Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Add-On (2)
SoutOOiami CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM THE CITY OF PLEASANT LIVING To: FROM: DATE: SUBJECT: BACKGROUND: AMOUNT: ACCOUNT: The Honorable Mayor & Members of the City Commission Steven Alexander, City Manager Agenda Item No AJ;' i" (a) June 17, 2014 A Resolution authorizing the City Manager to enter into a contract with JVA Engineering Contractor, Inc. for a total expenditure not to exceed $113,850 for the Sunset Drive Median Project. A Request for Proposal (RFP) was publicly advertised to perform the construction of a landscaped median on Sunset Drive between SW 57th Court and SW 58 th Avenue. The scope of work for this project includes curbing, new signage, pavement marking and striping, tree planting, sodding, and irrigation, milling and resurfacing. Four (4) interested vendors submitted bids, as shown below: B Square Construction Management Group, LLC JVA Engineering Construction, Inc. ERF Construction Group Inc. Turnkey Construction, Inc. $72,869.48 $99,000.00 $183,000.00 $198.000.00 B Square Construction Management Group rescinded their bid submittal due to an error on the quote. Based on a letter received on June 15, 2014, they requested their bid to be withdrawn. The basis for the withdrawal is due to a mistake on one of the line items, which was quoted incorrectly by a subcontractor. Upon the removal of B Square Construction Management Group, the next qualifying bidder is JVA Engineering Construction, Inc. The amount submitted by JVA Engineering Construction, Inc is $99,000. A 15% contingency over the proposal amount, $14,850, is to be appended to the bid price for unknown factors that may arise during the work. The total amount for the purchase order will total $113,850. Amount not to exceed $113,850 The expenditure shall be charged to the People's Transportation Trust Fund account number 124-1730-541-6490 which has a balance of $821,675.72 before this request was made. Sout~iami CITY OF SOUTH MIAMI OFFICE OF THE CITY MANAGER INTER-OFFICE MEMORANDUM THE CITY OF PLEASANT LIVING ATTACHMENTS: Resolution Bid Opening Report Proposals Sunset Drive Median Construction Plan B Square Construction Management Group Withdrawal Request Letter 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 34 35 36 37 38 39 40 41 42 43 44 4 5 46 47 48 49 50 51 52 53 54 55 56 57 RESOLUTION NO.: _____ _ A Resolution authorizing the City Manager to enter into a contract with JVA Engineering Contractor, Inc. for a total expenditure not to exceed $113,850 for the Sunset Drive Median Project. WHEREAS, the Mayor and City Commission wish to provide infrastructure improvements along Sunset Drive I SW 72 Street, between SW 58th Avenue and SW 57th Court; and WHEREAS, pursuant to a competitive selection process, it was determined that B Square Construction Management Group, LLC submitted a proposal in the amount of $72,896.48 that was the most comprehensive and cost effective in its construction approach; and WHEREAS, B Square Construction Management Group, LLC made a mistake in preparing its proposed price and has requested the City's Consent to withdraw its proposal; and WHEREAS, City Manager has consented to the withdrawal by B Square Construction Management Group , LLC of its proposal ; and WHEREAS, pursuant to the competitive selection process, it was determined that JVA Engineering Contractor, Inc. submitted a proposal in the amount of $99,000 that was the next most comprehensive and cost effective in its construction approach; and WHEREAS, the City desires to provide a 15% contingency of $14,850, over the proposal amount for unknown factors that may arise during the work, for an amount of not to exceed $113,850; and WHEREAS, the total expend iture, including the contingency amount, is not to exceed $113,850; and WHEREAS , the Mayor and City Commission desire to authorize the City Manager to enter into a contract with JVA Engineering Contractor, Inc for the Sunset Drive Median project for a total amount not to exceed $113,850 . NOW, THEREFORE, BE IT RESOLVED BY THE MAYOR AND CITY COMMISSION OF THE CITY OF SOUTH MIAMI, FLORIDA THAT: Section 1: The City Manager is authorized to negotiate better terms and conditions than contained in the base contract and enter into a contract with JVA Engineering Contractor, Inc for the Sunset Drive Median project for an amount not to exceed $99,000 and he is authorized to expend up to $14 ,850 for unforeseen conditions for a project cost not to exceed a total amount of $113,850. A copy of the base contract is attached . Section 2: The expenditure shall be charged to the People's Transportation Plan account number 124-1730-541-6490 which has a balance of $821 ,675.72, before this request was made. Section 3: If any section clause, sentence, or phrase of this resolution is for any reason held invalid or unconstitutional by a court of competent jurisdiction , the holding shall not affect the validity of the remaining portions of this resolution. Section 4. This resolution shall take effect immediately upon adoption. PASSED AND ADOPTED this day of , 2014 . ATTEST : APPROVED : CITY CLERK MAYOR 58 59 60 61 62 63 64 65 READ AND APPROVED AS TO FORM LANGUAGE, LEGALITY AND EXECUTION THEREOF CITY ATTORNEY COMMISSION VOTE: Mayor Stoddard Vice Mayor Harris Commissioner Welsh Commissioner Liebman Commissioner Edmond BID OPENING REPORT ! f,. () () QL..yYJ Bids were opened on : Frid ay . Jun e 13 . 20 14 after: -1.-8i1Oam n'WJA.Il For:Kffflml#PW 2014-04 -SUNSET DRIVE DO\VNTO\VN MEDIAN \j)'''~ j/ COMPANIES THAT SUBMITTED I)ROPOSALS: AMOUNT: ~ - 1. ERF CONSTRUCTION GROUP INC. ~ 1??3 t1/JtJ, ~?:) 2. JVA ENGINEERING CONTRACTOR, INC. qC; At:JtJ ~ 3. TURNKEY CONSTRUCTION , INC. Iq~ O/JO. ~ 4 . B SQ UARE CONSTRUCTION MANAGEMENT GROUP, LLC 7..17 5?tb 9. ~ 7 THE ABOVE Bms HAVE NOT BEEN CHECKED. THE BIDS ARE SUBJECT TO CORRECTION AFTER THE BIDS HAVE BEEN COMPLETELY REVIEWED. City Clerk: ;r/atja. /1 Ne.fJ~nd'f'z- Pdn{Namc Witn ess : ~e ...... ~ ~ Prill t Name "fitness: . t N':unc n Pnn . Signature ~ , .r IND£X OF SHEETS SHE!' r Of \·CRiP1l0.'/ CO .. !R r;r.A.'r.~1I). NO<t5 SC;MAIA«Y 01 ("'W,f'im,y:s / (JAY fJ!~M ~Ol(.'i I!'(Ml,;W~ y l'tAN 1f411{J.'ir;,.,~!'.r; PI. AN IRR:(;~ ri~ ;;r.AN (;:/~f'''J,\~iC $rAI<{j)-flPf)..-; ).."((1 .'iP(C:r.-C,ITI('.N5 !.I.I)JII,llo (lfAA~f/,lf.N' (,I,' :HA.'f)p~r/i1:()N, fP,I'S/t;N ~ ,,'14) ~ CiSQI ~r~ff1.J.4110S ~fF.() ,,!-""~ . .i.1r? ~INt:;,v.'(: y>!r,;:,;tC,u,~$ roM 1104() "'-ID ~!J,;!, t;OH'SrHl}Cfirw D"Uf:O ZOO? ~!i AUgY)dl In' f,'ONr'lJiO {X'C:.f~ ,,;~. -CI1Y or S~!H v;.c:l,I: £NG;krr:Pl';C; STjh'!i>4!1CS (lAT!:';' r~HJ~j -W.'rP! VI" l).'.-:rnr:u .,.,·;NVt,t !iWJO.#It;!i ~ ,'Y'<>.;;tI, r.ONSlil!;'CT:oN. )!J!) ,;.1;JI1{Nkf';t: r;).~ Si".~rrs Ao,o /ltr..l/W:AY;i • A!'~I\:!'B CALL $11 • rulli'ORB YOI1 ora ~ f liOlf Ki/A't' 9 &BLOlI 'PI'WW.I:.n"sul1~llne rr,1Q CI TY OF S"OL) TI-( MIAMI SUNSET DRIVE MEDIAN IMPROVEMENTS FROM SW 57TH COURT TO SW 58TH AVENUE' =_IL~Oillldr:: := 7/\\/ -~\ \ • ., Sf/"'" 1_ ~~J~ //"""]! " ... , ~r-J\~' ~'/ J\ _. -J~I -,~. / Z --:::-A~ .. 2f,!)El.D'I. ~ ."!ilis:"~TfdL7 /~.1 r -]Ii i ~I\ \~ , / ~·11. l&i ~ ~X /~f=-'-~--=O -l\'=] -] ~j!l=t,JU)---II_o··11 .-' ' .... ,.m.' ,I r ' ill"r.W PiIO.£r: r ~A le'l<·!i~.6~ Ii SURVl'Y PilFPARED FOR CITY OF "oum MIAMI May 7, 2012 PlANS FREPAR[O BY ~o~l pALM ""'." "'~;"'""'~ fflolNepftllillO If.=.; o.~~ ~ ~ '_ onOURtNC. Y.(.r-,1UoC ~.l,.m~!IY~ h • IJ!Rt:f;C.(!£ f)f" AM}f(',/If,~).ff:-"·1 NO. I}ti;J (.(;"M(J..\Hf'oi'J: r ND P{IOJ£CT firA f6/.(IO fI SIIRI£\' I ~ I III N.1:S. t/IJ)~ mr~r;(;W IS I)~~rr~ i(} Tlir. rACY 7~r 1110'[ Pr.N6 A.(.4Y ,(J~' BiOI P.f.mJf;F.O H<I S;Z[ .fIr ~.o/ilO():JCJ!OIt, iHl!> UUSi fie ~~If!{) 1tffl.1t OO~"'~'JC so.:.lf'l ()ot"!'). qTY COMMISSION MA YOR: plI.~lJa I(. STOOLWItJ. PhD VICE .\/)\ rO!l; V~L ~RIE NEY.!lIIN CO/lAflSSlONCRS: \.f"/.w~ PAUIEF/ r,",~/I 0. P.l'A!LF.r )!~tlD/ A, IM"I/S W I' I.W/~l'fR: IJ(Cm,9 ",lflAM/:' flrO CI/Y A rTotIN£r. Mill"!; put' Cl r y CI.e;){: 1-/,."'''' &I, A/LNUI:JU PuB!!r. 11f'-RY.S Cl'ffl"'710N~ IJ!.NM;(JI: /(fi71! II~; CI'M _GEJ:1L~ 7. -' <. ~~~;~'~n(rrt~',:~~I:t~ ~~ "~jt4~'1 \~~ ~~~:i~ ~'Jft1~; I~ r~L'" r;e~,.!1C "'-:.L-" IJ."1. /f,·,';..,(AlIm$. JlJ:ll',t1t "01 mr.tr.fi'l'f". Iltr '::0'0 'N';f.1~ !dIJ.L F,EJAD-J.I.(J ~t' ,,'I CClttl#"C~ (1) .... ·,JlJtNfS. r:."t'!IJQ .... r, JIU' IOU II.W1fO ro r~ F;.~."'";. tcc!.r,;;l ~. ClIJLt'"", lUfJJ.O: INJi ~~ "l~ nle ~4C~ vlIlT#l. 'l'A:ioI$ AI.;) c:.'-"f·L1'I~.'i; r~ 'l!'.!,. f,l;\~,rN.r. ,J.!aJ CGU ~r tJrr4 AU mLl#C!:1,$.'Jf'1I·m, JP/f.:a~ ANY 6i.~~ IJAFY" ~.·Ir; ~m.h 110£ flllll)· 01 CC:J~lRtJ'CTJ(iIJ (~' ;~j Of: 1-,*>7ICYr'/J ANO ~rrr~z .. ~~~ ~~fff $ ~ 'WiJ:i:rr.,::~~ ~i.~~:rsl~/!ft:~;·~lfm!i;bu~j}pt:;/r;/ l:tV!Nf;/t·U; rt".)f~i< Al 7Jlr sm:. £u:lIAr;(). ... ~ 1."( "ff.A1,,;£' 10 ..... C\{!. AU PilH: Ie OJ/[) "~rr: 4'~ u<·.~Nt:.. 'tt. !UllJ r1!/." LJMITS Cf c~s:r"VCr.!Pf A"t t(1'~ ~",'«(Ui.CJIQ H'I m, "1UT1f"~ At" rtN~p-,., C(){;IjO(~ /.J.'(J ~Q:"'M.,W~ tV ~':l Nm mr rt~1( A.t}!! 1.'1 .!&A.t.iR.~ U Pi,...~ ~.v.;'ti!. autJh))fU. OR Ct:l\'!~o ,UU I,t "'~"'J t l"~ Iffrr1lUi.1 ii, Ao la:l!·:trrl.t!) L~··~ $CJN~Y()N ' .. ~ .~t~· .. lt: ~''nl mC' ~,·\-, .... i rr.t;lfN/C~ ~fIAlt.IM=r OF lH(' 1l£r=C.-61.\d'D ~ PJilQrt"!'-.:Q\'.A, tAH~ S'.Ilf:.trn ,Hk."'. to lJ~J;lIIII/t.·1G -:~~I /;4?~~fJf'tt'~Cic~JtkN:u.;t;t!tf ~~ ~~ci~::/~~f1'~!1 IUI'I'~'I I~ l!~ o),!)r Wo!lTH Vhl4tl ~ ~~t> A,.,., ~I U ,'try W" '(kir lA~ WH~~'!-""'S -("ltl/&" ~~~ (cH ar lia"'= StrAtI. hJ.' /)f Ilt,jJj ~1fO.lI'AL 11) n<t£ PIHJA.:,:.t to.tr .N.i p"'I£~Hr D!AWIStONS MIC TO til!' f.l)Q; Of' P;'YfAI.{IVr (}P, UP cr C;;!!'I."R U.\'USS 1.J7flt:f~'MSr srI. rEf) t-~~JJ:~!1J'E~J.~~.f:it:N~~i~~1tJJ .':%1;CJ~J4~.&~r::~iu~? :"'v~V;J.q~Q;} MWCHWr C":t":smUC':,'.I.~ IN ~ r."iflIf f7' ", ... (C!(R(,(lMr !n fN"..Jh,'I. hf!-PiJOU:; H9l11l ~ ... i) $1r£fY co"'",#.:. ~/t\-f ~~ NJC ~~'t r;A.tJ.(Jl (icm,.;!)Itr(~ ~1A1JtiJCIHIttJ roSmvvrwN CI ,,1\'0 l lJJl'tA.--W .~ ro"'~i1IrN r Vi1tttH;·,'i ,.tU ,Iq(,,(!l~1l' fOP ";:Un' ~f1.n5rw.·.'I'ft; UJJIIJ ~ ~1,JJc IN '(P1h:{~ A l L£A!f1 r...., ('I) 4tfilt<; IN 1ot;\'I,IICl". ,*I{)/I 1;) ~~J;;;;;rIl~~}I~J.c""" t.CiI'VCUtif ?cA.tL ,.'H)'o4')f" to tlt£ €JP Ij£PRrsrHr~"'.t: ;(N(1;i.N iJ!f!,lrr COJ.IPAt.{,'£..'; Ih ~£ pif().ccr UMIf,'j m~u;,-;t:, 9Uf ARC NOT lMTfJ) 10: fIll AT.tT AlI~/.1f [JADE .vA TEfl ANI) SE"~!R 4IIAW-DH1( PMJ :.:rJl orr CAS AS ~t!jU1RCO ~y ~It rl/Pf.', <Nt.; me: aN or stHf,i '6'.4"" mr. C(\'H~"C1()r~ ~1H~1ti. Iff RCSPOOS,'8U 1":)(1 "trt.',,1.C t.o,\'Tt'JC 1J,..J.'1$ r:r.J:.A1I1Y MN.t\\C JlATtJl'AI" UWftOQr. f>f11,.IS, £iC. W~INO me iXN'fT'fL;~/r(~,JtI ut) ,A~roO;".'~ ClY.if ret mr: O"MI/:H. a. C'X/5TING ()JlA.WIl(;[ srrl'JCtuRn Mml!o/ "'HE U.lIITS or CMSTRVCTI()l1 !~AH RfJJAW UM.fSS· omcf;;l#sr ~rpf.(J fO fl. i2. " 1:-' f6. '0. ,. U1511!i(,' :1.U 7.r; S(;f;m!1t ro T(} NlYIJN SH).l..t lX rJiORW(JJILY C(l'AN{f) 8y H/:'A,lOWiG ~H. nflJRl,5 JlN(} !>W»J"~l.'r M InC C&JPI.£TPf'A ('oF tHf pt?OJ(cr. t'(UIIV,\!:'It..-~'Ni. ,-J.'oA/'S' ..... , (:t'1S~ urUtii!5 ~:XWIG t,S:ft tiM lMK(J fO' V04UC 11!1~ l'l.(AN .. (I(J($. a!J" .. CYr ~S JlflU r-m(~ fATal N#)'~~. Cl'llold. 1J""'~r. '~\.T:n. J IL 10 ,.'In I./'W ~~IJ£5.. ~r .rr:.pttOf'n ~,,~!;n.~"7If:i Slt.-H.' tiC Q!\IW\rtrD f411obr: ,.I,'~ r..>lAfJl. IIiiI10R m (.t::AIt~vt;.'Jt ~ .\1.t~Alt P"""JG COkm~~rr:t s,:t /AU. '..:1..t..")1 ",. w~h ~j,D '~Ut' S)l'f'S Vt}1ft'"1 ,..~~ lIt/,'/S Jt) f!~..&(, (P.AJ)C C.f'J Ir t.'f}f Sh'''''''l CN !'l./1.!6: ~"'t::IfE NEW PAVE,VUiJ" MEns I;"XISTJN(;. !',(!sm«; Nvt.'.IJlNr 'SHAll BE .s~w cor ANi) COO.i,fCnr)fJ SH~U. Dr ",.IJ..f)C"1 A NfM ~rHA~{;JJr uwr. "'h'O n.us~ ~fH TI~ 1;";(!!'i;JN(l r;OSl. t~\,:::...;g~rAv7' TlC:!·~j~'~/g:/~~;.t~~,~~,~d :~~I ~;:r;c~~}~ ~r::f/ .::;;'.;.'"1: /.I' "fT.;;T rJlr r.CWfm..cu;1l Wlf SEr.IfF.£ r.'OP.K SIT(: TV PRma:r flit p(Jtr.{r; ItrAl TH At.,{) '1/F.f..FAff[". ~~~ c;cp.n~AcrCR a.lLL J"lt1JHC "':U PL1~NH~ ('-NI UrI.' 1'rVH-c ~/:l..t:i;~/n 1'0 C(J.V.,..,I.ETf T'gS Pf1(J..£CT CI)IUi'?/;cr(,r?' ro RfPM'f Au. \?AMt1(ji:.,> tNr;rl.HHti) itS A R€!i'JLT or C(~f;JIlVC".t:r'J ACIH1H!.S $l}CH AS lI'Jr HQl' lI'J1TCO 10 ':"'UfWALi(, PA!Iflr£"'iT, LIUli)SCAF1A1C, liARO.s::AJlmC He. 110 "'VVfTIt]!Jl.L CW,fPfNSATFr.'fJ ~I/ fir OI'tf:N, ;1Ii:: ;::o .... rq,o,CrU{f -SIlA{I. tlorwr rMl CHY IN ~",'ING M H:,I."'j1 ~H H!.);.)ns' f"Hlop' TO CQI,fYCNClU[N( (7 C(W5S::~I;;;n<w. 20 jill; 1,,:():';f/l/:!~fVl( ~"HA.LI, 1]£ R£"$PCNS;alE 10 ~r~fY 1M It/'(J'i./rtU:·JJlhIS or Ar';" RrCif... A roRY AC{ N:;T "tif~ rs J.v RrGARDS ro Cf;lVsmucr.r;.N ACTMJ!fS Ao'i;J pt;'t" f[D ~om().vs PRIOR lV !H( !o.lftHl CIi CQHSrpl.)CT1()'\f, /! ~;1(X.KPf/ ,WI; Of lJ.J.T!RI,.t( (,'I Rlr,UT-r,:I-'-'rMY VH Cl'1t':lt,?(;Hl SUlG.',"rG OF '-IIH[IhAl 1,0;; nnr I!II.DI\-f.·i) :17, rJlL c:o.·;Irr~CllJl..' SHA.I.L flom:Y ,"H(;' £Nf;J"i!f.~ IN I'tHfl4'IG J!IUEfJlA !!l ,.. OJ.: A:lty r;Oo",,'OCJ /:,i?r$,W: IXJRtNG f'XNtjTlu·;cnr,N (OR ,ANY WP!?QIifJ./iN1S SJ.iOitf( 0:. ... PIOC CJ?AWAi't'tS. :lJ O~ Ix).\·rrt~c.,..)(1 ro RCHGRf /.U. [KISliNG ~f./UtS· u/ ;HE. PfN}.Jf't.', WHiCH A.f.tf. /1I5"/:.'11((J r>uF TO CGJriSiP.U(;)l')!J I;crrV/T{[r 2.1, N.t ~'H(J/}o.r;E[) ~K $.AI.L Of P£..'I1f'OI-IAtUJ tttr:~fN lIse UMIi5 ~ ",If. rxr.r;m.,,"; ,~'rMf;t<.1CA:~ HI(;!Jr··(".!-I'I~r. IlH!) ALL m.PRQVf.jJr.~""$ 5~W.~ m: CO"/STlf(l(':TEO AND 1.'JsrAUW 'rtHHIN SItJD r[1I115. 2~ {Ht COVnLAC/...., ~/.lll. J,$.!!5T 1'HT. "" Wort, ",.,. JJiJNOl.fUG OT THr PVfjOC i."''"()I(VA1rOH "AwttA{~ i1fr., 1r.)M'i f.0X,:c."1 f>k YUSI.-')£s.'S (1'JJ!Jf.Jt HC!!,flD."'/U,W UY'ffllS ANU ;"/l()..I(,:cr CG"Js',",vcrc.. !.iV\"S F,,'t(;> GJ I"fr. S.( .. ~r (V tilt')' .')!(Nlnr~NT ~A5E. or crfi,GfFI./CTf()tJ c:a;r C!" rr¥~ trcW" 3HAU. Be r,'Cl.CN[{; U r,," ViUNiUM .. N!.'t. Of TR.tFTtC IriJ Ij[M. M&I1IDW1''-OF T8/!Ff/C GENERAL NQ'ffS ~r./;z.~~~r #,!:¥*=~~~o;~~J :rrn~~~~~~~~'~~"'1f »1£ (~Plr c:t:i1IC;'" C!' "It n.~ tJ/:j'NIW[H1 C..r tRtlJl$P()Il rAmJN n:~,,, ~tI~.",I N:15" NIEX t;wl AW, III, tJl.~NIfI r,ti Ul'N'::)C'~ m..cr1':t: C~/~Dt ~~a.'.t :~~.~~~~rrf:s ~~ .• ~ ~Lfl'~If,f~~~ CO~~rvPlt:I1%r.k;r r~H1. JI),!N7t"':Nf!H<X or rRArm:. 1.711 i'" IfO( ~. rH[' r~I1"'ITG "'NU r"'l\~rj WII~ SlfA(.£ Nor Bi.· ,.t!..n:~:{) !J't nfl' r..W'f"Cfa,f~ TO C1lf.A!l:'" loMRK Ie!,( 1I1"'r.. AU ,',~01? A!~ MM[IfII"(, It"tl AV ..... l..c.8U ffJR W[ co.VS(JIVCno,~ t¥ ~A r AA("A f?[CV!ATQRY 51'tJ:D F.srASUSflF.!J "'miIN "".:wI(' l(J~r 'HA\OU "'''YS 91AU. 8E f1If rx:srwa ?OS.1fO ~t.Ul ~=~ f~~ ~~ (~:~.r.r;;,.nr~i,'Jr, ~~~~~~ :::;: ~~t~:;:s ~~NS PIAtt a .v.C::Lvtt£(l IN u rCrNlrNAJ:O t)I I~JTIC ft~r JffM ~::':l;'O:l1rtfi ~~::~. {1J/~~~,fJW:tl~Y'~f!'::'!(Lr, ~::= ~~_~111:~ G(!Ut]t"'Cn)f' !RII.I L ~.'iIM' Rti" SlQ(';;; iO tJ.Xln ~G:.'I,,, 1~11(H, em (7 ~'1"1lr C!i\S9,,1C ~ r.r;UO\'.\"1,f7o'!:1 ~1!.YO AN91t£5.?:IR'JIr;-11£ ~., -JiHA1.L a!' ,~~ (fI v.A:."'f!H.AHCC ()6-' mAIne PAY IifJ.l r:(llm~c1UR !JIMI. IIf 0CSI'~l)'t1kl rrP Itt( ,'MMUJMTl. R£~OV,li1.. OF $;¢~ .. ~".q l~lJJ 't!:'"i:cl.~!)g::.;) ~I~f;~~~ ~~(~I~ ~I~ r:i5[~1 ~~~~~'1~~~{) PNO~:C1 .QBfJe....()£EJ TJl£ CONiRAC1OR SM',liU. PRO'i'[CT me r\<ORA" I."PHt' W-fH OE"rfC£S APPlWKO tly PIC CHY OF' ~/AU! c~slHl'r:Jr!Jl.,' j,/MIIt~'fft ')tiC'" [J,~V:; (JUS t;X(,,"ll''jj J" A!,)JACE"'r 'II;) '-"'Al'll .. WAr.).. ~SM'~~ .at ,,~ UJtJ Of lAct; "[~" {U" Vi' ~la"Of" nc IfIC~N LONE 9[~~ rlli cmr •.. ,.., (1.;'V' {)I'f MJ...v:£Jlr '0 Nil! 1'f:t'!'Sl'n'1AN, ".!w:L( ~ ~f.lr:J.J\J.'i' m.~'Kt ,1\t4f;)' '!Z/~Lt. IJC 1h-'-"'1ff~IIf) rw~ "'l;f SJ,p .P;tjf(1i r,;:J "H'!J/t~,rD I "'~ 9~"RlCl.f.'C'it " vP:.wJ.Rt ~1t" flAR/lrtJt OIl ... ~~.,rD "~..I.Il.. CO',,~' QA!rnu...~-,.;;ron r»r NUl. a (I/(,V.JDEO ,~ JJAfNlf.:'<lAME.T. OF TP.foPr'.I; PI! rill;'" :;, J'f!.'£SR1-.N. D'/;If:JL N,'¢I """"lH.J'A:fj rG"F'to: ::H ALI ,11.' ,nt'/MOfjUI 4 "t(J .t;WlCll fnNn ~~~If W.Al:.~k~ fJw"~, j,',~'II.',·tG NJD (I.f.AJJ,foTP/AttriIJ utWCiS av .. r J.C4sr (AIr ~ Q ~ '~I!{ ~r~" bV.!'s ~()tQ-t~! 1Jll' IIUfJJicf U1J1I$. IJfG 1oiM\a. "4.f11 SUN J HE" v,1p"\C,lI r;r .. II" "'l1J' 4:l DI .I s:t ~1"f I '~.I,f.t JlMf 1$ ,t..,r ~ !.Nt' jf Qt/)(JtD t'£ :!~~~~,£e~'~~f'r.C!~;~ ~ *'it: ~:~,F&i~'f~~~~1J/~~-; 11,';., ~A~R ~ THE rXAr.T l.o6tno!{ AtJl) :sJlt' Of' (I;Jllrl!.S ~nr. Nor FWI..)YJLlrl) On THF.SE f'L"',N,t;, J. ["X1SrrNC i./1ILWl"!i' -"i/IAv' itt' ,1JAI,l.{i'Al;~>[O IN sr."YfC( OUfi:t:C !.,'01'."S"T1ifJeTiON ))Ntf~"!i J. om£'R'ltfSC f,;',::Ino ... UJ fJ'f ?HF. ./mlrY OiW[R. AU, f.,(iSr,,,C Ur;(..iflES ARE 70 flCMAt:i UNlESS cm~~f?'Mst' NorfD. ,r ~a li{" TIIr I;t:.i1 /H"AClo;t !~ F!'9O"I"'11'lrl'f kI · ... 1I'Ii'C.I,U.'.LWI HfWtX""',,.,tr I~a:r.;r JJiY AI,/, Nt F,lJ;iPjr; U'1inf": (>" irl'.'C Il~-cr J,J,( " ..... ~t'If m Qi()1 (1/:1/1.>1':'; ~4' ($ ,·.T)I !JlChN {;: "'1.11;$ 9~~u.. (r( (AflIM;.t"/fJ '" RfNlRrrQ m I1£. C;,n,JlT f1~~'t:l' TN.! OItlUN-... ~'I"'-S IR ~I' ro IN)I[I)'( SJJt.H (jA fJ A.'Z IE' (jI5Xu;..-w; ~1I!J.'tJr i lIofU1f:S Rl MI-YC • .t1fl1 ~'i'I ... "ti ,4 " {J~I.J"'ifi1.x cr IJoE (.c:.·~·tIt.'?:rM otr. 11.'\111 w .... !Ui"A.l CMlft:~"""" ~!!in'll r.TT" .. W~tll~'K. ',nJ"~ Hun :"'1 J fI'~l..- _WIJUIJUJfQ PAVEMENT MIJWNG NOrcs .Jl.l ~ J,I(:J P~t:..Mt,vl AlAJif./Nr..""r PISJ'ItI,l!J) r\$ flAJfI (F mn:(' A :14S PMU ~(JiF.'"-MU ;.., me lrTJ¥ t;l/I{110 .... (Jr "'t. I I.t-!JtAt. H.~, .. '.I )' .. rw:.-J'~P~"ll(JriG;ru~ "A\'tI,.( or l:tfE(#4f,f ~:;,;:,:::~a: :~~;f:dr.~rr~Att"·~~"";~~ ~~tf' (F /!J,;,.~rr-'/J ~'n' .t:nI mE. IJU$J 1l!:c4/fI UimCN (II" ,,~ iHJtltAL ,IoI(;I'iltAf" "lit! "'tt.t.( \-,),,ijlf,n(W S''''NN~ ,./..:!!.:UifA T ..... ~1'f5, 2, mr COHRI..CI(jf( SH~a INS'''U. fU.t5fO IJtlJf plo.vat(Nr U)..RkfRS IRCNmc; AU, nf.'f H'rVf.J.AN"["i PM 2~9 ,lJVJtTJ <; rAN()A.fr()!; SJr}/IMIYAfER PO/,WUON PFIf1IfW1Ot! PHACnccs nr: ,t;'(ONII?rJ. 'IJI P«U/JI''i'iW P7f[lf.MI'r:;w ,.,.IV (r;t't~'. 'r prt;'Ut.~n./iI; ~~1 , C~ IN t'i:1A,t loICN }Joe c.tb"StfWCflr.N tflfW ( "'.1. ~ Plr .. SC() "H,m RFWJro '0 'f"..·tr~J»W t~r{J.v JtU(U/..1.)I:; fir me (/".i:t(A UM/'(W~'f:' A~ ~f'U",.~, !I(~J(..\I C~ .. r.[\or..~/Ul1,"'S, r4ft ::'IW~~.J;lf::~·-:: ~~r~~::::.; tlt:;~)~WIS '1IISf 111' I . AL1 £!I\CtrOfl:UCtlfAJ C.I,WTRQ. ('0 TrJFr[S Aile so iJJ UAI'{'I'utlfiJ r-~; rNt UFE ~ .. r;~ i'S"OXC, ,., ",CC'~'I(~ ~f).( .VP.n.f.S. al.·~/lflO'ry,1S. U4( cYYl1tl)r.i(lt \'UM [N5<JRr. rl1,4,' ..tU. ')~N['·,lfA.r. co.'II:r»G{, rCA TUR!:"!; I(l'lCmw PPOPCm. Y M All ~UItt. J ,4..L! r.RO~~ MO .vA rt."i?}4t r:f:POSlts MiJSl W. C()iolT~lnl{J ""mllN nil: 1'P.Q.J£Cl Uhlir'S, 4. ANY I)NlAG!..lJ CY? i .... 'CfT£<:-,,*. IWCK (lAGS AP.£ ro-9C R[P(Ati,,1J Ilfrtf NfW CNCf :}. (;IJrm ~""!.E.T5 .§HAL!. Of ,.'ft()1I,Cr(.D U/OU Sfow:rnr I~T:41<r UNfll... iHE PRox.cr 15 eVMPi.CiZ: Ati"( f¥'FSJl'£ S/X)(.I.I(N; (J(S(..'f~.~GE ro A MV."'OPA! S/'PAHA1[ SrOfW W,A'tR 5't!>!O.t ~mSWt; tM.Y '(Hf CtJl.,'1.It,A,CTOH'S Ar.JJvr;~f5' IS NOT ,~.u .. o~a ~ I O'~ -!h ':~;';"11':=l"P .," ,-/I#-", 6iJ.'....-I -=::....j..I...::~I-.~-1 I ~ ~M ::.·,~:.~"" ~.~: ~:;; I F, -~-:;~ or<:-.;~;;w... C£NERAL NOirS _____ . .. .. III~r:::t:;. ..... ~ .... _.. 'IOIV.-..~ '!iI''''',II , ... t:.~'_ r .... S31111Nvno .:10 ).WYiiVnS r ,,,,, M/If ~ j. ~;f~' 1rY1t1 lanos ,f) Mo NO II .? ~IS I'lJlc//. j 'XOifddV 00 1191 V1S' 01 00;'991 '~1S 1338£5' GNU. IriS '''W '''H_'~'Hb§-, "0 C< "'. ." ,tr O J 9NiJ~V1;J OIJIT ." "'. " :fl ~t .. :1 YJ so " i.-.~ (,rPUJ ~ /1 ,,'Po .. $$11) J~ ,J,JiWi fM S~!I (JllJ:.'UJ1d 3AJ~ <).1 NriGJIt RUN) 3fJISf,'/ (lJl;'JiJ" :MJ OJ 7l'J>Ote l(;$(tOJ/(jN~ s:xJ,n:mr I -~-ox IN; ~~ ~~lI. .. n 1.~fI!!rl.~ ~~,.!~~t~, .. ~fr~~~f..~~~_+ __ --'''-~/c_,~;,;;,-. .:=.-"r -:·-::':j·tt,t~~~~{!OJ~-¥-gr,~~,~,.H~vr~¥i-.~H~"'Q::t~Y;i',~'","~(~iji;~':~~-~'~/~-~i""~I'T~~'~,'r~"""~~"""""~-i·~,~'ing ___ "'~/.~"~"r fI ,,~.~~~ OW!JI6tJJr.I ;07Yf ~:.'tfI1'{;s..tOJ./t»I'IS !:JI.PJ;;tft) ~:~;"! kW::~;{= ~ t---ill. 'It -1f;l~~IAJ~)S.QIJ~~1t )'}'UL~~ 'N":f.:-&- 1-".,;i~;;-·:T-'·';';":'j'T--::-::-:-:-:·':"":"'=====~r~, ... ~'~5;1\<;~" ~':~"~:-~~~~~·~~ri..-4~1·~~'iJ~~iy~~~!~YJ~·"~~~"~'t:~~::~·""~~~~~~~~·,~;j:·""~~~~IRf~~3=:~:~=:.: ..... "J"'~-~~ .. ~~~" ·d3.~"""Y.i .0..1/ ()IJ::J.1hK1 .~... ~"cr'i ','iQf;r.)/KIS '#()iJ:J/'JJIJ .'t.rIi<XJ OV" lJ1iI1:J '#IOr1t~r.JKJ '!H;IW~f'S :.'0 ;Sf)~ $.~)lll;)I~ 04 1··Vl~ ·IN.lIfr.>t).,J .(;~1.'" TN;/GI (no:; Jt:rJ.) ~u.:u~, s, ... 'O''1'.rfl.l:'9 S.lM;Juf 'trY rCJ11 '01/ lUll ).Vd SJIll1NVno "'0 ).~mf(nS r-" S. W 72nd S7RECT (SUNSrr DRIVE) ... ,:': __ --r __ •• __ .. _~~_,. ____ ~ ... __ .. _ •• _._w_ .. ~-.. -..... o .~t;.'i~ ~i;!.',.I .. ,... j: •• ,J -":~.:,:,~~~, --",,, ,. ;."Il./t • ..;.r:''I''l' t\".".U '1'." I ___ '~1'.'M"M"--'rf; ~L_ li) i# t'" • j ."\~ , (X,."";: t?;"?';" foYlll ~ ~ 1="-'!"F~~ __ :.;:: =.-= == ----i-V) i '( . . ....... _. --; .,:~\ _J j ,~ t,..,'''; S'!'","iIOIL ' .. \1 t _ .. ___ , ____ . : 1/'=::::: I ":-'M: 16<1+00 -Ie- 'I'~ L.J ~~ ~ ~il .. <q ", '\):) . I I I " ',- :(1 ~t.· u. II)''', C!I"('S'i .t.'}J.J<' PAVING' PLAN S,W 72nd --... !,.'lUr.O_ 17.,~,.. ~~.-_.,. '\ --r--"'-'E lJ/V I -I J _ I --= I ---~', "',~ I --.--.,.~ ----MINt ._. "0<"~ I" ...• ~':., ... ·11 . ",s.,,) ~" ... ~ •. J." PAVEMENT MARKING PLAN .J ........ I'r .,., ... ~~') bi]~LM -" ,-.. ~ ~.:t.~~~t;:.;:_, .. , ''';;I,(.~''.) ~I ,,' ~ t .... '" .r.: END PRQ.JiiCT "III) JJ}~IJ!!.G ~ I?fPstJRFJlClNC 'ST~7'iOO,1!8 € SURVf:Y (51\' 72NO STREET) 1M TCI/ EXIST. CONe. WALK --;-1 j-lr1~~~' Ir ',., :c I" .'. " '.~"'""!. .. ..!:::... n'PE D ctJ/I(/ r '£!)BJJ~ actAL PRQJ£Cl..1ImI§ C<'~N:!to:VM WWfll r:tf'4'106Wt -sw UlIi CI ;0 ~'K ~~I .&\£ ....... ~.", U/\H ""II LV'. ~ ~ } }-) ~ "" lIr.fml" {(lCArh?HS ~ ~~I"l".fflD All'!: "1f) 8l: 'lfRfF~O 9t c~rRAt1'OR ~ ro fJrt"'AVArfQN . 1. lY.)In,; SHlli i1f; J.(.VNT~!Nf'fJ t;N {), .. sr-rncc ASP/Pl.';':: CO!'It"A(r~' ~"l)P.f~E Ar M(, ~III(S. .J. Its CQN,,'4et""'f :\1'iac;t ~.w \1')~::;,~ .-(~ W 'i""CfII;II;~ IJJD Pl.Unl/ht.'{ Al:a:n to ~.t5!O ", ~U t)l£;i. :J{f ~1JCItJ A'fft.rI) ,Ott P"t!'C oCJ\'t.Aj, ~.!06u It! .L lvr.r" t-; ). IKJC#P ~ fHlll .. ~M1W 11 M)'1ft.$ 111 ~cr It'tlll ",rrcm7 .rJtI1;"V"t':»I'S COQR""'II.ilON :wtnt ~JrY or ,'KJIJfH tr,.J« fOH MMf([nAftCr. ()F fR..IF1'i(: ~ t IJC' Rf."O{I.iIlf.() AU. t·"",sY..:wt $N"'.I",4(J(" Slj,lJl, RrwJAI UItUS!; O,~ IHSr,j""tf'h 'i!fli!t'VfJJBIf MARKING ~ lJ 'J.I.()IX2a Ii SUR\f:'Y (SlY 72NO STREET) M~ TCH EXIST, ~ ~/".!: !~:t>51~· .J:~~ •. ,.,.\/---=':= +J I .. i', 1l:: I L<'") :.5 ~ Yr.;-'~"r;; ',"= ~I ~ I_ -o· t. ... }" _,",,'f I-,.:':,;.1 If,r-"" "I ~~ ....,.-.... ~- art rI $OJl11 UWII r,,~,/'1 .... _' ... 1 ..... ..... ~- ROADWAY PlANS NiI7d DNllNVld .,"" Hlno, 0<) IJIJ 11OO}Io($ a.~lt:ll.lllr. S.A,ltJ ~~ 7.Jfl'lQt1(I):W ,. ~ 11f1"1S ","aJll"..u '!;N'JII~-4 dill'" ,ri31r;''iD,wf1 rJ1IJ3JVM. Jli 'n",s J .. ~Jlm J.iVYfd N.]n {IV 11 'SW..2'II1l.d ~JJJr ,l,U.tHO)M~ CJ]A/)!) /10 '.JJJfY.J~ JU l'J'I'Ii!i 'S1f1YJ UNY 5.J;JUJ. 1/Y vi "Sn.1J:; 0".( S;.No1dl J<;~ I.;;"..", :11'<1 1~' IYJ C~lil]!i li2L-¥ a.l<mSI"3t\" 18 OJ Hl.''')f:;l#f ~.'fi.-#l J¥J l'MJiM(i 11;1:) 01" .~;UH H1l.o~ Qt."i ll('.hliS l .... ~ Je'>Ol/Mi J.l:)]!tn V;"'rJ7t"1" .10 J C~' 'cj ~~\o(.W"'i}' IMt" IJJn~' J() All:) t/ilJ 1J.JL(!!ur.1.J j(JM'J:iI YJ,"/75 X!.l~· m.v r.(Y~'<fOJ .:X f).4fj.fit} 'Hi.! AIJ/I H~~ eJ,rnu :Jd 11",/:; IIJa,", IMO)II ,... .. W JQ:/JU 71 sa:.l'I! .1.0 :lltU 1:J "'I)I}; ... -v.1.Vi ~)JNS.I lW INJrf<j01:J1l.~ ;,lJrfl,r ~;'j iY:I·{inill:l0:N1 qy,!)W N:;';;'" $NliH(t.·,-o:,) Pi" .W ~:':.:ffl~;)fI.1 n1.11~ !'>!1y 1)/(wrnd JtIOOR ~j H!)Y~ (HlV JfJIfIr.'!J IJ.'IS lit' .~.".(1 nrwS" ~1.1r'b:CN(X) ~J.~Y:11 V'( :::).'(/tf tJ.'JI"')V1);) J.b'f'>SJ;;.~ JHl ')Nf!vll'le-.J (J .... t S'.i<!IIUI W1'WM:> c.w "'rI'~ALY.Wr1 'fit ~'!A.:rt£M !;OJ :J Wf$'N"'~"':::J $I 6')i:N:uf:fXJ 'V.)IJV'IIVJ.~N OJ l!()QM M/JS~f'i'" :Jm .Nf 'n1HlIYII J,v'"lld AM ru I/.,:)lf~ ~ )mJ. y ·1:.J:l"~'U .~,,u1:] ltiA/. 1"if1f!"JJln "H~}~ ir.'!l.)WI.'f'KV ·S:lI\f.j't).W;SJUdlIl /IllH.J dO/Wit' (f"IV"df .... Ulai 10 .U" ,lI/J .ur ~Wd'l 1l}{2lJJiM U1Jd.T.l:)v i9 1MIS .~lfII'ISRII." ON ·.;sn 1.'N1wJ :1).11 iii a~If:Jl&B JO~ SJH1f11.lJJK'r01/a ~IJS :JHi a1~:.J liO O"lrY TTtJl'; '/~'IS't'n )~Y'Id"/7Y r :1.:N1G711Jn;' ,1~1 l1l'h'.\' j.·ii«"-dfl ""1 !iJ!.~/.11:I:rS1J ,A(1fh""m'> ,~ .: .... \) .WI 1;1 'It,yru( CNI:J,'<.jlWfOJ 01 ,"OOM $JtJ~J,,""i() 1W ~,1,'ju.lwl" H01 .1JmSIJ(MS"" Hm:nYIN(J;) .A1ru) HmOPftIdfl.rn HO.f ,~# $,7WJ"'rfllJ l,"lrf 'r. ~'Yi:)(:~SN\):J ]'J(JP.JO (J.'1. O,.-ob' 001 $!Jt;:J':.NI,~k!J WMWrJS l00J 113d S~ all j'r'.lSlW.' Ell H~;; ~f..w~"~1; ., t:I'C.~ ~~/!i.~J.m' /r0."J~j~ ,.rw XJ()f"(JJIt ,,~~,,: D.:JJ:~J:J~p ;t:U=-fd f{.I.,tl "ShY.) NO""~ i' o. 1'f1l1\lO.3OO .{/"~~~ ~r,;OffHIO~J _~=~.....::-nJ/!M=~,l!>~--,Pfi!l~::.::~~ ... ~ 1MH mJWJ'lotl 1- ::wt ". ... .n\~& J,.,c~., ... ~X.'" .. X'\IJ % ~~S ~E+-lnr""'~=\-?=~_""''''''~--,I---!::-~,nw.N .~~~ (~ti;~'fJ!fn'fj)~lttllf J(A::I U(l(J."11'1YH.'11 .. UO"4J d MlI!t! .. ~ GJi.7f:'! ~ • ..( lIN.,... (rri) U ~ :> .lHY P..WtiH:f1tl * !jrGol""Y1Jo,'W IJ() ')]~OJI.:J'v''J~ (Nfl 'LJ iJJ -x ~:r l n T I I. -<?-j 7w130 {)NilNV7d mVd 700NTIW ., ~}-~ ...:r~/r~;~----{' ~~~-. ';' f~ 'Jid.Ah""'t:1 Of jGO'~t .."a . , ..,,, ! I ; I NV7d NOll V!)IClHI Yl ;t'.1, o:t')NnO~ Cf if:r71;;;hfNO:1 hQl1.l 1i.l:rl'.~ (IN IWi'. ri,.:nm.1tlo,-o.' 3iJ il..,...S ~V ;llIiY.) "'Pt1¥Ji1 J~NI(} fiN!)[»J"~.;cwn (J~k/)t m ~)'h;'().1 (}(iC>5 JJJOHt(1 JiC ,." ill lfwr~' ..1.C;..I 1(y l:f,t;tn n' H:JI4..llJI .~,~ JHJ f.H 1/11&.'0,'1 ItJ ~ JOeI.f/vO,1 fif;((r'Wilil J:;r"tl "" '~IfI." ,10 )011('1 "'CJlLi .. ' a,bJ'kJ JIJ H~~-s!Nl.·~ ~])If,'.lIdf1..t dfl-lJt.'d • '1<)Jr:t .if) {j(>J (tJ OJlNl5~ HMm '.~l 51)(11.:11Y1 C1<N _fll ,[1M." n" .l.Yfl!I '(JlJl,J ]t11 Nr rrJJ...t;(l.'Y}V Jfl 7J~ G/C04/r:J()' 'hAl S~'UJ(~ )~~119 !JItQ6.Jr 1:;Y ItQ.II.;B :Jl/tf.£M.;".J' ~r itvJl."1J' ~ :?i:J/¥.nJ HOJ ~ niJ1K?U Jdblc.'i ':;t..:j ()) Jwa1ffJS )0 r/rHS" .1MiId 17'J' 'r 'A.,I!4S lO':Io'AoI .JO rJr-1Um %Q6 JO Ifil.IIHiIII 1')iJ1/tl ~a~ Z(xU T..d4.OUJ lMlS "'JJ~ NOuW>IJJ!M;P11 'l W)jrH'~1f) M»f:. {lJ 1(!ti (l1,a'UlS.'f1 1¥f liJlJUit Udll.ta 11" OJ .n..~JS r"" uru:;3Ii liD 'J),1.JiJI "iIr-l.Kf ru '>dJ1S JJ"fI{/./I"tJ'C JJWL1J1"PtS' ~:wrtPlOj]H) '&::JtJ{'1IJ11 ~S!xl tlV JO ~r.JOr ;C-il GlIP~3A lIa:J ~..,..1ttHOdi.N: Sf bOJ!Wi::w.1 .vU! ~11'1!J11JB1 'MljN3!) ;1~13a fJNldld '? 83111'1 '",aJel .;rvlor'fl t.-; .. l: ."lr:.>Oln s;;.:...6;J, iX¥r-dQri .. i' rUfi U/¥IOlIll'dh/" ~~s Yli,J-fWS-{j()g1 ~PO<:4l AQ(d!; O/JUJ.'Wi/ (.;1J!4f 6:.0:0 .... J()~i '1:diJ'd ..to 3M f,'4!6"/" '(:/ ,,~'If.l/l(llJtJ • ..,r~ ~ INI UGl.II >#!J.JfI/ '-!U!~ ~ r'W"> ,')\0' nr ~itiP"I.st ~ fPlr;-t c:twoNr' .')'1': '(S~ .n woCloltIt u ""~) ~ 0' ~y:JC otq J1OtI. J:~ .". SKl/~'''' :Jkf IUJJ Id: H .. :;.:"...,:';I;-r:t Ij "::~/' j"-!~6' ,,/ ",:Jr.'~..:" ... " J£«:" . <> , . .{~ .",--... ~---- :. ... ';", "" ~ " , 1 ~ L. ... .... J ,.. '!J,1,f ,... ---= f;ONSTRIJ ffj110N MA '=ACJ!=.rv1'FNTt;R:OtJP •• , "lI I, ~ ~ ) ~ ~I II . June 13, 2014 Attention: Steven P. Kulick City of South Miami 6130 Sunset Drive South Miami, FI 33143 Subject: Withdrawal Request by B Square Construction Management Group, LLC Re: Project Description -Sunset Drive Downtown Median RFP #PW-2014-04 Proposal Date: 11 AM, June 13,2014 Sir, B Square Construction Management Group, LLC made a bidding error on the project noted above and hereby request our bid to be withdrawn. Our error is found in the following Bid item 580-1-2 "Landscape Complete -Large Plants (Palms) (Includes watering and fertilization)" Specifically, on the Medjool Palms which were quoted incorrectly by our landscaping sub-contractor. We formally request withdrawal of our bid for this project and relief from it We apologize for any inconvenience on our part in advance and appreciate your assistance. If you have any questions please feel free to contact me directly at 786.3252759 or by email at info@b2cmg.com . Sincerely, B Square Construction Management Group, LLC 8~ Gabriel Martinez Owner/Manager cc: Purchasing Manager City Clerk City Attorney City Manager llF Clge ORIGINAL Sou tOO i ami ~Hf ([Iy O~ fl! E'\,';A~ r r 1\'1i';(. CITY OF SOUTH MIAMI Sunset Drive Downtown Median From SW 57th Court to SW 58th Avenue Proposal Due Date: 1 1 AM, June 13, 2014 RFP #pW-20 14-04 The City of South Miami. Florida. hereinafter referred to as "CSM", through its chief executive officer (City Manager) hereby solicits sealed proposals responsive to the City's request (hereinafter referred to as "Request for Proposals" or "RFP'l All references in this Solicitation (also referred to as an "Invitation for Proposals") to "City" shall be a reference to the City Manager. or the manager's designee, for the City of South Miami unless otherwise specifically defined. The City is hereby requesting sealed proposals in response to this RFP # PW-20 14-04 titled "Sunset Drive Downtown Median". The site is located along Sunset Drive between SW 57th Avenue and SW 58th Avenue. South Miami, FL 33143. The purpose of this RFP is to contract (or the services necessary (or the completion of the project in accordance with the "Scope of Services" as described in this RFP. Interested persons who wish to respond to this RFP can obtain the complete RFP package at the City Clerk's office Monday through Friday from 9:00 AM. to 4:00 P.M. or by accessing the following webpage: http://www.southmiamifl.gov which is the City of South Miami's web address for solicitation information. Proposals are subject to the Standard Terms and Conditions contained in the complete RFP Package, including all documents listed in the RFP Table of Contents. The Proposal Package shall consist of one (I) original unbound proposal, four (4) additional copies and one (I) digital (or comparable medium including Flash Drive, DVD or CD) copy all of which shall be delivered to the Office of the City Clerk located at South Miami City Hall, 6130 Sunset Drive, South Miami, Florida 33143. The entire Proposal Package shall be enclosed in a sealed envelope or container and shall have the following Envelope Information clearly printed or written on the exterior of the envelope or container in which the sealed proposal is delivered: the tide of this RFP, as follows "Sunset Drive Downtown Median" RFP # PW-20 14-04 and the name of the Proposer (also referred to as "Respondent"). Special envelopes such as those provided by UPS or Federal Express will not be opened unless they contain the required Envelope Information on the front or back of the envelope. Sealed Proposals must be received by Office of the City Clerk, either by mail or hand delivery, no later than 11:00 A.M. local time on June Il, 2014. A public opening will take place at II AM. on the same date in the City Commission Chambers located at City Hall, 6130 Sunset Drive, South Miami 33143. Any Proposal received after I I AM . local time on said date will not be accepted under any circumstances. Any uncertainty regarding the time a Proposal is received will be resolved against the person submitting the proposal and in favor of the Clerk's receipt stamp. A Non-Mandatory Pre-Proposal Meeting will be conducted at City Hall in the Commission Chambers at 6130 Sunset Drive, South Miami, FI 33143 on June 6 th 2014 at II :00 AM. Proposals are subject to the terms. conditions and provisions of this letter as well as to those provisions, terms, conditions, affidavits and documents contained in this RFP Package. The City reserves the right to award the Project to the person with the lowest, most responsive, responsible Proposal, as determined by the City, subject to the right of the City, or the City Commission, to reject any and all proposals, and the right of the City to waive any irregularity in the Proposals or RFP procedure and subject also to the right of the City to award the Project, and execute a contract with a Respondent or Respondents, other than to one who provided the (owest Proposal Price. © Thomas F. Pepe. 2014. 03 124114 Maria M. Menendez. CMC City Clerk Page I of 72 SCHEDULE OF EVENTS No. Event I Advertisement! Distribution of RFP & Cone of silence begins Non-Mandatory Pre-Proposal Conference 2 City of South Miami, City Hall Chambers, 6130 Sunset Drive, South Miami, FL 33143 3 Deadline to Submit Questions 4 Deadline to City Responses to Questions 5 Deadline to Submit Bid-Response 6 Evaluation of Bid Responses 7 Agenda for Commission Approval of Contractors/Cone of Silence ends ----- END OF SECTION -1;) Thomas F. Pepe, 2014 4/28/2014 Date* Time* (EST) 6/212014 4:00 PM 6/6/2014 11:00 AM 6111/2014 I 1:00AM 611212014 t 1:00AM 6113/2014 11:00 AM 6/16/2014 10:00 AM 6117/2014 7:00 PM Page 2 of 72 SCOPE OF SERVICES I. Scope of Work: The Project is generally described as construction of a landscaped median. The scope of work for this project includes milling and resurfacing. curbing. new signage. pavement marking and striping. tree planting. sodding, and irrigation. II. Site Location: The site is located along Sunset Drive between SW 57th Avenue and SW 58th Avenue. III. Plans and Specifications Sunset Drive Median Improvements. prepared by Palm Engineering. Inc. Dated May 7.2012. IV. Project Duration The current estimate to complete construction of the project is 30 days from issuance of Notice to Proceed. SPECIAL CONDITION: Due to traffic congestion in the area as well as the businesses being affected by the improvements to the road, City staff recommends that work is to be performed during the night hours from I I PM to 5 AM of the following day. The night work shall continue until such time in the construction process that the contractor and the City agree that the work will not interfere with the flow of traffic or the businesses in the area. The contractor shall provide a quote considering the night work as well as reopening the streets in the morning to allow normal traffic flows. V. Warranty: The standard manufacturer's warranty information must be proVided in writing for all equipment being proposed, including installation by an authorized dealer. Native trees planted by the awarded vendor for this project shall be warranted to be healthy and growing for a period of one (I) year from the date of planting. Note: A Proposal Bond is NOT required for this project. t! Thomas F. Pepe. 2014 4/28/2014 END OF SECTION Page 3 of 72 INSTRUCTIONS for RESPONDENT IT IS THE RESPONSIBILITY OF THE RESPONDENT TO THE SOLICITAl10N TO ENSURE THAT THE RESPONSE TO THE SOLICITATION (HEREINAFTER ALSO REFERRED TO AS THE "PROPOSAL" THROUGHOUT THE CONTRACT DOCUMENTS) REACHES THE CITY CLERK ON OR BEFORE THE CL()SINS;J;iHlJ~ A.N9 ,J?ATi:gATJ:D 9N.J.I::t~,~I7~ f9iV1·, 'C I. Purpose of RFP. The City of South Miami is requesting proposals for the lowest and most responsive price for Sunset Drive Downtown Median. The City resetYes the righ1: to award the contract: to the Respondent whose proposal is found to be in the best interests of the City. 2. Qualification of Proposing Rrm. Response submittals to this RFP will be considered from firms normally eng3geOln pro'liding the 'seMces requested~ The proposing ·firin must demonstrate adequate experience. organization, offices, equipment and personnel to ensure prompt and efficient service to the City of South Miami. The City reserves the right, before recommending any award. to inspect the offices and organization or to take any other action necessary to determine ability to perform in accordance with the specifications, terms and conditions. The City of South Miami will determine whether the evidence of abnity to perform is satisfactory and reserves the righ1: to reject all response submittals to this RFP where evidence submitted. or investigation and evaluation, indicates inability of a fitm to perform. 3 . Deviations from Specifications. The awarded firm shall clearly indicne, as applicable. all areas in which the services proposed do not fully comply with the requirements of this RFP. The decision as to whether an item fully complies with the stated reqUirements rests solely with the City of South Miami. 4 . Designa1:ed Contact. The awarded firm shall appoint a person to act as a primary contact with the City of South Miami. This person or back-up shall be readily available during normal work hours by phone, email, or in person. and shall be knowledgeable of the terms of the contract. 5. Precedence of Conditions. The proposing firm . by virtue of submitting a response, agrees that City's General Provisions, Terms and Conditions herein will take precedence over any terms and conditions submitted with the response. either appearing separately as an attachment or included wichin the Proposal. In the event of a conflict betWeen documents the following order of precedence shall apply, unless otherwise specified in the Contract or General Conditions to the Contract, and the conflicting document found above the other conflicting document or documents in the list shall take precedence over the documents in the list found below it: a) Addenda to RFP b) Attachments/Exhibits to RFP c) RFP d) AttachmentslExhibits t:o Special or supplementary conditions to Contract e) Special or supplementary conditions to Contract f) AttachmentlExhibits to Contract g) Contract h) General Conditions to Contract i) Proposal 6. Response Withdrawal. After Proposals are opened, corrections or modifications to Proposals are not permitted, but the proposing firm may be permitted to withdraw an erroneous Proposal prior to the confirmation of the proposal award by City Commission, if the following is established: a) The proposing firm acted in good faith in submitting the response; b} The error was not the result of gross negligence or willful inattention on the part of the firm; c) The error was discovered and commun icated to the City within twenty-four (24) hours of opening the response submittals received, along with a request for permission to withdraw the response; or d) The firm submits documentation and an explanation of how the response submittal error was made. 7. The terms, provisions, conditions and definitions contained in the Solicitation cover letter shall apply to these instructions to Respondents and they are hereby adopted and made a part hereof by reference. 8. Any questions concerning the Solicitation or any reqUired need for clarification must be made in writing, by 11:00 A.M., June 11,2014 prior to the date of the RFP opening to the attention of Steven P. Kulick at skulick@soutbmiamifl.eov or via facsimile at (30S) 663-6346. © Thomas F. Pepe, 2014 412812014 Page 4 of 72 9. The issuance of a written addendum is the only official method whereby interpretation and/or clarification of information can be given. Interpretations or clarifications, considered necessary by the City in response to such questions, shall be issued by a written addendum to the RFP Package (also known as "RFP Specifications" or "RFP") by U.S. mail or other delivery method convenient to the City and the City will notify all prospective firms via the City's website. I O. Verbal interpretations or clarifications shall be without legal effect. No plea by a Respondent of ignorance or the need for additional information shall exempt a Respondent from submitting the Proposal on the required date and time as set forth in the public notice. I I. Cone of Silence: You are hereby advised that this Invitation to Propose is subject to the "Cone of Silence," in accordance with Miami-Dade County Ordinance Nos. 98106 and 99-1. From the time of advertising until the City Manager issues his recommendation, there is a prohibition on verbal communication with the City's professional staff. All written communication must comply with the requirements of the Cone of Silence. The Cone of Silence does not apply to verbal communications at: pre-proposal conferences, verbal presentations before evaluation committees, contract discussions during any duly noticed public meeting. public presentations made to the City Commission during any duly notice public meeting. contract negotiations with the staff following the City Manager's written recommendation for the award of the contract, or communications in writing at any time with any City employee. official or member of the City Commission unless specifically prohibited . A copy of all written communications must be contemporaneously filed with the City Manager and City Clerk 12. Violation of these provisions by any particular Respondent or proposer shall render any recommendation for the award of the contract or the contract awarded to said Respondent or proposer voidable, and. in such event, said Respondent or proposer shall not be considered for any Solicitation for a proposal, for qualifications, for a letter of interest or bid concerning any contract for the provision of goods or services for a period of one year. Contact shall only be made through regularly scheduled Commission meetings, or meetings scheduled through the Purchasing Division. which are for the purposes of obtaining additional or clarifying information. 13. Lobbying. All firms and their agents who intend to submit, or who submitted, bids or responses for this RFP. are hereby placed on formal notice that neither City Commissioners, candidates for City Commissioner or any employee of the City of South Miami are to be lobbied either individually or collectively concerning this RFP. Contact shall only be made through regularly scheduled Commission meetings, or meetings scheduled through the Purchasing Division. which are for the purposes of obtaining additional or clarifying information. 14. Reservation of Right. The City anticipates awarding one contract for services as a result of this RFP and the successful firm will be requested to enter into negotiations to produce a contract for the Project. The City. however. reserves the right, in its sole discretion, to do any of the following: a) to reject any and all submitted Responses and to further define or limit the scope of the award. b) to waive minor irregularities in the responses or in the procedure required by the RFP documents. c) to request additional information from firms as deemed necessary. d) to make an award without discussion or after limited negotiations. It is. therefore, important that all the parts of the Request for Proposal be completed in all respects. e) to negotiate modifications to the Proposal that it deems acceptable. f) to terminate negotiations in the event the City deems progress towards a contraa to be insufficient and to proceed to negotiate with the Respondent who made the next best Proposal. The City reserves the right to proceed in this manner until it has negotiated a contract that is satisfactory to the City. g) To modify the Contraa Documents. The terms of the Contraa Documents are general and not necessarily specific to the Solicitation. It is therefore anticipated that the City may modify these documents to fit the specific project or work in question and the Respondent, by making a Proposal, agrees to such modifications and to be bound by such modified documents. h) to cancel, in whole or part, any invitation for Proposals when it is in the best interest of the City. I S. Contingent Fees Prohibited. The proposing firm must warrant that it has not employed or retained a company or person, other than a bona fide employee. contractor or subcontraaor, working in its employ. to solicit or secure a contract with the City, and that it has not paid or agreed to pay any person, company, corporation, individual or firm other than a bona fide employee, contraaor or sub-consultant, working in its employ. any fee. commission, percentage, gift or other consideration contingent upon or resulting from the award or making of a contract with the City. -to Thomas F. Pepe. 2014 412812014 Page 5 of 72 16. Public Entity Crimes. A person or affiliate of the Respondent who has been placed on the convicted vendor list pursuant to Chapter 287 following a conviction for a public entity crime may not submit a Proposal on a contract to provide any goods or services, or a contract for construction or repair of a public bUilding, may not submit proposals on leases of real property to or with the City of South Miami, may not be awarded a contract to perform work as a CONTRACTOR, Sub-contractor, supplier, Sub-consultant, or consultant under a contract with the City of South Miami, and may not transact business with the City of South Miami for a period of 36 months from the date of being placed on the convicted vendor list. 17. Respondents shall use the Proposal Form(s) furnished by the City. Failure to do so may cause the Proposal to be rejected. Failure to include any of the Proposal Forms may invalidate the Proposal. Respondent shall deliver to the City, as a RFP Package, the following documents: a) The Invitation for Proposal and Instructions to Respondents. b) A copy of all issued addenda. c) Four (4) copies of the completed Proposal Form fully executed. d) Proposal Bond, (Bond or cashier's check) attached to the Proposal Form. e) Certificates of Competency as wen as all applicable State, County and City Licenses held by Respondent f) Certificate of Insurance and/or Letter of Insurability. g) The entire RFP Package shall be placed in a sealed, opaque envelope and clearly marked with the Respondent's name and tided as follows : "SEALED PROPOSAL, "Sunset Drive Downtown Median", RFP #pW-2014-04. 18. All erasures and corrections must have the initials of the Respondent's authorized representative in ink at the location of each and every erasure and correction. Proposals shall be signed using Blue ink; all quotations shall be typewritten or printed with ink. All spaces shall be filled in with the requested information or the phrase "not applicable". 19 . Goods: If goods are to be provided pursuant to this RFP the following applies: a) Brand Names: If a brand name, make, manufacturer's trade name, or vendor catalog number is mentioned in this Solicitation, whether or not followed by the words "approved equal", it is for the purpose of establishing a grade or quality of material only. Respondent may offer goods that are equal to the goods described in this Solicitation with appropriate identification, samples and/or specifications for such item(s). The City shall be the sole judge concerning the merits of items proposed as equals. b) Pricing: Prices should be stated in units of quantity specified in the Proposal Form. In case of a discrepancy, the City reserves the right to make the final determination at the lowest net cost to the City. c) Mistake: In the event that unit prices are part of the Proposal and if there is a discrepancy between the unit price(s) and the extended price(s), the unit price(s) shall prevail and the extended price(s) shall be adjusted to coincide. Respondents are responsible for checking their calculations. Failure to do so shall be at the Respondent's risk, and errors shall not release the Respondent from his/her or its responsibility as noted herein. d) Samples: Samples of items, when required, must be furnished by the Respondent free of charge to the City. Each individual sample must be labeled with the Respondent's name and manufacturer's brand name and delivered by it within ten (10) calendar days of the Proposal opening unless schedule indicates a different time. If samples are requested subsequent to the Proposal opening, they shall be delivered within ten (10) calendar days of the request. The City shall not be responsible for the return of samples. e) Respondent warrants by signature on the Proposal Form that prices quoted here are in conformity with the latest Federal Price Guidelines. f) Governmental Restrictions : In the event any governmental restrictions may be imposed which would necessitate alteration of the material quality, workmanship, or performance of the items offered on this Proposal prior to their delivery, it shall be the responsibility of the successful Respondent to notify the City at once, indicating in its letter the specific regulation which required an alteration. The City of South Miami reserves the right to accept any such alteration, including any price adjustments occasioned thereby, or to cancel all or any portion of the Contract, at the sole discretion of the City and at no further expense to the City with thirty (30) days advanced notice. 'id Thomas F. Pepe, ~014 4128:'2014 Page 6 of 72 g) Respondent warrants that the prices, terms and conditions quoted in the Proposal shall be firm for a period of 180 calendar days from the date of the Proposal opening unless otherwise stated in the Proposal Form. Incomplete, unresponsive, irresponsible, vague, or ambiguous responses to the Invitations for Proposals shall be cause for rejection, as determined by the City. h) Safety Standards: The Respondent warrants that the product(s) to be supplied to the City conform in all respects to the standards set forth in the Occupational Safety and Health Act (OSHA) and its amendments . Proposals must be accompanied by a Materials Data Safety Sheet (M.S.D.S) when applicable. 20. Liability, Licenses & Permits: The successful Respondent shall assume the full duty, obligation, and expense of obtaining all necessary licenses, permits, and inspections required by this RFP and as required by law. The Respondent shall be liable for any damages or loss to the City occasioned by the negligence of the Respondent (or its agent or employees) or any person acting for or through the Respondent. Respondents shall furnish a certified copy of all licenses, Certificates of Competency or other licensing requirement necessary to practice their profession and applicable to the work to be performed as required by Florida Statutes. the Florida Building Code. Miami-Dade County Code or City of South Miami Code. These documents shall be furnished to the City as part of the Proposal. Failure to have obtained the required licenses and certifications or to furnish these documents shall be grounds for rejecting the Proposal and forfeiture of the Proposal Bond. 21. Insurance: Respondent shall meet the Indemnification and Insurance ReqUirements set forth in the General Conditions to the Contract which is attached to this RFP Package. a) Failure to fully and satisfactOrily comply with the City's insurance and bonding requirements set forth herein shall authorize the City to implement a rescission of the Proposal Award or rescission of the recommendation for award of contract without further City action. The Respondent, by submitting a Proposal. thereby agrees to hold the City harmless and agrees to indemnify the City and covenants not to sue the City by virtue of such rescission. 22. Copyrights and/or Patent Rights: Respondent warrants that as to the manufacturing. producing or selling of goods intended to be shipped or ordered by the Respondent pursuant to this Proposal. there has not been. nor will there be. any infringement of copyrights or patent rights. The Respondent agrees to indemnify City from any and all liability, loss or expense occasioned by any such violation or infringement. 23. Award of Proposals: The City of South Miami reserves the right to award the contract to the lowest, most responsive, responsible Respondent, as determined by the City Commission, subject to the right of the City to reject any and all proposals, to waive any irregularity in the proposals or RFP procedure and subject also to the right of the City to award contract to a Respondent other than the one with the lowest price for the work. The Respondent to this RFP agrees that by submitting a response or a proposal. that said Respondent agrees to the terms of the form contract and to the terms of the general conditions to the contract, both of which are part of this RFP package and agrees that Respondent's Signature on the response to this RFP shall be treated as the Respondent's signature on the contract after the appropriate information. obtained from the proposal. is inserted into any blank spaces in the contract documents. 24. Evaluation of Proposals: The City, at its sole discretion. reserves the right to inspect the facilities of any or all Respondents to determine its capability to meet the requirements of the Contract. In addition, the price. responsibility and responsiveness of the Respondent, the financial position, experience. staffing, equipment, materials, references, and past hiStory of service to the City and/or with other units of state, and/or local governments in Florida, or comparable private entities. will be taken into consideration in the Award of the Contract. 25. Drug Free Workplace: Failure to provide proof of compliance with Florida Statute Section 287.087. as amended, when requested shall be cause for rejection of the Proposal as determined by the City. 26. Public Entity Crimes: A person or affiliate who was placed on the Convicted Vendors List follOWing a conviction for a public entity crime may not submit a response on a contract to provide any services to a public entity. may not submit RFP on leases of real property to a public entity. and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017. for a period of 36 months from the date of being placed on the Convicted Vendors List. 27. Contingent Fees Prohibited: The proposing firm must warrant that it has not employed or retained a company or person, other than a bona fide employee. contractor or subcontractor, working in its employ. to solicit or secure a contract with the City. and that it has not paid or agreed to pay any person, company. corporation, individual or firm other than a bona fide employee. contractor or sub-consultant, working in its © Thomas F. Pepe. 2014 412812 014 Page 7 of 72 employ. any fee, commission. percentage. gift or other consideration contingent upon or resulting from the award or making of a contract with the City. 28. Hold Harmless: All Respondents shall hold the City. its officials and employees harmless and covenant not to sue the City. its officials and employees in reference to its decisions to reject. award, or not award a contract. as applicable, unless the claim is based solely on allegations of fraud and/or collusion. The submission of a proposal shall act as an agreement by the Respondent that the proposal bond shall not be released until and unless the Respondent waives any and all claims that the Respondent may have against the City that arise out of this RFP process or until a judgment is entered in the Respondent's favor in any suit filed which concerns this proposal process. In any such suit, the prevailing party shall recover its attorney's fees, court costs as well as expenses associated with the litigation . In the event that fees, court cOSts and expenses associated with the litigation are awarded to the City, the Proposal Bond shall be applied to the payment of those COSts and any balance shall be paid by the Respondent. 29 . Cancellation: Failure on the part of the Respondent to comply with the conditions. specifications. requirements. and terms as determined by the City. shall be JUSt cause for cancellation of the Award or termination of the contract. 30. Bonding Requirements: The Respondent, in submitting this Proposal. shall include a Proposal Bond in the amount of 5% of the total amount of the base Proposal on the Proposal Bond Form included herein. A company or personal check shall not be deemed a valid Proposal Security. 3 I . Performance and Payment Bond: The City of South Miami may require the successful Respondent to furnish a Performance Bond and Payment Bond. each, in the amount of 100% of the total Proposal Price. including Alternates if any. naming the City of South Miami as the obligee. as security for the faithful performance of the Contract and for the payment of all persons or entities performing labor. services and/or furnishing materials in connection herewith . The bonds shall be with a surety company authorized to do business in the State of Florida. 32. Forfe twre of Bid Sec urity/Pe rforman ce an d Pay ment Bo nd. if any are reQ uired : 32. I Within ten (10) calendar days of being notified of the Award. Respondent shall furnish a Performance Bond and a Payment Bond containing all the provisions of the Performance Bond and Payment Bond attached. 32 .1.1 Each Bond shall be in the amount of one hundred percent (100%) of the Contract Price guaranteeing to CITY the completion and performance of the Work covered in such Contract as well as full payment of all suppliers, material man. laborers. or Subcontractor employed pursuant to this Project. Each Bond shall be with a Surety company whose qualifications meet the requirements of Sections 32.1.4, 32.1.5, and 32.1.6. 32.1 .2 Each Bond shall continue in effect for five year after final completion and acceptance of the Work with the liability equal to one hundred percent (100%) of the Contract Sum . 32.1.3 Pursuant to the requirements of Section 255 .05( I), Florida Statutes, Respondent shall ensure that the Bond(s) referenced above shall be recorded in the public records of Miami-Dade County and provide CITY with evidence of such recording. 32.1.4 Each Bond must be executed by a surety company authorized to do business in the State of Florida as a surety. having a resident agent in the State of Florida and having been in business with a record of successful continuous operation for a least five (5) years . 32 .1.5 The surety company shall hold a current certificate of authority as acceptable surety on federal bonds in accordance with the United States Department of Treasury Circular 570, current revisions. 32 .1.6 The CITY shall only be required to accept a surety bond from a company with a rating A. VII or better. 32.1.7 Failure of the successful Bidder/Respondent to execute and deliver the Contract, and deliver the reqUired bonds and Insurance documents shall be cause for the CITY to annul the Notice of Award and declare the Bid and any security therefore forfeited . 33 . Proposal Guarantee: The successful Respondent shall execute the Contract (Agreement) and provide the applicable insurance documents. and a Performance and Payment Bond. if required, within ten (10) calendar days of Notice of Award by the City. The Respondent who has the Contract awarded to him and who fails to execute the Contract and/or furnish the required Bonds and Insurance documents within the specified time shall, at the City's sole and absolute discretion. forfeit the Proposal Bond/Security that accompanied the rid Thomas F. Pepe.20 14 4128 /2014 Page 8 of 72 Proposal, and the Proposal BondiSecurity shall be paid to the City and retained as liquidated damages by the City, and it is agreed that this sum, if the bond is required and provided, is a fair estimate of the amount of damages the City will sustain in case the Respondent fails to enter into the Contract or furnish the Bonds and insurance documents. Proposal BondlSe<urity deposited in the form of a cashier's check drawn on a local bank in good standing shall be subject to the same requirements as a Proposal Bond. The City may, in its sole and absolute discretion, sue for breach of contract if the successful Respondent fails to provide the required insurance and bonding. 34. Pre-proposal Conference Site Visits: It is mandatory that all Respondents attend a pre-proposal conference if required or requested by the City, and tour all areas referenced in the Proposal Documents. It shall be grounds for rejecting a Proposal from a Respondent who did not attend the pre-proposal conference. No pleas of ignorance by the Respondent of conditions that exist, or that may hereinafter exist, as a result of failure to make the necessary examinations or investigations, or failure to complete any part of the RFP Package, will be accepted as basis for varying the requirements of the Contract with the City of South Miami or the compensation of the Respondent. 35. Time of Completion: The time is of the essence with regard to the completion of the Work to be perfonned under the Contract to be awarded. Delays and extensions of time may be aflowed only in accordance with the provisions stated in the appropriate section of the Contract Documents, including the Proposal Form. 36. Submittal Requirements: All Proposals shall comply with the requirements set forth herein. 37. Cancellation of Bid Solicitation: The City of South Miami reserves the right to cancel, in whole or part, any invitation to bid when it is in the best interest of the City. 38. Respondent shall not discriminate with regard to its hiring of employees or subcontractors or in its purchase of materials or in any way in the performance of its contract, if one is awarded, based on race, color, religion, national origin. sex. age, sexual orientation, disability, or familial Status. 39. All respondents, at the time of bid opening, must have fulfilled all prior obligations and commitments to the City in order to have their bid considered, including all financial obligations. Prior to the acceptance of any bid proposal or quotation, the City's Finance Department shall certify that there are no outstanding fines, monies, fees, taXes, liens or other charges owed to the City by the Respondent, any of the Respondent's principal, partners, members or stockholders (collectively referred to as "Respondent Debtors"). A bid. proposal or quotation will not be accepted until all outstanding debts of all Respondent Debtors owed to the city are paid in full . No bidder who is in default of any prior contract with the City may have their bid considered until the default is cured to the satisfaction of the City Manager. il;i Thomas F. Pepe, 2014 4/28/2014 END OF SECTION Page 9 of 72 Proposal Submittal Checklist Form This checklist indicates the forms and documents required to be submitted for this solicitation and to be presented by the deadline set for within the solicitation. Fulfillment of all solicitation requirements listed is mandatory for consideration of response to the solicitation. Additional documents may be required and, if so, they will be identified in an addendum to this RFP. The response shall include the following items: Attachments and Other Documents to be Completed: Check Indicating Complete / Bid Form X ./ Proposal Bid Bond N/A Performance Bond Power of Attorney X BIDDER Qualification Statement X Non-Collusion Affidavit X / / Public Entity Crimes and Conflicts of Interest X 7 Drug Free Workplace X / Acknowledgement of Conformance with OSHA Standards X List of Proposed Subcontractors and Principal Suppliers X Related Party Transaction Verification Form / X Indemnification and Insurance Docume.nts X Note: A Proposal Bid Bond is NOT required for the project. Submit this checklist along with your proposal indicating the completion and submission of each required forms and/or documents. e Thomas F. Pepe, 2014 4/2812014 END OF SECTION Page 10 of 72 THIS PROPOSAL IS SUBMITTED TO: Steven Alexander City Manager City of South Miami 6130 Sunset Drive South Miami, Fl 33 143 BID FORM I. If this Proposal is accepted the undersigned Respondent agrees that by signing this Bid Fonn, the Respondent is agreeing to each and every term, provision and condition contained in the form of the Contract that is included in this RFP Package ("the RFP Contract"), and to perform and furnish all work as specified or indicated in this RFP for the Proposed Price, within the Contract Time and in accordance with the other terms and conditions of the RFP Package and the RFP Contract. The Respondent agrees that if the contract is awarded to the Respondent. the signature of the Respondent, or the signature of its authorized representative, on this Bid Form shalf be the same as a signature on the RFP Contract. 2. Respondent accepts all of the terms and conditions of the Advertisement. RFP, Invitation for Proposals and Instructions to Respondents, including without limitation those dealing with the disposition of Proposal Bond/Security. This Proposal will remain subject to acceptance for 180 calendar days after the day of the Proposal Opening. Respondent agrees to sign and submit the Contract with the Bonds, Insurance Policy with appropriate endorsements, Insurance Certificate and other documents required by the RFP within ten (10) calendar days after the date of the City's Notice of Award. 3. In submitting this Proposal, Respondent represents that a Respondent has examined copies of all the RFP Documents and of the follOWing Addenda, if any (receipt of all which is hereby acknowledged.) Addendum No. Dated: 06/03/2014 Addendum No. 2 Dated: O~~ Addendum No. Dated: Addendum No. Dated: Addendum No. Dated: Addendum No. Dated: b. Respondent has familiarized himself with the nature and extent of the Contract Documents, the proposed work. site, locality, and all local conditions and laws and regulations that in any manner may affect coSt. progress, performance or furnishing of the Work. c. Subsurface conditions: If applicable to this RFP, the Respondent represents that i. Respondent has studied carefully all reports and drawings, if applicable, of subsurface conditions and drawings of physical conditions. ii. Respondent has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying) all such examinations, investigations. explorations, tests and studies in addition to or to supplement those referred to in (c) above which pertain to the subsurface or physical conditions at the site or otherwise may affect the cost. progress, performance, or the furnishing of the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents. The Respondent hereby acknowledges that no additional examinations, investigations, explorations. tests, reports or similar information or data are, or will, be required by Respondent for any reason in connection with the Proposal. The failure of the Respondent iQ Thomas F Pepe.2014 412812014 Page II of72 to request a pre-bid marking of the construction site by any or 01.1/ utility companies shall create an irrefutable presumption that the Respondent's bid. or proposal price, has taken into consideration all possible underground conditions and Respondent, if awarded the contract. shall not be entitled to a change order for any such condition discovered thereafter. iii. Respondent has correlated the results of all such observations, examinations, investigations, explorations, tests, reports and studies with the terms and conditions of the Contract Documents. iv . Respondent has reviewed and checked all information and data shown or indicated in the RFP Package or in the Contract Documents with respect to existing Underground Facilities at or contiguous to the site and assumes responsibility for the accurate location of all Underground Facilities . No additional examinations, investigations, explorations, tests, reports or similar information or data in respect to any Underground Facilities are, or will be. required by Respondent in order to perform and furnish the Work at the Contract Price. unless the respondent makes a written request to the City for additional information prior to submitting the bid or proposal as required in subsection ii above. within the Contract Time and in accordance with the other terms and conditions of the Contract Documents. d. Respondent has given the City written notice of all conflicts. errors or discrepancies that it has discovered in the Contract Documents and. if any confliCts. errors or discrepancies have been found and notice given. the Respondent represents. by submitting its proposal to the City, that the Respondent has received sufficient notice of the resolution thereof (rom the C ity, that such resolution is acceptable to Respondent and that the Respondent waives any claim regarding the conflicts . errors or discrepancies . e. This Proposal is genuine and not made in the interest of or on behalf of any undisclosed person. firm or corporation and is not submitted pursuant to any agreement or rules of any group . association. organization, or cOll'oration ; Respondent has not directly or indirecdy induced or solicited any other Respondent to submit a false or sham Proposal; Respondent has not solicited or induced any person, firm or corporation to refrain from responding; and Respondent has not sought by collusion or otherwise to obtain for itself any advantage over any other Respondent or over the CITY . 4 . Respondent understands and agrees that the Contract Price is the amount that it needs to furnish and install all of the Work complete and in place. The Schedule of Values, if required, is provided for the purpose of Proposal Evaluation and when initiated by the CITY , it shall form the basis for calculating the pricing of change orders. The Contract Price shall not be adjusted in any way so as to result in a deviation from the Schedule of Values, except to the extent that the CITY changes the scope of the Work after the Contract Date. As. such. the Respondent shall furnish all labor. materials. equipment. tools, superintendence and services necessary to provide a complete, in place Project for the Proposal Price of: LUMP SUM BASE PRICE : dollars and Alternates: t;; Thomas F. P~. 2014 4'211/"014 #1 #2 #3 #4 }.),f)EN NlnC T4v6 ft "d. 1 l£1t() #5 #6 #7 #S cents $ Cjq Qq). 00 Page 12 of 72 A fee breakdown. if applicable. for each task mun be completed in the table shown above. Failure to complete this information shall render the proposal non-responsive. 5. The ENTIRE WORK shall be completed. in full. within 30 woridng days from the date stipulated in the NOTICE TO PROCEED. Failure to complete the entire work during the described time period shall result in the assessment of liquidated damages as set forth in the Contract. 6. Communications concerning this Proposal shall be addressed to: RESPONDENT: JV A Enweering Contractor. Inc . Address: 6600 NW 32nd Avenue, Miami. FL 33147 Telephone: 305-696-7902 Facsimile: 305-696-7903 Attention: 7. The terms used in this Proposal which are defined in the Contract shall have the same meaning as is assigned to them in the Contract Documents, unless speCifically defined in this RFP Package. SUBMITTED THIS 12th PROPOSAL SUBMITTED BY: Compa" r{;) Thomas F. Pepe, 2014 4128/2014 DAY OF Inc. June 20-.l.4..... 305-696-7902 Telephone Number 305-696-7903 Fax Number ima@jvaengineering.com Email Address END OF SECTON Page 13 of 72 PROPOSAL BOND (Note: Not Required for this project) STATE OF FLORIDA COUNTY OF MIAMI-DADE i KNOW All MEN BY THESE PRESENTS. that we. ____ ~---''-A-_________ _ ___________ , as Principal, and _______________________ _ __________ -" as Surety. are held and finnly bound unto the City of South Miami ("City"). a municipal corporation of the State of Florida in the sum of __ ---::-___ ----, ___________ _ Dollars ($ ). lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves. our heirs. executors. administrators and successors jointly and severally. finnly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that: WHEREAS, the Principal has submitted the accompanying Proposal dated . for the pursuant to an RFP and a condition precedent to the submission of said Proposal is that a Proposal Bond in the amount of five percent (5%) of the Base Proposal be submitted with said Proposal as a guarantee that the Respondent would fulfill the obligations set forth in the RFP and proposal documents; NOW THEREFORE, A If the principal shalf not withdraw said proposal within one hundred eighty (180) calendar days after the date for opening of the same. and shall, within ten (10) calendar days after the prescribed fonns are presented to it for signature, enter into a written contract with the City in accordance with the proposal as accepted. and give bonds with good and sufficient surety or sureties. as may be reqUired, for the faithful performance and proper fulfillment of such contract, and provide proof of insurance as required, then the above obligations shall be void and of no effect, otherwise to remain in futl force and effect.. B. However, in the event of the principal's unauthorized withdrawal of said proposal within one hundred eighty (180) calendar days after the date of the opening of the same or the failure to enter into a written contract with the Owner in accordance with the proposal as accepted. and/or the failure to provide the City with bonds issued from good and sufficient surety or sureties, as may be required, for the faithful performance and proper fulfillment of such Contract and proof of insurance within ten (10) calendar days after the prescribed forms are presented to it for signature and/or in the event that the principal is not awarded the project but fails to waive all claims that arose or might have arisen out of the RFP process. then the above obligations shall remain in full force and effect and the bond shall thereafter be disburse. by court order. to the Owner in the full amount of the bond if the Proposal Documents provide for liquidated damages under the circumstance of the case or. if liquidated damages are not applicable. then in an amount that is adequate to fully compensate the Owner for all of its damages incurred due to the breach of the terms of this Bond. including all attorney fees, court costs and legal expense incurred by the City for any and all action taken, whether before or after the commencement of legal proceedings. including. proceedings required to obtain the court order of disbursement, including the cost of all appeals or other related proceedings, as well as the fees and costs incurred to collect these damages . IN WITNESS WHEREOF, the above bonded parties have executed this instrument under their several seals this day of . 20 __ . the name and the corporate seal of each corporate party being hereto affixed and these presents being duly signed by its undersigned representative. (1) Thomas F. Pepe. 2014 4128/2014 IV fA- Page 14 of 72 SECOND PAGE OF A TWO (2) PAGE PROPOSAL BOND IN PRESENCE OF: N~ <'WI (Individual or Partnership Principal) (Business Address) (City/State/Zip) (Bus iness T e lephone) ATTEST: Secretary (Corporate Surety)* By: __________ _ *Impress Corporate Surety Seal IMPORTANT Surety companies executing bonds must appear on the Treasury Department's most current list (circular 570 as amended) and be authorized to transact business in the State of Florida. FAILURE TO COMPLETE. SIGN, & RETURN THIS FORM MAY DISOUALIFY YOU ~ Thomas F. Pepe,2014 4128r.W14 By: wilt Page IS of 72 FORM OF PERFORMANCE BOND KNOW All MEN BY THESE PRESENTS: That, pursuant to the requiremenG of Florida Statute 255.05, we, ________________ ---" whose business address is and whose telephone number is as Principal (hereinafter referred to as "Contractor"). and _________ -:--_____________ -::-" whose business address is and whose telephone number is • as Surety. are bound to the City of South Miami whose business address is and whose telephone number is , and Miami-Dade County whose business address is and whose telephone number is ____________ as Obligee. (hereinafter referred to as "City") in the amount of Dollars ($ ) for the payment whereof Contractor and Surety bind themselves, their heirs, executors. administrators, successors and assigns, jointly and severally. WHEREAS, Contractor has entered into a Contract, for the Sunset Drive Downtown Median, awarded on the day of , 20 __ , under Contract Number ___ by the City for the construction of (brief deSCription of the Work) in accordance with drawings (plans) and specifications prepared by Palm Enitineerini. Inc. which Contract is hereby made a part hereof by reference, and is hereafter referred to as the "Contract"; THE CONDITION OF THIS BOND is that the Contractor: I. Fully performs the Contract between the Contractor and the City for the _________ , within days after the date of Contract commencement as specified in the Notice to Proceed and in the manner prescribed in the Contract; and 2. Indemnifies and pays City all losses, damages (specifically including, but not limited to, damages for delay and other foreseeable consequential damages), expenses, costs and attorney's fees, including attorney's fees incurred in appellate proceedings, mediation and arbitration, if any, that City sustains because of default by Contractor under the Contract or caused by or arising out of any action or proceeding to enforce the Contract or this Bond; and 3 . Upon notification by the City, correct any and all patently defective or faulty Work or materials that appear within one (I) year after the issuance of the Certificate of Occupancy, and correct any and all latent defects that are discovered before the expiration of the third (3rd) year following the date of the issuance of the Certificate of Occupancy; and 4. Performs the guarantee of all Work and materials furnished under the Contract for the time speCified in the Contract. If all of the forgoing conditions are met, then this Bond is void, otherwise it shall remain in full force and effect. Whenever Contractor shall be, and declared by the City to be, in default for failing to perform in strict accordance with any of the terms of the Contract, the Surety shall promptly remedy the default as well as perform in the following manner: Complete the Contract in accordance with the Contract's terms and conditions provided the City makes available, as Work progresses, that portion of the Contract Price that has not already been paid to, or on behalf of, the Contractor. The City shall not be required to pay any more than the amount of the Contract Price. The surety shall not be obligated to pay more than the maximum amount for which the Surety may be liable as set forth in the first paragraph of this bond. If the Surety fails to commence the Work within thirty (30) days of receipt of the City's declaration of a default or if the Surety fails to man the job with sufficient forces, or suspends the Work, for more than thirty (30) days, either consecutive or in combination with separate occasions, the City shall have the option, in the City's sole discretion, and without waiving its right to any other remedy or damages provided for by this bond, to complete the Work with other forces and the Surety shall pay for the cost to complete the Work. The term "balance of the Contract Price" as used in this paragraph, shall mean the total amount payable by City to Contractor under the Contract and any amendments thereto. less the amount properly paid by the City to the Contractor. ;;:, Thomas F. Pepe. 2014 412812014 Page 16 of 72 No right of action shall accrue on this Bond to or for the use of any person or corporation other than the City named herein. The Surety hereby waives notice of and agrees that any changes in or under the Contract Documents and compliance or noncompliance with any formalities connected with the Contract shall not affect the Surety's obligation under this Bond. IN WITNESS WHEREOF, the above bonded parties have executed this instrument under their several seals on this day of . 20 __ , the name and the corporate seal of each corporate party b7ing hereto affixed and these presents being duly Signed by its undersigned representative. IN PRESENCE OF: (Individual, President, Managing Member or General Partner, etc.) (Business Address) (City/StatelZip) (Business Telephone) OR (Corporate Name) ATTEST: (PreSident) Secretary (Business Address) (CitylStatelZip) (Business Telephone) IN THE PRESENCE OF: ________ ,INSURANCE COMPANY: BY: (SEAL) (Agent and Attorney-in-fact Signature) (Business Address) (CitylStatelZip (Business Telephone) STATE OF FLORIDA COUNTY OF MIAMI-DADE On this, the day of , 20 __ , before me, the undersigned notary public of the State of Florida, the foregoing perfonnance bond was acknowledged by (Corporate Officer), __________ -:-__ -:-:-__ (Title), of (Name of Corporation), a ____ -::-:---:-::.,..-_,.....-_ (State of Incorporation) corporation, on behalf of the corporation. WITNESS my hand and official seal. -----:--:---::--:c---::---:--:-------- Notary Public, State of Florida NOTARY PUBUC: SEAL OF OFFICE: (Name of Notary Public: Print, Stamp or Type as commissioned.) Personally known to me, or Personal identification: ......... __ -;-:-__ ,--__ :-_______ _ Type of Identification Produced Did take an oath, or Did Not take an oath. ,tJ Thomas F. Pepe, 2014 4/2812014 Page 17 of 72 FORM OF PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: That. pursuant to the requirements of Florida Statute 255.0 I. et seq.. Florida Statutes. we, _____________________ ' whose business address is and whose telephone number is ,as Principal. (hereinafter referred to as "Contractor"). and _______________ ----,------" whose business address is and whose telephone number is , as Surety. are bound to the City of South Miami. whose business address is ________ and whose telephone number is • as Obligee, (hereinafter referred to as "City") in the amount of Dollars ($ ) for the payment whereof Contractor and Surety bind themselves, their heirs. executors. administrators, successors and assigns. jointly and severally. WHEREAS, Contractor has. by written agreement. entered into a Contract for the Sunset Drive Downtown Median, awarded on the day of . 20 __ • under Contract Number for the construction of (brief description of the Work) by the City in accordance with drawings (plans) and specifications prepared by Palm Engineering, Inc. which Contract is hereby made a part hereof by reference and is hereafter referred to as the "Contract"; THE CONDITION OF THIS BOND is that if the Contractor. I. Promptly performs the construction work in the time and manner prescribed in the Contract; and 2. Promptly makes payments to all claimants. as defined in Section 255.05. Florida Statutes. supplying Contractor with labor. materials. or supplies. used directly or indirectJy by Contractor in the prosecution of the work provided for in the Contract; and 3. Pays City all losses, damages. expenses, costs, and attorney's fees, including those incurred in any appellate. mediation or arbitration proceedings, if any. that Owner sustains because of a default by Contractor under the Contract; and 4. Performs the guarantee of all work and materials furnished under the contract for the time specified in the contraCt, then this obligation shall be void; otherwise, it shall remain in full force and effect. Any action instituted by a claimant under this bond for payment must be in accordance with the notice and time limitation provisions in Section 255.05(2), Florida Statutes. The Surety hereby waives notice of and agrees that any changes in or under the Contract Documents and compliance or noncompliance with any formalities connected with the Contract shall not affect the Surety's obligation under this Bond . IN WITNESS WHEREOF, the above bonded parties have executed this instrument under their several seals on this day of , 20 __ , the name and the corporate seal of each corporate party being hereto affixed and these presents being duly Signed by its undersigned representative. IN PRESENCE OF: OR ATTEST: Secretary © Thomas F. Pepe. 2014 4!28/2014 (Individual. President. Managing Member or General Partner. etc.) (Business Address) (City/State/Zip) (Business Telephone) (Corporate Name) (President) (Business Address) Page 18 of 72 SECOND PAGE OF A twO PAGE PAYMENT BOND WHEREBY _________ IS THE PRINCIPAL AND _________________ ISTHESU~ (CitylStateJZip) (Business Telephone) IN THE PRESENCE OF: ____________ INSURANCE COMPANY: BY: (SEAL) (Agent and Attorney-in-fact Signature) (Business Address) (Clty/StateJZip (Business Telephone) STATE OF FLORIDA COUNTY OF MIAMI-DADE On this, the day of , 20 __ , before me, the undersigned notary public of the State of Florida, the foregoing payment bond was acknowledged by (Corporate Officer), __________ -:= __ -:-:-__ (Title), of (Name of Corporation), a ___________ (State of Incorporation) corporation, on behalf of the corporation . WITNESS my hand and official seal. __________________ _ NOTARY PUBLIC: SEAL OF OFFICE: Personally known to me, or Personal identification: Type of Identification Produced Did take an oath, or Did Not take an oath. *Power of Attorney must be attached. IQ Thomas F. Pepe, 2014 4/28/2014 Notary Public, State of Florida (Name of Notary Public: Print, Stamp or Type as commissioned.) END OF SECTION Page 19 of72 RESPONDENT QUALIFICATION STATEMENT The response to this questionnaire shall be utilized as part of the CITY'S overall Proposal Evaluation and CONTRACTOR selection . I. Number of similar construction projects completed. a) In the past 5 years lQ In the past 5 years On Schedule 10 b) In the past 10 years 15 In the past I 0 years On Schedule 1" 2. List the last three (3) completed similar projects. a) b) C>Thomas F Pepe.2014 4/2812014 Project Name: Miami River Greenwav NW 54th Street B ri d ge, Ext. ()NnerNam~ ~C~ity~o~fLM~i~a~m~i~ __________________ __ ()Nner Address: 444 NW 2nd Ave ., Miami, FL 33131 ()Nner Telephone: -1.:78~6>l.:-:.;,2Q6,£3-:.;;2'-..!1.d.3d..3 ________ _ Original Contract Completion Time (Days): --=27-'-'°"-""D'-'=a,...v"'-s __________ __ Original Contract Completion Date: ~O~c:!:to~b:::.e:::r:.....:::2.:::0..:.1 .:::3 __________ _ Actual Final Contract Completion Date: Original Contract Price: Actual Final Contract Price: Project Name: October 2013 $896.818.25 $896.818.25 Silver Bluff Drainage Improvements Page 20 of 72 r© Thomas F. Pepe, 2014 4/28/2014 OwnerNMne: __ C __ iry~o~f~~ __ irun~~i __________________ _ Owner Address: 444 NW 2nd Ave .• ~iami. FL 33131 Owner Telephone: 954-682-9063 ------------------------------ Original Contract Completion Time (Days): ~1~8~0~D~a~y.£.s _________ __ Original Contract Completion Date: __ ... S",e<!<p~tel<Jmu.&.!o<b",e:.Lr_",2c!.10ul..!.3C_. _______ __ Actual Final Contract Completion Date: _...:S""e::.tP""t""em=.::b:.::e""T..=2""0..:.1:::;.3 ________________ _ Original Contract Price: __ $""5...:.5 .... 7 .... 6u7.../.7 .... .5 .... 5"--_______________ _ Actual Final Contract Price _---!!:$:.:::5~5..:.7~.6~7:..;7..:. • .::.55.=:..._ ________ _ Project Name: NW 143rd Street Drainage & Roadway Imps, OwnerNMne: ~C_iry~o_f~Op~a_-L_o_c_k_a ________ _ Owner Address: 780 Fisherman Street, Cpa-Locka, FL 33054 Owner Telephone: __ -'--7""8""6..:-3"-'8""'2=--..:..79:::..:..17'--______________ _ Original Contract Completion Time (Days): __ -=-3-=c65=--=D-=a:..:..ys::..-________ _ Original Contract Completion Date: June 2013 ------------------------ Actual Final Contract Completion Date: June 2013 --~~~~~---------------- Page 21 of 72 Original Contract Price: $468,644.80 Actual Final Contract Price: $468,644 .80 3. Current workload 305-669-6919 $1,012.000.00 FOOT 305-986-2754 $1 493.07 4 . The following information shall be attached to the proposal. a) RESPONDENTs home office organization chart. See attached b) RESPONDENTs proposed project organizational chart. See attached c) Resumes of proposed key project personnel. including on-site Superintendent. See attached 5 . List and describe any : a) Bankruptcy petitions filed by or against the Respondent or any predecessor organizations. None b) Any arbitration or civil or criminal proceedings. or None Suspension of contracts or debarring from Bidding or Responding by any public agency brought c) against the Respondent in the last five (5) years None I. Government References: © Thomas F. Pepe.1014 4!2812014 Page 11 of 71 List other Government Agencies or Quasi-government Agencies for which you have done business within the past five (5) years. Name of Agency: Address: Telephone No.: Contact Person: Type of Project Name of Agency: Address: T etephone No.: Contact Person: Type of Project Name of Agency: Address: Telephone No.: Contact Person: Type of Project: © Thomas F Pepe,2014 412812014 City of Miami 444 NW 2nd Avenue, Miami, FL 33131 305-416-1298 Robert Fenton (786-263-2133), Eric Rush (954-682-9063) Multiple Projects City of Hollywood 2600 Hollywood Blvd., Hollywood, FL 33025 954-805-3681 Clece Aurelus 8-Inch Water Main and Site Restoration Miami-Dade County Parks, Recreation and Open Spaces 272 NW 2nd Street, 4th Floor, Miami, FL 33128 786-586-8325 Lydia Salas New Construction and Reconstruction of Bike Path Page 23 of 72 NON-COLLUSION AFFIDAVIT STATE OF FLORIDA COUNTY OF MIAMI-DADE Jose M . Alvarez being first duly sworn. deposes and states that (I) HefShefThey is/are the __ ---IP...Jr~e"'sJ..\id..,ednilt~ ________________ _ (Owner, Partner, Officer, Representative or Agent) of IVA Enll ineennsaContractQ(. Inc. the Respondent that has submitted the attached Proposal; (2) HelShefThey is/are fully informed concerning the preparation and contents of the attached Proposal and of all pertinent circumstances concerning such Proposal; (3) Such Proposal is genuine and is not a collusive or sham Proposal; (4) Neither the said Respondent nor any of its officers. partners, owners. agents, representatives. employees or parties in interest, including this affiant, have in any way colluded. conspired. connived or agreed, directly or indirectly, with any other Respondent, firm, or person to submit a collusive or sham Proposal in connection with the Work for which the attached Proposal has been submitted; or to refrain from Bidding or proposing in connection with such Work; or have in any manner, directly or indirecrly. sought by agreement or collusion. or communication, or conference with any Respondent, firm, or person to fix any overhead, profit, or COSt elements of the Proposal or of any other Respondent, or to fix any overhead, profit, or cost e l em en ~ the Proposal Price or the Proposal Price of any other Respondent, or to secure . ro h any .COII USi[\ n. conspiracy, connivance, or unlawful agreement any advantage against (ReciP irt ). or nz/erson i terested in the proposed Work; (5) The price or prices quoted in the attached Proposal ,are fa ir . proper d are not tainted by any ;(j Thomas F Pepe.2014 411 8/2014 By: j '\ 7 / Print Name and Title 06 /13 /2014 Date Page 24 of 72 ACKNOWLEDGEMENT STATE OF FlORIDA COUNTY OF MIAMI-DADE On this the 13th day of June , 20~. before me, the undersigned Notary Public of the State of Florida, personally appeared (Name(s) of individual(s) who appeared ~efore notary) Jose M. Alvarez apd whose n within instrument. and he/she/they acknowledge that heisheithey.lAeqn:~d.f .. / " WITNESS my hand and official seal. NOTARY PUBLIC: SEAL OF OFFICE: \\\\1\111111,,;/ ~",,~ .. VQIiiO?'(I,,,, .:Sf-•••••••• ()'~~ ~~ .~~c, .c.:.-. 0 ~ ~~ ... ~ ,~ .. ~~ ~tt"'.s,~ ~ ·t1>'.~~ E.!:!!.:~~ '~%Ij!.~lJ>E :t--!gC\.i • ~ l~:~-== :::::J • <J> -''d: r. -..J:: ~cJ.~~~ ,. ~i!§~ ~o ... ~~ .. ,Ci;.~ ...".n... 'li:" ~ ~.·.:vJ(" .•• ~:~ ~;Q'"l»,: •••••••• ~\C)"\ ~" '/"" FY ... ",,'\ .... 1111111"""\\\\\ co Thomas F. Pepe, 2014 4128/2014 Maria G. Gutierrez (Name of Notary Public: Print. Stamp or type as commissioned.) X Personally known to me, or Personal identification: Type of Identification Produced Did take an oath. or X Did Not take an oath. Page 2S of 72 PUBLIC ENTITY CRIMES AND CONFLICTS OF INTEREST Pursuant to the provisions of Paragraph (2) (a) of Section 287.133, Florida State Statutes -"A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a Proposal or bid on a Contract to provide any goods or services to a public entity. may not submit a Bid or proposal for a Contract with a public entity for the construction of repair of a public building or public work, may not submit bids or proposals on leases or real property to a public entity, may not be awarded to perform Work as a CONTRACTOR. Sub-contractor. supplier. Sub-consultant. or Consultant under a Contract with any public entity. and may not transact business with any public entity in excess of the threshold amount Category Two of Section 287.017. Florida Statutes. for thirty six (36) months from the date of being placed on the convicted vendor list". The award of any contract hereunder is subject to the provIsions of Chapter 112. Florida State Statutes. Respondents must disclose with their Proposals. the name of any officer. director, partner. associate or agent who is also an officer or employee of the City of South Miami or its agencies. SWORN STATEMENT PURSUANT TO SECTION 287.133 (3) (a). FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. I. This sworn statement is submitted to City of South Miami [print name of the public entity] by Jose M. Alvarez. President [print individual's name and title] for N A Engineering Contractor, Inc . [print name of entity submitting sworn statement] business address is and (if applicable) its Federal Employer Identification Number (FEIN) is 48-1277685 (If the entity has no FEIN, include the Social Security Number ofthe individual signing this sworn statement: .) 2 . I understand that a "publiC entity crime" as defined in Paragraph 287.133 (I )(g). Florida Statutes. means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to • any bid, proposal or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitruSt. fraud. theft. bribery. collusion. racketeering. conspiracy. or material misrepresentation. 3 . I understand that "convicted" or "conviction" as defined in Paragraph 287.133 (I) (b), Florida Statutes. means a finding of guilt or a conviction of a public entity crime, with or without an adjudication of guilt. in any federal or state trial court of record relating to charges brought by indictment or information after July I. 1989. as a result of a jury verdict, non-jury trial. or entry of a plea of guilty or nolo contendere. 4 . I understand that an "affiliate" as defined in Paragraph 287.133 (I) (a), Florida Statutes. means: (a) A predecessor or successor of a person convicted of a public entity crime; or (b) An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers. © Thomas F. Pepe. 2014 4/28/2 014 Page 26 of 72 directors, execut.ives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in any person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. 5. I understand that a "person" as defined in Paragraph 287.133 (I) (e), Florida Statutes. means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or proposal or applies to bid or proposal on contracts for the provision of goods or services let by a public entity. or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers. directors, executives, partners, shareholders, employees, members. and agents who are active in management of an entity. 6. Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this swom statement. [Indicate which statement applies.} ~ Neither the entity submitting this swom statement, nor any of its officers. directors. executives, partners. shareholders. employees, members. or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July I, 1989. ___ The entity submitting this sworn statement, or one or more of its officers, directors. executives. partners. shareholders. employees, members, or agents who are active in the management of the entity. or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1,1989. ___ The entity submitting this swam statement, or one or more of its officers. directors, executives. partners, shareholders. employees. members. or agents who are active in the management of the entity. or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent of July I. 1989. However. there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final O r~ntey!d\ by the Hearing Officer determined that it was not in the public interest to place th1.en ty su8!;njfting \this swom statement on the convicted vendor list. [attach a copy of the final order.] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CON CTlNGjfFlCER liaR THE PUBLIC ENTITY INDENTIFIED IN PARAGRAPH I (ONE) ABOVE IS FOR THAT PUBLIC ENTI ONLY AND T~AT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS XLED . I 'LSO UI1JDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING I TO A ONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017. FLORIDA STA UTES. OR cATEGORY TWO OF ANY CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. .. Sworn to and subscribed before me this 13th day of ! J'1"" -if " !,. c Personally known ___ .LX"'-_______ _ OR Produced identification ________ _ (Type of identification) Form PUR 7068 (Rev.D6/1 1/92) tj Thomas F. Pepe,2014 4i2X/2014 My commission expires V ..)/ lLI..,V .1.<) (Printed. typed or stamped commissioned ~,\\,\\\\\\I~l/'~ai"l/~am e of notary public) :o..~'" ••••••• 190>~ ,;:::'_y.", ••• 1'5 a •• {y ~ ~ W .·c\l?-~'. ~~ ~ ~ .~~ 't:. O~ ~~:~_~'Yl ~"\,.\l~ -~ .~~~ ~ '2. ...... ...-;_ ::;:) 0 0 "~ f lri"'o ,",-- ::(!) :Ci:i ~ • H?:~= -.(/) -. -==.".~{', 6u. ""'''::; -"'-"' • ..,.,... ...... L1--:::;:_ ~ . .&-··~O ~ ~ _.s~ S:I ~ ~~.' ~ ..-.",...., ~V'h "'. ,(IV ••• ~~ ~,."' .••• '0..'';::: ~"Y ••••••• 'K~, .. 'X-,", :1'//1 ~ ~ ~\~ 11("1111 ""11\\\\ Page 27 of 72 DRUG FREE WORKPLACE Whenever two or more Bids or Proposals which are equal with respect to price. quality and service are received by the State or by any political subdivisions for the procurement of commodities or contractual services. a Bid or proposal received from a business that certifies that it has implemented a drug-free workplace program shall be given preference in the award process. Established procedures for processing tie Bids or proposals shall be followed if none of the tied vendors have a drug-free workplace program. In order to have a drug-free workplace program, a business shall: I) Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession. or use of a controlled substance is prohibited in the workplace and specifying the actions that shaH be taken aga inst employees for violations of such prohibition . 2) Inform employees about the dangers of drug abuse in the workplace. the business' policy of maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee assistance programs. and the penalties that may be imposed upon employees for drug abuse violations. 3) Give each employee engaged in providing the commodities or contractual services that are under Bid a copy of the statement specified in Subsection (I). 4) In the statement specified in Subsection (I). notify the employees. that, as a condition of working of the commod ities or contractual services that are under Bid, he employee shall abide by the terms of the Statement and shall no ti fy the employee of any conviction of, or plea of guilty or nolo contendere to, any violation ~apter 893 or of any controlled substance law of the United States or any state, for a . la . n o c urring in the workplace no later than five (5) business days after such conviction. 5) Impose a sanction 0 or req ire the s atisfactory parLicipation in a drug abuse assistance or rehabilitation prog m, if s u is ava i ble in the employee's community, by any employee who is so convicted. J j 6) Make a good faith O rt to ntinu to maintain a drug-free workplace through implementation of this section. \ As the person authorized to sign the s\ate nfo n\'fcertlfy that this firm complies fully with the above requirements. RESPONDENTs Signature: ---.....,,7,L./~\r>7,(L-......,---------- Print Name: Date: 06113/2014 © Thomas F. Pepe.2014 4128i2014 Page 28 of 72 ACKNOWLEDGEMENT OF CONFORMANCE WITH OSHA STANDARDS TO THE CITY OF SOUTH MIAMI We, N A Engineering Contractor, Inc. (Name of CONTRACTOR), hereby acknowledge and agree that as CONTRACTORs for the project as specified have the sole responsibility for compliance with all the requirements of the Federal Occupational Safety and Health Act. of 1970, and all State and local safety and health regulations, and agree toX e mnify and hold harmless the City of South Miami and against any and all liability, claims, damages-Liosses,and ewenses they may incur due to the failure of (Sub-Contract.or's names): President Title ~'Thomas F. Pepe, 2014 4128/2014 Page 29 of 72 LIST OF PROPOSED SUBCONTRACTORS AND PRINCIPAL SUPPLIERS LandsCl~ Soddmg and T uri Work Elecmal Irrigation PaYing Park Amenities Graphics Utilities Excavation Building Structures Plumbing ~inting Testing Laboratory Soil FumIgator Signs Other: This list shall be provided to the City within five (5) business days after Bid Opening. ~ Thomas F. Pepe. 2014 4128/2014 Page 30 of 72 RELATED PARTY TRANSACTION VERIFICATION FORM Jose M.Alvarez . individually and on behalf of N A Engineering Contractor, Inc. ("Firm")have Name of Representative Company/Vendor/Entity read the City of South Miami ("City'')'s Code of Ethics, Section 8A-1 of the City's Code of Ordinances and I hereby certify. under penalty of perjury that to the best of my knowledge, information and belief (I) neither I nor the Firm have any conflict of interest (as defined in section SA-I) with regard to the contract or business that I, and/or the Firm, am(are) about to perform for, or to transact with, the City, and (2) neither I nor any employees, officers, directors of the Firm, nor anyone who has a financial interest greater than 5% in the Firm. has any relative(s). as defined in section SA-I. who is an employee of the City or who is(are) an appointed or elected official of the City. or who is(are) a member of any public body created by the City Commission, i.e.. a board or committee of the City[See Note #1 below], and (3) neither I nor the Firm. nor anyone who has a financial interest greater than 5% in the Firm, nor any member of those persons' immediate family (I.e .. spouse, parents. children. brothers and sisters) has transacted or entered into any contract(s) with the City or has a financial interest, direct or indirect, in any business being transacted with the city. or with any person or agency acting for the city. other than as follows: _______________________________ Of necessary use a separate sheet to supply additional information that will not fit on this line but make reference on the line above to the separate sheet. Le., "see attached additional information" and make reference to this document and this paragraph on the additional sheet which additional sheet must be signed under oath). [See Note #1 below]; and (4) no elected and/or appointed official or employee of the City of South Miami, or any of their immediate family members (I.e .• spouse. parents. children, brothers and sisters) has a financial interest, directly or indirectly. in the contract between you and/or your Firm and the City other than the following individuals whose interest is set forth following their use a separate names: _________ -,-_______________________ (if necessary use a separate sheet to supply additional information that will not fit on this line but make reference on the line above to the separate sheet, i.e .• "see attached additional information" and make reference to this document and this paragraph on the additional sheet which additional sheet must be signed under oath). The names of all City employees and that of all elected and/or appointed city officials or board members. who own. directly or indirectly, an interest of five percent (5%) or more of the total assets of capital stock in the firm are as follows: _____ _ ______________________________________ (if necessary use a separate sheet to supply additional information that will not fit on this line but make reference on the line above to the separate sheet, i.e., "see attached additional information" and make reference to this document and this paragraph on the additional sheet which additional sheet must be signed under oath). [See Note #1 below] (5) I and the Firm further agree not to use or attempt to use any knowledge. property or resource which may come to us through our position of trust, or through our performance of our duties under the terms of the contract with the City, to secure a special privilege. benefit. or exemption for ourselves. or others. We agree that we may not disclose or use information. not available to members of the general public, for our personal gain or benefit or for the personal gain or benefit of any other person or business entity. outside of the normal gain or benefrt anticipated through the performance of the contract. C Thomas F. Pepe. 2014 412812014 Page 31 of 72 (6) I and the Firm hereby acknowledge that we have not contracted or transacted any business with the City or any person or agency acting for the City, and that we have not appeared in representation of any third party before any board, commission or agency of the City within the past two yean; other than as follows: (if necessary use a separate sheet to supply additional information that will not fit on this line but make reference on the line above to the separate sheet, i.e ., "see attached additional information" and make reference to this document and this paragraph on the additional sheet which additional sheet must be signed under oath). (7) Neither I nor any employees, officers, or directors of the Firm, nor any of their immediate family (i.e., as a spouse, son. daughter, parent, brother or sister) is related by blood or marriage to: (i) any member of the City Commission; (ii) any city employee; or (iii) any member of any board or agency of the City other than as follows: ____________________ -:-__ (if necessary use a separate sheet to supply additional information that will not fit on this line but make reference on the line above to the separate sheet, Le., "see attached additional information" and make reference to this document and this paragraph on the additional sheet which additional sheet must be signed under oath). [See Note #1 beloW]; and . (8) No Other Firm, nor any officers or directon; of that Other Firm or anyone who has a financial interest greater than 5% in that Other Firm, nor any member of those persons' immediate family (i.e., spouse, parents, children, brothers and sisters) nor any of my immediate family memben; (hereinafter referred to as "Related Parties') has responded to a solicitation by the City in which I or the Firm that I represent or anyone who has a financial interest greater than 5% in the Firm. or any member of those persons' immediate family (Le. spouse. parents, children, broth en; and sisters) have also responded, other than the following: __ -------------------__ (if necessary use a separate sheet to supply additional information that will not fit on this line but make reference on the line above to the separate sheet, Le .• "see attached additional information" and make reference to this document and this paragraph on the additional sheet which additional sheet must be signed under oath). [while the eth ics code still applies, if the person executing this form is doing so on behalf of a firm whose stock is publicly traded, the statement in this section (8) shall be based solely on the signatory's pen;onal knowledge and he/she is not reqUired to make an independent investigation into the Other Firm, or the Firm he/she represents, as to their officers, directors or anyone having a financial interest in those Firms or any of their any member of those persons' immediate family.] (9) I and the Firm agree that we are obligated to supplement this Verification Form and inform the City of any change in circumstances that would change our answen; to this document. Specifically, after the opening of any responses to a soli citatio n I and e r;ir m have an obligation to supplement this Verification Form with the name of all Related Parties w~. ave I responded to the same solicitation and to disclose the relationship of those parties to me and Firm. I (10) A violation of h e City'sttl ics C ?de . the giving of any false information or the failure to supplement this Verification Form, ay sub je t e or/t he Firm to immediate termination of any agreement with the City. and the imposition of the ~axi m u m~ an d/" r any penalties allowed by law. Additionally. violations may be considered by and subject to actior by the iam i-I ade County Commission on Ethics. Under penalty of perjury, I declare that I have made a dlll gen\ effort 'nv tigate the matten; to which I am attesting hereinabove and that the statements made hereinabove a ke trU a n ·o rrect to the best of my knowledge. information and belief. Signature: £, r , 7 '\. 7 1 lvarez. Pres id ent Date: 06,-,1 lw3"-"/2 ...... Qu..1 ::r.4 ____ _ tlj Thomas F. Pepe. 2014 4/2812014 Page 32 of 72 Note # I: While the ethics code still applies, if the person executing this fann is doing 50 on behalf of a finn with more than I 5 employees, the statement: in this 5eCtion shall be based solely on the signatory's personal knowledge and helshe Is not required to make an independent investiption as to the relationship of employees; if the finn is a publicly traded company. the statement in this section shall be based solely on the signatory's personal knowledge and heJshe is not required to make an Independent investigation as to the relationship of employees or of those who have a financial interest in the Rrm or of the financial interest In the Firm 0( city employees, appointed officials or the immediate family members of elected andlor appointed official or employee or as to the relationship by blood or maniage 0( employees, officers, or directors of the Firm, or 0( any of their immediate family to any appointed or elected officials of the City. or to their immediate family members. Sec. SA-( -Conflict of interest and code of ethics ordinance. Municode Page IOf4 Sec. SA-I. -Conflict of interest and code of ethics ordinance. (a) Designation. This section shall be designated and known as the "City of South Miami Conflict of Interest and Code of Ethics Ordinance." This section shall be applicable to all city personnel as defined below, and shall also constitute a standard of ethical conduct and behavior for all autonomous personnel, quasi-judicial personnel, advisory personnel and departmental personneL The provisions of this section shall be applied in a cumulative manner. By way of example, and not as a limitation, subsections (c) and (d) may be applied to the same contract or transaction. (b) Definitions. For the purposes of this section the following definitions shall be effective: (I) The term "commission members" shall refer to the mayor and the members of the city commission. (2) The term "autonomous personnel" shall refer to the members of autonomous authorities, boards and agencies, such as the city community redevelopment agency and the health facilities authority. (3) The term "quasi-judicial personnel" shall refer to the members of the planning board, ,he environmental review and preservation board, the code enforcement board and such other individuals. boards and agencies of the city as perform quasi-judicial functions . (4) The term "advisory personnel" shall refer to the members of those city advisory boards and agencies whose sole or primary responsibility is to recommend legislation or give advice to the City commission . (5) The term "departmental personnel~ shall refer to the city clerk, the city manager. department heads, the city attorney. and all assistants to the city clerk. city manager and city attorney, however tided. (6) The term "employees· shall refer to all other personnel employed by the city. (7) The term "compensation" shall refer to any money, gift. favor , thing of value or financial benefit conferred. or to be conferred, in return for services rendered or to be rendered. (8) The term "controlling financial interes," shall refer to ownership, directly or indirectly. of ten percent or more of the outstanding capital stock in any corporation or a direct or indirect interest of ten percent or more in a firm, partnership, or other business entity at the time of transacting business with the City. (9) The term "immediate family· shall refer to the spouse. parents, children, brothers and sisters of the person involved. (10) The term "transact any business" shall refer to the purchase or sale by the city of specific goods or services for consideration and to submitting a bid, a proposal in response to a RFP, a statement of qualifications in response to a request by the city, or entering into contract negotiations for the provision on any goods or services, whichever first occurs. (c) Prohibition on transacting business with the city. No person included in the terms defined in paragraphs (b)( I) through (6) and in paragraph (b)(9) shall enter into any contract or transact any business in which that person or a member of the immediate family has a financial interest, direct or indirect with the city or any person or agency acting for the city, and any such contract, agreement or business engagement entered in violation of this subsection shall render the transaction voidable . Willful violation of this subsection shall constitute malfeasance in office and shall affect forfeiture of office or position. Nothing in this subsection shall prohibit or make illegal: (I) The payment of taXes, special assessments or fees for services provided by the city government; Ii) Thomas F Pepe.2014 4/28 /2014 Page 33 of 72 (2) The purchase of bonds, anticipation notes or other securities that may be issued by the city through underwriters or directly from time to time. Waiver of prohibition. The requirements of this subsection may be waived for a particular transaction only by four affirmative votes of the city commission after public hearing upon finding that: (I) An open-to-all sealed competitive proposal has been submitted by a city person as defined in paragraphs (b)(2), (3) and (4); (2) The proposal has been submitted by a person or firm offering services within the scope of the practice of architecture, professional engineering, or registered land surveying, as defined by the laws of the state and pursuant to the provisions of the Consultants' Competitive Negotiation Act., and when the proposal has been submitted by a city person defined in paragraphs (b)(2), (3) and (4); (3) The property or services to be involved in the proposed transaction are unique and the city cannot avail itself of such property or services without entering a transaction which would violate this subsection but for waiver of its requirements; and (4) That the proposed transaction will be in the best interest of the city. This subsection shall be applicable only to prospective transactions, and the city commission may in no case ratify a transaction entered in violation of this subsection. Provisions cumulative. This subsection shall be taken to be cumulative and shall not be construed to amend or repeal any other law pertaining to the same subject matter. (d) Further prohibition on transacting business with the city. No person included in the terms defined in paragraphs (b)(I) through (6) and in paragraph (b)(9) shall enter into any contract or transact any business through a firm, corporation, partnership or business entity in which that person or any member of the immediate family has a controlling financial interest, direct or indirect., with the city or any person or agency acting for the city, and any such contract., agreement or business engagement entered in violation of this subsection shall render the transaction voidable. The remaining provisions of subsection (c) will also be applicable to this subsection as though incorporated by recitation. Additionally, no person included in the term defined in paragraph (b)( I) shall vote on or participate in any way in any matter presented to the city commission if that person has any of the follOWing relationships with any of the persons or entities which would be or might be directly or indirectly affected by any action of the city commission: (I) Officer, director, partner, of counsel, consultant, employee, fiduciary or beneficiary; or (2) Stockholder, bondholder, debtor, or creditor, if in any instance the transaction or matter would affect the person defined in paragraph (b)(l) in a manner distinct from the manner in which it would affect the public generally. Any person included in the term defined in paragraph (b)( I) who has any of the specified relationships or who would or might, directly or indirectly, realize a profit by the action of the city commission shall not vote on or participate in any way in the matter. (E) Gifts. (J )Definition. The term "gift" shall refer to the transfer of anything of economic value, whether in the form of money, service, loan, travel, entertainment, hospitality, item or promise, or in any other form, without adequate and lawful consideration. (l)Exceptions. The provisions of paragraph (e)( I) shall not apply to: a. Political contributions specifically authorized by state law; b. Gifts from relatives or members of one's household. unless the person is a conduit on behalf of a third party to the delivery of a gift that is prohibited under paragraph(3); c. Awards for profeSSional or civic achievement; d. Material such as books, reports, periodicals or pamphlets which are solely informational or of an advertising nature. (3) Prohibitions. A person described in paragraphs (b)(l) through (6) shall neither solicit nor demand any gift. It is also unlawful for any person or entity to offer, give or agree to give to any person included in the terms defined in paragraphs (b)( I) through (6), or for any person included in the terms defined in paragraphs (b)( I) through (6) to accept or agree to accept from another person or entity, any gift for or because of: a. An official public action taken, or to be taken, or which could be taken, or an omission or failure to take a public action; b. A legal duty performed or to be performed, or which could be performed, or an omission or failure to perform a legal duty; ~ Thomas F. Pepe. 2014 4/2812014 Page 34 of 72 c. A legal duty violated or to be violated, or which could be violated by any person included in the term defined in paragraph (b)(I); or d. Attendance or absence from a public meeting at which official action is to be taken. (4) Disdosure. Any person included in the term defined in paragraphs (b)( I) through (6) shall disclose any girr. Qr series of gifts from anyone person or entity, having a value in excess of $25.00. The disclosure shall be made by filing a copy of the disclosure form required by chapter I 12, Florida Statutes, for -local officers" with the city clerk simultaneously with the filing of the form with the clerk of the county and with the Florida Secretary of State. (f) Compulsory disclosure by employees of firms doing business with the city. Should any person included in the terms defined in paragraphs (b)( I) through (6) be employed by a corporation, firm. partnership or business entity in which that person or the immediate family does not have a controlling financial interest, and should the corporation. firm, partnership or business entity have substantial business commitments to or from the city or any city agency, or be subject to direct regulation by the city or a city agency, then the person shall file a sworn statement disclosing such employment and interest with the clerk of the city. (g) Exploitation of official position prohibited. No person included in the terms defined in paragraphs (b )( I) through (6) shall corruptly use or attempt to use an official pOSition to secure special privileges or exemptions for that person or others. (h) Prohibition on use of confidential information. No person included in the terms defined in paragraphs (b)( I) through (6) shall accept employment or engage in any business or professional activity which one might reasonably expect would require or induce one to disclose confidential information acquired by reason of an official pOSition, nor shall that person in fact ever disclose confidential information garnered or gained through an official positi<:ln with the city, nor shall that person ever use such information. directly or indirectly, for personal gain or benefit. (i) Conflicting employment prohibited. No person included in the terms defined in paragraphs (b)( I) through (6) shall accept other employment which would impair independence of judgment in the performance of any public duties. (j) Prohibition on outside employment. (I) No person included in the terms defined in paragraphs (b)(6) shall receive any compensation for services as an officer or employee of the city from any source other than the city, except as may be permitted as follows: a. Generally prohibited. No full-time city employee shall accept outside employment, either incidental, occasional or otherwise, where city time, equipment or material is to be used or where such employment or any part thereof is to be performed on city time. b. When permitted. A full-time city employee may accept incidental or occasional outside employment so long as such employment is not contrary, detrimental or adverse to the interest of the city or any of its departments and the approval required in subparagraph c. is obtained . c. Approval of department head required. Any outside employment by any full-time city employee must first be approved in writing by the employee's department head who shall maintain a complete record of such employment. d. Penalty. Any person convicted of Violating any provision of this subsection shall be punished as provided in section I-I I of the Code of Miami-Dade County and, in addition shall be subject to dismissal by the appointing authority. The city may also assess against a violator a fine not to exceed $500.00 and the costs of investigation incurred by the city. (2) All full-time city employees engaged in any outside employment for any person, firm, corporation or entity other than the city, or any of its agencies or instrumentaJities, shall file, under oath. an annual report indicating the source of the outside employment. the nature of the work being done and any amount of money or other consideration received by the employee from the outside employment.. City employee reports shall be filed with the city clerk. The reports shall be available at a reasonable time and place for inspection by the public. The city manager may require monthly reports from individual employees or groups of employees for good cause. (k) Prohibited investments. No person included in the terms defined in paragraphs (b)( I) through (6) or a member of the immediate family shall have personal investments in any enterprise which will create a substantial conflict between private interests and the public interest. (;) Thomas F. Pepe. 2014 4/2812014 Page 35 of 72 (I) Certain appearances and payment prohibited. (I) No person included in the terms defined in paragraphs (b)( I). (5) and (6) shall appear before any city board or agency and make a presentation on behalf of a third person with respect to any matter, license, contract, certificate, ruling. decision, opinion, rate schedule, franchise, or other benefit sought by the third person. Nor shall the person receive any compensation or gift. directly or indirectly, for services rendered to a third person, who has applied for or is seeking some benefit from the city or a city agency, in connection with the particular benefit sought by the third person. Nor shall the person appear in any court or before any administrative tribunal as counselor legal advisor to a party who seeks legal relief from the dty or a city agency through the suit in question. (2) No person included in the terms defined in paragraphs (b)(2). (3) and (4) shall appear before the city commission or agency on which the person serves, either directly or through an associate, and make a presentation on behalf of a third person with respect to any matter, license, contract, certificate. ruling, decision. opinion, rate schedule, franchise. or other benefit sought by the third person. Nor shall such person receive any compensation or gift, directly or indirectly, for services rendered to a third party who has applied for or is seeking some benefit from the city commission or agency on which the person serves in connection with the particular benefit sought by the third party. Nor shall the person appear in any COUrt or before any administrative tribunal as counselor legal advisor to a third party who seeks legal relief from the city commission or agency on which such person serves through the suit in question. (m) Actions prohibited when financial interests involved. No person included in the terms defined in paragraphs (b) (I) through (6) shall participate in any official action directly or indirectly affecting a business in which that person or any member of the immediate family has a financial interest. A financial interest is defined in this subsection to include, but not be limited to. any direct or indirect interest in any investment, eqUity. or debt. (n) Acquiring financial interests. No person included in the terms defined in paragraphs (b)(l) through (6) shall acquire a financial interest in a project, business entity or property at a time when the person believes or has reason to believe that the financial im:erest may be directly affected by official actions or by official actions by the city or city agency of which the person is an official, officer or employee. (0) Recommending professional services. No person included in the terms defined in paragraphs (b)( I) through (4) may recommend the services of any lawyer or law firm. architect or architectural firm , public relations firm. or any other person or firm, profesSional or otherwise, to assist in any transaction involving the city or any of its agencies, provided that a recommendation may properly be made when reqUired to be made by the duties of office and in advance at a public meeting attended by other city officials, officers or employees . (p) Continuing application after city service. (I) No person included in the terms defined in paragraphs (b)( I). (5) and (6) shall, for a period of two years after his or her city service or employment has ceased. lobby any city official [as defined in paragraphs (b)( I) through (6)] in connection with any judicial or other proceeding, application, RFP, RFQ, bid, request for ruling or other determination, contract, claim, controversy, charge. accusation. arrest or other particular subject matter in which the city or one of its agencies is a party or has any interest whatever, whether direct or indirect. Nothing contained in this subsection shall prohibit any individual from submitting a routine administrative request or application to a city department or agency during the two-year period after his or her service has ceased. (2) The provisions of the subsection shall not apply to persons who become employed by governmental entities. 50 I (c)(3) non·profit entities or educational institutions or entities. and who lobby on behalf of those entities in their official capacities. (3) The provisions of this subsection shall apply to all persons described in paragraph (p)( I) whose city service or employment ceased after the effective date of the ordinance from which this section derives. (4) No person described in paragraph (p)( I) whose city service or employment ceased within two years prior to the effective date of this ordinance shall for a period of two years after his or her service or employment enter into a lobbying contract to lobby any city official in connection with any subject described in paragraph (p)( I) in which the city or one of its agencies is a party or has any direct and substantial interest; and in which he or she participated directly or indirectly through decision. approval, disapproval, recommendation, the rendering of advice. investigation, or otherwise, during his or her city service or employment. A person participated "directly" where he or she was substantially involved in the particular subject matter through decision, approval, disapproval, © Thomas F. Pepe. 2014 4/28 /2014 Page 36 of 72 recommendation, the rendering of advice, investigation, or otherwise, during his or her city service or employment. A pe~on participated "indirectly· where he or she knowingly participated in any way in the particular subject matter through decision, approval, disapproval, recommendation, the rendering of advice, investigation, or otherwise, during his or her city service or employment. All persons covered by this paragraph shall execute an affidavit on a form approved by the city attorney prior to lobbying any city official attesting that the requirements of this subsection do not preclude the pe~on from lobbying city officials. (5) Any person who violates this subsection shall be subject to the penalties provided in section BA-2(p). (q) City attorney to render opinions on request. Whenever any person included in the terms defined in paragraphs (b)(l) through (6) and paragraph (b)(9) is in doubt as to the proper interpretation or application of this conflict of interest and code of ethics ordinance, or whenever any person who renders services to the city is in doubt as to the applicability of the ordinance that person. may submit to the city attorney a full written statement of the facts and questions. The city attorney shall then render an opinion to such person and shall publish these opinions without use of the name of the person advised unless the person permits the use of a name. (Ord. No. 6-99-/680, § 2. 3-2-99) Editor's note-Ord. No. 6-99-1680, § I. adopted 3-2-99, repealed §§ BA-I and BA-2 in their entirety and replaced them with new §§ BA-I and BA-2. Former §§ 8A-1 and BA-2 pertained to declaration of policy and definitions, respectively. and derived from Ord. No. 634. §§ I (IA-J), J (JA-2) adopted Jan ... 11. 1969. lid Thomas F. Pepe. 2014 4/28/2014 Page 37 of7l NOTICE OF AWARD The City has considered the Proposal submitted by your firm for the Sunset Drive Downtown Median in response to its advertisement for Request for Proposal and Instructions to Respondents. You are hereby notified that your Proposal has been accepted for the Sunset Drive Downtown Median in the lump sum amount of $ . broken down as follows : Base Proposal: Alternate #1: Alternate #2: Alternate #3: You are required by the Instructions to Respondents to execute the Contract and furnish the required Performance Bond. Payment Bond. Insurance documents (see Proposal Submittal Checklist Form) within ten (10) day from the date of this Notice to you. If you fail to execute said Contract and to furnish said bonds or required Insurance documents within ten (10) calendar days from the date of this notice. the CITY . at its sole and absolute discretion. shall be entitled to disqualify the Proposal, revoke the award and retain the Proposal Bond/Security. Please be advised that if the contract price exceeds $5.000.00 or if it is a multi-year contract requiring payment out of more than one year's appropriation, the award and the contract must be approved by the City Commission before it is binding on the City. BY: Steven Alexander City Manager Dated this __ day of . 20 __ ACCEPTANCE OF NOTICE Receipt of the above Notice of Award is hereby acknowledged by ________________ _ On this the day of . 20 __ . BY : TITLE: You are required to return an acknowledged copy ofthis Notice of Award to the City Manager . ([) Thomas F. Pcpe, 2014 4 /28/2014 Page 38 of 72 CONTRACT Sunset Drive Downtown Median From SW 57th Court to SW 58th Avenue THIS CONTRACT was made and entered into on this day of . 20 __ , by and between hereafter referred to as "Contractor", and the City of South Miami, hereafter referred to as "Owner", through its City Manager, hereafter referred to as "Oty". WITNESETH: That, the Contractor, for the consideration hereinafter fully set out, hereby agrees with the Owner as follows: I. The Contractor shall furnish all labor, materials. equipment, machinery, tools, apparatus, transportation and any other items necessary to perform all of the work shown on and described in the Contract Documents and shall do everything required by this Contract and the other Contract Documents hereinafter referred to as the Work. 2. The Contract Documents shall include this Contract, the General Conditions to the Contract, if any. the drawings, plans. specifications and project manual, if any. any supplementary or special conditions. other documents referring to this contract and signed by the parties, the solicitation documents ("hereinafter referred to as "Bid Documents") and any documents to which those documents refer and which are used by the Owner as well as any attachments or exhibits that are made a part of any of the documents described herein. 3. The Contractor shall commence the Work to be performed under this Contract on a date to be specified in a Notice to Proceed and shall complete all Work hereunder within the length of time set forth in the Contract Documents. 4. The Owner hereby agrees to pay to the Contractor for the faithful performance of this Contract, subject to additions and deductions as provided in the Contract Documents and any properly approved, written change orders. in lawful money of the United States. the amount of: {5p<!iI Dolw-Amoont tlere) Dollars ($ .OO~, Lump Sum ("Contract Price 'J. s. The expenses of performing Work after regular working hours, and on Sunday and legal holidays shall be included in the Contract Price. However. nothing contained herein shall authorize work on days and during hours that are otherwise prohibited by ordinance unless specifically authorized or instructed in writing by the City. 6. If the Work is expected to require more than one month, the Owner shall make monthly partial payments to the Contractor on the basis of a duly certified and approved schedule of values for the Work performed during each calendar month by the Contractor. less the retainage (all as provided for in the Contract Documents). which is to be withheld by the Owner until completion and acceptance of the complete project in accordance with this Contract and the other Contract Documents and until such Work has been accepted by the City. 7. Upon submission by the Contractor of evidence satisfactory to the City that all labor, material, and other costs incurred by the Contractor in connection with the construction of the Work have been paid in full. and after compliance with the terms for payment prOVided for in the Contract Documents. final payment on account of this Contract shall be made within sixty (60) calendar days after the completion by the Contractor of all Work covered by this Contract and the acceptance of such Work by the City. 8. 8. In the event that the Contractor shall fail to complete the Work within the time limit stipulated in the Contract Documents, or the extended time limit agreed upon, in accordance with the procedure as more particularly set forth in the Contract Documents. liquidated damages shall be paid by the Contractor at the rate of 52,000 dollars per day, plus any monies paid by the Owner to the Consultant, if any, for additional engineering and inspection services. if any, associated with such delay. 9. It is further mutually agreed between the parties hereto that if a Payment and/or Performance Bond ("Bond") is required and if. at any time after the execution of this Contract and the Bond for its faithful performance and payment, the City shall deem the Surety or Sureties upon such bond(s) to be unsatisfactory, or if. for any reason such bond ceases to be adequate to cover the performance of the ~ Thomas F. Pepe, 2014 4/28/2014 Page 39 of 72 Work or payment to subcontractors and suppliers, the Contractor shall, at its expense within five (5) business days after the receipt of notice from the C~ so to do, furnish an additional bond or bonds in such form and amount and with such Surety or Sureties as shall be satisfactory to the City. In such event, no further payment to the Contractor shall be deemed to be due under this Contract until such new or additional security for the faithful performance of the Work is furnished in the manner and in the form satisfactory to the City. 10. No additional Work or extras shall be done unless the same is duly authorized in writing and in advance of the work by appropriate action by the City and in accordance with the Contract Documents. II. The date that this contract was "made and entered into" and its effective date is the date that the contract is the signed by the City. IN WITNESS WHEREOF, the parties hereto have executed this Contract on or prior to the day and date first above written, in five (5) counterparts, each of which shall, without proof or accounting for the other counterpart be deemed an original Contract.. WITNESSES: (print name of Witness) (print name of Witness) AUTHENTICATION: Signature: _-:-_-,-,-_______ __ Maria Menendez City Clerk Read and Approved as to Form. Language. Legality and Execution thereof: Signature: City Attorney © Thomas F. Pepe. 2014 4/28/2014 CONTRACTOR: __________________ __ Signature: _____________ _ Name: _______________ _ Tru~ ___________ _ OWNER: CITY OF SOUTH MIAMI Signalur~__:--__:___:_----------- Steven Alexander City Manager Page 40 of 72 GENERAL CONDITIONS Sunset Drive Downtown Median ARTICLE I -DEFINrTlONS Whenever used in these General Conditions or in the other Contract Documents, the following terms shall have the meaning indicated. These definitions shall always apply when the section of the Contract specifically refers to this Article for the purpose of interpreting a word or group of words in that section of the Contract Document. However, when the section of the Contract, where the word to be defined is used, does not specifically refers to this Article to define the word or group of words. the definitions contained in this Article shall not apply unless the word or group of words, in the context of it or their uSe in the Contract Document in question. is/are ambiguous and open for interpretation . In addition, these definitions shall also not apply to interpret terms in a specific provision of a Contract Document if that specific provision contains a definition of these terms: Addenda; Written or graphic documents issued prior to the Bid Opening which modify or interpret the Contract Documents, Drawings and Specifications. by addition, deletions. clarifications or correction. Application for Payment A form approved by the CONSULTANT, if any, or the Oty Manager which is to be used by the CONTRACTOR in requesting progress payments . .!llit The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices and other terms for the Work to be performed. Bidder: Any person. firm or corporation submitting a response to the Owner's solicitation for proposals or bids for Work. Bid Documents: The solicitation for bids or proposals and all documents that make up the solicitation including the instructions, form of documents and affidavits . Bonds: Bid bond, performance and payment bonds and other instruments of security, furnished by the CONTRACTOR and its surety in accordance with the Contract Documents and in accordance with the laws of the State of Florida. Change Order: A written order to the CONTRACTOR signed by the City Manager authorizing an addition, deletion or revision in the Work. or an adjustment in the Contract Price or the Contract Time issued after execution of the Contract. CITY : The City Manager for the City of South Miami, 6130 Sunset Drive, South Miami. Fl 33143, unless the context wherein the word is used should more appropriately mean the City of South Miami. Construction Observer; An authorized representative of the CONSULTANT, if any, or otherwise a representative of the City assigned to observe the Work performed and materials furnished by the CONTRACTOR. The CONTRACTOR shall be notified in Writing of the identity of this representative. Contract Documents: The Contract Documents shall include the Contract between the Owner and the Contractor, other documents listed in the Contract and modifications issued after execution of the Contract as well as all Bid Documents including but not limited to the solicitation for Bid, CONTRACTOR'S Bid, the Bonds, Insurance endorsements, Insurance Certificates and poliCies, the Notice of Award, the Notice to Proceed, the General Conditions, Special Conditions, if any, any Supplementary Conditions, the Technical Specifications. Drawings. including any incorporated specifications, addenda to the drawings issued prior to execution of the Contract, Change Orders, Construction Change Directives and any written order for a minor change in the Work, and written modifications to any of the Contract Documents. Contract Price: The total moneys payable to the CONTRACTOR pursuant to the terms of the Contract Documents. Contract Time: The number of calendar days stated in the Contract for the completion of the Work. Contracting Officer: The individual who is authorized to sign the contract documents on behalf of the OWNER. CONTRACTOR: The person, firm or corporation with whom the OWNER has executed the Contract. CONSULTANT: The person identified as the CONSULTANT in the Supplementary Conditions or, if none, then CITY's designated representative as identified in the Supplementary Conditions. Day: A period of twenty-four hours measured from the beginning of the day at 12:0 I a.m. and it shall be presumed to be a calendar day unless specifically designated as a business day. © Thomas F. Pepe. 2014 4/2812014 Page 41 of 72 Qm: The number of twenty-four (24) hour periods following the event to which the word "days" refers commencing at I 2:0 I am. at the start of the next day. Therefore. in computing any period of time prescribed or allowed by the Contract Documents. the day of the act, event or default from which the designated period of time begins to run shall not be included. The last day of the period so computed shall be included unless it is a Saturday. Sunday or IegaJ holiday. in which event the period shall run until the end of the next business day that is not a Saturday. Sunday or legal holiday. Defective Work: Work that is unsatisfactory. faulty. or deficient in that it does not conform to the Contract Documents, or does not meet the requirements of any applicable inspection. reference standard, test, or approval referred to in the Contract Documents. or has been damaged prior to the CONSULTANTS recommendation of final payment (unless responSibility for the protection thereof has been delegated to the Owner); substitutions that are not properly approved and authorized. any deficiency in the Work. materials and equipment; materials and equipment furnished under the Contract that are not good quality and new unless otherwise required or permitted by the Contract Documents. Prawin~: The drawings which show the character and scope of the Work to be performed and which have been prepared or approved by the CONSULT ANT, or if none. then by an architect or engineer hired by the City and are referred to in the Contract Documents. Reid Order: A written order issued by the CONSULTANT which clarifies or interprets the Contract Documents in accordance with Paragraph 9.3 or orders minor changes in the Work in accordance with paragraph 10.2. Modification: (a) A written amendment of the Contract Documents signed by both parties. (b) a Change Order signed by both parties. (c ) a written clarification or interpretation if issued by the CONSULTANT in accordance with paragraph 9.3 or (d) a written order for minor change or alteration in the Work issued by the CONSULTANT pursuant to Paragraph 10.2. A modification may only be issued after execution of the Contract, it must be in writing and signed by the party against whom the modification is sought to be enforced. Notice of Award: The written notice by CITY to the apparent successful Bidder stating that upon compliance with the conditions precedent to be fulfilled by it within the time specified. CITY will execute and deliver the Contract to him. Notice to Proceed: A written notice given by CITY to CONTRACTOR (with copy to CONSULTANT) fixing the date on which the Contract Time shall commence to run and on which CONTRACTOR shall start to perform its obligations under the Contract Documents. ~: An individual or legal entity. Proiect: The entire construction operation being performed as delineated in the Contract Documents. Policy: The term "policy" as used in the Contract Documents shall mean the insurance binder, if it is issued, the declaration page of the policy and the body of the policy. including all endorsements. RFP: Request for Proposal. Shop Drawin~: All drawings. diagrams. illustrations, brochures. schedules and other data which are prepared by the CONTRACTOR, a Subcontractor, manufacturer, supplier. or distributor, and which illustrate the equipment, material or some portion of the work and as required by the Contract Documents. Samples: Physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. Specifications: Those portions of the Contract Documents consisting of written technical descriptions of materials. equipment, construction systems, standards and workmanship as applied to the Work. Subcontractor: An individual. firm or corporation having a direct contract with CONTRACTOR or with any other Subcontractor for the performance of a part of the Work at the construction site. Substantial Completion: The date, as certified by the CONSULTANT. when the construction of the Project or a certified part thereof is 5ufficiendy completed. in accordance with the Contract Documents. so that the Project, or a substantial part, can be utilized for the purposes for which it was intended without restriction or limitation to any degree, other than for the repair of minor "punch list" items; or if there be no such certification. the date when final payment is due in accordance with paragraph 14.9. However. in no event shall the proiect or portion thereof, be deemed to be substantially completed until a certificate of occupancy or certificate of use is lawfully issued by the applicable governmental agency. A certificate of Substantial Completion. issued by the CONSULTANT, shall be null and void if it is based on false. misleading or inaccurate information, from any source. ~ Thomas F. Pepe. 2014 4f2812014 Page 42 of 72 or when it would not have been issue but for the consideration of Work that is thereafter found to be defective to a degree greater than that which would normally to be considered by the City to be minor "punch list" work. Supplier: Any person or organization who supplies materials or equipment for the Work. induding the fabrication of an item, but who does not perform labor at the site of the Work. ~ The individual or entity who is an obligor on a Bond and who is bound with the CONTRACTOR for the full and faithful performance of the Contract and for the payment of all labor, services and materials used on the project. Work: Any and all obligations, duties and responsibilities necessary for the successful performance and completion of the Contract. Notice: The term "Notice" as used herein shall mean and indude all written notices, demands, instructions, c/aims, approvals and disapprovals required to obtain compliance with Contract reqUirements. Written notice shall be deemed to have been duly served if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or to an authorized representative of such individual, firm, or corporation, or if delivered at or sent by registered mail to the last known business address. Unless otherwise stated in writing, any notice to or demand upon the OWNER under this Contract shall be delivered to the City Manager and the CONSUL T ANT. ARTICLE 2-PRELIMINARY MATTERS Award: 2.1 The CITY reserves the right to reject any and all Bids, at its sole discretion. Bids shall be awarded by the CITY to the lowest responsive and responsible Bidder. No Notice of Award shall be given until the CITY has concluded its investigation, as it deems necessary, to establish. to the satisfaction of the CITY. which Bidder is the most responsive and responsible of all the Bidders to complete the Work within the time prescribed and in accordance with the Contract Documents. The CITY reserves the right to reject the Bid of any Bidder who is not believed to be, in the sole discretion and satisfaction of the City, to be sufficiently responsible, qualified and financial able to perform the work. In analyzing a Bid, the CITY may also take into consideration alternate and unit prices, if requested by the Bid forms. If the Contract is awarded, the CITY shall issue the Notice of Award and give the successful Bidder a Contract for execution within ninety (90) day after opening of Bids. Execution of Contract 2.2 At least four counterparts of the Contract, the Performance and Payment Bond, the Certificates of Insurance. the Binder of Insurance if issued, the Insurance Declaration Page if not included in the Policy of Insurance, the Policy of Insurance required by the Contract Documents. the written notice of designated supervisor or superintendent as provided in Section 6. I of the General Conditions and such other Documents as required by the Contract Documents shall be executed and delivered by CONTRACTOR to the CITY within ten (10) calendar days of receipt of the Notice of Award. A Contract Document that requires the signature of a party may be executed in counterparts separately by each of the parties and. in such event, each counterpart separately executed shall. without proof or accounting for the other counterpart be deemed an original Contract Document. Forfeiture o f Bid Securin!Perfg rmance and Payment Bond. if any ar e reqU ired by the applicable RFP : 2.3 Within ten (10) calendar days of being notified of the Award. CONTRACTOR shall furnish a Performance Bond and a Payment Bond containing all the provisions of the Performance Bond and Payment Bond attached. 2.3.1 2.3.2 2.3.3 Each Bond shall be in the amount of one hundred percent (100%) of the Contract Price guaranteeing to OWNER the completion and performance of the Work covered in such Contract as weJl as fuJI payment of all suppliers, material man. laborers. or Subcontractor employed pursuant to this Proiect. Each Bond shall be with a Surety company whose qualifications meet the reqUirements of Sections 2.3.4. 2.3.S, and 2.3.6. Each Bond shall continue in effect for fIVe year after final completion and acceptance of the Work with the liability equal to one hundred percent (100%) of the Contract Sum. Pursuant to the requirements of Section 2SS.0S( I). Florida Statutes, CONTRACTOR shall ensure that the Bond(s) referenced above shall be recorded in the public records of Miami-Dade County and provide CITY with evidence of such recording. Page 43 of 72 © Thomas F. Pepe.20]4 4/28/2014 2.3.4 Each Bond must be executed by a surety company authorized to do business in the State of Florida as a surety. having a resident agent in the State of Florida and having been in business with a record of successful continuous operation for a least five (5) years. 2.3.5 The surety company shall hold a current certificate of authority as acceptable surety on federal bonds in accordance with the United States Department of Treasury Circular 570. current revisions . 2.3 .6 The CITY shall only be required to accept a surety bond from a company with a rating A. VII or better. 2.3.7 Failure of the successful Bidder to execute and deliver the Contract, and deliver the required bonds and Insurance documents shalf be cause for the CITY to annul the Notice of Award and declare the Bid and any security therefore forfeited. Contractor's Pre-Start Representation: 2 .4 CONTRACTOR represents that it has familiarized itself with, and assumes full responsibility for having familiarized itself with the nature and extent of the Contract Documents. Work. locality. and with all local conditions and federal, state and local laws. ordinance, rules and regulations that may in any manner affect performance of the Work. and represents that it has correlated its study and observations with the requirements of the Contract Documents. CONTRACTOR also represents that it has studied all surveys and investigations, reports of subsurface and latent physical conditions referred to in the specifications and made such additional surveys and investigations as it deems necessary for the performance of the Work reflected in the Contract Documents and that he has correlated the results of all such data with the reqUirements of the Contract Documents. Commencement of Contract Tim ~ 2 .5 The Contract Time shall commence to run on the date stated in the Notice to Proceed. Startin~ the Project: 2.6 CONTRACTOR shall start to perform its obligations under the Contract Documents on the date the Contract Time commences to run. No Work shall be done at the site (as defined in Article I), prior to the date on which the Contract Time commences to run. except with the written consent of the CITY. Before Startin~ Construction: 2 .7 Before undertaking each part of the Work. CONTRACTOR shall carefully study and compare the Contract Documents and check and verify pertinent figures shown thereon and all applicable field measurements and conditions . It shall at once report in writing to CONSULTANT any conflict, error, or discrepancy which it may discover. Neither the OWNER nor the CONSULTANT shall be liable for any harm. damage or loss suffered by CONTRACTOR as a result of its failure to discover any conflict, error, or discrepancy in the Drawings or Specifications nor shall the CONTRACTOR be entitle to any compensation for any harm, damage or loss suffered by the CONTRACTOR due to any conflict:, error. or discrepancy in the Contract Documents. Schedule of Completion: 2 .8 Within Five (5) business days after delivery of the Notice to Proceed by CITY to CONTRACTOR, CONTRACTOR shall submit to CONSULTANT for approval. an estimated construction schedule indicating the starting and completion dates of the various stages of the Work, and a preliminary schedule of Shop Drawing submissions. The CONSULTANT shall approve this schedule or require revisions thereto within seven (7) calendar days of its submittal. If there is more than one CONTRACTOR involved in the Project:, the responsibility for coordinating the Work of all CONTRACTORS shall be prOVided in the Special Conditions. 2.9 Within five (5) business days after delivery of the executed Contract by CITY to CONTRACTOR, but before starting the Work at the site. a pre-construction conference shall be held to review the above schedules. to establish procedures for handling Shop Drawings and other submissions, and for processing Applications for Payment, and to establish a working understanding between the parties as to the Project, t; Thomas F. Pcpe .2014 4/28 /20J4 Page 44 of 72 Present at the conference will be the CITY'S representative, CONSULTANT, Resident Project Representatives. CONTRACTOR and its Superintendent. Oualifications of Sybcontraqors, Material men and Suppliers: 2.10 Within five (5) business days after bid opening, the apparent lowest responsive and responsible Bidder shall submit to the CITY and the CONSULTANT for acceptance a list of the names of Subcontractors and such other persons and organizations (including those who are to furnish principal items of materials or equipment) proposed for those portions of the Work as to which the identity of SubcontraCtors and other persons and organizations must be submitted as specified in the Contract Documents. Within thirty (30) calendar days after receiving the list, the CONSULTANT will notify the CONTRACTOR in writing if either the CITY or the CONSULTANT has reasonable objection to any Subcontractor. person, or organization on such lise. The failure of the CITY or the CONSULTANT to make objection to any Subcontractor, person, or organization on the list within thirty (30) calendar days of the receipt shall constitute an acceptance of such Subcontractor. person or organization. Acceptance of any such SubcontraCtor. person or organization shall not constitute a waiver of any right of the CITY or the CONSULT ANT to reject defective Work, material or equipment, or any Work, material or eqUipment not in conformance with the reqUirements of the Contract Documents. 2. I I If, prior to the Notice of Award, the CITY or the CONSULTANT has reasonable objection to any Subcontractor. person or organization listed, the apparent low Bidder may, prior co Notice of Award, submit an acceptable substiwte without an increase in its bid price. ARTICLE 3-CORRELATION. INTERPRETATION AND INTENT Of CONTRACT DOCUMENTS 3.1 It is the intent of the Specifications and Drawings to describe a complete Project to be constructed in accordance with the Contract Documents. The Contract Documents comprise the entire Contract between the OWNER and the CONTRACTOR. They may be altered only by a modification as defined in Article I. 3.2 The Contract Documents are complementary; what is called for by one is as binding as if called for by all the documents. If CONTRACTOR finds a conflict, error or discrepancy in the Contract Documents, it shall, before proceeding with the Work affected thereby, immediately call it to the CONSULTANT's attention in writing. The various Contract Documents are complementary; in case of conflict, error or discrepancy, the more stringent interpretation and requirement thac shall provide the maximum benefit to the Owner shall apply 3.3 The words "furnish" and "furnish and install", "install", and "provide" or words with similar meaning shall be interpreted. unless otherwise specifically stated, to mean "furnish and install complete in place and ready for service". 3.4 Miscellaneous items and accessories which are not specifically mentioned, but which are essential to produce a complete and properly operating installation, or usable structure, providing the indicated functions, shall be furnished and installed without change in the Contract Price. Such miscellaneous items and accessories shall be of the same quality standards. including material. style, finish. strength, class, weight and other applicable characteristics, as specified for the major component of which the miscellaneous item or accessory is an essential part, and shall be approved by the CONSULTANT before installation. The above requirement is not intended to include major components nat covered by or inferable from the Drawings and Specifications. 3.5 The Work of all trades under this Contract shall be coordinated by the CONTRACTOR in such a manner as obtain the best workmanship possible for the entire ProjeCt, and all components of the Work shall be installed or erected in accordance with the best practices of the particular trade. 3.6 The CONTRACTOR shall be responsible for making the construction of habitable structures under this Contract rain proof, and for making equipment and utility installations properly perform the specified function. If the CONTRACTOR is prevented from complying with this provision due to the Drawings or Specifications, the CONTRACTOR shall immediately notify the CONSULTANT in writing of such limitations before proceeding with construction in the area where the problem exists. 3.7 Manufacturer's literature, when referenced. shall be dated and numbered and is intended to establish the minimum reqUirements acceptable. Whenever reference is given to codes, or standard specifications or :1;; Thomas F. Pepe.2014 4/28/2014 Page 4S of 72 other data published by regulating agencies or accepted organizations, including but not limited to National Electrical Code, applicable State Building Code, Florida Building Code, Federal Specifications, ASTM Specifications, various institute specifications, and the like, it shall be understood that such reference is to the latest edition including addenda in effect on the date of the Bid. 3.8 Brand names where used in the technical specifications, are intended to denote the standard or quality required for the particular material or product. The term "equal" or "equivalent", when used in connection with brand names, shall be interpreted to mean a material or product that is similar and equal in type, quality, size. capacity, composition, finish. color and other applicable characteristics to the material or product specified by trade name, and that is suitable for the same use capable of performing the same function. in the opinion of the CONSULTANT. as the material or product so specified. Proposed eqUivalent items must be approved by CONSUL T ANT before they are purchased or incorporated in the Work. (When a brand name, catalog number, model number, or other identification, is used without the phrase ·or equal", the CONTRACTOR shall use the brand, make and model specified). 3.9 Throughout this agreement the male pronoun may be substituted for female and neuter and vice versa and the singular words substituted for plural and plural words substituted for singular wherever applicable. 3 .10 All technical interpretations shall be made by the CONSULTANT as set forth in Section 9.3 below. 3.11 The CONTRACTOR shall advised the CONSULTANT, prior to performing any work involving a conflict in the Contract Documents and the CONSULTANT shall make the final decision as to which of the documents shall take precedence. In the event that there is a conflict between or among the Contract Documents, only the latest version shall apply and the latest version of the Contract Documents. The CONSULTANT shall use the follOWing list of Contract Documents as a guide. These documents are set forth below in the order of their precedence so that all the documents listed above a given document should have precedence over all the documents listed below it. (a) Amendments and Change Orders (b) Addenda to Contract (c) Contract with all Exhibits thereto Supplementary Conditions Special Conditions General Conditions Written or figured dimensions Scaled dimensions Drawings of a larger scale Drawings of a smaller scale Cd) (e) (f) (g) (h) (i) 0) (k) Drawings and Specifications are to be considered complementary to each other ARTICLE 4 -AVAILABILITY OF LANDS SUBSURFACE CONDITIONS REFERENCE POINTS Availability of lands: 4.1 The OWNER shall furnish, as indicated in the Contract Documents, the lands upon which the Work is to be done. rights-of-way for access thereto, and such other lands which are designed for the use of the CONTRACTOR. Easements for permanent structures or permanent changes in existing facilities will be obtained and paid for by the OWNER, unless otherwise specified in the Contract Documents. Other access to such lands or rights-of-way for the CONTRACTOR'S convenience shall be the responsibility of the CONTRACTOR. The CONTRACTOR shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of material and eqUipment. 4.2 The CITY will, upon request, furnish to the Bidders, copies of all available boundary surveys and subsurface testS at no cost. Subsurface Conditions: 4.3 The CONTRACTOR acknowledges that he has investigated prior to bidding and satisfied himself as to the conditions affecting the Work, including but not limited to those bearing upon transportation, disposal, handling and storage of materials, availability of labor. water. electric power. roads and C Thomas F. Pepe. 2014 4i28/2014 Page 46 of 72 uncertainties of weather. river stages. tides. water tables or similar physical conditions at the site. the conformation and conditions of the ground. the character of equipment and facilities needed preliminary to and during prosecution of the Work. The CONTRACTOR further acknowledges that he has satisfied himself as to the character. quality and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site. including all exploratory work done by the OWNERI CONSULTANT on the site or any contiguous site. as well as from information presented by the Drawings and Specifications made part: of this Contract, or any other information made available to it prior to receipt of bids. Any failure by the CONTRACTOR to acquaint itself with the available information shall not relieve it from responsibility for estimating properly the difficulty or cost of successfully performing Work. The OWNER assumes no responsibility for any conclusions or interpretations made by the CONTRACTOR on the basis of the information made available by the OWNERI CONSULTANT. Differin~ Site Conditions: 4A The CONTRACTOR shall within forty eight (48) hours of its discovery. and before such conditions are disturbed. notify the CITY in writing. of. 4.4.1 Subsurface or latent physical conditions at the site differing materially from those indicated in the Contract Documents. and 4.4.2 Unknown physical conditions at the site. of an unusual nature. differing materially from those ordinarily encountered and generally inherent in Work of the character provided for in this Contract. The CITY shall promptly investigate the conditions, and if it finds that such conditions do materially differ to the extent as to cause an increase or decrease in the CONTRACTOR'S cost of. or the time required for, performance of any part of the Work under this Contract, an eqUitable adjustment shall be made and the Contract modified in writing accordingly. 4.5 No claim of the CONTRACTOR under this clause shall be allowed unless the CONTRACTOR has given the notice required in 4A above: provided, however, the time prescribed therefore may be extended by the CITY, but only if done in writing Signed by the City Manager or the CONSULTANT ARTICLE 5 -INSURANCE 5.0 The Contractor shall purchase insurance from and shall maintain the insurance with a company or companies lawfully authorized to do business in the State of Florida as will protect the Contractor from claims as set forth below which may arise out of or result from the Contractor's operations under the Contract and for which the Contractor may be legally liable, whether such operations be by the Contractor or by a Subcontractor or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable : 5.0.1 claims under workers' compensation, disability benefit and other similar employee benefit aCts which are applicable to the Work to be performed; 5.0.2 claims for damages because of bodily injury. occupational sickness or disease. or death of the Contractor's employees; 5.0.3 claims for damages because of bodily injury. sickness or disease, or death of any person other than the Contractor's employees; 5.0A claims for damages insured by usual personal injury liability coverage; 5.0.5 claims for damages, other than to the Work itself, because of injury to or destruction of tangible property, including loss of use resulting there from; 5.0.6 claims for damages because of bodily injury, death of a person or property damage arising out of ownership, maintenance or use of a motor vehicle; 5.0.7 claims for bodily injury or property damage arising out of completed operations; and 5.0.8 claims involving contractual liability insurance applicable to the Contractor's obligations under the Contract. © Thomas F. Pepe, 2014 4i28/2014 Page 47 of 72 Contractor's liability Insurance: 5.1 CONTRACTOR shall provide and maintain in force and effect until all the Work to be performed under this Contract has been completed and accepted by OWNER (or for such duration as is otherwise specified hereinafter), the insurance coverage written on Florida approved forms and as set forth below: 5.1.1 Worker's Compensation insurance at the statutory amount as to all employees in compliance with the ·Workers' Compensation lawN of the State of Florida and all applicable federal laws. In addition, the policy(ies) must include: Employers' Liability at the statutory coverage amount. The CONTRACTOR shall further insure that all of its Subcontractors maintain appropriate levels of Worker's Compensation Insurance. 5.1.2 Comprehensive General Liability insurance with broad form endorsement, on a Florida approved form including automobile liability, completed operations and products liabiHty, contractual liability, severability of interest with cross liability provision, and personal injury and property damage liability with limits of $1,000,000 combined single limit per occurrence and $2,000,000 aggregate, including: Personal Injury: $1,000,000; Medical Insurance: $5,000 per person; Property Damage: $500,000 each occurrence; Automobile Liability: $1,000,000 each accidentloccurrence. S. f .2.1 Umbrella Commercial Comprehensive Genera! liability insurance shall be written on a Florida approved form with the same coverage as the primary insurance policy but in the amount of $1,000,000 per claim and $2,000,000 Annual Aggregate. Coverage must be afforded on a form no more restrictive than the latest edition of the Comprehensive General Liability policy, without restrictive endorsements, as filed by the Insurance Services Office, and must: include: (a) Premises and Operation (b) Independent Contractors (c) Products and/or Completed Operations Hazard (d) Explosion. Collapse and Underground Hazard Coverage (e) Broad Form Property Damage (f) Broad Form Contractual Coverage applicable to this specific Contract, including any hold harmless and/or indemnification agreement. (g) Personal Injury Coverage with Employee and Contractual Exclusions removed, with minimum limits of coverage equal to those required for Bodily Injury Liability and Property Damage Liability. 5.1.3 Business Automobile Liability with minimum limits of One Million Dollars ($1.000,000.00) plus an additional One Million Dollar ($ I ,000,000.00) umbrella per occurrence combined Single limit for Bodily Injury Liability and Property Damage Liability. Umbrella coverage must be afforded on a form no more restrictive than the latest edition of the Business Automobile Liability policy, without restrictive endorsements, as filed by with the state of Florida, and must include: (a) Owned Vehicles. (b) Hired and Non-Owned Vehicles (c) Employers' Non-Ownership 5.2 Before starting the Work. the CONTRACTOR shall deliver to the CITY and CONSULTANT certificates of such insurance, acceptable to the CITY, as we/! as the insurance binder, the declaration page and all applicable endorsements and policies of insurance and provide the name, address and telephone number of the insurance agent or broker through whom the policy was obtained. The insurer shall be rated AVII or better per AM. Best's Key Rating Guide, latest edition and authorized to issue insurance in the State of Florida. All insurance must remain in full force and effect for the duration of the contract period with the Owner. All insurance policies must be written on forms approved by the State of Florida and they must remain in full force and effect for the duration of the contract period with the Owner. The CONTRACTOR must provide not only a "certified copy" of the Binder but also the Policy. as defined in Article I above as well as the name, address and phone number of the agent and agency procuring the insurance. In addition, the CONTRACTOR shall deliver, at the time of delivery of the insurance certificate, an endorsement to the policy naming the Owner as an additional named insured and an endorsement that requires the insurer to provide the OWNER with notice. as set forth below. of © Thomas F. Pepe. 2014 4/28/2014 Page 48 of 72 modification, lapse, termination or cancellation (including cancellation for non-payment of premium) of the policy 10 days prior to effective date of the modification, lapse, termination or cancellation, including cancellation for non-payment of premium. The notification shall be in Writing and served by certified mai~ with proof of deliver, on the OWNER. It shall be the responsibility of the CONTRACTOR as well as the insurer to notify the Owner of modification. termination or cancellation, lapse or modification of any insurance coverage or policies insuring the CONTRACTOR. which relate to the activities of such CONTRACTOR and the City of South Miami. Therefore, the CONTRACTOR shall deliver, at the time of delivery of the insurance policy. the following endorsements unless the policy contains substantially similar provisions: (a) "The City of South Miami is an additional insured. The insurer shall pay all sums that the City of South Miami becomes legally obligated to pay as damages because of 'bodily injury". 'property damage' , or "personal and advertising injury" and it will provide to the Owner all of the coverage that is typically provided under the standard Florida approved forms for commercial general liability coverage A and coverage B"; (b) "This policy shall not be cancelled (including cancellation for non-payment of premium), materially modified or terminated, without first giving the City of South Miami ten (10) days advanced written notice of the intent to cancel or terminate the policy for any reason." 5.3 SUBCONTRACTS: The CONTRACTOR agrees that if any part of the Work under the Contract is sublet, the subcontract shall contain the same insurance provision as set forth in section S. I and 5.2 above and substituting the word SUBCONTRACTOR for the word CONTRACTOR and substituting the work CONTRACTOR for CITY or OWNER where applicable. Fire and Extended Covera&e Insurance (Builders' Risk): SA In the event that this contract involves the construction of a structure, the CONTRACTOR shall maintain, with an Insurance Company or Insurance Companies acceptable to the CITY. Fire, Extended Coverage and Vandalism & Malicious Mischief Insurance on buildings and structures, while in the course of construction. including foundations, additions. attachments and all permanent fixtures belonging to and constituting a part of said buildings or structures. The policy or policies shall also cover machinery, if the cost of machinery is included in the Contract, or if the machinery is located in a building that is being renovated by reason of this contract. The amount of insurance must at all times be at least equal to the actual cash value of the insured property. The policy shall be in the name of the OWNER and the CONTRACTOR. as their interest may appear, and shall also cover the interests of all Subcontractors performing Work 5.S The CONTRACTOR shall provide the CITY with evidence satisfactory to the CITY certifying that the foregoing insurance is in force; and such evidence shall include provisions that the insurance shall not be canceled or materially changed until at least 10 calendar days prior written notice has been given by the insurer to the OWNER by certified mail. Miscellaneous: 5.6 If any notice of cancellation of insurance or change in coverage is issued by the insurance company or should any insurance have an expiration date that will occur during the period of this contract, the CONTRACTOR shall be responsible for securing other acceptable insurance prior to such cancellation, change. or expiration so as to provide continuous coverage as specified in this section and so as to maintain coverage during the life of this Contract. 5.7 All deductibles must be declared by the CONTRACTOR and must be approved by the CITY. At the option of the CITY, either the CONTRACTOR shall eliminate or reduce such deductible or the CONTRACTOR shall procure a Bond. in a form satisfactory to the CITY covering the same. 5.8 The policies shall contain waiver of subrogation against Owner where applicable, shall expressly provide that such policy or policies are primary over any other collectable insurance that Owner may have. The City reserves the right at any time to request a copy of the required policies for review. All policies shall contain a "severability of interest" or "cross liability" clause without obligation for premium payment of the OWNER. © Thomas F. Pepe, 2014 4128/2014 Page 49 of 72 ARTICLE 6 -CONTRACTOR'S RESPONSIBILITIES Supervision and Superintendence: 6.1 The CONTRACTOR shall supervise and direct the Work. It shall be solely responsible for the means, memods, techniques. sequences and procedures of construction. The CONTRACTOR shall employ and maintain a qualified supervisor or superintendent (hereinafter referred to as "Supervisor" at the Work site who shall be designated in writing by the CONTRACTOR. before the CONTRACTOR commences the Work and within the time required by the Contract, as the CONTRACTOR'S representative at the site. The Supervisor or so designated shall have full authority to act on behalf of the CONTRACTOR and all communications given to the Supervisor shall be as binding as if given to the CONTRACTOR. The Supervisor(s) shall be present at each site at all times as reqUired to perform adequate supervision and coordination of the Work. (Copies of written communications given to the Supervisor shall be mailed to the CONTRACTOR'S home office). 6.1.1 The CONTRACTOR shall keep one record copy of all Specifications. Drawings. Addenda, Modifications and Shop Drawings at the site at all times and in good order and annotated to show all changes made during the construction process. These shall be available to the CONSULTANT and any CITY Representative at all reasonable times. A set of "As-Built" drawings. as well as the original Specifications. DraWings. Addenda, Modifications and Shop Drawings with annotations, shall be made available to the City at all times and it shall be delivered to the CITY upon completion of the Project. Labor. Materials and Equipment: 6 .2 The CONTRACTOR shall provide competent, SUitably qualified personnel to layout the Work and perform construction as required by the Contract Documents. It shall at all times maintain good discipline and order at the site. 6.3 The CONTRACTOR shall fumish all materials, equipment, labor. transportation, construction equipment and machinery, tools. appliances, fuel, power, light, heat, local telephone. water and sanitary facilities and all other facilities and incidentals necessary for the execution. testing, initial operation and completion of the Work. 6.4 All materials and equipment shall be new, except as otherwise provided in the Contract Documents. When special makes or grades of material which are normally packaged by the supplier or manufacturer are specified or approved, such materials shall be delivered to the site in their original packages or containers with seals unbroken and labels intact. 6 .S All materials and equipment shall be applied, installed. connected. erected, used. cleaned and conditioned in accordance with the instructions of the applicable manufacturer. fabricator. or processors, except as otherwise provided in the Contract Documents. Materials Equipment, Products and Substitutions: 6.6 Materials, equipment and products incorporated in the Work must be approved for use before being purchased by the CONTRACTOR. The CONTRACTOR shall submit to the CONSULTANT a list of proposed materials, equipment or products. together with such samples as may be necessary for them to determine their acceptability and obtain their approval, within ninety (90) calendar days after award of Contract unless otherwise stipulated in the Special Conditions. No request for payment for "or equal" equipment will be approved until this list has been received and approved by the CONSULTANT. 6 .6 .1 Whenever a material, article or piece of equipment is identified on the DraWings or Specifications by reference to brand name or catalog number, it shall be understood that this is referenced for the purpose of defining the performance or other salient reqUirements and that other products of equal capacities. quality and function shall be considered. The CONTRACTOR may recommend the substitution of a material, article, or piece of equipment of equal subStance and function for those referred to in the Contract Documents by reference to brand name or catalog number, and if. in the opinion of the CONSULTANT. such material, article. or piece of equipment is of equal substance and function to that speCified. the CONSULTANT may approve its substitution and use by the CONTRACTOR. Incidental ~ Thomas F Pepe. 2014 4 128 /2014 Page SO of 72 changes or extra component parts required to accommodate the substitute will be made by the CONTRACTOR without a change in the Contract Price or the Contract Time. 6.6.2 No substitute shall be ordered or installed without the written approval of the CONSULTANT who shalf be the judge of quality. 6.6.3 Delay caused by obtaining approvals for substitute materials shall not be considered justifiable grounds for an extension of construction time. 6.6.4 Should any Work or materials. equipment or products not conform to requirements of the Drawings and Specifications or become damaged during the progress of the Work, such Work or materials shall be removed and replaced. together with any Work disarranged by such alterations. at any time before completion and acceptance of the Project. All such Work shall be done at the expense of the CONTRACTOR. 6.6.5 No materials or supplies for the Work shall be purchased by the CONTRACTOR or any Subcontractor subject to any chattel mortgage or under a conditional sale or other agreement by which an interest is retained by the Seiter. The CONTRACTOR warrants that they have good title to all materials and supplies used by them in the Work. Concemin~ Subcontractors: 6.7 The CONTRACTOR shall not employ any Subcontractor, against whom the CITY or the CONSULTANT may have reasonable objection, nor will the CONTRACTOR be reqUired to employ any Subcontractor who has been accepted by the CITY and the CONSULTANT, unless the CONSULTANT determines that there is good cause for doing so. 6.8 The CONTRACTOR shall be fully responsible for all acts and omissions of its Subcontractors and of persons and organizations directly or indirectly employed by it and of persons and organizations for whose acts any of them may be liable to the same extent that they are responsible for the acts and omissions of persons directly employed by them. Nothing in the Contract Documents shall create any contractual relationship between OWNER or CONSULTANT and any Subcontractor or other person or organization having a direct contract with CONTRACTOR, nor shall it create any obligation on the part of OWNER or CONSULTANT to payor to see to payment of any persons due subcontractor or other person or organization, except as may otherwise be required by law. CITY or CONSULTANT may fumish to any Subcontractor or other person or organization. to the extent practicable. evidence of amounts paid to the CONTRACTOR on account of specified Work done in accordance with the schedule values. 6.9 The divisions and sections of the Specifications and the identifications of any Drawings shall not control the CONTRACTOR in dividing the Work among Subcontractors or delineating the Work performed by any specific trade. 6.10 The CONTRACTOR agrees to bind specifically every Subcontractor to the applicable terms and conditions of the Contract Documents for the benefit of the OWNER. 6.11 All Work performed for the CONTRACTOR by a Subcontractor shall be pursuant to an appropriate agreement between the CONTRACTOR and the Subcontractor. 6.12 The CONTRACTOR shall be responsible for the coordination of the trades. Subcontractors material and men engaged upon their Work. 6.12.1 The CONTRACTOR shall cause appropriate provisions to be inserted in all subcontracts relative to the Work to bind Subcontractors to the CONTRACTOR by the terms of these General Conditions and other Contract Documents insofar as applicable to the Work of Subcontractors, and give the CONTRACTOR the same power as regards to terminating any subcontract that the OWNER may exercise over the CONTRACTOR under any provisions of the Contract Documents. 6.12.2 The CITY or CONSULTANT will not undertake to settle any differences between the CONTRACTOR and their Subcontractors or between Subcontractors. 6. I 2.3 (~~ Thomas F. Pepe, 2014 4/28/2014 If in the opinion of the CONSULTANT, any Subcontractor on the Project proves to be incompetent or otherwise unsatisfactory, they shall be promptly replaced by the CONTRACTOR if and when directed by the CONSULTANT in writing. Page 51 of 72 6.12A Discrimination: No action shaH be taken by the any subcontractor with regard to the fulfilment of the terms of the subcontract, including the hiring and retention of employees for the performance of Work that would discriminate against any person on the basis of race, color, creed, religion, national origin, sex. age, sexual orientation, familial status or disability. This paragraph shall be made a part of the subcontractor's contract with the Contractor. Patent Fees and Royalties: 6.13 The CONTRACTOR shall pay all license fees and royalties and assume all costs incident to the use of any invention, design, process or device which is the subject of patent rights or copyrights held by others. He shall indemnify and hold harmless the OWNER and the CONSULTANT and anyone directly or indirectly employed by either of them from against all claims, damages, losses and expenses (including attorney's fees) arising out of any infringement of such rights during or after the completion of the Work. and shall defend all such claims in connection with any alleged infringement of such rights. 6.14 The CONTRACTOR shalt be responsible for determining the application of patent rights and royalties materials, appliances, articles or systems prior to bidding. However, he shall not be responsible for such determination on systems which do not involve purchase by them of materials, appliances and articles. ~ 6.1 5 The CONTRACTOR shall secure and pay for all construction permits and licenses and shall pay for all governmental cha.rges and inspection fees necessary for the prosecution of the Work, which are applicable at the time of his Bid . When such charges are normally made by the CITY and when so stated in the Special Conditions. there will be no charges to the CONTRACTOR. The CITY shall assist the CONTRACTOR. when necessary. in obtaining such permits and licenses. The CONTRACTOR shall also pay all public utility charges. Electrical Power and Lil:htin~: 6.16 Electrical power required during construction shall be prOVided by each prime CONTRACTOR as required by it. This service shall be installed by a qualified electrical Contractor approved by the CONSULTANT. Lighting shall be provided by the CONTRACTOR in all spaces at all times where necessary for good and proper workmanship, for inspection or for safety. No temporary power shall be used off temporary lighting lines without specific approval of the CONTRACTOR. Laws and R~lations : 6.17 The CONTRACTOR shall comply with all notices. laws, ordinances, rules and regulations applicable to the Work. If the CONTRACTOR observes that the Specifications or Drawings are at variance therewith, it shall give the CONSULTANT prompt written notice thereof, and any necessary changes shall be adjusted by an appropriate modification. If the CONTRACTOR performs any Work knowing it to be contrary to such laws, ordinances. rules and regulations, and without such notice to the CONSULTANT. it shall bear all costs arising there from; however. it shall not be its primary responsibility to make certain that the Drawings and Specifications are in accordance with such laws. ordinances, rules and regulations. Discrimination : 6.17 A No action shall be taken by the Contractor with regard to the fulfilment of the terms of the Contract, including the hiring and retention of employees for the performance of Work that would discriminate against any person on the basis of race. color, creed. religion, national origin. sex. age. sexual orientation, familial status or disability. Taxes: 6.18 Cost of all applicable sales. consumer use. and other taxes for which the CONTRACTOR is liable under the Contract shall be included in the Contract Price stated by the CONTRACTOR. if:! Thomas F. Pepe.2014 4 128110 14 Page 52 of 72 SafetY and Protection: 6.19 The CONTRACTOR shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. They shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 6.19. I All employees and other persons. who may be affected thereby, 6.19.2 All the Work and all materials or equipment to be incorporated therein, whether in storage on or off the site. and 6 .19 .3 Other property at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, strucrures and utilities not designated for removal, relocation or replacement in the course of construction. 6.20 The CONTRACTOR shall designate a responsible member of their organization at the site whose duty shall be the prevention of accidents. This person shall be the CONTRACTOR'S Superintendent unless otherwise deSignated in writing by the CONTRACTOR co the CITY. Eme~ncies: 6.21 In emergencies affecting the safety of persons or the Work or property at the site or adjacent thereto, the CONTRACTOR. without special instruction or authorization from the CONSULTANT or CITY, is obligated to act, at his discretion, to prevent threatened damage, injury or loss. He shall give the CONSULTANT prompt written notice of any significant changes in the Work or deviations from the Contract Documents caused thereby. If the CONTRACTOR believes that additional Work done by him in an emergency which arose from causes beyond his control entitles him to an increase in the Contract Price or an extension of the Contract Time, he may make a claim therefore as provided in Articles II and 12. Shop Drawings and Samples: 6.22 After checking and verifying all field measurements, the CONTRACTOR shall submit to the CONSULTANT for review, in accordance with the accepted schedule of shop drawing submissions, six (6) copies (or at the CONSULTANT option, one reproducible copy) of all Shop Drawings, which shall have been checked by and stamped with the approval of the CONTRACTOR. The Shop Drawings shall be numbered and identified as the CONSULTANT may require. The data shown on the Shop Drawings shall be complete with respect to dimensions. design criteria, materials of construction and the like to enable the CONSULTANT to review the information without any unnecessary investigation. 6.23 The CONTRACTOR shall also submit to the CONSULTANT for review. with such promptness as to cause no delay in Work. all samples required by the Contract Documents. All samples shall have been checked by and stamped with the approval of the CONTRACTOR, identified clearly as to material, manufacturer, any pertinent catalog numbers and the use for which intended. 6.24 At the time of each submission, the CONTRACTOR shall notify the CONSULTANT, in writing, of any deviations between the Shop Drawings or samples and the requirements of the Contract Documents. 6.25 The CONSULTANT shall review with responsible promptness Shop Drawings and Samples, but his review shall be only for conformance with the design concept of the Project and for compliance with the information given in the Contract Documents. The review of a separate item as such will not indicate review of the assembly in which the items functions . The CONTRACTOR shall make any <orrections required by the CONSULTANT and shall return the required number of corrected copies of Shop Drawings and resubmit new samples until the review is satisfactory to the CONSULTANT. The CONTRACTOR shall notify the CONSULTANT, in writing, of any prior Shop DraWing or revisions to Shop Drawings that are in conflict with each submission or re-submission. The CONTRACTOR'S stamp of approval on any Shop DraWings or sample shall constitute representation to the CITY and the CONSULTANT that the CONTRACTOR has either determined and/or verified all quantities, dimension, field construction criteria, materials, catalog numbers and similar data or they assume full responsibility for doing so, and that they have reviewed or coordinated each Shop Drawing or sample with the reqUirements of the Work and the Contract Documents. 6.26 No Work requiring a submittal of a Shop Drawing or sample shall be commenced until the submission has been reviewed and approved in writing by the CONSULTANT. A copy of each Shop Drawing and each ~ Thomas F. Pepe,2014 4128i2014 Page 53 of 72 approved sample shall be kept in good order, in a book or binder, in chronological order or in such other order required by the CONSULTANT in writing, by the CONTRACTOR at the site and shall be available to the CONSULTANT. 6.27 The CONSULTANTs review of Shop Drawings or samples shall not relieve the CONTRACTOR from his responsibility for any deviations from the requirements of the Contract Documents unless the CONTRACTOR has informed the CONSULTANT. in writing, to each deviation at the time of submission and the CONSULTANT has given written approval to the speCific deviation, nor shall any review by the CONSULTANT relieve the CONTRACTOR from responsibility for errors or omissions in the Shop Drawings or samples. 6.271 The CONTRACTOR shall be liable to the OWNER for any additional cost or delay that is caused by its failure to notify the CONSULTANT of any of said deviations or conflicts between Shop DraWings or due to errors in the Shop Drawings or samples. Cleanin, Up: 6.28 The CONTRACTOR shall clean up behind the Work as much as is reasonably possible as the Work progresses. Upon completion of the Work. and before acceptance of final payment for the Project by the OWNER, the CONTRACTOR shall remove all his surplus and discarded materials, excavated material and rubbish as well as all other material and eqUipment that does not form a part of the Work. from the property, roadways, sidewalks. parking areas. lawn and all adjacent property. In addition, the CONTRACTOR shall clean his portion of Work involved in any building under this Contract, so that no further cleaning by the OWNER is necessary prior to its occupancy and he shall restore all property, both public and private. which has been disturbed or damaged during the prosecution of the Work so as to leave the whole Work and Work Site in a neat and presentable condition. 6.29 If the CONTRACTOR does not clean the Work site. the CITY may clean the Work Site of the materials referred to in paragraph 6.28 and charge the cost to the CONTRACTOR. Public Convenience and Safety: 6.30 The CONTRACTOR shall, at all times, conduct the Work in such a manner as to insure the least practicable obstruction to public travel. The convenience of the general public and of the residents along and adjacent to the area of Work shall be provided for in a satisfactory manner, consistent with the operation and local conditions. "Street Closed" signs shall be placed immediately adjacent to the Work. in a conspicuous position, at such locations as traffic demands. At any time that streets are required to be closed, the CONTRACTOR shall notify law enforcement agencies and in particular, the City of South Miami Police Department, before the street is closed and again as soon as it is opened. Access to fire hydrants and other fire extinguishing equipment shall be provided and maintained at all times. Sanitary Provisions: 6.3 I The CONTRACTOR shall provide on-site office. and necessary toilet facilities, secluded from public observation. for use of all personnel on the Work Site. whether or not in his employ. They shall be kept in a clean and sanitary condition and shall comply with the requirements and regulations of the Public Authorities having jurisdiction. They shall commit no public nuisance. Temporary field office and sanitary facilities shall be removed upon completion of the Work and the premises shall be left dean. Indemnification: 6.32 The CONTRACTOR shall indemnify and hold harmless the OWNER and the CONSULTANT, as well as their officers. agents and employees or any of them from and against claims. damages, losses and expenses (including but not limited to attorneys' fees) received or sustained by any person or persons during or on account of or arising out of any operations connected with the Work. but only to the extent caused in whole or in part by the negligent acts or omissions of the CONTRACTOR, a Subcontractor, or anyone directly or indirectly employed by them or anyone for whose acts they are liable. This indemnification provision is cumulative with all other remedies or other indemnification provisions contained in the Contract Documents. The CONTRACTOR shall pay all claims and losses of any kind or nature whatsoever, in connection therewith. including the CITY's attorney's fees and expenses in the © Thomas F. Pepe, 2014 4!2812014 Page 54 of 72 defense of any action in law or equity brought against the Owner arising from either the negligen4 willful. wanton or intentional error, omission, or act of the CONTRACTOR. its sub-contractor or assigns as well as all of their agents. representatives or employees, incident to. arising out of or resulting from the performance of the CONTRACTOR's services under this Agreement. The CONTRACTOR agrees and recognizes that the Owner shall not be held liable or responsible for any claims. including the costs and expenses of defending such claims which may result from or arise out of actions or omissions of the CONTRACTOR, its sub-contractOr or assigns as well as all of their agents. representatives or employees. In reviewing. approving or rejecting any submissions or acts of the CONTRACTOR, the Owner in no way assumes or shares responsibility or liability of the CONTRACTOR, or its sub-contractOr or assigns, or any of their agents, representatives or employees 6.33 In the event that: any action or proceeding is brought against: OWNER or CONSULTANT by reason of any such claim or demand. CONTRACTOR. upon written notice from CITY shall defend such action or proceeding by counsel satisfactory to CITY. The indemnification provided above shall obligate CONTRACTOR to defend at its own expense or to provide for such defense, at CITY'S option. any and all claims of liability and all suits and actions of every name and description that may be brought against OWNER or CONSULTANT, excluding only those claims that allege that the injuries arose out of the sole negligence of OWNER or CONSULTANT. 6.34 The obligations of the CONTRACTOR under paragraph 6.33 shall not extend to the liability of the CONSULTANT. its agents or employees arising out of (a) the preparation or approval of maps. drawings. opinions. reports. surveys. Change Orders. designs or specifications or (b) the giving of or the failure to give directions or instructions by the CONSULTANT, its agents or employees provided such act or omission is the primary cause of injury or damage. 6.34A All of the forgoing indemnification provisions shall survive the term of the Contract to which these General Conditions are a part. Indemnification shall not exceed an amount equal to the total value of all insurance coverage required by Section 5.1 of this document. Indemnification is limited to damages caused in whole or in part by any act., omission. or default of the Contractor. the Contractor's subcontractors. sub-subcontractors, materialmen, or agents of any tier or their respective employees to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of the indemnifying party and persons employed or utilized by the indemnifying party in the performance of the construction contract. Responsibility for Connection to Existin~ Work: 6.35 It shall be the responsibility of the CONTRACTOR to connect its Work to each part of the existing Work, existing building or structure or Work previously installed as required by the Drawings and SpeCifications to provide a complete installation . 6.36 Excavations, grading, fill, storm drainage, paving and any other construction or installations in rights-of- ways of streets, highways. public carrier lines, utility lines, either aerial. surface or subsurface, etc., shall be done in accordance with requirements of the special conditions. The OWNER will be responSible for obtaining all permits necessary for the Work described in this paragraph 6.36 . Upon completion of the Work, CONTRACTOR shall present to CONSULTANT certificates, in triplicate, from the proper authorities. stating that the Work has been done in accordance with their requirements. 6.36.1 The CITY will cooperate with the CONTRACTOR in obtaining action from any utilities or public authorities involved in the above reqUirements. 6.36.2 The CONSULTANT shall be responsible for obtaining elevations of curbs and gutters. pavement. storm drainage structures, and other items which must be established by governmental departments as soon as grading operations are begun on the site and, in any case, sufficiently early in the construction period to prevent any adverse effect on the Project. Cooperation with Governmental Departments. Public Utilities. Etc.: 6.37 The CONTRACTOR shall be responsible for making all necessary arrangements with governmental departments, public utilities. public carriers. service companies and corporations (hereinafter referred to as "third parties') owning or controlling roadways. railways, water, sewer, gas, electrical conduits, telephone. and telegraph facilities such as pavements, tracks, piping, wires. cables, conduits. poles. guys, etc., including incidental structures connected therewith. that are encountered in the Work in order that r, Thomas f Pepe.2014 4/28/2014 Page 55 of 72 such items are properly shored, supponed and protected, that their location is identified and to obtain authority from these third parties for relocation if the CONTRACTOR desires to relocate the item. The CONTRACTOR shall give all proper notices, shall comply with all requirements of such third parties in the performance of his Work, shall permit entrance of such third parties on the Project in order that they may perform their necessary work, and shall pay all charges and fees made by such third parties for their work. 6.37.1 6.372 Use Premises: The CONTRACTOR'S attention is called to the fact that there may be delays on the Project due to work to be done by governmental departments. public utilities, and others in repairing or moving poles, conduits, etc. The CONTRACTOR shall cooperate with the above parties in every way pOSSible, so that the construction can be completed in the least possible time. The CONTRACTOR shall have made itself familiar with all codes, laws, ordinances, and regulations which in any manner affect those engaged or employed in the Work, or materials and equipment use in or upon the Work. or in any way affect the conduct of the Work, and no plea of misunderstanding will be considered on account of damage or delay caused by his ignorance thereof. 6.38 CONTRACTOR shall confine its apparatus, storage of materials, and operations of its workmen to the limits indicated by law. ordinances, permits and directions of CONSULTANT and CITY, and shall not unnecessarily encumber any part of the site or any areas off site. 6.38.1 CONTRACTOR shall not overload or permit any part of any structure to be loaded with such weight as will endanger its safety, nor shall it subject any work to stresses or pressures that will endanger it. 6.38.2 CONTRACTOR shall enforce the rules and regulation promulgated by the CONSULT ANT and OWNER as well as their instructions with regard to signs, advertisements. fires. and smoking. 6.38.3 CONTRACTOR shall arrange and cooperate with CITY in routing and parking of automobiles of its employees, subcontractors and other personnel, as well as that of the material delivery trucks and other vehicles that come to the Project site. 6.38:4 The City will designate specific areas on the site for storage, parking, etc. and the job site shall be fenced to protect the job site and the general public. 6.38.5 The CONTRACTOR shall furnish, install and maintain adequate construction office facilities for all workers employed by it or by its Subcontractors. Temporary offices shall be provided and located where directed and approved by the CONSULTANT. All such facilities shall be furnished in strict accordance with eXisting governing regulations. Field offices shall include telephone facilities. Protection of Existine PropertY Improvements: 6.39 Any existing surface or subsurface improvements. such as pavements, curbs, sidewalks, pipes or utilities, footings, or structures (including portions thereof), trees and shrubbery, not indicated on the Drawings or noted in the Specifications as being removed or altered shall be protected from damage during construction of the Proiect. Any such improvements damaged during construction of the Proiect shall be restored at the expense of the CONTRACTOR to a condition equal to that existing at the time of award of Contract. ARTICLE 7 -WORK BY OTHERS 7.1 The CITY may perform additional Work related to the Project or may let other direct contracts therefor which shall contain General Conditions similar to these. The CONTRACTOR shall afford the other contractors who are parties to such direct contracts (or the OWNER, if it is performing the additional Work itself), reasonable opponunity for the introduction and storage of materials and equipment and the execution of Work, and shall properly connect and coordinate its Work with theirs. 7.2 If any part of the CONTRACTOR'S Work depends upon proper execution or results of the Work of any other contractor or the OWNER, the CONTRACTOR shall prompdy report to the CONSULTANT in e Thomas F. Pepe. 2014 412812014 Page 56 of 72 writing any defects or deficiencies in such Work that render it unsuitable for the CONTRACTOR's Work. 7.3 The CONTRACTOR shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and fit to receive or be received by such other Work. The CONTRACTOR shall not endanger any Work of others by cutting, excavating or otherwise altering their Work and shall only cut or alter their Work with the written consent of the CONSULTANT and of the other contractor whose work will be affected. 7 .4 If the performance of additional Work by other contractors or the OWNER is not noted in the Contract Documents prior to the execution of the Contract, written notice thereof shall be given to the CONTRACTOR. prior to starting any such additional Work. If the CONTRACTOR. believes that the performance of such additional Work by the OWNER or others will cause the CONTRACTOR additional expense or entides him to an extension of the Contract Time, he may make a claim therefore as prOVided in Articles I I and 12. 7.5 Where practicable, the CONTRACTOR shall build around the work of other separate contractors or shall leave chases, slots and holes as required to receive and to conceal within the general construction Work the work of such other separate contractors as directed by them. Where such chases, slots, etc., are impracticable, the Work shall require specific approval of the CONSULTANT. 7.6 Necessary chases, slots, and holes not built or left by the CONTRACTOR shall be cut by the separate contractor requiring such alterations after approval of the CONTRACTOR. The CONTRACTOR. shall do all patching and finishing of the work of other contractors where it is cut by them and such patching and finishing shall be at the expense of CONTRACTOR 7.7 Cooperation is required in the use of site facilities and in the detailed execution of the Work. Each contractor shall coordinate their operation with those of the other Contractors for the best interest of the Work in order to prevent delay in the execution thereof. 7.8 Each of several contractors working on the Project Site shall keep themselves informed of the progress of the work of other contractors. Should lack of progress or defective workmanship on the part of other contractors interfere with the CONTRACTOR's operations, the CONTRACTOR shall notify the CONSULTANT immediately and in writing. Lack of such notice to the CONSULTANT shall be construed as acceptance by the CONTRACTOR of the Status of the work of other contractors as being satisfactory for proper coordination of CONTRACTOR's own Work. 7.9 The cost of extra Work resulting from lack of notice, untimely notice, failure to respond to notice, Defective Work or lack of coordination shall be the CONTRACTOR's cost. 7.10 The CITY reserves the right in the event the CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested, to obtain the good and/or services from other sources and deducting the cost from the Contract Price without violating the intent of the ContraCt. ARTICLE 8 -CITY'S RESPONSIBILITIES 8.1 The CITY will issue all communications to the CONTRACTOR through the CONSULTANT. 8.2 In cases of termination of employment of the CONSULTANT, the CITY will appoint a CONSULTANT whose status under the Contract Documents shall be that of the former CONSULTANT. 8.3 The CITY shall promptly furnish the data required of them under the Contract Documents. 8.4 The CITY'S duties in respect to providing lands and easements are set forth in Paragraphs 4.1 and 4.2. 8.5 The CITY shall have the right to take possession of and use any completed or partially completed portions of the Work, notwithstanding the fact that the time for completing the entire Work or any portion thereof may not have expired; but such taking possession and use shall not be deemed an acceptance of any Work not completed in accordance with the Contract Documents. ARTICLE 9 -CONSULTANTS' STATUS DURING CONSTRUCTION Cit;y's Representative: 9 .1 The CONSULTANT shall be the CITY'S representative during the construction period. The duties and responsibilities and the limitations of authority of the CONSULTANT as the CITY'S representative during © Thomas F Pepe, 2014 4!28i 20J4 Page 57 of 72 construction are set forth in Articles I through 16 of these General Conditions and shall not be extended without written consent of the CITY and the CONSULTANT. 9.1.1 The CONSULTANTs decision. in matters relating to aesthetics. shall be final. if within the terms of the Contract Documents. 9.1.2 Except as may be otherwise provided in this contract. all claims. counterclaims. disputes and other matters in question between the CITY and the CONSULTANT arising out of or relating to this Contract or the breach thereof. shall be decided in a court of competent jurisdiction within the State of Florida Visits to Site: 9.2 The CONSULTANT shall provide an inspector to make periodic visits to the site at each phase of construction to observe the progress and quality of the executed Work and to determine if the Work is proceeding in accordance with the Contract Documents. His efforts shall be directed toward providing assurance for the OWNER and all applicable regulatory agencies that construction is in compliance with the Construction Documents and applicable laws, rules and regulations. On the basis of these on site- observations as an experienced and qualified design professional, he shall keep the CITY informed of the progress of the Work and shall guard the OWNER against defects and deficiencies in the Work of CONTRACTOR. Clarificatjons and Inten>retations: 9.3 The CONSULTANT shall issue. with reasonable promptness. such written clarifications or interpretations of the Contract Documents (in the form of DraWings or otherwise) as it may determine necessary. which shall be consistent with. or reasonably inferable from. the overall intent of the Contract Documents. If the CONTRACTOR seeks an increase in the Contract Price or extension of Contract Time based on a written clarification and/or interpretation it shall be required to submit a timely claim as provided in Articles I I and 12. Measurement of Quantities: 9.4 All Work completed under the Contract shall be measured by the CONSULTANT according to the United States Standard Measures. All linear surface measurements shall be made horizontally or vertically as required by the item measured. Rejecting Defective Work: 9.5 The CONSULTANT shall have authority to disapprove or reject Work that is "Defective Work" as defined in Article I. It shall also have authority to reqUire special inspection or testing of the Work including Work fabricated on or off site, installed or completed as provided. In the event that the CONSULT ANT requires testing of completed Work, the cost of such inspections and/or testing shall be approved in writing by the CITY. All consequential cost of such inspections and testing, including but not limited to the COst of testing and inspection, the COSt of repairing any of the Work, or the work of others, the cost to move fumiture and eqUipment and/or the cost to provide alternative facilities until the repair work can be completed. shall paid by the CONTRACTOR if the Work is found to be Defective Work. Shop Drawin~, Change Orders and Payments: 9.6 In connection with the CONSULTANT responsibility as to Shop Drawings and samples. see paragraphs 6.25 through 6.28, inclusive. 9.7 In connection with the CONSULTANTs responsibility for Change Orders see Articles 10, II, and 12. 9.8 In connection with the CONSULTANT responsibilities with respect to the Application for Payment, etc., see Article 14. Decisions on Disagreements: 9.10 The CONSULTANT shall be the initial interpreter of the Construction Documents. () Thomas F. Pepe, 2014 4/28/2014 Page 58 of 72 Limitations on Consultant's Responsibilities: 9.1 I The CONSULTANT will not be responsible for the construction means, methods, techniques, sequences or procedures. or the safety precautions and programs incident thereto. 9.12 The CONSULTANT will not be responsible for the acts or omissions of the CONTRACTO~ or any Subcontractors, or any of their agent, servants or employees. or any other person performing any of the Work under or through them. ARTICLE 10 -CHANGES IN THE WORK 10. I Without invalidating the Contract, the CITY may. at any time or from time to time, order additions, deletions or revisions in or to the Work which shall only be authorized by a written Change Orders. Upon receipt of a Change Order. the CONTRACTOR shall proceed with the Work involved. All such Work shall be performed under the applicable conditions of the Contract Documents. If any authorized written Change Order causes an increase or decrease in the Contract Price or an extension or shortening of the Contract Time, an equitable adjustment will be made as provided in Article II or Article 12. A written Change Order signed by the CITY and the CONTRACTOR indicates their agreement to the terms of the Change Order. All Change Orders shall be certified by the CONSULTANT as to the appropriateness and value of the change in the Work as well as to any change in the time to complete the Work under the circumstances. The failure to include a time extension in the Change Order or in the request for a change order shall result in a waiver of any extension of time due to the change in the work as reflected in the Change Order. 10.2 The CONSULTANT may authorize minor changes or alterations in the Work not involving extra cost and not inconsistent with the overall intent of the Contract Documents without the need for a formal written Change Order provided the CONTRACTOR does not request additional time or additional compensation. These may be accomplished by a written Field Order. If the CONTRACTOR believes that any change or alteration authorized by the CONSULTANTs Field Order would entitles the CONTRACTOR to an increase in the Contract Price or extension of Contract Time, it must submit a written notice of intent to demand a Change Order within twenty four (24) hours of the issuance of the Field Order and submit a written proposal for Change Order within four (4) days thereafter, otherwise the CONTRACTOR shall be deemed to have waived such claim. 10.3 Additional Work performed by the CONTRACTOR without authorization of a written Change Order shall not entitle it to an increase in the Contract Price or an extension of the Contract Time, except in the case of an emergency as provided in paragraph 6.22 and except as provided in paragraph 10.2. 10.4 The CITY will execute appropriate Change Orders prepared by the CONSULTANT covering changes in the Work. to be performed as provided in paragraph 4.4. and Work performed in an emergency as provided in paragraph 6.22 and any other claim of the CONTRACTOR for a change in the Contract Time or the Contract Price which is approved by the CONSULTANT. 10.5 It is the CONTRACTOR'S responsibility to notify its Su rety of any changes affecting the general scope of the Work or change in the Contract Price or Contract Time and the amount of the applicable bonds shall be adjusted accordingly. The CONTRACTOR shall furnish proof of such an adjustment to the CITY before commencement of the Change Order Work. The Work shall be stopped until the CONTRACTOR provides such proof of adjustment in the Bond amount and any such delay shall be charged to the CONTRACTOR. ARTICLE II -CHANGE OF CONTRACT PRICE I 1.1 The Contract Price constitutes the total compensation payable to the CONTRACTOR for Performing the Work. All duties. responsibilities and obligations aSSigned to or undertaken by the CONTRACTOR shall be at its expense without changing the Contract Price. I 1.2 The CITY may, at any time. without written notice to the sureties. by written order designated or indicated to be a Change Order. make any change in the Work within the general scope of the Contract, including but not limited to changes to or in: I 1.2.1 Specifications (including drawings and designs); 11.2.2 Method or manner of performance of the Work. I 1.2.3 CITY-furnished facilities. equipment. materials. services. or site; or {) Thomas F. Pepe, 2014 4128!2014 Page 59 of 72 I 1.2.4 Acceleration in the performance of the Work. II J Except as provided in this section, or sections referred to in this section. no order. statement, or conduct of the CITY shall be treated as a Change Order or entitle the CONTRACTOR to an equitable adjustment unless and until the change in the Work is specifically and expressly provided for in a written Change Order, or as otherwise provided in another section of the Contract Documents. 11.4 When a Change Order is issued by the CONSULTANT and signed by the CITY or issued by the CITY in writing. the CONTRACTOR shall perfonn the Work even if the CONTRACTOR does not agree with the dollar amount of the Change Order. If any Change Order causes an increase or decrease in the CONTRACTOR'S cost of, or the time required for, the performance of any part of the Work under this Contract, for which the CITY and the CONTRACTOR cannot reach a timely agreement. an eqUitable adjustment based on the cost of the Work shall be made and the Contract modified accordingly. I 1.5 If the CONTRACTOR intends to assert a claim for an equitable adjustment or contest the equitable adiustment made by the CONSULTANT, it shall. within ten (10) calendar days after receipt of a written Change Order, submit to the CITY and CONSULTANT a written notice including a statement setting forth the general nature and monetary extent of such claim for equitable adjustment, time eXLension requested and supporting data In detennining the cost of the Change Order. the costs shall be limited to those listed in section I 1.7 and I 1.8. I 1.6 No claim by the CONTRACTOR for an equitable adjustment hereunder shall be allowed if not submitted in accordance with this section or if asserted after final payment under this Contract. I 1.7 The value of any Work covered by a Change Order or of any claim for an increase or decrease in the Contract Price shall be determined in one of the follOWing ways: I 1.7.1 By negotiated lump sum. 11.7.2 On the basis of the reasonable COSt and savings that results from the change in the Work plus a mutually agreed upon fee to the CONTRACTOR to cover overhead and profit not to exceed 15%. If the CONTRACTOR disagrees with the CONSULTANTs determination of reasonable costs, the CONTRACT shall provide a list of all costs together with backup documentation I 1.8 The tenn cost of the Work means the sum of all direct eXLra costs necessarily incurred and paid by the CONTRACTOR in the proper performance of the Change Order. Except as otherwise may be agreed to in writing by CITY. such costs shall be in amounts no higher than those prevailing in Miami-Dade County and shall include only the follOWing items: I 1.8.1 Payroll costs for employees in the direct employ of CONTRACTOR in the performance of the Work described in the Change Order under schedules of job classifications agreed upon by CITY and CONTRACTOR. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall be limited to: salaries and wages, plus the costs of fringe benefits which shall include social security contributions. unemployment, excise and payroll taXes, workers' compensation, health and retirement benefits, sick leave. vacation and holiday pay applicable thereto. Such employees shall include superintendents and foremen at the site. The expenses of performing Work after regular working hours, on Sunday or legal holidays shall be included in the above only if authorized by CITY and provided it was not in any way, whether in whole or in part the result of the fault of the CONTRACTOR due to negligence of the CONTRACTOR or those acting by or through him or due in whole or in part to Defective Work of the CONTRACTOR. 11.8.2 Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage, and manufacturers' field services required in connection therewith . The CONTRACTOR shall notify the CITY of all cash discounts that are available and offer the CITY the opportunity to deposit funds with the CONTRACTOR for the payment for items that offer a discount. Cash discounts shall accrue to CONTRACTOR unless the CONTRACTOR fails to timely notify the CITY of the discounts or if the OWNER deposits funds with CONTRACTOR with which to make payments in which cases the cash discounts shall accrue to the OWNER. All trade discounts, rebates and refunds. and all returns from sale of surplus materials and equipment shall accrue to OWNER, and CONTRACTOR shall make provisions so that they may be obtained. t(J Thomas F. Pepc:, 2014 4/28/2014 Page 60 of 72 11.8.3 Payments made by CONTRACTOR to the Subcontractors for Work performed by Subcontractors. If required by CITY, CONTRACTOR shall obtain competitive bids from Subcontractors acceptable to him and shall deliver such bids to CITY who will then determine, with the advice of the CONSULTANT, which Bids will be accepted. No subcontract shall be a cost plus contract unless approved in writing by the CITY. If a Subcontract provides that the Subcontractor is to be paid on the basis of Cost of Work plus a fee, the cOst of the Work shall be determined in accordance this section I 1.8 and in such case the word "Subcontractor" shall be substituted for the word "CONTRACTOR". 11.8.4 Rentals of all construction equipment and machinery. except hand tools. and the parts thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by CITY with the advice of CONSULTANT. and the costs of transportation. loading. unloading, installation. dismantling and removal thereof -all in accordance with terms of said rental agreements. The rental of any such equipment, machinery or parts shall cease when the use thereof is no longer necessary for the Work. I 1.8.5 Sales. use or similar taXes related to the Work, and for which CONTRACTOR is liable, imposed by any governmental authority. I 1.8.6 Payments and fees for permits and licenses. Costs for permits and licenses must be shown as a separate item. I 1.8.7 The cost of utilities. fuel and sanitary facilities at the site. I 1.8.8 Minor expenses such as telegrams. tong distance telephone calls. telephone service at the site, expressage and similar petty cash items in connection with the Work. 11.8.9 Cost of premiums for additional Bonds and insurance required solely because of changes in the Work. not to exceed two percent (2%) of the increase in the Cost of the Work 11.9 The term Cost of the Work shall NOT include any of the follOWing: 11.9.1 Payroll costs and other compensation of CONTRACTOR'S officers. executives. principals (of partnership and sale proprietorships). general managers. engineers. architects. estimators, lawyers. agents. expediters. timekeepers, clerks and other personnel employed by CONTRACTOR whether at the site or in its principal or a branch office for general administration of the Work and not specifically included in the schedule referred to in Subparagraph I 1.5. 11.9.2 Expenses of CONTRACTOR'S principal and branch offices other than its office at the site. I 1.9.3 Any part of CONTRACTOR'S capital expenses. including interest on CONTRACTOR'S capital employed for the Work and charges against CONTRACTOR for delinquent payments. 11.9.4 Cost of premiums for all bonds and for all insurance poliCies whether or not CONTRACTOR is reqUired by the Contract Documents to purchase and maintain the same (except as otherwise provided in Subparagraph 11.8.9). I 1.9.5 Costs due to the negligence of CONTRACTOR, any Subcontractor. or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective work, disposal of materials or equipment wrongly supplied and making good any damage to property. 11.9.6 Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraph I 1.8. 11.10 The CONTRACTOR'S fee which shall be allowed to CONTRACTOR for its overhead and profit shall be determined as follows: 11.10.1 A mutually acceptable firm fixed price; or if none can be agreed upon. I 1.10.2 A mutually acceptable fixed percentage (not to exceed 15%). 11.11 The amount of credit to be allowed by CONTRACTOR to OWNER for any such change which results in a net decrease in cost will be the amount of the actual net decrease in costs calculated in the same manner as provided in 11.8. When both additions and credits are involved in anyone change, the net shall be computed to include overhead and profit, identified separately. for both additions and credit, provided however, the CONTRACTOR shall not be entitled to claim lost profits for any Work not performed. C Thomas F. Pepe,2014 412812014 Page 61 of72 ARTICLE 12 -TIME FOR COMPLETION, L10UIDATED DAMAGES AND CHANGE OF THE CONTRACT TIME 12.1 Time is of the essence to this contract and the date of beginning and the time for completion of the Work are essential conditions of the Contract. Therefore, the Work shall be commenced on the date specified in the Notice to Proceed and completed within the time specified for completion of the work. 12 .2 The CONTRACTOR shall proceed with the Work at such rate of progress to ensure full completion within the Contract Time. It is expressly understood and agreed, by and between the CONTRACTOR and the OWNER, that the Contract Time for the completion of the Work described herein is a reasonable time, taking into consideration the average climatic and economic conditions and other factors prevailing in the locality of the Work. No extension of time shall be granted due conditions that the Contractor knew of or should have known of befo re bidding on the project: or due to inclement weather, except as provided in section 12.7. 12 .3 If the CONTRACTOR shaH fail to complete the Work within the Contract Time, or extension of time granted by the CITY. then the CONTRACTOR shall pay to the OWNER the amount of liquidated damages as specified in the Contract Documents for each calendar day after the scheduled date for completion as adjusted by written Change Orders that extended the completion date. 12.3 .1 These amounts are not penalties but are liquidated damages incurred by the OWNER for its inability to obtain full use of the Project. liquidated damages are hereby fixed and agreed upon between the parties, recognizing the impossibility of precisely ascertaining the amount of damages that will be sustained as a consequence of such delay, and both parties desiring to obviate any question or dispute concerning the amount of said damages and the cost and effect: of the failure of CONTRACTOR to complete the Contract on time. The above-stated liquidated damages shall apply separately to each phase of the Project for which a time for completion is given. 12.3.2 CITY is authorized to deduct the liquidated damages from monies due to CONTRACTOR for the Work under this Contract. 12 .4 The Contract Time may only be changed by a written Change Order. Any claim for an extension in the CONTRACT TIME shall be based on written notice delivered to the CITY and CONSULTANT within five (5) business days of the occurrence of the event giving rise to the claim and stating the general nature of the claim including supporting data. All claims for adjustment in the Contract Time shall be evaluated and recommended by the CONSULTANT, with final approval by the CITY'S representative. Any change in the Contract Time resulting from any such claim shall be incorporated in a written Change Order. 12.5 All time limits stated in the Contract Documents are of the essence of the Contract. 12 .6 No claim for delay shall be allowed because of failure to furnish DraWings before the expiration of fourteen (14) calendar days after demand has been made in writing to the CONSULTANT for such Drawings. Furthermore, there shall be no monetary compensation for such delay and the CONTRACTOR's sole remedy shall be an extension of time for the period of delay. 12.7 Extensions to the Contract Time for delays caused by the effects of inclement weather shall not be granted unless the weather was unusual for South Florida and could not have been anticipated, the abnormal weather is documented by records from the national weather service and the abnormal weather is documented to have had a substantial affected on the construction schedule. 12 .8 No Damages for Delay: The CONTRACTOR agrees that he shall not have any claim for damages due to delay unless the delay exceeds 6 months, whether indiVidually or cumulatively, and then the damages shall be limited to increased cost of materials that were unanticipated and that would not have been incurred but for the delay . Other than as set forth above, the only remedy for any delay shall be limited to an extension of time as provided for in Section 12.4 which shall be the sale and exclusive remedy for such resulting delay. Other than as set forth above, CONTRACTOR shall not be entitled to an increase in the Contract Price or payment or compensation of any kind from OWNER for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to, costs of acceleration or ineffic iency, overhead or lost profits, arising because of delay, disruption, interference or hindrance from any cause whatsoever, whether such delay, disruption, interference or hindrance be reasonable or unreasonable, foreseeable or unforeseeable. or avoidable or unavoidable . 12.9 The CONTRACTOR waives all claims that are not presented to the City in writing on or before the 21" day following the date of the event upon which the claim is based. co Thomas F. Pepe, 2014 4 /28/2014 Page 62 of 72 ARTICLE I 3 -GUARANTEE 13.1 The CONTRACTOR shall guarantee and unconditionally warrant through either the manufacturer or the CONTRACTOR directly, all materials and equipment fumished and Work performed for patent Defective Work for a period of one (I) year from the date of Final Acceptance as indicated in the CONSUL T ANT Letter of Recommendation of Acceptance or from the date when the defect was first observable, whichever is later. The same guarantee and unconditional warranty shall be extend for five (5) years from the date of Final Acceptance as indicated in the CONSULTANT Letter of Recommendation of Acceptance for latent Defective Work. The CITY will give notice of observed defects with reasonable prompmess. In the event that the CONTRACTOR should fail to commence to correct such Defective Work within ten (10) calendar days after having received written notice of the defect, or should the CONTRACTOR commence the corrective work, but fail to prosecute the corrective work continuously and diligently and in accordance with the Contract Documents. applicable law, rules and regulations. the CITY may declare an event of default., terminate the Contract in whole or in part and cause the Defective Work to be removed or corrected and to complete the Work at the CONTRACTOR's expense, and the CITY shall charge the CONTRACTOR the cost thereby incurred. The Performance Bond shall remain in full force and effect through the guarantee period. 13.2 The specific warranty periods Hsted in the Contract Documents, if different from the period of time listed in Section 13.1, shall take precedence over Section 13.1. I 3.3 CONTRACTOR shall act as agent.. on a limited basis for the OWNER, at the CITY's option, solely for the follow-up concerning warranty compliance for all items under manufacturer's Warranty/Guarantee and for the purpose of completing all forms for Warranty/Guarantee coverage under this Contract. 13.4 In case of default by the CONTRACTOR, the Oty of South Miami may procure the articles or services from other sources and hold the CONTRACTOR responsible for any excess costs occasioned or incurred thereby. 13.5 The CITY may withhold acceptance of. or reject items which are found upon examination. not to meet the specification requirements. Upon written notification of rejection, items shall be removed within five (5) business days by the CONTRACTOR at his own expense and redelivered at his expense. Rejected goods left longer than thirty (30) calendar days shall be regarded as abandoned and the Oty shall have the right to dispose of them as its own property and the CONTRACTOR thereby waives any claim to the good or to compensation of any kind. Rejection for non-conformance or failure to meet delivery schedules may result in the Contract being found in default.ARTICLE 14 -PAYMENTS AND COMPLETION Payments to Contractor 14. I The Contractor shall not be entitled to any money for any work performed before the issuance of a Notice to Proceed on the form described in the Contract Documents and the issuance by the City of a "purchase order", or any other document, does not and shall not authorize the commencement of the Work. At least ten (10) calendar days before each progress payment falls due (but not more often than once a month). the CONTRACTOR shall submit to the CONSULTANT a partial payment estimate filled out and Signed by the CONTRACTOR covering the Work performed during the period covered by the partial payment estimate and supported by such data as the CONSULTANT may reasonably require. All progress payment applications after the first progress payment shalt be accompanied by partial releases of lien executed by all persons, firms and corporations who have furnished labor, services or materials incorporated into the work during the period of time for which the previous progress payment was made, releasing such claims and lien rights, if any. of those persons. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and SUitably stored at or near site. the partial payment estimate shall also be accompanied by such supporting data, satisfactory to the CITY, which establishes the OWNER'S title to the material and equipment as well as certificates of insurance providing coverage for 100% of the value of said material and equipment covering the material and equipment from all casualties as well as theft, vandalism. fire and flood. The CONTRACTOR shall replace at its expense any stored materials paid for which are either damaged or stolen before installation. The CONSULTANT will within ten (10) calendar days after receipt of each partial payment estimate, either certifying in writing its approval of payment and present the partial payment estimate to the OWNER. or return the partial payment estimate to the te; Thomas F. Pepe. 2014 4/28/2014 Page 63 of 72 CONTRACTOR, indicating in writing his reasons for refusing to approve payment. In the latter case, the CONTRACTOR may make the necessary corrections and resubmit the partial payment estimate. The OWNER, will within thirty (30) calendar days of presentation to it of any approved partial payment estimate, pay the CONTRACTOR a progress payment on the basis of the approved partial payment estimate. The OWNER shall retain ten (10%) percent of the amount of each payment until Final Completion and Acceptance of all Work covered by the Contract Documents. Any interest earned on the retainage shall accrue to the benefit of the OWNER. 14.2 The CONTRACTOR, before it shall receive final payment, shall deliver to the CITY a Contractor's Final Payment Affidavit: as set forth in the Florida Construction Lien Statute as well as final releases of lien executed by all persons who have performed or furnished labor, services or materials, directly or indirectly, which was incorporated into the Work. If any person refuses to provide such a release or provides a conditional release, the CITY shall have the right to issue a joint check made payable to the CONTRACTOR and such person. ContraCtor's Warranty of Title 14.3 The CONTRACTOR warrants and guarantees that title to all Work, materials and equipment covered by an Application for Payment whether the Work, material or equipment is incorporated in the Project or not, shall have passed to the OWNER prior to the making of the Application for Payment, free and clear of all liens, claims, security interest and encumbrances (hereafter in these General Conditions referred to as "liens"); and that no Work, materials or equipment, covered by an Application for Payment, will have been acquired by the CONTRACTOR or by any other person performing the Work at the site or furnishing materials and equipment for the Project, under or pursuant to an agreement under which an interest therein or encumbrance thereon is retained by the seller or otherwise imposeq by the CONTRACTOR or such other person. Approval of Payment 14:4 The CONSULTANTs approval of any payment requested in an Application for Payment shall constitute a representation by him to the CITY, based on the CONSULTANTs on site observations of the Work in progress as an experienced professional and on his review of the Application for Payment and supporting data, that the Work has progressed to the point indicated in the Application for Payment; that, to the best his knowledge , information and belief. the quality of the Work is in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning Project upon substantial completion as defined in Article I. to the results of any subsequent testS called for in the Contract Documents and any qualifications stated in his approval); and that the CONTRACTOR is entitled to payment of the amount approved. However, by approving. any such payment the CONSULTANT shall not thereby be deemed to have represented that he made exhaustive or continuous on-site observations to check the quality or the quantity of the Work, or that he has reviewed the means, methods. techniques. sequences and procedures of construction or that he had made any examination to ascertain how or for what purpose the CONTRACTOR has used the moneys paid or to be paid to him on account of the Contract Price, or that title to any Work, materials, or equipment has passed to the OWNER free and clear of any liens. 14 .5 The CONTRACTOR shall make the follOWing certification on each request for payment: "I hereby certify that the labor and materials listed on this request for payment have been used in the construction of this Work and that all materials included in this request for payment and not yet incorporated into the construction are now on the site or stored at an approved location. and payment received from the last request for payment has been used to make payments to all his Subcontractors and suppliers, except for the amounts listed below beside the names of the persons who performed work or supplied materials". In the event that the CONTRACTOR withholds payment from a Subcontractor or Supplier, the same amount of money shall be withheld from the CONTRACTOR's payment until the issue is resolved by written agreement between them and then a joint check shall be made payable to the person in question and the CONTRACTOR in accordance with the settlement agreement, otherwise the money shall be held by the OWNER until a judgment is entered in favor of the CONTRACTOR or the person. in which rc Thomas F. Pepe.l014 4!28i2014 Page 64 of 72 case the money shall be paid according with said judgment. Nothing contained herein shall indicate an intent to benefit any third persons who are not signatories to the Contract. 14.6 The CONSULTANT may refuse to approve the whole or any part of any payment if, in its opinion, it is unable to make such representations to the OWNER as reqUired this Section 14. It may also refuse to approve any payment, or it may void any prior payment application certification because of subsequendy discovered evidence or the results of subsequent inspection or tests to such extent as may be necessary in its opinion to protect the OWNER from loss because: 14.6.1 of Defective Work. or completed Work has been damaged requiring correction or replacement, 14.6.2 the Work for which payment is requested cannot be verified, 14.6.3 claims of Liens have been filed or received. or there is reasonable evidence indicating the probable filing or receipt thereof. 14.6.4 the Contract Price has been reduced because of modifications, 14.6.5 the CITY has correct Defective Work or completed the Work in accordance with Article r 3. 14.6.6 ·of unsatisfactory prosecution of the Work. including failure to clean up as required by paragraphs 6.29 and 6.30. 14.6.7 of persistent failure to cooperate with other contractors on the Project and persistent failure to carry out the Work in accordance with the Contract Documents. 14.6 .8 of liquidated damages payable by the CONTRACTOR, or 14.6.9 of any other violation of. or failure to comply with provisions of the Contract Documents. 14.7 Prior to Final Acceptance the OWNER, with the approval of the CONSULTANT, may use any completed or substantially completed portions of the Work provided such use does not interfere with the CONTRACTOR's completion of the Work. Such use shall not constitute an acceptance of such portions of the Work. 14.8 The CITY shall have the right to enter the premises for the purpose of doing Work not covered by the Contract Documents. This provision shall not be construed as relieving the CONTRACTOR of the sole responsibility for the care and protection of the Work. or the restoration of any damaged Work except such as may be caused by agents or employees of the OWNER. 14.9 Upon completion and acceptance of the Work the CONSULTANT shall issue a Certificate attached to the Final Application for Payment that the Work has been accepted by it under the conditions of the Contract Documents. The entire balance found to be due the CONTRACTOR, including the retained percentages. but except such sums as may be lawfully retained by the OWNER, shall be paid to the CONTRACTOR within thirty (30) calendar days of completion and acceptance of the Work. 14.10 Upon The awarded CONTRACTOR will be strongly encouraged to register as an ePayables Vendor with the Owner. The Bank of America ePayables Solution is an automated card payment process that shifts accounts payable disbursements to corporate purchasing cards. ePayables. streamline the process of making payments to your organization going forward. the City will provide the CONTRACTOR with a credit card account number to keep on file. This card has unique security features. with $0 of available funds until an invoice is approved for payment. After an invoice has received proper and complete approval. an electronic remittance advice will be sent via e-mail. or fax. which notifies the CONTRACTOR that the funds have been transferred in to the account linked to the card for the amount listed on the invoice and/or remittance email. Please refer to the ePayables Questions & Answers Form contained in this RFP or contact the OWNER's Finance department at (305) 663-6343 with any questions. Acceptance of Final Payment as Release 14.1 I The Acceptance by the CONTRACTOR of Final Payment shall be and shall operate as a release to the OWNER and a waiver of all claims and all liability to the CONTRACTOR other than claims preViously filed and unresolved. The waiver shall include all things done or furnished in connection with the Work and for every act and neglect of the OWNER and others relating to or arising out of this Work. Any payment, however. final or otherwise. shall not release the CONTRACTOR or its sureties from any obligations under the Contract Documents or the Performance Bond and Payment Bonds. 14.12 The CONSULTANT may void any certification of Substantial Completion or Final Completion of the Work as may be necessary in his opinion to protect the OWNER from loss if he determines. because of subsequently discovered evidence or the results of subsequent inspection or tests, that: IC Thomas F. Pepe, 2014 4/2812014 Page 6S of 72 14.12.1 the Work is defective, or that the completed Work has been damaged due to the fault of the CONTRACTOR or any individual or entity operating under or through it requiring correction or replacement to the extent that the project is no longer Substantially Completed, or in the case of Final Completion certification, is no longer Finally Competed. 14.12.2 the Work necessary to be completed for the purpose of certifying the work as being Substantially Completed or Finally Completed cannot be verified, 14.12..3 claims or Uens have been filed or received, or there is reasonable evidence indicating the probable filing or receipt thereof that. if valid and paid, would reduce the amount owing to the CONTRACTOR BY 20% in the case of Substantial Completion and 5% in the case of Final Completion. 14.12.5 there is Defective Work the value of which, if deducted from the contract price would reduce the amount owing to the CONTRACTOR BY 20% in the case of SubStantial Completion and 5% in the case of Final Completion. 14.13 If the CONSULTANT de-certifies any portion of the Work that was certified ("Initial Certification") by the CONSULTANT, the CONTRACTOR shall repay to the City of South Miami any money paid as a result of said Initial Certification being issued which shall be paid only when the decertified work is re-certified. ARTI CLE 15 -SUSPENSION OF WORK AND TERMINATION 15.1 The CITY may. at any time and without cause. suspend the Work or any portion thereof for a period of not more than ninety (90) calendar days by notice in writing to the CONTRACTOR and the CONSULTANT. which shall fix the date on which Work shall be resumed. The CONTRACTOR shalf be allowed an increase in the Contract Price or an extension of the Contract Time, or both. directly attributable to any suspension and if a claim is timely made and if it is allowed under the terms of Articles " or Article 12 . City May Terminate 15.2 If the CONTRACTOR is adjudged bankrupt or insolvent. or if he makes a general assignment for the benefit of its creditors, or if a trustee or receiver is appointed for the CONTRACTOR or for any its property, or if he files a petition to take advantage of any debtor's act. or to reorganize under bankruptcy or similar laws. or if he repeatedly fails to supply sufficient skilled workmen or suitable materials or equipment. or if he repeatedly fails to make prompt payments to Subcontractors or for labor. materials or equipment or he disregards laws . ordinances. rules, regulations or orders of any public body having jurisdiction. or if he disregards the authority of the CONSULTANT, or if he otherwise violates any provision of. the Contract Documents, then the CITY may, without prejudice to any other right or remedy and after giving the CONTRACTOR and the Surety seven (7) calendar days written notice, terminate the services of the CONTRACTOR and take possession of the Project and of all materials. equipment. tools, construction equipment and machinery thereon owned by the CONTRACTOR, and finish the Work by whatever method it may deem expedient. In such case the CONTRACTOR shall not be entitled to receive any further payment until the Work is finished. If the unpaid balance of the Contract Price exceeds the direct and indirect costs of completing the Project, including compensation for additional professional services. such excess shall be paid to the CONTRACTOR. If such costs exceed such unpaid balance. the CONTRACTOR or the Surety on the Performance Bond shall pay the difference to the OWNER. Such costs incurred by the OWNER shall be determined by the CONSULTANT and incorporated in a Change Order. If after termination of the CONTRACTOR under this Section. it is determined by a court of competent jurisdiction for any reason that the CONTRACTOR was not in default, the rights and obligations of the OWNER and the CONTRACTOR shall be the same as if the termination had been issued pursuant to Section 15.5 15.3 Where the CONTRACTOR'S services have been so termillated by the CITY said termination shall not affect any rights of the OWNER against the CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys by the OWNER due the CONTRACTOR shall not release the CONTRACTOR from liability. ~, Thomas F. Pepe, 2014 4128/2014 Page 66 of 72 15.4 Upon seven (7) calendar days written notice to the CONTRACTOR and the CONSULTANT, the CITY may, without cause and without prejudice to any other right or remedy, elect to terminate the Contract for the convenience of the OWNER. In such case, the CONTRACTOR shall be paid for all Work executed and accepted by the CITY as of the date of the termination, minus any deduction for damage or Defective Work. No payment shall be made for profit for Work which has not been performed. 15.4A The CITY reserves the right in the event the CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested. to obtain the good and/or services from other sources and deducting the cost from the Contract Price without violating the intent of the Contract. Removal of Equipment 15.5 In the case of termination of this Contract before completion for any cause whatever. the CONTRACTOR. rf notified to do so by the CITY. shall promptly remove any part or all of its equipment and supplies from the property of the OWNER. Should the CONTRACTOR not remove such equipment and supplies, the CITY shall have the right to remove them at the expense of the CONTRACTOR and the CONTRACTOR agrees that the OWNER shall not be liable for loss or damage to such equipment or supplies. Equipment and supplies shall not be construed to include such items for which the CONTRACTOR has been paid in whole or in part. Contractor May Stop Work or Terminate 15.6 If. through no act or fau~ of the CONTRACTOR, the Work is suspended for a period of more than ninety (90) calendar days by the CITY or by order of other public authority. or under an order of court or the CONSULTANT fails to act on any Application for Payment within thirty (30) calendar days after it is submitted. or the OWNER fails to pay the CONTRACTOR any sum approved by the CONSULTANT, within thirty (30) calendar days of its approval. and presentation, then the CONTRACTOR may, upon twenty (20) calendar days written notice to the CITY and the CONSULTANT, terminate the Contract. The CITY may remedy the delay or neglect within the twenty (20) calendar day time frame. If timely remedied by the CITY the Contract shall not be considered terminated. In lieu of terminating the Contract, rf the CONSULTANT has failed to act on an Application for Payment or the OWNER has failed to make any payment as afore said, the CONTRACTOR may upon ten (10) calendar days' notice to the CITY and the CONSULTANT stop the Work until it has been paid all amounts then due. Indemnification of Independent Consultant. 15.7 The CONTRACTOR and the CITY hereby acknowledges that if the CONSULTANT is an independent contractor of the OWNER, the CONSULTANT may be reluctant to rule on any disputes concerning the Contract Documents or on the performance of the CONTRACTOR or the OWNER pursuant to the terms of the Contract Documents. Therefore, the OWNER. at the CONSULTANTs request, agrees to provide the CONSULTANT with a written indemnification and hold harmless agreement to indemnify and hold the CONSULTANT harmless as to any decision in this regard before the CONSULTANT makes an interpretation. de-certifies a payment application. decertifies Substantial Completion. decertifies Final Completion. certifies an event of default. or approves any action which requires the approval of the CONSULTANT. ARTICLE 16 -MISCELLANEOUS 16.1 Whenever any provision of the Contract Documents requires the giving of written notice it shall be deemed to have been validly given if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or if delivered at or sent by regis~ered or certified mail, postage prepaid. to the last known business address. 16.2 The Con~ract Documents shall remain the property of the OWNER. The CONTRACTOR and the CONSULTANT shall have the right to keep one record set of the Contract Documents upon completion of the Project. 16.3 The duties and obligations imposed by these General Conditions. Special Conditions and Supplemental Conditions. if any, and the rights and remedies available hereunder, and, in particular but without limitation. the warranties, guarantees and obligations imposed upon CONTRACTOR by the Contract © Thomas F. Pepe, 2014 4128/2014 Page 67 of 72 Documents and the rights and remedies available to the OWNER and CONSULTANT thereunder. shall be in addition to, and shaH not be construed in any way as a limitation of. any rights and remedies available by law. by special guarantee or by other provisions of the Contract Documents. 16.4 Should the OWNER or the CONTRACTOR suffer injury or damage to its person or property because of any error. omission. or act of the other or of any of their employees or agents or others for whose acts they are legally liable, claim shall be made in writing to the other party within twenty one (21) calendar days of the first observance of such injury or damage. ARTICLE 17 -WAIVER Of IURY TRIAL 17.1 OWNER and CONTRACTOR knowingly. irrevocably voluntarily and intentionally waive any right either may have to a trial by jury in State or federal Court procee<lings in respect to any action. proceeding. lawsuit or counterclaim arising out of the Contract Documents or the performance of the Work thereunder. ARTICLE 18 -ATTORNEYS fEES JURISDICTION I VENUE I GOVERNING LAW 18. I The Contract shall be construed in accordance with and governe<l by the law of the State of Florida. f 8.2 The parties submit to the jurisdiction of any COUrt of competent jurisdiction in Florida regarding any claim or action arising out of or relating to the Contract or Contract Documents. Venue of any action to enforce the Contract shall be in Miami-Dade County. Florida. 18.3 If either the CITY or CONTRACTOR seeks to enforce the terms of the Contract by court proceedings. the prevailing party shall be entitled to recover all such costs and expenses. including. but not limited to. court costs, and reasonable attorney's fees . 18.4 Except as may be otherwise provided in the Contract Documents. all claims. counterclaims. disputes and other matters in question between the OWNER and the CONTRACTOR arising out of or relating to this Contract or the breach thereof, shall be decided in a court of competent jurisdiction within the State of Florida. ARTICLE 19 -PROIECT RECORDS 19.1 The CITY shall have right to inspect and copy during regular business hours at OWNER'S expense. the books and records and accounts of CONTRACTOR which relate in any way to the Project, and to any claim for additional compensation made by CONTRACTOR, and to conduct an audit of the financial and accounting records of CONTRACTOR which relate to the Project. CONTRACTOR shall retain and make available to CITY all such books and records and accounts, financial or otherwise. which relate to the Project and to any claim for a period of three (3) years following final completion of the Project. During the Project and the three (3) year period following final completion of the Project. CONTRACTOR shall provide CITY access to its books and records upon five (5) business day's written notice. 19.2 CONTRACTOR and all of its subcontractors are reqUired to comply with the public records law (s. I 19.070 I) while providing services on behalf of the OWNER and the CONTRACTOR. under such conditions. shall incorporate this paragraph in all of its subcontracts for this Project. CONTRACTOR and itS subcontractors are specifically required to: (a) Keep and maintain public records that ordinarily and necessarily would be required by the public agency in order to perform the service; (b) Provide the public with access to public records on the same terms and conditions that the public agency would prOVide the records and at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law; (c) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law; and (d) Meet all requirements for retaining public records and transfer. at no cost, to the public agency all public records in possession of the contractor upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirementS. All records stored electronically must be provided to the public agency in a format that is compatible with the information technology systems of the public agency. ~ Thomas F Pepe.2014 4i28l2014 Page 68 of 72 19.3 If CONTRACCTOR or its subcontractor does not comply with a public records request. the CITY shall have the right to enforce this contract provision by specific performance and the person who violates this proviSion shall be liable to OWNER for its costs of enforcing this provision, including attorney fees incurred in all proceedings, whether administrative or civil court and in all appellate proceedings. ARTICLE 20 -SEVERABILITY 20.1 If any provision of the Contract or the application thereof to any person or situation shall to any extent, be held invalid or unenforceable, the remainder of the Contract, and the application of such provisions to persons or situations other than those as to which it shall have been held invalid or unenforceable shall not be affected thereby, and shall continue in full force and effect, and be enforced to the fullest extent permitted by law. ARTICLE 21 -INDEPENPENT CONTRACTOR 21.1 The CONTRACTOR is an independent CONTRACTOR under the Contract. Services provided by the CONTRACTOR shall be by employees of the CONTRACTOR and subject to supervision by the CONTRACTOR, and not as officers, employees, or agents of the OWNER. Personnel policies, taX responsibilities, social security and health insurance, employee benefits, purchasing policies and other similar administrative procedures, applicable to services rendered under the Contract shall be those of the CONTRACTOR. ARTICLE 22 -ASSIGNMENT 22.1 The CONTRACTOR shall not transfer or assign the performance, duties, obligations and responsibilities reqUired by the Contract without prior written consent of the City. CONTRACTOR shall not assign or transfer its rights under this Agreement without the express written consent of the City. The City will not unreasonably withhold and/or delay its consent to the assignment of the CONTRACTOR's rights. The City may, in its sole discretion, allow the CONTRACTOR to assign its duties, obligations and responsibilities provided the assignee meets all of the City's requirements to the City's sole satisfaction, executes all of the Contract Documents that were required to be executed by the CONTRACTOR and provided the CONTRACTOR remains jointly and severally liable for any breach of the Agreement by the assignee. IN WITNESS WHEREOF, the parties hereto have executed the General Conditions to acknowledge their inclusion as part of the Contract Documents on this __ day of . 20 __ , WITNESSES: CONTRACTOR: Signature: ,.--__________ _ Name: ___________ _ Title: ___________ _ AUTHENTICATION : OWNER: CITY OF SOUTH MIAMI Signature: ___ ----------- Maria Menendez City Clerk Read and Approved as to Form, Linguage, Legality, and Execution Thereof: Signature: ______ --------- City Attorney e Thomas F. Pep<:. 2014 4.'28/2014 Signature: ______________ _ Steven Alexander. City Manager Page 69 of 72 Supplementary Conditions Sunset Drive Downtown Median A. Consultant In accordanc.e with ARTICLE 1 of the General Conditions CONSULTANT is defined as the th~person identified as the CONSULTANT in the Supplementary Conditions or if none, then CITY's designated represeritatlve as identified in me Supplementary Conditions. The CONSULTANT's. if any, and the City's Designated Representative's name, address, telephone number and facsimile number are as follows: Consultant City's Designated Representative Ricardo A. Ayala, PE Capital Improvement Project Manager 4795 SW 75 Ave 400 Miami, FI. 33155 Phone 305-403-20n Fax 305--668-n08 B. Supplemental Definition: Work that does not conform to the Contract Documents indudes work that is unsatisfactory, faulty, or deficient or that does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents, or has been damaged prior to CONSULTANTs recommendation of final payment (unless responsibility for the protection thereof has been assumed in writing by CITY). C. Termination or Substitution: Nothing herein shall prevent the CITY from terminating the services of the CONSULTANT or from substituting another "person" as to act as the CONSULTANT. D. Disputes: If any dispute concerning a question of fact arises under the Contract, other than termination for default or convenience, the CONTRACTOR and the city department responsible for the administration of the Contract shall make a good faith effort to resolve the dispute. If the dispute cannot be resolved by agreement, then the department with the advice of the City Attorney and the CONSULTANT shall rule on the disputed issue and send a written copy of its decision to the CONTRACTOR, which shall be binding on both parties. E. Non-conformance to Contract The City of South Miami may withhold acceptance of, or reject items which are found upon examination. not to meet the specification requirements or conform to the plans and drawings. Upon written notification of rejection. items shall be removed or un installed within five (5) business days by the CONTRACTOR at his own expense and redelivered andlor reinstalled at his expense. Rejected goods left longer than thirty (30) calendar days shall be regarded as abandoned and the CITY shall have the right to dispose of them as its own property and the CONTRACTOR thereby waives any claim to the good or to compensation of any kind for said goods. Rejection for non-conformance or failure to meet delivery schedules may result in the CONTRACTOR being found in default F. Default Provision: In case of default by the CONTRACTOR, the City of South Miami may procure the articles or services from other sources and hold the CONTRACTOR responsible for any excess costs occasioned or incurred thereby G. Secondary/Other Contractors: The CITY reserves the right in the event the CONTRACTOR cannot provide an item(s) or service(s) in a timely manner as requested. to obtain the good andlor services from other sources and deducting the cost from the Contract Price without violating the intent of the Contract. H. Assignment The CONTRACTOR shall not transfer or assign any of its rights or duties, obligations and responsibilities arising under the terms, conditions and proviSions of this Contract without prior written consent of the City Manager.. The CITY will not unreasonably withhold andlor delay its consent to the assignment of !Q Thomas F. Pepe. 2014 4/2812014 Page 70 of 72 the CONTRACTOR's rights. The CITY may, in its sole and absolute discretion. refuse to allow the CONTRACTOR to assign its duties. obligations and responsibilities. In any event, the CITY shall not consent to such assignment unless CONTRACTOR remains jointly and severally liable for any breach of the Agreement by the assignee. the assignee meets all of the CITY's requirements to the CITY's sole satisfaction and executes all of the Contract Documents that were required to be executed by the CONTRACTOR.. I. Plans for Construction: The successful CONTRACTOR r will be furnished four sets of Contract Documents without charge. Any additional copies required will be furnished to the CONTRACTOR at a cost to the CONTRACTOR equal to the reproduction cost. J Warranty/Guarantee: CONTRACTOR shall act as agent. on a limited basis for the OWNER, solely for the follow-up concerning warranty compliance for all items under manufacturer's Warranty/Guarantee and for the purpose of completing all forms for Warranty/Guarantee coverage under this Contract. IN WITNESS WHEREOF. the parties hereto have executed the Supplementary Conditions to acknowledge their inclusion as part of the Contract on this __ day of . 20_. WITNESSES: AUTHENTICATION: Signature: ----, ______ -----:----------- Maria Menendez City Clerk Read and Approved as to Form. Language, Legality, and Execution Thereof: Signature: --::::--____________________ _ City Attorney '" Thomas F. Pepe. 2014 4/28/2014 CONTRACTOR: ________________________ _ Signature: ______________ _ Name: ________________________________ __ OWNER: Signature: END OF SECTION Title: CITY OF SOUTH MIAMI Steven Alexander City Manager Page 71 of72 TO: NOTICE TO PROCEED Sunset Drive Downtown Median DATE: PROJECT DESCRIPTION: <<PROJECT» in accordance with Pfans and Contract: Documents as may be prepared in whole or in part by < >, You are hereby notified to commence Work in accordance with the Contract dated ~:-----:=-~ ___ _ on or before . You are to complete me work within 30 days. The date of completion of all Work is therefore City of South Miami B~ __ ~ __ ~ ____________ _ Steven Alexander. City Manager ACCEPTANCE OF NOTICE Receipt of the above Notice to Proceed is hereby acknowledged by ______________ __ on this __ day of _______ , 20 __ , BY: nTLE: ___________ _ <0 Thomas F. Pepe. 2014 412812014 END OF DOCUMENT Page 72 of 72 sou tOO iami U{1, Ul, Or Pl~ASM'T liVING ADDENDUM No. #1 Project Name: Sunset Drive Downtown Median RFPNO. PW2014-04 Date: June 3, 2014 Sent: Fax/E-maiVwebpage This addendum submission is issued to clarify, supplement and/or modify the previously issued Request for Qualifications (RFQ) Documents, and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. Question #) : I have a question for the above referenced Request For Proposal. What is the estimated budget? Answer to Question #1: The line item in the City's FY 2014 Budget, Capital Improvements Projects (CIP) 5-Year Plan is titled "Sunset Drive Median Construction," under Roadway Infrastructure. A copy of the CIP 5-Year Plan is attached. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAY BE ISSUED FOR A SPECIFIC SOLICITATION. Page 1 ofl rt South rMiami IHf t ll,(fH flr\~.·\"',1 !:\o ... ,( ADDENDUM No. #2 Project Name: Sunset Drive Downtown Median RFP NO. PW-2014-04 Date: June 6, 2014 Sent: FaxJE-mail/webpage This addendum submission is issued to clarify, supplement andlor modify the previously issued Request for Qualifications (RFQ) Documents, and is hereby made part of the Documents. All requirements of the Documents not modified herein shall remain in full force and effect as originally set forth. It shall be the sole responsibility of the bidder to secure Addendums that may be issued for a specific solicitation. Question #1: In the Scope of Services, Section IV. "Project Duration" that section indicates work is to be perfonned during the night hours from II PM to 5 AM. What are the preferred days of the week? Answer to Question #1: The work for this project is to be perfonned Monday through Friday from II PM to 5 AM. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO SECURE ADDENDUMS THAT MAYBE ISSUED FOR A SPECIFIC SOLICITATION. Page 1 of 1 JVA Engineering Contractor, Inc. 1 Maria G. Gutierrez Project Coordinator Office Organization Chart Jose M. Alvarez President I I Cesar Gonzalez PM/Superintendent -I Juan C. Cardenas Plan Designer JVA Engineering Contractor, Inc. Project: Sunset Drive Downtown Median From SW 57 th Court to SW 58 th Avenue Jose M. Alvarez Project Manager Cesar Gonzalez Superintendent Drainage Crew & Restoration Crew JVA Engineering Contractor, Inc Organizational Chart Jose M . Alvarez President I r 1 I Jose Alvarez Juan C. Cardenas Maria G. Gutierrez VP of Operation! General Manager Office Managerl Construction Safety Director I I I 1 Cessr Gonzalez Pedro Luis Lopez, Edgar Vazquez Civil Engineer! Civil Engineer! Comptroller Estimator Surveyor I Rogelio Milian Surveying Team -Project Manager Rene Arevalo F: .-General ~ Landscaping Sub Superintendent ... JVA Site Crews Miami-Dade B@nch 6600 NW 32 Ave Miami, Fl33147 ExPerience i. i :l .~ Ph: (305) 696-7902 Fax: (305) 696r7903 e-mail: jma@jvaengineering.com '" Jose Mario Alvarez 2002-Current President JVA Engineering Contractor, Inc. 2013 City of Miami-Citywide Sewer Repair Contract, M-0083 Installation and Repair of the Storm Sewer system at locations citywide 2013 City of Miami-Miami River Greenway NW 5th Bridge Extension Fumishing all materials, labor, and equipment, necessary for road improvements, drainage system installations, milling and resurfacing, new sidewalks replacement, striping, signs, landscaping, hardscape, decorative street and pedestrian lighting, and ADA compliant ramps 2012 City of Hollywood-Distribution Piping Upgrade for Existing Condition N 56th Ave from Douglas Street to Stirling Road to N 58th Avenue, Fumish and Install 8-inch OJ. Pipe and all 0.1. Fittings 2012 Miami-Dade Water & Sewer Im provem ents -Fumish & Install 36-lnch 0.1. Water Main in NW 87th Avenue, Approximate ly 1,905 L F of 36-lnch and 25 LF of 6-inch ductile iron pipe and fittin gs for a wate r ma in in NW 87th Avenue from NW 154 Street to NW 186 Street, Section 10, 15, and 16 2011 Miami-Dade Water & Sewer Improvements-Perrine/Cutler Ridge Water & Sewer Improvements Basin A P0067-4,991 LF of Water Main Installation, 5,035 LF of Sanitary Sewer Installation and 848 LF of 12" Gravity Sewer Installation, Sewer Lateral Installations and Restoration 2011 Miami-Dade Aviation Department-MIA NW 67th Ave and NW 36th Street Intersection Improvements, Land Clearing, Excavation, Earthwork, Pre- Stressed Concrete Pipe Storm Sewer Distribution, Subgrade, Base and Asphalt Pavement 2011 City of Miami-Kinloch Storm Sewer and Road Construction Project, Storm Drainage Distribution, Asphalt Pavement, and Concrete Work 2010 Marlins Ballpark, Storm Water Distribution 2009 Miami-Dade Water & Sewer-8" Water Main Extension, Excavation Water Main Distribution, Restoration including Asphalt Pavement, and Concrete work 2009 Miami-Dade County Water & Sewer Department, NAP Misc. 12" Sanitary Sewer and Force Main Improvements, sanitary sewer and force main replacements, asphalt restoration, concrete restoration. 2009 Miami-Dade County Water & Sewer Department, Pump Station No. 57 Upgrade Sewage Pump Station including place suitable backfill material; refurbish wet well; electrical work, concrete sidewalk; and restoration 2009 Miami-Dade County Water & Sewer Department, Pump Station No. 46 Upgrade Sewage Pump Station including place suitable backfill material; refurbish wet well; electrical work, concrete sidewalk; and restoration 2009 Port of Miami, Cruise Terminal D&E Runway Extension for PBB and Mooring Bollards Construction of reinforced concrete runway and wheel pad slabs; compression auger cast piles; mooring bollards foundation concrete caps; tension auger cast piles; procurement and installation of six mooring bollards and demolition of abandoned electrical bays 2009 Port of Miami, Fender/Curb/Pad Eye Plate Repairs And Installation- Gantry Area Installation of fenders, _pad eyes, and curbs for seawall. :2008 Miami-Dade Public Works , Rdwy Widening of 97 tl1 Ave Clearing & Grubbing, Excavation, Lim erock Base , Milling, Paving, Concrete Work, Fencing & Guardrails, Electrical Work, Roadway Widening Sign age , Pavement Markings & Signage, and Construction of New Roads 2008 Alvarez Engineers, Waterstone Way Widening at SW 312 St Clearing & Grubbing, Excavation, Limerock Base, Milling, Drainage, Manhole Installations, Paving, Concrete Work, Fencing & Guardrails, Electrical Work, Roadway Widening Signage, Pavement Markings & Signage 2008 FOOT, SR 959 Rdwy Improvements Excavation, Drainage Limerock Base, Milling, Paving, Signage, Pavement Markings 2008 John Moriarty & Associates of Florida Icon Brickell Site Work, Storm Drainage System, Sanitary Sewer System and Water Distribution, Asphalt Pavement, Concrete Work, Pavement Markings & Signage 2008 Miami-Dade Water & Sewer Department, Nap Misc. 12" Sanitary Sewer and Force Main Project Installation of 12" DIP Sewage Force Main, 12" DIP Gravity Sewer, Manhole installation and Pavement Repairs 2008 Miami-Dade County Water & Sewer Department, Installation of 24" 01 Water Main, Construction of 24" Iron Ductile Water Main sub aqueous crossing canal C103 2008 Village of Pinecrest, Public Works Complex Drainage and Asphalt Resurfacing, Drainage and Asphalt Resurfacing 2008 City of South Miami, City Hall Water Main Improvements, Installation of 12" Water Main along Sunset Dr. and Asphalt Restoration 2008 Miami-Dade County, WASD Roadway Rehabilitation, Street Asphalt Pavement Rehabilitation 2008 Coreland Construction Co, Opa-Locka Head Start Facility, Storm Drainage System, Sanitary Sewer System, Water Distribution, Asphalt Pavement 2007 Miami-Dade County Park & Recreation Department, Biscayne Garden Park Improvements, Grading, Drainage, & Sidewalk 2007 KM Plaza, Town Center One at Dadeland, Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2007 Tri -C Construction Co, Inc. -CVS Pharmacy #6732 87 & Flagler Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2007 Robertson Properties Group -Nationwide Theaters, W. Flagler St Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2007 City of Sweetwater -Various Street Improvements Storm Drainage System, Sidewalks & Asphalt Paving 2006 John Moriarty & Associates of Florida, Inc. -Trump Tower If Site Work, Storm Drainage System, Sanitary Sewer System and Water Distribution 2006 John Moriarty & Associates of Florida, Inc. -Trump Tower III Site Work, Storm Drainage System, Sanitary Sewer System and Water Distribution 2005 Tri -C Construction Co, Inc. -CVS Pharmacy #5897 3ih & 199th Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution 2005 Tri -C Construction Co, Inc. -CVS Pharmacy #7131 Kendall & 127th Site Work, Asphalt Paving, Concrete, Storm Drainage System, Sanitary Sewer System and Water Distribution ~tions Education 2009 -2012 2010 Army Corp of Engineers-Quality Control Manager OSHA 30-Hour state of Florida Certified General Contractor #CGC1516849 Certified Underground Utility Contractor #CUC1224696 Broward License Primary Pipelines License # 07-1A14144-X Major Roads Ucense # 07-3A-14148-X Miami Dade County License Engineering Contractor License # E221300 2002-Current Associate in Arts 1999-2002 High School Diploma Miami Dade Community College South West High School Diploma Miami, A Miami, FI Miami-Dade BranctJ 6600 NW 32 Ave Miami, Fl33147 Experielace Ph: (305) 696-7902 Fax: (305) 696-7903 e-mail: cg@jvaengineering.com Cesar Gonzalez 2009-Present JVA Engineering Contractor, Inc. Project Manager 2013 City of Miami-Citywide Sewer Repair Contract, M-0083 Installation and Repair of the Storm Sewer system at locations citywide 2013 City of Miami-Miami River Greenway NW 5tn Bridge Extension Furnishing all materials, labor, and eqUipment, necessary for road improvements, drainage system installations, milling and resurfacing, new sidewalks replacement, striping, signs, landscaping, hardscape, decorative street and pedestrian lighting, and ADA compliant ramps 2012 City of Opa-Locka-143'd Street Distribution Piping Project, Roadway Reconstruction 2012 City of Hollywood-Distribution Piping Upgrade for EXisting Condition N 56m Ave from Douglas Street to Stirling Road to N 58th Avenue, Furnish and Install 8-inch D.1. Pipe and all D.l. Fittings 2012 Miami-Dade Water & Sewer Improvements-Furnish & Install 36-lnch D.1. Water Main in NW 87m Avenue, Approximately 1,905 LF of 36-lnch and 25 LF of 6-inch ductile iron pipe and fittings for a water main in NW 87th Avenue from NW 154 Street to NW 186 Street, Section 10, 15, and 16 2011 Miami-Dade Water & Sewer Improvements-Perrine/Cutler Ridge Water & Sewer Improvements Basin A P0067-4,991 LF of Water Main Installation, 5,035 LF of Sanitary Sewer Installation and 848 LF of 12" Gravity Sewer Installation , Sewer Lateral Installations and Restoration 2011 Miami-Dade Aviation Department-MIA NW 67th Ave and NW 36 th Street Intersection Improvements, Land Clearing, Excavation, Earthwork, Pre- Stressed Concrete Pipe Storm Sewer Distribution, Subgrade, Base and Asphalt Pavement 2011 City of Miami-Kinloch Storm Sewer and Road Construction Project, Storm Drainage Distribution, Asphalt Pavement, and Concrete Work 2010 Marlins Ballpark, Storm Water Distribution 2009 Miami-Dade Water & Sewer-8" Water Main Extension , Excavation Water Main Distribution , Restoration including Asphalt Pavement. and Concrete work 2009 Miami-Dade County Water & Sewer Department, NAP Misc. 12" Sanitary Sewer and Force Main Improvements, sanitary sewer and force main replacements, asphalt restoration, concrete restoration. 2009 Miami-Dade County Water & Sewer Department, Pump Station No. 57 Upgrade Sewage Pump Station including place suitable backfill material; refurbish wet well ; electrical work, concrete sidewalk; and restoration 2009 Miami-Dade County Water & Sewer Department, Pump Station No. 46 Upgrade Sewage Pump Station including place suitable backfill material; refurbish wet well; electrical work , concrete sidewalk; and restoration 2009 Port of Miami. Cruise Terminal D&E Runway Extension for PBB and Mooring Bollards Construction of reinforced concrete runway and wheel pad slabs; compression auger cast piles; mooring bollards foundation concrete caps; tension auger cast piles; procurement and installation of six mooring bollards and demolition of abandoned electrical bays 2009 Pori of Miam i, Fender/Curb/Pad Eye Plate Repairs And Installation- Gantry Area Installation of fenders, pad eyes, and curbs for seawalL System and Water Distributio-n E ....... G ........ EEFtI ....... G CONTRACTOR. INC_ June 13,2014 City of South Miami 6130 Sunset Drive South Miami, FL 33143 Attn: City Manager Re: JVA Engineering Contractors' Past Experience and Corporate References Please allow this letter to serve as an official listing of our active and completed jobs for the past five years. The following list provides corporate References for each project that can speak of our professional competency, manpower and financial capability to perform your project: RFP #PW-2014-04 Sunset Drive Downtown Median. The following is an official list of JVA's completed and active projects from private and government sectors and corporate references that can verify our competency and reliability. All of the projects below were fully executed and submitted on a timely manner. JVA Engineering Contractor, Inc. provided all manpower, eqUipment, and maintenance facilities for the completion of these: Tri-C Construction Co., Inc. 100 W. Cypress Creek Rd. Ft. Lauderdale, FL 33309 Contact: Chris Lawrence Phone: (954) 677-0356 Fax: (954) 6n-0359 2005 Tri -C Construction Co, Inc. -CVS Pharmacy #5897 37th & 199th Completion Date: January 2006 Amount: $371,260.00 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. 2005 Tri -C Construction Co, Inc. -CVS Pharmacy #7131 Kendall & 127th Completion Date: February 2006 6600 rNV 32"d Ave Miami, FL 33147 Tel: 305-696-7902·Fax: 305-696-7903 Amount: $323,856.31 Scope of work: Water Distributio(l, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. 2007 Tri -C Construction Co, Inc. -CVS Pharmacy # 6732 87th & Flagler Completion Date: August 2007 Amount: $688,823.453 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. John Moriarty & Associates of Florida, Ind. 1942 Tyler Street Hollywood, FL 33020 Contact: Bill Suarez Phone: (954) 261-0781 Fax: (305) 944-5352 2006 John Moriarty & Associates of Florida, Inc. -Trump Tower II Amount: $288,359.00 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. 2006 John Moriarty & Associates of Florida, Inc. -Trump Tower III Amount: $ 298,024.00 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. MAD Construction Corp. 3930 NW 26th Street Miami, FL 33142 Contact: Alan Janney Phone: (305) 871-6410 Fax: (305) 871-1293 2006 Trademark Metal Recycling Completion Date: January 2007 Amount: $365,820.00 Scope of work: Asphalt Pavement, Drainage Distribution. 2007 3939 NW 25th Street Completion Date: August 2007 Amount: $91,600.00 Scope of work: Storm Water Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. City of Sweetwater 500 SW 109th Avenue Sweetwater, FL 33174 Contact: Antero Espinosa Phone: (305) 221-0411 Fax: (305) 480 3849 2007 Various Locations Improvements (Drainage, Concrete & Asphalt Pavement). Amount: $55,786.25 Completion Date: July 2007 Kimley-Horn and Associates, Inc. 1691 Michigan Avenue Suite 400 Miami Beach, FL 33139 Contact: Walter Lugo Phone: (305) 673-2025 Fax: (305) 673-4882 2007 Retail Building 87th & Flagler Completion Date: August 2007 Amount: $3,500,000 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. Village of Pinecrest 12645 Pinecrest Parkway Pinecrest, Florida 33156 Contact: Daniel F. Moretti Phone: (305) 669-6916 Fax: (305) 669-6919 E-mail: moretti@pinecrest-fl.gov 2007 SW 79th Ave Roadway Improvements Completion Date: November 2007 Amount: $280,196.50 Scope of wone Storm Water System, Asphalt Pavement, Concrete Pavement. 2007 SW 70th Ave Improvements Completion Date: August 2007 Amount: $10,700.000 Scope of work: Storm Water System, Asphalt Pavement, Concrete Pavement. 2013 Pine Needle Lane & Rock Garden Storm Water Improvements Completion Date: March 2014 (Active) Amount: $1,012,000.00 Scope of Work: Storm Water System, Asphalt, Concrete Pavement KM Plaza Construction Services 120 NE 27th Street Suite 600 Miami, FL 33137 Contact: Robert Lalle Phone: (786) 693-8717 Fax: (786) 693-8738 2007 Town Center One at Dadeland Completion Date: December 2008 Amount: $490,000.00 Scope of work: Water Distribution, Storm Water Dist., Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. Miami-Dade County Aviation Department 4200 NW 36st Street, Building 5A Miami, FL Contact: Johnny Peterson Phone: E-mail: jpet@mikegconst.com MIA-NW 67th Ave & NW 36th Street Intersection Improvements Completion Date: October 2011 Value: $977,000.00 Scope: Storm Sewer Distribution and Roadway Reconstruction Miami-Dade County-Parks, Recreation, and Open Spaces Department 275 NW 2nd Street, 4th Floor Miami, FL 33128 Contact: Lydia Salas Phone: 305-755-5456 Fax: 305-755-7995 Cell: 786-586-8325 E-mail: Iydias@miamidade.gov 2007 Biscayne Garden Park Improvement Completion Date: November 2007 Amount: $329,601.10 Scope of work: Storm Water Dist., Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement Black Creek Trail Segment A-Phase I, II, and III Completion Date: August 2013 Amount: $2,054,514.45 Scope of Work: New Construction and Reconstruction of Bike Path, Miami Dade County Public Works Department 111 NW 1 Street Miami, FL 33128 Contact: Jesus Gonzalez Phone: 305 375 2172 2008 WASD Roadway Rehabilitation Contract Completion Date: June 2008 Amount: $323,000.00 Scope of work: Asphalt Pavement Miami Dade County Public Works Department 111 NW 1 Street Miami, FL 33128 Contact: Nestor Melian Phone: 786-375-0004 PTP Pavement Marking Installation Completion Date: October 2011 Amount: $ 356,572.78 Scope of Work: Pavement Markings 2008 gih Ave Roadway Widening Completion Date: January 2009 Amount: $ 514,615.63 Scope of work: Asphalt Pavement, Clearing, Grubbing, Earthwork, Utility Adjustments, Fencing & Guardrail, and Concrete 2013 Drainage Improvement Project for Multiple Sites-NE 91 Street and NE 87th Street From NE 10 Court to North Bayshore Drive Project No.: 20130156 Completion Date: 05/31/2014 Amount: $632,909.70 Scope of Work: Drainage Improvements on Multiple Sites Miami Dade County Water & Sewer Department 3071 SW 38 Ave, Miami, FL 33146 Contact: Nelson Cespedes Phone: 7865528142 E-mail: ncesp@miamidade.gov 2014 Furnish and Install 6", 8", and 10" DIP Force Main in NW 52nd Ave Completion Date: December 2014 Project Number: T1811 Amount: $775,281.75 Scope of Work: Water Main, Gravity Sewer and Force Main 2011 Perrine Cutler Ridge Water & Sewer Improvements Completion Date: December 2012 Project Number: TP0067 Amount: $2,254,103.10 Scope of Work: Water Main, Gravity Sewer and Force Main 2011 Furnish and Install 36-lnch 01 Water Main in NW 87th Ave Completion Date: December 2012 Project Number: T1562 Amount: $907,216.57 Scope of Work: Water Main, Gravity Sewer and Force Main Install 24" 01 Water Main Project Number: ER# 15865 Amount: $698,858.67 Scope of work: Water Distribution, Asphalt Pavement NAP Misc .-12 Sanitary Sewer Improvements Project Number: RPQ T1026 Amount: $ 838,558.26 Scope of work: Gravity Sewer, Force Main, Asphalt Pavement Restoration, Concrete City of South Miami 4795 SW 75th Avenue Miami, FL 33155 Contact: Ajibola Balogun Phone: (305) 668-7355 City Hall 12-lnch Water Main Extension Amount: $217,851.15 Scope of work: Water Distribution, Asphalt Pavement Citywide Resurfacing Project Phase II Project Number: SM-2011-16-PW Amount: $195,788.34 Scope of Work: Road Resurfacing, Milling, Clearing and Grubbing, Asphalt Placement, Retro Reflective Pavement Markers and Striping City of Miami 444 NW 2nd Ave, Miami, FL 33131 Contact: Eric Rush Phone: 954-682-9063 or 305-416-1298 E-mail: erush@miamigov.com Contact: Robert Fenton Phone: 786-263-2133 E-mail: rfenton@miamigov.com 2011 Kinloch Storm Sewer Improvements PH-II Completion Date: November 2011 Amount: $898,630.00 Scope of Work: Storm Sewer Distribution and Roadway Reconstruction 2013 Miami River Greenway NW 5th Street 8ridge Extension Project No.: 8-30336 Completion Date: October 2013 Amount: $896,818.25 Scope of Work: Road Improvements, Drainage System Installations, Milling and ResurfaCing, New Sidewalks replacement, Striping, Landscaping 2013 Citywide Storm Sewer Repair Contract Project No.: M-0083 Completion Date: February 2014 Amount: $995,855.00 Scope of Work: Storm Sewer Repair 2013 Silver 81uff Drainage Improvements Project No.: 8-30776 Completion Date: September 2013 Amount: $557,677.55 Scope of Work: Construction of New Drainage System 2013 DISTRCIT 3-Roadway, Traffic & Drainage Improvements Part II Project No.: 8-40300, 8-40303, 8-40310, 8-40311, 8-40317 Completion Date: February 2014 Amount: $343,301.15 Scope of Work: Road Improvements, Milling & Resurfacing, Drainage Improvements, Curb & Gutter, Sidewalk Repairs, Striping, Signs, and ADA ramp upgrades 2013 Garden Storm Sewers-Phase I Project No.: 830183 Completion Date: June 2014 Amount: $$776,678.50 Scope of Work: Design & Construction of Stormwater Drainage System, Milling & Resurfacing, Roadway Pavement, Reworking and Re-grading swales, Landscaping, Repair Sidewalks Port of Miami 1015 North America Way Miami, FL 33132 Contact: Bart Sanfilipo Phone: 305-347-4988/ Contact: Juan Bergouignan Phone: 305-347-4974 Contac: Kari Garland Phone: 305-347-3235 or 305-905-2714 E-mail: kari@miamidade.gov Scope of work: Various Site and Marine Construction Opa-Locka Head Start Facility Amount: $165,000.00 Scope of work: Water Distribution, Storm Water Dist., Excavation & Grading, Asphalt Pavement. 2012 Surface Lot E Taxi & Overflow Parking Lot Amount: $216,470.00 Completion Date: January 2013 Scope of work: Parking lot reconstruction, Asphalt Milling, New Asphalt, New Concrete YEMC Construction 14750 SW 24th Street Miami, FL Contact: Carlos Armas Phone: (305) 219 0862 Coral Way Offices Amount: $105,067.50 Scope of work: Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. Gamma Construction 4850 SW 72 Ave Miami, FL 33155 Contact: Jorge Jones Phone: 305 661 1569 Community Bible Baptist Church Amount: 214,417.00 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. VP Construction 7600 Red Rd #128 Miami FI33143 Contact: George Perendes Phone: (305) 667-6060 Valencia Village Amount: $218,276.50 Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt Pavement, Concrete Pavement. FOOT 1000 NW 111th Ave, Room 6203 Miami, FL 33172 Contact: John Botton Phone: 305-654-7019 Fax: 305-654-7020 Contact: Sunday Enegieru Phone: 305-640-7103 Cell: 305-986-2754 Roadway Improvements on SR 959 Coral Way to SW 22nd Street Amount $73,932.00 Scope of Worle Drainage, and Asphalt Restoration, Striping and Signage. Golden Glades Interchange Park & Ride Lot Project Number: E611 0 Amount: $1,336,493.07 Completion Date: September 2014 Scope of Work: Rehabilitation and Improvement of Parking Lot Alvarez Engineers, Inc. 10305 NW 41 Street Suite 103 Doral, FL 33178 Juan R. Alvarez 305-640-1345 E-mail: Juan.Alvarez@AlvarezEng.com Waterstone Way Amount $1,054,313.50 Scope of Work: Concrete, Drainage, Asphalt Striping, Manhole, Manhole, Sanitary Sewer, and 8" Water Main Beacon Tradeport Development District Amount $120,000 Scope of Work: Concrete City of OPA-LOCKA 780 Fisherman Street Opa-Locka, FL 33054 Contact: Nasir Mohammad Phone: 786-382-7917 Fax: 305-953-2824 Email: mnacir@opalockafl.gov 2012 NW 143rd Street Drainage & Roadway Improvements Project Completion Date: June 2013 Project Number: 11 ~2012100 Amount: $468,644.80 Scope of Work: Installation of new Drainage System, Road Rehabilitation, Repair and Renovations of existing Sidewalks 2013 Rutland Street Drainage Improvements Completion Date: May 2013 Project Number: 12~1607100 Amount: $127,850.00 Scope of Work: Drainage Improvements 2013 Burlington Drainage Improvements Completion Date: June 2013 Project Number: 12-1712200 Amount: $463,529.45 Scope of Work: Drainage Improvements City of Hollywood 2600 Hollywood Blvd. Hollywood,FL Contact: Clece Aurelus Phone: 954-805-3681 Fax: 954-921-3258 E-mail: caurelus@hollywoodfl.org 2012 Distribution Piping Upgrades on N 56 th Ave from Douglas Street to Stirling Road to N 58 th Ave. Completion Date: February 2013 Amount: $930,000.00 Scope of Work: 8" Water Main and Site Restoration City of Sunny Isles Beach 18070 Collins Avenue Sunny Isles Beach, FL 33160 Contact: Helen Gray, PE Phone: 305-792-1913 Fax: 305-792-1641 E-mail: hgray@sibfl.net 2013New Port Fishing Pier and Restaurant Utilities Completion Date: June 2013 Amount: $174,230.00 Scope of Work: 8" PVC Water Main Federal Highway Administration Eastern Federal Lands Highway Division 21400 Ridgetop Circle Sterling VA 20166-6511 Contact: Donald Mcintosh Phone: 305-242-n71 E-mail: donald.macintosh@dot.gov 2013 Everglades National Park Completion Date: December 2013 Amount: $850,000 Scope of Work: Resurfacing & Rehabilitation of 1.09 miles of A-Loop Road (NPS Route 220), 1.26 miles of Long Pine Key Access Road (NPS Route 228), Superpave Asphalt Concrete Pavement Overlay, Pavement Markings and other Miscellaneous Work. If you have any questions, please do not hesitate to contact us. Sincerely, Jose M. Alvarez, President JVA Engineering Contractor, Inc. ",'- 1/ • 01 Ii ~h , , , 0 f!hi , .., .... N i , N I W ~U~ .,--, I , un . ; , R ~INEERING ~AC"l"OlINC T~OFgV __ " :'-':<;l:L1)' E>QKERING ~ ,.. .... ilf ........ '"""-..iaa!~~ ~ ........... .V TAX 25000 0212-14(100.024 ocalBusiness Tax Receipt t --.... - EXPIRES c: OW SEC. T""" OF 8~" N '. WEERNGr -TOR 196 . GE ' ,. BULC TOR ~) 1 CGC1 2 -1 '" .J , .. u , . 1_ .;,. ...... 11 .. _ f4,..ic.. .. .t ' ,.-.HI.., ..... ........ ........... ---. .. Tu IIIa.r .0 .• c.4e ..... ~1l Ii.1 •• : .... 1.. 1tE:NO'WA L U7TS3 .g EXPI RES SEPTEMBER 30, 201 ow ..... ;· . SEC. riP'l OF .u.iINESS .: 196 S?ECiAzi, ENGI 'lfSIlNC ~.!.Cf 'AVMI!l'rt~ .Y TAX ~_ NA £Nq·:EERING CONfAACToR INC , 7 5.00 98/06 /10 13 Water(s) . cue 112:;{)9&, (1'222-1 ~824 '. no .. Lo.:al ....... ro. ~ onfy co"*-......... of ....... lAc", SUd .... TIL n.lI>ocoipl '-""01. No-. ·,.,..I\. ... ~un .... IIIiI""''''I~&f;: __ •• k&I ......... _ ...... willl.., ... ....-. ." ..... "._ ... 1 .. ;......" ..... 1M ............... 1IIIIIk~ .""............ . •. no. R£ctl" NO ...... _ •• ,".p~ .... 11._c~' ..... -... 1 .... Co4' ... ...,. hr .............. itIf ..-., .. .,.t .... I ....... Gi:m LocalSasiness Tax Receipt Mmmiw·O~Cc>unty. ,"\',f Hr ' ~ ~ 15 l1U f A lIIH .00 !!lOt I'M' ,.. ~*P'r1f!O. ow aliC_ TYPE OF a~_ EXPIReS TEMBEP 30 ,2014 .,~- JV'l , ,NEERNG ',:ntitRACTOR 196 SPE l \' Y PA'l'MItHT n ''; -'.0 aYfAXcQt"C 'QR ...c ~(Sl l ING -, E221 ;00 n;,OQ OI!IiO(I/J(t13 0'l22. 13-1XlOft2<1 nla t. ........... , ....... IlIy • .-,..... ...... LA .. I ....... ,.,. ...... .,1 ..... ,k._, ,.raIl ........ 6li ........ , •• ,-• .-_ .... l ... _. Hotl .. , _ c~ .. ~ .... _ ........ .. ..... .. ol .. ~,,""".d '.. ._ ....... "Hit .... '--. T .. IIRIIP'f.a.""_ ... ~ .... "'_I .. " ... -..... ~c ... s.~ .. .". ,. ........ ,. ...... -.... ,~-- STATE OF FLORIDA DBPARTMENT OF BUSINESS AND PROFBSSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD 1940 NORTH MONROB STRBBT TALLAHASSBE FL 32399-0783 ALVAREZ, JOSB M JVA BNGINBERING CONTRACTOR INC 6600 NW 32ND AVE MI~ FL 33147 Congratulations! Wfth this ~cense you become one of me nearly one million Floridians licensed by the Depat1JTlent of Business and Professional Regulation . Our professionals and businesses range from arcMects to yacht brokers. from boxers 10 baroeQue restaurants. and mey keep Flo rida 's e<:Of1omy s1tong . Ellery" day we woric to imprOll8 the way we do business In orde< to serve you bette'r For infonnation about our sBfVices. please log onto _.myftoridaflcen ••. com. There you C3f1 find moI'e information about our divisions and the regulations thai Impact you . subscribe to department newsletters and leam more about the Departmenrs initiatives , Our mission at the Department is: License Efficiently, Regulate Fairly. We I constantfy strive to serve you beUer so that you can serve your customers. I Thank you for doing business in Florida . and congratulations on your new license! I DETACH HERE \C# 6255900 STATE OF FLORIDA (850) 487-1395 STATE OF Ft.ORIOA AG# b 255 qOO DEPARTImNT OF BUSINESS AND PROFBSSIONAL REGULATION CUC1224696 ~'/O"12 118208900 ,. , CBRT UNDBRQaotJIID a IlXCAV CNTR ALVARBZ, JOar. :., . JVA BNGINIBRlNG COMTRACTOR INC . . .... : IS C.Jl.TIPIIlD Wl~r ttle pro"'iaioa.. of CII .• 89 "s _tcau,,", ...... , Aoo 31. 201. ['120B08Q1925 DEPARTMENT OF BUSINBSS AND PROFBSSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD The UNDERGROUND UTILITY • EXCAVATIQN CO Named below IS CBRTIFIED . . . ~, Onder the provisions of Chapter 489. PS. Expiration date: AUG 31, 2014 ALVARBZ, JOSE M JVA ENGINEBRING CONTRACTOR INC 6600 NW 32ND AVE MIAMI FL 33147 RICK SCOTT GOVERNOR DISPLAY AS REQUIRED BY LAW SEQ# L12080801925 KEN LAWSON SECRETARY STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD (850) 487-1395 1940 NORTH MONROE STREET TALLAHASSEB FL 32399-0783 ALVA.R.BZ, JOSB M JVA ENGINEERTNG CONTRACTOR INC 6600 NW 32ND AVE MIAMI FL 33147 Congrarulations! With this license you become one of the nearty one million Fl oridians ncensed by the Department of Business and Professional Regulation Our professionals and busmesses range from architects to yacht brokers. from boxers to barbeque restaurants. and they keep Florida's economy strong, , Every day we work to improve ttHJ way we do business in order to serve you betteA For infonnation about our services. please log onlo www.myflc:wldallcens •. com. j Th ere you can find mare information about our divisions and the regulations thaI I impact you . subscribe 10 department newsletters and learn more about the Department's in lli atives . Our mission at the Department is; license Efficiently , Regulate Fairty. We I constantly strive to serve you better so that you can serve your customers. Thank you for doing business in Florida . and congratulations on your new license!! DETACH HERE ._' •• t .C#6255463 STATE OF FLORIDA ---.-----------.--'''--''.-. ------_._- STATE OF FlOfMlA AC# b 2551., b 3 OBPARTMBHT OF BUSINBSS AND PROFBSS~OMAL REGULATION CGClS1684:9' 08/08/12 118208900 CERTIFIED G~ CONTRACTOR AL VARBZ , JOSS: Ii . ; JVA ENGINKftING COWl'RACTOR INC :: 5.' xs CDTIrxSD WlIUI: ttl. pro",1ai"". of 0..489 PS _luu_ ...... AUG 31. 1014 LllO&OS01488 ------~ ---~ .. --~ -. ----- DEPARTMENT OF BUSINESS AND PROFBSSIONAL REGULATION CONSTRUCTION INDUSTRY LICBNS.I .NG BOARD SEnM The GENERAL CONTRACTOR " Named below IS CBRTIFIED Under the provisions of Cha.pter .48" .. PS. Expiration date: AUG 31, 2014 ALVAREZ, JOSE M JVA ENGINEERING CONTRACTOR INC 6600 NW 32ND AVE KIAMI FL 33147 RICK SCOTT GOVERNOR DISPI AY AS. QJ;:(")llIoc::n ov I A'A, ~ L12080801488 KEN LAWSON SBCRETARY ~ ! DATE (IAMIODIYYYY] I I -12113113 THIS CERTIFICATE IS ISSUED AS A MATTER Of INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERT IFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND. EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE Of INSURANCE OOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(SI. AUTHORIZED ~ REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. , IMPORTANT; If the ""rtllb l" holder Is an ADDITIONAL INS URED. the p o llcy(lesJ must be ....,dorsad. If SUBROGATION IS WAIVED, s ubjl!d. to trnIlMm$ .nd conditions of the poUcy, certain policies rruoy require an endorsemenL A statement on this certificate does not confer rights 10 lhe I certificate holder In lieu of such endol'Sfit1e<\t{s). I PROOOCER ~~CT Herrisphef8 Insurance Group PItOfIE (305) 501-2801 I f~,No': (305} 553-901 0 eM< Nlz ~I . 11401 SW 40 Sl Sle 340 lo~sS hemispher9lnsgrp@aol com I Miami. FL 33165 lHSUfti'R f S \ IIFFOROOIG COliElUGE /Y<IC , i Phone (305) 501-2801 Fax (305 )553-9010 MAXUM INDEMNITY INSURANCE COMPANY J INSURER A: , INSURED INSURER B; FCC! INS COMPANY I . I JVA ENGINEERING CONTRACTORS INC IHSURER C SCOTTSDAlE INSURANCE COMPANY 1 6600 NW 32nd Ave IIISURER Q. BRIDGEFIELD CASUALTY INS COM -----.- I INSURER E 1 MIAMI. FL 33147 (305) 696-7902 INSURER F: - COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: B THIS IS TO CE Rn F-=-" THAT THE pOLICiES OF NsuRANCE LISTED BELOW HAVE BEEN ISSUED TO THE iNsuRED NMIED ASOVEFOR THE POLICY PERIOD INDICATED NOTWITHSTANDING ANY REQU!RE,-£NT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE iSSUED OR MAY PERTAIN. THE I'ISURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POliCES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. AUTOMOBILE LlASlurr ':t!.: ANY AUTO I-- ALL OV'JNED AUTOS :;j1 HIRED AUTOS I 1 yi SCHEDULED AUlOS Vi ~3~~NED COM61NEDEINGLE LIMIT 1 000 000 00 (E8_ ~C;;J~rr__ _' __ ' __ _ BOOll Y INJURY (Per pe<OOr.) 1211312014 I 1211312014 I BOOIl Y INJURY (po< OCCidenl 1 PROPERTY DAMAGE (Per~IL ._. _. t EACH OCCURRENCE j S 3,000.000 00 1 1211712013 112117/2014 A ~E~ATE ..! 3,~,OOO 00 1 l l V' UMBRELLA LIAS . OCCUR C 1'-~ EXCE~.~ CL ;"M5-</AOE L l..-1 OED ~ , RETENHON S 1312052 I WORKERS COMPEI'ISAnol'l I -:;'i fo'k~:.~% -. 9l}: AND EIIlPLOYERS' UABlUTY Y I ,. " I ANY PROI'RIETORll'ART>oIERl~H::UnvE 0830024596 E_L EACH ACCIDENT I S 1 000 000 00 o I OFFICERIMEMSEi'lE>CCWOEIT' [J N I A 1211312013 1211312014 1 .• . (1oI,.nd.tory In H~) E L DISEASE· EA EMPLOYE I S 1.000 ,000 00 ~ """ a.scn","uM", i I I D~StRIP ;lONOF O"~"llO"S t .. ,ow i 1 : E L DISEASE -POLICY LIMIT S 1.000 ,000 00 I .1 . . _ _ _ _ I I DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES I_h ACORD 101. Addldonal Romo",s ScMdulo .1f rnot1I .pac. Is required) CERTIFICATE HOLDER City of South Miami 6130 SUJ'\Se( Drive South Miami, FL 33143 ACORD 25 (2010105) OF --- CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOnCE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHOR~DREPRESEHTAnvE ~7</d~~~- © 1988-2010 ACORD CORPORATION. All rights reserved. The ACORD name and togo are registered marks of ACORD