations are begun on the site and, '10 any case, sufficiently early in the construction period to prevent any adverse effect on the Project. Cooperation with Goyernmental Departments. Public Utilities, Etc . 6.37 The CONTRACTOR shall be responsible for making all necessary arrangements with governmental departments. public utilities, public carriers, service companies and corporations (hereinafter referred to as "third parties") owning or controlling roadways, railways, water, sewer, gas, electrical conduits, telephone. and telegraph facilities such as pavements, tracks, piping, wires, cables, conduits, poles, guys, 45 etc., including incidental structures connected therewith, that are encountered in the Work in order that such items are properly shored, supported and protected, that their location is identified and to obtain authority from these third parties for relocation if the CONTRACTOR desires to relocate the item. The CONTRACTOR shall give all proper notices, shall comply with all requirements of such third parties in the performance of his Work, shall permit entrance of such third parties on the Project in order that they may perform their necessary work, and shall pay all charges and fees made by such third parties for their work. 6.37.1 The CONTRACTOR'S attention is called to the fact that there may be delays on the Project due to work to be done by governmental departments, public utilities, and others in repairing or moving poles, conduits, etc. The CONTRACTOR shall cooperate with the above parties in every way possible, so that the construction can be completed in the least possible time. 6.37.2 The CONTRACTOR shall have made itself familiar with all codes, laws, ordinances, and regulations which In any manner affect those engaged or employed in the Work, or materials and equipment use in or upon the Work, or in any way affect the conduct of the Work, and no plea of misunderstanding will be considered on account of damage or delay caused by his ignorance thereof. Use Premises' 6.38 CONTRACTOR shall confine its apparatus, storage of materials, and operations of its workmen to the limits Indicated by law, ordinances, permits and directions of CONSULTANT and CITY, and shall not unnecessarily encumber any part of the site or any areas off site. 6.38.1 CONTRACTOR shall not overload or permit any part of any structure to be loaded with such weight as will endanger its safety, nor shall it subject any work to stresses or pressures that will endanger it. 6.38.2 CONTRACTOR shall enforce the rules and regulation promulgated by the CONSULTANT and OWNER as well as their instructions with regard to signs, advertisements, fires and smoking. 6.38.3 CONTRACTOR shall arrange and cooperate with CITY in routing and parking of automobiles of its employees, subcontractors and other personnel, as well as that of the material delivery trucks and other vehicles that come to the Project site. 6.38.4 The City will designate specific areas on the site for storage, parking, etc. and the job site shall be fenced to protect the job site and the general public. 6.38.5 The CONTRACTOR shall furnish, install and maintain adequate construction office facilities for all workers employed by it or by its Subcontractors. Temporary offices shall be provided and located where directed and approved by the CONSULTANT. All such racilities shall be furnished in strict accordance with existing governing regulations. Field offices shall include telephone facilities. Protection of EXisting Property Improvements: 6.38 Any existing surface or subsurface improvements. such as pavements, curbs, sidewalks, pipes or utilities, footings, or structures (including portions thereof), trees and shrubbery, not indicated on the Drawings or noted in the Specifications as being removed or altered shall be protected from damage during construction of the Project. Any such improvements damaged during construction of the Project shall be restored at the expense of the CONTRACTOR to a condition equal to that eXisting at the time of award of Contract. ARTICLE 7 • WORK BY OTHERS. 7.1 The CITY may perform additional Work related to the Project or may let other direct contracts therefor which shall contain General Conditions similar to these. The CONTRACTOR shall afford the other contractors who are parties to such direct contracts (or the OWNER, if it is performing the additional Work Itself), reasonable opportunity for the introduction and storage of materials and equipment and the execution of Work, and shall properly connect and coordinate its Work with theirs. 7.2 If any part of the CONTRACTOR'S Work depends upon proper execution or results of the Work of any other contractor or the OWNER, the CONTRACTOR shall promptly report to the CONSULTANT in writing any defects or deficiencies in such Work that render It unsuitable for the CONTRACTOR's Work. 7.3 The CONTRACTOR shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and fit to receive or be received by such other Work. The CONTRACTOR shall not endanger any Work of others by cutflng, excavating or otherwise altering their 46 Work and shall only cut or alter their Work with the written consent of the CONSULTANT and of the other contractor whose work will be affected. 7.4 If the performance of additional Work by other contractors or the OWNER is not noted in the Contract Documents prior to the execution of the Contract, written notice thereof shall be given to the CONTRACTOR prior to starting any such additional Work. If the CONTRACTOR believes that the performance of such additional Work by the OWNER or others will cause the CONTRACTOR additional expense or entitles him to an extension of the Contract Time, he may make a claim therefore as provided In Articles II and 12. 7.5 Where practicable, the CONTRACTOR shall build around the work of other separate contractors or shall leave chases, slots and holes as required to receive and to conceal within the general construction Work the work of such other separate contractors as directed by them. Where such chases, slots, etc., are impracticable, the Work shall require specific approval of the CONSULTANT. 7.6 Necessary chases, slots, and holes not built or left by the CONTRACTOR shall be cut by the separate contractor requiring such alterations after approval of the CONTRACTOR. The CONTRACTOR shall do all patching and finishing of the work of other contractors where it is cut by them and such patching and finishing shall be at the expense of CONTRACTOR 7.7 Cooperation is reqUired in the use of site facilities and in the detailed execution of the Work. Each contractor shall coordinate their operation with those of the other Contractors for the best interest of the Work in order to prevent delay in the execution thereof. 7.8 Each of several contractors working on the Project Site shall keep themselves informed of the progress of the work of other contractors. Should lack of progress or defective workmanship on the part of other contractors Interfere with the CONTRACTOR's operations, the CONTRACTOR shall notify the CONSULTANT Immediately and in writing. Lack of such notice to the CONSULTANT shall be construed as acceptance by the CONTRACTOR of the status of the work of other contractors as being satisfactory for proper coordination of CONTRACTOR's own Work. 7.9 The cost of extra Work resulting from lack of notice, untimely notice, failure to respond to notice, Defective Work or lack of coordination shall be the CONTRACTOR's cost. 7.10 The CITY reserves the right in the event the CONTRACTOR cannot provide an item(s) ar service(s) in a timely manner as requested, to obtain the good and/or services fram other sources and deducting the cost from the Contract Price without violating the intent of the Contract. ARTICLE 8 -CITY'S RESPONSIBILITIES, 8.1 The CITY will issue all communications to the CONTRACTOR through the CONSULTANT. 8.2 In cases of termination of employment of the CONSULTANT, the CITY will appoint a CONSULTANT whose status under the Contract Documents shall be that of the former CONSULTANT. 8.3 The CITY shall promptly furnish the data reqUired of them under the Contract Documents. 8.4 The CITY'S duties in respect to providing lands and easements are set forth in Paragraphs 4.1 and 4.2. 8.5 The CITY shall have the right to take possession of and use any completed or partially completed portions of the Work, notWithstanding the fact that the time for completing the entire Work or any portion thereof may not have expired; but such taking possession and use shall not be deemed an acceptance of any Work not completed in accordance with the Contract Documents, ARTICLE 9 -CONSULTANTS' STATUS pURING CONSTRUCTION, City's Representative: 9.1 The CONSULTANT shall be the CITY'S representative during the construction period. The duties and responsibilities and the limitations of authority of the CONSULTANT as the CITY'S representative during construction are set forth in Articles I through 16 of these General Conditions and shall not be extended without written consent of the CITY and the CONSULTANT. 9.1.1 The CONSULTANT's decision, in matters relating to aesthetics, shall be final, if within the terms of the Contract Documents. 9.1.2 Except as may be otherwise provided in this contract, all claims, counterclaims, disputes and other matters in question between the CITY and the CONSULTANT arising out of or relating to this Contract or the breach thereof, shall be decided in a court of competent jurisdiction within the State of Florida. Visits to Site: 41 9.2 The CONSULTANT shall provide an inspector to make periodic visits to the site at each phase of construction to observe the progress and quality of the executed Work and to determine if the Work is proceeding in accordance with the Contract Documents. His efforts shall be directed toward providing assurance for the OWNER and all applicable regulatory agencies that construction is in compliance with the Construction Documents and applicable laws, rules and regulations. On the basis of these on site~ observations as an experienced and qualified design professional, he shall keep the CITY Informed of the progress of the Work and shall guard the OWNER against defects and deficiencies in the Work of CONTRACTOR, Clarifications and Interpretations' 9.3 The CONSULTANT shall issue, with reasonable promptness, such written clarifications or interpretations of the Contract Documents (In the form of Drawings or otherwise) as it may determine necessary. which shall be consistent With, or reasonably inferable from, the overall intent of the Contract Documents. If the CONTRACTOR seeks an increase in the Contract Price or extension of Contract Time based on a written clarification andlor Interpretation it shall be required to submit a timely claim as provided in Articles I I and 12. Measurement of Ouantitles: 9.4 All Work completed under the Contract shall be measured by the CONSULTANT according to the United States Standard Measures. All linear surface measurements shall be made horizontally or vertically as required by the Item measured. Rejecting Defectjye Work: 9.S The CONSULTANT shall have authority to disapprove or reject Work that is "Defective Work" as defined in Article I. It shall also have authority to require special inspection or testing of the Work including Work fabricated on or off site, installed or completed as prOVided. In the event that the CONSULTANT reqUires testing of completed Work. the cost of such inspections andlor testing shall be approved in writing by the CITY. All consequential cost of such inspections and testing, including but not limited to the cost of testing and inspection. the cost of repairing any of the Work, or the work of others, the cost to move furniture and equipment and/or the cost to provide alternative facilities until the repair work can be completed, shall paid by the CONTRACTOR if the Work is found to be Defective Work. Shop DraWings. Cbange Orders and Payments: 9.6 In connection with the CONSULTANT respons'lbility as to Shop Drawings and samples. see paragraphs 6.25 through 6.28, inclusive. 9.7 In connection with the CONSULTANT's responsibility for Change Orders see Articles 10, II, and 12. 9.8 In connection with the CONSULTANT responsibilities with respect to the Application for Payment, etc., see Article 14. Decisions on Disaereements: 9.10 The CONSULTANT shall be the Initial interpreter of the Construction Documents, limitations on Consultant's Responsibilities; 9.11 The CONSULTANT will not be responsible for the construction means, methods, techniques, sequences or procedures, or the safety precautions and programs incident thereto. 9,12 The CONSULTANT will not be responsible for the acts or omissions of the CONTRACTOR, or any Subcontractors, or any of their agent, servants or employees, or any other person performing any of the Work under or through them. ARTICLE 10· CHANGES IN THE WORK. 10.1 Without invalidating the Contract, the CITY may. at any time or from time to time, order additions, deletions or revisions in or to the Work which shall only be authorized by a written Change Orders. Upon receipt of a Change Order, the CONTRACTOR shall proceed with the Work involved. All such Work shall be performed under the applicable conditions of the Contract Documents. If any authorized written Change Order causes an increase or decrease in the Contract Price or an extension or shortening of the Contract Time, an equitable adjustment will be made as provided in Article II or Article 12. A written Change Order signed by the CITY and the CONTRACTOR indicates their 48 agreement to the terms of the Change Order. All Change Orders shall be certified by the CONSULTANT as to the appropriateness and value of the change In the Work as well as to any change in the time to complete the Work under the circumstances. The failure to include a time extension in the Change Order or in the request for a change order shaH result In a waiver of any extension of time due to the change in the work as reflected in the Change Order. 10.2 The CONSULTANT may authorize minor changes or alterations in the Work not involving extra cost and not Inconsistent with the overall intent of the Contract Documents without the need for a formal written Change Order provided the CONTRACTOR does not request additional time or additional compensation. These may be accomplished by a written Field Order. If the CONTRACTOR believes that any change or alteration authorized by the CONSULTANT's Field Order would entities the CONTRACTOR to an increase in the Contract Price or extension of Contract Time, it must subm'lt a written notice of intent to demand a Change Order within twenty four (24) hours of the issuance of the Field Order and submit a written proposal for Change Order within four (4) days thereafter, otherwise the CONTRACTOR shall be deemed to have waived such claim. 10.3 Additional Work performed by the CONTRACTOR without authorization of a written Change Order shall not entitle it to an Increase in the Contract Price or an extension of the Contract Time, except In the case of an emergency as provided in paragraph 6.22 and except as provided in paragraph 10.2. 10.4 The CITY will execute appropriate Change Orders prepared by the CONSULTANT covering changes In the Work. to be performed as prOVided in paragraph 4.4, and Work performed in an emergency as provided in paragraph 6.22 and any other claim of the CONTRACTOR for a change in the Contract Time or the Contract Price which is approved by the CONSULTANT. 10.5 It Is the CONTRACTOR'S responsibility to notify its Surety of any changes affecting the general Scope of the Work or change in the Contract Price or Contract Time and the amount of the appl!cable bonds shall be adjusted accordingly. The CONTRACTOR shall furnish proof of such an adjustment to the CITY before commencement of the Change Order Work. The Work shall be stopped until the CONTRACTOR provides such proof of adJustment in the Bond amount and any such delay shall be charged to the CONTRACTOR. ARTICLE II -CHANGE OF CONTRACT PRICE. I 1.1 The Contract Price constitutes the total compensation payable to the CONTRACTOR for Performing the Work. All duties, responsibilities and obligations assigned to or undertaken by the CONTRACTOR shall be at its expense without changing the Contract Price, 11.2 The CITY may, at any time, without written notice to the sureties. by written order deSignated or indicated to be a Change Order. make any change in the Work within the general scope of the Contract, Including but not limited to changes to or In: I 1.2.1 Specifications (Including drawings and designs); I 1.2.2 Method or manner of performance of the Work, I 1.2.3 CITY-furnished facilities, equipment, materials, services, or site; or 11.2.4 Acceleration in the performance of the Work. 11.3 Except as provided in this section. or sections referred to in this section. no order. statement, or conduct of the CITY shall be treated as a Change Order or entitle the CONTRACTOR to an eqUitable adjustment unless and until the change in the Work Is specifically and expressly prOVided for in a written Change Order. or as otherwise prOVided in another section of the Contract Documents. 11.4 When a Change Order Is Issued by the CONSULTANT and signed by the CITY or issued by the CITY in writing. the CONTRACTOR shall perform the Work even If the CONTRACTOR does not agree with the dollar amount of the Change Order, If any Change Order causes an increase or decrease in the CONTRACTOR'S cost of, or the time required for. the performance of any part of the Work under this Contract, for which the CITY and the CONTRACTOR cannot reach a timely agreement, an eqUitable adjustment based on the cost of the Work shall be made and the Contract modified accordingly. 11.5 If the CONTRACTOR intends to assert a claim for an eqUitable adjustment or contest the equitable adjustment made by the CONSULTANT, it shall, within ten (10) calendar days after receipt of a written Change Order, submit to the CITY and CONSULTANT a written notice including a statement setting forth the general nature and monetary extent of such claim for equitable adjustment. time extension requested and supporting data. In determining the cost of the Change Order, the costs shall be limited to those listed In section I 1.7 and 11.8. 11.6 No claim by the CONTRACTOR for an equitable adjustment hereunder shall be allowed if not submitted in accordance with this section or if asserted after final payment under this Contract. 49 11.7 The value of any Work covered by a Change Order or of any claim for an increase or decrease In the Contract Price shall be determined In one of the following ways: I 1.7.1 By negotiated lump sum. I 1.7.2 On the basis of the reasonable cost and savings that results from the change in the Work plus a mutually agreed upon fee to the CONTRACTOR to cover overhead and profit not to exceed 15%. If the CONTRACTOR disagrees with the CONSULTANTs determination of reasonable costs, the CONTRACT shall provide a list of all costs together with backup documentation I 1.8 The term cost of the Work means the sum of all direct extra costs necessarily incurred and paid by the CONTRACTOR in the proper performance of the Change Order. Except as otherwise may be agreed to in writing by CITY. such costs shall be in amounts no higher than those prevailing in Miami-Dade County and shall include only the following items: 11.8.1 Payroll costs for employees in the direct employ of CONTRACTOR in the performance of the Work described in the Change Order under schedules of job classifications agreed upon by CITY and CONTRACTOR. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall be limited to: salaries and wages, plus the costs of fringe benefits which shall include social security contributions, unemployment, excise and payroll taxes, workers' compensation, health and retirement benefits, sick leave, vacation and holiday pay applicable thereto. Such employees shall include superintendents and foremen at the site. The expenses of performing Work after regular working hours, on Sunday or legal holidays shall be included in the above only if authorized by CITY and provided it was not in any way, whether in whole or in part the result of the fault of the CONTRACTOR due to negligence of the CONTRACTOR or those acting by or through him or due in whole or in part to Defective Work of the CONTRACTOR. 11.8.2 Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage. and manufacturers' field services required in connection therewith. The CONTRACTOR shall notify the CITY of all cash discounts that are available and offer the CITY the opportunity to deposit funds with the CONTRACTOR for the payment for items that offer a discount. Cash discounts shall accrue to CONTRACTOR unless the CONTRACTOR fails to timely notify the CITY of the discounts or if the OWNER deposits funds with CONTRACTOR with which to make payments in which cases the cash discounts shall accrue to the OWNER. All trade discounts. rebates and refunds, and all returns from sale of surplus materials and equipment shall accrue to OWN ER, and CONTRACTOR shall make provisions so that they may be obtained. I 1.8.3 Payments made by CONTRACTOR to the Subcontractors for Work performed by Subcontractors. If required by CITY. CONTRACTOR shall obtain competitive bids from Subcontractors acceptable to him and shall deliver such bids to CITY who will then determine, with the advice of the CONSULTANT. which Bids wUl be accepted. No subcontract shall be a cost plus contract unless approved In writing by the CITY. If a Subcontract provides that the Subcontractor is to be paid on the basis of Cost of Work plus a fee. the cost of the Work shall be determined In accordance this section I 1.8 and in such case the word "Subcontractor" shall be substituted for the word "CONTRACTOR". I (.8,4 Rentals of all construction equipment and machinery, except hand tools, and the parts thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by CITY with the advice of CONSULTANT, and the costs of transportation, loading, unloading, Installation, dismantling and removal thereof -all in accordance with terms of said rental agreements. The rental of any such equipment, machinery or parts shall cease when the use thereof is no longer necessary for the Work. 11.8.S Sales, use or similar taxes related to the Work, and for which CONTRACTOR is liable, imposed by any governmental authority. 11.8.6 Payments and fees for permits and licenses. Costs for permits and licenses must be shown as a separate item. 11.8.7 The cost of utilities, fuel and sanitary facilities at the site. 11.8.8 Minor expenses such as telegrams, long distance telephone calls, telephone service at the site, expressage and similar petty cash items in connection with the Work. 11.8.9 Cost of premiums for additional Bonds and insurance required solely because of changes in the Work, not to exceed two percent (2%) of the increase in the Cost of the Work. 11.9 The term Cost of the Work shall NOT include any of the follOWing: so 11.9.1 Payroll costs and other compensation of CONTRACTOR'S officers, executives, principals (of partnership and sole proprietorships), general managers, engineers, architects, estimators, lawyers, agents, expediters, timekeepers, clerks and other personnel employed by CONTRACTOR whether at the site or in its principal or a branch office for general administration of the Work and not specifically included in the schedule referred to in Subparagraph 11.5. 11.9.2 Expenses of CONTRACTOR'S principal and branch offices other than Its office at the site. 11.9.3 Any part of CONTRACTOR'S capital expenses, including interest on CONTRACTOR'S capital employed for the Work and charges against CONTRACTOR for delinquent payments. 11.9.4 Cost of premiums for all bonds and for all insurance policies whether or not CONTRACTOR is required by the Contract Documents to purchase and maintain the same (except as otherwise provided In Subparagraph II.B.9). 11.9.5 Costs due to the negligence of CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective work, disposal of materials or eqUipment wrongly supplied and making good any damage to property. 11.9.6 Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraph II.B. I 1.10 The CONTRACTOR'S fee which shall be allowed to CONTRACTOR for its overhead and profit shall be determined as follows: 11.10.1 A mutually acceptable firm fixed price; or if none can be agreed upon. 11.10.2 A mutually acceptable fixed percentage (not to exceed 15%). 11.11 The amount of credit to be allowed by CONTRACTOR to OWNER for any such change which results in a net decrease in cost will be the amount of the actual net decrease in costs calculated in the same manner as provided in II.S. When both additions and credits are involved in anyone change, the net shall be computed to include overhead and profit, identified separately, for both additions and credit, provided however, the CONTRACTOR shall not be entitled to claim lost profits for any Work not performed. ARTICLE 12 -TIME FOR COMPLETION, LIOUIDATED DAMAGES AND CHANGE OF THE CONTRACT TIME. 12.1 Time is of the eSSence to this contract and the date of beginning and the time for completion of the Work are essential conditions of the Contract. Therefore, the Work shall be commenced on the date specified in the Notice to Proceed and completed within the time specified for completion of the work 12.2 The CONTRACTOR shall proceed with the Work at such rate of progress to ensure full completion within the Contract Time. It is expressly understood and agreed, by and between the CONTRACTOR and the OWNER, that the Contract Time for the completion or the Work described herein Is a reasonable time. taking Into consideration the average climatic and economic: conditions and other factors prevailing in the locality of the Work. No extension of time shall be granted due conditions that the Contractor knew of or should have known of before bidding on the project or due to Inclement weather, except as provided in section 12,7. 12.3 If the CONTRACTOR shall fail to complete the Work within the Contract Time, or extension of time granted by the CITY, then the CONTRACTOR shall pay to the OWNER the amount of liqUidated damages as specified in the Contract Documents for each calendar day after the scheduled date for completion as adjusted by written Change Orders that extended the completion date. 12.3.1 These amounts are not penalties but are liquidated damages Incurred by the OWNER for its inability to obtain full use of the Project. liquidated damages are hereby fixed and agreed upon between the parties, recognizing the impossibility of precisely ascertaining the amount of damages that will be sustained as a consequence of such delay, and both parties desiring to obviate any question or dispute concerning the amount of said damages and the cost and effect of the failure of CONTRACTOR to complete the Contract on time. The above-stated liquidated damages shall apply separately to each phase of the Project for which a time for completion is given. 12.3.2 CITY is authorized to deduct the liquidated damages from monies due tOt CONTRACTOR (or the Work under this Contract. 12.4 The Contract Time may only be changed by a written Change Order. Any claim for an extension in the CONTRACT TIME shall be based on written notice delivered to the CITY and CONSULTANT within five (5) business days of the occurrence of the event giving rise to the claim and stating the general nature of the claim including supporting data, All claims for adjustment in the Contract Time shall be evaluated 51 and recommended by the CONSULTANT, with final approval by the CITY'S representative. Any change in the Contract Time resulting from any such claim shall be incorporated in a written Change Order. 12.5 All time limits stated in the Contract Documents are of the essence of the Contract. 12.6 No claim for delay shall be allowed because of failure to furnish Drawings before the expiration of fourteen (14) calendar days after demand has been made in writing to the CONSULTANT for such Drawings. Furthermore, there shall be no monetary compensation for such delay and the CONTRACTOR's sale remedy shall be an extension of time for the period of delay. 12.7 Extensions to the Contract Time for delays caused by the effects of inclement weather shall not be granted unless the weather was unusual for South Florida and could not have been anticipated, the abnormal weather is documented by records from the national weather service and the abnormal weather Is documented to have had a substantial affected on the construction schedule. 12.8 No Damages for Delay: The CONTRACTOR agrees that he shall not have any claim for damages due to delay unless the delay exceeds 6 months, whether Individually or cumulatively, and then the damages shall be limited to increased cost of materials that were unanticipated and that would not have been incurred but for the delay. Other than as set forth above, the only remedy for any delay shall be limited to an extension of time as provided for In Section 12.4 which shall be the sole and exclusive remedy for such resulting delay. Other than as set forth above, CONTRACTOR shall not be entitled to an increase in the Contract Price or payment or compensation of any kind from OWNER for direct, indirect, consequential, Impact or other costs, expenses or damages, including but not limited to, costs of acceleration or inefficiency, overhead or lost profits, arising because of delay, disruption, interference or hindrance from any cause whatsoever, whether such delay, disruption, interference or hindrance be reasonable or unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable, 12,9 The CONTRACTOR waives all claims that are not presented to the City In writing on or before the 21 st day following the date of the event upon which the claim is based. 12.10 Dispute Resolution: If any dispute concerning a question of fact arises under the Contract, other than termination for default or convenience, the CONTRACTOR and the city department responsible for the administration of the Contract shall make a good faith effort to resolve the dispute, If the dispute cannot be resolved by agreement, then the department with the advice of the City Attorney and the CONSULTANT shall rule on the disputed issue and send a written copy of its decision to the CONTRACTOR. CONTRACTOR shall comply with such decision and shall not delay the project. ARTICLE 13 -GUARANTEE, 13.1 The CONTRACTOR shall guarantee and unconditionally warrant through either the manufacturer or the CONTRACTOR directly, all materials and eqUipment furnished and Work performed for patent Defective Work for a period of one (I) year from the date of Final Acceptance as indicated in the CONSULTANT Letter of Recommendation of Acceptance or from the date when the defect was first observable, whichever is later. The same guarantee and unconditional warranty shall be extend (or five (5) years from the date of Final Acceptance as indicated in the CONSULTANT Letter of Recommendation of Acceptance for latent Defective Work. The CITY will give notice of observed defects with reasonable promptness. In the event that the CONTRACTOR should fall to commence to correct such Defective Work within ten (10) calendar days after haVing received written notice of the defect, or should the CONTRACTOR commence the corrective work, but fail to prosecute the corrective work continuously and diligently and in accordance with the Contract Documents, applicable law, rules and regulations, the CITY may declare an event of default, terminate the Contract in whole or in part and cause the Defective Work to be removed or corrected and to complete the Work at the CONTRACTOR's expense, and the CITY shall charge the CONTRACTOR the cost thereby incurred. The Performance Bond shall remain in (ull force and effect through the guarantee period. 13.2 The specific warranty periods listed in the Contract Documents, if different from the period of time listed in Section 13.1, shall take precedence over Section 13.1. 13.3 CONTRACTOR shall act as agent, on a limited basis for the OWNER, at the CITY', option, solely for the follow~up concerning warranty compliance for all items under manufacturer's Warranty/Guarantee and for the purpose of completing all forms for Warranty/Guarantee coverage under this Contract. 13.4 In case of default by the CONTRACTOR, the City of South Miami may procure the articles or services from other sources and hold the CONTRACTOR responsible for any excess costs occasioned or Incurred thereby. 13.S The CITY may withhold acceptance of, or reject items which are found upon examination, not to meet the specification reqUirements. Upon written notification of rejection, items shall be removed within five 52 (5) business days by the CONTRACTOR at his own expense and redelivered at his expense. Rejected goods left longer than thirty (30) calendar days shall be regarded as abandoned and the City shall have the right to dispose of them as its own property and the CONTRACTOR thereby waives any claim to the good or to compensation of any kind. Rejection for Non-conforming Work or failure to meet delivery schedules may result in the Contract being found in default. ARTICLE 14. PAYMENTS AND COMPLETION. payments to Contractor 14, I The Contractor shall not be entitled to any money for any work performed before the issuance of a Notice to Proceed on the form described in the Contract Documents and the issuance by the City of a "purchase order", or any other document, does not and shall not authorize the commencement of the Work. At least ten (10) calendar days before each progress payment falls due (but not more often than once a month). the CONTRACTOR shall submit to the CONSULTANT a partial payment estimate filled out and signed by the CONTRACTOR covering the Work performed during the period covered by the partial payment estimate and supported by such data as the CONSULTANT may reasonably require. All progress payment applications after the first progress payment shall be accompanied by partial releases of lien executed by all persons, firms and corporations who have furnished labor, services or materials incorporated into the work during the period of time for which the previous progress payment was made, releasing such claims and lien rights, if any, of those persons. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and SUitably stored at or near site, the partial payment estimate shall also be accompanied by such supporting data, satisfactory to the CITY, which establishes the OWNER'S title to the material and equipment as well as certificates of insurance providing coverage for 100% of the value of said material and equipment covering the material and equipment from all casualties as well as theft, vandalism, fire and flood. The CONTRACTOR shall replace at its expense any stored materials paid for which are either damaged or stolen before installation. The CONSULTANT will within ten (10) calendar days after receipt of each partial payment estimate, either certifying in writing its approval of payment and present the partial payment estimate to the OWNER, or return the partial paYl)1ent estimate to the CONTRACTOR, indicating in writing his reasons for refusing to approve payment. In the latter case, the CONTRACTOR may make the necessary corrections and resubmit the partial payment estimate. The OWNER, will within thirty (30) calendar days of presentation to it of any approved partial payment estimate, pay the CONTRACTOR a progress payment on the basis of the approved partial payment estimate. The OWNER shall retain ten (10%) percent of the amount of each payment until Final Completion and Acceptance of all Work covered by the Contract Documents, Any Interest earned on the retainage shall accrue to the benefit of the OWNER. 14.2 The CONTRACTOR. before it shall receive final payment. shall deliver to the CITY a Contractor's Final Payment Affidavit as set forth in the Florida Construction lien Statute as well as final releases of lien executed by all persons who have performed or furnished labor, services or materials, directly or indirectly, which was incorporated into the Work. If any person refuses to provide such a release or provides a conditional release, the CITY shall have the right to issue a joint check made payable to the CONTRACTOR and such person. Contractor's Warranty of Title 14.3 The CONTRACTOR warrants and guarantees that title to all Work, materials and equipment covered by an Application for Payment whether the Work, material or eqUipment is incorporated In the Project or not, shall have passed to the OWNER prior to the making of the Application for Payment, free and clear of all liens, claims, security interest and encumbrances (hereafter in these General Conditions referred to as "liens'1i and that no Work. materials or equipment, covered by an Application for Payment. will have been acquIred by the CONTRACTOR or by any other person performing the Work at the site or furnIshing materials and eqUipment for the Project, under or pursuant to an agreement under which an interest therein or encumbrance thereon is retained by the seller or otherwise imposed by the CONTRACTOR or such other person. Approyal of Payment 14.4 The CONSULTANT's approval of any payment requested in an Application for Payment shall constitute a representation by him to the CITY, based on the CONSULTANT's on site observations of the Work in progress as an experienced professional and on his review of the Application for Payment and supporting data, that the Work has progressed to the point indicated in the Application for Payment; that. to the 51 best his knowledge, information and belief, the quality of the Work is in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning Project upon substantial completion as defined In Article I, to the results of any subsequent tests called for in the Contract Documents and any qualifications stated in his approval); and that the CONTRACTOR is entitled to payment of the amount approved. However, by approving, any such payment the CONSULTANT shall not thereby be deemed to have represented that he made exhaustive or continuous on·site observations to check the quality or the quantity of the Work, or that he has reviewed the means, methods, techniques, sequences and procedures of construction or that he had made any examination to ascertain how or for what purpose the CONTRACTOR has used the moneys paid or to be paid to him on account of the Contract Price, or that title to any Work, materials, or eqUipment has passed to the OWNER free and clear of any liens. 14.5 The CONTRACTOR shall make the following certification on each request for payment: "I hereby certify that the labor and materials listed on this request for payment have been used in the construction of this Work and that all materials included in this request for payment and not yet Incorporated into the construction are now on the site or stored at an approved location, and payment received from the last request for payment has been used to make payments to all his Subcontractors and suppliers, except for the amounts listed below beside the names of the persons who petiormed work or supplied materials". In the event that the CONTRACTOR withholds payment from a Subcontractor or Supplier. the same amount of money shall be withheld from the CONTRACTOR's payment until the issue is resolved by written agreement between them and then a joint check shall be made payable to the person in question and the CONTRACTOR in accordance with the settlement agreement. otherwise the money shall be held by the OWNER until a judgment is entered In favor of the CONTRACTOR or the person, in which case the money shall be paid according with said judgment. Nothing contained herein shall indicate an intent to benefit any third persons who are not signatories to the Contract. 14.6 The CONSULTANT may refuse to approve the whole or any part of any payment if, in its opinion, it is unable to make such representations to the OWNER as required this Section 14. It may also refuse to approve any payment, or It may void any prior payment application certification because of subsequently discovered eVidence or the results of subsequent inspection or tests to such extent as may be necessary in its opinion to protect the OWNER. from loss because: 14.6.1 of Defective Work, or completed Work has been damaged requiring correction or replacement, 14.6.2 the Work for which payment is requested cannot be verified. 14.6.3 claims of Liens have been flied or received, or there is reasonable evidence indicating the probable filing or receipt thereof, 14.6.4 the Contract Price has been reduced because of modifications, 14.6.S the CITY has correct Defective Work or completed the Work in accordance with Article 13. 14.6.6 of unsatisfactory prosecution of the Work, including failure to dean up as required by paragraphs 6.29 and 6.30, 14.6.7 of persistent failure to cooperate with other contractors on the Project and persistent failure to carry out the Work In accordance with the Contract Documents, 14.6.8 of liqUidated damages payable by the CONTRACTOR, or 14.6.9 of any other violation of, or failure to comply with provisions of the Contract Documents. 14.7 Prior to Final Acceptance the OWNER, with the approval of the CONSULTANT, may use any completed or substantially completed portions of the Work provided such use does not interfere with the CONTRACTOR's completion of the Work. Such use shall not constitute an acceptance of such portions of the Work. 14.8 The CITY shall have the right to enter the premises for the purpose of doing Work not covered by the Contract Documents. This provision shall not be construed as relieving the CONTRACTOR of the sole responsibility for the care and protection of the Work. or the restoration of any damaged Work except such as may be caused by agents or employees of the OWNER. 14.9 Upon completion and acceptance of the Work the CONSULTANT shall issue a Certificate attached to the Final Application for Payment that the Work has been accepted by It under the conditions of the Contract Documents. The entire balance found to be due the CONTRACTOR. including the retained percentages, but except such sums as may be lawfully retained by the OWNER. shall be paid to the CONTRACTOR within thirty (30) calendar days of completion and acceptance of the Work. 5. 14.10 Upan The awarded CONTRACTOR will be strangly encouraged ta register as an ePayables Vendor with the Owner. The Bank of America ePayables Solution is an automated card payment process that shifts accounts payable disbursements to corporate purchasing cards. ePayables, streamline the process of making payments to your organization going forward, the City will provide the CONTRACTOR with a credit card account number to keep on file. This card has unique security features, with $0 of available funds until an invoice is approved for payment. After an invoice has received proper and complete approval, an electronic remittance advice will be sent via e-mail, or fax, which notifies the CONTRACTOR that the funds have been transferred in to the account linked to the card for the amount listed on the invoice and/or remittance email. Please refer to the ePayables Questions & Answers Form contained in this RFP or contact the OWNER's Finance department at (305) 663-6343 with any questions. Acceptance of Final Payment as Release 14.11 The Acceptance by the CONTRACTOR of Final Payment shall b. and shall operate as a release to the OWNER and a waiver of all claims and all liability to the CONTRACTOR other than claims previously filed and unresolved. The waiver shall include all things done or furnished in connection with the Work and for every act and neglect of the OWNER and others relating to or arising out of this Work. Any payment, however, final or otherwise, shall not release the CONTRACTOR or its sureties from any obligations under the Contract Documents or the Performance Bond and Payment Bonds. 14.12 The CONSULTANT may void any certification of Substantial Completion or Final Campletion of the Work as may be necessary In his opinion to protect the OWNER from loss if he determines, because of subsequently discovered evidence or the results of subsequent inspection or tests, that: 14.12.1 the Work is defective, or that the completed Work has been damaged due to the fault of the CONTRACTOR or any individual or entity operating under or through It requiring correction or replacement to the extent that the project is no longer Substantially Completed, or in the case of Final Completion certification, Is no longer Finally Competed. 14.12.2 the Work necessary to be completed for the purpose of certifying the work as being Substantially Completed or Finally Completed cannot be verified, 14.12.3 claims or liens have been filed or received, or there is reasonable evidence indicating the probable filing or receipt thereof that, if valid and paid, would reduce the amount owing to the CONTRACTOR BY 20% in the case of Substantial Completion and 5% in the case of Final Completlan. 14.12.4 there is Defective Work the value of which, If deducted from the contract price would reduce the amount owing to the CONTRACTOR BY 20% in the case of Substantial Completion and 5% In the case of Final Completion. 14.13 If the CONSULTANT de-certifies any portion of the Work that was certified ("Initial Certification") by the CONSULTANT, the CONTRACTOR shall repay to the City of South Miami any money pa.ld as a result of said Initial Certification being issued which shall be paid only when the decertified work is re- certified. ARTICLE 15 -SUSPENSION OF WORK AND TERMINATION. 15.1 The CITY may, at any time and without cause, suspend the Work or any portion thereof for a period of not more than ninety (90) calendar days by notice in writing to the CONTRACTOR and the CONSULTANT, which shall fix the date on which Work shall be resumed. The CONTRACTOR shall be allowed an increase in the Contract Price or an extension of the Contract Time, or both. directly attributable to any suspension and if a claim is timely made and If it is allowed under the terms of Articles I I or Article 12. City May Terminate 15.2 If the CONTRACTOR is adjudged bankrupt or insolvent, or if he makes a general assignment for the benefit of its creditors, or if a trustee or receiver is appointed for the CONTRACTOR or for any its property, or if he files a petition to take advantage of any debtor's act, or to reorganize under bankruptcy or similar laws, or if he repeatedly fails to supply sufficient skilled workmen or suitable materials or equipment, or if he repeatedly fails to make prompt payments to Subcontractors or for labor, materials or eqUipment or he disregards laws, ordinances, rules, regulations or orders of any pUblic body having jurisdiction, or if he disregards the authority of the CONSULTANT, ar if he otherwise violates any provision of. the Contract Documents, then the CITY may. without prejudice to any other right or remedy and after giving the CONTRACTOR and the Surety seven (7) calendar days written notice. ss terminate the services of the CONTRACTOR and take possession of the Project and of all materials, equipment, tools, construction equipment and machinery thereon owned by the CONTRACTOR, and finish the Work by whatever method it may deem expedient, In such case the CONTRACTOR shail not be entitled to receive any further payment until the Work Is finished. If the unpaid balance of the Contract Price exceeds the direct and indirect costs of completing the Project. including compensation for additional professional serv1ces, such excess shall be paid to the CONTRACTOR. If such costs exceed such unpaid balance, the CONTRACTOR or the Surety on the Performance Bond shall pay the difference to the OWNER, Such costs incurred by the OWNER shall be determined by the CONSULTANT and incorporated in a Change Order, If after termination of the CONTRACTOR under this Section, It is determined by a court of competent jurisdiction for any reason that the CONTRACTOR was not in default, the rights and obligations of the OWNER and the CONTRACTOR shall be the same as if the termination had been issued pursuant to Section IS,S 15.3 Where the CONTRACTOR'S services have been so terminated by the CITY said termination shall not affect any rights of the OWNER against the CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys by the OWNER due the CONTRACTOR shall not release the CONTRACTOR from liability, I SA Upon seven (7) calendar days written notice to the CONTRACTOR and the CONSULTANT, the CITY may, without cause and without prejudice to any other right or remedy, elect to terminate the Contract for the convenience of the OWNER, In such case, the CONTRACTOR shall be paid for all Work executed and accepted by the CITY as of the date of the termination, minus any deduction for damage or Defective Work. No payment shall be made for profit for Work which has not been performed. I 5AA The CITY reserves the right in the event the CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested, to obtain the good andlor services from other sources and deducting the cost from the Contract Price without Violating the intent of the Contract. Removal of Equipment 15.S In the case of termination of this Contract before completion for any cause whatever, the CONTRACTOR, if notified to do so by the CITY, shall promptly remove any part or all of its equipment and supplies from the property of the OWNER, Should the CONTRACTOR not remove such equipment and supplies, the CITY shall have the right to remove them at the expense of the CONTRACTOR and the CONTRACTOR agrees that the OWNER shall not be liable for loss or damage to such eqUipment or supplies. Equipment and supplies shall not be construed to include such items for which the CONTRACTOR has been paid in whole or in part, Contractor May Stop Work or Terminate 15,6 If, through no act or fault of the CONTRACTOR, the Work is suspended for a period of more than ninety (90) calendar days by the CITY or by order of other public authority, or under an order of court or the CONSULTANT fails to act on any Application for Payment within thirty (30) calendar days after it is submitted, or the OWNER fails to pay the CONTRACTOR any sum approved by the CONSULTANT, within thirty (30) calendar days of its approval, and presentation, then the CONTRACTOR may, upon twenty (20) calendar days written notice to the CITY and the CONSULTANT, terminate the Contract. The CITY may remedy the delay or neglect within the twenty (20) calendar day time frame, If timely remedied by the CITY the Contract shall not be considered terminated. In lieu of terminating the Contract, if the CONSULTANT has failed to act on an Application for Payment or the OWNER has failed to make any payment as afore said, the CONTRACTOR may upon ten (10) calendar days' notice to the CITY and the CONSULTANT stop the Work until it has been paid all amounts then due, Indemnification of Independent Consultant. 15,7 The CONTRACTOR and the CITY hereby acknowledges that if the CONSULT ANT is an independent contractor of the OWNER, the CONSULTANT may be reluctant to rule on any disputes concerning the Contract Documents or on the performance of the CONTRACTOR or the OWNER pursuant to the terms of the Contract Documents. Therefore, the OWNER, at the CONSULTANT's request. agrees to provide the CONSULTANT with a written indemnification and hold harmless agreement to indemnify and hold the CONSULTANT harmless as to any decision in this regard before the CONSULTANT makes 56 an interpretation, de-certifies a payment application, decertifies Substantial Completion, decertifies Final Completion. certifies an event of default, or approves any action which requires the approval of the CONSULTANT. ARTICLE 16 -MISCELLANEOUS. 16.1 Whenever any provision of the Contract Documents requires the giving of written notice It shall be deemed to have been validly given if delivered in person to the Individual or to a member of the firm or to an officer of the corporation for whom It is intended, or if delivered at or sent by registered or certified mail, postage prepaid, to the last known business address. 16.2 The Contract Documents shall remain the property of the OWNER. The CONTRACTOR and the CONSULTANT shall have the right to keep one record set of the Contract Documents upon completion of the Project. 16.3 The duties and obligations Imposed by these General Conditions, Special Conditions and Supplementary Conditions, if any, and the rights and remedies available hereunder, and, in particular but without limitation, the warranties, guarantees and obligations imposed upon CONTRACTOR by the Contract Documents and the rights and remedies available to the OWNER and CONSULTANT thereunder, shall be in addition to, and shall not be construed in any way as a limitation of, any rights and remedies available by law. by special guarantee or by other prOVisions of the Contract Documents. 16.4 Should the OWNER or the CONTRACTOR suffer injury or damage ta its person or property because of any error, omission, or act of the other or of any of their employees or agents or others for whose acts they are legally liable, claim shall be made in writing to the other party within twenty one (21) calendar days of the first observance of such injury or damage. ARTICLE 17. WAIVER OF IURY TRIAL. 17.1 OWNER and CONTRACTOR knowingly, Irrevocably voluntarily and intentionally waive any right either may have to a trial by jury in State or Federal Court proceedings in respect to any action, proceeding, lawsuit or counterclaim arising out of the Contract Documents or the performance of the Work thereunder. ARTICLE 18· ATTORNEYS FEES IURISDICTION I VENUE I GOVERNING LAW. 18.1 The Contract shall be construed in accordance with and governed by the law of the State of Florida. 18.2 The parties submit to the jurisdiction of any court of competent jurisdiction in Florida regarding any claim or action arising out of or relating to the Contract or Contract Documents. Venue of any action to enforce the Contract shall be in Miami-Dade County, Florida. 18.3 Except as may be otherwise prOVided in the Contract Documents. all claims, counterclaims, disputes and other matters in question between the OWNER and the CONTRACTOR arising out of or relating to this Contract or the breach thereof, shall be decided in a court of competent jurisdiction within the State of Florida. ARTICLE 19. PROIECT RECORDS. 19.1 The CITY shall have right to inspect and copy during regular business hours at OWNER'S expense, the books and records and accounts of CONTRACTOR which relate in any way to the Project, and to any claim for additional compensation made by CONTRACTOR, and to conduct an audit of the financial and accounting records of CONTRACTOR which relate ta the Project. CONTRACTOR shall retain and make available to CITY all such books and records and accounts, financial or otherwise, which relate to the Project and to any claim for a period of three (3) years following final completion of the Project. During the Project and the three (3) year period following final completion of the Project, CONTRACTOR shall provide CITY access to its books and recards upon five (5) business day's written notice. 19.2 CONTRACTOR and all of Its subcontractors are reqUired to comply with the public records law (5.119.070 I) while providing services on behalf of the OWNER and the CONTRACTOR, under such conditions, shall incorporate this paragraph in all of Its subcontracts for this Project. CONTRACTOR and its subcontractors are specifically required to: (a) Keep and maintain public records that ordinarily and necessarily would be reqUired by the public agency in order to perform the service; (b) Provide the public with access to pUblic records on the same terms and conditions that the public agency would provide the records and at a cost that does not exceed the cost provided in this chapter or as otherwise 57 provided by law; (c) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law; and (d) Meet all requirements for retaining public records and transfer, at no cost, to the public agency all public records in possession of the contractor upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. All records stored electronically must be provided to the public agency in a format that is compatible with the information technology systems of the public agency. 19.3 If CONTRACCTOR or its subcontrnctor does not comply with a public records reques~ the CITY shall have the right to enforce this contract provision by specific performance and the person who violates this provision shall be liable to OWNER for its costs of enforcing this provision, including attorney fees incurred in all proceedings, whether administrative or civil court and in all appellate proceedings. ARTICLE 20 -SEVERABILITY. 20.1 If any provision of the Contract or the application thereof to any person or situation shall to any extent, be held invalid or unenforceable, the remainder ofthe Contract, and the application of such provisions to persons or situations other than those as to which it shall have been held invalid or unenforceable shall not be affected thereby, and shall continue in full force and effect, and be enforced to the fullest extent permitted by law. ARTICLE 21 -INDEPENDENT CONTRACTOR. 21.1 The CONTRACTOR is an independent CONTRACTOR under the Contract. Services provided by the CONTRACTOR shall be by employees of the CONTRACTOR and subject to supervision by the CONTRACTOR, and not as officers, employees, or agents of the OWNER. Personnel policies, tax responsibilities, social security and health insurance, employee benefits, purchasing policies and other similar administrative procedures. applicable to services rendered under the Contract shall be those of the CONTRACTOR. ARTICLE 22 -ASSIGNMENT. 22.1 The CONTRACTOR shall not transfer or assign any of Its rights or duties, obligations and responsibilities arising under the terms, conditions and provisions of this Contract without prior written consent of the City Manager. The CITY will not unreasonably withhold andlor delay its consent to the assignment of the CONTRACTOR's rights. The CITY may, in its sole and absolute discretion, refuse to allow the CONTRACTOR to assign its duties, obligations and responsibilities. In any even~ the CITY shall not consent to such assignment unless CONTRACTOR remains jointly and severally liable for any breach of the Agreement by the assignee. the assignee meets all of the CITY's requirements to the CITY's sale satisfaction and the assignee executes all of the Contract Documents that were required to be executed by the CONTRACTOR IN WITNESS WHEREOF, the parties hereto have executed the General Conditions to acknowledge their indusion as part of the Contract Documents on this __ day of , 20 __ , Print Signatory' arne: Monica Hernandez Title of Signatory. __ -'-P"-'e:cs:..:id=e=nt'--_______ _ ATTESTED: Signature: -:-:-:--,::-_-:-____ _ Maria Menendez City Clerk Read and Approved as to Form. Language. Legality, and Execution Thereof: Signature: --:::--;-_______ _ City Attorney OWNER: CITY OF SOUTH MIAMI Signature: 58 Steven Alexander City Manager EXHIBIT 8 Supplementary Conditions Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW·20 15·20 A. Consultant: In accordance with ARTICLE I of the General Conditions CONSULTANT is defined as the person identified as the CONSULTANT in the Supplementary Conditions or if none, then CITY's designated representative as Identified in the Supplementary Conditions. The CONSULTANT's, if any, and the City's Designated Representative's name, address, telephone number and facsimile number are as follows: Consultant: T.Y. Lynn/HJ Ross 20 I Alhambra Clrcie, Suite 900 Coral Gables. FI 33134 Phone: 305/567·1888 Fax: 305/567·177 I B. Termination or Substitution of Consultant Nothing herein shall prevent the CITY from terminating the sertices of the CONSULTANT or from subStituting another "person" to act as the CONSULTANT. C. Plans for Construction: The successful CONTRACTOR will be furnished one (I) sets of Contract Documents without charge. Any additional copies required will be furnished to the CONTRACTOR at a cost to the CONTRACTOR equal to the reproduction cost D. The Scope of Services, also referred to as the Work in the contract documents, is as set forth in the RFP and in the attached EXHIBIT I and if there is a conflict the attached Exhibit shall take precedence. E. Contractor shall comply with the insurance and indemnification requirements as set forth in the RFP and in the attached EXHIBIT 2 and if there Is a conflict the attached Exhibit shall take precedence. F. The Work shall be completed in 75 calendar days unless a shorter time is set forth in the Contract and in such event the Contract shall take precedent notwithstanding any proviSion in the General Conditions to the Contract that may be to the contrary .. IN WITNESS WHEREOF, the parties hereto have executed the Supplementary Conditions to acknowledge their inclusion as part of the Contract on this __ day of , 20 Signat Print Signatory's Name. -r-:..M~o:un~ica~H=,:,e!;!r]JnW~O\L ____ _ Title of Signatory: '----'-P"'re"s"'id"'e"'n"'t _________ _ ATTESTED: Signature: --:--:-:-::-:--'7'----- Maria Menendez City Clerk Read and Approved as to Form, Language, Legality. and Execution Thereof: Signature: -:::--:-_______ _ City Attorney 59 OWNER: CITY OF SOUTH MIAMI Signature: Steven Alexander City Manager Project Name: RFPNO. Date: Sent: lilt ( 11\ Of PI t,\'!>M, r IIY!,\(, ADDENDUM No. #1 Mango Terrace Neighborhood Traffic Calming Improvements #PW·20 15·20 July 28, 2015 FaxlE.maii/webpage This addendum submission is issued to clarify, supplement and/or modify the previously issued Solicitation, and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. Question # I: Could you please provide a rough estimate of the project value for the project listed above? Answer to Question #1: The budget line item for this project in the City's Adopted Budget for FY 2014 -20 IS, Capital Improvement Program S·Year Plan is $140,000. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TQ SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. Pagelofl 60 Project Name: RFP NO. Date: Sent: ADDENDUM No. #2 Mango Terrace Neighborhood Traffic Calming Improvements #PW-20 I 5-20 July 30. 2015 FaxlE-mail/webpage This addendum submission is issued to clarify. supplement andlor modify the previously issued Solicitation. and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. SPECIAL NOTE: The proposed Traffic Calming Circle included in the plans as Exhibit I, Attachment B in the RFP. is under Miami-Dade County Review. If the Traffic Calming Circle is not approved by Miami Dade County. the City will not proceed with constructing the Traffic Calming Circle. Therefore. the "Construction Bid Form," Exhibit 4, is amended and attached to Addendum No.2 and shall be a part of the RFP by way of reference. Respondents shall submit two price proposals; (I) a "Lump Sum Price" for the entire project as depicted in the plans. Exhibit I, Attachment Band; (2), a "Lump Sum Price" WITHOUT the Traffic Calming Circle in the event Miami-Dade County does not approve the Traffic Circle. Respondents shall submit the revised "Construction Bid Form" dated July 30. 2015 with their proposal. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATIO:~ Page 1 of 4 /fjlflfJ 61 Project Name: RFPNO. Date: Sent: ADDENDUM No. #3 Mango Terrace Neighborhood Traffic Calming Improvements #PW·20 15·20 August 4. 2015 FaxlE-mail/webpage This addendum submission is issued to clarify. supplement and/or modify the previously issued Solicitation. and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. I. In the above project if you look at sheet II and sheet 4 in the center of the circle should be sod. but the cross section D·D on sheet 4 is showing pavers instead of sod. Please clarify. RESPONSE: The detail in section D-D on sheet 4 is showing a hatch similar to pavers in the center ofthe traffic circle. The center ofthe circle is to have sod. as per plan view. 2. Note I in sheet 4 say: "Contractor to repair existing pavement damaged during installation of traffic calming devices. Cost shall be incidental to contract price." Does mean that the cost for asphalt repair will be reimbursable? RESPONSE: No. The contractor is responsible for any damage to the existing pavement caused by his work. 3. Is a revised Schedule of Values available that depicts a Lump Sum Base Price without the Traffic Calming Circle? Page I of5 62 RESPONSE: A revised schedule of values for Mango Terrace is attached, and shall be a part of the RFP by way reference. This schedule of values is for the entire project. Respondents shall subtract all items related to the traffic circle for the Lump Sum Base Price (Without Traffic Calming Circle). 4. Is there any traffic signalization or street lighting for this project? RESPONSE: No. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. Page 2 ofS 63 CORELAND CONSTRUCTION Past Construction Projects Project Client Contract Completion Project Description Information Information Amount Date City of Florida City General C0Q.Struction: FL City Community Redevelopment Agency Community Redevelop. Agency • 293.119 Dec.201' Installation Of new sewer lines, abandonment of septic tanks and connection Roadway and Sanitary Sewer Improvements 404 west Palm Drive (lump sum) to new sewer lines, sitework, installation of new curbs and sidewalks, Project# 10-019-04 Florida City. FL 33034 asphalt paving. striping, signage, landscaping. CM: Rick SuMs 3Q&.247-82.21 g:8exdj[@fioridas;iMl·gj2v South Broward Drainage District General Construction' SBDD Culvert Replacement 6591 SW 160 Avenue • 71.673 Dec.2012 Installation of 48" reinforced concrete pipe culvert and headwalls across No ContractJProject# AssigrIed Southwest Ranches, FL (Iumpaum) roadway While maintaining egress for trafftc; expansion of roadway, grading, PM: Luis Ochoa 954-68()..3337 paving, and installation of guardrails, luis~d.org Electrical RehabiUtation @ National Perk Service Genera! Construction: Fort Jefferson Nationa! Park 40001 State Road 9336 $ 320,712 Feb.2012 Complete rehabilitation/upgrade to electrical system at Fort Jefferson National Dry T ortugas, Fl Homestead, Fl 33034 (Jump.sum) Park, in Dry Tortugas, FL Remote project site located 70 miles offshore from Owner: US Government CO: William leady 305-242-n92 Key West, Flo only acceSsible via boat / plane, COTR: William Shebey305-242.n48 City of Fort lauderdale General Construction· COBG Speed Hump Installation 100 North Andrews Avenue $ 120,767 Jul.2012 InstaUation of 31 flat top profile speed humps, 38 signs, sbiplng, and all other Project# 11806 Ft. lauderdale, Fl (lumpeum) related work. PM: Dane ESdeUe 954-828-6885 desdelle®fo~ uderdale OIl US National Pari( Service eneral 0 ·0 . Frog City Air Boat Ramp 40001 State Road 9336 $ 45,348 Feb,2013 Installation of pre-cast concrete ramp for air boatlboat launching, Wort< incl,: Contract#-P12PC41070 Homestead, Fl 33034 (lumpaum) turbidity/erosion control. excavation, grading, hauVdlsposal ofwaste material, PM: WilHam Shelley 3Q5..242·7748 installation of pre-east concrete, rip rap. william shel~nl!§,go ... CIty of South Miami General Construction· Sidewalk Repair Phase II 6130 Sunset Drive $ 20,681 Apr.2013 Demolition and installation of sidewalks throughout multiple locations within Contract# P0012076 South Miami, FL 33143 (Iumpeurn) City Of South Miami. PM: Jorge Vera 305-403-2072 jvera@Bouthmlamifl.gov City of lauderhill General Construction' Supply & InstaJlaUonIConstruction ofConentte 5581 W. Oakland Perk Blvd, • 91,619 Mar.2014 Blanket contract to $UPply & install/construct concrete sidewalks, pads & Sidewalks, Pads & Curbs During the Period LaudemHl, Fl 33313 {lump sum) curbs through inalV'ldual purchase orders based on City's requirements/needs February 1, 2013 to .h!Inuary 31. 2014 PM: Vince Miller 954-730-4233 at various locations throughout City of LaudertJiU, Bid# 2013-009 "",il!er@lau96rtlilI.n 90'1 March 1. 2014 to February 28,2015 Bid# 2014-015 I '---&4 CORELAND CONSTRUCTION Past Construction Projects Project Client Contract Completion Project Description Infonnation lnfonnation Amount Oate Broward County Transit Dept. Generpl Construction" Transit Infrastructures & Bus Shelters 1 N. University Drive, 24018 $ 119,414 Feb.2014 Install concrete pads, curbs/gutters, & electrical and install new owner-provided Improvements Plantation,Fl (lump sum) bus Shelter structures at five different locations within 8roward County. Work W0#158S-A PM: Arethia Oouglas conducted on roadways, requiring MOT planslpenniis. !!~!.!lI~~afdO<!O National Par1t Selvice US National Park Service Genera! Construction' New Residence @ Ft Jefferson 12795 W. Alameda Parkway. Rm 311 $ 1,152.000 Apr. 2014 New construction of six unit residence slrucbJre to house park staff Dry Tortuga National Park Denver. Colorado (lump sum) Garden Cove Key. Fl CO: Damn Knepp, 303-969-205S Trades: Sitework, Concrete/Masonry, ROofing, Plumbing, Electrical, DRTO# 168911 COTR: Jose Baerga 305-242·ffie Mechanical, Fire Sprinklers/Protection. Windows/Doors, Finishes. etc. 6S Coreland Construction Corp. Home Office Organization Chart & Proposed Project Organization Chart I. Home . Office . Monica ' -Nestor Hemandez Hernandez President Finance Admin. InstJrance . Ma~eting . Personnel & Customer Relations ... Cori!J:.d Admin. '- Alvaro Medina construction Mariager Oscar Sel!ran . Superintendent Construction PersonnellLabor Proposed Project Per:sonnel Nestor Hernandez Sr. ProjeCt Manager 66 VP ... Project Estimating Admin. "' ~- EDUCATION I LICENSES: NESTOR J. HERNANDEZ 7335 SW 142 Terrace Palmetto Bay, FL 33158 nhernandeZ@corelandconstruction.com Florida Licensed General Contractor -CGC 15 I 0780 Miami-Dade Community College -Course study focusing in architecture Miami Senior High School PROFESSIONAL EXPERIENCE: Coreland Construction Corp. -Vice President (1995 -Present), President (1988 -1995) Duties and responsibilities include: Estimating -attending pre-bid meeting to fumiliarize site conditions (etc.), reviewing plans and specifications, preparing detailed materialsllabor take-off, analyzing and comparing sub-trade bids, finalizing final bid estimate and bid documents for submittal. Soliciting potential work (bid journals, invitations to bid, etc.), preparing & sending invitations to bid to sub- trades and suppliers, preparing & distributing bidding packages to sub-trades and suppliers, preparing pre-bid RFI's (requests for information). Project Management -preparing project schedule, schedule of values, attending pre-construction and construction meetings, preparing'reviewing product specifications submittals, coordinating'scheduling labor & subcontractors, preparing RFls/correspondence, overseeing field work/progress of work to comply with contract documents, preparing monthly payment requisitions. Amcon Inc. -Vice President (1994 -1996) Duties and responsibilities included: Estimating -attending pre-bid meeting to familiarize site conditions (etc.), reviewing plans and specifications, preparing detailed materialsllabor take-off, analyzing and comparing sub-trade bids, finalizing final bid estimate and bid documents for submittal. Soliciting potential work (bid journals, invitations to bid, etc.), preparing & sending invitations to bid to sub- trades and suppliers, preparing & distributing bidding packages to sub-trades and suppliers, preparing pre-bid RFl's (requests for information). Project Management ~ preparing project schedule, schedule of values, attending pre-construction and construction meetings, preparing'reviewing product specifications submittals, coordinating'scheduling labor & subcontractors, preparing RFIs/correspondence, overseeing field work/progress of work to comply with contract documents, preparing monthly payment requisitions. Status Construction -Superintendent (1987 -1988) Duties and responsibilities included: coordinating/scheduling labor and materials deliveries, overseeing labor, subconh·actors and progress of work to comply with drawings/code, maintaining daily job reports and labor time sheets. Deco Truss Corp. -Draftsman I Plant operations supervisor (1984 -1987) Duties and responsibilities included: design and drafting of truss layout plans, preparing engineering cut sheets, jobsite trouble shooting, overseeing manufacturing plant operations. COMPUTER SKILLS I SPECIALIZED TRAINING: Microsoft Project Quick Books Pro Carpenter by trade (finish and rough) Hands-on experience in site preparation, building layout, shell construction, setting wood trusses and other scope of work. 67 H.I!II/<HI~O\l.II<.d fiu,\-jll('.u SRA ('(Tllfied Small fli'lIdl'(llIlrlgnllJlI~ilJL'H S",It: '!( Hurit/a Mill(ll'i(1" 8UI;II;'S,I' F.llle'1'l'j,li.: (.\[8E) ,\li(lmi-Dade CfJlml.' COli/lll/mily Small 811.I'il/('.I".I" Ellle'pri,I'" (eSBE) I. Mr. Jerry Lopez, Contracling Officer United States Coast Guard BSU Miami (IP) 909 SE First Avenue, Suite 512 Miami, FL 33159 Phone: 305-415-70S5 Fax: 305-415-7092 JERRY.LOPEZ@USCG,MIL Government References Type ofProjecl(s): Multiple projects from 200S-present with scope of work ranging from interior renovations, ramp/deck, electrical. 2, Mr, Rick Stauts City ofFlorida City 404 W. Palm Drive Florida City, FL 33034 Phone: 305-247-S221 CRAEXDIR@FLORIDACITYFL.GOV Type ofProject(s): Roadway improvements and construction of emergency generator building, 3, Mr. Darrin Knapp, Contracting Officer US National Park Service Denver Service Center 12795 W. Alameda Parkway, Rm, 311 Denver, CO Phone: 303-969-2055 DARRIN KNAPP@NPS,GOV Type of Project(s): New construction of 6 unit housing facility at Fort Jefferson, Dry Tortugas National Park, 12301 S,W, 128· Court, Suite 107 • Miami, FL 33186.305-233-1709 Office. 305-233-1809 Fax www.corelandconstruction.com 68 RICK SCOTT, GOVERNOR KEN LAWSON, SECRETARY STATE OF FLORIDA , ' DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD " 'd 3Mi"i Hi 'lii1 CGC058444 The GENERAL CONTRACTOR Named below IS CERTIFIED Under the provisions of Chapter 489 FS. Expiration date: AUG 31, 2016 HERNANDEZ, MONICA ,," CORELAND CONSTRUCTIOIiICORP 12301 SW 128TH COURT,SUIl'E'.107 . MIAMI FL 33186: ' ISSUED: 0812712014 DISPLAY AS REQUIRED BY LAW 69 -. ' .. SEa # L1408270003523 CERTIFICATE OF LIABILITY INSURANCE THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND. EXTEND OR ALTER THE COVERAGE AFFORDED BYTHEPOLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S). AUTHORIZED REPRESENTATIVE AND THE CERTIFICATE HOLDER. I I INSURED B Coreland Construction Corp. 12301 SW 128 Court. Sult0107 Miami. FL 33186 UMI~00lt0134 I· ..... """-'".!----------------- 03/2212015103/2212016 I I ' I EACH OCOJRRENCE _____ . $ 12/05/2014 12/05/2015 r~;;-~Ft~Q;T~ __ '_-.:~- ! ' '03/22/2015 i 03/2212016 I I DESCRIPTlON OF OPERAllONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if mora space Is requlllld) CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POL.ICIES BE CANCELLED BEFORE City of South Miami THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 6130 Sunset Drive ACCORDANCE WITH THE POLICY PROVISIONS. South Miami. FL 33143 AUTHORIZED REPRESENTATIVE JM.~4 70 © 1988·2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD EXHIBIT#I SCOPE OF SERVICES Attachment A Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW-20 15-20 I. Scope of Work: Scope of work the construction of mUltiple speed tables within the City of South Miami. Work shall comply with applicable standards, including but not limited to the FDOT and the Miami Dade County Public Works standards. Work covered under this contract shall also include and is not limited to maintenance of traffic, milling, clearing and grubbing, asphalt placement, and striping and shall be reflected in Respondents Lump Sum Base Price, refer to Construction Bid Form, EXHIBIT 4. The construction is to be performed per specifications and the construction documents of "Mango Terrace Neighborhood Traffic Calming Improvements," prepared by T.Y. Lin International/H.J. Ross. This includes, but is not limited to, the furnishing of all goods, materials, supplies and services, including but not limited to all labor of Contractor and all allowable subcontractors, disposal of materials, and cost of machinery, tools, transportation, equipment rental and permits, to perform all of the Work described below and which is necessary to provide a completed project that meets all of the needs described in this Scope of Services and which the awarded vendor must obtain any and all permits required. The City will waive all City permit fees. Permits that may be required by other agencies will be the responsibility of the awarded vendor, including applicable fees. Work activity is limited to the hours from 7:00 a.m. through 6:00 p.m., on weekdays from Monday through Friday unless authorized or directed otherwise by the City Manager. II. Site Locations: • SW 69 Avenue, between SW 74th Terrace and SW 80th Street • SW 75 Terrace, between SW 67 Avenue and SW 68 Court • SW 76 Terrace, between SW 67 Avenue and SW 69 Avenue • SW 77 Terrace, between SW 67 Avenue and SW 69 Avenue • SW 78 Terrace, between SW 67 Avenue and SW 69 Avenue III. Plans and Specifications: Plans prepared by T.Y. Lin International/H.J. Ross titled "Mango Terrace Neighborhood Traffic Calming Improvements," EXHIBIT I, Attachment B, are a part of this RFP by way of reference. SPECIAL NOTE: Respondents shall use the quantities listed in the "Schedule of Values," EXHIBIT I, Attachment A and NOT the values that appear in the plans in EXHIBIT I, Attachment B when preparing their submittal. 32 IV. Project Duration: The current estimate to complete construction of the project is 45 calendar days for substantial completion. Thermoplastic paint shall be installed 30 calendar days after substantial completion. 75 total calendar days to final completion from issuance of Notice to Proceed. V. Project Funding: This project is funded through City Funds. VI. Warranty: If equipment is being provided, the standard manufacturer's warranty information must be provided in writing for all equipment being proposed, including installation by an authorized dealer before final payment is made. A Performance and Payment Bond is required for the full amount ofthe project END OF SECTION 33 EXHIBIT#I Attachment B: Mango Terrace Neighborhood Traffic Calming Improvements RFP #PW-20 15-20 Plans prepared by T.Y. Lin International/H.J. Ross "Mango Terrace Neighborhood Traffic Calming Improvements," 36 INTERGOVERMENTAL AGENCY AGREEMENT TO PERFORM TRAFFIC ENGINEERING FUNCTIONS THIS INTERGOVERNMENTAL AGENCY AGREEMENT TO PERFORM T ~FIC ENGINEERING FUNCTIONS (AGREEMENT), made and entered into this 2S day of ~, 2014 by and between the CITY OF SOUTH MIAMI, FLORIDA, a municipal corporation of the STATE OF FLORIDA, hereinafter referred to as the "CITY" and MIAMI- DADE COUNTY (COUNTY), a political subdivision of the STATE OF FLORIDA, MIAMI- DADE County. WITNESSETH WHEREAS , pursuant to Section 2-96.1 of the Miami-Dade County Code, all traffic control and traffic engineering services in Miami-Dade County are under the exclusive jurisdiction of the COUNTY; and WHEREAS, th e CITY desires to assume the installation and maintenan ce respo nsibiliti es of ce rtain traffic engineering fun ctions pertaining to its local municipal streets only; and WHEREAS, the COUNTY has d etermined that the CITY is both equipped and able to perform the traffic engineering functions as herein specified on its local streets; and WHEREAS, the CITY has, by proper resolution attached hereto and by referen ce made a part hereof, authorized its officers) to enter into this AGREEMENT. NOW THEREFORE, the CITY and the COUNTY agree as follows: 1. The reci tals set forth above are incorporated herein by reference. 2. The CITY will only install and maintain th e following designated types of traffi c co ntrol devi ces and/or signs and only on those loca l municipal st reets operated and maintained by th e CITY within its boundari es: a) Traffic Circles b) Speed Humps d Historic Street Name Signs d) In-Street Pedestrian Crossing Signs Traffic calming devices may be installed on local municipal streets only after an appropriate traffic engineering study has been performed and sealed and signed plans have been submitted to the Public Works and Waste Management Department of the COUNTY for its review and approval. 3. The CITY shall attach a decal to the back of the sign panels indicating ownership and date of installation. 4. The CITY assumes sole and complete responsibility for the maintenance of all such signs that are installed by the CITY within its boundaries. 5. The CITY assumes sole and complete liability for any accidents and/or injuries which mayor are alleged to occur or arise out of the installation, operation or maintenance of said traffic control devices, and hereby indemnifies to the extent allowed by 768.28, Florida Statutes, and saves harmless the COUNTY from any and all claims as a result of the installation, operation or maintenance of said signs attributable to the negligence of the City. 6. All traffic control signs installed by the CITY in accordance with this AGREEMENT shall conform to the applicable requirements established by the following publications: Florida Department of Transportation's Standard Specifications for Road and Bridge Construction. Manual on Uniform Traffic Control Devices for Streets and Highways, U.S. Department of Transportation Federal Highway Administration, including latest revisions. Standard H'ighway Signs, U.S. Department of Transportation, Federal Highway Administration. Miami-Dade County Public Works Manual (available from the Public Works and Waste Management Department, Reproduction Services, 111 NW 1 Street, Suite 1604, Miami, FL 33128). 7. For installation of traffic control devices, the CITY shall hire a COUNTY licensed contractor or perform the work in-house by the CITY Public Works crew. 8. Should the CITY install street name signs at the same site where a stop-top street name exists, then the CITY shall utilize the other corners of the intersection. Subsequently, the CITY, shall remove the COUNTY'S stop-top street name signs by an approved sign contractor. All signs and hardware removed shall be dismantled and returned to the Traffic Signals and Signs Division of the COUNTY'S Publ ic Works and Waste Management Department. 9. The CITY shall be responsible for keeping records of any and all installations and repairs, and furnishing pertinent documents as and when said records may be requested . 10. Failure to carry out any of the duties and responsibilities assumed herein by the CITY may result in termination of this AGREEMENT, at the sole discretion of the COUNTY. IN WITNESS WHEREOF, the CITY and the COUNTY have set their hands the day and year above written. Attest: Miami-Dade County ",' HARVEY RUVIN, CL ·RK Attest: CITY OF SOUTH MIAMI By: ____ ~_/~----------- Maria M. e Alexander, City Manager Approved as to form, Language and legal Approved as to form and legality: sufficiency : By: IV\-A Risk Management Department THE CITY OF PLEASANT LIVING .-} LOCATION MAP NOT TO SCALE CITY OF SOUTH MIAMI MANGO TERRACE NEIGI-IBORHOOD TRAFFIC CALMING IMPROVEMENTS SW 69 AVE AND SW 75 TERR TRAFFIC CIRCLE SW 69 Ct SPEED TABLE SW 78 Terr SPEED TABLE SW 76 Terr SPEED TABLE SW 75 Terr SPEED TABLE SW 69 CT SPEED TABLE PREPARED FOR: CITY OF SOUTH MIAMI MIAMI-DADE COUNTY, FLORIDA ~WORK ZONE \.~-­ --"----- CITY COMMISSION: MAYOR: V ICE-MAYOR: COMMISSIONERS: ClTY MANAGER: CITY ATTORNEY: ClTY CLERK: PUBLIC WORKS: PREPARED BY: PHIUP K. STODDARD WALTER A HARRIS GABRIEL EDMOND JOSH LIEBMAN ROBERT (BOm WELSH STEVE ALEXANDER THOMAS F. PEPE MARIA M. MENENDEZ RICARDO A. AYALA P.E. T'Y'LlNINTERNATIONALIHJ ROSS 3'T 201 ALHAMBRA CIRCLE SUITE 900 CORAL GABLES. FLORIDA 33134 PHONE: (305) 567-18BB FAX: (305) 567-1771 EB00002017 FI Oililmt!:: UJ errs VICINITY MAP NOT TO SCALE INDEX OF SHEETS SHEET DESCRIPTION NO. I COVER 2 NOTES 3 SUMMARY OF QUANTITIES 4 DETAILS 5 PROJECT LAYOUT 6 PLANS -SW 75 TERRACE 7 PLANS -SW 76 TERRACE 9 PLANS -SW 78 TERRACE ]0 PLANS -SW 69 AVENUE ]] PLANS -TRAFFIC CIRCLE NOTE: THE SCALE OF THESE CHANGED DUE TO IQI'OW WHAT'S ALWAYS CALL BEi'ORE YOU • of lIle:.2 GENERAL NOTES: L EXISTING TOPOGRAPHIC INFORMATION AND CENTERLINE GEOMETRY SHOWN ON PLANS WERE TAKEN FROM THE SURVEY PREPAREO BY AVINa & ASSOCiATES ENGINEERS, PLANNERS AND SURVEYORS. DATED 09/10/2013, 2. ALL PUBLIC LAND CORNERS AND MONUMENTS W!THIN THE LIMITS OF CQ,"ISTRUCTION ARE TO BE PROTECTED By THE CONTRACTOR AS FOLLOWs: CORNERS AND MONUMENTS IN CONFLfCT WITH THE WORK AND IN DANGER OF BEING DAMAGED, DESTROYED OR COVERED SHALL BE PROPERLY RFFFRENCED BY A REGISTERED LAND SURVEYOR IN ACCORDANCE WITH THE MINIMUM TECHNICAL STANDARDS OF THE FLORIDA BOARD OF PROFESSIONAL LAND SURVEYORS PRIOR TO 8EGfNNING WORK AT THAT SfTE. THE CONTRACTOR SHALL RETAIN THE LAND SURVEYOR TO REFERENCE, AND RESTORE UPON COMPLETiON OF THE WORK, ALL SUCH CORNERS AND MONUMENTS AND SHALL FURNISH TO THE ENGINEER A SIGNED AND SEIILED COPY OF THE LAND SURVEYOR'S REFERENCE DRAWfNG. COST OF THIS WORK SHALL BE DEEMED INCIDENTAL TO THE TOTAL PROJECT COST, 3 TlI[ INFORMATION PROVIDED IN THESE DRAWINGS IS SOLELY TO ASS'ST THE CONTRACTOR IN ASSESSING THE NATURE AND EXTENT OF CONDITIONS WHICH WILL BE ENCOUNTERED DURING Tiff COURSE OF THE WORK. THE CONTRACTORS ARE DIRECTED, PRIOR TO BIDDING, TO CONDUCT All INVESTIGATIONS DEEMED NECESSARY TO ARRIVE AT THEIR OWN CONCLUSION REGARDING THE ACTUAL CONDITIONS THAT WILL BE ENCOUNTERED, AND UPON WHICH BID5 WfLL BE BASED, 4 PRIOR TO CONSTRUCTION THE CONTRACTOR SHALL VERIFY/CONFIRM AU TOPOGRAPHICAl. SURVEY, INCLliDING BUT NOT LIM/TED TO PROPOSED CENTERL/NES AND RIGHT -OF-WAY LINES AND SHALL NOTIFY THE ENGINEER OF ANY DISCREPANCIES ENCOUNTERED. 5 THE CONTRACTOR SHALL NOTIFY THE CfTY OF WEST MIAMI PUBLIC WORKS DEPARTMENT AT LEAST 48 HOURS PRIOR TO COMMENCEMENT OF CONSTRUCT ION. 6. ALL CONSTRUCT/ON AND MATERIALS SHALL CONFORM TO ALL LATEST APPLICABLE STANDARDS AND SPECIFICATIONS OF THE FLORIDA DEPARTMENT OF TRANSPORTATION, UNLESS OTII[RWISE NOTED. 7. THE CONTRACTOR SHALL BE RESPONSIBLE TO SATISFY ALL REQUIREMENTS OF ANY REGULATORY AGENCY PERMITS IN REGARDS TO CONSTRUCTION ACTIVITIES AND RELATED CONDITIONS PRIOR TO THE START OF CONSTRUCTION. 8, PRIOR TO THE COMMENCEMENT OF CONSTRUCTION THE CONTRACTOR SHALL PROVIDE SUITABLE EQUIPMENT AND METHODS FOR THE DISPOSAL OF SfORM WATER FOR THE DURATION OF THE PROJECT. COST SHALL BE DEEMED INCIDENTAL TO THE TOTAL PROJECT COST. 9. THE CONTRACTOR'S ATTENTION 15 DIRECTED TO THE PROVISIONS OF THE TRENCH SAFETY ACT (FLORIDA STATUTES SECTION 553.60 E1. SEQ,) AND STANDARDS (29 C.F.R. SECTION 1926.650, SUB-PART P) WHICH SHIILL APPLY TO CONSTRUCTION, OPERATION, AND MAINTENANCE PURSUANT TO THIS AGREEMENT. 10. THE CONTRACTOR SHALL MAINTAIN ACCESS TO ALl. ADJACENT PROPERTIES AT ALL TlMES UNLESS OTHERWISE APPROVED BY THE [lTY. 11. THE CONTRACTOR SHALL NOT ENCROACH INTO PRIVATE PROPERTY WITH PERSONNEL, MATER TAL OR EQUIPMENT, 12, THE CONTRACTOR SHAI.L DfSP05E OF AI.!. FXCESS EXCAVATED MATERIAL AND DEBRiS TO AN APPROVED STTE IN A LEGAL MANNER AT NO ADDITIONAL C051 TO THE C/TY, STOCKPILING OF MATERIAL IN ROADWAY 15 NOT AI.IOWfO, 13. UNDER NO CIRCUMSTANCES SHALL THE CONTRACTOR LEAVE EXCAVATED TRENCHES, DR PARTS OF SUCH, EXPOSED OR OPEN AT THE END OF EACH WORK/NG DAY. WHEN THE CONTRACTOR 15 NOT WORKING, ALL TRENCHES SHALL BE COVERED, FIRMLY SECURED AND MARKED ACCORDINGLY FOR PEDESTRIAN TRAFFIC AT NO ADDITIONAL COST TO THE PROJECT. 14. THE CONTRACTOR SHALL VERIFY, PHOTOG RAP II AND INVENTORY THE EXACT LOCATION OF ALL EXISTING TREES, STRUCTURES, PAVEMENT OR OTHER FEATURES, ANY EXISTING STRUCTURE, PAVEMENT, TREE OR OTHER EXISTING FEATURE, WHICH 15 IN CONFLICT OR DAMAGED, EXPOSED OR IN ANY WAY DISTURBED BY CONSTRUCTION PERFORMED UNDER THIS CONTRACT, SHALL BE RESTORED PROMPTLY TO IT'S ORIGINAL CONDITION AT NO ADDITIONAL COST TO THE CITY. UNLESS IDENTIFIED 8Y A 810 ITEM IN THE PROPOSAL. 15, THE CD.'oJTRACTOR SHALL NOT REMOVE OR RELOCATE ANY TREES WITHOUT PRIOR APPROVAL FROM THE CITY. THE CONTRACTOR SHALL OBTAIN ALL REQUIRED PERMITS FROM THE CITY OF WEST MIAMI PUBLIC WORKS DEPARTMENT PRIOR TO CONSTRUCTION. THF CONTRACTOR SHALL PRUNE, ROOT PRUNE, AND SUPPORT ALL TREES THAT ARE ADJACENT TO TRENCH EXCJ\VATION. COST SHALL BE DEEMED INCIDENTAL TO THE TOTAL PROJECT COST. 16. ALL AVAILABLE UTILITY LOCATION INFORMATION 15 DEPICTED, CONTRACTOR SHALL CONFIRM IT BEFORE CONSTRUCTION BEGiNS. 17. EXISTING UTILITIES SHALL BE MAINTAINED IN SERVICE DURING CONSTRUCTION UNLESS OTHERWISE APPROVED BY THE UTILITY CWNER, ALL EXISTING UTILITIES ARE TO REMAIN UNLESS OTHERWISE NOTED. 18. THE CONTRACTOR SHAi.L CONTACT SUNSHINE AT 1-800-432-4770 liT LEAST 48 HOURS PRIOR TO ANY EXCAVATION TO COORDINATE THE LOCATION OF EX/STING UTILITIES, THE CONTF!JlCTOR SHALL BE AWARE THAT NOT ALL UTlLlTIEs SUBSCRIBE TO SUNSHINE. 19, THE LOCATION AND SIZE OF EXISTING UTILITIES AND OTHER FEATURES SHOWN ON I HES£ DRAWINGS ARE APPROX!MATE, AND HAS BEEN PREPARED FROM THE MOST RELIABLE INFORMATION AVAILABLE TO THE ENGINEER. OTHER UTILITIES MAY BE ENCOUNTERED DURING THE CONSTRUCTION. THE CONTRACTOR SHALL FIELD VERIFY AND LOCATE (LINE & GRADE) ALL EXISTING UTILITIES, THE CONTRIICTOR SHALL VERIFY ALL UTILITIES BY ELECTRONIC METHODS AND BY HAND EXCAVATION IN COORDINATION WfTH ALL UTILITY COMPANIES PRIOR TO COMMENCING ANY CONSTRUCTiON OPERATION. THIS WORK BY THE CONTRACTOR SHALL BE CONSIDERED INCID[NTAL TO TIlE CONTRACT AT NO ADDITIONAL COST TO THE CITY. SHOWN ON THESE DRAWfNGS, 22. THE CONTRACTOR IS ADVISED THAT PROPERTIES ADJACENT TO THE PROJECT MAY HAVE ELECTRIC, TELEPHONE. GIIS, WATER, AND/OR SEWER LATERALS WHiCH MAY NOT BE SHOWN ON THE PLANS, THE CONTRACTOR SHALL REQUEST THE LOCATION OF THESE SERVICES FROM THE UTILfTY COMPANIES. THE ADDITIONAL COST OF EXCAVATING. INSTALL/NG, BACKFILL AND COMPACTING AROUND THESE SERVICES SHALL BE INCIDENTAL TO THE CONTRACT AT NO ADDITIONAL COST TO THE CITY. 23. THE CONTRACTOR SHALL ENGAGE A flORIDA REGISTERED LAND SURVEYOR TO PREPARE AND CERTIFY THE AS-BUILT RECORDS OF ALL IMPROVEMENTS. 24, THE CONTRACTOR SHALL BE RESPONSIBLE FOR DAMAGE, REMOVAL OR MODIFICATION, ACCIDENTALLY OR PURPOSELY, CAUSED TO ANY IRRIGATION SYSTEMS. PRiVATE OR PUBLIC. THE CONTRACTOR SHALL REPLACE IINY DAMAGED, REMOVED OR MODIFIED IRRIGATION PIPES, SPRINKLER HEADS OR OTHER RELATED ITEMS OF SUCH WORK SHALL BE DETERMINED INCIDENTAL AT NO ADDITIONAL COST TO THE CITY, 25. ANY MAIL BOXE5, WALLS, FENCES OR OTIf[R HOMEOWNER PROPERTY OR IMPROVEMENTS IN DIRECT CONFLICT WITH THE WORK BEING PERFORMED SHALL BE TEMPORARILY RELOCATED AND REPLACED. THE CONTRACTOR SHALL COORDINATE WITH THE u.s. POSTAL SERVICE TO PROVIDE UN-INTERRUPTED MAIL SERVICE TO ALL PROPERTIES AFFECTED BY CONSTRUCTION ACTiVITIES. COST OF SUCH WORK SHALL BE DEEMED INCIDENTAL TO THE TOTAL PROJECT COST. 26. ALL CONSTRUCTION LAYOUT SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR. 27. GRADING CONSISTS OF ALL EXCAVArION, BACKFILL, SHAPING AND SLOPING NECESSARY FOR THE CONSTRUCT/ON, PREPARATION AND COMPLETION OF ALL SUB GRADES, SHOULDERS, SLOPES, INTERSECTIONS, PAVEMENT AND OTHER AREAS, ALL IN ACCORDANCE WITH THE LAYOUT AND GRADES SHOWN TN THESE DRAWINGS. 28. ALL EXISTING AND COMPLETED DRAINAGE STRUCTURES SHALL BE PROTECTED FROM CONSTRUCT/ON ACTIVITIES AND CONTAMINATION BY SILT AND CONSTRUCTION DEBRIS. HIE CONTRACTOR SHALL PLACE FILTER FABRIC BETWEEN FRAME AND INLET GRATE UNTIL CONSTRUCTION OPERATIONS ARE COMPI.ETED. ALL EXISTING AND COMPLETED DRAINAGE STRUCTURES SHALL BE FREE OF ALL SILT, CONSfRUCTlON DEBRIS, AND OTHER FOREIGN MATERIAL PRIOR TO FINAL JlCCEPTANCE AND FINAL PAYMENT. COST SHALL BE OEEMED INCIDENTAL TO THE TOTAL PROJECT COST. 29. THE CONTRACTOR SHALL REPLACF /III. PAVING, STABIl.IZlNG EARTH, DRIVEWAYS, SIDEWALKS, ETC. WITH THE SAME TYPE CF MATERIAL THAT VIAS REMOVf:D DURING CONSTRUCT/ON OR AS DIRECTED BY THE CITY, THE CONTRACTOR SHALL REPAIR OR RESTORE ALL IMPACTED PAVEMENT WITHIN THE LIMITS OF CONSTRUCTION IN ACCORDANCE WITH APPLICABLE DETAILS ON THE MISCELLANEOUS DETAILS SHEET. TYPE OF PAVEMENT REPAIR SHALL BE ACCORDING TO THE MIAMI-DIIDE COUNTY PUBLIC WORKS DEPARTMENT, 3D, WHERE NEW PAVEMENT MATCHES EXISTING PAVEMENT, THE TIE-IN SHALL BE MADE IN A NEAT, STRAIGHT SAW CUT JOINT. 31. EXISTING PAVEMENT MARKINGS AND STREET SIGNS SHALL BE IMMEDIATELY RESTORED TO ORIGINAL CONDlnON, PER THE MIAMI-DADE COUNTY PUBLIC WORKS DEPARTMENT DETAIL R18,1 AND R1B.2. ALL INTERSECTION PAVEMEfoJT DISTURBED BY CONSTRUCTION SHALL BE PROPERLY MARKED PER THE AFOREMENTIONED DETAlLS, IF EXISTING MARKINGS WERE PRESENT PRIOR TO CONSTRUCTION 32. EXCAVATION FOR TRENCH AND CURB: AS PER MIAMI-DADE COUNTY PUBUC WORKS DEPARTMENT. SFCTION 310.03 33. BACKFILL/NG: AS PER MIAMI-DADE COUNTY PUBLIC WORKS DEPARTMENT, SECTION 40. 34. PAVEMENT RESTORATION: AS PER MIAMI-DADE COUNTY PUBLIC WORKS DEPARTMENT, SECTION 40. SIGNING & PAVEMENT MARKING NOTES: 1. ALL SIGNING AND PAVEMENT MARKINGS INSTALLED AS PART OF THESE PLANS SHALL CONFORM TO THE CURRENT EDITION OF THE FEDERAL HIGHWAY ADMINISTRATION (FHWA) MA."IUAL OF UNIFORM TRAFFIC CONTROL DEVICES FOR STREET AND HIGHWAYS, FLORIDA DEPARTMENT OF TRANSPORTATION DESIGN STANDARDS (2009) UNLESS OTHERWISE NOTED. ALL SIGN PANELS SHALL BE FABRICATED TO COMPLY WITH THE MOST RECENT EDITION OF THE FEDERAL HIGHWAY AND ADMINISTRATION STANDARD HIGHWAY SIGNS. 2, MATCH EXISTING PAVEMENT MARKINGS AT THE BEGINNING AND THE END OF THE PROJECT AND AT ALL SIDF. STREETS WITHOUT JOGS AND OFFSETS, 3. SIGN ASSEMBLY LOCATIONS SHOWN ON PLANS WHICH ARE IN CONfLICT WITH LIGHTING, UTI/./TlES, DRIVEWAYS. WHEELCHAIR RAMPS, ETc., MAY BE IIDJUSTED SLIGHTLY AS DIRECTED BY THE ENGJNEER. EXTREME LOCATION CHANGES MUST BE APPROVED BY THE CITY, 4. INCORRECTLY PLACED THERMOPLASTIC OR PA/NT MARKINGS OVER SURFACE WILL BE REMOVED BY MILLING AND REPLACING THE SURFACE A MINIMUM W/DTII OF 18 INCHES AT THE CONTRACTOR'S EXPENSE. THE ENGINEER MAY APPROVE AN ALTERNATIVE METHOD IF fT CAN BE DEMONSTRATED TO COMPLETELY REMOVE THE MIIRKING5 WITHOUT DAMAGING THE ASPHALT. 5. THE CONTRACTOR SHALL RELOCATE ALL EXISTING POST-MOUNTED STREET NAME AND STOP SIGNS TO A VISIBLE AREA UNDISTURBED BY THE CONSTRUCTfON 50 AS TO MINIMIZE DAMAGE TO THE SIGNS DURING CONSTRUCTION. THE STREET NAME SHALL BE REATTACHED TO THE TOP OF THE NEW STOP SIGNS ON MINOR SIDE STREETS AT THE END OF CONSTRUCTION. THE NEVI STOP SIGNS SHALL HAVE ADEQUATE LENGTH TO ACCOMMODATE THE EXISTING STREET NAMeS AT THE rop. COST OF RELOCATION AND REATTACHMENT OF SAID SIGN SHAI.L BE PAID FOR UNDER PAY ITEM 102-1, MAINTENANCE OF Tl~.AFFIC. 20, THE CONTRACTOR SHALL COORDINATF WITH UTILITY COMPANIES TO ARRANGE RELOCATION AND/OR TEMPORARY SUPPORT OF UTILITY FE.A!.U-":~.s.:!I""6r,,,. ETC. AS NECESSARY TO COMPLETE THE WORK, IT SHALL BE THE CONTRACTOR'S RESPONSIBILITY TO VERTICALLY AND HORIZONT ANY AND ALL EXISTING UTILITIES AND/OR STRUCTURES ON THIS PROJECT. ANY DAMAGE TO SUCH UTILITIES/STRUCTURES SHOWN ON THE PLANS SHALL BE IMMEDIATELY REPI11RED TO THE UTILITY OWNER'S SATISFACTION AT NO ADDITIONAL COST ro CONTRACTOR SHALL SUBMIT A LIST OF THE EXISTING SIGNS TO THE PROJECT ENGINEER liT THE PRE-CONSTRUCTION CONFERENCE, ANY DAMAGED SIGNS DURING CONSTRUCTION SHALL BE REPLACED AT NO ADDITIONAL COST. COST OF MI1INTIIINING OF EXISTING SiGNS TO IN ITEM 102-1, MAINTENANCE OF TRAFFIC. OWNER RESERVES THE RIGHT TO REMEDY SUCH DAMAGE BY ORDERING OUTSIDE PARTIES TO MAKE SUCH REPAIRS AT THE EXPEli$!';J);~' CONTRACTOR, 21. THE CONTRACTOR SHALL CONTAcr THE ENGINEER IMMEDIATELY OF ANY CONrLlCT ARISING DURING CONSTRUCTION FOR ANY DATE DRAWN; DESIGNED (HEcnO SCAlf 07/73/15 M. PUP(} F ALONSO C DMZ T'Y'LlN INTERNATIONAL rOlJOIJOO-lOl .In! AIH4MefL'< CIRCLE' SUiTE 9(10 CORAl GAQUS. rtOI!lDA JJ13f PHON~; IJ05) ~61·!8lJa .fA~; (lO'iJ .161 Inl CITY OF SOUTH MIAMI ;!I:;;;j'IIMIAMI-DADE COUNTY. FLORIDA MANGO TERRACE TRAFFIC CALMING IMPROVEMENTS NOTES SHEET No. 2 ROADWAY PAY ITEM PAY ITEM DESCRIPTION UNIT PLAN QUANTITY 101-1 MOBlLf ZATION LS 1 102-1 MAINTENANCE OF TRAFFIC LS 1 110-1-1 CLEARING AND GRUBBING (Includes removal of asphalt pavement) LS 1 2]0-2 Limerock-New Material for Reworking Base (8") new driveway SY 61 285-711 Optional Base Group 11 (12" Limerock LBR 100, new driveway) SY 61 327 -70-1 MILLING EXISTING ASPHALT PAVEMENT (0.5" AVERAGE) (at speed tables) SY 4,114 334-1-13 SUPERPAVE ASPHALTIC CONCRETE, TRAFFIC C (] JOLBS/SY -IN.) (speed tables 3.5" Avg and TN 13,996 new driveway 2") 164-4 TYPE B STABILIZATION, 6" (traffic circle and sad areas) SY 298 520-2-2 CONCRETE CURB TYPE "B" LF 248 520-2-4 CONCRETE CURB TYPE "0" LF 413 570-1-2 PERFORMANCE TURF, SOD SY 228 0526-1-2 PAVERS (Raised Traffic Circle and Islands) SY 48 Driveway Bricks SY 52 SIGNING AND PAVING MARKING PAY ITEM PAY ITEM DESCRIPTION UNIT PLAN QUANTITY 0700-20-12 SINGLE POST SIGN, F&I, 12-20 SF AS 54 0700-48-48 SIGN PANELS RELOCATE, 15 OR < AS 1 0706-3 RETRO-REFLECTIVE PAVEMENT MARKERS AS 41 711-1-6111 6" SOLiD TRAFFIC STRIPE (WHITE) NM om 711-1-1123 12" SOLID TRAFFIC STRIPE (WHITE) LF 1,078 711-1-6131 6" SKIP (2/4) TRAFFIC STRIPE (WHITE) GM 0.01 711 -1-1180 STANDARD, WHITE, YIELD LINE LF 30.00 711-1-6211 6" SOLiD TRAFFIC STRIPE (YELLOW) NM 0.12 711-11-224 18" SOUD TRAFFIC STRIPE (YELLOW) LF 10 fN",. ,::,0 J. A~o. ... ~: ... ~~~~~~ ,,' '··'Jc.N~t (;) if: /'rn~ 66918 ~, ~, , '\ ('t:..-MANGO TERRACE TRAFFIC CALMING SHEET I/o. DATE 07123115 i DRAWN. !<to PUPO T'Y'LlN INTERNATIONAL 'c •. i:::.,'~ J CITY OF SOUTH MIAMI IMPROVEMENTS DESIGNED: F. ALONSO 3 f600QOO407 • io:' 1 MIAMI DADE COUNTY, FLORIDA CHFCKEO c. DIAZ JOt A<.HA~88.l "~ClE • 5UHf 900 SUMMARY OF QUANTITIES (ORAl GA8tfS. fLORIOA }11J4 SUItE PHONE-fjDS) 56]-IIIB8 ·FA~' I]~'} 'H-JlII ';._ "I': ~~,,;,~ IUI'lI\';,;;",.· , """" ""'" , ., <N"""" ,"~ NOTES: 1. USE SUPERPAVE ASPHALTIC CONCRETE PER FOOT STANDARD SPEC IF ICAT IONS. 2. MILL EXIST. PAVEMENT 1/2" AND APPLY TACK COAT PER fOOT STANDARD SPECIFICATIONS. B/-DIRECTroNAL _. 1-------22'----- 10' ISPEED TABLE1 PLAN VIEW YELLOW RPM 2' O.c. 6" YELLOW TYPE B CURB LEADING EDGE OF SPEED HUMP REFER TO SHEET 11 FOR REFERENCE POINT PLAN VIEW LANE TRAFFIC BEARING BRICK PAVERS TRAFFIC CIRCLE N.T.5 ~-. 12" WHITE ~ i OF APPROACHING ----~f Ii It I~ ~ I~ I~ ----P -~;~--+-IO'-+---12'-..J...-14'~16'-..J...-l17--l--20'-j DArt-; :i"~/2~'~n~'c=== DRAWN' hi pupa DESIGNED F 1l1ONSO (HECKf'D; Co DIAZ 5CflLE; T'Y'LlN INTERNATIONAL f!/O(l()(10407 101 1\1I,~aRA CIRClE' SIlITE !lao rOIl~l CASlfS. nOR/Oil JJIJ4 PHO!;.: /J()5/561·/B89 • fill: ')OS} 55'·1711 EDGE OF PAVEMENT PROP. SPEED TABLE AREA EDGE OF PAVEMENT SPEED TABLE N,T,5 B CURB FLUSH CONCRETE CURB 1--'+-24%'" 19" 1-------117,-- 1% PAVERS EXIST. BASE COMPACTED SOIL EXIST. BASE NOTES: CONTRACTOR TO REPAIR EXISTING PAVEMENT OAMAGED DURING INSTALLATION OF TRAFFIC C/,L/lfffiG DEVICES. COST SHAll HI' INCtDENTAL TO CONTRACT PRICE SECT/ON D-D 3/8" v-~ OF SPEED TABLE I SEE NOTE 2 +---5'-~+---6'----'./ SECT/ON A-A EXIST. PAVEMENT 5EE NOTE SEE NOTE 2 EXIST. PAVEMENT SAW CUT EXIST. PAVT. EXIST. PAVT. EXIST. BASE SECT/ON B-B CURB TYPE "8" PAVERS EXIST. SECT/ON C-C . " .'.' TYPE B CURB OR 9" - FLUSH CONCRETE CURB (REFER TO SHEET 11 FOR REFERENCE) "-. PC/PT/PRC (TYP.) CITY OF SOUTH MIAMI MIAMI-DADE COUNTY, FLORIDA MOUNTABLE MEDIAN DETAIL II N.T.S MANGO TERRACE TRAFFIC CALMING IMPROVEMENTS DETAILS 4 DATE. 071lJII5 DRAW/II : /.t PVPO rnSIGNFD f. ALONSO CHECKED; C DIft,Z SCALE; tu llJ :r: V) T'Y'LiN INTERNATIONAL fBOOOOO4(l} 201 ~UIAJ,fBR~ ClRctf • 5ulU 900 CORM ~A~lE5. FlOnlO~ 331.H PIIONE: pa'lJ 56}· 1888 • fAX. (305/ 56}_1711 --I -_ .. ',\! l '~ , .r I"'r' e, -i I CITY OF SOUTH MIAMI MIAMI-DADE COUNTY, FLORIDA MANGO TERRACE TRAFFIC CALMING IMPROVEMENTS PROJECT LAYOUT SHEET No. 5 6861 6860 6830 6800 lJ.J ' I : I R/W~ ~ I l ~ ,0 \ 10 ~ I \\ R/W llj " ,,---.. -----~r-___ J! ~ ~ lUI I ,''', 10 , " ) a . (.Q J;u,,: 66'-, H r ,-~ " ,,-, . ~ ',-,,--'---··1 ~ ........ ", .... / ~/ ~ 1I) .... l~ I I <q" 1 lJ.J \\ ~,!~r /J~---------:\ ~ \ \jl,: / c 3~':;; =fI ~ ,,, ,I WI6-9P :;: '-l.,/ 24"xt2" ~ " I 700-1.IU. 1 i STA 18+93.73 ~ I I 1 AS j I j R/W.J1 ,: I I! 6780 6781 40 5 I 6771 6761 6751 6731 6731: I i I 6721 6301 I c W17-I, -. I II R/W ~ __ . -' c: Wl1-1 ::> :~~;b::: I 30"x3(r ! 10"x30" C:::> C W17~1 :::> u:; c W16-JP ::> q WI. 9P => I I 30">30" ) 0>11 24"x~ 14~X~'2'" I C WI,6·9p :> g OQQ:):Jl! ~~ I I r;;;-j2~4"~X~'2"(I;;:: '1 , ~ ~~~:~_____ __ ST~[~e~ __ -, ____ , __ ~ 5~A :1:~8: 11 AS : IST:O!~ff'i031, A'-:~~i: I I , , '" II / ~ ; +27.69 ~ I \ 8. \ ---T---~-----------------r~-~----t5 -T---~---:O;-':l ________ -1..______ -------------.--------.. .-.: ," '\ d; , ~ , 9.2' U 0 , j'; \ 'GRAVEL I '" , I -I GRAVEL ~ 1 0 ' " , 0 , "", " ~ 20'{)O~--___ 1-'::_, ___ l' I , I'" ':ii,]L /s[ ,"-I~' ,~y ~ FI'J'~ ] ~ 1 1, I Lr~pj~~T-'~~-~-; -I' • -~"~-" "; -"--~"-"22-:(jO" _,_~b_L "~----'I---------TH-,.!,.-~~J.s~ -L;I~f i,r,S1',. 9.2._E_\. ______ J 25+;0 2~) 133 VI '----7-, ' ___ y ___ :'AV!,~C.NT/.. ___ ,_, _ _ __s.V'L!~_rERB(1CE ___ ~~__ •• I I I I J 4 AVE" NfL I 1-"--I €--I-------I +t--l I,. '\ ,: +05.69 \ " ""l+C):) \ ----.~-,,--~ -', ~ \~--.~~---"'--'-~'--\ ,,, I ~ I \~/73'7i , ;;0, ,: ',GRAVEL : ~ I " ~ / -. -)%~I .. ------------------'" ~ /1/--------.--.--~-.'>" ~,' -J ___ -+-_ .. 7-------I Cl.), -,,' I I 0:::, \ ~ / I tC. I \ Vi I ('-t-.-"'" ..... I ~ I RjW . ~--c=-~~;_;--------T -~EF'iP.ToA .. DVANCE-----!-.. --.. -c-~7:~~-T~-~·~--------J.. .. t.;-Lr .. ----------------..I-~ ...... --.. --.. -.... \1-'f/ \ ~ I r--JO"x30"! WARNING MARKING 30"x30" I G Wif.:L:::> ............. \ 'I \ ~ , <l: C WI6-7P :> I DETAil (SHEET 4, ryp.) C]fiE@::> lJo'x3O" \ I, Ill), :;: II 24~/fJ2" 24~xJ2" I d: W16-7P :::> \ \, 700+11 I I CZgFETCl I I ]4"'12" • " STA 20+06.13 I STA 21+92.73 I I ; 700-1-11 I lIAS I SiT A 23+05,03 , 1AS I , V') I I I I I 3 6770 6760 6750 A ' Q. 6730 7550 RjW J ! I g; [@~~~1S .....--.----~~'------' ~2 OATf ~O~"~lJ~nt';==== ~ I , ~:;~~m -:::;:" ToY-LIN INTERNATIONAL CITY OF SOUTH MIAMI MANGO TERRACE TRAFFIC CALMING 'HWVo. 3 (HfCKED C DIM }OJA(HA"'8~~~~g:r.>UJrE900 IMPROVEMENTS SCALE' CMAL GABLES. Fla~'OA JJIJ4 'l~,\.,.\{i< !!!!~i'o/l M f AMI-DADE COUNTY, FLORIDA 6 PI!QH£,U05IW-/elI~ .m_'30~J~67.lm PLANS -SW 75 TERRACE I ASPH I I I : I I I; 6861 I I I <t w17-J ::> 3{J'x30" W16~7P 6851 ,---~~ ---~---~----. / 6860 6770 \ ~ /+07.65 I ~ I 9.6' R --------r-------.--------------- cL~ , 3Q"dO" ~ 24"x 12" 1700 .. 1-11 I S A 12+19.63 ! J A5 I I 6850 6760 6841 C WJ7~1 :;, 30~x30" C W17~1 J 30"1(30" C W16~7P :> 24"xI2" I 700~J-JJ I 5T A 13+07.73 J A5 6840 6750 6831 6821 6811 679/ 6830 SHEET No. 7 6867 I I I 6861 I c w,,-~ :> 30"x30~ I C WI6-7~ :> I I 24".1 700~'~ I I Rrw I 5TA13+493 ~ , 1 A5I 6851 6841 c 36'~:;~" ,> CO WI6-9PI:;:. 24")(12" I 6831 6821 681 I I I I I I 6803 6785 1 I \ I- _J _____ .. _____ !..-.. _______________ .J _____ _ I lOO.I~J1::J STA 14+65153 lIAS I ---"--,-----------.1..;------- I I /1 R/W \ I~ -----~------..---~~--------------L------__:"""---:>" -~;_------------~:-~---------:---;-I ~ 13+00 +---+'------1'----+',--.+1- -----l..-.. r------- C WI7-J ~ 30"x3(1' 6880 I I I I I I I 6870 C W 16~9P :::> 24"x 12" I 700-1-11 I ST A 12+43,63 1 A5 6860 , I I I I I I I I I 6850 --------15+00 ---16+00 '_~'~.s>-?,. \ --------------~TfOO "~I ~ -'t -.~' ,-----1--'SVlJ 7i TEJili~C:L~~_ ' _'~~~;1T?' rk' +~ ,---',~ -'"" \I) I ' I : " '\ ~!~ 7' lLJ -r-----------r------~-R7F';;~-;tWAZCE .. r---------y-r-----------.. , \ ~I~ :~_ /~ .. ------l-------.J ~ c: WI1-J:::> I WARNING MARKfNG I R/W I ", ~ "{II;{ I -~7 ! , :r: JO"x3fl' I DETAIL (SHEET 4, TYP,/' I \ ~-=> _~ \J, ,'GRAVEL,I I :-0 CW1f!'!C::> ,~ 2,-,12" 'I ~ :, IJJ ,1 ',-------I' II,', ~ I '700-1·" ::::J l. l:9 t ~ 1 ' : ST A 13+43.53 I ~ -.... J "C j-'" I 1 AS I ../l ~i: " R/W I $:'" I 6800 : V) I 1\. __ R/W 6792 6794 I • I !+65.49 if6'T' [11+00 ['11"-1-' I , -, 6840 6830 6820 I 6785 6775 6765 6747 6737 :. 7710 1 , / , I 1 : R/W~ ~ ! I I : J 51 ! I I I I : • IJJ/ :0" "I ~ I I I R/W ~~ I / ;; I _______________ ""'""'"" _____________ l ____ .. __________ ~~------___________ l _____ -;--______________________ 1 ______ -:--______________________ -/' ~ 1---113'1 DO 1---1----+-----4'---+, --~ r I9 +OO ·-j---I---t-, ----20100" --- --+----1I--_t_ I , , 21+lJO . 22+00, . r --. --~ .. -. /':i~-i)(] t-----'----r----+----+---I-----+-,--+_ I---I----l \I) IJJ 2: ~ - SW 77 TERRACE ~I " ------7--1-----------------1------------1-----------1----------------· .. --------.. --------.... --.. --..,-----1------------------------, iSl R/W i I I I i I "-." t;;: 1 I 'I I I I \ :;:, I I I ! I i I I I I J'1 I I I R/W I , , I 6794: 6772 6762: 6752 6744 " 6720 7730 I _77_20 ,, ____ ~ ____ J ..... "'I $:. \1)/ • 1 23 j 56 / · / · / , / , I i I , , DATE 07123/15 ORAVIN . M. pupa f. ALONSO T'Y'LlN INTERNATIONAL CITY OF SOUTH MIAMI _"'I,MIAMI-DADE COUNTY, FLORIDA MANGO TERRACE TRAFFIC CALMING IMPROVEMENTS DESIGNED CHECKl:D.-C DIAt SC.ME f8QOOOQ40? ?O~ ~llf""II.qA CiRCl[ • .sUiTf 'MO (O~Al-~ABtf5. FLORIDA 3313_ PHOl(f, (JOS) 567·IB/18 • fAX: IJQS} S07-I111 PLANS -SW 77 TERRACE SMrET No. 8 6885 C W17-1 ::> 30")(30' c..WI6.7P 24"1( 12" [ 70D~J-l1 I STA /1+98.43 ____________ L ____ ~~ _____ _ 6875 6861 c::::Yi!rD 30"x30" C W16~9P ::;, 24"xI2" 6851 6841 t~ 1_700"'-11 I ~A 12+98.43 I I 6831 6807 ! I 5791 R/W-~ / / -~-.-,---:-~----------"-"~~"---"----'-__ r-__ -L'~~~::~"'---L_I __ ~_----_ .. -----------,/' J +Ofr.JU-I I t:. 1 I tj I ! , i I ~ I {-I 1 ..... 1 ! IQ\ I 72' L I I ~ \ I ~ \ II I ~ \ r-,--1I'lr.o6··C1 __ -'--____ .... __ .. _._ .. l}:!·QQ_ . _______ .... 1 -L----L--'-1.4 .. '_OOL-.. ---.' , I-I,_L_,J_-,--1·-------+· .. ----1-----1 1 1 .;-- SW 78 TERRACE _'.J.-.L--'-.L _________ .... ___ . __ ..... 1-... "._ .. _-\ I---T---------"·,-------r-,-----------T-- \ :r.: I:r: \ l: / I I I GRAVEL I \ It. I 0... I \ e:; I I GRAVEL I __ ..J \':Q: \~I \ <::1;1 '; r---- -----1----------.1....-.. -[ -....l....--------L-:---1.l--------;:r-----J.----l---J-------- -REFER TO ADVANCE , R/W-ctw!!?c:::> I WARNING MARKING 1 1 30"xJO" I DETAIL (SHEET 4, TYP.) I <WI.·7" :> I I 24"'/,12" I 1100-1-1/ I I I 5Tt J 1;;643 I I i I I 6890 I I 6880 ,6870 I 6850 6840 6834 I 6791 6777 6761 6747 6747 6727 , J C'!!J.lL::> 3(1'00· C:WVT::::> 30")(30" "" C Wt6-1P ::> o "" 24"x 12" [ 700·1-11 I STA 18+43.63 ::, I w~ ~ ------:~~--" ~ II ~ l _______ --l_1>--_____________________ _ ~ <{ I ~ _. .18.UJO ;:: I t---'-+---"I -j. ~ I ~~~\I:t )JJ'E--'-I ~ <: \ 0.. t21.73 ...... I I ~ !10..3' R -.J • ___ ---.. __ ...1-_1._ ..... _____ _ ~ I : : < "/17-/ :> ~ I' JrrdO~ ~ I I C W16-7P I' J , , ,! I 1. 1 MIA"li I DADE, , COUNrI, 24"x12· I 700-1-lJ STA 18+21.73 1 AS 6780 , l: I I 0.. ' I ~ ! , I _" 19'1-_0.Q~~_ __ . JO+9.Q ___ ~ __ ~_.~. -l---I-f-I -',L---t-'--~f_"_--t 1 ··+1=--+---+ SW 78 TERRACE i ,.-----------,.---"" i .. ----.~--.,----.--.---- c.. \ ~, --0-" I, <;;( i ---------i--\.~---------..T-~--- • REFER TO ADV,ANCE R/W I WARNING MARKING DETAIL (SHEEf 4, TYP,) 6770 6760 6742 6800 6717 6740 DAlE DRAW,.. DESIGNED, (Ht-CHO SCALI' OII13/1~ M. PUPO f ALONSO C. DIAl T'Y'LlN INTERNATIONAL EBOaoo040} 201 AlH~~IMA ClRet[ 'SUirE 900 (ORAl GAllUS. flOHWA JlJ)~ PIIDN!. rJDS! 557-!888 'F~~ f)O~) $67-1111 ~n!d CITY OF SOUTH MIAMI t'i'i~j('J1 MIAMI-DADE COUNTY, FLORIDA o 20 40 +22.78 -4:4'( 7810 :'!"W"W"' ____ R/w-~ I C WI7-1::-::> I 3f)"x3(}" : C WIl;.9P::::> J 24"x12" " 700-1-11 1 Sf A 22+87.53 / 1 AS /" --------- 7830 MANGO TERRACE TRAFFIC CALMING IMPROVEMENTS PLANS -SW 78 TERRACE I I I SHUT No. 9 II z£ 7850 7800 C WJ7-J --=> 30"x30" 6890 6891 C WI6-9P :::> 24'x12" 7QO-l-11 I +56.07 STA 14+56.13 I ~ lAS ... _--------------- 14-1 CO , , II , ------------r ~ \------------11 r r -r------.----i -----;----~ -"SPHALl -.:; 15: 00 '---~ , ~ \--~---T -;~-;n-:--n-------~V:M:,:T---u----fll ~ o j (~I \ V'l: 10'1"00 jl,~ __ ~I n l 1~1 :b"lJ.J ---.I.--'--JT'J-" l--------r---~~--------.. ,.. \ ~ -::,' "111 ~Cif- RIV'! -I REFER TO ADVANCE ..' .... WARNING MARKING \ : o::! I DETAIL (SHEET 4, TYP.) \ --oTi"-- I I R!VI ...... 1----' ~ i:,I' I' ~ c.:.Yill.:l=:> 30"x.3(Y' C W16-7P ~ 24"xl2" 700-1 11 STA 13+34.13 1 AS 7881 I I "l AsrH V) J I 6890 '1--, I I 1 , , , :: II I I 7871 , I I II 7740 7700 7630 7600 6910 z £ , , II C WI7-J ::> 30'x30" , , c: WJ6~lP ~ -~ II R/W -~ ~ ~ I I------~~--~---------r---,-.. ----.. -------r_--\------r-b""""'-----__________________ ~~--------------... ------,----.---,-. .,..--~:::.:,--,-.---.-~:r:: ~ all 1;JJ:t:I, 1\ ",1./1\ IV'll I::", ~ ~._--'-<'-~l..~"'---.. -------f-~O~=-~\... ... /CCNC_\~ __ ..-/ ~ \', .____________ I~\, "-' 19+OC)-20lCO c:::. ASP11MJ SW 69 AliENUE 22100-------7---~~--------f-----.. -------------------------------------f~~~-,~---------------------T __ ~---------------~-----~·~-~A~S~I~'H~A~L~r~~-~---~_.--._l--r_~_1~-~1 ~ '1--~---._... -,------.-----.-----.;;;-~ --'r o ,--._.-- I a 21+00 ~ II _-------------~_:RAV:-L-~-----------------L ~-iT-------------. ~ ,,.....-' , .../ I r: i RM " , i i: : I W!7 1 , R/W II 7719 I 7705 6890 101,60 __ n_L-".AV,"'C""" --'--, I'" _n ~ C Wl7 o ' :;, }O"x30" CFl§::2C:> 14~~ 11" 1_.1.OQcElLJ 5TA 22+23.13 1 AS 6891 C Wl1~1 ~ 30"x30" C W16-7P ::::> 24"xI2" [J9iiTILJ STA 23+23.83 1 AS '" '" -..J :r:: v l~ , 6880 I MANGO TERRACE TRAFFIC CALMING IMPROVEMENTS PLANS -SW 69 AVENUE SHEET No. 10 * C) C) B RIC K ~ ____ ~'[02L7i ~.,.~ ~--~ .. ~ -- -ASPH LT PAVEMENT BRICK / ; T;;'~~ ; PROP. CURB· TYPE "0" (TYP.) c-~~= -24·x24~ ~::J1!C;> 24~x IS" I 700-'-11 I STA 10+6].23 J A5 6901 BRICK DRIVEWAY RELOCATION +22.38 3J7T 50" DOUBLE YELLOW 6" W/ RPM PER Foor STANDARD 17352 30"x30"x30" C R5-5P :::> 30"x30" I 700-J·(CJ ST A 11+39.33 J AS 6910 C WIl-1 :::> 3(J<x3rr LLQ9.:l:LL .. .l 5TA 24+15.83 1 AS R/VI , o o + " N - , " C RI-2 ::> 30"d(f'x30~ C 1l6-5P ::::::> 30"dO" lOOlJJ I STA 12+01.33 1 A5 6881 c: W2·fj :.:> 24"x24" C WI6-I2P :::> 24"xI8" 100~1-1I J STA 12+97.63 J A5 +69.57· 263 L .. , , , , , 1J-t 50' DOUBLE YELLOW 6" WI RPM PER FOOT STANDARD 17352 ~~~~.~~ ~~ ~~~-~~ ~~===~ -======~~~~ ~--~~-~ ~"-"'-'-------------------;r---------------- c: RJ~2 :J 30"x30"x30" C R6-SP :::> 30"x30" t 700 J 11 ST A 24+28.33 J AS RjW ; , , 50' DOUBLE PER FOOT BRICK 6'· WI RPM ANOARD 17352 6880 20 -, NOTE: PARTIAL STATION I OFFSET /IRE TAKEN FROM SW 75 : cRR ALIGNMENT , REFER TO ADVAI'Cf WARNING T MARKlNG DETAIL 4, TYP.) !- , , f' C W2-6 :> 24-xN· CWI6-J2P :::::> 24'"xlB" 700-'-11 5TA 23+69.33 J AS DI1Tc· DRAWN· DES/GIIED CHECKED SCAtE. 07123/15 M. PUPO f. ALONSO C. OIA7 , , T'Y-LIN INTERNATIONAL {BOOOOMOl 7(11 N!I~.~~IM (11/CLf '5UI/f 900 [MAL G~a(H. IWUIO~ HI.N "H~lif IJQ~! 5~1-le8/J ·F41. fJ03! ~Gl-I711 CITY OF SOUTH MIAMI ="v ... , MIAMI-DADE COUNTY, FLORIDA MANGO TERRACE TRAFFIC CALMING IMPROVEMENTS PLANS -TRAFFIC CIRCLE SHEfT No. 11